03/11/1998 DV03A2520
AGlffiEMENT, MADE THIS
CONTRACT AGREEMENT
// /1 day of /l,i /!./.... {//-l 1998, by and
r' j \ \ I l t:-! I
betweerL, Arnold's Towing
("Contractor"), and the BOARD OF
COUNllY COMMISSIONERS OF MONROE COUNTY, FLORIDA, of the County of
Monroe, State of Florida ("Board").
The Contractor and the Board, for the consideration named agree as follows:
1. 1fhe Contractor shall furnish all the materials and perform all the work as
requirecl by the Specifications for the emergency removal of DV03A2520 for
which Florida Marine Patrol Derelict Vessel Report is attached as Exhibit A.
2. llhe work to be performed under this contract shall commence immediately from
the date the Liaison provides the Notice to Proceed and shall be completed by
March 31. 1998.
3 . The Contractor understands the rules of the Florida Department of
Environmental Protection and shall comply with those rules, along with the rules and
procedures instituted by the Board to ensure an orderly progress to the project. Both
the intent and the requirements of the specifications, attached as Exhibit B, are
understood by the Contractor.
4. The Board shall pay the Contractor $ $1.080.00 for the removal and legal
disposal of DV03A2520. Payment will be upon completion of work by the Contractor
and review and approval by the Marine Projects Coordinator.
1
5. The attached Derelict Vessel Reports, Specifications, and the Monroe County
Insurance Requirements together with this Agreement, form the Contract. They are
fully a p1art of this Contract as if repeated herein verbatim.
6. The Contractor covenants and agrees to indemnify and hold harmless the
Monroe County Board of County Commissioners from any and all claims for bodily
injury (including death), personal injury and property damage (including property
owned l)y the County) and other losses, damages, and expenses (including attorney's
fees) wllich arise out of, in connection with, or by reason of services provided by the
Contractor or any of its Subcontractor (s) in any tier, their employees or agents. The
purchase of the insurance required in paragraph 11 does not vitiate this indemnification
(jpfjf- -
provision. J -~ -1 II
7. The Contractor agrees to supply the County with a set of photographs of each
vessel in all phases of the removal and disposal process. The Contractor will be
responsible for the camera, film, and development costs.
8. 'The Contractor must inform the County and the Florida Marine Patrol prior to
initiatioll of work.
9. lrhe parties agree that a timely performance of this agreement is essential due to
possible damage to the natural resources, hazards to navigation, or threats to human
health a:nd welfare. Therefore, the parties agree that the Contractor shall be liable to
the Board for $100 per day of liquidated damages for each day after 3-31-98 that the
Contractor's obligations under this agreement remain unperformed. The parties agree
2
that such amount is by the way of compensatory damages and does not constitute a
penalty.
10. :Due to the use of heavy equipment and, at times, dangerous work environment,
the COIltractor understands and agrees to maintain an alcohol an drug free work
envirorunent.
11 " The Contractor will be responsible for all necessary insurance coverage as
indicate~j by an "X" on the attached forms identified as INSCKLST 1-4, as further
detailed on forms VL1, WC1, WCJA, GL1, WL1, & POLl attached as Exhibit C. All
policies must list Monroe County as additional insured with the exception of the
W orker~' s Compensation policy.
12. A person or affiliate who has been placed on the convicted vendor list
followinlg a conviction for public entity crime may not submit a bid on a contract to
provide any goods or services to a public entity, may not submit a bid on a contract
with a ~lublic entity for the construction or repair of a public building or public work,
may not submit bids on leases of real property to public entity, may not be awarded or
perform work as a contractor, supplier, subcontractor, or consultant under a contract
with an)r public entity, and may not transact business with any public entity in excess of
the threshold amount provided in Section 287.017, for CATEGORY TWO ($10,000)
for a period of 36 months from the date of being placed on the convicted vendor list.
13. The Board may terminate this agreement with or without cause at anytime
upon gi',ing the contractor a minimum of ten days in writing. The contractor, upon
receipt of the notice, shall immediately cease work. The Board shall pay the contractor
3
the per1centage of the contract sum which is proportional to the amount of work
performled by the contractor in a manner satisfactory to the Board up to the date the
Contractor received the Notice of Termination.
IN 'WITNESS WHEREOF the parties hereto have executed this Agreement to day
and year first written above.
~'})~cI/
/4,,( - /,"', / , .
" " GI"
Cf/."A/ ~
Title: Owner
'I:. -"-
,~l~;rj~/c/,? ~-..t/' ',.~-
-7
Business name:
BOARD OF COUNTY COMMISSIONERS
~
,~
OR/CHAIRMAN
~sr. DANNY L KOLHAGE CLERK
(SEAL) ATTEST: ·
BY
CLERK
4
Exhibit A
ZONE .1/1-
INCIDENT REPOiRT NARRATIVE CONTINUATION
DERELICT VESSEL # 3A- 2 5 2- (} INCIDENT # q! .3A ..l 3 7
1. REG # ~l.- .J21f5ftLENGTHL~FT. MAKE: uAJ(<:. MODELII""'~C6d-t7COLOR8L-Uc/6C(;-~'\l
HULL MA.rERIAL: WOOD /FiG METAL_ OTHER (SPECIFY)
MOTOR YES_NO ./ TYPE ::?A OTHER IDENTIFIERSN4ItMCc> H..)/Nf,<<y' I...e.-f ,,-
OfflcerCs) Reporting (please print)
D t(: . J 0 tV /f17"..4 Ai C . (=:(2 (~ K"-
Reviewed By:
'VL--- ~ -r ~ c/ L.
Citation Number /
IV(/f
2.
3.
4.
5.
6.
~
! 7.
8.
9.
10.
11.
12.
13.
14.
VESSEL O'WNER:
ADDRESS:
.J (M,.l{ V ;t1 CA- D~
Po T>o K '-f~ I Z-
k-c'l We-Sf. r?- .3 30 VI
"
COUNTY HV A./ ReC
D.O.B. ~G/ 03/ <(3
PHYSICAl. LOCATION OF DV: L.JE~'- ~{/~C ol:=- LvlS,n..,2l4 (SL4,ul;> /LC-y ~c?( 1-I-1-l~~(j~
. II I f ) 6-1../? Y <1" 'f
LA TITUDE:/LONGITUDE (DEGREES, MINUTES, SECONDS) vJ 2- 'I u 3 1 . e> Z-' I W LJ g / f 0 · y
CONDITIOIN: WRECKED_ JUNKED_ DISMANTLED ABANDONED./ AGROUND
BURNED_ CAPSIZED_ BROKEN UP ___
SUBMERGED IV it % DEPTH N h FT. ANCHORED /" ADRIFT
ON SHORE_ IN WETLANDS_ TIED TO OBJECT_ OTHER_~~_
I
(t~.
