10/21/1998 DV03A2700
~annp 1... 1&olbage
BRANCH OFFICE
3117 OVERSEAS HIGHWAY
MARA mON, FLORIDA 33050
TEL. (305) 289-6027
FAX (305) 289-1745
CLERK OF THE CIRCUIT COURT
MONROE COUNTY
500 WHITEHEAD STREET
KEY WEST, FLORIDA 33040
TEL. (305) 292-3550
FAX (305) 295-3660
BRANCH OFFICE
88820 OVERSEAS HIGHWAY
PLANTATION KEY, FLORIDA 33070
TEL. (305) 852-7145
FAX (305) 852-7146
MEMORANDUM
TO: Peter Horton, Director
Division of Community Services
FROM:
Attention: Kim McGee, Marine Projects Coordinator
Ruth Ann Jantzen, Deputy Clerk ~/'
November 20, 1998
DATE:
On October 21, 1998, the Board of County Commissioners adopted Resolution
No. 397-1!~98 authorizing an allocation from the Boating Improvement Fund in the
amount of $1,820.00 for the immediate removal of DV03A2700, located off of South
Roosevelt Blvd., Key West, AND granted approval and authorized execution of a
Contract J'greement between Monroe County and Arnold's Towing for the emergency
removal of same.
En~~losed please find a fully executed duplicate original of the above contract for
return to .Arnold's Towing, and a certified copy of the above Resolution for your records.
If J'OU have any questions concerning the above, please do not hesitate to contact
me.
Enclosure
cc: COlLlnty Attorney
Finlance
COlLlnty Administrator, w/o document
File
CONTRACT AGREEMENT
AGREEMENT, MADE THIS P (;tf day of / ( ?itq.~J998, by and
between, Arnold's Towing
("Contractor"), and the BOARD OF
COUNT~Y COMMISSIONERS OF MONROE COUNTY, FLORIDA, of the County of
Monroe, State of Florida ("Board").
The (:ontractor and the Board, for the consideration named agr~e as follows:
1. The Contractor shall furnish all the materials and perform all the work as
....,.. '"
required by the Specifications for the emergency removal of DV03A2700 for whick::a PlQrid&P
z ..,.- z
:.;;~: ('"'''),. 0
C) ~"'"'- ~.~, ..c
Marine P'atrol Derelict Vessel Report is attached as Exhibit A. p-, N
(") , r- 0
C) C'r'.
2. ~rhe work to be performed under this contract must be completed by Octoi~f~~ ~
-\ r--- X
:< ~ ::r: . ,...
1998. ...,,' :;~ ~
I CJ (.,.)
~ fTl Q)
3. The Contractor understands the rules of the Florida Department of Environmental
Protection and shall comply with those rules, along with the rules and procedures instituted by
the Board to ensure an orderly progress to the project. Both the intent and the requirements of
the Specifications, attached as Exhibit B, are understood by the Contractor.
4. The Board shall pay the Contractor $ 1.820.00 for the removal and legal disposal of
DV03A2700. Payment will be upon completion of work by the Contractor and review and
approval by the Marine Projects Coordinator.
5. The attached Derelict Vessel Reports, Specifications, and the Monroe County Insurance
Requirern.ents together with this Agreement, form the Contract. They are fully a part of this
Contract as if repeated herein verbatim.
6. The Contractor covenants and agrees to indemnify and hold harmless the Monroe
County Board of County Commissioners from any and all claims for bodily injury (including
death), personal injury and property damage (including property owned by the County) and
..."
---
r-
rr1
CJ
..,.,
o
:N
;0
rt1
C")
o
;0
o
1
other losses, damages, and expenses (including attorney's fees) which arise out of, in
connection with, or by reason of services provided by the Contractor or any of its
Subcontractor (s) in any tier, their employees or agents. The purchase of the insurance
required in paragraph 11 does not vitiate this indemnification provision.
7. The Contractor agrees to supply the County with a set of photographs of each vessel in
all phases of the removal and disposal process. The Contractor will be responsible for the
camera, film, and development costs.
8. The Contractor must inform the County and the Florida Marine Patrol prior to initiation
of work.
9. The parties agree that a timely performance of this agreement is essential due to possible
damage to the natural resources, hazards to navigation, or threats to human health and welfare.
Therefore, the parties agree that the Contractor shall be liable to th,e Board for $100 per day of
liquidated damages for each day after 10-31-98 that the Contractor's obligations under this
agreement remain unperformed. The parties agree that such amount is by the way of
compensatory damages and does not constitute a penalty.
10. ])ue to the use of heavy equipment and, at times, dangerous work environment, the
Contractor understands and agrees to maintain an alcohol an drug free work environment.
11. Jlhe Contractor will be responsible for all necessary insurance coverage as indicated by
an "X" on the attached forms identified as INSCKLST 1-4, as further detailed on forms VL1,
WC1, W~~JA, GL1, WL1, & POLl attached as Exhibit C. All policies must list Monroe
County as additional insured with the exception of the Worker's Compensation policy.
12. l"he Contractor warrants that it has not employed, retained or otherwise had act on its
behalf any former County officer or employee subject to the prohibition of Section 2 of
Ordinance: No. 010-1990 or any County officer or employee in violation of Section 3 of
2
Ordinance No. 020-1990. For breach or violation of this provi~ion, the owner may, in its
discretion, terminate this contract without liability and may also, in its discretion, deduct from
the contract or purchase price, or otherwise recover the full amount of any fee, commission,
percentage, gift, or consideration paid to the former County officer or employee.
13. A person or affiliate who has been placed on the convicted vendor list following a
conviction for public entity crime may not submit a bid on a contract to provide any goods or
services to a public entity, may not submit a bid on a contract with a public entity for the
construction or repair of a public building or public work, may not submit bids on leases of real
property to public entity, may not perform work as a contractor, supplier, subcontractor, or
consultant under a contract with any public entity, and may not transact business with any
public entity in excess of the threshold amount provided in Section 287.017 of the Florida
Statutes, for CATEGORY TWO for a period of 36 months from the date of being placed on the
convicted. vendor list.
.\.....-ll~ WITNESS WHEREOF each party hereto have executed this Agreement the day and
~'''''''''
"
year fi~~t '.written above.
(SEAL) ;;J/'
Attest~~~NY L. KOLHAGE, CLERK
,
BOARD OF COUNTY COMMISSIONERS
OF MONROE COUNTY, FLORIDA
By:R~~J
Depu Cler
). //.~,
Witness: } . //// <. .
Witness:Q~ L~
Business Name: Arnold's Towing
B){~?~li/ a~
Title: Owner
3
EXHIBIT A
INCIDENT REPORT NA1RRATIVE CONTINUATION ZONE:
DERELICT VESSEL 3A- 2700
INCIDENT NO. 98-JA- 12890
I. REG.tHIN: Fl. 1578 AC LENGTH: ~FT. MAKE: Chriscraft
HULLMATE1UAL: WOODJ F/G_ METAL_ RUBBER_ OTHER(sPECIFY)
MOTOR: YES_ NO-X- TYPE: _ VESSEL NAMEIHOME PORT: None
OTHER IDEN1~IFIERS:
2. VESSEL OWl'rER/CUSTODIAN: William E. Newmeyer'
ADDRESS:Rt 1 Box 612 (Hollerich Dr.)
