10/18/1988
SECTION 00500
CONTRACT
THIS AGREEMENT, made and entered into this 18th day of October, 1988, A.D., by
and between ~vIonroe County, Florida, party of the first part (hereinafter sometimes
called the "Ownertt), and The Brewer Company of Florida, Inc., party of the second
part (hereinafter sornetilnes called the "Contractor").
WITNESSETH: That the parties hereto, for the consideration hereinafter set forth,
mutually agree as follows:
1.01 SCOPE OF TI-IE \VORK
A. The Contractor shall furnish all labor, materials, equipment, machinery, tools,
apparatus, and transportation and perform all of the work shown on the
Drawings and described in the Specification entitled:
ROADWAY IMPROVEMENTS
CUDJOE KEY ROADS I
SP ANISH MAIN DRIVE, PUERTO BELLO DRIVE
MONROE COUNTY, FLORIDA
Less item No.2, creation of a 2% cross slope on Spanish Main Drive, as
prepared by Post, Buckley, Schuh & Jernigan, Inc., acting as, and in the
Contract Documents entitled the Owner's Engineer, and shall do everything
required by this Contract and the other Contract Documents.
1.02 THE CONTRACT SUM
A. The Owner shall pay to the Contractor for the faithful performance of the
Contract, in lawful money of the United States, and subject to addition and
deductions as provided in the Contract Documents, as follows:
B. Based upon the price shown in the Proposal heretofore submitted to the Owner
by the Contractor, a copy of said Proposal being a part of these Contract
Documents, the aggregate amount of this Contract is the sum of
One hundred fifty-seven thousand three hundred and sixty /100 Dollars
($157,300.60).
1.03 COl\1MENCEMENT AND COMPLETION OF WORK
A. The Contractor shall commence work within 10 calendar days after receipt of
Notice to Proceed.
B. The Contractor shall prosecute the work with faithfulness and diligence and
shall complete the work not later than 120 calendar days after receipt of
Notice to Proceed.
c. The date on which contract time will begin shall be either the date on which the
Contractor actually begins work or 10 days after the :Notice to Proceed is
issued, whichever is earlier.
00500-1
04-004.87
1.04 CONTRACTOR'S ACCEPT4-\NCE OF CONDITIONS
4-\. The Contractor hereby agrees that he has carefully examined the surface of the
site and has made sufficient test holes, or other subsurface investigations to
fully satisfy himself that such site is a correct and suitable one for this ~Nork
and he assumes full responsibility therefore. "The provisions of this Contract
shall control any inconsistent provisions contained in the specifications. All
Drawings and Specifications have been read and carefully considered by the
Contractor, who understands the same and agrees to their sufficiency for the
work to be done. It is expressly agreed that under no circumstances, conditions
or situations shall this Contract be more strongly construed against the Owner
than against the Contractor and his Surety.
B. Any ambiguity or uncertainty in the Dra wings or Specifications shall be
interpreted and construed by the Owner's Engineer and his decision shall be
final and binding upon all parties.
c. It is distinctly understood and agreed that the passing, approval and/or
acceptance of any part of the work or material by the Owner, his Engineer, or
by any agent or representa tive as in compliance with the terms of this Contract
and/or of the Drawings, and Specifications covering said work, shall not operate
as a waiver by the Owner of strict compliance with the terms of this Contract,
and/or the Drawings and Specifications covering said work; and the Owner may
require the Contractor and/or his surety to repair, replace, restore and/or make
to comply strictly and in all things lNith this Contract and the Drawings and
Specifications any and all of said work and/or materials which within a period
of one year from and after the date of the passing, approval, and/or acceptance
of any such work or material, are found to be defective or to fail in any way to
comply with this Contract or with the Drawings and Specifications. This
provision shall not apply to materials or equipment normally expected to
deteriorate or TNear out and become subject to normal repair and replacement
before their condition is discovered. The Contractor shall not be required to do
normal maintenance work under the guarantee provisions. Failure on the part
of the Contractor and/or his Surety, immediately after Notice to either, to
repair or replace any such defective materials and workmanship shall entitle
the Owner, if it sees fit, to replace or repair the same and recover the
reasonable cost of such replacement and/or repair from the Contractor and/or
his surety, ~Nho shall in any event be jointly and severally liable to the Owner
for all damage, loss and expense caused to the Owner by reason of the
Contractor's breach of this Contract and/or his failure to comply strictly and in
all things with this Contract and with the Drawings and Specifications.