PROPERTY OWNER: Sr4-~ ~ p PLlI {,-(OA
STATE LAND.L\"
PERMIT F:OR ABANDONMENT: YES_ NO /~SSUED BY
/l/ fA
ABANDOINMENT REASON
l,( N I<. ,
NAVIGATION THREATENED? YESL NO_HOW "'0 A-.v cdc ,z L( t? II r I> IS I~U' ~ e:-~
n 2 E t( LA C..-t,.n.y' 15 IZ C .+ ~~ PrZ t:. -c 0 ~ ~ c CJ t~ {(f/ {,.
ENVIRONIMENT ENDANGERED? YES_ NOL H.QW N /A-
TOWED WITHOUT REPAIR? YES_ NO_ UNK LaTHER # fA
RECOMMI:NDED DISPOSITION: LANDFILL / ARTIFICIAL REEF
MARINE HABITAT_ REC'(CLE 1V1ETAL OTHER
NARRATIVE I DILIGENT SEARCH (EXPLAIN) Au 0 ~ D (N ~ 'H) j7l::.-o Pt-L ':-~M IL I~IC- Lv {n-l
T1-/ e v 0 r L--:- c- -a../ c- C> LV M f::.:~ k, A- ~ ~ ( L L (;..-e:> l,v ~ C A- f<... ,1-cL. it:> L-.-(,,7:
.1) C) ~ A";/'( (L V ( > fC.4/0 v/.V () F A- A.J<C> Ale> (? A-f.> l:~(A/ C I~ S"'t-t 0 ~ ( .-c./ Go
.~o t7-1t::.lL 0 "-VA/elL cAA.../ l5~ LOC~TCD-
PAINTED [)V# ON VESSEL? / DATE o{ / cP-/ rsr 4 PHOTOS OF DV INCLUDED? /
o / (JrY'~E
. ~-Z6 - ,7;
/
A-/,
Number Arrested /
/VII!-
o
INCIDENT REPOF~T NARRATIVE CONTINUATIOr~
DERELICT VESSEL II 3A- 2 ~ L-t)
ZONE -~' /t
I
I
1-'~~~:~~~7- . '.- . .
.... . ,.M...:.....,"....'...'-.'.
,,.,,. ,
~J~~'"
I~"K.
r' u" ';, .
Offlcer<s) ReJ)orti ng (pi ease prin t)
o ("c.. J 0 tV -1 TI-{ "...r .() C (-~/~ {c t::-
Reviewed Gy:
~f~~cer:~.{~~~e:0?K~~c 0 I/~J' ~ S
//
1< e v i (?/ we r' s S i ~J n Zl t: u r e
rJ:1t:e
7r:J71 )DIT-----------------. . _"_'__H_ -----.---------PJ{J (~---2--.o
~-
.
<->~
.....
J.
}:
l
,/ O)-n-
/' :5: -
// U1. :n N
,/ co wI\) La
4-- No,a
C[:i~~. . ~; 'B rc~'
-- ~ ~ ;4' ?;./
N " C-..)
)25 m.$ __~ / _
-- / -- -nO.)'- -- '" J]V ~
r .,... -r /"t- -r -r 1""'"r- . "
" / s \ .rJ' :::; "" ::~
.) , ^ ..rvJV . :
l' / .j.4\,jv. \~.i
JV '6~-' .-- _:~.
.rv.~,;S/ ~
'-"'~ \, 0)/ f'
-f--43_G20 VI
~~ //
.. tV //
~/
~~
/~tj) ~~>.
, 'L\.:
~I?,\'I ,~
-~--[; - . ==
7-'t) ~~
.::--- ~ ~ ~ ~ tJ
:: gQ.~~~c-
~ "'2 <0 ~ 6 ~ ~
O&~~ii~~
s_~~l ~I
<D
(X)
rv
OJ
m
~
1"':~\':"
(':-, "'//"
/'
,/
G.)
-.....J
--...J
'-J
(L)
~
N
<n
I
, -29--1998 1 0 ~ 5EiPM
FROM MAR I ~ PROJECTS 295 431 7
To: !Um McGee, Marine Projects Coordinator
From: iDfficer Michael R. Emma, K-34
FMP;Dffi~iC}~-A
-?yl~~ --Ac 'I-r IIf
Date: January 30, 1998
Subject: Emergency Removal of DV03A2520
You are .in receipt of derelict vessel report 2520 on a 24' houseboat.
An indivIdual sailed this vessel from Christmas Tree Island to the Eastern Dry Rocks
and it ~!; been abandoned. The vessel has been towed in by the FKNMS for safety
reasons .
The vess~~l is unlighted, in poor condition. and may get hit at night.. Please remove this
vessel as soon as possible.
g-4//
OK 7t) ~CJCeE()
Wlilf f)E/'VtOVA- L. ,
P.2
EXHIBIT B
DERELICT VESSEL REMOVAL CONTRACT SPECIFICATIONS
FOR MONROE COUNTY, FLORIDA
1. 11\fTENT: It is intended that these specifications shall cover all aspects of the work.
TIle purpose of this section is to provide specific conditions applicable to this
contract where such coverage is not provided in other portions of the documents.
2. BID FORMAT: A dollar amount per foot must be submitted for the removal of as
many derelict vessels on the primary list for which a Florida Marine Patrol Derelict
Vessel Report is provided and as funding will allow. Any deviation from this
format will result in an unaccented bid. A contract will not be granted on the basis
of combined, related, linked, or discounted bids. Not applicable due to emergency
relnoval of one or more derelict vessels for less than $25,000 total.
3. PIJANS: There are no plans for this project, but copies of the Florida Marine
Patrol Derelict Vessel Report with location sketches have been bound into these
documents for the Contractor's use. The Specifications include a section on
instructions to bidders, both general and specific, and a copy of each Derelict
Vessel Report from the Florida Marine Patrol. Only those derelict vessels for
wllich a report is included and listed on the Bid Response Form are to be bid upon
an(! subsequently removed.
Th.e County reserves the right to remove any or all vessels from this contract at any
tinle prior to actual removal from the water and disposal by the Contractor.
The County has a limited amount of money to effect the removal of these derelict
vessels. We have established priorities based on public safety, navigational hazard,
an(j environmental considerations. Ifbids exceed the County's resources for
rernoval based on these considerations, we shall limit vessel removal based on the
cOllsiderations and cost effectiveness.
4. VE~SSEL IDENTIFICATION AND LOCATION: Each of the vessels have been
given a derelict vessel identification number, which is shown with the location in
the Florida Marine Patrol Derelict Vessel Report, included herewith.
Each bidder is responsible for his own identification of each derelict vessel as to
location, description and condition. If a derelict vessel cannot be (1) located, (2)
renloved, (3) verified and (4) disposed of, as specified in these procedures, then no
payment will be made forthcoming to the Contractor for that vessel. Those four
corlditions must be met on each derelict vessel along with compliance of all laws
for paymellt to be made.
