Loading...
DV3A3714 CONT~ AGREEMENT. AGREEMENT, MADE TillS ~f, day of J 0 V 2002, by and , between, Blue Water Marine Services, Inc. ("Contractor"), and the BOARD OF COUNTY COMMISSIONERS OF MONROE COUNTY, FLORIDA, of the County of Monroe, State of Florida ("Board"). The Contractor and the Board, for the consideration named agree as follows: I. The Contractor shall furnish all the materials and perfonn all the work required to remove and legally dispose of DV3A3714 located off of Key Largo for which a F.W.C.C. Derelict Vessel Report is attached as Exhibit A. 2. The work to be perfonned under this contract must be completed by October 20,2002. 3. The Contractor understands the rules of the Florida Fish and Wildlife Conservation Commission and shall comply with those rules, along with the rules and procedures instituted by the Board to ensure an orderly progress to the project. Monroe County's perfonnance and obligation to pay under this Agreement is contingent upon an annual appropriation by the Board. The Contractor understands both the intent and the requirements of the Specifications, attached as Exhibit B. 4. The Board shall pay the Contractor $ 9.500.00 for the removal and legal disposal of DV3A3714. Payment will be upon completion of work by the Contractor and review and approval by the Marine Projects Coordinator. 5. The attached Derelict Vessel Report, Specifications, and the Monroe County Insurance Requirements together with this Agreement, fonn the Contract. They are fully a part of this Contract as if repeated herein verbatim. 6. The Contractor covenants and agrees to indemnity and hold harmless the Monroe County Board of County Commissioners from any and all claims for bodily injury (including death), personal injury and property damage (including property owned by the County) and other losses, 1 damages, and expenses (including attorney's fees) which arise out of, in connection with, or by reason of services provided by the Contractor or any of its Subcontractor (s) in any tier, their employees or agents. The purchase of the insurance required in paragraph I 1 does not vitiate this indemnification provision. 7. The Contractor agrees to supply the County with a set of photographs of each vessel in all phases of the removal and disposal process. The Contractor will be responsible for the camera, film, and development costs. 8. The Contractor must inform the County and the Florida Marine Patrol prior to initiation of work. 9. The parties agree that a timely performance of this agreement is essential due to possible damage to the natural resources, hazards to navigation, or threats to human health and welfare. Therefore, the parties agree that the Contractor shall be liable to the Board for $ I 00 per day of liquidated damages for each day after 10-20-02 that the Contractor's obligations under this agreement remain unperformed. The parties agree that such amount is by the way of compensatory damages and does not constitute a penalty. 10. Due to the use of heavy equipment and, at times, dangerous work environment, the Contractor understands and agrees to maintain an alcohol an drug free work environment. I I. The Contractor will be responsible for all necessary insurance coverage as indicated by an "X" on the attached forms identified as INSCKLST 1-4, as further detailed on forms VLI, WCI, WCJA, GLl, WLI, & POLl attached as Exhibit C. All policies must list Monroe County as additional insured with the exception of the Worker's Compensation policy. 12. The Contractor warrants that it has not employed, retained or otherwise had act on its behalf any former County officer or employee subject to the prohibition of Section 2 of Ordinance No. 010-1990 or any County officer or employee in violation of Section 3 of Ordinance No. 020- 1990. For breach or violation of this provision, the owner may, in its discretion, terminate this 2 contract without liability and may also, in its discretion, deduct from the contract or purchase price, or otherwise recover the full amount of any fee, commission, percentage, gift, or consideration paid to the former County officer or employee. 13. A person or affiliate who has been placed on the convicted vendor list following a conviction for public entity crime may not submit a bid on a contract to provide any goods or services to a public entity, may not submit a bid on a contract with a public entity for the construction or repair of a public building or public work, may not submit bids on leases of real property to public entity, may not perform work as a contractor, supplier, subcontractor, or consultant under a contract with any public entity, and may not transact business with any public entity in excess of the threshold amount provided in Section 287.017 of the Florida Statutes, for CATEGORY TWO for a period of 36 months from the date of being placed on the convicted vendor list. BOARD OF COUNTY COMMISSIONERS OFMONROECO~'FLORIDA By: Mayor/Chairman ::tI::1JX;tE~~ . T'---.f\n '- g:...~- I TItle: l~'lcXl S~~-" 0) :.::;. c-.\ _; (J r''- -0 .. ":-f :';,.~ :t:: ., .> r- I';) '>l ;:~ rq (..) r'\) 2! r- r., C) -q o :::0 ::tJ rq CJ C:;:J ;"""J o 3 t-lIJL ~t.l...l.HL t.1'Ir" HKt.H r"d)\' .;)V~__,O:) "U.V v~,..,.I.V v.. ......,....... - -- - -..- -...,..-..- ------.. :S-0d.- 1 99S e ~ t 7PM F~ MARII'C PRO.JEOT~ ~gs 4317 EXHIl\IT A P.1 '~..."f* ..... . , .' ........ .. .DERELIcr OR ABANDONEl) VESSEL REPORT nVN~ or AVI# lNcmENJ: #I rrJ.,.SJr,.. w- '1 rruf D ~ -Rq 35':J ~ PT. MAICB\ J.n=utatAI ALl <:t TYPIl..."\<l.t L ctJkqNUYRBGl;:n~ YES_~ L\STREGI5'l'ER!riDATE J....J~ STA11i ~,~ aut. ~~ AtI9I? NO_ ~ Wll4TCOUNm\'? (~l" )~ HtllLMA1'J!RW..: WOOD_F'G_M5TAL~ JWBBEILOTHER~ c;oLOB.f,..~~ MOTOaAITACHEl11 JoC_ YES_ ~O'B_JfO_IN_ ANYNAME. wom. txSPLAYClaOllJERIDP.N'1'IF.1aS? ~11!t ~ ~ " C'I1S'I'OJQftOROWNa~JtD Co - ~, c.o~\ DA.~OF~ d'I.YO J&Dr>>BSS......".,..--.pj-.r)~I/t/J . 'St.l. ") 6~"Hl.' " aT'f b\VIF StATE ~ ~ :~iil PHONE . J:IUVIR'SLKmSFM~() ,tq" ~"2.