1.05 LIQUIDATED DAMAGES
4.:\. It is mutually agreed that time is of the essence of this Contract and should the
Contractor fail to complete the work within the specified time, or any
authorized extension thereof, there shall be deducted from the compensation
otherwise to be paid to the Contractor, and the Owner will retain the amount of
Two Hundred Dollars ($200.00) per calendar day as fixed, agreed, and liquidated
damages for each calendar day elapsing beyond the specified time for
completion or any authorized extension thereof, which sum shall represent the
actual damages which the Owner will have sustained by failure of the
Contractor to complete the work within the specified time; it being further
agreed that said sum is not a penalty, but is the stipulated amount of damages
sustained by the Owner in the event of such default by the Contractor.
00500-2
04-004.87
B. For the b1urposes of this _-\rticle, the day of final acceptance of the l.vork shall
be considered a day of delay, ~,d the scheduled day of completion of the 'Nork
shall be considered a day scheduled for production.
1.06 P..t\RTIAL ~L\.ND FINAL PAYMENTS
.~. In accordance ~Nith the 9rovisions fully set forth in the General Conditions, and
subject to additions and deductions as 9rovided, the Owner shall pay the
Contractol- as follows:
1. Within 30 days after receipt of the Contractor's request for partial
payment by the Owner, the Owner shall make partial payments to the
Contractor, on the basis of the estimate of wor!< as approved by the
Owner's Engineer, for work performed during the preceding calendar
month, less ten percent (10%) of the amount of such estimate \vhich is to be
retained by the Owner until all work has been performed strictly in
rlccordance with this Agreement and until such work has been accepted by
the Owner.
2. Upon submission by the Contractor of evidence satisfactory to the Owner
that all payrolls, material bills and other costs incurred by the Contractor
in connection with the construction of the tNork have been paid in full, and
also, after all guarantees that may be required in the specifications have
been furnished and are found acceptable by the Owner, final payment on
account of this Agreement shall be made within sixty (60) days after
completion by the Contractor of all work covered by this ..~greement and
acceptance of such work by the Owner.
1.07 ADDITIONAL BOND
4~. It is further mutually agreed between the parties hereto that if, at any time
after the execution of this Agreement and the Performance and Payment Bonds
hereto attached for its faithful performance, the Owner shall deem the surety
or sureties upon such bonds to be unsatisfactory, or if, for any reason, such
bond(s) ceases to be adequate to cover the performance of the vVork, the
Contractor shall, at his expense, and within three days after the receipt of
Notice from the Owner to do so, furnish an additional bond or bonds, in such
form and amount, and with such sureties as shall be satisfactory to the Owner.
In such event, no further payment to the Contractor shall be deemed due under
this Agreement until such new or additional security for the faithful
performance of the work shall be furnished in manner and form satisfactory to
the Owner.
1.08 CONTRACT DOCUMENTS
A. 'The Contract Documents, as stated in the Instructions to Bidders and attached
hereto, are as fully a part of this Contract as if herein repeated. An
enumeration of the Drawings accompanying these Contract Documents follows:
Sheet No. Title
1 Cover Sheet
2 Typical Section and Details
3-5 Plan and Profile
00500-3
04-004.87
IN ~VITNESS WHEREO F the ~arties hereto have executed this ..-\greernent on the day
and date i"irst above 'Nritten in three (3) counterparts, each of 'Nhich shall, fNiti10Ut
proof or accounting for the other counterparts, be deemed an original Contract.:iC
MONROE COUNTY,
FT.ORTnA ~~~~X
Party ~he Firs~art . ~..,
3y: V~~I'. b/
MayorjChai man of the Board
()f r()llnt'y r()mm; ~~i ()npr~
.i:~ r D,.O :~-~. ~ /t~e A S TO FORAf
\~~
Attorney". Qflr:e
Attest:DANNY L. KOLHAGE, Clerk
, (Seal)
rlprk
Signed, Sealed and Witnessed in the
presence of:* *
The Brewer Co. of Florida, Inc.
nd Part
By:
Walter R. Brewer
Vice - President
Ti tIe
Atte
dCo ~ (Seal)
· Gwe~ L!uecke Assistant Secretary
(*) In the event that the Contractor is a Corporation, there shall be attached to
each counterpart a certified copy of a resolution of the Board of Directors of
the Corporation, authorizing the officer who signs the Contract to do so in its
behalf.
(* *) Two witnesses are required when Contractor is sole ownership or partnership.
00500-4
04-004.87
CERTIFICATE
(Sample)
ST.\TE OF FLORIDA )
\ 55
COUNTY OF LJ#);E'" )
I HEREBY CERTIFY that a meeting of the Board of Directors of
The Brewer Co. of Florida, Inc. , a corporation under the laws of the State of
/i ;J,e"'LJ/! , held on,I/JIJIE #J~ / d, , 19fcf~ the following resolution was duly passed and
I -
adopted:
Walter R. Brewer
!fRESOLVED, that , as
ViCC President of the corporation, be and he is
here~y authorized. ,.-, to execute the Contract dated
tJt!lZ!bC:.L- /) , 19}1, between Monroe County, Florida, and
this corporation, andthat his execution thereof, attested by the
Secretary of the corporation and ~Nith corporate seal a.ffixed,
shall be the official act and deed of this corporation."
