Loading...
10/21/2009 AgreementDANNY L. KOLHAGE CLERK OF THE CIRCUIT COURT DA TE: October 26, 2009 TO: Lynda Stuart, Office Manager Tourist Development Council ATTN: Maxine Pacini Administrative Assistant 1101 FROM: Pamela G. Hancock, D. C. At the October 21, 2009, Board of County Commissioners meeting the Board granted approval and authorized execution of the following: Grant Award Agreement with Key West Botanical Garden Society, Inc. for the creation of the Miami Blue Butterfly Garden Project at the Key West Tropical Forest and Botanical Garden in an amount not to exceed $50,000, DAC I, FY 2010 Capital Resources. Grant Award Agreement with The Marathon Community Theatre, Inc. for their Remodel/Repair project in an amount not to exceed $9,550, DAC III, FY 2010 Capital Resources. Grant Award Agreement with Key West Film Society, Inc. for the Tropic Cinema Phase SA project p p oject in an amount not to exceed $75,000, DAC I, FY 2010 Capital Resources. Grant Award Agreement with Dolphin Research Center, Inc. for the facility improvements project in an amount not to exceed $17,900, DAC III, FY 2010 Capital Resources. Grant Award Agreement with Marine Mammal Conservancy, Inc. for the Marine Mammal Conservancy, Inc. for the Marine Mammal Conservancy Phase I project in an amount p not to exceed $74,985, DAC V, FY 2010 Capital Resources, Grant Award Agreement with City of Marathon for the Sombrero Beach Playground Equipment project in an amount not to exceed $25,000, DAC III, FY 2010 Capital Resources. Enclosed are two fully executed duplicate originals of the above -mentioned for your handling. Should you have any questions please feel free to contact our office. cc: County Attorney Finance File Grant Award Aareement /1Vd THIS AGREEMENT (Agreement) is entered into this ~ day of t:2J., 2009 by and between MONROE COUNTY, a political subdivision of the State of Florida (County or Grantor) and'the Marine Mammal Conservancy, Inc. a not for profit organization organized and operating under the laws of the state of Florida (Grantee). WHEREAS, the district pennies of Tourist Development Tax may be used to acquire, construct, extend, enlarge, remodel, repair or improve, convention centers, sports stadiums, sports arenas, coliseums, auditoriums, fishing piers, museums, zoological parks, nature centers, beach improvements and beach park facilities which are publicly owned and operated or owned and operated by not-for-profit corporations, and WHEREAS, Grantee has applied for funding for the Marine Mammal Conservancy Phase I project; and WHEREAS, the Grantor and Tourist Development Council (TDC) have determined that it is in the best interest of the County, for purposes of promoting tourism and preserving the heritage of the community, to attract tourists, and construct the property for use as a zoological park that is open to the public; NOW, THEREFORE, in consideration of the mutual covenants and payments contained herein, the Grantee and the Grantor have entered into this Agreement on the terms and conditions as set forth below. 1. GRANT AGREEMENT PERIOD. This Agreement is for the period of October 21, 2009 through to September 30, 2010. This Agreement shall remain in effect for the stated period unless one party gives to the other written notification of termination pursuant to and in compliance with paragraphs 7, 12 or 13 below. 2. SCOPE OF AGREEMENT. The Grantee shall provide the following scope of services: SeQment 1: Framing; Electrical; HVAC; Insulation and Drywall. Segment 2: Railings; Stucco; Tile; Painting; Plumbing; Electrical; Lift; Hot water system. Seament 3: Curb; Driveway; Gate. Segment(s) of the work is/are more particularly described in Exhibit(s) A, detailing the work and the cost allocable to each segment, attached hereto and incorporated herein by reference. All work for which grant funds are to be expended must be completed by the stated termination date of September 30, 2010 and all invoices pertaining to this project shall be submitted to the Finance Department of Monroe County no later than September 30, 2010 to be considered for payment. a) There shall be a project manager to acknowledge receipt of goods or work performed. This Project Manager shall be Robert Lingenfelser, PO Box 1625, Key Largo, FL 33037 (Telephone: 305-451-4774). Should there be a change in the project manager specified in the Grantee's application, a new project manager shall be designated and notice with new contact information shall be provided in writing to the TDC administrative office. Marine Mammal Conservancy FY 2010 Funding Contract 10#: 636 b) If, and to the extent that, Grantee contracts for any of the work funded under this Agreement to be performed or completed, Grantee shall give notice to County of the contractual relationship, provide County with a copy of any and all contracts and shall require the contractor(s) to comply with all the terms of this contract. Should Grantee contract the work and then decrease the scope of work to be performed by a contractor, Grantee shall provide County with an amended contract executed by Grantee and its contractor. (i) A Grantee which is a governmental entity shall comply with the procurement regulations and policies to which it is subject, and shall provide Grantor documentation of the procurement requirements applicable to the project and compliance therewith. (ii) A Grantee which is a not-for-profit entity shall undergo procurement processes for those parts of the project to be contracted (not performed by the entity's employees), which shall, at a minimum, require the acquisition of two written quotes for work expected to be under $25,000 or a notarized statement as to why such written quotes were not feasible. For work expected to be $25,000 or more, a competitive bid process must be performed. County procurement policies and procedures may be used by the Grantee as a guideline. c) Grantee shall exercise good internal controls to assure that the project as described in the funding application shall be completed on a timely basis within the proposed budget and shall provide to County any certifications, including those by the architect, engineer, contractor or an independent consultant if necessary, required to establish that materials which are purported to be applied to the project are in fact so applied. Further verification shall be required to show that equipment and other fixtures and personal property covered by this Agreement are delivered to and installed in the project site. When any permit is required by any governmental agency, copies of plans and other documents which are submitted to the applicable agency shall be submitted to the County Engineering Division to enable verification that the scope of services under this Agreement has been provided. 