TYPE: Cabin Cruiser
COLOR: White
D.O.B.
I I
~3043
CITY/STATE/ZIP:
Rig 'Pinp l{Py, Fl
3. PIIYSICAL L()CATION OF DV: Off of seawall, South Roosevelt acroos from Key Wester Inn
LA TITUDEIL()NGITUDE (DEGREES, tv1lNUTI:S, SECONDS) N24. 32. 229/W 082.00.599
4. CONDITION: WRECKED---X- JUNKED-X- DISMANTLED---X- ABANDONED_ AGROUND_
BROKEN UP _ BURNED_ CAPSIZED_ LISTING_ SCUTTLED
5. SUBMERGED: ~ % DEPTH 3 FT. ANCHORED DOCKED ADRIFT
IN WETLANDS_ TIED TO OBJECT (SPECIFY) MARKED WITH BUOY
WASHED ASHORE BELOW M.H.W.L. ABOVE M.H.W.L. OTHER
6. PRIVATE PR()PERTY OWNER/ADDRESS: N/A
STATE SUBMERGED LAND:_ FEDERALPROPER1Y:_ OTHER: (SPECIFY)
7. PERl\1IT FOR ABANDONMENT: YES_ NO_ ISSUED BY
8. REASONS FOJR ABANDONl\1ENT: Unknown
9. TIIREA T TO r~A VIGA TION: YES~ NO_ }--IO\\T Unlighted may get hit at night.
10. DANGER TO ]~N\rIRONMENT: YES~ NO_ HOW Sitting on bottom.
11. TO'\'ED \\'ITIIOUT REPAlR: YES_ NO--L U1'\TKNO\\'N OTHER
12. RECOl\1l\lENI)ED DISPOSITION: LEAVE AS IS_ TAKE TO LANDFILL X RECYCLE METAL
HA VE THE OWNER/CUSTODIAN REMOVE IT_ TURN OVER TO ANOTHER AGENCY
MARINE HABITAT/ARTIFICIAL REEF_ OTHER
13. NARRATI\'E / DILIGENT SEARCH: (EXPL~T) No activity since 1987. No local phone listing.
No decal's (expired or current).
14. DO NOT l\1AI~K \-'ESSEL.JS: _ NOTICE DECAI-i PLA(:ED ON DV:
-16-98
Ofliccr(s) RcportiI.lg (pIC<.lsl~ print)
De ut John W.. McG~e-KCSO #7878
Reviewed By:
Reviewer's Signature
Dale
DV OfTiccr's Sigrwhu'c
Dale
1 )alc Report Completed
OBTS Nwnhcr
Original
Supplement
DEP 20-045^ (2/<JH) VI.
I )agc--L- (\f~
IL''i l."l U cl ~ 1
"-"_ __~_._=-_--=-_=-_1_~' -~ ~. ~~~~='~_'~~ ,~-~, ~-=~~~~~~-f.-~~-"- -~.<~~ .-. ~
l -\. L l ~ \J t <. l i ~ J-\. t~ t "- i~ l l. \l t.: ~ U l" l ll... U t ~ 1 1 U l ~
-,<~;
:';t
01.
". 1- - "
4~~' . .,
DERELICT VESSEL i ~A.
,,>,; ,,,:' ;tl.~':' ',:.".;'>.:,1.., ....,; ;,.".~~ltf&
'.. ,'" F.:""'..\ ~<'t\ ?":i(''''Af''1"~~~~_
. . ;<:.,,:1:~;!;\~tji:~tl~~~f~~;;'~}~?~~
v... , .-
I, ~~" .
~
~
~
}
'...... ..,...:.\,:j.....,: r I-
'; " ?4~_'~:. " '''l~'
\
o ( fl ce r( ~ 1 (~" Il' Jr tll\' J ((ll ( , :1,') (1 I', ,f \ I \ \ 1
Deputy John W. Hcc(~('-I/~)]B
Meso
\ -;'~'~~:~,~j II II ,-
j
I
(:i:\((~
p('\f(( 'VJ\ '( 1
N
>:.....
~
C'-'
\ ~ /\@
>- u~ ~~c ~<~_:L
, ./ ,....
('oJ
\~8
(")
~.,
'" . (")
b
~" ~
~ :.: (")
>- ('-oJ
C") ..;:~
.,:::.. .
~'N
1O
M
M.
M
~
..:t
..:t
("")
~w
~
...... -.:
... .....
an
\0
&f)r
~
N
I
~
· II
~
...
"
'-
...
N X
N
~ N
"
~
~ -- ~
~ --M~ta:~
:---:::::: :::::::. ::::::::::'~~-';'':: ~ f M
,,> Ll) ~: (\~ !,
. f ~.::-:,.
) ~ t M ~ ~....: N
..n ~ ..n 0 ~.... ....
~.,~ g Ii-
. .J:;:::::r::::::::::" ~.-
C'it
C'i
("")
\D
("')~
~
M ..
("-.I ~ 4
a:;- ~ ~
(") 4" a:: m C"') t't"\
t"""t =- 4 :-
~ . a:-
Gl
~ ...
...
0- ~
...
.:;
C~~
~ " C\/'~
~ / ~ M
I
'.::.. c;
Ll) M N \::O~ ..'::
.:::r: ~ C'~~e~r N
:::).~'" ~ 0 __ ~
~----: -- ~ N
e'~~[~ ~~ <0 l.':" _
.." " -:2!.. . _ .~_... ~)
:~:_-;~:.". ....\- ~..l N
i....??\ ? <:> =' _ '_.
c?--; . - .... .' .. 0. ..
. ..'" \\ -' ~... i
"9/ .-:..::.'. 0
,-~ ~ M
.,,'-".... ~ I
'" --"--:: 1\0
........
......,,'-.....
1r................ ...
.........
.........
I
tN N 1
~ ----~
~ () ~':"'. ..r ~:-- 1 ~
"';'::";~~':::~"-c/~>1~; ~~.. (,able Ar: l' ~ ~
M ) ".~".,;,~:;y M~';.:"' " ~;- - - ::- .:: f
. /'>r:~;~j:_~.~;- "~"~~~;:....~:..
~ ~...- - i..: .;..,.~ ."," :........ ~ lQ,Y.Q -"~:'Iia~
(') -----.,---. ~ :9'~ . " .... .:" -4' ;:!l=..... ,. . _ ~" . :~:
'." - - '- ~ ~ . . -'- ....-...... . .. 1>'- "" __. . ___ ...?~ .
:~ ~ ~--- ~; / ~.~~: ': ..~r.'i;:...r t::.~ ~~.,,~::-1~~::~
C<' -~. It: 00".. '. . '. '. _". 0.