I further certify that said resolution is now in full force and effect.
IN WITNESS WHEREOF, I have hereunto set my hand and affixed the official seal of
the corporation this Ill' day of AJct/c?nt:V1 ,191'/
~U~<LJ~
/;(?.5/ . Secre Y
?
~wen Luecke
END OF SECTION
00500-5
04-004.87
THis BOND .5 Of !5. EXECUTED COPIES
BOND PREMIUM BASED ON
FINAL CONTRACT PRICE
SECTION 00610
BOND NO. 1161534
PREMIUM: $3,146.00
PERFORMANCE BOND
ST~\TE OF FLORIDA )
5S
COUNTY OF Broward)
!{NOW ALL MEN BY THESE PRESENTS that The Brewer Company of Florida, Inc., as
Principal, hereinafter called Contractor, and
AMWEST SURETY INSURANCE COMPANY as Surety, hereinafter called Surety, are held
and firmly bound unto Monroe County, Florida, as Obligee, hereinafter called O\vner, in
the amount of One Iiundred Fifty Seven Thousand Three IIundred Dollars and Sixty /100
Dollars ($157,300.60) for the payment whereof Contractor and Surety bind themselves,
their heirs, executors, administrators, successors and assigns, jointly and severally,
fir.mly by these presents.
'"vVHEREAS, Contractor has by \vritten agreement dated October 18, 1988, entered into
a Contract with Owner for:
ROADWAY IMPROVEMENTS
CUDJOE KEY ROADS I
SP ANISH MAIN DRIVE, PUERTO BELLO DRIVE
MONROE COUNTY, FLORIDA
Less item No.2 creation of a 2% cross slope on Spanish lV1ain Drive, in accordance with
Drawings and Specifications prepared by Post, Buckley, Schuh & Jernigan, Inc., which
Contract is by reference made a part hereof and is hereinafter referred to as the
Contract.
NOlV, THEREFORE, THE CONDITIONS OF TliIS OBLIGATION ARE SUCH, that, if
the Principal shall in all respects promptly and faithfully perform and comply with the
terms and conditions of said Contract and his obligations thereunder and shall indemnify
the Owner and the Consulting Engineer and save either or all of them harmless against
and from all costs, expenses and damages arising from the performance of said Contract
or the repair of any work thereunder, then this obligation shall be void; other\vise, this
Bond shall remain in full force and effect, in accordance with t~e following terms and
conditions:
A. The Principal and Surety jointly and severally agree to pay the Owner any
difference bet\veen the sum to which the said Principal would be entitled on the
completion of the Contract, and that sum which the Owner may be obliged to pay
for the completion of said work by Contract or otherwise, and any damages,
direct or indirect or consequential, which the said Owner may sustain on account
of such work, or on account of the failure of said Contractor to properly and in all
things, keep and execute all of the provisions of said Contract.
00610-1
04-004.87
THIS BOND --5. OF ,5 - EXECUTED COPIES
B. ..:\nd this Bond shall remain in full force and effect for a period of one (1) year
from the date of acceptance of the project by the Owner and shall provide that
the Contractor guarantees to repair or replace for said period of one (1) year all
.vVork performed and materials and equipment furnished that were not performed
or furnished according to the terms of the Contract, and shall make good, defects
thereof tNhich have become apparent before the expiration of said period of one
(1) year. If any !?art of the project, in the judgment of the Owner, for the reasons
above stated needs to be replaced, repaired or made good during that time, the
Owner shall so notify the Contractor in writing. If the Contractor refuses or
neglects to do such work within five (5) days from the date of service of such
Notice, the Owner shall have the work done by others and the cost thereof shall
be paid by the Contractor or his Surety.
c. LL\.nd the said Surety, for value received hereby stipulates and agrees that no
change, extension of time, alteration or addition to the terms of the Contract or
to the iNork to be performed thereunder or the specifications accompanying the
same shall in any ~vise affect its obligations on this bond, and it does hereby 'Naive
Notice of any change, extension or time, alteration or addition to the terms of the
Contract or to the work or to the Specifications.
D. The surety represents and warrants to the. Owner tha t they have a Best's Key
Rating Guide General Policyholder's Rating of n A n and Financial
Category of "Class V n.
00610-2
04-004.37
THIS BOND.Ji.... OF ,~ EXECUTED COPIES
IN ~VITNESS ~VHEREOF, the above bounded f:)arties executed this instrument under
their several seals, this 8th day of November 19 88, A.D., the name and
corporate seal of each corporate party being hereto affixedand these presents duly
signed by its undersigned representative, pursuant to authority of its governing body.
vVITNESS: (If Sole O'(Nnership or Partnership, tTNO (2) Witnesses required).