3. AMOUNT OF AGREEMENT AND PAYMENT. The Grantor shall provide an amount not to exceed $74,985 for materials and services used to improve the property. Reimbursement request must show that Grantee has paid in full for materials and services relating to the segment prior to seeking the 500/0 (fifty percent) reimbursement from Grantor. Payment shall be 50% (fifty percent) reimbursement of the total cost of the segment, subject to the cap on expenditures for that segment as set forth in Exhibit A. Reimbursement can be sought after each segment of the Agreement is completed and signed by the Monroe County Engineering Department as outlined in 3.a. The Board of County Commissioners and the Tourist Development Council assume no liability to fund this Agreement for an amount in excess of this award. Monroe County's performance and obligation to pay under this Agreement is contingent upon an annual appropriation by the BOCC. a) Payment shall be made upon the completion of a specific segment as outlined in the Scope of Services and Exhibit A. Payment for expenditures permissible by law and County Marine Mammal Conservancy FY 2010 Funding Contract 10#: 636 2 policies shall be made through reimbursement to Grantee upon presentation of Application for Payment Summary- AlA Document G702 or similar certification as required below for governmental entities and not-for-profit entities, invoices, canceled checks and other documentation necessary to support a claim for reimbursement. Included in said documentation shall be proof that the Grantee has received the property, realty or personally, for each segment of Agreement as outlined in Exhibit A and paid an amount equal to or greater than the amount invoiced to the Grantor. It shall be necessary for the Grantee to contact the County Engineering Division and to arrange for inspections upon the completion of each segment. The documentation needed to support the payment request shall be in the form necessary for submission and available to the County Engineer at the time of inspection. All submissions for payment shall have a proposed schedule of values for segment(s) and indicate the percentage of completion of the overall project as of the submission. This document should be signed by the project architect, engineer, general contractor or project manager. Photos of the progress of the work shall also be submitted with the payment application. It shall be the responsibility of the project architect, engineer, general contractor or project manager to initiate the communication with the Monroe County Engineering Division to facilitate the inspection(s) of the segment of the project. All submissions requesting payment shall be approved in writing, and signed, by the Monroe County Engineering Division as to the completion of the segment of the project for which payment is requested. The application for payment document must be certified through a statement signed by an officer of the organization and notarized, declaring that representations in the invoice are true and factual. Grantee shall also provide partial releases of liens or certifications of non-lien if applicable. Grantor shall retain 1 0% of any payment on work in progress until the Grantee has provided a Final Release of Lien for each vendor/Contractor for whom payment is requested. For projects exceeding $25,000 in TDC funding under this Agreement, final payment will not be made until the following documents are complete and submitted to the Grantor: AlA Document G-702 Application for Payment Summary AlA Document G-704 Certificate of Substantial Completion AlA Document G-706 Contractor's Affidavit of Debts & Claims AlA Document G-706A Contractor's Affidavit of Release of Liens AlA Document G-707 Consent of Surety to Final Payment (when applicable) Final Release of Lien or Affidavit and Partial Release of Lien For projects for which TDC funding under this Agreement is $25,000 or less, the AlA documentation is not required, but sufficient documentation must be submitted to County to provide similar assurances that the work has been completed and contractors/suppliers paid. All payment requests must be submitted no later than the completion of project of September 30, 2010. Invoices received after September 30, 2010 will not be considered for payment. Marine Mammal Conservancy FY 2010 Funding Contract 10#: 636 3 b) Documentation shall be submitted to the TDC Administrative Office to show the receipt and application of in-kind donations of goods, professional services, and materials. Said documentation should include invoices, bills of lading, etc., and be verified as received and applied to the project through a notarized statement of the project architect, engineer, general contractor or project manager. The receipt and application to the project of volunteer labor are to be documented and verified by notarized signature of the project architect, engineer, general contractor or project manager, and said documentation submitted to the TDC Administrative Office. All submissions shall identify the items included in Exhibit A and grantee shall complete the Application for Payment form which is provided within the payment/reimbursement kit provided to the grantee, listing the schedule of values which are sought to be reimbursed and shall indicate the percentage of completion of the overall project as of the submission. This document should be signed by the project architect, engineer, general contractor or project manager. Photographs showing progress on project shall be included in any payment request. The Project Manager shall certify delivery to the project site and installation therein of any goods or services provided other than through an architect, engineer or contractor. All work performed and goods received on site and incorporated into the project shall be verified by one of the foregoing. Submission of any documentation which is untrue, falsified, or otherwise misrepresents the work which has been completed, paid, or donated shall constitute a breach of agreement, for which breach the contract may be immediately terminated at the discretion of the County, whose decision shall be final. c) Grantee must submit all documentation for final payment on or before the termination date of this grant of September 30, 2010. Invoices received after September 30, 2010 will not be considered for payment. d) At any time that the documentation requirement policies of Monroe County are revised, such as to require annual inventory reports for equipment purchased under a TDC capital project grant, Grantee shall comply thereafter with such increased requirements, or further funding under the Agreement may be terminated by County. e) Upon successful completion of this Grant Agreement, the Grantee may retain ownership of the real and personal property acquired and/or improved with funding under this Grant Agreement. However, the Grantee shall maintain, preserve and operate the property which was acquired or improved under this Agreement for the uses and purposes which qualified the Grantee for tourist development tax funding. Grantee shall complete and sign a Property Reporting Form (provided within payment/reimbursement package) for personal property and forward said completed form with the appropriate invoice to the TDC Administrative Office. Real property acquired or improved through funding under this Agreement shall remain dedicated for the purposes set forth herein or for other purposes which promote tourism and ownership of said property shall be retained by the Grantee. The following terms shall apply: (i) The Grantee shall have the use of the property, including both realty and personally acquired with funding under this agreement, at the project site for so long as the facility is operated by Grantee, open to the public, and has a primary purpose of promoting tourism. Marine Mammal Conservancy FY 2010 Funding Contract 10#: 636 4 At such time as any of the conditions in the preceding sentence shall cease to exist, the Grantee shall transfer ownership and possession of equipment and personal property to a local government or another not-for-profit organization which is a facility for which tourist development taxes may be used pursuant to Florida Statute with prior approval from TDC and BOCC. (ii) At any time