M .~ . ~ ~ ~~.1~:;/.: ....... ~ '.J ~
~ ,., ~- \.' - '-'''""'. '..N
"'oi U - ":'f~ 1~::__.' ':.. ~
: ->b, ~ \ ~
("")
N
-~
.
~
~ ("")
-" ~
t.. ...
~j .
~:s : N
~t 0
N
N
('\; ..::- -4' i 'Gi '!. ~
IN ~
~ t .:f:.."
M
N
LO
N
"ffi;
"c:J
\
. \
'. .~ .. "'(""
No.
r
E c)
"'2C1.
V)Q
,~
\- <:>
--..l . . /
~ '/'(1)
\
\
\
\
\
\
~:
-)'
----,/
/ ./
,/ ,/
,/ /
,/ ,/
/' ,/
;' ./
;' ;'
/
;'
.J_
()
1
I
a
Lu
Q::
:J
C)
In
CJ
o
'/.\:
,'w
~
~
'0 ~
N 0
II / 'rr f L.:
,". 0<, J"'r .;;: 0 ,
.~~) ';~()
INCIDENT REPORT NARRATIVE CONTINUATION REPORr. _9~"~,-, \..2..&9-CL_
. ................................ ...... ..... .... ..... .... ...........~_..3.~..~._.. .... ..~:::T..Q..o-._.... ...... -....... -.................. ........ ....... -.. - .....-
........... ............. ...... ..... ......._ ... _... _. ......_. ..._ _ ._........................ ..... .............. ....... .................... ...... ........ .. ...... ,. . I." ... ... ... ..... -. ........... ....... .......... .. ........... ...... ...... ..... ,..... .. . .. .. .... .. ...... ..... .. . "" ... . .. . .... .... . . I . . . . .. . , .... ... . .. , . .. .... . .. .... .. .... . .. . Il.' . '" . . .. .... . .... .... . .. .. """ ...... ...... .. . . ...... """
................_lu .l~......Va~.E.1-......\.-:lASl.......~~..~-E'O - .....v.~......Q.~ ... ...1'.l..\.~...... IS. ~c....~. -.... _~~.~ ......... ...... .......
...........__....x~~..... ...6E:.s...~........~.~.$_..~..~ .~.h-J....... -.. ~ .o~.e.\- ........'- ~ ...... ...~e. ~...... .~E ~~. -. -.
u........... .....:r. ~ ~.$....... v .~~ "6..1.-.. ..... ~ e..~s.. ~.o.6 10.. .... .lZ..c..^^- o.v~Q ... - J hAM.e: DJ .~-:r. e-:. '- '1'.~
w
>
t=
~
a;
ct
Z
Revi~w~r.s Signature
Uol Officer(~) Reportinkl fp(e~$~ print}
~
,...
~ Revi8wed By:
~
eft
2
~ Citetion Numbor
o
Co
Numb~1 Arr.stod
oaTS Numb~r
Original 0
Supol.mt:nt 0
DfP .2O-04SA (8/94]
PAQfj
of
, -. -
....
....
"a
NARRATIVE CONTINUATION
~
o
c(
1. Offenae
2. Arreat
)C~f2
- ~A
of
f t" _)~ ')r C(f;
z
o
i=
<(
:::>
z
i=
z
o
u
w
>
i=
<(
IT:
IT
<(
Z
~~~t A ~')v I ;>f b 1 jJ kr
,y ALJ~ ~L- p-r if-If
, ' ) , / . -~
^ /;' . \ "! (:. (;f.' 1\ f t v1 [) v('eJ)
, I /-
( L/tt3n)J (,{ (,( ( S f /rl__ ' ;~1? f7rZ ErI ~O
. I" .-\ -
-1, ..:.., j' ) c"") ( , kl ,^ - · "\ e L C (/~, J I cf J 7
), I ,./ 1" }, VV - l .' l--(/ J \
(~ D1:1 /) I Jl r) /\ f i1f) /1/ oX Lfc) 7:; 5,,1i~ Jli t'/7 r; tv
I AI /41~llT 2) 1- t:>' ~J/4T [~_ ( j'7
C " I L i J ttJ l\ ~ ! ,1.:1 (r~ ,~u~ C ,;;,71 {/2; I (;'
il: I 1\ t/ /....j / r J I II / .' / .I"
~ I [ i~ 'Jf (' (\ It ; r ~) '- ( TJ.II ~7 f? i Q a ;.::c;-r ~ (
"';'r )1.,'(.) /)!is<-:::ri ,-:;.i--~' 1/:' fJ\..": .:'.) /J -~J r J <.;,~,
\ ,-' i \,,..' / ,/ .~./",.. ( !. ~.'. - ,I! /) ^ ,/ c
/! .,}/)/{ l~~ )~ '-Z 5 {T'
)''],./} c' '/ ~'l ti AI /2 A ;' J ' A-
I :~ I~ /AJ()OD ~~ l. l ~ J"
! - t<:) r'" I )'- \
I } S./Y11jAJ f L G-J )
()\ cl f: ~) 0 t-~-l0./ l
t f'i?J c, l);:;
.'.:.~ C_,)
IVI \ 1: /
, 1 ,f , .1 .
: \ ,
l\/"~ "1'~ ( ~-/,C
/ /' v:' ) < ( ../
--7 /-/-;~-
.' I . l
I ;
/.- ,".-. ' . ~ I l...r - / <:
! //!( / /ll / t -../
/~ (
L,.~c:~') .:~.:(.~ L. ! / I ~+ !..~
//tl{ i.'
r ,/ .'~
) ~ ( ,i ' : t
/ ,{ .-1
I } .J l
/; C';( i) ! )\) I~} 'r- D;< / -1 )~l
- · I /; .'~: '7 /~;:? (/ r};2 7);; ~-;) .J y.; ;
/,>r j'; j. Z' r (' -r-
J.'-', l<: ( . '.- I
fCl'-~ i I
(;-t (~--.)\:, I
I
l
l/~ ~;. ~ ,"- { t
/'
r<"> })(', J( j
r'
rb (--c-: ' { {: J.A,\ _
I
1
I
j
I
I
I
I
I
I
I
I
i
I
i
I
-I
I
f l.'I" "1 ,
~' ! / (
( / ; / ( :'0
.,.------~--r
/ r,~, 4f1171LJ,' r ",),
-, ',.
. ._"""',,ed ; 01) (; j~~::,~~,; ,
H":"I,,,j [1"1'(1'1 IJllllI! Ii-'f(~)
~~ I )111' "'1~ i 1~"I"llil<i~J
I
<l.
g- Olllef'l li'~\'I('v-.lflq (II
<!)
LJ
.J
llllll
/
I
I ~111 11,-. j 1, I
H.,
[ :.11.
ell'CHallce 1 vpe
^" t~',1
I ,(', 'j l\ " 111.11
TN~I~; 'm", led
EXHIBIT B
l[)ERELICT VESSEL REMOVAL CONTRACT SPECIFICATIONS
FOR MONROE COUNTY, FLORIDA
1. ThITENT: It is intended that these specifications shall cover all aspects of the work.
Th.e purpose of this section is to provide specific conditions applicable to this
co:ntract where such coverage is not provided in other portions of the documents.