It is understood that the Contractor has, by personal examination and inquiry, if
necessary, satisfied himself as to local conditions of each derelict vessel and as to
the meaning, requirements and reservations of the specifications; for after contract
letting, no deviation will be allowed. In case errors are discovered, they are
to be reported by the Contractor to the County. The county assumes no
responsibility should there be any discrepancies in what is stated in these
documents and what the bidder evaluates.
Tile Contractor should take special care to remove only those derelict vessel's on
his Contract and for which he possesses a Florida Marine Patrol Derelict Vessel
Report. Other derelict vessels in the area but not under Contract, cannot be
molested.
It luay be possible to replace a derelict vessel of like kind, for the same or less
money, when mutual agreement can be reached by the Florida Department of
En.vironmental Protection, Monroe County Administrator of the Derelict Vessel
Program, and the Contractor. This will be applicable when a contracted derelict
vessel cannot be located. No derelict vessel may be replaced and removed without
the tri-party consent noted in this paragraph. A contractor may suggest a possible
rer)lacement vessel but he may not remove it without the appropriate consent above.
5. SCOPE OF WORK: The Contractor shall be responsible for providing all permits,
sUI)ervision, labor, equipment, tools, fees and taxes required to complete this
project to the satisfaction of the County.
The Contractor's procedure and methods of removal may be of his own selection
provided they secure results which satisfy the requirements of the Specifications
anel any necessary environmental permits.
Any vessel which is removed and disposed of shall be removed from its present site
in such a manner as to do the least possible damage to the natural environment.
All debris from the vessel shall be removed and the site left in a reasonably clean
condition. No oil or fuel shall be permitted to be dumped or spilled into or unto the
water or land. All pollutants shall be removed from the derelict vessel prior to
rerrloval from the water.
The Contractor shall be responsible for making any and all arrangement for access
to the vessel to be removed. If private property has to be traversed, then written
permission of the owner is necessary. In removing a derelict vessel that may lie on
or near grass or sponge flats extreme caution must be used to do the least possible
danlage.
2
Prior to delivery of derelict vessels to the disposal site, the Contractor must remove
all oil, gas and engines. He must dispose of them in any legal manner. Pure used
oil will be taken by Monroe County for disposal. Mixture of oil, gas, seawater or
any combination of the three must be transported from the County by an approved
hazardous waste handler. The names of handlers will be supplied by the Monroe
County Solid Waste Department. Metal becomes the property of the Contractor.
6. MATERIALS AND WORKMANSHIP: The Contractor shall provide the
necessary materials and equipment to safely complete the job. The Contractor
agrees that all work shall be performed by competent employees who are
experienced and qualified to do the work specified, and that all work will be
performed in accordance with the best commercial practices. A list of equipment
to be used and a description of the removal and transporting procedures to be
followed must be provided to the County at the pre-work conference described
below.
Precaution shall be exercised at all times for the protection of persons and property.
The safety provisions of the Occupational Safety and Health Act of 1970 (Public
Law 91-596) and other applicable laws, including building and construction codes
shall be observed. Machinery, equipment and other hazards shall be guarded in
accordance with safety provisions of the "Manual of Accident Prevention in
Construction", published by the Associated General Contractors of America, to the
extent that such provisions are not in contradiction of applicable law.
If any property is destroyed by any cause or means whatsoever, the Contractor shall
repair and replace or not receive payment for the unaccomplished work. The
Contractor shall maintain suitable and sufficient guards and barriers, and at night,
suitable and sufficient light or other appropriate security or protection for the
prevention of accidents.
Use of explosives is prohibited in carrying out the project.
7. ASSIGNMENT OF CONTRACT AND SUBCONTRACTS: It is expressly
understood that the Contractor is in all respects an independent Contractor for this
work, not withstanding under certain conditions he is bound to follow the
directions of the County, and is in no respect an agent, servant, or employee of the
County. Neither the Contract, nor any part thereof, nor any Moines due or to
become due thereunder, may be assigned by the Contractor without the prior
written approval of the County.
The Contractor is fully responsible to the County for the acts and omissions of his
subcontractors and of persons either directly or indirectly employed by said
3
sl.;lbcontractor, as he is for the acts and omissions of persons directly employed by
him. Nothing contained in the relation between any subcontractors shall abide by
the terms, conditions, and requirements of this Contract. It is the responsibility of
the Contractor to pay all debt obligations incurred with subcontractors in an
e~~pedient manner.
8. L]~GAL RESTRICTIONS. PERMITS AND TRAFFIC PROVISIONS: The
Contractor shall comply with all applicable local, State and Federal requirements
pertaining to the terms of this Contract. The Contractor will be responsible for
obtaining, at his own expense, any licenses or permits that may be required and
should inquire about permit requirements with the appropriate agencies. The
Contractor shall comply with all the requirements of the Federal Pollution Control
Act.
Tile Contractor shall conduct his operations so that he shall not close any
thoroughfare nor interfere in any way with traffic on highways, or on water,
without the written consent of the proper authorities. Work shall be done at any
tinle that shall not interrupt or disturb members of the public.
Utilization of off-loading sites located on private property (water to land for
transport to the landfill or other disposal site by vehicle) must have written
ap:proval of the land owner.
The Florida Marine Patrol should be contacted to initiate eviction proceedings for
COlltracted derelict vessels which are inhabited at the time of removal and when
another vessel is too close to the contracted derelict vessel to allow safe operations.
Direct confrontations with other boaters should be avoided and the Florida Marine
Patrol should be contacted immediately if such confrontations results from removal
of any contracted derelict vessels.
9. INSURANCE: The Contractor must obtain insurance required by the County and
submit proof of same to the County prior to acceptance of bid and contract approval
by Board of County Commissioners but no later than five working days after notice
of low bidder. All insurance shall be maintained until work has been completed
anel accepted by the County.
The Contractor shall furnish the following certificates of insurance for review by
the County's Risk Management Division:
Certificate (s) of Insurance wIlich clearly indicates that he has obtained the
insllrance coverage required in paragraphs a,b,c and d below.
The Contractor hereby certifies that no modification or change in insurance shall be
made without (10) days written advance notice to MONROE County, c/o the
Director of the Risk Management Division.
4
a. Vlorker's Compensation Insurance per Fl. Statutes
b. Federal Jones Act Coverage
c. General Liability Insurance on a comprehensive basis, in an amount not less than
$500,00.00 per occurrence for Bodily Injury and Property Damage combined, to
include contractual liability.
c. Pollution Liability Insurance in the Amount of $500,000.
d. Water Craft Liability Insurance in the Amount of $500,000.
e. Alltomobile liability insurance covering all owned, non-owned and hired vehicles
used in connection with the work, in an amount not less than
$300,000 per occurrence for Bodily Injury and Property and Damaged combined.
