Loading...
DV091891r CONTRACT AGREEMENT AGREEMENT, MADE THISday of aA 1995, by u t,lt and between, Spirit ("Contractor"), and ?_ T 3 the BOARD OF COUNTY COMMISSIONERS OF MONROE COUNTY, FLdRIDA,^ of _ the County of Monroe, State of Florida ("Board"). -D The contractor and the Board, for the consideraton'namod agree as follows: 1. The contractor shall furnish all the materials and. perform all the work as required by the Specifications for the emergency removal DV091891 for which derelict vessel report is attached as exhibit A. 2. The work to be performed under this contract shall commence immediately from the date the Liaison provides the Notice to Proceed and shall be completed by May 31, 1995 3. If the Notice to Proceed has not been given on or before May 18, 1995 then this agreement shall be null and void. 4. The work to be performed under the contract is contingent upon approval of appropriate grant monies from the State Department of Environmental Protection, Boating Improvement Fund. If this grant is denied, this Agreement shall be null and void. The contractor understands the rules of the Department of Environmental Protection and shall comply with said rules, along with the rules and procedures instituted by the Board to ensure an orderly progress to the project. Both the intent and the letter of the specifications are understood by the contractor. 13 5. The Board shall pay the Contractor the total sum of $1,092.50 for the emergency removal and legal disposal of DV091891. Payment for the work shall be upon completion by the contractor and acceptance by the Board, subject to the terms and conditions of the Specifications attached as Exhibit B and this contract. 6. The attached Derelict Vessel Report and Specifications together with this Agreement, form the the contract. They are fully a part of this contract as if repeated herein verbatim. 7. The contractor shall indemnify the Board from and against any and all claims, demands, actions, proceedings, damages, liabilities, costs and expenses, including attorney fees, arising out of, connected with, or resulting from the Agreement. 8. The contractor acknowledges his/her intention to comply with the need to coordinate all work with the appropriate environmental agencies, the Florida Marine Patrol, and the County. 9. The contractor agrees to supply the County with a set of photographs of the vessel in all phases of the removal and disposal process. The contractor will be responsible for the camera, film, and development costs. 10. The contractor understands and agrees that the receipt of the Notice to Proceed from the County does not relieve his responsibility to obtain any appropriate permits. The contractor must inform the appropriate permitting authorities prior to initiation of work. 11. The parties agree that timely performance of this agreement is essential due to possible damage to the natural resources, hazard to navigation, or threat to human health and welfare. Therefore, the parties agree that the contractor shall be liable to the Board for $100 per day of liquidated damages for each day after May 31, 1995 that any of the contractor's obligations under this agreement remain unperformed. The parties agree that such amount is by the way of compensatory damages and does not constitute a penalty. 12. Due to the use of heavy equipment and,, at times, dangerous work environment, the contractor understands and agrees to maintain an alcohol and drug free work environment. 13. The contractor will provide General Liability insurance in the amount of $300,000, Workers Compensations the amount of $500,000, Federal Jones Act (46 U.S.C.A. subsection 688) with limits not less than those specified for Employer's Liability, Vehicle Insurance in the amount of $100,000, Watercraft Liability in the amount of $300,000, and Pollution insurance in the amount of $500,000. All policies must list Monroe County as additional insured with the exception of the Worker's Compensation policy. 14. The Board may terminate this agreement with or without cause at anytime upon giving the contractor a minimum of ten days in writing. The contractor, upon receipt of the notice, shall immediately cease work. The Board shall pay the contractor the percentage of the contract sum which is proportional to the amount of work performed by the contractor in a manner satisfactory to the Board up to the date the contractor received the Notice to Proceed. IN WITNESS WHEREOF the parties hereto have executed this Agreement to day and year first written abo�' BY: i (Seal) Attest: Witness Owner Title _Spirit Firm BOARD OF COUNTY COMMISSIONERS OF MONROE COUNTY, FLORIDA V F BY: Mayor/Cha an (Seal) Attest: DANNY L. KOLHAGE, Clerk A►A'1JIA4. - . Clerk / JArtarea.K "� O ire __ MAY-09-1995 10:51 FROM FLA. MARINE PATROL DIST-9 TO 03052924417 P.01 • wow w-r ..�v.�.�.�. ..�.. �... ._. .. ... -------....... .__..._..,...._..._..----....... ...... _.... _.... .................. .............................................. C014DITIONS WRECKED �. ; JUNKED Y ,• ....._..........._..._---..._---- .............._....._.............._........................_................... ................... .......... ........ ..................-..................._..............._.............................................. ._..__.._...__ ___ ._._.._...._.. __._...._._....._._._...............I................................................................................._....................................................................... _........................._... DISMANTLED ... ; ABANDONED P- ..................... .. 3. SUBMERGED .. ...._.._......._....._......._ . ................... .....................................................................................................................................-..................----..............---- IN FT. OF WATER OR AFLOAT OR ON S11O , BELOW MEAN HIGH WATER LINE . 6. PROPIIRT1 OWHIMI ..----------- _---.........:................_......... STATE OF FLORIDA ...._........_._ ................. ...... YES NO ............... ........... ..._...-..... .......... ..... ...... . OR _..... _.._...... _---.......................... _............ ........... ---- ...............................I..... .. !. NAVIGATION THAHATBNRD? YES NO _.._....._ ............................... ...................... _........._...._....._.._................................... NO ................................................................................................................................ . 10. BNVIRONMBN4' BNbANtiERBD? YES __ .._ _ ._......