that the Grantee: (a) elects to stop the project or otherwise decide not to place into service for tourist-related purposes the facility acquired, constructed, or renovated with tourist development tax funding, (b) demolishes the project facility or divests itself of ownership or possession of the real property, or (c) ceases the use of the property with a primary purpose of promoting tourism, Grantee shall, pursuant to the formula set forth hereafter, refund to the County the Tourist Development funding. This provision shall survive the termination date of all other provisions of this contract for a period of ten years. Should the demolition, transfer of ownership, or change to a non-tourist related purpose occur after the facility has been used for tourist-related purposes for at least three (3) years, the amount of refund shall be pro-rated based on a useful life of ten (10) years. (iii) The Grantee is responsible for the implementation of adequate maintenance procedures to keep the real and personal property in good operating condition. (iv) The Grantee is responsible for any loss, damage, or theft of, and any loss, damage or injury caused by the use of, real or personal property or equipment purchased through funding under this Agreement. 4. RECORDS AND REPORTS. The Grantee shall keep such records as are necessary to document the performance of the Agreement and expenses as incurred, and give access to these records at the request of the TDC, the County, the State of Florida or authorized agents and representatives of said government bodies. The Grantee shall also provide such access to the personal property and equipment purchased under this Agreement. It is the responsibility of the Grantee to maintain appropriate records in accordance with generally accepted accounting principles consistently applied to insure a proper accounting of all funds and expenditures. The Grantee understands that it shall be responsible for repayment of any and all audit exceptions which are identified by the Auditor General for the State of Florida, the Clerk of Court for Monroe County, the Board of County Commissioners for Monroe County, or their agents and representatives. In the event of an audit exception, the current fiscal year grant award or subsequent grant awards will be offset by the amount of the audit exception. In the event the grant is not renewed or supplemented in future years, the Grantee will be billed by the Grantor for the amount of the audit exception and shall promptly repay any audit exception. (a) Public Access. The County and Grantee shall allow and permit reasonable access to, and inspection of, all documents, papers, letters or other materials in its possession or under its control subject to the provisions of Chapter 119, Florida Statutes, and made or received by the County and Grantee in conjunction with this Agreement; and the County shall have the right to unilaterally cancel this Agreement upon violation of this provision by Grantee. Marine Mammal Conservancy FY 2010 Funding Contract 10#: 636 5 5. MODIFICATIONS AND AMENDMENTS. Any and all modifications of the terms of this Agreement shall be only amended in writing and approved by the Board of County Commissioners for Monroe County. The terms, covenants, conditions, and provisions of this Agreement shall bind and inure to the benefit of the County and Grantee and their respective legal representatives, successors, and assigns. 6. INDEPENDENT CONTRACTOR. At all times and for all purposes hereunder, the Grantee is an independent contractor and not an employee of the Board of County Commissioners of Monroe County. No statement contained in this Agreement shall be construed as to find the Grantee or any of its employees, contractors, servants or agents to the employees of the Board of County Commissioners of Monroe County, and they shall be entitled to none of the rights, privileges or benefits of employees of Monroe County. (a) No Personal Liability. No covenant or Agreement contained herein shall be deemed to be a covenant or Agreement of any member, officer, agent or employee of Monroe County in his or her individual capacity, and no member, officer, agent or employee of Monroe County shall be liable personally on this Agreement or be subject to any personal liability or accountability by reason of the execution of this Agreement. 7. COMPLIANCE WITH LAW. In carrying out its obligations under this Agreement, the Grantee shall abide by all statutes, ordinances, rules and regulations pertaining to or regulating the provisions of this Agreement, including those now in effect and hereafter adopted. Any violation of said statutes, ordinances, rules or regulations shall constitute a material breach of this Agreement and shall entitle the Grantor to terminate this Agreement immediately upon delivery of written notice of termination to the Grantee. 8. RESTRICTIONS ON AGREEMENTS ENTERED PURSUANT TO THIS AGREEMENT. The Grantee shall include in all Agreements funded under this Agreement the following terms: a) Anti-discrimination. Contractor agrees that it will not discriminate against any employees or applicants for employment or against persons for any other benefit or service under this Agreement because of their race, color, religion, sex, national origin, or physical or mental handicap where the handicap does not affect the ability of an individual to perform in a position of employment, and to abide by all federal and state laws regarding non- discrimination. b) Anti-kickback. Contractor warrants that no person has been employed or retained to solicit or secure this Agreement upon an Agreement or understanding for a commission, percentage, brokerage or contingent fee, and that no employee or officer of the Contractor has any interest, financially or otherwise, in contractor. For breach or violation of this warranty, the Contractor shall have the right to annul this Agreement without liability or, in its discretion, to deduct from the Agreement price or consideration, the full amount of such commission, percentage, brokerage or contingent fee. Contractor acknowledges that it is Marine Mammal Conservancy FY 2010 Funding Contract 10#: 636 6 aware that funding for this Agreement is available at least in part through the County and that violation of this paragraph may result in the County withdrawing funding for the Project. c) Hold harmless/indemnification. Contractor acknowledges that this Agreement is funded at least in part by the County and agrees to indemnify and hold harmless the County and any of its officers and employees from and against any and all claims, liabilities, litigation, causes of action, damages, costs, expenses (including but not limited to fees and expenses arising from any factual investigation, discovery or preparation for litigation), and the payment of any and all of the foregoing or any demands, settlements or judgments (collectively claims) arising directly or indirectly from any negligence or criminal conduct on the part of Contractor in the performance of the terms of this Agreement. The Contractor shall immediately give notice to the County of any suit, claim or action made against the Contractor that is related to the activity under this Agreement, and will cooperate with the County in the investigation arising as a result of any suit, action or claim related this Agreement. d) Insurance. Contractor agrees that it maintains in force at its own expense a liability insurance policy which will insure and indemnify the Contractor and the County from any suits, claims or actions brought by any person or persons and from all costs and expenses of litigation brought against the Contractor for such injuries to persons or damage to property occurring during the Agreement or thereafter that results from performance by Contractor of the obligations set forth in this Agreement. At all times during the term of this Agreement and for one year after acceptance of the project, Contractor shall maintain on file with the County a certificate of the insurance of the carriers showing that the aforesaid insurance policy is in effect. The following coverage's shall be provided: 1. Workers Compensation insurance as required by Florida Statutes. 