All insurance policies required above shall be issued by companies authorized to do
business under the laws of the state of Florida. The MONROE County Board
of County Commissioners must be listed as "Additional Insured" on all policies,
except for the Worker's Compensation policy.
10. C()MMENCEMENT~ DELAYS AND COMPLETION OF WORK: After
receiving Board of County Commission approval of the Contract, and after
reconciliation of any details or conditions which may directly or indirectly interfere
or conflict with work of the Contract, the County will issue a "Notice to Proceed"
officially authorizing the Contractor to commence. The Contractor shall
COJmmence work within one week from the date on the "Notice to Proceed" letter.
If the Contractor should be delayed in the progress of the work included in the
Contract by enforceable causes beyond his control, the time for the completion of
the work may be extended upon agreement of the County representative. Requests
for an extension of time must be submitted in writing to the County representative.
Extensions of time cannot legally be approved unless the written request is
submitted in the time to permit it to be acted upon before the Contract expiration
date. To allow sufficient time for the administrative procedures required to obtain
action by the County Commission, a request for time extension must be received by
the County representative at least sixty (60) calendar days prior to the Contract
eXI)iration date.
Provided further that the Contractor shaH within ten (10) days from the beginning
of such delay notify the County, in writing, of the causes of the delay. The County
representative will ascertain the facts and the extent of the delay and notify the
Contractor within a reasonable time of her decision in the matter.
5
If the Contractor fails to complete the work within the time limit, and if the County
sblould nevertheless permit the Contractor to continue and complete the same
without official extension of time in writing, such permission shall not modify nor
waive any liability of the Contractor for damages arriving non-completion of work
within the time limit, but such liabilities shall be subject to continuation in full
force against the contractor.
11. CJHANGES AND INSPECTION: The vessels herein considered are to be removed
for the County by the Contractor in accordance with the specifications. The County
may give instructions or directions to supplement the specifications. These shall be
binding upon the Contractor and upon all his subcontractors, employees and agents
of every kind.
AIl work and every process and operation shall be subject to inspection at all
tirnes, and the County and their representatives shall have free access to all aspects
of the work. The Contractor shall remove and make good, as may be directed,
without charge, any defective work. Oversight or error of judgment of
inspections, or previous acceptance, shall not relieve the Contractor from the
obligation to make good any defect whenever discovered.
Tile right is reserved to change the Specifications consistent with regard to the
general intention of the contract for any part of the work or materials, either before
or after work has begun. Notice of such changes shall be given in writing to the
Contractor; such changes are not to be grounds for any claim by the Contractor for
damages, nor for the forfeiture of the Contract. It is possible that a Derelict Vessel
could disappear between the time of inspection by the contractor and the actual
effort to remove it. No payment will be forthcoming in event that this occurs.
Except when otherwise specified, the expense of all tests requested by the County
will be borne by the County.
12. AlfDIT RIGHTS: As a provision of the grant from the State of Florida to the
County, and if so requested by the State, the successful bidder agrees to provide
access to all records and allow the audit of any books, documents and papers
related to this project for a period of up to one year and during and after termination
of the contract.
13. CC)NTRACT A WARD: The County reserves the right to evaluate the submitted
bids and award a contract to the bidder submitting the lowest per foot bid for the
derelict vessels listed in the bid package as one project and for which a
Florida Marine Patrol Derelict Vessel Report is included. One bid will be accepted
and a Contract issued for the total removal of all listed derelict vessels as one
project, up to the limit of available funds.
6
Tlle actual number of vessels to be removed will depend on the accepted per foot
biel price and the available funds.
14. PFlEWORK CONFERENCE: A meeting will be necessary involving a
representative of the County, the Contractor and other parties with direct
in\'olvement prior to the signing of the Contract. The time and place of this
conference will be set by the County representative. At this time the Contractor
shall provide the County with a schedule as to the order in which he proposes to
relnove the vessels awarded to him.
15. C()NTRACT SECURITY: The Contractor is expected to act and deliver in good
faith all work, at the agreed price, in the allowed time. Failure to do so, could
jeopardize the contractor's reputation with the County and potentially influence any
future contracts with MONROE County.
16. E)CECUTION OF CONTRACT DOCUMENT: Due to the time frame involved
with this project, the Contractor upon notification that he is to be awarded the
co;ntract documents for execution, shall return said documents properly executed
along with insurance within TEN WORKING DAYS. This will assist in
acceleration of execution of the contract documents.
The Contractor, by virtue of signing the Contract, acknowledges that he and all his
sulJcontractors have satisfied themselves as to the nature and location of the work,
the general and local conditions, including, but not restricted to, those bearing upon
transportation, handling, access to the pick-up and disposal sites; and the character
of equipment and facilities needed to perform the work. Failure on the part of the
Contractor to completely or properly evaluate any factors of his costs prior to
biclding shall not form a basis for additional compensation if he is awarded the
Contract.
If for any reasons, not acceptable to the County, the Contractor does not perform,
the County shall have the right to levy liquidated damages against the Contractor.
Licluidated damages in the amount of $1 00 per day shall be assessed against the
Contractor for any bid item awarded to him which is not completed and accepted
by the County within the number of calendar days specified in the Contract.
Liquidated damages are accumulative.
17. NOTICE TO PROCEED: The Contractor shall commence work upon this project
within one week of the date of the Notice to Proceed letter and perform in a
corltinuous manner until completion and acceptance by the County. For Contracts
wherein a specified number of days for completion is stated in the Contract, the
ef~~ctive date oftl1e "Notice to Proceed with Contract Work" will establisl1 the
"beginning date" of the project.
7
18. Il~RMINA TION OF CONTRACT: This Contract may be terminated by the
County, giving up to ten (10) days written notice to the Contractor; said notice
shall be sufficient if delivered to the party personally or mailed by certified mail to
his mailing address as specified on the accepted bid.
19. FINAL CLEAN-UP: Upon completion of the work specified herein and before
acceptance and final payment shall be made, the Contractor shall remove from the
sites all machinery, equipment, surplus and discarded materials and temporary
structures. The disposal of materials, rubbish and debris shall be made at a legal
disposal site.
20. DISPOSAL SITES AND FEES: The Contractor is responsible for disposal of all
derelict vessels included in this contract and must make arrangements for legal
disposal. It is the responsibility of the Contractor to pay all disposal fees
incurred, and such removal related costs should be considered when bidding on this
contract.
Th.e Contractor will deliver the derelict vessels to a Florida Department of
En.vironmental Protection permitted disposal site that has current occupational tax
licenses. It is the intent of this contract to remove derelict vessels from their
present site and legally dispose of them. Upon receipt of vessels at the landfill,
they must be disposed of immediately.
There are several Monroe County disposal sites, Cudjoe Landfill, MM 21.5
(vessels must be 26' and under to be delivered in tact, over 26' they must be
broken up), Long Key Landfill MM 68, and Card Sound Road AKA SR905 other
landfills in neighboring countries or any other location for disposal as long as the
site is a legal licensed disposal site. Prior to transportation of vessels out of
County the County representative must approve. Vessels being disposed of at
County Landfill sites must be free of pollutants and engines.