__ _ ______......__...__...._...._................ _.... ........ ....... ............_ .... ........ ......... _......... ........................................... 11. TOWND WITHOUT RHPAIR? YES NO UNKNOWN ................. _.................... _....... I.- .... ........... ...... .......... ........ .. 12. RECOMMENDED DISPOSITION! LANDFILL OTHER PAn4WQd By: VM !o-o"A FIND Weil vets p.v.. 1 .1 3 ............ .................... _ .... , ❑' MAY-09-1911t. 10:r12 FRF-1111 FLO. MARINE PATROL DI T ') TO 0H0<<924417 P.02 Cv..'FENSi. INCIDENT REPORT NARRATIVF (�r)N'TifVlIt\-rinni ••.. -v.{q 11-1— Pllg IinOntO Orink —•, -• Oflicer"e Sipneture Lw �x / VNit 70 Ve5A rmr in/7rr --- -- --,� -- - .j --- ---- ^ ori0irrni G Supple ... ow Q MAY-09-1995 10.54 FROM FLA. MARINE PATROL DIST-9 TO 83052924417 P.03 ' ! . 1 .0 07 .7 '—j 7 a W n 'J ".'•. S ..• 7 . S , 6 7 7 7 7 a i f G. • 7 . 6 i 1 O 7 All 7 7 S ^\ '7 .7 • m 7 ti 10 G 7 , 7 • 7 li \G 7 _ 4 • la S S • 22 .>.• 7 S ^ all m" S Il�1fM S i U .A S % i v S • j O�Q'WOA �•� y S a li 1 is ! .�.• � �. - r: -'q �„5 { � t b• ice... .7 1t '\, i , ' ^~` \_ 1-.. YlbpAIIKEY If 7 �O n 11 • F �5.; 2 13 • ro a �, to tt i* t7 M K It 1i • ...1 - .. ! 26 K 1S _ • 75 $ . to7z 71 x L 29 1 7t 79 72 v as a , n 20 s s v \ s a 7! s 30 s a3 7t 30 a 7s x a ` � a s z ?oj7a 1 p 2 \ 8s . 7ar as 7i 31B x s p b 7s 7t A p p b ?! x all • s ��. a i7 •.. s s 72 s \ a x i at a •p .a, a 77 y a s v r as ry 76 1 77 at 71 s M a, V 71 7► D �8 a a! 79 s tit b 7/ at • r Y 3; 7♦ 1/ \ all a1 77 lA• 37 39 ' 7i — sy 22 IF m 39 77 35 40 all :9, 311, � = ;tom *,k.t 42 to•Z IF X-11 7S -a 30 TIC Y s, �r x sue$ a 71 all _— w 1 as _ 71 x all �f s iy x i s I'll �•s - » •� s 1r r .Gi as "AS all n all TOTAL P.03 UNITED STATES MEMORANDUM TO: Kim Blanco REPLY TO: ATTN OF: David L. Vecera, Lead Refuge Officer, Florida Keys Refuges DATE: 04-30-95 SUBJECT: Abandoned/Derelict Vessel at Boca Grande Key The following is the information you requested in order to process the vessel: DV 09 1891 FL#s: Tampered/unreadable, several possibilities by appearance. Footage: 18' approx. Motor: None. U.S. DEPARTMENTOFTHE INTERIOR U S FISH AND WILDLIFE SERVICE C� DIVISION OF REFUGES Material: Fiber over wood. DAVID L. VECERA Make: Unknown, possibly homemade. REFUGE OFFICER LAW ENFORCEMENT Type: Open fisherman. FLORIDA KEYS WILDLIFE REFUGES PO, BOX 430510 BIG PINE KEY. FLORIDA 33043-0510 Color: Gray & white. FAX 1305) 872-3675 TEL 13051 872-2239 Owners: Unknown - Location: NW beach of Boca Grande Key, approx. 200' south of mangroves. Status: Abandoned. Condition: Bad . Submerged: 5-100 (bottom only) Depth: 1'. Afloat or On Shore: On Shore. Photos: 2 Thank you for your prompt assistance. Dave MAY 01 '95 03:31PM FLORIDA KEYS REFUGES P.1/3 • United States Department of the Interior FISH AND WILDLIFE SERVICE 9 ` Florida Ken National Wildlife Re[Ws w P.O. Box 510 Big Pint Ker, Florida 33043 FAX o 51'L7 y DATE : 05-01-95 TO: Kim Blanco, Marine Projects Coordinator FROM: David L. Vecera, Lead Refuge Enforcement Officer SUBJECT: Derelict Vessel# DV 09 le91 NUMBER OF PAGES TO FOLLOW: 2 REMARKS/INSTRUCTIONS: Case Incident Report enclosed. First paragragh, page two, explains the why for the emergency removal. Thank yout MAY 01 '95 03:31PM FLORIDA KEYS REFUGES P.2/3 Afw%P•.-jJolt 11.S. FISII AN1) W'IL1)LIFE SERVI(.'E �81 #(fvIF.RF:f► By INCIDENT REPORT tce.Zs- o- ty-t .. ,&,r STATION CLASSIFIt.%TION OF INCIDENT FILE NI HRER I. Keys NWRs ABANDONED PROPERTY - Derelict ey West NWR vessel 114t LV4.PTION OF I-%CIDENF DATE OF INCIVJ-.NT TIME INt-ID!\TOCCI -RRED oca Grande XXXX XXXX •m ih J•. ,rrr pm REPORTED 'TO FTS BY ADDRESS PHONE HOW REPORTED ILMERS, T . USFWS •'�"• 872-2239 Neufu ❑ 4L i_uNTet.T Cl RECEIVED BY WHEN RECEIVED REPORT MADE BY DATE TIME DATE TtftE CERA, D.L. VECERA, D.L. 4-30-95 2:00 •'" 04-28-95 n/t PERSONS INVOLVED ADDRESS PHONE DOB INVOLVEMENT t t DETAILS OF INCIDENT/REMARKS (SEE ATTACHED NARRATIVE SHEET) lZ-petuy quenit, •ne e•itatel" ruwe of Irrepretr ta•at.ra tot tartaeut► DISPOSITION I REFERRED TO ORGkNIZATION A►u [• to urnr.E MAY 01 '95 03:32PM FLORIDA KEYS REFUGES P.3/3 U.S. FISH & WILDLIFE SERVICE INCIDENT REPORT (ATTACM4ENT) REFUGE GROUP: Florida Keys Refugee REFUGE: Key Went NWR CASE INCIDENT REPORT NUMBER: FKR 95-00-11 NATURE OF INCIDENT: ABANDONED PROPERTY - Derelict vessel NARRATIVE: On 04-28-95 Refuge Biologist Wilmers advised me he had found a derelict vessel on Boca Grande Key. I contacted Kim Blanco of the Florida Derelict Vessel program and received instructions for procedures to follow to have removal of the vessel expedited as an emergency. It was deemed an emergency because Wilmers had a concern that the vessel could interrupt nesting sea turtles from their normal nesting behavior. On 04-29-95 at 1:10 pm I arrived at Boca Grande and processed the derelict vessel for investigation and removal. The vessel was t issued the removal number: DV 09 1891, which I painted on its aides and top. The vessel registration numbers were difficult to decipher as they were partially peeled and there appeared to be several numbers on top of each other. However, I was able to trace one number which appeared to be of a consistent type: FL 6690 CE. On 04-30-95 at 1:50 pm I checked the number through the Monroe i County Sheriff's Office Dispatch. Registration# FL 6690 CE came back as "No Record Found". On 05-01-95 I submitted my data to Blanco and she made arrangements to have the vessel removed immediately. `)-/ FLORIDA KEYS REFUGES FKR 95-00-11 Page 2 of 2 DERELICT VESSEL REMOVAL CONTRACT SPECIFICATIONS FOR MONROE COUNTY, FLORIDA 1. INTENT: It is intended that these specifications shall cover all aspects of the work. The purpose of this section is to provide specific coverage for conditions applicable to this contract, where such coverage is not provided for in other portions of the contract documents. 2. BID FORMAT: THE BID MUST BE SUBMITTED ON THE BID RESPONSE FORM ENCLOSED IN THIS PACKAGE. A dollar amount per foot must be submitted for the removal of all derelict vessels on the primary list for which a Florida Marine Patrol Derelict Vessel Report is provided. Any deviation from this format will result in an unaccepted bid. A contract will not be granted on the basis of combined, related, linked, or discounted bids. Not applicable due to emergency removal of one or more derelict vessels for less than $25,000 total. 