~9 ~ _SISI_ Ot\Jt~ Ol'IDm vusa.'SPJDSlCALLOCATION ~~;SuC" {r~ 1= " NEAREST~ LA.TIL01<<iN 2-S;ot. ,.::::I Ir.uom:.t.~ ~ COI'lDlDON: VIIl2tDD_ JllIIQD_ SUlSrANIWLYIll5lirANn:ED ~ ~UP_PARI'OP"''VESSBL_ 8URNED_ CAPSJ2B)_UStINo_ sct1nI.Etl_ OF HOlES_PlUm WlllIWSGHr_FtIL OFW.A.'mR_ OTHBR. NUMBEltS ORICENmlERs .PJiMOVED_ HF.Al.mHAZAJtD~ ~VUSlLCOJllDl11ON: ABANDONED-.D ~11V&_ PAla'L\U.YDISMANtI.ED_ NO.APJIAReiT1N't1UlCC VALU.E_ PE'RSaW.11CMS 0NB0AR0_ 0'DIEk W$ULJS: AlLOAT/ADRIFr_ AGROUNo_ WASHEDASHORIL.. JN~_ IXXXED_ PlJI.LSDOHSHOIE_ ~_ 11EDTOO8JECT~ CAUSJm BY: MA.~t'lISAS1BR_ UNlCNOWN.l\ OI'NER~~( ua- SUlIMDGm J..tLL" DEl'THZta... FEET DAMAQNG SU8MBRGEDLANO; NO_ ~ UNK_ INJURING8ENIHC~; NO_ 'YES~ 0l1ISR;" OI.II&KftOPEKl'Y DAMACI:.J<<).DlYES_~ PltOI'EII.Tro~ STAlE l5tJBM!RQmLAND_ FIDmW..tL OIHSR OWNERlADDRISS ~ ,.,~ ~ ~ 1frh<:..:IfL ~f\ I~ S~". ~~ (J)/ NAVlGATIONKAZAaD; NO.:b~ YES_(UIWo ~f,(_/'" I~ :1f1'~nA- lOWED Wl'lIIXn"IZPAm.: NO~_ '\'ES_~ M ,.t...~ It.} ~ tJ "f'\ujl . ErMllONM:IItt~ TBIII;AT: NO_ tJNK_ YES~ ~~r..fjof')~~ ~ ~; ~~~ RECOJOtama) DISPOSI'bON: IJ!A.VBAS IS_REMOVE P!lCN WAlER~ TA1(2 ToLANDf1U._ KAVE~REM:lVE_ T.O.T._MAR.tNSHABlTAT_~ -~EM.5Io'~C'"'~"""~~ .~ !lo Il~ &l\LT tY~ ~/'W..",. ft'"...I!QV6 ~..J ~(J!;...,.n __ ~,,~ fJPA.a 0.; ..a~ e:.,;;;~ /~ 1::/b.4)"~ ~_~~=- ontCER,~-S~~ A.vc ~cl- _o..~~ REVIEWFJ)8Y~~d" ~~ DATE k.... ~WL ~tllHl tNr HK~ ~aX;~~-L~~-L~LO vC~ ~v v, ~V'~V - .,'. -:'.-~'.:.'- -' .,' .... .,' ..... ',' ICIDENT/SUMMARY REPORT NARRAnVE . REPORT' CRaItW. .0 [] The vessel 0.0.814357 is aground on French Reef. The F.W.C. S.E.A. and the Florida Keys National Marine sanctuary request an emergency removal of the vessel. The vessel is a thirty-five foot steel hull sailboat. The vessel is caU$U1g severe damage to the reef. ,. N A R R A T I V E .' :, .~ .. MIls HDun A o M I If FWCDl.&.04M (II1IIa:) ..... fII .. ......-. .. .... ., DERELICT OR ABANDONED VESSEL REPORT DV# '~(IL or AV# INCIDENT # 02-SE-o//I-l? I S-t/ D G~) \_' (I ~.r::---' REGroOC# ('rl.:::;;J ( LENGrn3Z. IT. MAKE ( J.:H?yHtWAL~).j S TYPE ~l L CURRENTI.. Y REGISTERED? YES_ NO){ LAST REGISTERED DATE ..J..-J ).A- STATE "-J I k H.I.N. "'b\t\351 ALIEN? NO_ YEsX WHATCOUNlRY? (~~Jtn,* HULL MATERIAL: WOOD _ F/G_ METAL (SPECIFY) SrfjJ.""::;:{ RUBBER_OTHER (SPECIF\') COLOR t,,)AYrr;f;p~:y MOTORAITACHED? NO_ YES_ UNl~ipfB_ I10_ IN_ ANY NAME, WORD, DISPLAY OR OTHER IDENTIFIERS? ~S T\t!( JAt~.CL r CUSTODIAN OR OWNER ~ J I D w . N I GO t \ DATE OF BIRrn::::G cA II 0 ADDRES$(FRoMDl..ORMOSTCT.;IUlENl) Lt'Il{ ~ 'S(JJ 66 ,n.. CIIT ~V(~ STATE />c ZlP 3"53Ii( PHONE DRIVER'S LICENSE# t-. J ~Lj () 'iq 11 NL a q () S/S# ft. tJl c: OTHER ID VESSEL'S PHYSICAL LOCATION ~P-..~)...) C c-\ l-r~~ ~ NEAREST MARKER/LANDMARK LATILONG N 2~ OL. . I~ I (}JCfii):. Z I ~ ,~}- '3 DERELICT VE~L CONDITION: WRECKED_ JUNKED_ SUBSTANI1ALLYDISMANnED ABANOONED SUNK~ BROKEN UP_PART OF A VESSEL_ BURNED_ CAPSIZED_LISTING_ SCUTTLED_ F L OF HOLES_ FILLED WITII WEIGHr_ FULL OF WATER_ OTHER N'UNffiERS OR IDENTIFIERS REMOVED_HEAL TII HAZARD (EXP1.~ ABANDONED VESSEL CONDITION: ABANOONEDL INOPERATIVE_ PARTIALLYDISMANnED_ NO APPARENf INTRINSIC VALUE_ PERSONAL ITEMS ONBOARD_ OTIffiR VESSEL IS: AFLOAT/ADRIFT_ AGROUND_ WASHEDASHORE_ INWETI..ANDSIMANGROVES_ I.XX:KED _ PULLED ONSHORE_ ANCHORED_TIED TO OBJECT(sPEclFY) CAUSED BY: NATURAL DISAS~ UNKNOWN~ OTHER a C> 01 "-~:) u~ SUBMERGED , DO % DEPTH '2--0 FEET DAMAGING SUBMERGED LAND: NO_ YEs1{ UNK_ . INJURINGBENIHIC COMMUNIIT: NO_ YES ~ OTIffiR; OTHER PROPERTY DAMAGE: NO~ YES_ (EXPl..ADI) PROPERTY OWNER: STATE SUBMERGED LAND_ FEDERALtL OTIffiR OWNER/ADDRESS 1=-l LiR.\M \G;v's N frr1r$v WAf"\. I>-JS" "Sf)t,Jr:rtv. 0''; NAVIGATION HAZARD: NO~ UNK_ YES_ (E<l'L\IJ'o1 <~IA ..J/( ( v ~o I ~n~ - TOWED WITIIOur REPAIR; NO~_ YES_(EXPL\IJ'o') 1--\ rX,:.-S Iv ~TlrylA 0 1'-1i-/ I{ . ENVIRONMENTAL TImEAT: NO_ ~ YES ~L-\IN) S~"'Of")~,<:;'S u~ 6r,~, \ ""\!~U'itl1<::;'" RECOMMENDED DISPOSITION: LEAVE AS IS_ REMOVE FROMWATERt><( TAKE TO LA.NDFll..L_ HA VE OWNER/CUSTODIAN REMOVE_ T.O.T. MARINE HABITAT_ OTIffiR NARRATIVE~ILIGENTSEAR:CH: p:.,~/~~" l'f:)c})~ 1==V at. )U~- ~%flLT (YIP. Or:>(j..Jf'b{rv-C ~( J....JlC/V(; O".) 07-0K-OC. N()P,t;- tJPP'CF" 0+ t1~V~ C{A"/S.~ I~ wP~ t:"\11k.fl, ~.:?J~ CIAN?C1~S- . OFFICE~AGENCY S:CP~~ REVIEWED BY (PM") r~c ~~C) (SIGN) DA IT. "8"=-30--0 DATE ""CIDLFA)48 DERELICT or ABANDONED VESSEL # -SE- (jI/-;:-/'..;-fID I ~ , LOCATION: REPORTING OFFlCER & AGENCY: ~/-. .!.....l / . " /. 1- ',_" -.~ _ _. ~ /' :;;::: :.-= --- - '\ DATE: FWC'DLE4I8 .... SNAKE PT BLACKWATER SOUND ".. eA.,. 11'-51"" 1I'-63} 128 , " 9 ", " . . .>- EXHIBIT B DERELICT VESSEL REMOVAL CONTRACT SPECIFICATIONS FOR MONROE COUNTY, FLORIDA 1. INTENT: It is intended that these specifications shall cover all aspects of the work. The purpose of this section is to provide specific conditions applicable to this contnlct where such coverage is not provided in other portions of the documents. .., BID FOR11A T: A dollar amount per foot must be submitted for the removal of as many derelict vessels on the primary list for which a Florida Marine Patrol Derelict Vessel Report is provided and as funding will allow. Any deviation from this format will result in an unaccented bid. A contract will not be granted on the basis of combinecL related, linke~ or discounted bids. Not applicable due to emergency removal of one or more derelict vessels for less than $25,000 total. 3. PLANS: There are no plans for this project, but copies of the Florida Marine Patrol Derelict Vessel Report with location sketches L.1ve been bound into these documents for the Contractor's use. The Specifications include a section on instructions to bidders, both general and specific, and a copy of each Derelict Vessel Report from the Florida Marine Patrol. Only those derelict vessels for which a report is included and listed on the Bid Response Form are to be bid upon and subsequently removed. The County reserves the right to remove any or all vessels from this contract at any time prior to actual removal from the water and disposal by the Contractor. The County has a limited amount of money to effect the removal of these derelict vessels. We have established priorities based on public safety, navigational hazard, and environmental considerations. Ifbids exceed the County's.resources for removal based on these considerations, we shaIllimit vessel removal based on the considerations and cost effectiveness. 