(If Corporation, Secretary Only ~vill attest and affix seal).
PRINCIP AL:
FLORIDA INC.
~van.er R. brewr1.ffix
Signature of Authorized Officer (Seal
WITN. ES: _._ _ . .
Ji- - ULq
~wen Luecke Assistant Secretary
Yice - President
~
Title
f,/t); M LV. /()~
Business Address
/nl #/n/' h6J~/ '~/I 33//~j?
/
City State
6ffe~:-/'
SURETY:
~VITNESS:
Ft. Lauderdale. FL 33309
City State
Frank B. Hall & Company of Florida
Name of Local Insurance Agency
00610-3
04-004.87
THIS BOND -b.- OF ~ EXECUTED COPIES
CERTIFICATES 4~S TO CORPOR.~TE PRINCIPAL
I,
Gwen ,Luecke
/>' ..~-~
t;...
/l.:5c/T
, certify that I am the Secretary of the Corporation
Walter R. b[c,..vcr
named as Principal in the within bond; that who signed the said
. . Vice - PresiLient
bond on behalf of the PrIncIpal, was then ~. of said Corporation; that I
know his signature, and his signature hereto is genuine; and that said bond was duly
signed, sealed, and attested for and in behalf of said Corporation by authority of its
governing body.
~
' __ ' i - ttllJ2.
/!::J~/. ?ecreta: '.
Corpora te
5e)u
STATE OF FLORIDA )
5S
COUNTY OF Brovard )
Before me, a Notary Public, duly commissioned, qualified and acting, personally
appeared Richard D. Zwetsch
to me well known, \vho being by me first duly sworn
upon oath, says that he is the .-\ttorney-in-Fact, for the AMWEST SURETY INSURANCE COMPANY
and that he has been authorized by
AMWEST SURETY INSURANCE COMPANY
to
execute the foregoing bond on behalf of the Contractor named therein in favor of the
Monroe County
Subscribed and sworn to before me this .Jl.th day of
November
, 19.8ll, A.D.
(Attach Power of Attorney)
.JJkl(j ~. (J1a1~l
Notary ubli
State of Florida-at-Large
My Commission Expires:
END OF SECTIO~,NOTARY PUBLIC, STATE OF FLORIDA.
l.~y COMMISSION EXPIRES: FEB. 23, 1982,
BONDED THRU NOTARY PUBLIC UNDIUIW"'TJU'.,
00610-4
04-004.87
THIS BOND -Jl- OF D- EXECUTED COPIES-
SECTION 00620
BOND NO. 1167534
PREMIUM: $3,146.00
BOND PREMIUM BASED ON
FINAL CONTRACT PRICE
PAYMENT BOND
ST4\TE OF FLORIDA )
S5
COUNTY OF Broward )
KNOW ALL l\1EN BY THESE PRESENTS that The Brewer Company of Florida, Inc., as
Principal, hereinafter called Contractor, and
AMWEST SURETY INSURANCE COMPANY as Surety, hereinafter called Surety, are held and
firmly bound unto l\1onroe County, Florida, as Obligee, hereinafter called Owner, in the
amount of One Hundred Fifty Seven Thousand Three Hundred Dollars and Sixty /100
Dollars ($157,300.60) for the payment whereof Contractor and Surety bind themselves,
their heirs, executors, administrators, successors and assigns, jointly and severally,
firmly by these presents.
WHEREAS, Contractor has by written agreement dated October 18, 1988, entered into
a Contract with Owner for:
ROADWAY IMPROVEMENTS
CUDJOE KEY ROADS I
SPANISH MAIN DRIVE, PUERTO BELLO DRIVE
MONROE COUNTY, FLORIDA
Less item No.2, creation of a 2% cross slope on Spanish Main Drive, in accordance with
Drawings and Specifications prepared by Post, Buckley, Schuh & Jernigan, Inc., which
Contract is by reference made a part hereof and is hereinafter referred to as the
Contract.
NOW, THEREFORE, THE CONDITIONS OF THIS OBLIGATION ARE SUCH, that, if
the Principal shall promptly make payments to all claimants, as hereinbelow defined,
then this obligation shall be void; otherwise, this Bond shall remain in full force and
effect, sUbject to the following terms and conditions:
A. A claimant is defined as any person supplying the Principal with labor, material
and supplies, used directly or indirectly by the said Principal or any subcontractor
in the prosecution of the work provided for in said Contract, and is further
defined in Section 255.05(1) of the Florida Statutes.
B. The above named Principal and Surety hereby jointly and severally agree with the
Owner that every claimant as herein defined, who has not been paid in full before
the expiration of a t;)eriod of ninety (90) days after performance of the labor or
after complete delivery of materials and supplies by such -claimant, may sue on
this Bond for the use of such claimant, prosecute the suit to final judgment for
such sum or sums as may be justly due claimant, and have execution thereon. The
Owner shall not be liable for the payment of any costs or expenses of any such
sui t.