2. Commercial General Liability Insurance with minimum limits of $500,000 per occurrence for bodily injury, personal injury and property damage. 3. Comprehensive Auto Liability Insurance with minimum limits of $300,000 combined single limit per occurrence. The Contractor, the County and the TDC shall be named as additional insured, exempt workers compensation. The policies shall provide no less than 30 days notice of cancellation, non-renewal or reduction of coverage. At all times during the term of this Agreement and for one year after acceptance of the project, Contractor shall maintain on file with the County a certificate of insurance showing that the aforesaid insurance coverage's are in effect. e) Licensing and Permits. Contractor warrants that it shall have, prior to commencement of work under this Agreement and at all times during said work, all required licenses and permits whether federal, state, County or City. Marine Mammal Conservancy FY 2010 Funding Contract 10#: 636 7 f) Right to Audit. The Contractor shall keep such records as are necessary to document the performance of the Agreement and expenses as incurred, and give access to these records at the request of the TDC, the County, the State of Florida or authorized agents and representatives of said government bodies. 9. HOLD HARMLESS/INDEMNIFICATION. The Grantee hereby agrees to indemnify and hold harmless the BOCC/TDC and the 3406 North Roosevelt Blvd. Corporation or any of its officers and employees from and against any and all claims, liabilities, litigation, causes of action, damages, costs, expenses (including but not limited to fees and expenses arising from any factual investigation, discovery or preparation for litigation), and the payment of any and all of the foregoing or any demands, settlements or judgments arising directly or indirectly under this Agreement. The Grantee shall immediately give notice to the Grantor of any suit, claim or action made against the Grantor that is related to the activity under this Agreement, and will cooperate with the Grantor in the investigation arising as a result of any suit, action or claim related to this Agreement. (a) Non-Waiver of Immunity. Notwithstanding he provisions of Sec. 768.28, Florida Statutes, the participation of the County and the Grantee in this Agreement and the acquisition of any commercial liability insurance coverage, self-insurance coverage, or local government liability insurance pool coverage shall not be deemed a waiver of immunity to the extent of liability coverage, nor shall any contract entered into by the County be required to contain any provision for waiver. (b) Privileges and Immunities. All of the privileges and immunities from liability, exemptions from laws, ordinances, and rules and pensions and relief, disability, workers' compensation, and other benefits which apply to the activity of officers, agents, or employees of any public agents or employees of the County, when performing their respective functions under this Agreement within the territorial limits of the County shall apply to the same degree and extent to the performance of such functions and duties of such officers, agents, volunteers, or employees outside the territorial limits of the County. 1 o. NONDISCRIMINATION. County and Grantee agree that there will be no discrimination against any person, and it is expressly understood that upon a determination by a court of competent jurisdiction that discrimination has occurred, this Agreement automatically terminates without any further action on the part of any party, effective the date of the court order. County or Grantee agree to comply with all Federal and Florida statutes, and all local ordinances, as applicable, relating to nondiscrimination. These include but are not limited to: 1) Title VI of the Civil Rights Act of 1964 (PL 88-352) which prohibits discrimination on the basis of race, color or national origin; 2) Title IX of the Education Amendment of 1972, as amended (20 use SSe 1681-1683, and 1685-1686), which prohibits discrimination on the basis of sex; 3) Section 504 of the Rehabilitation Act of 1973, as amended (20 use s. 794), which prohibits discrimination on the basis of handicaps; 4) The Age Discrimination Act of 1975, as amended (42 use SSe 6101-6107) which prohibits discrimination on the basis of age; 5) The Drug Abuse Office and Treatment Act of 1972 (PL 92-255), as amended, Marine Mammal Conservancy FY 2010 Funding Contract 10#: 636 8 relating to nondiscrimination on the basis of drug abuse; 6) The Comprehensive Alcohol Abuse and Alcoholism Prevention, Treatment and Rehabilitation Act of 1970 (PL 91-616), as amended, relating to nondiscrimination on the basis of alcohol abuse or alcoholism; 7) The Public Health Service Act of 1912, ss. 523 and 527 (42 USC ss. 690dd-3 and 290ee-3), as amended, relating to confidentiality of alcohol and drug abuse patent records; 8) Title VIII of the Civil Rights Act of 1968 (42 USC s. et seq.), as amended, relating to nondiscrimination in the sale, rental or financing of housing; 9) The Americans with Disabilities Act of 1990 (42 USC s. 1201 Note), as maybe amended from time to time, relating to nondiscrimination on the basis of disability; 10) Any other nondiscrimination provisions in any Federal or state statutes which may apply to the parties to, or the subject matter of, this Agreement. 11. ANTI-KICKBACK. The Grantee warrants that no person has been employed or retained to solicit or secure this Agreement upon an agreement or understanding for a commission, percentage, brokerage or contingent fee, and that no employee or officer of the County or TDC has any interest, financially or otherwise, in the said funded project, except for general membership. For breach or violation of this warranty, the Grantor shall have the right to annul this Agreement without liability or, in its discretion, to deduct from the Agreement price or consideration, the full amount of such commission, percentage, brokerage or contingent fee. 12. TERMINATION. This Agreement shall terminate on September 30, 2010. Termination prior thereto shall occur whenever funds cannot be obtained or cannot be continued at a level sufficient to allow for the continuation of this Agreement pursuant to the terms herein. In the event that funds cannot be continued at a level sufficient to allow the continuation of this Agreement pursuant to the terms specified herein, this Agreement may then be terminated immediately by written notice of termination delivered in person or by mail to Grantee. The Grantor may terminate this Agreement without cause upon giving written notice of termination to Applicant. The Grantor shall not be obligated to pay for any services or goods provided by Grantee after Grantee has received written notice of termination. 