2. BID FORMAT: A dollar amount per foot must be submitted for the removal of as
many derelict vessels on the primary list for which a Florida Marine Patrol Derelict
Vessel Report is provided and as funding will allow. Any deviation from this
format will result in an unaccented bid. A contract will not be granted on the basis
of combined, related, linked, or discounted bids. Not applicable due to emergency
rernoval of one or more derelict vessels for less than $25,000 total.
,
3. PLANS: There are no plans for this project, but copies of the Florida Marine
Patrol Derelict Vessel Report with location sketches have been bound into these
documents for the Contractor's use. The Specifications include a section on
instructions to bidders, both general and specific, and a copy of each Derelict
Vessel Report from the Florida Marine Patrol. Only those derelict vessels for
which a report is included and listed on the Bid Response Form are to be bid upon
ancl subsequently removed.
The County reserves the right to remove any or all vessels from this contract at any
timle prior to actual removal from the water and disposal by the Contractor.
The County has a limited amount of money to effect the removal of these derelict
vessels. We have established priorities based on public safety, navigational hazard,
ancl environmental considerations. If bids exceed the County's resources for
renloval based on these considerations, we shall limit vessel removal based on the
cOfLsiderations and cost effectiveness. '
4. VESSEL IDENTIFICATION AND LOCATION: Each of the vessels have been
given a derelict vessel identification number, which is shown with the location in
the Florida Marine Patrol Derelict Vessel Report, included herewith.
Each bidder is responsible for his own identification of each derelict vessel as to
location, description and condition. If a derelict vessel cannot be (1) located, (2)
remloved, (3) verified and (4) disposed of, as specified in these procedures, then no
payment will be made forthcoming to the Contractor for that vessel. Those four
conditions must be met on each derelict vessel along with compliance of all laws
for .paymellt to be made.
It is understood that the Contractor has, by personal examination and inquiry, if
necessary, satisfied himself as to local conditions of each derelict vessel and as to
the meaning, requirements and reservations of the specifications; for after contract
letting, no deviation will be allowed. In case errors are discovered, they are
to be reported by the Contractor to the County. The county assumes no
responsibility should there be any discrepancies in what is stated in these
documents and what the bidder evaluates.
Th,e Contractor should take special care to remove only those derelict vessel's on
his Contract and for which he possesses a Florida Marine Patrol Derelict Vessel
Report. Other derelict vessels in the area but not under Contract, cannot be
molested.
It lnay be possible to replace a derelict vessel of like kind, for the same or less
money, when mutual agreement can be reached by the Florida Department of
Environmental Protection, Monroe County Administrator of the Derelict Vessel
Program, and the Contractor. This will be applicable when a contracted derelict
vessel cannot be located. No derelict vessel may be replaced and removed without
the tri-party consent noted in this paragraph. A contractor may suggest a possible
ref)lacement vessel but he may not remove it without the appropriate consent above.
5. SCOPE OF WORK: The Contractor shall be responsible for providing all permits,
SUIJervision, labor, equipment, tools, fees and taxes required to complete this
project to the satisfaction of the County.
The Contractor's procedure and methods of removal may be of his own selection
provided they secure results which satisfy the requirements of the Specifications
an,l any necessary environmental permits.
Any vessel which is removed and disposed of shall be removed from its present site
in such a manner as to do the least possible damage to the natural environment.
All debris from the vessel shall be removed and the site left in a reasonably clean
corldition. No oil or fuel shall be permitted to be dumped or spilled into or unto the
water or land. All pollutants shall be removed from the derelict vessel prior to
renloval fi40m the water.
The Contractor shall be responsible for making any and all arrangement for access
to tIle vessel to be removed. If private property has to be traversed, then written
permission of the owner is necessary. In removing a derelict vessel that may lie on
or Jt1ear grass or sponge flats extreme caution must be use,d to do the least possible
danrlage.
2
Prior to delivery of derelict vessels to the disposal site, the Contractor must remove
all oil, gas and engines. He must dispose of them in any legal manner. Pure used
oil will be taken by Monroe County for disposal. Mixture of oil, gas, seawater or
an:y combination of the three must be transported from the County by an approved
hazardous waste handler. The names of handlers will be supplied by the Monroe
County Solid Waste Department. Metal becomes the property of the Contractor.
6. Mi\ TERIALS AND WORKMANSHIP: The Contractor shall provide the
necessary materials and equipment to safely complete the job. The Contractor
agrees that all work shall be performed by competent employees who are
ex]?erienced and qualified to do the work specified, and that all work will be
performed in accordance with the best commercial practices. A list of equipment
to "be used and a description of the removal and transporting procedures to be
followed must be provided to the County at the pre-work conference described
below.
Precaution shall be exercised at all times for the protection of persons and property.
The safety provisions of the Occupational Safety and Heqlth Act of 1970 (Public
La'w 91-596) and other applicable laws, including building and construction codes
shall be observed. Machinery, equipment and other hazards shall be guarded in
accordance with safety provisions of the "Manual of Accident Prevention in
Construction", published by the Associated General Contractors of America, to the
extent that such provisions are not in contradiction of applicable law.
If any property is destroyed by any cause or means whatsoever, the Contractor shall
rep'air and replace or not receive payment for the unaccomplished work. The
Contractor shall maintain suitable and sufficient guards and barriers, and at night,
suitable and sufficient light or other appropriate security or protection for the
prevention of accidents.
Use of explosives is prohibited in carrying out the project.
7. ASSIGNMENT OF CONTRACT AND SUBCONTRACTS: It is expressly
unclerstood that the Contractor is in all respects an independent Contractor for this
work, not withstanding under certain conditions he is bound to follow the
directions of the County, and is in no respect an agent, servant, or employee of the
COllnty. Neither the Contract, nor any part thereof, nor any Moines due or to
become due thereunder, may be assigned by the Contractor without the prior
written approval of the County.
The Contractor is fully responsible to the County for the acts and omissions of his
subcontractors and of persons either directly or indirectly employed by said
3
su'bcontractor, as he is for the acts and omissions of persons directly employed by
hiln. Nothing contained in the relation between any subcontractors shall abide by
the terms, conditions, and requirements of this Contract. It is the responsibility of
the Contractor to pay all debt obligations incurred with subcontractors in an
ex.pedient manner.
8. LI~GAL RESTRICTIONS. PERMITS AND TRAFFIC PROVISIONS: The
Contractor shall comply with all applicable local, State and Federal requirements
pertaining to the terms of this Contract. The Contractor will be responsible for
obtaining, at his own expense, any licenses or permits that may be required and
should inquire about permit requirements with the appropriate agencies. The
Contractor shall comply with all the requirements of the Federal Pollution Control
Act.
Th.e Contractor shall conduct his operations so that he shall not close any
thoroughfare nor interfere in any way with traffic on higl1ways, or on water,
without the written consent of the proper authorities. Work shall be done at any
tinle that shall not interrupt or disturb members of the public.