21. PROOF OF PROPER DISPOSAL AND NOTIFICATION TO MARINE
PATROL: Contractor must submit prior to receiving any payment: A receipt for
eac.h vessel including the date of disposal, the Florida Marine Patrol Derelict Vessel
Number, disposal site location, and the telephone number. Recipient of debris
should provide detailed receipt showing type and description of debris received.
In addition to the above information, Contractor must submit three pictures of
each vessel removed. The first photograph must be of the vessel at the current
location prior to removal, the second photograph must be of the vessel after
rerrloval but in the same general area preferably while in tow, and the third
photograph must be of the vessel at the disposal site with sufficient background to
depict disposal (i.e., building or sign identifying disposal site). The derelict
vessel number., when possible., must appear in all photographs.
8
TIle Contractor will be responsible for the camera, film, and development costs.
TIle photographs should be taken with a Polaroid camera that provides instant
pllotos since this minimizes loss of documentation due to camera malfunction or
loss overboard. This photos must be submitted on a vessel by to document the
relTIoval and disposal of the contracted vessels final payment can not be assured.
Tlle Contractor must notify the Florida Marine Patrol and the County
Representative in writing as to the work schedule of removal. This should be done
after the pre-work conference with the County representative. Notification is to be
made before doing any work on each vessel. This multiparty communication for
each Derelict Vessel is a requirement of the contract.
22. P p~ YMENT: All payments for the removal and disposal of each vessel, shall be
for the performance of the work as stipulated in these specifications and associated
co:ntractual documents. The unit rate of bid shall be totally inclusive for all phases
of the operation. The Contractor may request two partial payments by submitting
an invoice for the number of vessels removed up to the date of the invoice,
providing the Contract agreement does not explicitly prohibit partial payments.
Photographs, disposal receipts, and signed FDEP Disposition Certification form for
the vessels for which payment is being requested.
The Contractor understands and agrees that no payment will be forthcoming for the
removal and disposal of any derelict vessel (1) not listed on this contract nor (2) for
any derelict vessel on this contract for which a written certification verifying the
renaoval of the subject vessel has not been obtained from the Florida Marine Patrol
an(l a Representative of the disposal site at the time of delivery.
In addition, property, public or private, if damaged during the work or removed for
the convenience of the work, shall be replaced at the expense of the Contractor in a
manner acceptable to the County and the Owner, prior to the final payment for
corltracted work.
23. NON-COLLISIQN AFFIDAVIT: Upon entering into the contract, the Contractor
agrees to sign and endorse the Non-Collusion Affidavit form (attached).
24. ETHICS CLAUSE: Upon entering into the contract, the Contractor agrees to sign
and. endorse the Ethics Clause form (attached).
25. DRUG FREE WORK PLACE FORM: Upon entering the contract, Contractor
agrees to sign and endorse the Drug Free Work Place form (attached).
26. DE:RELICT VESSELS AT ISSUE: The derelict vessels listed on the Derelict
Vessel Working List for 1997 shall be removed and disposed of by the Contractor
in accordance with the provisions of these Specifications.
9
10
EXHIBIT C
1996 Edition
1\10NROE COUNTY, FLORIDA
INSURANCE CllECKLIST
FQR
VENDORS SUBMItTING PROPOSALS
FOR \VORK
To assist in the development of your proposal, the insurance coverages marked with an "X" wiII
be required in the event an award is made to your firm. Please review this fonn \vith your
insurance agent and have him/her sign it in the place provided. It is also required that the bidder
sign the form and submit it with each proposal. .
\\'ORKERS' C01\1PENSA TION
AND
Ei\1PLO')TERS'LIABILITY
Vie 1
WC2
Vie3
\\lCUSLH
X \\'orkers' Compensation
X Employers Liability
En1ployers Liabilit),
Employers Liability
US Longshoremen &
Harbor \\'orkers Act
X Federal Jones Act
Statuto!)' Limits
$100,000/$500,000/$100,000
$ 500,000/$ 5 00,000/$ 5 00,000
$ I ,000,000/$ I ,000,000/$ I ,000,000
Same as Employers'
Liabilit),
Same as Employers'
Liability
V/CJA
INSCKLST 1
Adrninistration Instruction
#4709.2
1996 Edition
GENERAL LIABILITY
As a minimum, the required general liability coverages will include:
· Premises Operations
· Blanket C9ntractual
· Expanded Definition
of Property Damage
Required l~imits:
GLI
x
GL2
GL3
GL4
Required Endorsement:
GLXCU
GLLIQ
GLS
Prqoucts and Completed Operations
Personal Injury
.
.
$100,000 per Person; $300,000 per Occurrence
$50,000 Property Dan1age
or
$300,000 Con1bined Single Limit
$250,000 per Person; $500,000 per Occurrence
$50,000 Property Damage
or
$500,000 Combined Single Limit
$500,000 per Person; $1,000,000 per Occurrence
$100,000 Property Damage
or .
$1,000,000 Con1bined Single Limit
$5,000,000 Combined Single Limit
Underground, Explosion and Collapse (XCU)
Liquor Liability
Security Sen'ices
All endorsements are required to have the same limits as the basic policy.
Adrninislralion Instruction
#4709.2
INSCKLST 2
1996 Edition
VEHICLE LIABILITY
As a minimum, coverage should extend to liability for:
· Owned; Non-owned; and Hired VehjGles
Required ]Limits:
VL1
VL2
\TL3
VL4
BR1
1\1 V C
PR01
PR02
PR03
POLl
POL2
POL3
EDI
ED2
GKI
GK2
GK3
WLl
x
x
x
Adlninistration Instruction
#4709.2
$50,000 per Person: $100,000 per Occurrence
$25,000 Property Damage
or
$100,000 Combined Single Limit
$100,000 per Person; $300,000 per Occurrence
$50,000 Property Damage
or
$300,000 Combined Single Limit
$500,000 per Person; $1,000,000 per Occurrence
$100,000 Property Damage
or
$1,000,000 Combined Single Limit
$5,000,000 Combined Single Limit
IvfJSCELLANEOUS COVERAGES
Builders'
Risk
Limits equal to the
completed project.
Motor Truck
Cargo
Limits equal to the maximum
\'alue of anyone shipment.
Professional
Liabilit),
$ 250,000 per Occurrence/$ 500,000 Agg.
$ 500,000 per Occurrence/$l ,000,000 Agg.
$1 ,000,000 per Occurrence/$2,000,000 Agg.
$ 500,000 per Occurrence/$l,OOO,OOO Agg.
$1,000,000 per Occurrence/$2,000,000 Agg.
$5,000,000 per Occurrence/$I 0,000,000 Agg.