3. PLANS: There are no plans for this project, but copies of the Florida Marine Patrol Derelict Vessel Report with location Sketches have been bound into these documents for the Contractor's use. The Specifications include a section on instructions to bidders, both general and specific, and a copy of each Derelict Vessel Report from the Florida Marine Patrol. Only those derelict vessels for which a report is included and listed on the Bid Response Form are to be bid upon and subsequently removed. The County reserves the right to remove any or all vessels from this contract at any time prior to actual removal from the water and disposition by the Contractor. The County has a limited amount of money to effect the removal of these abandoned vessels. We have established priorities based on public safety, navigation and traffic hazard, and environmental considerations. If bids exceed the County's resources for removal based on these considerations, we shall limit vessel removal based on the these considerations and cost effectiveness. 4. VESSEL IDENTIFICATION AND LOCATION: Each of the vessels have been given a derelict vessel identification number, which is shown with the location in the Florida Marine Patrol Derelict Vessel Report, included herewith. Each bidder is responsible for his own identification of each derelict vessel as to location, description and condition. If a Derelict Vessel cannot be (1) located, (2) removed, (3) verified and (4) disposed of, as specified in these procedures, then no payment will be made forthcoming to the Contractor for that vessel. Those four conditions must be met on each derelict vessel along with compliance with all laws and permits for payment to be made. It is .understood that the Contractor has, by personal examination and inquiry, if necessary, satisfied himself as to the local conditions of each derelict vessel and as to the meaning, requirements and reservations of the specifications; for after contract letting, no deviation will be allowed. In case errors are discovered, they are to be reported by the Contractor to the County. The County assumes no responsibility should there be any discrepancies in what is stated in these documents and what the bidder evaluates. A contractor should take special care to remove only those derelict vessel's on his contract and for which he possesses a Florida Marine Patrol Derelict Vessel Report. Other derelict vessel's in the area but not under contract, cannot be molested. It may be possible to replace a derelict vessel of like kind, for the same or less money, when mutual agreement can be reached by the Florida Department of Environmental Protection, Monroe County Administrator of the Derelict Vessel Program, and the Contractor. This will be applicable when a contracted derelict vessel can not be located. No derelict vessel may be replaced and removed without the tri party consent noted in this paragraph. A contractor may suggest a possible replacement vessel but he may not remove it without the appropriate consent above. 5. SCOPE OF WORK: The Contractor shall be responsible for providing all permits, supervision, labor, equipment, tools, fees and taxes required to complete this project to the satisfaction of the County. The Contractor's procedure and methods of removal may be of his own selection provided they secure results which satisfy the requirements of the Specifications and any necessary environmental permits. DV Specs --Page 2 Any vessel which is removed and disposed of shall be removed from its present site in such a manner as to do the least possible damage to the natural environment surrounding the vessel. All debris from the vessel shall be removed and the site left in a reasonably clean condition. No oil or fuel shall be permitted to be dumped or spilled into or unto the water or land. All pollutants shall be removed from the derelict vessel prior to removal from the water. The Contractor shall be responsible for making any and all arrangements for access to the vessel to be removed. If private property has to be traversed, then written permission of the owner is necessary. In removing a derelict vessel that may lie on or near grass or sponge flats extreme caution must be used to do the least possible damage. Prior to delivery of derelict vessels to the disposal site, the Contractor must remove all oil, gas and metal (including engines). He must dispose of them in any legal manner. Pure used oil will be taken by Monroe County for disposal. Mixture of oil, gas, seawater or any combination of the three must be transported from the County by an approved hazardous waste handler. The names of those firms will be supplied by the Monroe County Environmental Management Department. Metal becomes the property of the Contractor. In those cases where a derelict vessel number can not be found, i.e. derelict vessel is underwater, the contractor shall provide marine transportation to the site for the County representative to verify the vessel and location using the original Derelict Vessel Report from the Florida Marine Patrol. 6. MATERIALS AND WORKMANSHIP: The Contractor shall provide the necessary materials and equipment to safely complete the job. The Contractor agrees that all work shall be performed by competent employees who are experienced and qualified to do the work specified, and that all work will be performed in accordance with the best commercial practices. A list of equipment to be used and a description of the removal and transporting procedures to be followed must be provided to the County at the Pre -Work Conference described below. Precaution shall be exercised at all times for the protection of persons and property. The safety provisions of the Occupational Safety and Health Act of 1970 (Public Law 91-596) and other applicable laws, including building and construction codes shall be observed. Machinery, equipment and other hazards shall be guarded in accordance DV Specs --Page 3 with safety provisions of the "Manual of Accident Prevention in Construction", published by the Associated General Contractors of America, to the extent that such provisions are not in contradiction of applicable law. The Contractor shall store materials and shall maintain partly or wholly finished work during the continuance of the Contract and until the final acceptance. If any materials or part of the work become lost, damaged, or destroyed by any cause or means whatsoever, the Contractor shall repair and replace or not receive payment for the unaccomplished work. The Contractor shall maintain suitable and sufficient guards and barriers, and at night, suitable and sufficient light or other appropriate security or protection for the prevention of accidents. Use of explosives is discouraged in carrying out the project. No blasting with explosives shall be done except under prior approval by the County and as permitted by all relevant governmental agencies such as the Department of Environmental Protection, Department of Environmental Regulation, U.S.Army Corps of Engineers, U.S. Fish and Wildlife Service and the U.S. Coast Guard. When the use of explosives is approved the Contractor shall use the utmost care so as not to endanger life or property and whenever directed the number and sizes of the charges shall be reduced. All explosives shall be marked clearly "DANGER EXPLOSIVES", and shall be in the complete care of competent watchmen. The Contractor shall secure the proper competent watchmen. The Contractor shall assume all responsibility for damages caused by explosives. 