Utilization of off-loading sites located on private property (water to land for
transport to the landfill or other disposal site by vehicle) must have written
ap]Jroval of the land owner.
The Florida Marine Patrol should be contacted to initiate eviction proceedings for
cOlltracted derelict vessels which are inhabited at the time of removal and when
another vessel is too close to the contracted derelict vessel to allow safe operations.
Direct confrontations with other boaters should be avoided and the Florida Marine
Patrol should be contacted immediately if such confrontations results from removal
of any contracted derelict vessels.
9. INSURANCE: The Contractor must obtain insurance required by the County and
submit proof of same to the County prior to acceptance of bid and contract approval
by Board of County Commissioners but no later than five working days after notice
of low bidder. All insurance shall be maintained until work has been completed
ancl accepted by the County.
The Contractor shall furnish the following certificates of insurance for review by
the COUllty'S Risk Management Division:
Ce11ificate (s) of Insurance which clearly indicates that he has obtained the
insl1rance coverage required in paragraphs a,b,c and d below.
The Contractor hereby certifies that no modification or change in insurance shall be
made without (10) days written advance notice to MONROE County, c/o the
Dir1cctor of the Risk Management Division.
4
a. Worker's Compensation Insurance per FI. Statutes
b. Federal Jones Act Coverage
c. Gt~neral Liability Insurance on a comprehensive basis, in an amount not less than
$500,00.00 per occurrence for Bodily Injury and Property Damage combined, to
include contractual liability.
c. Pollution Liability Insurance in the Amount of $500,000.
d. Water Craft Liability Insurance in the Amount of $500,000.
e. AlLtomobile liability insurance covering all owned, non-owned and hired vehicles
used in connection with the work, in an amount not less than
$300,000 per occurrence for Bodily Injury and Property and Damaged combined.
All insurance policies required above shall be issued by companies authorized to do
business under the laws of the state of Florida. The MONROE County Board
of County Commissioners must be listed as "Additional Insured" on all policies,
except for the Worker's Compensation policy.
10. CC)MMENCEMENT~ DELAYS AND COMPLETION OF WORK: After
receiving Board of County Commission approval of the C;ontract, and after
reconciliation of any details or conditions which may directly or indirectly interfere
or conflict with work of the Contract, the County will issue a "Notice to Proceed"
officially authorizing the Contractor to commence. The Contractor shall
COlnmence work within one week from the date on the "Notice to Proceed" letter.
If the Contractor should be delayed in the progress of the work included in the
Contract by enforceable causes beyond his control, the time for the completion of
the work may be extended upon agreement of the County representative. Requests
for an extension of time must be submitted in writing to the County representative.
Extensions of time cannot legally be approved unless the written request is
submitted in the time to permit it to be acted upon before the Contract expiration
date. To allow sufficient time for the administrative procedures required to obtain
action by the County Commission, a request for time extension must be received by
the County representative at least sixty (60) calendar days prior to the Contract
eXI>iration date.
Provided further that the Contractor shall within ten (1 0) days from the beginning
of such delay notify the County, in writing, of the causes of the delay. The County
representative will ascertain the facts and the extent of the delay and notify the
COlt1tractor within a reasonable time of her decision in the matter.
5
If the Contractor fails to complete the work within the time limit, and if the County
should nevertheless permit the Contractor to continue and complete the same
without official extension of time in writing, such permission shall not modify nor
waive any liability of the Contractor for damages arriving non-completion of work
within the time limit, but such liabilities shall be subject to continuation in full
force against the contractor.
11. CI-IANGES AND INSPECTION: The vessels herein considered are to be removed
for the County by the Contractor in accordance with the specifications. The County
may give instructions or directions to supplement the specifications. These shall be
bin.ding upon the Contractor and upon all his subcontractors, employees and agents
of every kind.
All work and every process and operation shall be subject to inspection at all
timles, and the County and their representatives shall have free access to all aspects
of the work. The Contractor shall remove and make good, as may be directed,
without charge, any defective work. Oversight or error of judgment of
inspections, or previous acceptance, shall not relieve the Contractor from the
obligation to make good any defect whenever discovered~
The right is reserved to change the Specifications consistent with regard to the
gerleral intention of the contract for any part of the work or materials, either before
or after work has begun. Notice of such changes shall be given in writing to the
Co:ntractor; such changes are not to be grounds for any claim by the Contractor for
darnages, nor for the forfeiture of the Contract. It is possible that a Derelict Vessel
cOlLld disappear between the time of inspection by the contractor and the actual
eff()rt to remove it. No payment will be forthcoming in event that this occurs.
Except when otherwise specified, the expense of all tests requested by the County
will be borne by the County.
12. AUDIT RIGHTS: As a provision of the grant from the State of Florida to the
COllnty, and if so requested by the State, the successful bidder agrees to provide
access to all records and allow the audit of any books, dCfcuments and papers
related to this project for a period of up to one year and during and after termination
of the contract.
13. CONTRACT AWARD: The County reserves the right to evaluate the submitted
bids and award a contract to the bidder submitting the lowest per foot bid for the
derelict vessels listed in the bid package as one project and for which a
Florida Marine Patrol Derelict Vessel Report is included. One bid will be accepted
and a Contract issued for the total renloval of all listed derelict vessels as one
project, up to the limit of available hInds.
6
The actual number of vessels to be removed will depend on the accepted per foot
bicl price and the available funds.
14. f,BEWORK CONFERENCE: A meeting will be necessary involving a
reI~resentative of the County, the Contractor and other parties with direct
in\rolvement prior to the signing of the Contract. The time and place of this
cOllference will be set by the County representative. At this time the Contractor
shall provide the County with a schedule as to the order in which he proposes to
reI1nove the vessels awarded to him.
15. C()NTRACT SECURITY: The Contractor is expected to act and deliver in good
faith all work, at the agreed price, in the allowed time. Failure to do so, could
jeopardize the contractor's reputation with the County and potentially influence any
future contracts with MONROE County.
16. E)(ECUTION OF CONTRACT DOCUMENT: Due to the time frame involved
with this project, the Contractor upon notification that he is to be awarded the
COIltract documents for execution, shall return said documents properly executed
along with insurance within TEN WORKING DAYS. This will assist in
acceleration of execution of the contract documents.
The Contractor, by virtue of signing the Contract, acknowledges that he and all his
sut)contractors have satisfied themselves as to the nature and location of the work,
the general and local conditions, including, but not restricted to, those bearing upon
trallsportation, handling, access to the pick-up and disposal sites; and the character
of equipment and facilities needed to perform the work. Failure on the part of the
Co:ntractor to completely or properly evaluate any factors of his costs prior to
bidding shall not form a basis for additional compensation if he is awarded the
Co:ntract.
If for any reasons, not acceptable to the County, the Contractor does not perform,
the County shall have the right to levy liquidated damages against the Contractor.
Liquidated damages in the amount of $1 00 per day shall be assessed against the
COlltractor for any bid item awarded to him which is not completed and accepted
by the County within the number of calendar days specified in the Contract.