$ 10,000
$100,000
Pollution
Liabilit)'
Employee
Dishonesty
Garage
Keepers
$ 300,000 ($ 25,000 per Veh)
$ 500,000 ($100,000 per Yeh)
$1,000,000 ($250,000 per Veh)
Watercraft Liability $500,000
INSCKLST 3
) 996 Edition
mSURANCEAGENTfSSTATEMENT
I have reviewed the above requirements with the bidder named below. The following deductibles
apply to t11e corresponding policy.
POLICY
DEDUCTIBLES
Liabilit), policies are
Occurrence
Clain1s 1\1ade
Insurance Agency
Signature -
BIDDERS STA TE1\1ENT
I understand the insurance that wiII be mandatory if awarded the contract and wiII comply in full
\vith all the requirements.
Bidder
Signature
INSCKLST 4
Adrninistration Instruction
#4709.2
1996 Edition
'VORKERS' COMPENSATION
INSURANCE REQUIRE1\IENTS
FOR
CONTRACT
I
BET\VEEN
1\10NROE COUNTY, FLORIDA
AND
Prior to the commencement of work governed by this contract, the Contractor shall obtain
Workers' Compensation Insurance 'with limits sufficient to respond to Florida Statute 440.
In addition, the Contractor shall obtain Employers' Liability Insurance v.ith limits of not less
than:
$100,000 Bodily Injury by Accident
$500,000 Bodily Injury by Disease, policy limits
$100,000 Bodily Injury by Disease, each employee
Coverage shall be maintained throughout the entire term of the contract.
Coverage shall be provided by a company or companies authorized to transact business in the
state of Florida.
If the Contractor has been approved by the Florida's Department of Labor, as an authorized self-
insurer, the County shall recognize and honor the Contractor's status. The Contractor may be
required to submit a Letter of Authorization issued by the Department of Labor and a Certificate
of Insurance, providing details on the Contractor's Excess Insurance Program.
If the Contractor participates in a self-insurance fund, a Certificate ofInsurance will be required.
In addition, the Contractor may be required to submit updated financial statements from the fund
upon request from the County.
\ \' C 1
Administration Instruction
#4709.2
1996 Edition
\\'ORKERS' C01\1PENSATION
INSURANCE REQUIRE1\fENTS
FOR
CONTRACT
1 1
BET\VEEN
MONROE COUNTY, FLORIDA
AND
Recognizing that the work governed by this contract involves Maritime Operations, the Contractor's
Workers' Compensation Insurance Policy shall include coverage for claims subject to the Federal Jones
Act (46 V.S.c.A. subsection 688) with limits not less than those specified for Employer's Liability.
The Contractor shall be permitted to provide Jones Act Coverage through a separate Protection and
Indemnity Policy, in so far as the coverage provided is no less restrictive than would have been provided
by a Workers' Compensation policy.
'\'CJA
Adrninistration Instruction
#4709.2
1996 Edition
GENERAL LIABILITY
INSURANCE REQUIRE1\fENTS
FOR
CONTRACT
,
BET\\'EEN
1\10NROE COUNTY, FLORIDA
AND
Prior to the commencement of work governed by this contract, the Contractor shall obtain
General Liability Insurance. Coverage shall be maintained throughout the life of the contract and
include, as a minimunl:
· ~Premises Operations
· :Products and Completed Operations
· JBlanket Contractual Liability
· ]~ersonal Injury Liability
· ]::xpanded Definition of Property Damage
111e mininlum limits acceptable shall be:
$300,000 Combined Single Limit (CSL)
If split limits are provided, the minimum limits acceptable shall be:
$100,000 per Person
$300,000 per Occurrence
$ 50,OOO.Property Damage
An Occurrence Form policy is preferred. If coverage is provided on a Claims Made policy, its
provisions should include coverage for claims filed on or after the effective date of this contract.
In addition, the period for which claims may be reported should extend for a minimum of twelve
(12) months following the acceptance of work by the County.
The Monroe County Board of County Commissioners shall be named as Additional Insured on
all policies issued to satisfy the above requirements.
GLI
Administration Instruction
#4709.2
1996 Edition
VEI-IICLE LIABILITY
INSURANCE REQUIREMENTS
FOR
CONTRACT
, ,
B ET\VEEN
~fONROE COUNTY, FLORIDA
AND
Recognizing that the work governed by this contract requires the use of vehicles, the Contractor
prior to the commencement of work, shall obtain Vehicle Liability Insurance. Coverage shall b~
maintained throughout the life of the contract and include, as a minimwn, liability coverage for:
· Owned, Non-O\\'I1ed, and Hired Vehicles
The minirnum limits acceptable shall be:
$100,000 Combined Single Limit (CSL)
If split linlits are provided, the minimum limits acceptable shall be:
$ 50,000 per Person
$100,000 per Occurrence
$ 25,000 Property Damage
The Monroe County Board of County Commissioners shall be named as Additional Insured on
all policies issued to satisfy the above requirements.
VLl
Administration Instruction
#4709.2
1996 Edition
POLLUTION LIABILITY
INSURAN CE REQ UIRE1\1ENTS
FOR
CONTRACT
1 f
BET\\'EEN
MONROE COUNTY, FLORIDA
AND
Recognizing that the work governed by this contract involves the storage, treatment, processing,
or transporting of hazardous materials (as defined by the Federal Environmental Protection
Agency), the Contractor shaIl purchase and maintain, throughout the life of the contract,
PoIlution Liability Insurance which wiIl respond to bodily injury, property damage, and
en\'ironmental damage caused by a pollution incident.
The minirrlum limits of liability shall be:
$500,000 per Occurrence/$1 ,000,000 Aggregate
If coverage is provided on a claims made basis, an extended claims reporting period of four (4)
years will be required.
POLl
Adm in istration Instruction
#47092
1996 Edition
'VATER CRAFT LIABILITY
INSURANCE REQUIRE1\fENTS
FOR
CONTRACT
1 1
B ET\\'EEN
l\10NROE COUNTY, FLORIDA
AND
Prior to the commencement of work governed by this contract; the Contractor shall obtain
\Vater Craft Liability Insurance with terms no less restrictive than those found in the
standard "American Institute Hull Clauses" (June 2, 1977 edition). Coverage shall be
maintained throughout the life of the contract and include, as a minimum:
.
Injury (including death) to any Person
Damage to Fixed or Movable Objects
Costs Associated with the Removal of \Vrecked Vessels
Contractual Liability ","ith Respect to this Contract
.
.
.
If the policy obtained states that coverage applies for the "Acts or Omissions of a Vessel",
it shall be endorsed to provide coverage for the legal liability of the shipovmer.
The minimllill limits acceptable shall be:
$500,000 Combined Single Limit (CSL)
Coverage provided by a Protection and Indemnity Club (P&I) shall be subject to the
approval of the County.