7. ASSIGNMENT OF CONTRACT AND SUBCONTRACTS: It is expressly understood that the Contractor is in all respects an independent Contractor for this work, not withstanding under certain conditions he is bound to follow the directions of the County, and is in no respect an agent, servant, or employee of the County. Neither the Contract, nor any part thereof, nor any monies due or to become due thereunder, may be assigned by the Contractor without the prior written approval of the County. The Contractor is fully responsible to the County for the acts and omissions of his subcontractors and of persons either directly or indirectly employed by said subcontractor, as he is for the acts and omissions of persons directly employed by him. Nothing contained in the Contract Documents shall create a contractual relation between any subcontractor and the County. All subcontractors shall abide by the terms, DV Specs --Page 4 conditions, and requirements of this Contract. It is the responsibility of the Contractor to pay all debt obligations incurred with subcontractors in an expedient manner. 8. LEGAL RESTRICTIONS, PERMITS AND TRAFFIC PROVISIONS: The Contractor shall comply with all applicable local, State and Federal requirements pertaining to the terms of this Contract. The Contractor will be responsible for obtaining, at his own expense, any licenses or permits that may be required and should inquire about permit requirements with the appropriate agencies. The Contractor shall comply with all the requirements of the Federal Pollution Control Act. The Contractor shall conduct his operations so that he shall not close any thoroughfare nor interfere in any way with traffic on highways, or on water, without the written consent of the proper authorities. Work shall be done at any time that shall not interrupt or disturb members of the public. Off-loading sites (water to land for transport to the landfill or other disposal site by vehicle) must have written approval of the land owner. The Florida Marine Patrol should be contacted to initiate eviction proceedings for contracted derelict vessels which are inhabited at the time of removal and when another vessel is too close to the contracted derelict vessel to allow safe operations. Direct confrontations with other boaters should be avoided and the Florida Marine Patrol should be contacted immediately if such confrontations may result from removal of any contracted derelict vessels. 9. INSURANCE: The Contractor must obtain all insurance required by the County and submit proof of same to the county prior to acceptance of bid and contract approval by Board of County Commissioners but no later than five working days after notice of low bidder. All insurance shall be maintained until work has been completed and accepted by the County. The Contractor shall furnish the following certificates of insurance for review by the County's Risk Management Division: Certificate(s) of Insurance which clearly indicates that he has obtained the insurance coverage required in paragraphs a,b,c and d below. DV Specs --Page 5 The Contractor hereby certifies that'no modification or change in insurance shall be made without (3) days written advance notice to Monroe County, c/o the director of the Risk Management Division. a. Worker's Compensation Insurance per F1. Statutes. b. General Liability Insurance on a comprehensive basis, in an amount not less than $300,00.00 per occurrence for Bodily Injury and Property Damage combined, to include contractual liability. C. Pollution Liability Insurance in the Amount of$500,000. d. Water Craft Liability Insurance in the amount of $500,000. e. Automobile liability insurance covering all owned, non -owned and hired vehicles used in connection with the work, in an amount not less than $100,000 per occurrence for Bodily Injury and Property and Damage combined. All insurance policies required above shall be issued by companies authorized to do business and under the laws of the State of Florida. The Monroe County Board of County Commissioners must listed as "Additional Insured" on all policies, except for Worker's Compensation. 10. COMMENCEMENT.DELAYS AND COMPLETION OF WORK: After receiving Board of County Commission approval of the Contract, and after reconciliation of any details or conditions which may directly or indirectly interfere or conflict with work of the Contract, the County will issue a "Notice to Proceed" officially authorizing the Contractor to commence. The Contractor shall commence work on said date. If the Contractor should be delayed in the progress of the work included in the Contract by unforeseeable causes beyond his control, the time for the completion of the work may be extended upon agreement of the County representative. Requests for extension of time must be submitted in writing to the County representative. Extensions of time cannot legally be approved unless the written request is submitted in the time to permit it to be acted upon before the Contract expiration date. To allow sufficient time for the administrative procedures required to obtain.action by the County Commission, a request for time extension must be. received by the County representative at least sixty (60) calendar daysprior to the Contract expiration date. . . Provided further that the Contractor shall within ten (10) DV Specs --Page 6 from the beginning of such delay notify the County, in writing, of the causes of the delay. The County representative will ascertain the facts and the extent of the delay and notify the Contractor within a reasonable time of her decision in the matter. If the Contractor fails to complete the work within the time limit, and if the County should nevertheless permit the Contractor to continue and complete the same without official extension of time in writing, such permission shall not modify nor waive any liability of the Contractor for damages arising from non -completion of work within the time limit, but such liabilities shall be subject to continuation in full force against the contractor. 