00620-1
04-004.87
THIS BOND F. OF....1:L EXECUTED COPIES'
c. No suit or action shall be commenced hereunder by any claimant:
1. Unless claimant, other than one having a direct contract with the
Principal, shall within forty-five (45) days after beginning to furnish labor,
materials or supplies for the prosecution of the work, furnish the Principal
\vith a notice that he intends to look to this bond for protection.
2. Unless claimant, other than one having a direct contract with the
Principal, shall \vithin ninety (90) days after such claimant's performance
of the labor or complete delivery of materials and supplies, deliver to the
Principal tNritten notice of the performance of such labor or delivery of
such material and supplies and the nonpayment therefor.
3. L~fter the expiration of one (1) year from the performance of the labor or
completion of delivery of the materials and supplies; it being understood,
however, that if any limitation embodied in this Bond is prohibited by any
law controlling the construction hereof such limitations shall be deemed to
be amended so as to be equal to the minimum period of limitation
permitted by such law.
4. Other than in a state court of competent jurisdiction in and for the county
or other political subdivision of the state in which the project, or any part
thereof, is situated, or in the United States District Court for the district
in which the project, or any part thereof, is situated, and not elsewhere.
D. The Principal and the Surety jointly and severally, shall repay the Owner any
sum which the Owner may be compelled to pay because of any lien for labor or
materials furnished for any work included in or provided by said Contract.
E. The Surety, for value received, hereby stipulates and agrees that no change,
extension of time, alteration of or addition to the terms or the Contract or to
the work to be performed thereunder or the Specifications applicable thereto
shall in any wise affect its obligations on this Bond, and the Surety hereby
waives notice of any such change, extension of time, alterations of or a.ddition
to the terms of the Contract, or to the work or to the Specifications.
F. The Surety represents and warrants to the Owner that they have a Best's Key
Rating Guide General Policyholder's rating of" A " and
Financial Category of "Class V ".
00620-2
04-004.87
THIS BOND -1i. OF !5 - EXECUTED COPIES .
IN ~VITNESS ~VHEREOF, the above bounded parties executed this instrument under
their several seals, this 8th day of November 19 8& A.D., the name and
corpora te seal of each corpora te 9arty being hereto affixedand these presents duly
signed by its undersigned representative, pursuant to authority of its governing body.
~VITNESS: (If Sole Ownership or Partnership, two (2) Witnesses required).
(If Corporation, Secretary Only will attest and affix seal).
PRINCIP ..~L:
ANY OF FL C.
.walter R. Brew~~ffix
(Seal
yVITNESSES:
~u~~-eJ~
.Vice - President
----)
Title
Gwen Luecke
Assistant Secretary fljiJ; ~ u). /L'4 ~E7
Business Address
/)?/ .ft7J}/~ ~LtV2/'2JrJ 33/:lJ?
City State
SURETY:
/j/~ g.(! &
~VITNESS:
Ft. Lauderdale. FL 33309
City State
Frank B. Hall & Company of Florida
Name of Local Insurance .t\.gency
00620-3
04-004.87
THIS BOND :5 OF ~EXECUTED COPIES-
CERTIFICATES ~~S TO CORPORATE PRINCIP..~L
I,
.~w.e~ Luecke
1/.:56 r~
, certify that I am the Secretary of the Corporation
Walter R. 8tewer
named as Principal in the within bond; that
who signed the said
Vice - President ,. .
.. or saId CorporatIon; that I
bond on behalf of the Principal, was then
know his signature, and his signature hereto is genuine; and that said bond was duly
signed, sealed, and attested for and in behalf of said Corporation by authority of its
governing body.
Il :J6r
STATE OF FLORIDA )
55
COUNTY OF Broward )
Before me, a Notary Public, duly commissioned, qualified and acting, personally
appeared Richard D. Zwetsch
to me well known, who being by me first duly sworn
upon oath, says that he is the Attorney-in-Fact, for the AMWEST SURETY INSURANCE COMPANY
and that he has been authorized by
AMWEST SURETY INSURANCE COMPANY
to
execute the foregoing bond on behalf of the Contractor named therein in favor of
Monroe County, Florida.
Subscribed and sworn to before me this ..8.th.. day of
November
, 19 88, A.D.
(Attach Power of Attorney)
~{~.cIa1~
Notary lic
State of Florida-at-Large
My Commission Expires:
END OF SECTION NOTARY PUBlrc, STATE OF FLORIDA
MY COM MISSION EXPIRES: FEB. 23, 1-992.