13. TERMINATION FOR BREACH. The Grantor may immediately terminate this Agreement for any breach of the terms contained herein. Such termination shall take place immediately upon receipt of written notice of said termination. Any waiver of any breach of covenants herein contained to be kept and performed by Grantee shall not be deemed or considered as a continuing waiver and shall not operate to bar or prevent the Grantor from declaring a forfeiture for any succeeding breach either of the same conditions or of any other conditions. Failure to provide Grantor with certification of use of matching funds or matching in-kind services at or above the rate of request for reimbursement or payment is a breach of Agreement, for which the Grantor may terminate this Agreement upon giving written notification of termination. 14. ENTIRE AGREEMENT. This Agreement constitutes the entire Agreement of the parties hereto with respect to the subject matter hereof and supersedes any and all prior Agreements with respect to such subject matter between the Grantee and the Grantor. Marine Mammal Conservancy FY 2010 Funding Contract 10#: 636 9 15. GOVERNING LAW, VENUE, INTERPRETATION, COSTS, AND FEES. This Agreement shall be governed by and construed in accordance with the laws of the State of Florida applicable to contracts made and to be performed entirely in the State. This Agreement is not subject to arbitration. Mediation proceedings initiated and conducted pursuant to this Agreement shall be in accordance with the Florida Rules of Civil Procedure and usual and customary procedures required by the circuit court of Monroe County. (a) Venue. In the event that any cause of action or administrative proceeding is instituted for the enforcement or interpretation of this Agreement, the County and Grantee agree that venue shall lie in the appropriate court or before the appropriate administrative body in Monroe County, Florida. (b) Severability. If any term, covenant, condition or provision of this Agreement (or the application thereof to any circumstance or person) shall be declared invalid or unenforceable to any extent by a court of competent jurisdiction, the remaining terms, covenants, conditions and provisions of this Agreement, shall not be affected thereby; and each remaining term, covenant, condition and provision of this Agreement shall be valid and shall be enforceable to the fullest extent permitted by law unless the enforcement of the remaining terms, covenants, conditions and provisions of this Agreement would prevent the accomplishment of the original intent of this Agreement. The County and Grantee agree to reform the Agreement to replace any stricken provision with a valid provision that comes as close as possible to the intent of the stricken provision. (c) Attorney's Fees and Costs. The County and Grantee agree that in the event any cause of action or administrative proceeding is initiated or defended by any party relative to the enforcement or interpretation of this Agreement, the prevailing party shall be entitled to reasonable attorney's fees, court costs, investigative, and out-of-pocket expenses, as an award against the non-prevailing party, and shall include attorney's fees, courts costs, investigative, and out-of-pocket expenses in appellate proceedings. (d) Adjudication of Disputes or Disagreements. County and Grantee agree that all disputes and disagreements shall be attempted to be resolved by meet and confer sessions between representatives of each of the parties. If the issue or issues are still not resolved to the satisfaction of the parties, then any party shall have the right to seek such relief or remedy as may be provided by this Agreement or by Florida law. This agreement shall not be subject to arbitration. (e) Cooperation. In the event any administrative or legal proceeding is instituted against either party relating to the formation, execution, performance, or breach of this Agreement, County and Grantee agree to participate, to the extent required by the other party, in all proceedings, hearings, processes, meetings, and other activities related to the substance of this Agreement or provision of the services under this Agreement. County and Grantee Marine Mammal Conservancy FY 2010 Funding Contract 10#: 636 10 specifically agree that no party to this Agreement shall be required to enter into any arbitration proceedings related to this Agreement. 16. ETHICS CLAUSE: Grantee warrants that he has not employed, retained or otherwise had act on his behalf any former County officer or employee in violation of Section 2 or Ordinance No. 1 0-1990 or any County officer or employee in violation of Section 3 of Ordinance No. 10-1990. For breach or violation of the provision the Grantor may, at its discretion terminate this Agreement without liability and may also, at its discretion, deduct from the Agreement or purchase price, or otherwise recover, the full amount of any fee, commission, percentage, gift, or consideration paid to the former or present County officer or employee. The County and Grantee warrant that, in respect to itself, it has neither employed nor retained any company or person, other than a bona fide employee working solely for it, to solicit or secure this Agreement and that it has not paid or agreed to pay any person, company, corporation, individual, or firm, other than a bona fide employee working solely for it, any fee, commission, percentage, gift, or other consideration contingent upon or resulting from the award or making of this Agreement. For the breach or violation of the provision, the Grantee agrees that the County shall have the right to terminate this Agreement without liability and, at its discretion, to offset from monies owed, or otherwise recover, the full amount of such fee, commission, percentage, gift, or consideration. (a) Covenant of No Interest. County and Grantee covenant that neither presently has any interest, and shall not acquire any interest, which would conflict in any manner or degree with its performance under this Agreement, and that only interest of each is to perform and receive benefits as recited in this Agreement. (b) Code of Ethics. County agrees that officers and employees of the County recognize and will be required to comply with the standards of conduct for public officers and employees as delineated in Section 112.313, Florida Statutes, regarding, but not limited to, solicitation or acceptance of gifts; doing business with one's agency; unauthorized compensation; misuse of public position, conflicting employment or contractual relationship; and disclosure or use of certain information. 17. PUBLIC ENTITY CRIME STATEMENT: A person or affiliate who has been placed on the convicted vendor list following a conviction for public entity crime may not submit a bid on an Agreement to provide any goods or services to a public entity, may not submit a bid on a Agreement with a public entity for the construction or repair of a public building or public work, may not submit bids on leases of real property to publiC entity, may not be awarded or perform work as a contractor, supplier, sub-contractor, or consultant under a Agreement with any public entity, and may not transact business with any publiC entity in excess of the threshold amount provided in Section 287.017, Florida Statutes, for CATEGORY TWO for a period of 36 months from the date of being placed on the convicted vendor list. By executing this document grantee warrants that it is in compliance with this paragraph. Marine Mammal Conservancy FY 2010 Funding Contract 10#: 636 11 18. AUTHORITY: Grantee warrants that it is authorized by law to engage in the performance of the activities encompassed by the project herein described. Each of the signatories for the Grantee below certifies and warrants that the Grantee's name in this Agreement is the full name as designated in its corporate charter (if a corporation); they are empowered to act and contract for the Grantee, and this Agreement has been approved by the Board of Directors of Grantee or other appropriate authority. 