11. CHANGES AND INSPECTION: The vessels herein considered are to be removed for the County by the Contractor in accordance with the Specifications. The County may give instructions or directions to supplement the Specifications. These shall be binding upon the Contractor and upon all his subcontractors, employees and agents of every kind. All work and every process and operation shall be subject to inspection at all times, and the County and their representatives shall have free access to all aspects of the work. The Contractor shall remove and make good, as may be directed, without charge, any defective work. Oversight or error of judgement of inspectors, or previous acceptance, shall not relieve the Contractor from the obligation to make good any defect whenever discovered. The right is reserved to change the Specifications consistent with regard to the general intention of the Contract for any part of the work or materials, either before or after work has begun. Notice of such changes shall be given in writing to the Contractor; such changes are not to be grounds for any claim by the Contractor for damages, nor for the forfeiture of the Contract. It is possible that a Derelict Vessel could disappear between the time of inspection by the contractor and the actual effort to remove it. No payment will be forthcoming in the case. Except when otherwise specified, the expense of all tests requested by the County will be borne by the County. 12. AUDIT RIGHTS: As a provision of the grant from the State of Florida to the County, and if so requested by the State, the successful bidder agrees to provide access to all records and allow the audit of any books, documents and, papers related to this project for a period of up to one yearand during and after termination of the contract. DV Specs --Page 7 13. CONTRACT AWARD: The County reserves the right to evaluate the submitted bids to award a contract to the bidders submitting the lowest per foot bid for the derelict vessels listed in the bid package as one project and for which a Florida Marine Patrol Derelict Vessel Report is included. One bid will be accepted and a contract issued for the total removal of all listed derelict vessels as one project, up to the limit of available funds. The actual number of vessels to be removed will depend on the accepted per foot bid price and the available funds. 14. PRE -WORK CONFERENCE: A meeting will be necessary involving a representative of the County, the Contractor and other parties with direct involvement prior to the signing of the contract. The time and place of this conference will be set by the County representative. At this time the Contractor shall provide the County with a schedule as to the order in which he proposes to remove the vessels awarded to him. 15. CONTRACT SECURITY: The contractoris expected to act and deliver in good faith all work, at the agreed price, in the allowed time. Failure to do so, could jeopardize the contractor's reputation with the County and potentially influence any future contracts with Monroe County. 16. EXECUTION OF CONTRACT DOCUMENTS: Due to the time frame involved with this project, the Contractor upon notification that he is to be awarded the contract documents for execution, shall return said documents properly executed along with insurance within TEN WORKING DAYS. With the Contractor's cooperation, if this period can be reduced, it will assist in acceleration the execution of the contract documents. The Contractor, by virtue of signing the Contract, acknowledges that he and all his subcontractors have satisfied themselves as to the nature and location of the work, the general and local conditions, including, but not restricted to, those bearing upon transportation, handling, access to the pick-up and disposal sites; and the character of equipment and facilities needed to perform the work. Failure on the part of the Contractor to completely or properly evaluate any factors of his costs prior to bidding shall not form a basis for additional compensation if he is awarded the contract. If for any reasons, not acceptable to the County, the Contractor does not perform, the County shall have the DV Specs --Page 8 right to levy liquidated damages against the Contractor. Liquidated damages in the amount of $100 per day shall be assessed against the Contractor for any bid item awarded to him which is not completed and accepted by the County within the number of calendar days specified in the Contract. Liquidated damages are accumulative. 17. NOTICE TO PROCEED: The Contractor shall commence work upon this project on the effective date of the Notice to Proceed and perform in a continuous manner until completion and acceptance by the County. For Contracts wherein a specified number of days for completion is stated in the Contract, the effective date of the "Notice to Proceed with Contract Work" will establish the "beginning date" of the project. 18. TERMINATION OF CONTRACT: This Contract may be terminated by the County, giving up to ten (10) days written notice to the Contractor; said notice shall be sufficient if delivered to the party personally or mailed by certified mail to his mailing address as specified on the accepted Bid. 19. FINAL CLEAN-UP: Upon completion of the work specified herein and before acceptance and final payment shall be made, the Contractor shall remove from the sites all machinery, equipment, surplus and discarded materials and temporary structures. All disposal of materials, rubbish and debris shall be made at a legal disposal site. 20. DISPOSAL SITES AND FEES: Contractor is responsible for disposal of all derelict vessels included in this contract and must make arrangements for legal disposal. It is the responsibility of the Contractor to pay all disposal fees incurred, and such removal related costs should be considered when bidding on this contract. The contractor will deliver the derelict vessel to the disposal site, where staff must be able to verify the derelict by its Florida Marine Patrol derelict vessel number or by some other means. It is the intent of this contract to remove derelict vessels from their present sites a legally dispose of them. Upon receipt of vessels at the landfill. They must be disposed of immediately. A legal disposal site is either the Long Key Landfill -Monroe County, MM 68 1/2, Long Key, Florida 33001, 305-664-9315, other landfills in neighboring countries or any other location for disposal as long as the FDEP Disposition Certification Form (attached) is fully documented. If a signature cannot be obtained on Florida DV Specs --Page 9 Department of Environmental Protection Disposition Certification, the Contractor must contact County Representative for written approval and instructions. 