4. VESSEL IDENTIFICATION AND LOCATION: Each of the vessels have been given a derelict vessel identification number, which is shown with the location in the Florida Marine Patrol Derelict Vessel Report, included herewith. Each bidder is responsible for his own identification of each derelict vessel as to location, description and condition. If a derelict vessel cannot be (1) located, (2) removed. (3) verified and (4) disposed at: as specified in these procedures, then no payment will be made forthcoming to the Contractor for that vessel. Those four conditions must be met on each derelict vessel along with compliance of all laws for payment to be made. It is understood that the Conuaetor bas, by personal examination and inquiry, if necessary. satisfied himself as to local conditions of each derelict vessel and as to the meaning, requirements and reservalions of the speciiications; for after contraCt letting, no deviation will be allowed. In case e1TOrs are discovered, they are to be reported by the Contractor to the County. The county assumes no responsibility should there be any discrepancies in what is stated in these documents and what the bidder evaluates. The Contractor should take special care to remove only those derelict vessel's on his ContraCt and for which he possesses a Florida Marine PatrOl Derelict Vessel Report. Other derelict vessels in the area but not under ContraCt, cannot be molested. It may be possible to replace a derelict vessel of like kind, for the same or less money. when mutual agreement can be reached by the Florida Department of Environmental Protection, Monroe County Administrator of the Derelict Vessel Program. and the ContraCtor. This will be applicable "hen a contracted derelict vessel cannot be located. No derelict vessel may be replaced and removed without the tri-part)' consent noted in this paragraph. A contractor may suggest a possible replacement vessel but he may not remove it without the appropriate consent above. 5. SCOPE OF WORK: The ContraCtor shan be responsible for providing all pennits, supervision, labor, equipment. 1001s, fees and taxes required to complete this project to the satisfaction of the County. The Contractor's procedure and methods of removal may be ofms own selection provided they secure results which satisfy the requirements of the Specifications and any necessary environmental permits. Any vessel which is removed and disposed of shall be removed from its present site in such a manner as to do the least possible damage to'the natural environment. All debris from the vessel shall be removed and the site left in a reasonably clean condition. No oil or fuel shall be permitted to be dumped or spilled into or unto the water or land. All pollutants shall be removed from the derelict vessel prior to removal from the water. The Contractor shall be responsible for making any and all arrangement for access to the vessel to be removed. If private property has to be traversed, then written permission of the owner is necessary. In removing a derelict vessel that may lie on or near grass or sponge flats extreme caution must be use$! to do the least possible damage. ..-. -- 2 Prior to delivery of derelict vessels to the disposal site, the Contractor must remove all ail, gas and engines. He must dispose of them in any legal manner. Pure used oil will be taken by Monroe County for disposal. MixtuI~ of oil, gas, seawater or any combination of the three must be tranSported from the County by an approved hazardous waste handler. The names of handlers will be supplied by the Monroe County Solid Waste Department. Metal becomes the property of the Contractor. 6. MA TERlALS AND WOR,N\1ANSillP: The ~ontractor shall provide the necessary materials and equipment to safely complete the job. The Contractor agrees that all work shall be performed by competent employees who are experienced and qualified to do the work specified, and that all work will be performed in accordance with the best commercial practices. A list of equipment to be used and a description of the removal and tranSporting procedures to be followed must be provided to the County at the pre-work conference described below. Precaution shall be exercised at all times for the protection of persons and property. The safety provisions of the Occupational Safety and Health Act of 1970 (Public Law 91-596) and other applicable laws, including buildi~g and construction codes shall be observed. Machinery, equipment and other hazards shall be guarded in accordance with safety provisions of the "Manual of Accident Prevention in ConstrUction", published by the Associated General Contractors of America, to the extent that such provisions are not in contradiction of applicable law. If any property is destroyed by any cause or means whatsoever, the ContraCtor sball repair and replace or not receive payment for the unaccomplished work. The Contractor shah maintain suitable and sufficient guards and barriers, and at night, suitable and sufficient light or other appropriate security or protection for the prevention of accidents. Use of explosives is prohibited in carrying out the project. 7. ASSIGN11ENT OF CONTRACT AND SUBCONTRACTS: It is expressly understood that the Contractor is in all respects an independent ContraCtor for this work. not withstanding under certain conditions he is bound to follow the directions of the County, and is in no respect an agent, servant, or employee of the County. Neither the Contract. nor any part thereof, nor any Moines due or to become due thereunder, may be assigned by the Contractor without the prior wrinen approval of the County. .