19. LICENSING AND PERMITS: Grantee warrants that it shall have, prior to commencement of work under this Agreement and at all times during said work, all required licenses and permits whether federal, state, County or City. 20. INSURANCE: Grantee agrees that it maintains in force at its own expense a liability insurance policy which will insure and indemnify the Grantee and the Grantor from any suits, claims or actions brought by any person or persons and from all costs and expenses of litigation brought against the Grantee for such injuries to persons or damage to property occurring during the Agreement or thereafter that results from performance by Grantee of the obligations set forth in this Agreement. At all times during the term of this Agreement and for one year after acceptance of the project, Grantee shall maintain on file with the Grantor a certificate of the insurance of the carriers showing that the aforesaid insurance policy is in effect. The following coverage's shall be provided: 1. Workers Compensation insurance as required by Florida Statutes. 2. Commercial General Liability Insurance with minimum limits of $500,000 Combined Single Limit (CSL) If split limits are provided, the minimum limits acceptable shall be $250,000 per Person $500,000 per occurrence $50,000 property damage. 3. Comprehensive Auto Liability Insurance with minimum limits of $300,000 combined single limit per occurrence. 4. The Contractor shall be required to purchase and maintain, throughout the life of the contract, and until the project is accepted by the County, Builder's Risk Insurance on an All Risk of Loss form. Coverage shall include: Theft Windstorm Hail Explosion Riot Civil Commotion Aircraft Vehicles Smoke Fire Collapse Flood The policy limits shall be no less than the amount of the finished project and coverage shall be provided on a completed value basis. Property located on the construction premises, which is intended to become a permanent part of the building, shall be included as property covered. Marine Mammal Conservancy FY 2010 Funding Contract 10#: 636 12 The policy shall be endorsed permitting the County to occupy the building prior to completion without affecting the coverage. The Monroe County Board of County Commissioners shall be named as Additional Insured and Loss Payee. The Grantee, the Grantor and the TDC shall be named as additional insured, except workers compensation. The policies shall provide no less than 30 days notice of cancellation, non- renewal or reduction of coverage. Grantee shall provide, to the County, as satisfactory evidence of the required insurance, including the insurance policy application and either: · Original Certificate of Insurance or · Certified copy of the actual insurance policy Or · Certificate of Insurance e-mailed from Insurance Agent/Company to County Risk Management - Telephone Maria Slavik at 295-3178 for details (Certificates can be e-mailed directly from the insurance agency to: Slavik-Maria @ MonroeCountv-FL.Gov - The e-mail must state that this is a certificate for a TOC project and should be forwarded to Maxine Pacini at the TOC administrative office) An original certificate or a certified copy of any or all insurance policies required by this contract shall be filed with the Clerk of the BOCC prior to the contract being executed by the Clerks office. The Insurance policy must state that the Monroe County BOCC and Monroe County TOC is the Certificate Holder and additional Insured for this contract. Insurance should be mailed to: Monroe County Board of County Commissioners C/O Risk Management P.O. Box 1026 Key West, FL 33041 21. NOTICE. Any notice required or permitted under this agreement shall be in writing and had delivered or mailed, postage prepaid, to the other party by certified mail, returned receipt requested to the following: For Grantee: Robert Lingenfelser PO Box 1625 Key Largo, FL 33037 Marine Mammal Conservancy FY 2010 Funding Contract 10#: 636 13 For Grantor: Lynda Stuart Monroe County Tourist Development Council 1201 White Street, Suite 102 Key West, FL 33040 and Cynthia Hall, Asst. County Attorney P.O. Box 1026 Key West, FL 33041-1026 22. CLAIMS FOR FEDERAL OR STATE AID. Contractor and County agree that each shall be, and is, empowered to apply for, seek, and obtain federal and state funds to further the purpose of this Agreement; provided that all applications, requests, grant proposals, and funding solicitations shall be approved by each party prior to submission. 23. NON-DELEGATION OF CONSTITUTIONAL OR STATUTORY DUTIES. This Agreement is not intended to, nor shall it be construed as, relieving any participating entity from any obligation or responsibility imposed upon the entity by law except to the extent of actual and timely performance thereof by any participating entity, in which case the performance may be offered in satisfaction of the obligation or responsibility. Further, this Agreement is not intended to, nor shall it be construed as, authorizing the delegation of the constitutional or statutory duties of the County, except to the extent permitted by the Florida constitution, state statute, and case law. 24. NON-RELIANCE BY NON-PARTIES. No person or entity shall be entitled to rely upon the terms, or any of them, of this Agreement to enforce or attempt to enforce any third- party claim or entitlement to or benefit of any service or program contemplated hereunder, and the County and the Grantee agree that neither the County nor the Grantee or any agent, officer, or employee of either shall have the authority to inform, counsel, or otherwise indicate that any particular individual or group of individuals, entity or entities, have entitlements or benefits under this Agreement separate and apart, inferior to, or superior to the community in general or for the purposes contemplated in this Agreement. 25. ATTESTATIONS. Grantee agrees to execute such documents as the County may reasonably require, to include a Public Entity Crime Statement, an Ethics Statement, and a Drug-Free Workplace Statement. 