21. PROOF OF PROPER DISPOSAL AND NOTIFICATION TO MARINE PATROL: Contractor must submit prior to receiving any payment: A receipt for each vessel including the date of disposal, the Florida Marine Patrol Derelict Vessel Number, disposal site location, and the telephone number, title and signature of person at disposal site verifying delivery of said derelict vessel. A County Disposition Affidavit is to also required to be signed by the Contractor. If vessel is not identifiable and/or if the derelict vessel number is not visible. Recipient of debris should provide detailed receipt showing type and description of debris received. if person delivering vessel to disposal site is other than contractor a written statement with a description of what type of debris was transported, dates, times, name, address, and phone number of site. In addition to the above information, Contractor must submit three pictures of each vessel removed. The first photograph must be of the vessel at the current location prior to removal, the second photograph must be of the vessel after removal but in the same general area preferably while in tow, and the third photograph must be of the vessel at the disposal site with sufficient background to depict of disposal (i.e., building or sign identifying disposal site). The derelict vessel number, when present, must appear in all photographs. The Contractor will be responsible for the camera, film, and development costs. The photographs should be taken with a Polaroid camera that provides instant photos since this minimizes loss of documentation due to camera malfunction or loss overboard. This camera and film must be provided by the Contractor. The photos must be submitted on a vessel by vessel basis according to removal schedule. Without photos to document the removal and disposal of the contracted vessels final payment can not be assured. The Contractor must notify the Florida Marine Patrol and the County Representative in writing as to the work schedule of removal. This should be done after the pre -work conference with the County representative. Notification is to be made before doing any work on each vessel. This multiparty communication for each Derelict Vessel is a requirement of the contract. 22. PAYMENT: All payments for the removal and disposal of each vessel, shall be for the performance of the work as DV Specs --Page 10 A stipulated in these specifications and associated contractual documents. The unit rate of bid shall be totally inclusive for all phases of the operation. Contractor may request two partial payments by submitting an invoice for the number of vessels removed up to the date of the invoice, providing the Contract agreement does not explicitly prohibit partial payments. Photographs, disposal receipts, signed FDEP Disposition Certification form for the vessels for which payment is being requested. The contractor understands and agrees that no payment will be forthcoming for the removal and disposal of any derelict vessel (1) not listed on this contract nor (2) for any derelict vessel on this Contract for which a written certification verifying the removal of the subject vessel has not been obtained from the Florida Marine Patrol and a Representative of the disposal site at the time of delivery. In addition, property, public or private, if damaged during the work or removed for the convenience of the work, shall be replaced at the expense of the Contractor in a manner acceptable to the County and the Owner, prior to the final payment for contracted work. 23. PUBLIC ENTITY CRIMES: Upon entering into the contract, the Contractor agrees to sign and endorse the Public Entity Crimes form (attached). 24. NON -COLLISION AFFIDAVIT: Upon entering into the contract, the Contractor agrees to sign and endorse the Non -Collusion Affidavit form (attached). 25. ETHICS CLAUSE: Upon entering into the contract, the Contractor agrees to sign and endorse the Ethics Clause form (attached). 26. DRUG FREE WORK PLACE FORM: Upon entering the contract, the Contractor agrees to sign and endorse the Drug Free Work Place form (attached). 27. DERELICT VESSELS AT ISSUE: The derelict vessels listed on the Derelict Vessel Bid Response Form shall be removed and disposed of by the Contractor in accordance with the provisions of these Specifications. H:\A\BIF\-DV\DV-1993\SPECS.NEW DV Specs --page 11 SWORN STATEMENT PURSUANT TO SECTION 287.133(3)(a), FLQ11_10A-STATUTES, ON PUBLIC ENTITY CRIMES THIS FORM MUST BE SIGNED AND SWORN TO IN THE PRESENCE OF A NOTARY PUBLIC OR OTHER OFFICIAL AUTHORIZED TO ADMINISTER OATHS. f 1. This sworn statement is submitted to ���' /o-,/�oE— �nU .✓r / --� [print name of the public entity] `�.✓� .r by [print individual's name and title] for [ rint name of entity submitting sworn statement] whose business address is and (if applicable) its Federal Employer Identification Number (FEIN) is (If the entity has no FEIN, include the Social Security Number of the individual signing this sworn statement: 2. I understand that a "public entity crime" as defined in Paragraph 287.133(lxg), Florida Statutes, means a violation of any state or federal law by a person with respect to and directly related to the transaction of business with any public entity or with an agency or political subdivision of any other state or of the United States, including, but not limited to, any bid or contract for goods er services to be provided to any public entity or an agency or political subdivision of any other state or of the United States and involving antitrust, fraud,.theft, bribery, collusion, racketeering, conspiracy, or material misrepresentation. 3. I understand that"convicted" or "conviction" as defined in Paragraph 287.133(l)(b), Florida Statutes, means a finding of guilt or a conviction of a public entity crime, with yr without an adjudication. -of guilt, in any federal or state trial court of record relating to charges brought by indictment or information. after July 1,1989, as a result of a jury verdict, nonjury trial, or entry of a plea of guilty or nolo contendere. 