Install 12 Channel Markers Windley Keyf I �
CONTRACT AGREEMENT
AGREEMENT, MADE THIS _day of ` 1997, by and
between, Spirit Marine Towing & Assistance ( "Contractor") , and the
BOARD OF COUNTY COMMISSIONERS OF MONROE COUNTY, FLORIDA, of the
County of Monroe, State of Florida ("Board").
The Contractor and the Board, for the consideration named,
agree as follows:
1. The Contractor shall furnish all the materials
for the installation of twelve channel markers in Windley Key
and the removal of approximately twenty six unofficial markers in
the same general area. A list of aids to be installed is attached
as Exhibit A.
2. The work performed under the Contract shall commence
immediately from the date the Liaison provides the Notice to
Proceed and shall be completed by June 30, 1997.
3. The work performed under the Contract is contingent upon
grant funding from the Florida Department of Environmental
Protection Boating Improvement Fund. If grant funding is
denied, then no compensation is due under this Contract. The
Contractor acknowledges the contingent nature of the State
Funding and agrees that, if the grant is denied, the Contractor
may not make a claim for compensation under this agreement or by
way of estoppel, detrimental reliance or otherwise. The
Contractor understands the rules of the Department of
Environmental Protection and shall comply with said rules, along
with the rules and procedures instituted by the Board to ensure
an orderly progress to the project. Both the intent and the
t
requirements of the Specifications are understood by the~f ..T
Contractor.
J
W,
4. The Board shall pay the Contractor the total sum of
$13,890.00 for the installation of twelve channel markers in
Windily Key and the removal of twenty six unofficial aids located
in the same general area. Payment shall be upon completion by
the Contractor and acceptance by the Board, subject to the terms
and conditions of the Specifications (attached as Exhibit B) and
this Contract.
5. The attached Specifications, together with this
Agreement, form the Contract. They are fully apart of this
Contract as if repeated herein verbatim.
6. The Contractor covenants and agrees to indemnify
and hold harmless Monroe County Board of County Commissioners
from any and all claims for bodily injury (including death),
personal injury, and property damage (including property owned
by Monroe County) and other losses, damages, and expenses
(including attorney's fees) which arise out of, in connection
with, or by reason of services provided by the Contractor or
any of its Subcontractor(s) in any tier, occasioned by the
negligence, errors, or other wrongful acts or omissions of the
Contractor or its subcontractor(s) in any tier, their employees
or agents. The purchase of the insurance required in
paragraph 12 does not vitiate this indemnification provision.
7. The Contractor acknowledges his/her intention to comply
with the need to coordinate all work with the appropriate
environmental agencies, the U.S. Coast Guard, and the County.
8. The Contractor agrees to supply the County with a
set of photographs of the repaired aid to navigation along with
a letter certifying completion of work.
Page 2
The Contractor will be responsible for the camera, film, and
development costs. The Contractor also agrees to provide
transportation for the Liaison to inspect completed project.
9. The Contractor understands and agrees that no payment
will be made for this project without required photographs
and written certification of completion.
10. Due to the use of heavy equipment and, at times,
dangerous work environment, the Contractor understands and
agrees to maintain an alcohol and drug free work environment.
11. The CONTRACTOR will be responsible for all necessary
insurance coverage as indicated by an "X" on the attached forms
identified as General Insurance Requirements and INSCKLST 1-4,
as further detailed on forms WC1, WCJA, GL1, & WL1 (attached
as Exhibit C). All policies must list Monroe County as
additional insured with the exception of the Workers Compensation
policy.
12. A person or affiliate who has been placed on the
convicted vendor list following a conviction for public entity
crime may not submit a bid on a contract to provide any goods
or -services to a public entity, may not submit a bid on a
contract with a public entity for the construction or repair
of a public building or public work, may not submit bids on
leases of real property to a public entity, may not be awarded
or perform work as a contractor, supplier, subcontractor, or
consultant under a contract with any public entity in excess
of the threshold amount provided in Section 287.017, for
CATEGORY TWO ($10,000.00) for a period of 36 months from the date
of being placed on the convicted vendor list.
Page 3
13. The Board may terminate this Agreement with
or without cause at any time upon giving the Contractor up to 10
days notice in writing. The Contractor, upon receipt of the
notice, shall immediately cease work. The Board must pay the
the Contractor the percentage of the contract price which is
proportional to the amount of work performed in a manner
satisfactory to the Board up to the date the contractor received
the notice of termination.