-.-- ------ .--.. ----~ _,-_.r-. 3 The Contractor is fully responsible to the County for the acts and omissions ofbis subcontractors and of persons either directly or indirectly"employed by said subcontractor, as he is for the acts and omissions of persons directly employed by bim. Nothing contained in the relation betWeen any subcontractors shall abide by the terms, conditions, and requirements of this ConuacL It is the responsibility of the Contractor to pay all debt obligations incurred with subcontractors in an expedient manner. . -'.. - t. 8. LEGAL RESTRICTIONS. PERMITS AND TRAFFlC PROVISIONS: The Contractor shall comply with all applicable local, State and Federal requirements pertaining to the terms of this Contract. The Contractor win be responsible for obtaining, at his own expense, any licenses or permits that may be required and should inquire about permit requirements with the appropriate agencies. The Contractor shall comply with all the requirements of the Federal Pollution Control Act. The Contractor shall conduct his operations so that he shall not close any thoroughfare nor interfere in any way with traffic on highways, or on water, without the written consent of the proper authorities. Work shall be done at any time that shall not interropt or disturb members of the public. Utilization of off-loading sites located on private property (water to land for transport to the landfill or other disposal site by vehicle) must have written approval of the land owner. The Florida Marine Patrol should be contacted to initiate eviction proceedings for contracted derelict vessels which are inhabited at the time of removal and when another vessel is too close to the contracted derelict vessel to allow safe operations. Direct confrontations with other boaters should be avoided and the Florida Marine Patrol should be contacted immediately if such confrontations results from removal of any contrac~ed derelict vessels. 9. INSURANCE: The Contractor must obtain insurance required by the County and submit proof of same to the County prior to acceptance of bid and contract approval by Board of County Commissioners but no later than five working days after notice of low bidder. All insurance shall be maintained until work has been completed and accepted by the County. The Contractor shall furnish the following certificates of insurance for review by the County's Risk Management Division: Certificate (s) of Insurance which clearly indicates that he has obtained the insurance coverage required in paragraphs ~b,c and d below. --- ..- .--" -' - - . - ----- .. ..,--"'.. 4 The ContraCIOr hereby certifies that no modification or change in insurance sball be made without (10) days written advance notice to MONROE County, clo the Director of the Risk Management Division. a. Worker's Compensation Insurance per Fl. Statutes b. Federal Jones Act Coverage c. General Liability Insurance on a comprehensive basis, in an amounl nolless than $500,00.00 per occurrence for Bodily Injury and Property Damage combined, to include contractual liability. c. Pollution Liability Insurance in the Amount of$500,000. d. Water Craft Liability Insurance in the Amount of$500,000. e. Automo bile liability insurance covering all owned, non-owned and hired vehicles used in connection with the work, in an amount not L~ss than $300,000 per occurrence for Bodily Injury and Property and Damaged combined. All insurance policies required above shall be issued by companies authorized to do business under the laws of the state of Florida. The MONROE County Board of County Commissioners must be listed as "Additional Insured" on all policies, except for the Worker's Compensation policy. 10. COMMENCE1vffiNT, DELAYS AND COMPLETION OF WORK: After receiving Board of County Commission approval of the Contract, and after reconciliation of any details or conditions which may directly or indirectly interfere or conflict with work of the Contract, the County will issue a "Notice to Proceed" officially authorizing the ContraCtor to commence. The Contractor shall commence work within one week from the date on the ''Notice to Proceed" letter. If the ContraCtor should be delayed in the progress of the work included in the Contract by enforceable causes beyond his control, the time for the completion of the work may be extended upon agreement of the County representative. Requests for an extension of time must be submitted in writing to the County representative. Extensions of time cannot legally be approved unless the written request is submitted in the time to permit it to be acted upon before the Contract expiration date. To allow sufficient time for the administrative procedures required to obtain action by the County Commission, a request for time extension must be received by the County representative at least sixty (60) calendar days prior to the Contract expiration date. . - --.- ~ .,,-.-,,. 5 . '. , Provided further that the Contractor shall within ten (10) days from the beginning of such delay notify the County, in writing, of the causes of the delay. The County representative will ascertain the facts and the extent of the delay and notify the Contractor within a reasonable time of her decision in the matter. If the Contractor fails to complete the work within the time limit, and if the County should nevertheless pennit the Contractor to continue ant! complete the same without official extension of time in writing, such pennission shall not modify nor waive any liability of the Contractor for damages arriving non-completion of work within the time limit, but such liabilities shall be subject to continuation in full force against the contractor. 