4. I understand that an "affiliate" as defined in Paragraph 287.133(l)(9), Florida Statutes, means: 1. A predecessor or successor of a person convicted of a public entity crime; or 2. An entity under the control of any natural person who is active in the management of the entity and who has been convicted of a public entity crime. The term "affiliate" includes those officers, directors, executives, partners, shareholders, employees, members, and agents who are active in the management of an affiliate. The ownership by one person of shares constituting a controlling interest in another person, or pooling of equipment or income among persons when not for fair market value under an arm's length agreement, shall be a prima facie case that one person controls another person. A person who knowingly enters into a joint venture with a person who has been convicted of a public entity crime in Florida during the preceding 36 months shall be considered an affiliate. 5. I understand that a "person" as defined in Paragraph 287.133(l)(e), Florida Statutes, means any natural person or entity organized under the laws of any state or of the United Slates with the legal power to enter into a binding contract and which bids or applies to bid on contracts for the provision of goods or services let by a public entity, or which otherwise transacts or applies to transact business with it public entity. The term "person" includes those officers, directors, executives, partners, shareholders, employees, members, and agents who are active in management of an entity. Based on information and belief, the statement which 1 have marked below is true in relation to the entity submitti this sworn statement. 1Indicate which staternenl applies.1 ZNeither the entity submitting this sworn statement, nor any of its officers, directors, executives, partners, shareholders, employees, members, or agents who are active in the management of the entity, nor any affiliate of the entity has been charged with and convicted of a public entity crime subsequent to July 1, 1989. The entity submitting this sworn statement, nor any of its officers, directors, exectutives, partners, shareholders, employees, members, or agents who are active in the management of the entity, nor an affiliate of the entity has been charged with and convicted of a public entity crime subsequent to July 1, 1989. The entity submitting this sworn statement, or one or more of its officers, directors, executives, partners, shareholders, employees, members, or agents who are active in the management of the entity, or an affiliate of the entity has been charged with and convicted of a public entity crime subsequent to July 1, 1989. However, there has been a subsequent proceeding before a Hearing Officer of the State of Florida, Division of Administrative Hearings and the Final Order entered by the Hearing Officer determined that it was not in the public interest to place the entity submitting this sworn statement on the convicted vendor list. [attach a copy of the final order] I UNDERSTAND THAT THE SUBMISSION OF THIS FORM TO THE CONTRACTING OFFICER FORTHE PUBLIC ENTITY IDENTIFIED ON PARAGRAPH 1(ONE) ABOVE IS FOR THAT PUBLIC ENTITY ONLY AND, THAT THIS FORM IS VALID THROUGH DECEMBER 31 OF THE CALENDAR YEAR IN WHICH IT IS FILED. I ALSO UNDERSTAND THAT I AM REQUIRED TO INFORM THE PUBLIC ENTITY PRIOR TO ENTERING INTO A CONTRACT IN EXCESS OF THE THRESHOLD AMOUNT PROVIDED IN SECTION 287.017, FLORIDA STATUTES FOR CATEGORY TWO OF ANY CHANGE IN THE INFORMATION CONTAINED IN THIS FORM. [signature] Sworn to and subscribed before me this day of ' 19 Personally known , ..._ OR Produced identification (Type of identification) COMW"M d CG3M EXPIRES 11"WA-;(GV Mfth u 24, 1999 TROY FAIN INSURANCE, INC. Notary Public - State of��� My Commission expires (Printed typed or stamped commissioned name of notary public) Form PUR 7068 (Rev. 06/11/92) SWORN STATEMENT UNDER ORDINANCE NO. 10-1990 MONROE COUNTY, FLORIDA ETHICS CLAUSE l warrants that he/it has not employed, retained or otherwise had act on his/its behalf any former County officer or employee in violation of Section 2 of Ordinance No. 10-1990 or any County officer or employee in violation of Section 3 of Ordinance No. 10-1990. For breach or violation of this provision the County may, in its discretion, terminate this contract without liability and may also, in its discretion, deduct from the contract or purchase price, or otherwise recover, the full amount of any fee, commission, percentage, gift, or consideration paid to the former Cou y offi er o�i employee. (signatur ) -�- Date: 's- STATE OF COUNTY OF //lames Subscribed and sworn to (or affirmed) before me on —` % �S� ` (date) by (name of affiant). He/She is personally known to me or has produced (type of identification) I48Mh 24, 1999 NX BONDED THOU TROY FAIN INSURANCE, ;f .' as identification. NOTARY PUBLIC MCPH4 REV. 2/92 DRUG -FREE WORKPLACE FORM The undersigned vendor in accordance with Florida Statute 287.087 hereby certifies that: (NO -a- of Business) 1. Publish a statement notifying employees that the unlawful manufacture, distribution, dispensing, possession, or use of a controlled substance is prohibited in the workplace and specifying the actions that will be taken against employees for violations of such prohibition. 2. Inform employees abotit the dangers of drug abuse in the workplace, the business's policy of maintaining a drug -free workplace, any available drug counseling, rehabilitation, and employee assistance programs, and the penalties that may be imposed upon employees for drug abuse violations. 3. Give each employee engaged in providing the commodities or contractual services that are under bid a copy of the statement specified in subsection (1). 4. In the statement specified in subsection (1), notify the employees that, as a condition of working on the commodities or contractual services that are under bid, the employee will abide by the terms of the statement and will notify the employer of any conviction of, or plea of guilty or nolo contendere to, any violation of Chapter 893 (Florida Statutes) or of any controlled substance law of the United States or any state, for a violation occuring in the workplace no later than five (5) days after such conviction. 5. Impose a sanction on, or require the satisfactory participation in a drug abuse assistance or rehabilitation program if such is available in the employee's community, or any employee who is so convicted. 