14. This contract is governed by the laws of the State of
Florida. Venue for any litigation arising under this contract
must be in Monroe County.
Page 4
IN WITNESS WHEREOF the parties hereto have executed this
agreement the day and year first written above.
BY:
TITLE:
(Seal)
Attest:
=4.
��
Witness
(Seal) i .
At t e s BEAU DANNY L KOUiAGE CLERK
UY
D1 rvc < IQ
Clerk
FIRM:
L
BOARD OF COUNTY COMMISSIONERS
OF MONROE C UN FLOR A
BY:
May a V14aK
Page 5
APPROV D AS To FO
AND AL SUFFICI
BY ON
z� 7
DATE
EXHIBIT A
Windley Key Channels
Description of Proposed Markers
. on Mounting
NIM Method Type of 3-Lqn Latitude Longitude
Long middle channel:
2
Piling
3'
triangular daymark - red
240
56.195
800
35.279
3
Piling
3'
square daymark - green
240
56.338.
800
35.351
4
Piling
3'
triangular daymark - red
240
56.410
800
35.407
6
Piling
3'
triangular daymark - red
240
56.509
800
35.436
7
Piling
3'
square daymark - green
240
56.619
800
35.506
8
Piling
3'
triangular daymark - red
240
56.714
800
35.537
9
Piling
3'
square daymark - green
240
56.828
800
35.597
10
Piling
3'
triangular daymark - red
240
56.832
800
35.589
Short side channel
to the west:
1
Piling_
3'
square daymark - green
240
56' 22"
800
35' 26"
i 2
Piling
3'
triangular daymark - red
240
56' 33"
800
35' 35"
3 '
Piling
3'
square daymark - green
240
56' 37"
800
35' 47"
4
Piling
3'
triangular daymark - red
240
56' 45"
800
35' 51"
We wish to place aids to navigation to mark two dredged channels through surrounding shallow water
out to deeper water in Hawk's Channel. The longer dredged channel to be marked begins just offshore
of the marina at Tropical Reef Resort and runs southeast for about one mile. Vessel traffic from the
resort marina and other businesses and residences on either side of the resort use the channel to
safely access deeper water. The latitude/longitude readings for the proposed markers were taken in
the field on a hand held GPS.
The short side channel we wish to mark begins at Coconut Cove Resort and runs west-southwest until it joins
the longer channel. This channel also receives a lot of vessel traffic has very shall9w water on either side.
The latitude/longitude readings for the proposed markers was taken from a navigational chart.
8 2•••,•.••'' o
I .•'' • : . 4 6 5 5
-- 5 I 5
` 1 7 5 gip' ti f .r�•. 4 7 5
I,•.;:t • f•,,r 5 7= %.••� 1 �, 5 6 rky 6
�•.� Subm ode ,
••" 4 • • 8 I R
s` 1 h'Orb y G I"13 Suom • 5 7 7
�� 0� ^ 11 " (� • 9 Ades
Gam_ Mcngrove `r/_ O 8 C • 5 7
3 FIX=V1lilsonD BRIDGES �R 7
Pm HOR CL 33 "12" K y 3 Crs 2 5
rp VERT C. 112 =, 1 g 1 5 5 ?.
d0 ESubrrt t'
MKR i5.e` 5. Pile r� �_i�_i ..� •• �. 4F
'„.••'' Ltd) 4 � '>s f''S .• • : • 4
2 0 10ft PA •� 2 Mangrove I 5 t •.;• 4 'ib 7•
5 Priv mamtd = 5` Q—� • . .r. 7
Dois --
3� 2 e oo\ 7 •'m L 2R A \ 2 0 3
4 2 a� •8• P.4 q Mangrove � • '•
7 6 —? � cFrQn �
5 G m R •6• b �/� BASCULE BRIDGE
5 V� r2
5 4 3 Sroa/ / 'r HOR CL 60 FT 1
7 _ y q ERT CL 27 FT �� i
2 �
9 5 Grs `� R 6 3 P.Ic�'J p�/�9 2
I I .4 j Shool
5 -4 -"ti 1 6 Q 4 n- p � �G, I I I R •-�
h 3 J, 4• Aye 1 a� �2 % t 984 0
5 3� y+47 Crs ��%/f Pile
e 8
9 2.3 m Pi
I a Qr G
F 2.5s 14ft 3M `AR • 5 1 ,-A�/ .9. 6� 9 `'�O% c
10 8 2 1 ti� �J G s I
13 II 8 4 4 1 "7A"m I
�
4 •7•
Pile 1 1
8 aO./ I C• "t`� IOA P R Tr
A• 1\_ I
9 4/ 4 S'1 �► R •6^ Shoal—
.