1 \. CHANGES AND INSPECTION: The vessels herein considered are to be removed for the County by the Contractor in accordance with the specifications. The County may give instrUCtions or directions to supplement the specifications. These shall be binding upon the Contractor and upon all his subcontractors, employees and agents of every kind. All work and every process and operation shall be suoject to inspection at all times, and the County and their representatives shall have free access to all aspects of the work. The Contractor shall remove and make good, as may be directed, without charge, any defective work. Oversight or error of judgment of inspections, or previous acceptance, shall not relieve the Contractor from the obligation to make good any defect whenever discovered. The right is reserved to change the Specifications consistent with regard to the gener31 intention of the contraCt for any part of the work or materials, either before or after work has begun. Notice of such changes shall be given in writing to the Contractor; such changes are not to be grounds for any claim by the Contractor for damages, nor for the forfeiture of the Contract. It is possible that a Derelict Vessel could disappear between the time of inspection by the contractor and the actual effort to remove it. No payment will be forthcoming in event that this occurs. Except when otherwise specified, the expense of all tests requested by the County will be borne by the County. 1:2. ACDIT RIGHTS: As a provision of the grant from the State of Florida to the County, and if so requested by the State, the successful bIdder agrees to provide access to all records and allow the audit of any books, documents and papers related to this project for a period of up to one year and during and after tennination of the contract. 13. CONTRACT AWARD: The County reserves the right to evaluate the submitted bids and award a contract to the bidder submitting the lowest per foot bid for the derelict vessels listed in the bid package as one project and for which a 6 Florida Marine Patrol Derelict Vessel Report is ineluded. One bid will be accepted and a Contract issued for the total removal of all listed derelict vessels as one . project, up to the limit of available funds. The actual number of vessels to be removed will depend on the accepted per foot bid price and the available funds. 14. PREWaR!( CONFERENCE: A meeting will be necessary involving a representative of the County, the Contractor and other parties with direct involvement prior to the signing of the Contract. The time and place of this conference will be set by the County representative. At this time the Contractor shall provide the County with a schedule as to the order in which he proposes to remove the vessels awarded to him. 15. CONTRACT SECURITY: The ContraCtor is expected to act and deliver in good faith all work, at the agreed price, in the allowed time. Failure to do so, could jeopardize the contraCtor's reputation with the County and potentially influence any future contracts with MONROE County. . 16. EXECUTION OF CONTRACT DOCUMENI: Due to the time frame involved with this project, the Contractor upon notification that he is to be awarded the contract documents for execution, shall return said documents properly executed along with insurance within TEN WORKING DAYS. This will assist in acceleration of execution of the contract documents. The Contractor, by virtUe of signing the Contract, acknowledges that he and all his subcontractors have satisfied themselves as to the nature and location of the work, the general and local conditions, including, but not restricted to, those bearing upon transportation, handling, access to the pick-up and disposal sites; and the character of equipment and facilities needed to perform the work. Failure on the part of the Contractor to completely or properly evaluate any factors ofhis costs prior to bidding shall not form a basis for additional compensation ifhe is awarded the Contract. . . If for any reasons, not acceptable to the County, the Contractor does not perform, the County shall have the right to levy liquidated damages against the Contractor. Liquidated damages in the amount of S 1 00 per day shall be assessed against the Contractor for any bid item awarded to him which is not completed and accepted by the County within the number of calendar days specified in the Contract. Liquidated damages are accumulative. 17. NOTICE TO PROCEED: The Contractor shall commence work upon this project within one week of the date of the Notice to Proceed letter and perform in a continuous manner until completion and acceptance by the County. For Contracts . --.. ..---- ------..--- 7 wherein a specified number of days for completion is stated in the Contract, the effective date of the "Notice to Proceed with Contract Work" will establish the "beginning date" of the project. 18. TERMINATION OF CONTRACT: 'Ibis ContraCt may be terminated by the County, giving up to ten (10) days written notice to the Contractor, said notice shall be sufficient if delivered to the party personally or mailed by certified mail to his mailing address as specified on the accepted bid. 19. FINAL CLEAN-UP: Upon completion of the work specified herein and before acceptance and final payment shall be made, the Contractor shall remove from the sites all machinery, equipment, surplus and discarded ~terials and temporary structures. The disposal of materials, mbbish and debris shall be made at a legal disposal site. 20. DISPOSAL SITES AND FEES: The ContraCtor is responsible for disposal of all derelict vessels included in this contract and must make arrangements for legal disposal. It is the responsibility of the ContraCtor to pt'Y all disposal fees incurred, and such removal related costs should be considered when bidding on this contract. The Contractor will deliver the derelict vessels to a Florida Department of Environmental Protection pennitted disposal site that has current occupational tax licenses. It is the intent of this contract to remove derelict vessels from their present site and legally dispose of them. Upon receipt of vessels at the landfill, they must be disposed of immediately. There are several Monroe County disposal sites, Cudjoe Landfill, MM 21.5 (vessels must be 26' and under to be delivered in tact, over 26' they must be broken up), Long Key Landf1l1 MM 68, and Card Sound Road AKA SR905 other landfills in neighboring countries or any other location for disposal as long as the site is a legal licensed disposal site. Prior to transportation of vessels out of County the County representative must approve. Vessels being disposed of at County Landfill sites must be free of pollutants and engines. 