.ONDeD THRU NOTARY PUBLIC UNDERWRITERS_
00620-4
04-004.87
AMWEST SURETY INSURANCE CO.
P.O. Box 4500
Woodland Hills, CA 91365
(818) 704-1111
POWER OF ATTORNEY
KNOW ALL MEN BY THESE PRESENTS, JhatAMWESTSURETY INSURANCE COMPANY,.A CALIFORNIA CORPORATION
does hereby make, constitute and appoint
.. ~ICHARD. D. ZW,ETSC,H,o:
, .
Its true and lawful Attorney(s)-in-Fact, with full power and authority for and on behalf of'the company as surety, to execute and
deliver and affix the seal of the companytheret9'f a seal Is required, bonds, undertakings,recognizances or otherwriUen obliga-
tlona In the nature thereof, as fOllOWS::;,:' ' ".
Contract, Court,.' License, Permit and Miscellaneous Bonds.
and to bind AMWEST SURETY INSURANCE COMPANY thereby, and all of the acts of said Attorneys-in-Fact, pursuant to these
presents, are hereby ratified and confirmed. This appointment Is made under and by authority of the following provisions of the By-
Laws of the company, which are now I,n full force and effect: ' .,',' -. ,. . '. · ,
Article III, Section 70f.the.By..L~ws'ofAMWEST SURETY INSURANCE COMPANY
This Power of Attorney Is signed and sealed by facsimile under and by the authority of the following resolutions adopted by
the board of directors of AMW.~ST~UAm;~~S~RA~CE ,CO~PA.NY a~, a meeting duly held on, December 15.1975. .
" ; ').':.~~~.:: ':: ; ." .
RESOLVED that the president or any vice-president, In conjunction with the secretary or any assistant secretary,
may appoint attorneys-in-factor agents with authority as defined or limited In the Instrument evidencing the appoint-
ment In each case, for and on,behalf of the company to execute and deliver and affix the seal of the company to bonds,
undertakings, recognizances, and suretyship obligations of all kinds; and saldofflcersrnayremo~e any such attorney-
In.fac~or agent' and revokea.ny. power ofa~~~rn~y prevlouslygrantedt~such pers()n....~:'. ' '. '
RESOLVED FURTHERthaf: any bond, undertaking, recognlzan~e, orsuretyshlp.obtigations~all, be valid and,
binding upon the company ,
. (I) when signed by the presl~entC?~anyvipe-president and attested and sealed (if a seal be required) by any sec-
retary or assistant secretary; or .
. (II) .when signed by the president or.any vice-president or secretary..or assis~ar1~..secretary, an,d countersigned
and sealed (If a seal be required) by a duly authorized attorney-in-fact or agent; or', .
(III) when duly executed and sealed (If a seal be required) by one or more attorneys-in-fact or agents pursuant to and '
within the limlts.of the authorlt~evidenced by the power of attorney issued.bY,th~cornpanyto such p'~rson or persons.
'RESOLVED FURTHER that the signature of.any authorized officer and the seal of thecompany.may be affixed.
by facsimile to any pow~r of attorney or certification thereof authorizing the execution and delivery of any bond, under-
taking, recognizance, or other suretYShip obligations of the company; and such signature and seal when so used shall
have. the aame force and effect as though manually affixed.
IN WITNESS WHEREOF, AMWEST SURETY INSURANCE COMPANY has caused these presents to be signed by its proper of-
flcerf and Ita corporate seal to be hereunto affixed thts 1 st day of ~ANUARY 19 88
AMWEST SURETY INSURANCE COMPANY
~ /f. ~eterson. President
~~C~
Karen G. Cohen, Secretary
STATE OF CALIFORNIA, COUNTY OF LOS ANGELES - ss
On this 1st day of JANUARY A.D., 19~. personally came before me Gary R. Peterson
and Karen G. Cohen to me known to be the individuals and officers of AMWEST SURETY INSURANCE COM-
PANY, CALIFORNIA who executed the above instrument, and they each acknowledged the execution of the same, and being by me
duly sworn, dId severally depose and say: that they are the said officers of the corporation aforesaid. and that the seal affixed to the
above instrument Is the seal of the corporation, and that said corporate seal and their signatures as such officers were duly affixed
and subscribed to the said instrument by the authority of the board of directors of said corporation.
- ~ ~ .- ~ -
4 ., OFFICIAL SEAL ~
~ JANICE ORUEZ .
~ NOTARY PUBLIC · CAUFORNIA
.
LOS NtGfLES COUNTY ~
Mr CIIIUII. expires MAY 1, 1989 ~
-- -- --
(SEAL)
STATE OF CALIFORNIA, COUNTY OF LOS ANGELES - sa
CERTIFICATE
I, the undersigned, secretary of the AMWEST SURETY INSURANCE COMPANY, a California corporation, DO
HEREBY CERTIFY that the foregoing and attached Power of Attorney remains in full force and has not been revoked, and further-
more, that the provisions of the By-Laws of the company and the Resolutions of the board of directors set forth In the Power of
Attorney, are now In force.