Liquidated damages are accumulative.
17. NOTICE TO PROCEED: The Contractor shall commence work upon this project
within one week of the date of the Notice to Proceed letter and perform in a
continuous manner until completion and acceptance by the County. For Contracts
wherein a specified number of days for completion is stated in the Contract, the
effective date of the "Notice to Proceed with Contract Work" will establish the
"beginning date" of the project.
7
18. TI~RMINA TION OF CONTRACT: This Contract may be terminated by the
County, giving up to ten (10) days written notice to the Contractor; said notice
shall be sufficient if delivered to the party personally or mailed by certified mail to
his mailing address as specified on the accepted bid.
19. EINAL CLEAN-UP: Upon completion of the work specified herein and before
acceptance and final payment shall be made, the Contractor shall remove from the
sit'es all machinery, equipment, surplus and discarded materials and temporary
structures. The disposal of materials, rubbish and debris ;hall be made at a legal
disposal site.
20. DISPOSAL SITES AND FEES: The Contractor is responsible for disposal of all
derelict vessels included in this contract and must make arrangements for legal
disposal. It is the responsibility of the Contractor to pay all disposal fees
incurred, and such removal related costs should be considered when bidding on this
COlltract.
The Contractor will deliver the derelict vessels to a Florida Department of
Environmental Protection permitted disposal site that has current occupational tax
licenses. It is the intent of this contract to remove derelict vessels from their
present site and legally dispose of them. Upon receipt of vessels at the landfill,
they must be disposed of immediately.
There are several Monroe County disposal sites, Cudjoe Landfill, MM 21.5
(ve:ssels must be 26' and under to be delivered in tact, over 26' they must be
broken up), Long Key Landfill MM 68, and Card Sound Road AKA SR905 other
landfills in neighboring countries or any other location for disposal as long as the
site is a legal licensed disposal site. Prior to transportation of vessels out of
County the County representative must approve. Vessels being disposed of at
County Landfill sites must be free of pollutants and engines.
21. PROOF OF PROPER DISPOSAL AND NOTIFICATION TO MARINE
PATROL: Contractor must submit prior to receiving any payment: A receipt for
each vessel including the date of disposal, the Florida Marine Patrol Derelict Vessel
Number, disposal site location, and the telephone number. Recipient of debris
should provide detailed receipt showing type and description of debris received.
In addition to the above information, Contractor must submit three pictures of
each vessel removed. The first photograph must be of the vessel at the current
location prior to removal, the second photograph must be of the vessel after
rerrloval but in the same general area preferably while in tow, and the third
photograph must be of the vessel at the disposal site with sufficient background to
depict disposal (i.e., building or sign identifying disposal site). The derelict
vessel number, when possible, must appear in all photographs.
8
The Contractor will be responsible for the camera, film, and development costs.
The photographs should be taken with a Polaroid camera that provides instant
photos since this minimizes loss of documentation due t<1 camera malfunction or
loss overboard. This photos must be submitted on a vessel by to document the
rernoval and disposal of the contracted vessels final payment can not be assured.
The Contractor must notify the Florida Marine Patrol and the County
Representative in writing as to the work schedule of removal. This should be done
after the pre-work conference with the County representative. Notification is to be
made before doing any work on each vessel. This multiparty communication for
each Derelict Vessel is a requirement of the contract.
22. P A~YMENT: All payments for the removal and disposal of each vessel, shall be
for the performance of the work as stipulated in these specifications and associated
cOlltractual documents. The unit rate of bid shall be totally inclusive for all phases
of the operation. The Contractor may request two partial payments by submitting
an invoice for the number of vessels removed up to the date of the invoice,
providing the Contract agreement does not explicitly prohibit partial payments.
Photographs, disposal receipts, and signed FDEP Disposition Certification form for
the vessels for which payment is being requested.
The Contractor understands and agrees that no payment will be forthcoming for the
renloval and disposal of any derelict vessel (1) not listed on this contract nor (2) for
an)f derelict vessel on this contract for which a written certification verifying the
renloval of the subject vessel has not been obtained from the Florida Marine Patrol
anel a Representative of the disposal site at the time of delivery.
In addition, property, public or private, if damaged during the work or removed for
the convenience of the work, shall be replaced at the expense of the Contractor in a
manner acceptable to the County and the Owner, prior to the final payment for
corltracted work.
23. NC~N-COLLISION AFFIDAVIT: Upon entering into the contract, the Contractor
agrees to sign and endorse the Non-Collusion Affidavit form (attached).
24. ETHICS CLAUSE: Upon entering into the contract, the Contractor agrees to sign
andl endorse the Ethics Clause form (attached).
25. DR.UG FREE WORK PLACE FORM: Upon entering the contract, Contractor
agrees to sign and endorse the Drug Free Work Place form (attached).
26. DERELICT VESSELS AT ISSUE: The derelict vessels listed on the Derelict
Vessel Working List for 1997 shall be removed and disposed of by the Contractor
in accordance with the provisions of these Specifications.
9
t',
.'
,
EXHIBIT C
1996 Edition
l\10NROE COUNTY, FLORIDA
INSURANCE CI-IECKLIST
FQR
VENDORS SUBM:ItTING PROPOSALS
FOR 'VORl(
To assist in tl~e development of your proposal, the insurance coverages marked with an "X" will
be required in the event an award is made to your firm. Please review this form with your
insurance agent and have himlher sign it in the place provided. It is also required that the bidder
sign the form and submit it with each proposal. .
\\'ORKERS' COMPENSATION
AND
EJ\1PLO)TERS' LIABILIT~
wel
WC2
\\'C3
VlCUSLH
X \\'orkers' Compensation
X Emplo)'ers Liability
Employers Liabilit),
Employers Liability
US Longshoremen &
Harbor V/orkers Act
X Federal Jones Act
\\' CJ A
INSCI<J--,Sl' 1
Adfl1inislralion Instruction
1/4709,2
Statutory Limits
$ 100,000/$500,000/$100,000
$ 500,000/$ 5 00,000/$ 5 00,000
$1,000,000/$1,000,000/$1,000,000
Same as Employers'
Liabilit),
Same as Employers'
Liability
1996 Edition
GENERAL l..lABILITY
As a minimum, the required general liability coverages will include:
· :Premises Operations
· :Blanket C9ntractual
· JExpanded Definition
of Property Damage
Required Limits:
GLI
x
GL2
GL3
GL4
Required Endorsement:
GLXCU
GLLIQ
GLS
Prqducts and Completed Operations
Personal Injury
.
.
$100,000 per Person; $300,000 per Occurrence
$50,000 Property Danlage
or
$300,000 Combined Single Limit
$250,000 per Person; $500,000 per Occurrence
$50,000 Property Damage
or
$500,000 Combined Single Limit
$500,000 per Person; $1,000,000 per Occurrence
$100,000 Property Damage
or .
$1,000,000 Conlbined Single Limit
$5,000,000 Combined Single Limit
Underground, Explosion and Collapse (XCU)
Liquor Liability
Security Sef\,ices
All endorsements are required to have the same limits as the basic policy.