26. NO PERSONAL LIABILITY. No covenant or Agreement contained herein shall be deemed to be a covenant or Agreement of any member, officer, agent or employee of Monroe County in his or her individual capacity, and no member, officer, agent or employee of Monroe County shall be liable personally on this Agreement or be subject to any personal liability or accountability by reason of the execution of this Agreement. Marine Mammal Conservancy FY 20 10 Funding Contract 10#: 636 14 27. FORCE MAJEURE. The Grantee shall not be liable for delay in performance or failure to complete the project, in whole or in part, due to the occurrence of any contingency beyond its control or the control of its contractors and subcontractors, including war or act of war whether an actual declaration thereof is made or not, act of terrorism impacting travel in the United States, insurrection, riot or civil commotion, act of public enemy, epidemic, quarantine restriction, storm, flood, drought or other act of God, or act of nature (including presence of endangered animal species which cannot be timely removed in a safe manner or any act of any governmental authority which prohibits the project from proceeding as described in the scope of services and incorporated references and which the Grantee has exercised reasonable care in the prevention thereof. However, lack of planning for normal and expected weather conditions for the time of year the project is to be executed shall not constitute an act of God excusing a delay. Any delay or failure due to the causes stated shall not constitute a breach of the Agreement; however, the SOCC shall have the right to determine if there will be any reduction to the amount of funds due to the Grantee after consideration of all relevant facts and circumstances surrounding the delay in performance or failure to complete the project within the contract period. Upon demand of TOe or SOCC, the Grantee must furnish evidence of the causes of such delay or failure. soce shall not pay for any goods received or services provided after the date(s) described in paragraph 1 and Scope of Services. 28. EXECUTION IN COUNTERPARTS. This Agreement may be executed in any number of counterparts, each of which shall be regarded as an original, all of which taken together shall constitute one and the same instrument and any of the parties hereto may execute this Agreement by singing any such counterpart. 29. SECTION HEADINGS. Section headings have been inserted in this Agreement as a matter of convenience of reference only, and it is agreed that such section headings are not a part of this Agreement and will not be used in the interpretation of any provision of this Agreement. REMAINDER OF THIS PAGE INTENTIONALLY LEFT BLANK Marine Mammal Conservancy FY 2010 Funding Contract 10#: 636 15 IN WITNESS WHEREOF, the parties hereto have caused this Agreement to be executed the day and year first above written. (C~PORATE$~~).. Attest.if}! By. . ~'^-CL r"- L. C I v"^- b Print Name Date: g / / fJI /.j. oo,? OR TWO WITNESSES (1 ) (1 ) Print Name Date: Marine Mammal Conservancy FY 2010 Funding Contract /D#: 636 Board of County Commissioners of Monroe County ~~ ~4 nolA4.'~ Mayor/Chairman Marin. Mammal Conservancy, Inc. By /JJ#C PresJdent\vf 12~G bf'tJ~~4'~IL~, Print Name Date: fir 1i1{U41 ,i?1Je>9 (2) :1: r:J ~~.~ (2) Print Name {".to1 ~."I;;"'4 .:. ;~~) C) :,,--:, :;?:~ ~ .-- ,~-~) :c :< :-i :t> -'q · C'.> r-' ~ f'Tl Date: ~ -r"1 ~ r- C) fT1 n 0 -t N ." o 0'\ :::0 > :::0 ::c fT1 C"') W 0 (..) ::0 N 0 MONROE COUNTY ATTORNEY APrf/io:rF: y H IA . AL ASSISTANT COUNTY ATTORNEY Date e - ~ - ;1.0f)' 16 <( I- - CD - :J: >< LLI u c: u c: o > ~ Q) en C o U+- - U o Q) E .0 EO: o~ ~ Q) Q) en c: 0 .- ..c ~a.... o ~ .. ~ .. U >w ~ .., i=0 ZO=: W A- u.. u.. 00 ww ~~ <C<C zz e (1).2 o .. ..... ..... c: c: Cb Cb E E Q).... Cb 0 (l)Q.. ..c: ... u.2 o c: Cb 0 "- .~ 00 c:.~ 0-- .~ Q. .....Q. .!!~ Q... E Cb O:E UO) ... c: Cb.~ 'S:s -i: ,,~ Cb..... ~ c: o Cb ==E o Cb )....~ --~ ~.Q ..... E c:... Cb e E ... Cb.2 M ...: -. )....... ~--~ C0 .Q Q.:: E Q. c: . . ... 0 Cb l-e~E U"'~Cb w.2e~ 0-, c: Cb ~ o .Q Ck: ... .S! E a.... ~ c: ... o "e e : I-.Q~:;::' ~ . c: V)(I):t::Cb z":SE w c:..c: ).... ~o><o .c:::::It::CbQ.. (j o.~ Cb w ~:E:E V) ... c: c: (I)... ... LL ~" ..c: o ~"" Cb :t:: c: ..... ~ ~~c:~ WOCb" a:lUeCb ~Gi~-g ~ .....1 u -- -JOoU Z Z " .5 c: o += :-. o a.... U o I- Q) :) o > '+- o Q) :) -0 Q) ..c U V) :-:1 ::t:I: +- C Q) E 0) Q) V) c o += ..c 0)-0 :) c: ~ 0 ." c o 0 u+= .C 0 +- - U :) Q) C w-:-:, ..cU 0)<( :)> OI Ck: . " ..c 0)0) c: :) .- 0 ECk: o ." L1:0) c:- ..c .- - 0).0 0 :)E~ o :) :-. ~a....O .C U en Q) o . o q 0--. "-0 Ll) M '+- o Q) 0> o a.... u o I- o q co C0 C0 ~ +- en o U o +- o I- <C I- - ~ - :I: >< w c o += '-- o a.... U o r- o o ~ ~ N M (V") '+- o N Q) 0> o a.... u o r- -------------------------------------------------------------------------------------------------- CD :::> o > '+- o CD :::> -0 CD ..c U V) ~I =#: ~ C CD E 0) CD V) C o += '-- .Q 'E '-- V) 2~CD ><:::>~ LU~V) >< >- 06U::V) '----0 o 0 c .C U 0 CD .- ~.;::E c u CD --:,CDO CD LU C i-= vl 0 , CD ~ o '-- CD u.2~ u >< 0 .2U::~ V) O)~ , C 0 &:0 I CE";"":- :.= '+- .0 :::> ~ ~ a.... 0.. -0 d> 0 CD C .S:2 =+=-0 .E .~ C V) 0 0 Ca....I .C U V) CD o o o N ~ M ~ ~ ~ V) o U o ~ o r- <C I- - a3 - ::I: >< w c: o ~ s..... o a.... U o t- (1)- :J o > '+- o (1) :J -0 (1) .r::. U V) C01 ~ ~ c: (1) E 0) (1) V) .C U V) (1) o o o o N N (V) '+- o (V) Q) Q) a a.. u o t- o q o ~ l.{) l.{) ~ ~ V) o U o ~ o t- --=:"-0 >-(1) o > ~ 0 .r::.a.... .0) -0 I c: V) 0 000) ~ (1) c s..... s......_ ~(1)<(U s..... > 0) c: OOc:(1) ~ ~:,Q LL 0)'- s..... (1) c:V)Oa . - ::) a.... I F'\ Q.. ... v OC:>-'" uOOO) V)~~c: -o:J(1):,Q c:U>5.... o .C 0 --.J-eOa.... -0 :J ~ Q.. (1)UUO ~ OU ~ ~ .- .- v O!: -0 ~ ~ 0 c (1) 0 (1) 0 a.... a.... a.... I ACORQ CERTIFICATE OF LIABILITY INSURANCE DATE IMLUDOMW) 10/01/2009 PRODUCER 305.852.3234 FAX 305.852.3703 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION Regan Insurance Agency, Inc. ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE 90144 Overseas Hwy• HOLDER.THIS CERTIFICATE DOES NOT AMEND,EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. Tavernier, FL 33070 INSURERS AFFORDING COVERAGE NAIC# INSURED Marine Mammal Conservancy INSURER A: Markel International Ins Co Lt PO Box 1625 INSURER B: Key Largo, FL 33037 INSURER C. INSURER P INSURER E: COVERAGES THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED.NOTWITHSTANDING ANY REQUIREMENT,TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN,THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS.EXCLUSIONS AND CONDITIONS OF SUCH POLICIES.AGGREGATE LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR AMYL POLICY EFFECTIVE POLICY EXPIRATION LTR NERD TYPE OF INSURANCE POLICY NUMBER DATE IMMIDDIYYYY) DATE IMMAD/YYVY) LIMITS GENERAL LJABIUTY MKFS281 09/29/2009 09/29/2010 EACH OCCURRENCE $ 1,000,000 COMMERCIAL GENERAL LIABILITY PREMISES(Ea oREmr ce) $ CLAIMS MADE X OCCUR MED EXP(My one person) $ A X X Owners & Contracto PERSONAL&ADV INJURY $ GENERAL AGGREGATE S 2,000,000 II GEN'L AGGREGATE LIMIT APPLIES PER PRODUCTS.COMP/OP AGG $ POLICY PRO LOC JECT AUTOMOBILE LNBIUTY COMBINED SINGLE LIMIT ANY AUTO (En&cadent) E ALL OWNED AUTOS BODILY INJURY $ SCHEDULED AUTOS (Per Pe,em) HIRED AUTOS BODILY INJURY NON-OWNED AUTOS L ` , (Per accident) $ 'D I — PROPERTY DAMAGE $ (Per accident) GARAGE LIABILITY , AUTO ONLY-EA ACCIDENT $ ANY AUTO OTHER THAN EA ACC $ AUTO ONLY: AGG $ EXCESSI UMBRELLA MABIUTY EACH OCCURRENCE $ OCCUR CLAIMS MADE AGGREGATE $ DEDUCTIBLE $ RETENTION $ $ WORKERS COMPENSATION WL BTA16 MN- AND EMPLOYERS'UABILRY YIN TORY LIMITS ER ANY PROPRIETORJPARTNERIEXECUTIVEn E L EACH ACCIDENT $ OFFICERMEMBER EXCLUDED? (Mandatory In NM) E L.DISEASE-EA EMPLOYEE $ Ify deamde ands SPECIAL PROVISIONS below E L DISEASE.POLICY LIMO $ ovum MKF5281 09/29/2009 05/01/2010 Total Cost 5154,000 Builders Risk-Property A Basic Form, 100% coinsurance -..-.... ..