Signed and sealed at Ft. Lauderdale
Bond No. 1167534
this 8 th day of
November
19J!!L.
y~ ~ ~COhen. Secretary
SECTION 00650
CERTIFICATE OF INSURANCE
'T'HIS IS TO CERTIFY THAT THE
Insurance Company
Address
of
has issued policies of insurance, as described below and identified by a t)olicy number, to
the insured named below; and to certify that such policies are in full force and effect at
this time. It is agreed that none of these policies \vill be cancelled or changed so as to
affect the interest(s) of the (hereinafter
sometimes called the Owner) until thirty (30) days after written notice of such
cancellation or change has been delivered to the Owner's Architect/Engineer; Post,
Buckley, Schuh &: Jernigan, Inc.
Insured
Address
Status of Insured _ Corporation _ Partnership
Location of Operations Insured
Individual
Description of ~Vork
INSURANCE POLICIES IN FORCE
Forms of Coverage
:41 Worker's Compensation/Employers' Liability
+Comprehensive Automobile Liability
oComprehensive General Liability
Policy Number
Exoiration Date
Contractual Liability
+Excess Liability
Other (Please specify type)
POLICY INCLUDES COVERAGE FOR:
YES
NO
1. Additional Insured: The Owner.
2. *Liability under the United States Longshoremen's and
Harbor Workers' Compensation Act.
3. +All owned, hired, or nonowned automotive equipment
used in connection with work done for the Owner.
00650 - 1
04-004.87
POLICY INCLUDES COVERAGE FOR: (Continued)
YES
NO
4. OOamage caused by explosion, collapse or structural
injury, and damage to Imderground utilities.
5. Products/Completed Opera tions
6. Owners and Contractors Protective Liability
7. Liability assumed in the Contract
8. Personal Injury Liability
9. +Excess Liability applies excess of:
(a) Employers' Liability
(b) Comprehensive General Liability.
(c) Co mprehensive ..:\utomobile Liabili ty
(d) Contractual Liability
FORM OF COVERAGE
Llrv1ITS OF ~IABILITY
B001L Y INJURY
PROPERTY DAMAGE
vVorker's Compensation
Statutory
xxxxxxxxxxxx
Employers' Liabilitv $
Each Accident XXXXXXXXXXXXXXX
Co mprehensive
Automobile Liability $
Each occurrence-
Combined Sin1!le Limit BI/PD
Co mprehensive
General Liability $
Each occurrence-
Combined Sine:le Limit BI/PD
Contractual
Liabili ty
$
Excess Liability
Other (please
specify type)
The Insurance Company hereby agrees to deliver, within ten (10) days, two (2) copies of
the above policies to the Owner's Architect/Engineer when so requested.
$
Each occurrence-
Combined Sillftle Limit BI/PD
NOTE: Entries on this certificate are limited to the Authorized Agent or Insurance
Company Representative.
Date
(SEAL)
Insurance Company
Issued at
.:\.uthorized Representative
Insurance Agent or Company
- Send original and one copy to:
Post, Buckley, Schuh & Jernigan, Inc.
1 North Krome Avenue
Homestead, Florida 33030
END OF SECTION
00650 - 2
04-004.87
~'--. --- .~ ~~ .------- --- ---- ~.__.- --~ - _.~_._--- -'-"-- -'-- -~. ,-~~- ~--- .-_. ---
ASSOCIATED GENERAL CONTRACTORS
SELF INSURERS FUND
~OO BOX 10409, TALLAHASSEE, FLORIDA 32302
CERTIFICATE OF SELF INSURANCE
ISSUED TO:
(VIc>nrc)e County Public Works Department
SOC) ~'ihi teh(=ad StreE?t.
~KE~Y ~\1e.st l ,Flol:"i(":;a 33C}4C>
This is to certify that
'Tl'H~: I.:{RE~WE:F;~ C;Ct,~ (Jr::' F~L..CH:;: I LiJ:~f~, ]J\!C~ ~ v
'l:lf:~<) :i. i") '# ttJ ';' :r ()t!.) ~:rrF:E:'E:'r
~~ I AM I
to" $
r' 1...
~3 :~3, 1 '"? ~:~
being subject to the provisions of the Florida Worker's Compensation Act, has secured the payment of
compensation by becoming a member of the Associated General Contractors Self Insurers Fund.