Adrninislr ,Hion Instruction
#4709.2
INSCKL~srr 2
1996 Edition
VEHICLE LIABILITY
As a minimum, coverage should extend to liability for:
· Owned; Non-owned; and Hired VehjGles
Required Limits:
VLI
VL2
VL3
VL4
BRl
1\1\' C
PROI
PR02
PR03
POLl
POL2
POL3
EDI
ED2
GKl
GK2
GK3
WLI
x
x
x
Ad III i n i strat ion I nstruct ion
#4709.)
$50,000 per Person: $100,000 per Occurrence
$25,000 Property Damage
or
$100,000 Combined Single Limit
$1 00,000 per Person; $300,000 per Occurrence
$50,000 Property Damage
or
$300,000 Combined Single Limit
$500,000 per Person; $1,000,000 per Occurrence
$ I 00,000 Property Damage
or
$ 1,000,000 Combined Single Limit
$5,000,000 Combined Single Limit
J\1ISCELLANEOUS COVERAGES
Builders'
Risk
Limits equal to the
completed project.
Motor Truck
Cargo
Limits equal to the maximum
value of anyone shipment.
Professional
Liability
$ 250,000 per Occurrence/$ 500,000 Agg.
$ 500,000 per Occurrence/$ 1 ,000,000 Agg.
$1,000,000 per Occurrence/$2,000,000 Agg.
$ 500,000 per Occurrence/$l ,000,000 Agg.
$1,000,000 per Occurrence/$2,000,000 Agg.
$5,000,000 per Occurrence/$10,000,000 Agg.
$ 10,000
$ I 00,000
Pollution
Liability
Employee
Dishonesty
Garage
Keepers
$ 300,000 ($ 25,000 per Veh)
$ 500,000 ($100,000 per Veh)
$ I ,000,000 ($250,000 per Veh)
Watercraft Liability $500,000
INSCI{LS1"' 3
1996 Edition
rnSURANCEAGENTSSTATEMENI
I have reviewed the above requirements with the bidder named below. The following deductibles
apply to the corresponding policy.
POLICY
, I
DEDUCTIBLES
Liabilit), policies are _ Occurrence
Claims 1\1ade
Insurance Agenc)'
Signature
BIDDERS ST A TEMENT
I understand the insurance that will be mandatory if av,rarded the contract and will comply in full
\vith all the requirements.
Bidder
Signature
INSCKI~ST It
A d rn i n i s t r a l ion Ins l rue l i () n
#4709.2
1996 Edition
'VORKERS' COMPENSATION
INSURANCE REQUIRE1\1ENTS
FOR
CONTRACT
,
BET\VEEN
1\10NROE COUNTY, FLORIDA
AND
Prior to the commencement of work governed by this contract, the Contractor shall obtain
Workers' Compensation Insurance v.~th limits sufficient to respond to Florida Statute 440.
In addition, the Contractor shall obtain Employers' Liability Insurance with limits of not less
than:
$ I 00,000 Bodily Injury by Accident
$500,000 Bodily Injury by Disease, policy limits
$ 100,000 Bodily Injury by Disease, each employee
Coverage shall be maintained throughout the entire term of the contract.
Coverage shall be provided by a company or companies authorized to transact business in the
state of Florida.
If the Contractor has been approved by the Florida's Department of Labor, as an authorized self-
insurer, the County shall recognize and honor the Contractor's status. The Contractor may be
required to submit a Lel1er of Authorization issued by the Department of Labor and a Certificate
of Insurance, providing details on the Contractor's Excess Insurance Program.
If the Contractor participates in a self-insurance fund, a Certificate ofInsurance will be required.
In addition, the Contractor may be required to submit updated financial statements from the fund
upon request from the Count)'.
\VCI
Adrninis(ration Instruction
#4709.2
1996 Edition
\\'ORKERS' C01\fPENSA TION
INSURANCE REQUIREMENTS
FOR
CONTRACT
I I
BET\VEEN
1\10NROE COUNTY, FLORIDA
AND
Recognizing that the work governed by this contract involves Maritime Operations, the Contractor's
Workers' Compensation Insurance Policy shall include coverage for claims subject to the Federal Jones
Act (46 U.S.C.A. subsection 688) with limits not Jess than those specified for Employer's Liability.
The Contractor shall be permitted to provide Jones Act Coverage through a separate Protection and
Indemnity Policy, in so far as the coverage provided is no less restrictive than would have been provided
by a Workers' Compensation policy.
\\'CJA
A drn in lstrat i on J nSlruc[ i () n
#4709.2
1996 Edition
GENERAL LIABILITY
INSURANCE REQUIREl\fENTS
FOR
CONTRACT
,
BET\\'EEN
1\10NROE COUNTY, FLORIDA
AND
Prior to the commencement of work governed by this contract, the Contractor shall obtain
General Liability Insurance. Coverage shall be maintained throughout the life of the contract and
include, as a minimun1:
· I>remises Operations
· f)roducts and Completed Operations
· I~lanket Contractual Liability
· F~ersonal InjuI)' Liability
· Expanded Definition of Property Damage
TI1e minimum limits acceptable shall be:
$300,000 Combined Single Limit (CSL)
If split limits are provided, the minimum limits acceptable shall be:
$100,000 per Person
$300.,000 per Occurrence
$ 50:,000 Property Damage
An Occurrence Form policy is preferred. If coverage is provided on a Claims Made policy, its
provisions should include coverage for claims filed on or after the effective date of this contract.
In addition, the period for which claims may be reported should extend for a minimum of twelve
(I2) months following the acceptance of work by the County.
The Monroe County Board of County Commissioners shall be named as Additional Insured on
all policies issued to satisfy the above requirements.
GLl
AdllliJlislralion Instruction
1/4709.2
1996 Edition
VEHICLE LIABILITY
INSURANCE REQUIREMENTS
FOR
CONTRACT
BETWEEN
l\10NROE COUNTY, FLORIDA
AND
Recognizing that the work governed by this contract requires the use of vehicles, the Contractor,
prior to the commencement ofvlork, shall obtain Vehicle Liability Insurance. Coverage shall be
maintained t]l1roughout the life of the contract and include, as a minimum, liability coverage for:
· Olwned, Non-O\\7J1ed, and Hired Vehicles
The minimuln limits acceptable shall be:
$100~tOOO Combined Single Limit (CSL)
If split limits are provided, the minimum limits acceptable shall be:
$ 50~,OOO per Person
$1 OO~OOO per Occurrence
$ 25~OOO Property Damage
The Monroe County Board of County Commissioners shall be named as Additional Insured on
all policies issued to satisf)r the above requirements.
VLl
Administration Instruction
#4709.2
80
1996 Edition
POLLUTION LIABILITY
INSURANCE REQUIREMENTS
FOR
CONTRACT
BET\VEEN
MONROE COUNTY, FLORIDA
AND
Recognizing that the work go\'emed by this contract involves the storage, treatment, processing,
or transportirlg of hazardous materials (as defined by the Federal Environmental Protection
Agency), the Contractor shall purchase and maintain, throughout the life of the contract,
Pollution Liability Insurance which ""ill respond to bodily injury, property damage, and
en\'ironmental damage caused by a pollution incident.