�..O. �. /LDCATIONS/VEHICLES/EXCLUSIONS ADDED BY ENDORSEMENT/SPECIAL PROVISIONS 102200 Overseas Highway, Key Largo, Fl 33037 :ertificate holder is shown as an additional insured per policy forms, conditions, limitations and exclusions CERTIFICATE HOLDER CANCELLATION SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF,THE ISSUING INSURER WILL ENDEAVOR TO MAIL 10 DAYS WRITTEN NOTICE TO THE CERTIFICATE HOLDER NAMED TO THE LEFT,BUT FAILURE TO DO SO SHALL IMPOSE NO OBLIGATION OR LIABILITY OF ANY KIND UPON THE INSURER.ITS AGENTS OR Monroe County BOCC & TDC REPRESENTATIVES. PO Box 1026 AUTHORIZED REPRESENTAUVE 9/ ,� 0 Keyl West, FL 33041-1026 John Crowell/BMONRO �/4"1"1 ACORD 25(2009/07) FAX: 305.295.3179 ©1988-2009 ACORD CORPORATION. All rights reserved. The ACORD name and logo are registered marks of ACORD 19%Edition MONROE COUNTY,FLORIDA Request For Waiver of Insurance Requirements It is requested that the insurance requirements,as specified in the County's Schedule of Insurance Requirements,be waived or modified on the following contract. Contractor: Marine Mammal Conservancy,Inc. Contract for: Completion of the construction of Phase I of the Marine Mammal Conservancy. TIC Monies will be used to reimburse MMC for documented expenses to suppliers,the General Contractor,subcontractors and MMC related construction expenses. Address of Contractor: Mailing: PO Box 1625;Key Largo, FL 33037 _Physical: 102200 Overseas Hwy; Key Largo, FL 33037 Phone: 305-451-4774 Scope of Work: Completion of the interior of the building including the electrical/plumbing and HVAC Systems,stucco/painting of the exterior of the two buildings,installation of the Curb Cut on US 1/Driveway/Parking Lot,Installation of the connection/lift/pump station and pipeline to tie into the Key Largo Waste Water Treatment System,Installation of a new Gate Fence,and landscaping. Reason for Waiver: NO WORKERS COMPENSATION The Marine Mammal Conservancy is all volunteer and has no paid staff. Volunteers do sign waivers and hold harmless agreements in order to participate in MMC sponsored activities._ Policies Waiver will apply to:_Marine Mammal Conservancy,Inc and all of its volunteers Signature of Contractor: Aoki/g£ingenfeta JA President Apro^v,(e I Not Approved Risk Management: U I \\,,,,ll ����rr Date: ,C7lVv) County Administrator Appeal: Approved Not Approved Date: Board of County Commissioners Appeal: Approved Not Approved Meeting Date: ACORQI CERTIFICATE OF LIABILITY INSURANCE DATE'MYW 07/21/2009 PRODUCER (305)852-3234 FAX (305)852-3703 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION Regan Insurance Agency, Inc. ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER.THIS CERTIFICATE DOES NOT AMEND,EXTEND OR 90144 Overseas Hwy. ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. Tavernier, FL 33070 INSURERS AFFORDING COVERAGE NAIC e INSURED Marine Mammal Conservancy INSURER A'. Western World Insurance Co 13196 PO Box 1625 INSURERS Key Largo, FL 33037 INSURERC. INSURER D. I INSURERE'. COVERAGES THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED.NOTWITHSTANDING ANY REQUIREMENT,TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN,THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS,EXCLUSIONS AND CONDITIONS OF SUCH POLICIES.AGGREGATE LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. CY EXPIRATION LNTR INSRD TYPE OF INSURANCE POLICY NUMBER IATEC(MWDWYYY) DAAIVE TEaIwoo'YYYY1 LIMITS GENERAL LIABILITY NPP1185761 12/01/2008 12/01/2009 EACH OCCURRENCE 1,000,000 DAMAGE I HEN I EO 50,000 X COMMERCIAL GENERAL LIABILITY PREMISES(Ea occurrence) CLAIMS MADE X OCCUR MED EXP(My One Persm) 5,000 A X PERSONAL&ADV INJURY 1,000,000 GENERAL AGGREGATE 2,000,000 GENL AGGREGATE LIMIT APPLIES PER PRODUCTS-COMP/OP AGG Excluded Y I POLICY 7 JE T LOC AUTOMOBILE UABIUTY COMBINED SINGLE LIMIT a ANY AUTO IODILY INJURY $ ALL OWNED AUTOS 1 \ I\ BODILY SCHEDULED AUTOS v �J � IP°'°°'°"I $ HIRED AUTOS • -dace/7/ . BODILY/INJURY NON-OWNED AUTOS (Per aaCanO $ PROPERTY DAMAGE $ • (Per accident) I — GARAGE LIABILITY AUTO ONLY-EA ACCIDENT $ ANY AUTO OTHER THAN EA ACC $ AUTO ONLY'. AGG $ EXCESS I UMBRELLA LIABILITY EACH OCCURRENCE $ OCCUR CLAIMS MADE AGGREGATE $ $ DEDUCTIBLE $ RETENTION $ $ WORKERS COMPENSATOR WC STATU- UTH- AND EMPLOYERS'LIABILITY TORY LIMITS ER ANY PROPRIETONPARTNEEXECUTIVEY]R/ EL.EACH ACCIDENT $ OW Iddaaoryfin NXR EXCLUDED? EL.DISEASE EA EMPLOYEE $ Iy tlescnbe under SPECIAL PROVISIONS EeIo% E.L.DISEASE-POLICY LIMIT $ OTHER DESCRIPTION OF OPERATIONS!LOCATIONS/VEHICLES/EXCLUSIONS ADOED BY ENDORSEMENT I SPECIAL PROVISIONS -escue, rehab & release of dolphins and whales ertificate Holder is shown as an additional insured per policy forms, conditions, limitations nd exclusions EF: TDC CONTRACT CERTIFICATE HOLDER CANCELLATION SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF,THE ISSUING INSURER WILL ENDEAVOR TO MAIL 10 DAYS WRITTEN Monroe County Board of County Commissioners NOTICE TO THE CERTIFICATE HOLDER NAMED TO THE LEFT,BUT FAILURE TO DO SO SHALL & TDC IMPOSE NO OBLIGATION OR LIABILITY OF ANY KIND UPON THE INSURER,ITS AGENTS OR c/o Risk Management REPRESENTATIVES. PO Box 1026 AUTHORIZED REPRESENTATIVE c.o.. A, Key West, FL 33041 John Crowell/BMONRO ACORD 25(2009/01) ©1988-2009 ACORD CORPORATION. All rights reserved. The ACORD name and logo are registered marks of ACORD ACORD CERTIFICATE OF LIABILITY INSURANCE DATEIMMIDDIYYYYI 07/31/2009 PRODUCER 305.852.3234 FAX 305.8 3' THISt,tK ITFIC TE IS ISSUED AS A MATTER OF INFORMATION Regan Insurance Agency, Inc. ON AND CO FERS NO RIGHTS UPON THE CERTIFICATE 9 9 HOL ER,,THIS ERTIFICATE DOES NOT AMEND,EXTEND OR 90144 Overseas Hwy. I ALTER THE CO ERAGE AFFORDED BY THE POLICIES BELOW. Tavernier, FL 33070 INSUBHRS�FF0 DING COVERAGE NAIC# INSURED MARINE MAMMAL CONSERVANCY INSIIRERA S nti el Ins Co P0 BOX 1625 INSURERS 4 KEY LARGO, FL 33037 INSURE-RC INSURER o INSURERS COVERAGES THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED.NOTWITHSTANDING ANY REQUIREMENT.TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN.THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS.EXCLUSIONS AND CONDITIONS OF SUCH POLICIES.AGGREGATE LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS INSR ADD'L POLICY EFFECTIVE POLICY EXPIRATION LIMITS LTR!DI TYPE OF INSURANCE POLICY NUMBER DATE IMMIDDIYYYYI DATE IMMIDOIYYYY GENERAL LIABILITY ' EACH OCCURRENCE DAMAGE TD PEN FED COMMERCIAL GENERAL LIABILITY PREMISES Ea occurrenmi CLAIMS MADE OCCUR MED EXP IAcv oca Deuon� PERSONAL S ADV INJURY GENERAL AGGREGA I GENL AGGREGATE LIMIT APPLIES PER PRODUCTS-COMP:oP AGO PRO- POLICY JECT LOC AUTOMOBILE LIABILITY 21UECNF1499 02/27/2009 02/27/2010 COMBINED SINGLE LIMIT ANY AUTO Ea a"'ear° 100,000 ALI OWNED AUTOS BODILY INJURY S X SCHEDULED AUTOS Pw Pcraary A X X HIRED AUTOS PROPvY E X NON OWNED AUTOS Per aC ' O ccerc PROPERTY DE UAMAaE Pe,awdenr. S GARAGE LIABILITY \\'\�\�\�\(�' / -[� AUTO ONLY.EA ACCIDENT n ANY AUTO V 0 OTHER THAN EA ACC S UTO ONLY AGG 3EXCESSIUMBRELIA LIABILITY OCGVRRFNf.E o OCCUR CLAIMS MADE AGGREGAIF S S DEDUCTIBLE RETENTION a_ $ WORKERS COMPENSATION C STATU- OTH. AND EMPLOYERS'LIABILITY YIN TO LIMITS FR I ANY FRO -F O PN RI NEF'F XE CU IIvEr 1 ,. I `InENT 'OFFICERMEMBEREXCLUDEV+ DISEASE EA CMPIOYFt S (MaMabry in NW II yes describe were. 1 I DISEASE POLICY LIMIT SPECIAL PROVISIONS[elev. OTHER DESCRIPTION OF UVLXAIIONS I LOCATIONS I VEHICLES I EXCLUSIONS ADDED BY ENDORSEMENT I SPECIAL PROVISIONS rescue, rehab & release of dolphins and whales ertificate holder is shown as an additional nsured per policy forms, conditions, limitations and exclusions Ref: TDC contract CERTIFICATE HOLDER CANCELLATION SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF,THE ISSUING INSURER WILL ENDEAVOR TO MAIL 10 DAYS WRITTEN NOTICE TO THE CERTIFICATE HOLDER NAMED TO THE LEFT,BUT FAILURE TO DO SO SHALL Monroe County Board of County Commissioners & TDC IMPOSE NO OBLIGATION OR LIABILITY OF ANY KIND UPON THE INSURER,ITS AGENTS OR c/o Risk Management REPRESENTATIVES. PO Box 1026 AUTHORIZED REPRESENTATIVE ✓L S// /2 —Key West, FL 33041 John Crowell/BMONRO ACORD 25(2009/01) 01988-2009 ACORD CORPORATION. All rights reserved. The ACORD name and logo are registered marks of ACORD