21. PROOF OF PROPER DISPOSAL AND NOTIFICATION TO MARJNg PATROL: ContraCtor must submit prior to receiving any payment: A receipt for each vessel including the date of dispos~ the Florida Marine Patrol Derelict Vessel Number, disposal site location, and the telephone number. Recipient of debris should provide detailed receipt showing type and description of debris received. In addition to the above information, Contractor must submit three pictures of each vessel removed. The first photograph must be of the vessel at the current location prior to removal. the second photograph must be of the vessel after removal but in the same general area preferably while in tow, and the third .. -- -....-. s photograph must be of the vessel at the disposal site with sufficient background to depict disposal (Le.. building or sign identifying disposal site). The derelict vessel number, when possible, must appear in all photographs. The Contractor will be responsible for the camera, film, and development costs. The photographs should be taken with a Polaroid camera that provides instant photos since this minimizes loss of documentation due tg camera malfunction or loss overboard. This photos must be submitted on a vessel by to document the removal and disposal of the contracted vessels fmal payment can not be assured. The Contractor must notify the Florida Marine Patrol and the County Representative in writing as to the work schedule of removal. nus should be done after the pre-work conference with the County representative. Notification is to be made before doing any work on each vessel. This multipartY communication for each Derelict Vessel is a requirement of the contract. 22. PAYMENT: All payments for the removal and disposal of each vessel, shall be for the performance of the work as stipulated in these ~pecifications and associated contractual documents. The unit rate of bid shall be totally inclusive for all phases of the operation. The Contractor may request two partial payments by submitting an invoice for the number of vessels removed up to the date of the invoice, providing the Contract agreement does not explicitly prohibit partial payments. Photographs, disposal receipts, and signed FDEP Disposition Certification form for the vessels for which payment is being requested. The Contractor understands and agrees that no payment will be forthcoming for the removal and disposal of any derelict vessel (I) not listed on this contract nor (2) for any derelict vessel on this contraCt for which a written certification verifying the removal of the subject vessel has not been obtained from the Florida Marine Patrol and a Representative of the disposal site at the rime of delivery . In addition, property, public or private, if damaged during the work or removed for the convenience of the work, shall be replaced at the 'expense of the Contractor in a manner acceptable to the County and the Owner, prior to the fmal payment for contracted work.. ::3. NON-COLLISION AFFIDA VIT: Upon entering into the contract, the Contractor agrees to sign and endorse the Non-Collusion Affidavit form (attached). 24. ETHICS CLAUSE: Upon entering into the contract, the Contractor agrees to sign and endorse the Ethics Clause form (attached). 25. DRUG FREE WORK PLACE FORM: Upon entering the contract, Contractor agrees to sign and endorse the Drug Free Work Place form (attached). 9 . 26. DERELICT VESSELS AT ISSUE: The derelict vessels listed on the Derelict Vessel Working Bid List shall be removed and disposed of by the Contractor in accordance with the provisions of these Specificatio~. 10 1996 Edition EXHIBIT C =r f\10NROE COUNTY, FLORIDA INSURANCE CHECKLIST FQR VENDORS SUBf\UTIING PROPOSALS FOR 'VORK To assist in the development of your proposal, the insurance coverages marked with an "X" will be required in the event an award is made to your firm. Please review this form with your insurance agent and have him/her sign it in the place provided. It is also required that the bidder sign the form and submit it with each proposal. . WORKERS' COMPENSATION AND EMPLOYERS'LIABILITY X V.,T orkers' Compensation x Employers Liability Employers Liability Employers Liability US Longshoremen & Harbor Workers Act X Federal Jones Act Statutory Limits $J 00,000/$500,000/$100,000 $300,000/S500,000/$500,000 $ 1 ,900,000/S 1 ,000,000/$1 ,000,000 Same as Employers' Liability Same as Employers' Liability WCl WC2 WC3 WCUSLH WCJA INSCKLST 1 Adl1\lnl!\lrallOn lnsuucllon 147092 GENfRAl llA.RTi ;-';1.< As a minimum. the required general liability coverages will include: . Premises Operations . Blanket Contractual . Expanded Definition of Property Damage Required Limits: GL1 x GL2 GL3 GL4 Required Endorsement: GLXCU GLLIQ GLS . PrOQUctS and Completed Operations Personal Injury . S100,000 per Person; 5300,000 per Occurrence $50,000 Property Damage or S300,000 Combined Single Limit $250,000 per Person; S500,000 per Occurrence $50,000 Property Damage or $500,000 Combined Single Limit S500,000 per Person; $l,OOO,Oqo per Occurrence $100,000 Property Damage or . $1,000,000 Combined Single Limit $5,000,000 Combined Single Limit Underground, Explosion and Collapse (XCU) Liquor Liability Security Services All endorsements are required to have the same limits as the basic policy. AdmlOlSlrallon InSlfucuon 1/47092 INSCKLST 2 '996 Edition YEHICLE L'AB't~!' As a minimum, coverage should extend to liability for: . Owned; Non-owned; and Hired Vehjc;les Required Limits: X VLl VL2 VL3 VL4 BRl MVC PROl PR02 PR03 POLl POL2 POL3 EDl ED2 GKl GK1 GK3 Wl.l x x AdnllnlSlrallon