The Monroe County Board of County Commissioners shall be named as Additional
Insured on all policies issued to satisfy the above requirements.
\\'Ll
Adlninistration Instruction
#4709.2
DRUG-FREE WORKPLACE FORM
The undersigned vendor in accordance with Florida Statute 287.087 hereby certifies that:
~r"~
/171/110/0 ,.:s ~/bt// ~9
(Name of Business) 7-
I. Publish a statement notifYing employees that the unlawful manufacture, distribution, dispensing,
possession, or use of a controlled substance is prohibited in the workplace and specifYing the actions that
wi II be taken against employees for violations of such proh ibition.
2. Inform employees about the dangers of drug abuse in the workplace, the business's policy of maintaining
a drug-free workplace, any available drug counseling, rehabilitation, and employee assistance programs,
and the penalties that nlay be inlpo~ed upon employees for drug abuse violations.
3. Give each employee engaged in providing the commodities or contractual services that are under bid a
copy of the statement specified in subsection (I).
4. In the statement specified in subsection (I), notify the employees that, as a condition of working on the
commodities or contractual services that are under bid, the employee will abide by the terms of the
statement and will notifY the employer of any conviction of, or plea of guilty or nolo contendere to, any
violation of Chapter 893 (Florida Statutes) or of allY controlled substance law of the United States or any
state, for a violation occurring in the workplace no later than five (5) days after such conviction.
5. Impose a sanction on, or require the satisfactory participation in a drug abuse assistance or rehabilitation
program if such is ava"ilable in the employee's comrnunity, or any employee who is so convicted.
6. Make a good faith effort to continue to maintain a drug-free workplace through implementation of this
section.
As the person authorized to sIgn the statement, I certify that this firm complies fully with the above
requirements.
2d~tb( ~
l./Bi der's Signature : 0---
~ /~ -7r
Date
OMB - MCP#5
SWORN STATEMENT UNDER ORDINANCE NO. 10-1990
MONROE COUNTY, FLORIDA
ETHICS CLAUSE
.-
A~"if N~ tef..s ( b"'// "7 warrants that he/it has not employed, retained
or othen;vise had act on his/its behalf any former County officer or employee in violation of
Section :2 of Ordinance no. 10-1990 or any County officer or emplo.yee in violation of
Section 3 of Ordinance No. 10-1990. For breach or \Tiolation of this provision the County
ma)', in its discretion, terminate this contract without liability and may also, in its discretion,
deduct fiom the contract or purchase price, or otherwise reco\'er, the full amount of an)' fee,
commission, percentage, gift, or consideration paid to the former County officer or emplo)Tee.
~ w: fLJI
(signature)
4 -/ ~ -7r----
Date:
STATE OF
COUNTY OF 4,y-7?~ E
F4r:f'~
PERSONALL Y APPEARED BEFORE ME~rSigned authority,
fi 'r'~I'9"ff/ /,// 7f ~~o, after fIrst being sworn by me, affixed hislher
signature (nan1e of individual signing) in the space provided above on this ~ ~r~ay of
Fc/:';7:ifvh71Y ,19~
/ ~~~~
NOTARY PUBLIC
My comlnission expires:
MCP#4
"""~";""
/i!-~.'~~ Gloria K. Mceee
~f ,. rb:.-':!.~ MY 00MMISSl0N, CC529329 EXPIRES
..,f.~~oW March 24. 1m
, "Rr..~' SOHOEO llRJ TAOV fAIN INSURANCE. INC.
NON-COLLUSION ~IDA VIT
1,_ ~ i-"/# 4nA'b#
;;tJ1;!trof .~~~
under penalty of perjury, depose and say that;
Jr. ~
1) I am /177 42Jh.5 1/ C'v'/'vy
the Proposal for the project described as follows:'
of the
according to law on my oath, and
, the bidder making
2) The prices in this bid have been arrived at independently without collusion,
consultation, communication or agreement for the purpose of restricting competition, as
to any matter relating to such prices with any other bidder or with any competitor;
3) Unless otherwise required by law, the prices which have been quoted in this
bid have not been knowingly disclosed by the bidder and will not knowingly be disclosed
by the bidder prior to bid opening, directly or indirectly, to any other bidder or to any
competitor; and
4) No attempt has been made or will be made by the bidder to induce any other
person, IJartnership or corporation to submit, or not to submit, a bid for the purpose of
restricting competition;
5) The statements contained in this affidavit are true and correct, and made with
full knov\fledge that Monroe County relies upon the truth of the statements contained in
this affidavit in awarding contracts for sai ject.
STATE OF r /eJ~/c;:t; U/' a..
COUNTYOF 4~p~
.;( -/A -7 r
DATE
PERSONALLY APPEARED BEFORE ME, th~Signed authority,
71~ ~/7ff~ ~ /7ft'Y2l~, after first being sworn by me, (name of
individucll signing) affixed his/her signature in the space provided above on this
I ~~ ~f1day of F~~ 7?cJ/9ff!/19 7r-
~
~~~'7<?//k
NOTARY PUBLIC
My commission expires:
~1CP # 1
...~\~~... Gloria K. McGee
{\,~~/~ MY COMMISSION 1/ CC52ll329 EXPIRES
~~""'b~~~ March 24,1999
, ",9r.,t~'" BONDED THRu TROY FAIN INSURANCE,INC.
~~]IIIIII~~i~~~~!~~~~~~~N
DONATO INS. AGENCY INC. ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE
~ O~~~Ir:'\~)M~ ~I HOLDER. THIS CERTIFICATE DOES NOT AMEND, EXTEND OR
P.O. SOX 607518 ""\ :1 ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW.
ORLANDO FL 32750 l~m t.1j CjJU COMPANIES AFFORDING COVERAGE
407-889-7525 - I .:11
~#i. . COMPANY
n .. A UNITED CAPITAL INSURANCE
INSURED
COMPANY
ARNOLD1S TOWING SERVICE J B WATER QUALITY INSURANCE SYNDICATE
~~OW~~ AVINUE FL 33040 7' COMPANY
I :; COM~ANY
THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD
INDICATED, NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS
CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS,
EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS.