6. Make a good faitli effort to continue to maintain a drug -free workplace through implementation of this section. As the person authorized to sign this firm complies fully with the MCP#5 REV. 6/91 the statement, I certiW, that above requirement 7 Bidders Signature Date of NON -COLLUSION AFFIDAVIT Go c, W// of the -;ity - according to law on my oath, and under penalty of perjury, depose and say that; 1) I am ,, :'-�/ the bidder making the Propos 1 for the project described as follows: 2) the prices in this bid have been arrived at independently without collusion, consultation, communication or agreement for the purpose of restricting competition, as to any matter relating to such prices with any other bidder or with any competitor; 3) unless otherwise required by law, the prices which have been quoted in this bid have not been knowingly disclosed by the bidder and will not knowingly be disclosed by the bidder prior to bid opening, directly or indirectly, to any other bidder or to any competitor; and 4) no attempt has been made or will be made by the bidder to induce any other person, partnership or corporation to submit, or not to submit, a bid for the purpose of restricting competition; 5) the statements contained in this affidavit are true and correct, and made with full knowledge that Monroe County relies upon the truth of the statements contained in this affidavit in awarding contracts for said project. (Signature of idder) STATE OF COUNTY OF DATE �/ //O �/%3�E^` PERSONALLY APPEARED BEFORE ME, t undersigned authority, wi ho, after first being sworn by me, (nam of individual signing) affixed his/her signature in the space provided above on this day of r op19 jc-----_ NOTARY PUBLIC My commission expires: Z'V,'r�' tEs GLORIA IC BLANCO *=My COMMISSION March 24C 1C ggg EWES �. h ;k iiucD TNRU TROY FAIN #M&ANM W Ar //Gil. E ,FC,aA; l PRODUCER Alan R. Mott Agency, Inc. 184 East Main Street PO Box 995 Huntington, NY 11743 INSURED Spirit Marine Towing & Assist. d/b/a Sea Tow Florida Keys 911 West Indies Drive Ramrod Keys, FL 33043 " DATE (11MIDWYI� VC `� 11/29/94 r THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. COMPANIES AFFORDING COVERAGE COMPANY ASK�4ANi1 Insurance Co. of America BY. DATE 1 �C /.1 WAIVER: N/IA _-�Ii----YES GOV ERAGtS-�{+ THAT THE POLICIES OF INSURANCE -LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD WHICH THIS INDICATED, IS TO CERTIFY NOTWITHSTANDING REQUIREMENT,CONDITION AF AFFORDED OFCONTRACT THE POLICIES DOCUMENT OR OTHER DESCRIBED RESPECT TO IS SUBJECT TO ALL THETERMS, CERTIFICATE MBESED OR MAY PERTAIN. INSURANCE POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. EXCLUSIONS AND CONDITIONS OF SUCH • POLICY EFFECTIVE POLICY EXPIRATION LIMITS TYPE OF INSURANCE POLICY NUMBER DATE (MMIDDJYY) DATE (MMIDDIM L0 GENERAL AGGREGATE f GENERAL LIABILITY PRODUCTS-COMP/OP AGG $ COMMERCIAL GENERAL LIABILITY � OCCUR PERSONAL d ADV INJURY f EACH OCCURRENCE f CLAIMS MADE OWNERS d CONT PROT FIRE DAMAGE (Any one fire) f MED EXP (Any one person) f COMBINED SINGLE LIMIT f AUTOMOBY..E LIABILITY ANY AUTO ALL OWNED MHOS BODILY INJURY (Per person) f SCHEDULED AUTOS HIRED AUTOS BODILY INJURY (Per acdcleM) f NON OWNED AUTOS i PROPERTY DAMAGE S ece_v � AUTO ONLY - EA ACCIDENT f GARAGE LIABILITY OTHER THAN AUTO ONLY: emu.. ANY Auto Risk Mgmt. & Control EACH ACCIDENT f DATE AGGREGATE f INITIAL EACH OCCURRENCE f EXCESS IJABRM AGGREGATE f i UMBRELLA FORM OTHER THAN UMBRELLA FORM STATUTORY LIMITS ';, r�S WOWMM CO PENSATION AND EMPLOYERS LIABILITY EACH ACCIDENT f -POLIC DISEASE Y LIMIT f _ THE PROPRIETOR! III PARTNERS/EXECUTIVE DISEASE - EACH EMPLOYEE f OFMERS ARE: EXCL OTHER Protection & Indemnity ROYALAP789 11/10/94 11/10/951 $500,00.0. DESCRIPTION OF OPERATIONSILOCA ITEMS '75 Spacecraft 25' #SPA02753M75L 174 Thunderbird 24' #TNR23086M75C 180 Spirit 34' DOC# 639586 Monroe County Board of County Commissioners Attn: Kim Blanco 5100 College Road Key West, FL 33040 ACORD 25-S (3193) y. ACELLATION as ..r - _T SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, THE ISSUING COMPANY WILL ENDEAVOR TO MAIL 30 DAYS WRITTEN NOTICE TO THE CERTIFICATE HOLDER NAMED TO THE LEFT, BUT FAILUR O MAIL SUCH NOTICE SHAL IMPOSE NO OBLIGATION OR LIABILITY OF 6�0* THE Ap Y, S AGEN4 OR REPRESENTATIVES. ® ACORD'CORPORATION 1993 JCIYI D1•nMua/rVrtCnNIYU,IIVJ ,IL' 0-01 , I.37 , OIJ0107077" JU7LyL4411,8 I PERIOD THIS IS TO OERTIFY THAT THE POLICIES OF lVSIARANCE VOTED BELOW HAVE BEEN ISWW TO THS INSURED NAMED ABOVE FOR THE POVCY lrotwo. NOTYfiTN ffANDm ANY REOUIREMENT, TERM OR OONDMONOF ANY CONTRACT OR OTHGR DOCUMENT WITH RESPECT TO WHICH THIS 6ERTIFIG►TE MAY BE IOOUED OR MAY PERTAIN, THE IVSUR/WCi AFFORDED ByTHE POLICIES DESCRIBED HEREIN 4SUBJECT TO ALL THE TERMS, EXCLUSI" AND CONDITIONS OF SUCH POLE LIMITS SHOWN MAY HAVE BEEN REDUCED SY PMD_CLUMB. ...........___._............................................ .............. .......... _....._...................................................._....... ................... . POLICY IMSCf1Y! 'FOLIC[ @BIATIOx' LBARB 0 - PORJCT N{IM� OAT! OrtM aoM i OATS PI'YI M� PU76967 3 24 95 3 24 96 *��ATt ..............:>t300,� Q00 ................... :...X CoRrm1CIAL gowimL wou " ' PROOIICTBCOMNO► Af0 B NWADN& A ADY. NJURY l CLAMS IAAD[ oomm _ ..._........ . ..... woHOccum"Di a B3001000..... oY "w* a CONTPACTOR's PROT. ............................ I" OAM&M Vw wo •mot s :........: ........ _.. ........ ................ mm Room (xv am en.oiu >f AA..... o." LIASIJTY APPROVED BY RISK MANAGEMENt +® �0� oumrr ;ANY AUTO ................ ......._....._..-......... _ ......_................... `Au oY++Mo AUTO* ;.....-...: BY DOOLY INJURY vw,or ..... - ............ IAU0 ........ AITOB DATE ....... .......... _ ............._... ...... _Y mooLY NQURs .........SHOlHAm HON4"Ill) Auros , _ .......... ................... . .`OARASELIABILITY I,-- w AVER: N/A./ YES MpEmrDAMAGE .9 BACH OOCURRENCi i Glom LMBRITY - ...... AeORCOATE B NM A FORM ;< ' OTHBA THAN UMBROAA DORM STATUTORY L*AITs GOIIrBII BAUM Acomff l .......................... AND DIlAOI-pouGN tYR.................. ArrLDYEnB• LIA UIT plsiASFrEAR1 600YC! : s oceawrnm OP OPHIA if� COMPANY A IS SPHERE DRAM INSURANCE CO MONROE COUNTY BOARD OF COUNTY COMMISSIONERS IS ADDITIONAL INSURED BUT ONLY AS RESPECTS OPERATIONS PERFORMED BY THE NAMED INSURED — .-• - SHmn ANY of THE ABOVE DEBCRmD POucm BIE cANcreL BEFORE THE E)MIRATAON DATE THEREOF. THE I8IR)M COMPANY WILL ENDEAVOR TO MONROE COUNTY BOARD OF COUNTY : MAIL 3 0 DAYS Wnrn :N NOTICE TO THE CERTIFICATE HOLDER NAMED TO THG COMMISSIONERS KIM BLANCO LEFT. SITT FAIVIRE TO MAIL SUCH NOTICE BHAIl IMPOBE NO Ol""TbN OR 5100 COLLEGE ROAD LIAIRM OF ANY xm UPON THE COMPANY, ITS AOEM OR MO EOONTA"4M KEY WEST FL 33040 77;FOREJR DD (B )