Instruction U 70Q 2 $50,000 per Person: S100,000 per Occurrence $25,000 Property Damage or $100,000 Combined Single Limit S100,000 per Person; S300,000 per Occurrence S50,000 Property Damage or $300,000 Combined Single Limit $500,000 per Person; S1,000,000 per Occurrence S100,000 Property Damage or Sl,OOO,OOO Combined Single Limit S5,000,000 Combined Single Lintit JyHSCELLA'NEOUS COVFRAGES Builders' Risk Limits equal to the completed project. Limits equal to the maximum value of anyone shipment. Motor Truck Cargo Professional Liability $ 250,000 per OccurrencelS 500,000 Agg.. S 500,000 per OccurrencelS1 ,000,000 Agg. Sl,OOO,OOO per OccurrencelS2,000,000 Agg. S 500,000 per OccurrencelS1,000,000 Agg. S1,000,000 per OccurrencelS2,OOO,OOO Agg. S5,000,000 per OccurrencelSl 0,000,000 Agg. S 10,000 S100,000 Pollution Liability Employee Dishonesty Garage S 300,000 ($ 25,000 per Veh) Keepers S 500,000 ($100,000 per Veh) $1,000,000 ($250,000 per Veh) Watercraft Liability $500,000 INSCKLST 3 ... ._~ ,no t.amon INSURANCE AGENT'S ST~TEMENT I have reviewed the above requirements with the bidder named belo.w. The {ollowing deductibles apply to the corresponding policy. , . POLICY , ' DEDUCTIBLES Liability policies are _ Occurrence _ Claims ~.{ade Signature Insurance Agency . BTDDF.RS STATEMENT I understand the insurance that will be mandatory if awarded the contract and will comply in full with all the requirements. Signature Bidder INSCKLST 4 Administntion Instruction 14709.2 1996 Edition 'VORKERS' COMPENGATION INSURANCE REQUlREl\{ENTS FOR CONTRACT , BET\VEEN l\{ONROE COUNTY, FLORIDA AND Prior to the commencement of work governed by this contract, the Contractor shall obtain Workers' Compensation Insurance with limits sufficient to respond to Florida Statute 440. In addition, the Contractor shall obtain Employers' Liability Insurance with limits of not less than: S100,000 Bodily Injury by Accident S500,000 Bodily Injury by Disease, policy limits S100,000 Bodily Injury by Disease, each employee ~ Coverage shall be maintained throughout the entire term of the contract. Coverage shall be provided by a company or companies authonzed to transact business in the state of Florida. If the Contractor has been approved by the Florida's Department of Labor, as an authorized self- insurer, the County shall recognize and honor the Contractor's status. The Contractor may be required to submit a Letter of Authorization issued by the Department of Labor and a Certificate of Insurance, providing details on the Contractor's Excess Insurance Program. If the Contractor participates in a self-insurance fund, a Certificate of Insurance will be requirec In addition, the Contractor may be required to submit updated financial statements from the fun upon request from the County. \Vel Administration Instrucllon "'709.2 '. . 1996 Edition \\'ORKERS' COM:~NSATION INSURANCE REQUIREMENTS FOR CONTRAcr . I BE1\VEEN MONROE COUNTY, FLORIDA AND Recognizing that the work governed by this contract involves Maritime Operations, the Contractors Workers' Compensation InsuranCe Policy shall include coverage for claims subject to the Federal Jon Act (46 U.S.C.A. subsection 688) with limits not less than those specified for Employer's Liability. The Contractor shall be permitted to provide Jones Act Coverage through a separate Protection and Indemnity Policy, in so far as the coverage provided is no less restrictive than would have been provi< by a W orkersl Compensation policy. .I \\'CJA AdmlnlSII3110n I nSlnJction U 10Q "} ............ 1996 Edition GENERAL LIADIJ..:TV. INSURANCE REQUlREl\{ENTS FOR CONTRACT I BETWEEN MONROE COUNTY, FLORIDA AND Prior to the commencement of work governed by this contract, the Contractor shall obtain General Liability Insurance. Coverage shall be maintained throughout the life of the contract and include, as a minimum: . Premises Operations . Products and Completed Operations . Blanket Contractual Liability . Personal Injury Liability . Expanded Definition of Property Damage The minimum limits acceptable shall be: $300,000 Combined Single Limit (CSL) If split limits are provided, the minimum limits acceptable shall be: J. $100,000 per Person S300,000 per Occurrence S 50,000.Property Damage An Occurrence Fonn policy is preferred. If coverage is provided on a Claims Made policy, its provisions should include coverage for claims filed on or after the effective date of this contract. In addition, the period for which claims may be reported should e"'t~nd for a minimum of twelve . (12) months following the acceptance of work by the County. . - ..- The Monroe County Board of County Commissioners shall be named as Additional Insured on all policies issued to satisfY the above requirements. GLl Administration Instruction U'7092 1996 F.dilian VEHICLE LIABILi't=F e. INSU~~CE REQUIREMENTS FOR CONTRACT BETWEEN "IONROE COUNTY. FLORIDA AND Recognizing that the work governed by this contract requires the use of vehicl~ the Contractor, prior to the commencement of work, shall obtain V chicle Liability Insurance. Coverage shall be maintained throughout the life of the contract and include, as a minim~ liability coverage for: . Owne~ Non-Owne~ and Hired Vehicles The minimum limits acceptable shall be: . $100,000 Combined Single Limit (CSL) .a If split limits are provide~ the minimum limits acceptable shall be: . , $ 50,000 per Person $100,000 per Occurrence $ 25,000 Proper1)' Damage The Monroe County Board of County Commissioners shall be named as Additional Insured on all policies issued to satisfy the above requirements. VLl AdnllnlSlr311Un IlIlitruCltOIl U 70Q 2 KO 1996 Edi1ioIl . POLLUTION LIABILITY INSURANCE REQUIREMENTS FOR CONTRACI" BETWEEN MONROE COUNTY, FLORIDA AND Rec05roi'7'in~ that the work governed by this contraCt involves the storage, trea.tmen~ processing, or transporting ofbaz,ardous materials (as defined by the Federal Environmental Protection Agency), the Conuac:tOr shall ~hase and maintain, throughout the life of the contract, pollution Liability Insurance Which will ~~nd.to bodily injury, property d~ma.ge, and environmental damage caused by a polluuon mctdent. The mi"imum limits of liability shall be: S500,000 per Occurr:ncelSl,OOO,OOO Aggregate If co,'erage is pro~ided on a claims made basis, an extended claims reporting period of four (4) years will be reqmred. POLl Ac1ministr:nion lnsuuclion #4709.2 71 \ ~ .. .. 