COVERAGE NUMBER: E3....f:3C.....():I. ~.~(y()
EFFECTIVE DATE:
::) ./' () 1 /" t:~~]
Statutory - State of Florida
EXPIRATION DATE:
J. () 1 /"~3fj':;
;1;:1. ~ ()()() .. ()()() Employers Liability
C:CljViI-:{ I ,".IE]) E~ J hH3L.E:: L I t1 T'}
REMARKS:
~~,dditionul Insur~<:e I'Jonr-oe County Publ ic ~liorks Depa.ctment
Pt-c'ject
· OL1-r)()LJ.~ B'7 l f<oadwa}l' Irnprovement[;
Cu6joe Key Roads I
This certificate is not a policy and of itself does not afford any coverage. Nothing contained in this certificate
shall be construed as extending coverage not afforded by the group shown above or as affording coverage
to any member not named above.
DATE:
l~obeInber 1 Cl . 198f"i
BY:~S%~
Vice President
CRIMS, Inc.
CRIMS, INC.
Combined Risk and Insurance Management Services
P.O. Box 149025 · 4401 E. Colonial Drive. Orlando, Florida 32814-9025 . (305) 898-0666
~~ttRI~
PRODUCER
ISSUE DATE (MM/DD/YY)
11/4/88
THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS
NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AMEND,
EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW
ARTHUR J. GALLAGHER & CO.
P.O. Box 02-5288
Miami, FL 33102-5288
Tel 11(305) 592-6080
CODE SU~CODE
COMPANIES AFFORDING COVERAGE
~~~~NY A National Union Insurance Co.
NOV 8 IS'38
~~+-i~~NY C
f~~~~NY B International Insurance Co.
~< .
INSURED
The Brewer Company of Florida, Inc.
9801 NW 106th Street
Miami, FL 33178
~~~~NY D
~~~~~NY E
t
I. .'
::~,....,. ...
,: .~ j ~ 'g'~
eG\fERA.8ES
THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD
INDICATED, NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS
CERTIFICATE MAY BE ISSUED OR MAY PERTAiN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS,
EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS.
CO
LTR
POLICY NUMBER
POLICY EFFECTIVE . POLICY EXPIRATION
DA TE (MM/DD/YY) DA TE (MM/DD/YY)
TYPE OF INSURANCE
GENERAL LIABILITY
A X COMMERCIAL GENERAL LIABILITY
CLAIMS MADE X OCCUR.
OWNER'S & CONTRACTOR'S PROTo
8171212RA
9/1/88
9/1/89
AUTOMOBILE LIABILITY
A X ANY AUTO
ALL OWNED AUTOS
SCHEDULED AUTOS
X HIRED AUTOS
X NON-OWNED AUTOS
GARAGE LIABILITY
9/1/88
CA82308093RA
9/1/89
This Cf~rtificat8 01 fn;~~:ur:'.nc'~ 0: B~nd~~l ev~d9ncs. "
the !irnits of d'~n'.e jnGt;'p~G;Jn
Hf{i~~tl
; j ~";'i ~ '~;'3.. Hi'; d
A~~ i
EXCESS LIABILITY
B X
Umbrella
524-202158-7
9/1/88
9/1/89
OTHER THAN UMBRELLA FORM
WORKER'S COMPENSATION
AND
EMPLOYERS'LlABILlTY
OTHER
ALL LIMITS IN THOUSANDS
GENERAL AGGREGATE $
PRODUCTS-COM PlOPS AGGREGATE $
PERSONAL & ADVERTISING INJURY $
EACH OCCURRENCE $
2,000
1,000
1,000
1,000
100
5
FIRE DAMAGE (Anyone fire) $
MEDICAL EXPENSE (Anyone person) $
COMBINED
SINGLE $ 1,000
LIMIT
BODILY
INJURY $
(Per person)
BODIL Y
INJURY $
(Per accident)
PROPERTY $
DAMAGE
EACH
OCCURRENCE
$ $
5,000
STATUTORY
AGGREGATE
5,000
$
$
$
(EACH ACCIDENT)
(DISEASE-POLICY LIMIT)
(DISEASE-EACH EMPLOYEE
DESCRIPTION OF OPERA TIONS/LOCA TIONS/VEHICLES/RESTRICTIONS/SPECIAL ITEMS
Addi tional Insured - :Monroe County Board of County Corrmissioners for Roadway Irrprovenents,
CUdjoe Key Roads I, Project #04-004.87
OERTlFtCA.....s.....eiZDsR
~nroe County Board of County
500 White Street
Rey west, Fla. 33040
ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE
EXPI~'ON DATE THEREOF, THE ISSUING COMPANY WILL ENDEAVOR TO
MAll_ DAYS WRITTEN NOTICE TO THE CERTIFICATE HOLDER NAMED TO THE
LEFT, BUT FAILURE TO MAIL SUCH NOTICE SHALL IMPOSE NO OBLIGATION OR
LIABILITY OF. NY KIND UPON THCOMPANY, ITS AGENTS OR REPRESENTATIVES.