14 9 _ R 4- +4A r
14 G•3 I
12 Project Area G •1• A R 4s 16ft "2 - Treasure
16 15 7 4 2 1 U, Harbord
.. (3 4 I g�eG
16 12 11 8 Grs
9 3 2 4
16 14 14 1 1
15
h �
14 \ II 9 52
9 17 \ rky 5
14 10 13
17 10
17 7
16 15 12 13 9
. 14 8 6
19 14 16 �.
17 16
- 19 �
— 19 7
Purpose: Place aids to navigation +
Water Body: Hawk Channel S of Windley iW
17 County: Monroe
Datum __posed g1a(;QmQ.nt g
f markers
Frn NQAA !4 14r3
1
SPECIFICATIONS FOR THE REPAIR/REPLACEMENT/
OR INSTALLATION OF AIDS TO
NAVIGATION , MONROE COUNTY, FLORIDA
Specifications for installation of treated wood piles complete
with U.S Coast Guard approved Daybeacons, in the locations indi-
cated are in the enclosed materials.
A. DAYBEACON PILES:
1. Pile shall be of timber treated with chromated copper
arsenate (C.C.A.).
2. Pile shall be of timber which will stand the driving for
which they are intended.
3. A straight line drawn from the center of the butt to the
center of the tip shall not at any point face further
away from center of the pile than a distance equal to 10-.
of the length of the pile.
4. Minimum butt diameter = 12" measured 3' from end.
Minimum tip diameter = 811.
S. Piles to be sufficient length to provide a minimum of
four feet penetration into existing sea floor and the
base of the dayboard must be eight feet above mean high
water.
6. Pile shall be driven or best installation practices used.
B. DAYBEACONS:
Daybeacons to be constructed and erected as indicated on the
- enclosed sketches and documents. There are two day boards
per daybeacon.
1. Construct all daybeacons as noted in the U.S. Coast Guard
Specifications enclosed.
SEVENTH COAST GUARD DISTRICT
PRIVATE AIDS TO NAVIGATION STANDARDS
DAYBEACONS (UNLIGHTED BEACONS)
AND LIGHTS (LIGHTED BEACONS)
SHAPE•
Dayboards on lights have the same shapes as those on
daybeacons.
Starboard hand dayboards have a triangular shape.
Port hand dayboards have a square shape.
Safe water dayboards have an octagonal shape.
COLOR OF DAYBOARDS:
Starboard hand, triangular dayboards are red.
Port hand, square dayboards are green.
Safe water, octagonal dayboards are red on the right half and
white on the left half.
see "RETROREFLECTIVE MATERIALS" for colors of letters and
borders.
CHARACTERS•
See "DIMENSIONS" for the correct size and distance from the
base or lower apex of the dayboard.
Red starboard hand triangular dayboards have even numbers.
Green port hand square dayboards have odd numbers.
Safe water dayboards are not numbered but may be lettered for
identification purposes. Letters should be sized and placed in
the same way as numbers. However, letters on safe water
dayboards should be centered in the red, right half.
FLUORESCENT AND RETROREFLECTIVE MATERIALS:
Fluorescent background material and retroreflective numbers,
letters, and borders, although optional, should be used on
dayboards. Retroreflective numbers, letter, and borders should
be the same color but a contrasting darker shade) as the
background material; alternatively, numbers and letters may be
white.
The signal characteristics of paint are relatively poor, but
use of paint is not prohibited. If paint is used, then numbers
and letters are white.
DIMENSIONS:
DAYBOARDS: The minimum acceptable dimensions are for a nonlnal range of 1/2
nautical mile
(nml).
Applicants may
establish larger sizes
if they
wish. Optional fluorescent
background and
retroreflective numbers, letters, and borders
are encouraged. All dimensions are
In Inches.