The minim urn limits of liability shall be:
$500,000 per Occurrence/$ 1,000,000 Aggregate
If Co\'erage is pro\Tided on a claims made basis, an extended claims reporting period of four (4)
years \\ri II be required.
POLl
Ado1 in istrat ion Instruction
#4709.2
71
1996 Edition
'VA TER CRAFT LIABILITY
INSURANCE REQUlREl\fENTS
FOR
CONTRACT
f I
BET\VEEN
l\10NROE COUNTY, FLORIDA
AND
Prior to the commencement of work governed by this contract, the Contractor shall obtain
Water Craft Liability Insurance with terms no less restrictive than those found in the
standard "American Institute Hull Clauses" (June 2, 1977 edition). Coverage shall be
maintained throughout the life of the contract and include, as a minimum:
· Injury (including death) to any Person
· I)amage to Fixed or Movable Objects
· <:05ts Associated with the Removal of \Vrecked Vessels
· <:ontractual Liability \vith Respect to this Contract
If the policy obtained states that coverage applies for the "Acts or Omissions of a Vessel",
it shall be endorsed to provide coverage for the legal liability of the shipowner.
The minimum limits acceptable shall be:
$500',000 Combined Single Limit (CSL)
Coverage provided by a Protection and Indemnity Club (P&I) shall be subject to the
approval of the Count)'.
The Monroe County Board of County Commissioners shall be named as Additional
Insured on aU policies issued to satisfy the above requirements.
\\'LI
Adlninistration Instruction
#4709.2
..:::r.....)t..c.oiijj........t111:I;811I'lillll~I:I'El~11II'j;l_i~[I'II'I;.I:II::::I1[::tJ~:l:::~::i:~:i::[:~:~~Ij:~~~::~~:i~~il~~t~::l::I[........DATE(NIWD/YY).........i:
B__.~=~=_~~.~~~0~~~t~S,~~h~~~;4J~.-\j~j~?~~ Mhzns t
.p.RoD.ucEf............ . THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ..
DONATO, INS. AGENCY IHe:. ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE
HOLDER. THIS CERTIFICATE DOES NOT AMEND, EXTEND OR
P.O. BOX 607518 ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW.
ORLAhOO FL 32750 COMPANIES AFFORDING COVERAGE
407-889-7525
COMPANY
A CONNECTICUT INDEMNITY
ARNOLD'S T<I'IHG SVC, ARNOLD'S AUTO & MARINE,
BK TOWING & ROADSIDE ASSIST IN
5540 3RD AVE.
KEY WEST FL 33040
COMPANY
B
INSURED
COMPANY
C
COMPANY
o
QQyg~~$.:.,,):::'t::::::};):::,,:I::::::):I):[:::::::":::I:::::m)'I::)::::::::::):::)t:):::::tt:)t':::t1':1:::::),::::::::):::):):::::::,::::)t)):::::::::::::::)'I':::::::=::)::::::::,::t::::):::::,1tt:::::::::'::::):)t:'t::::::::::t},::::::::::::::::::::::,,;;;[::::=:::I:::::,:,,)}:::::,:::%::)::m::):m::::):mi
THIS IS TO CERTIFY THAT .THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD
INDICATED. NOlWlTHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS
CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS,
EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS.
AUTOMOBILE UABIUTY
ANY AUTO
ALL OWNED AUTOS
X SCHEDULED AUTOS
HIRED AUTOS
NON-OWNED AUTOS
V'iA!VrR:
POUCY EFFECTIVE POUCY EXPIRA nON UMITS
DATE (MMIDD/VY) DATE (MMIOO/VY)
GENERAL AGGREGATE $
PRODUCTS - COMP/OP AGG $
PERSONAL & ADV INJURY $
EACH OCCURRENCE $
FIRE DAMAGE (Anyone fire) $
MED EXP (Anyone person) $
COMBINED SINGLE UMIT $
500,000
BODIL Y INJURY $
(Per person)
04/30/99 BOOIL Y INJURY
(Per accident) $
CO
lTR
TYPE OF INSURANCE
POUCY NUMBER
GENERAL UABIUTY
COMMERCIAL GENERAL LJABIUTY
CLAIMS MADE D OCCUR
OWNER'S & CONTRACTOH'S PROT
l)A 1 L -
A
TT101489
PROPERTY DAMAGE
TT101489
04/30/98
04/30/99
AUTO ONLY - EA ACCIDENT $
OTHER THAN AUTO ONLY:
EACH ACCIDENT $
AGGREGATE $
500,000
GARAGE UABIUTY
ANY AUTO
A X X
500,000
500,000
EXCESS UABIUTY
UMBRELlA FORM
OrnER mAN UMBRELLA FORM
WORKERS COMPENSA nON AND
EMPLOYERS' UABIUTY
EACH OCCURRENCE
AGGREGATE
$
$
$
OTH-
ER
THE PROPRIETOR!
PARTNERS~ECUTNE
OFFICERS ARE:
OTHER
INCL
EXCL
$
EL DISEASE - POUCY UMIT $
El DISEASE - EA EMPLOYEE $
RAGEKEEPERS LEGAL LIAS.
A ON-HOOK
TTI01489
04/30/98
04/30/99
$1,000 OED
$1,000 DED
$100,000
$50,000
DESCRIPTlON OF OPERATJONS/LOCATIONSNEHICLESISPECIAL ITEMS
MONROE COUNTY BOARD OF COUNTY COMMISSIONERS IS INCLUDED AS POLLUTION COVERAGE - COMPANY B POLICY 110619-02
ADDITIONAL INSURED ~OR REMOVAL OF DERELICT VESSESl 08/21/97 - 08/21/98
REVISED
~ERTIFlCArE:HOLt)~13.,::::mI):m:.:m:.',:::::'::):IIm::::m:III:m):mI,:m:I))Im':.::,:I:I:9AN~~1.;:n$;jJ~:mj:~5~o.o~~>. ................. .. . .. .. ... .
MONROE COUNTY BOARD OF COUNTY C0ff4ISSIONERS SHOULD ANY Of THE ABOVE DESCRIBED POUCIES BE CANCElLED BEFORE THE
ATTN: RISK MGT. EXPIRATION DATE THEREOF, THE ISSUING COMPANY WILL ENDEAVOR TO MAIL
5100 COLLEGE ROAD ~ DAYS WRITTEN NonCE TO THE CERTIFICATE HOLDER NAMED TO THE LEFT,
KEY WEST fl 33040-4399 BUT FAILURE TO MAIL SUCH NOTICE SHALL IMPOSE NO OBUGATlON OR UABlUTY
ATTH: KIM McGEE, MARINE PROJECTS COORDINATER
FAX: 305-295-4317
OF ANY KINO UPON T E
AUTHORIZED REPRESENTA TlV
TION19sa
ACORD 25~S