CO TYPE OF INSURANCE
Lm
~!4ERAl UABIUTY
COMMERCIAL GENERAL LJABIUTY
==:=J CLAIMS MADE D OCCUR
OWNER'S & CONTRACTOI~'S PROT
-
-
AUTOMOBILE UABIUlY
-
ANY AUTO
-
AlL OWNED AUTOS
-
SCHEDULED AUTOS
-
HIRED AUTOS
-
NON-OWNED AUTOS
-
-
~RAGE UABIUlY
ANY AUTO
-
-
EXCESS UABIUTY
~ UMBRELl.A FORM
OTHER THAN UMBREUA FORM
WORKERS COMPENSATION AlID
EMPLOYERS' UABIUTY
THE PROPRIETOR! FllNCl
PARTNERS/EXECUTlVE
OFFICERS ARE: EXCL
OTHER
COMMERCIAL HULL/MACHINERY &
A PROTECTION & INDEMNITY
POUCY NUMBER
POUCY EFFECTIVE POUCY EXPIRATION
DATE (MMIDD/VV) DATE (MM/DD/VV)
UMITS
GENERAL AGGREGATE
$
PRODUCTS COMP/OP AGG $
PERSONAL & ADV INJURY $
$
$
$
EACH OCCURRENCE
FIRE DAMAGE (Anyone fire)
MED EXP (Anyone person)
WOM1258157
08/19/97
COMBINED SINGLE UMIT $
BODILY INJURY $
(Per person)
BODILY INJURY $
(Per accident)
PROPERTY DAMAGE $
AUTO ONLY - EA ACCIDENT $
OTHER THAN AUTO ONLY:
EACH ACCIDENT $
AGGREGATE $
EACH OCCURRENCE $
AGGREGA TE $
$
I WC STATU- I IOTH-
TORY UMITS ER
EL EACH ACCIDENT $
EL DISEASE POUCY UMIT $
EL DISEASE EA EMPLOYEE $
COMM. HULL/MACHIN. $5,000
08/19/98 P & I $500,000 CSL
APP.~~ BY ~~ M ~fVfMF.Nr
BY '6 b I. ^,"h ()} A:i?\
q-;jql
'. ",r",. -,. / \WI'
I'll '" .~l
DATE
L17A" (11Jl~
A
C~~
~ lim m ((-;fjL
DESCRIPTION OF OPERA TIONS/LOC4" TIONSNEHICLES/SPECIAlITEMS
MONROE COUNTY BOARD OF COUNTY COMMISSIONERS IS INCLUDED AS POLLUTION COVERAGE - COMPANY B
ADDITIONAL INSURED FOR REMOVAL OF DERELICT VESSESL 08/21/97 - 08/21/98
!~.~I~.@..mW.II~~mmWmW0~~~~@.~~1.1
MONROE COUNTY BOARD OF COUNTY COMMISSIONERS SHOULD ANY OF THE ABOVE DESCRIBED POUCIES BE CANCELLED BEFORE THE
5100 COLLEGE ROAD EXPIRATION DATE THEREOF. THE ISSUING COMPANY WILL ENDEAVOR TO MAIL
KEY WEST FL 33040-4399 ...12.- DAYS WRITTEN NOTICE TO THE CERTIFICATE HOLDER NAMED TO THE LEFT,
BUT FAILURE TO MAil SUCH NOTICE SHALL IMPOSE NO OBUGA nON OR LIABILITY
ACORh25~k{i:~~:~~_~~~~~31~RINE PR:E:TS~~~:~: AUT~~R~~ R~~N:ES~:;A~'v~fL5~~:::::::::sa
--- U
_.-- ------------------- -------- - --- --.--
il~C o'!eTM............i.~.iwl.~.!~&;~....f8.....~..ml..i.~I~g.I.~I......I.r't!.~.m.~i~.!.~~....................................................................................... .
PRODUCEF
DONATe IN!~. I.'iENCY II~C.
P.o. BOX 607518
ORLANDO
407-889-7525
FL
32750
DATE (MM/OOfYY)
04/09/97
THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION
ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE
HOLDER. THIS CERTIFICATE DOES NOT AMEND, EXTEND OR
ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW.
COMPANIES AFFORDING COVERAGE
COMPANY
A CONNECTICUT INDEMNITY
INSURED
ARNOLD1S TOWING SERVICE
5540 3RD AVENUE
KEY WEST FL 33040
COMPANY
B
COMPANY
C
THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD
INDICATED, NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS
CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS,
EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS.
CO TYPE OF INSURANCE POLICY NUMBER POLICY EFFECTIVE POLICY EXPIRA nON LIMITS
lTR DATE (MM/DDIYY) DATE (MM/DO/VY)
GENERAL LIABILITY GENERAL AGGREGATE $
COMMERCIAL GENERAL UABIUTY PRODUCTS - COMP/OP AGG $
CLAIMS MADE CJ OCCUR PERSONAL & ADV INJURY $
OWNER'S & CONTRACTOR'S PROT EACH OCCURRENCE $
FIRE DAMAGE (Anyone fire) $
MED EXP (Anyone person) $
AUTOMOBILE LIABILITY
COMBINED SINGLE LIMIT $
ANY AUTO 500,000
ALL OWNED AUTOS BODILY INJURY
$
X SCHEDULED AUTOS (Per person)
A X HIRED AUTOS TTI00745 04/30/97 04/30/98
BODILY INJURY $
X NON-OWNED AUTOS (Per accident)
PROPERTY DAMAGE $
GARAGE LIABILITY AUTO ONLY - EA ACCIDENT $ 500,000
ANY AUTO OTHER THAN AUTO ONLY:
A X X TTI00745 04/30/97 04/30/98 EACH ACCIDENT $ 500,000
AGGREGATE $ 500,000
EXCESS LIABILITY EACH OCCURRENCE $
UMBRELLA FORM AGGREGATE $
OTHER THAN UMBREUA FORM $
WORKERS COMPENSA nON AI~D
EMPLOYERS' LIABILITY
$
THE PROPRIETOR! INCL EL DISEASE - POLICY LIMIT $
PARTNERS/EXECUTIVE
OFFICERS ARE: EXCL EL DISEASE - EA EMPLOYEE $
OTHER
RGEKEEPERS LEGAL LIAS. $1,000 DED $50,000
A ON-HOOK TTI00745 04/30/97 04/30/98 $1,000 DED $50,000
DESCRIPTION OF OPERA TIONS/LOCA. TIONSNEHICLES/SPECIALITEMS
MONROE COUNTY BOARD OF COUNTY Cot+1ISSIONERS IS INCLUDED AS POLUTION COVERAGE - COMPANY B
ADDITIONAL INSURED FOR REMOVAL OF DERELICT VESSELS 08/21/96 - 08/21/97
... ........... .... .,.. ... .. ... LIMIT OF LIABI LITY - $500,000 .. ............ ........
MONROE COUNTY BOARD OF COUNTY Cot+1ISSIONERS SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE
5100 COLLEGE ROAD EXPIRATION DATE THEREOF, THE ISSUING COMPANY WILL ENDEAVOR TO MAIL
KEY WEST FL 33040-4399 ~ DAYS WRITTEN NOTICE TO THE CERTIFICATE HOLDER NAMED TO THE LEFT,
BUT FAILURE TO MAIL SUCH NOTICE SHALL IMPOSE NO OBLIGATION OR L1ABILllY
OF ANY KIND UPON THE COMPANY, ITS AGENTS OR REPRESENTATIVES.
AUTHORIZED REPRESENTATIVE
ATTN: KIM McGEE, MARINE PROJECTS COORDINATER
ACORD