NOMIINAL TYPE
SIZE - NUMBER/
DISTANCE DAYBOARD
RETROREFLECTIYE
RANGE
DAYBOARD LETTER SIZE
BASE TO NUMBER BASE
BORDER SIZE
(nml)
(single)
(double)
(single) (double)
(optional)
PORT
HMO
1/2
Square
side length-18 8
6
5 4
1.5
***** 1
Square
side length-36 12
12
12 12
2
2
Square
side length-48 16
16
16 16
3
3
Square
side length-72 24
24
24 24
4
STARBOARD HAND
1/2
Triangle
height-24 8
6
5 4
1.5
width• -24
***** 1
Triangle
height-48 12
12
10 7
2
width• -48
2
Triangle
height-72 16
16
16 12
3
width• -72
3
Triangle
height-96 24
24
20 14
4
width• -96
SAFE WATER
1
Octogon
height••-48 12
8
21••• 21•••
3
-
width" -48
side length-20
3
Octogon
height••-96 16
12
42••• 42•••
6
width'• -96
side length-40
e
Width at base of
the triangle '
e•
Width/height from
side to the opposite side
•••
Distance from the
lower apex to the letter base
***** Please Use this size.
(DIMENSIONS continued)
STRUCTURES: There are not required dimensions,, materials,
fastenings, or designs for structures supporting dayboards and
associated lights. No particular height above mean high water is
mandated.
Permitees should insure all aids to navigation are established
consistent with prudent, sound engineering practice and the harsh
nature of the marine environment. The following sketches are
for general reference and should be modified to suit the
circumstances.
LIGHTING EQUIPMENT ON LIGHTS (LIGHTED BEACONS):
COLOR•
Lights on starboard hand lighted beacons are red.
Lights on port hand lighted beacons are green.
Lights on safe water beacons are white.
LIGHT NOMINAL (VISUAL) RANGE:
The minimum visual range of a light is one nautical mile.
Depending on the circumstances a greater range may be permitted,
required, or prohibited.
FLASH CHARACTERISTICS:
Red and green flashing lights are laterally significant and
usually flash (light off longer than on) regularly with a
frequency of not more than 30 flashes per minute. When special
caution is necessary, such as sharp turns, obstructions, wrecks,
etc., quick flashing lights (60 flashes per minute) may be used.
- White lights on safe water beacons flash in a Morse Code "A"
rhythm (short -long flash).
These are general recamlendations and may be adapted to specific
circuistances. They should also be modified as necessary to meet the
requirements of prudent sound engineering practice and the demands of the
marine environment.
DOLL, tttu Li -I
j ri" O
SLt "OIL L �
DAt wtRK lTC�4La�
—.... ...40 i
TO/
Or ►ILC ' ,
caw
FILLZ It
1` Xi ROIL 2
1 - ,`�OOLT
• Utivttw VC fTCLA LL-2 ZM •44
a PILE ITLm LZ-i 04 �' r [ '
t I•,t itI► li•�(Ot11OFAl� ���///
� ►orrom
bt
li
MATERIAL LIST
ItemQuantity
Naterlals
Size
LII-1
2
6061 Aluminum alloy bolts nuts d washers
1%2' X 22,1
1.11-2
1 (optional)
Concrete, prestresed le_ngtn es redu(red
lo" X 10"
L11-3
2
Da board
Size as needed
LII-4
2
6061 Aluminum alloy Dolts nuts, washers
1/211 X 14"
LII-5
I
Mood pressure treated length as required
12" dla.
Note 1: All aluminum bolts meet recognized standards for marine use.
Note 2: Place a 2" X 4" filler will be placed between daymarks and the pile
at the upper bolt connection to provide a five degree outboard tilt.
PORT AND STARBOARD MARKERS
(nominal range. 1 nmi)
Port
2" GREEN
(OPTIONAL
RETROREFLECTIVE)
BORDER
.: :::-._-:.•`.�:.
12" GREEN
(OPTIONAL
RETROREFLECTIVE)
NUMBER
Starboard
,...• ^.. ..Y_... -
GREEN
2" RED
(OPTIONAL
(OPTIONAL RETROREFLECTIVE)
FLUORESCENT
BORDER
(�3'
FILM)
_
12" RED
(OPTIONAL RETROREFLECTIVE)
NUMBER'_
^
=•`"'"' -
RED �'
.f_
i 1 LM)
2" GREEN
(OPTIONAL RETROREFLECTIVE)
BORDER
GREEN (OPTIONAL
FLUORESCENT FILM)
1
8" GREEN
(OPTIONAL RETROREFLECTIVE)
NUMBERS
2" RED
(OPTIONAL RETROREFLECTIVE)` 1
BORDER
12" RED
(OPTIONAL RETROREFLECTIVE)
NUMBERS
RED
(OPTIONAL
F I LM)
4'
*For 2 numerals, use 12" numbers at a height of 12" off base.