'YYQ &;.u".un , .- ,y A TER CRAIT LIA81.LtT.:\: INSURANCE REQUIREl\ft;N1'S FOR CONTRACT , ' BET\\'EEN MONROE COUNTY, FLORIDA AND Prior to the commencement of work governed by this contract; the Contractor shall obtain Water Craft Liability Insurance with terms no less restrictive than those found in the standard" American Institute Hull Clauses" (June ~ 1977 edition). Coverage shall be maintained throughout the life of the contract and include, as a minimum: . Injury (mcluding death) to any Person . Damage to FIXed or Movable Objects . Costs Associated with the Removal of Wrecked Vessels . Contractual Liability with Respect to this Contract If the policy obtained states that coverage applies for the " ActslJr Omissions of a Vessel", it shall be endorsed to provide coverage for the legal liability of the shipowner. The minimum limits acceptable shall be: $500,000 Combined Single Limit (CSL) Coverage provided by a Protection and Indemnity Club (P~l) shall be subject to the approval of the County. .~. The Monroe County Board of CoUnty Commissioners shall be named as Additional Insured on all policies issued to satisfy the above requirements. . . \VLl Admlnl~lr.\itln I,,\u\lc\lon 147092 ------- -- ACORD".. 'CERTIFICATE OF LIABILITY INSURANCE I DATE (MMIODlYY) 10/18/02 PRODUCER THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION Starkweather & Shepley ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AMEND, EXTEND OR PO Box 549 ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. Providence, RI 02901-0549 401 435-3600 INSURERS AFFORDING COVERAGE ------- ----~ -- ----------- --- ._-----~_.__. ----- -- INSURED INSURER A: THE ST PAUL COMPANIES, INC. Blue Water Marine Services INSURER B: P.O. Box 901716 . INSURER c: Homestead, FL 33090 , INSURER D: INSURER E: .......Cll t,.rr oJ'U'U_ COVERAGES THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT. TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN. THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS. EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. AGGREGATE LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. ~f~ TYPE OF INSURANCE POLICY NUMBER "8~.feY ~:5~~E LIMITS A 390FA52876 GENERAL LIABILITY ! COM M ERCIAL GENERAL L1AB ILITY CLAIMS MADE OCCUR GEN'L AGGREGATE LIM IT APPliES PER: POLICY n PRo;. LOC AUTOMOBILE LIABILITY . ANY AUTO ALL OWNED AUTOS ~ , SCHEDULED AUTOS HIRED AUTOS NON-0WNED AUTOS GARAGE LIABILITY --i ANY AUTO ! EXCESS LIABILITY '-----; OCCUR ! I CLAIMS MADE ; DEDUCTIBLE RETENTION S WORKERS COMPENSATION AND EMPLOYERS' LIABILITY A OTHERP&I 390FA52876 , 12/20/01 12/20/02 DESCRIPTION OF OPERATlONSlLOCATlONSlVEHICLESlEXCLUSIONS ADDED BY eNDORSEMENT/SPECIAL PROVISIONS Certificate Holder listed below is named as Additional Insured P & I includes the Jones Act, Collision, Tower's & Salvor's Liability and Diver Coverage Vessels: 199426' Silvership, 199825'9" Madison, 199824' Silvership, 26' (See Attached Descriptions) CERTIFICATE HOLDER CANCELLATION AD 0 mONAL INSURED; INSURER LETTER: ! EACH OCCURRENCE i $1 ,000,000 , FIRE DAMAGE (Any one tire) i s50,000 ; MED EXP (Anyone person) : s5,000 : PERSONAL & AOV INJURY : $1 ,000,000 GENERAL AGGREGATE i s2,000,000 . PRODUCTS .COMPIOP AGG : $1,000,000 . ! COMBINED SINGLE LIMIT i (Ea accident) I 1$ BODILY INJURY (Per person) is . BODILY INJURY , (Per accident) s I PROPERlY DAMAGE i (Per accident) 1$ ! AUTO ONLY - EA ACCIDENT i $ EAACC i $ : OTHER THAN ! AUTO ONLY: AGG : S 1$ 1$ i$ 1$ ! is i_WC STATU- IOTH-' ~O!rLLIMITSJ..__-L6L-_ E.L EACH ACCIDENT i $ E.L DISEASE - EA EMPL OYEE' S I E.L. DISEASE - POLICY LIMIT'S $1,000,000 I EACH OCCURRENCE i i AGGREGATE Monroe County Board Of Commissioners Risk Management 1100 Simonton Street Key West, FL 33040 SHOULD ANYOFTHE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, THE ISSUING INSURER WILL ENDEAVOR TOMAIL30___DAYSWRITTEN NOTICE TOTHE CERT1FICA~~Aii!!D.Torillflm~Ai'~~Ae' TO DO SO SHALL IMPOSE NO OBLIGATION llATIS.u 'AN~.o,Q '"': ~ ~~~~~.ITS AGENTS OR A~t0ri1r... .. REPRESENTATIVES. AUTHORIZED REPRESENTATlV 1 :./ ACORD 25-S (7/97) 1 of 3 #S57245/M54105 ~ @ ACORD CORPORATION 1988 . ~ Allstate. You're in good hands, CUSTOMER SERVICE REQUEST COMMERCIAL AUTO POLICY Policy Number: 049828888 02/02 ALLSTATE INDEMNITY COMPANY Home Office Northbrook, Illinois Calendar Date 09/26/2002 FLORIDA BUSINESS NAME BUSN ADDRESS CITY HOME PHONE BLUEWATER MARINE SERVICE PO BOX 901716 HOMESTEAD ST: FL ZIP: 33090 ( 305 ) 230 - 0030 BUSINESS PHONE : ( 305 ) 230 - 0030 ----------------------------------------------------------------------------- CHANGE COVERAGES - These are the coverages that apply to your vehicle(s) after your requested change has been made. ITEM 001 300000 300000 5000 0000 01 AB Combined BI & PO SS UM Bodily Injury CC Medical Payments VA Basic PIP (Oed) PIP Plan ----------------------------------------------------------------------------- ADD ITEM INTERESTED PARTY On Item: 1985 F100 SERIES lFTCF15F5FNA10694 Certificate of Insurance Holder Name: KIM MCGEE/MONROE CNT Address: 5100 COLLEGE RD Exp Year: City: KEY WEST State: FL Zip: 33040 Dir Code: 000000 ----------------------------------------------------------------------------- THIS REQUEST IS SUBJECT TO POLICY TERMS AND IS EFFECTIVE ONLY IF THE POLICY NOTED IS CURRENTLY IN FORCE EFFECTIVE 05:28 PM 09/26/2002 Notice: it is a~rime to knowingly provide false. incomplete or misleading information to an insurance company for the purpose of defrauding the company, Penalties include imprisonment. fines and denial of insurance benefits. NO: 051833 LOC: 070 305-245-8488 Agent's Phone# Page 1 of 01 R2853-1