**For 3 nunerals, use 8" numbers at a height of 12" off base.
,
SEVENTH COAST GUARD DISTRICT
PRIVATE AIDS TO NAVIGATION STANDARDS
DAYBEACONS (UNLIGHTED BEACONS)
AND LIGHTS (LIGHTED BEACONS)
(SPECIAL PURPOSE SUPPLEMENT)
SHAPE:
Special purpose dayboards have a diamond shape.
COLOR OF DAYBOARDS•
Special purpose dayboards are yellow.
See "RETROREFLECTIVE MATERIALS" for colors of letters and
borders.
-CHARACTERS:-
Special purpose dayboards are not numbered but may be
lettered for identification purposed. Letters should be sized
and placed as described for numbers.
See "DIMENSIONS" for the correct size and distance from the
lower apex of the dayboard.
RETROREFLECTIVE MATERIALS:
Retroreflective letters and borders, although optional,
should be used on dayboards. They should be the same color, (but
a contrasting darker shade) as the background material; letters
may be white.
-The signal characteristics of paint are relatively poor, but
the use of paint is not prohibited. If paint is used, then
letters are black.
DIMENSIONS:
DAYBOARDS: The minimum acceptable dimensions are for a
nominal (visual) range of 1/2 nautical (nmi). Applicants may
establish larger sizes if they wish. Optional retroreflective
letters and borders are encouraged. All sizes are in inches.
DIMENSIONS (continued):
NOR I MI. TYPE
S 1 ZE
KJ►GER/
D I STAN--E DtiYBc urD
R£TROREFLEC'T I VE
RµGE
DAYBOAFO LETTER SIZE
BASE TO K,WQ; BASE
BORDER SIZE
ONO
(single)
(double)
(single) (double)
(optional)
SPECIAL PURPOSE
1/2
V&CMde
side
length-18 !!
6
914• 9
115
1
Diamond•
side
length-36 12
12
20" 20
2
Z
DlaRond•
side
length-48 16
16
2604 26
3
3
Dia1hond•
side
length-72 24
24
40 " 40
4
• All •ngles-900
of Distance from the lower apex to the letter base
STRUCTURES:
There are not required dimensions, materials, fastenings, or
designs for structures supporting dayboards and associated
lights. No height above mean high water is mandated.
Permittees should insure that all aids to navigation are
established consistent with prudent, sound engineering practice
and the harsh nature of the marine environment. The enclosed
sketches are for general reference and should be modified to suit
the circumstances.
LIGHTING EQUIPMENT ON LIGHTS (LIGHTED BEACONS):
COLOR:
Lights on special purpose beacons are yellow.
LIGHT VISUAL RANGE:
The minimum visual range of a light is one nautical mile.
Depending on the circumstances a greater range may be permitted,
required, or prohibited.
FLASH CHARACTERISTICS:
Yellow lights on special purpose beacons are fixed or flash
(light off longer tLan on) regularly with a frequency of not more
than 30 flashes per minute.
y
GENERAL CONTRACT SPECIFICATIONS
FOR INSTALLATION OF AIDS TO NAVIGATION
AND REGULATORY BUOYS/SIGNS
1. SCOPE OF WORK: The Contractor shall be responsible for
providing all supervision, labor, equipment, tools,
fees and taxes required to complete this project to the
satisfaction of the County.
The Contractor's procedure and methods of installation
must satisfy the requirements of these Specifications and
and all necessary environmental permits.
2. MATERIALS AND WORKMANSHIP: The Contractor shall
provide the necessary materials and equipment to safely
complete the job. The Contractor agrees that all work
shall be performed by competent employees who are
experienced and qualified to do the work specified, and
that all work will be performed in accordance with the best
commercial practices.
Precaution shall be exercised at all times for the
protection of persons and property. The safety provisions
of the Occupational Safety and Health Act of 1970 (Public
Law 91-596) and other applicable laws, including building
and construction codes shall be observed.
The Contractor shall store materials and shall be
responsible for them during the contract time frame and
until final acceptance of the completed work. If any of
the materials becomes lost, damaged, or destroyed by any
cause or means whatsoever, the Contractor shall
satisfactorily repair and replace or not receive payment for
the unaccomplished work. The Contractor shall maintain
suitable and sufficient guards and barriers, and at night,
suitable and sufficient light or other appropriate security
or protection for the prevention of accidents.
3. ASSIGNMENT OF CONTRACTOR AND SUBCONTRACTS: It is
expressly understood that the Contractor is in all
respects an independent Contractor for this work, not
withstanding under certain conditions he is bound to
follow the directions of the County, and is in no respect
an agent, servant, or employee of the County. Neither the
Contract, nor any part thereof, nor any monies due or to
become due there under, may be assigned by the Contractor
without the prior written approval of the County.
10
The Contractor is fully responsible to the County for the
acts and omissions of his subcontractors and of persons
either directly or indirectly employed by said
subcontractor, as he is for the acts and omissions of
persons directly employed by him. Nothing contained in
the Contract Documents shall create any contractual
relations between any subcontractor and the County. All
subcontractors shall abide by the terms and conditions,
and requirements of this Contract. It is the
responsibility of the Contractor to pay all debt
obligations incurred with subcontractors in an expedient
manner.
4. LICENSE, POLLUTION CONTROL ACT, AND TRAFFIC PROVISIONS:
The Contractor shall comply with all applicable local,
State and Federal requirements pertaining to the terms
of this Contract. The Contractor will be responsible for
obtaining, at his own expense, any licenses that may
be required. The Contractor shall comply with all the
requirements of the Federal Pollution Control Act.
The Contractor shall conduct his operations so that he
shall not close any thoroughfare nor interfere in any way
with traffic on highways, or on water, without the
written consent of the proper authorities. work shall be
done at any time that shall not interrupt or disturb
members of the public. Consideration should be given at
all times to the welfare of the public.
5. INSURANCE: The Contractor must obtain all insurance
required by the County and submit proof of same to the
County prior to contract approval by Board of County
Commissioners but not later than ten working days after
notice of low bidder. All insurance shall be maintained
until work has been completed and accepted by the
County.
The Contractor shall furnish the following certificates
of insurance for review by the County's Risk Management
Division.
Certificates of Insurance: provide proof that the
Contractor has obtained the insurance coverage required
in paragraphs a,b,c,d,and e below.
a. Worker's Compensation Insurance as required by
Florida Statutes.
b. General Liability Insurance in the amount of
$300,000.
C. Water Craft Liability Insurance in the amount of
$500,000.
IT
d. Federal Jones Act Coverage.
All insurance policies required above shall be issued
by companies authorized to do business under the laws
of the State of Florida. All policies must list Monroe
County as additional insured with the exception of the
Worker's Compensation Policy.
6. COMMENCEMENT, DELAYS AND COMPLETION OF WORK:After
receiving Board of County Commission approval of the
Contract, and after reconciliation of any details or
conditions which may directly or indirectly interfere
or conflict with work of the Contract, the County will
issue a "Notice to Proceed with Contract Work"
officially authorizing the Contractor to commence.
The Contractor shall commence work on said date or shortly
thereafter.
If the Contractor should be delayed in the progress
of the work included in the Contract by unforeseeable
cause beyond his control, the time for the completion
of the work may be extended upon agreement of the
County representative. Requests for extension of time
must be submitted in writing to the County representative.
Extensions of time cannot legally be approved unless the
written request is submitted in time to permit it to be
acted upon before the Contract expiration date. To allow
sufficient time for administrative procedures required to
obtain action by the County Commission, a request for time
extension must be received by the County representative at
least ten (10) calendar days prior to the contract
expiration date.
Liquidated damages resulting from factors beyond the
control of the Contractor which occur too late to
allow time for action by the Board of County
Commissioners approving a time extension may be waived
by the County Commission. Such waiver shall be
granted only when the County representative determines
that the delay is beyond the control of the
Contractor, and in this event the Contractor shall not
be charged with liquidated damages or any excess cost
when the delay in the completion of the work is due:
a. To any duly issued order by the County or the
State Department of Environmental Protection
changing the Contractor's approved work schedule.
b. To unforeseeable cause beyond the control and
without the fault or negligence of the Contractor.
C. To any delays of subcontractors or suppliers
occasioned by any of the causes specified in
subparagraphs (a) and (b) above.
, 4 ,
Provided further that the Contractor shall within
ten (10) days from the beginning of such delay notify
the County, in writing, of the causes of the delay.
The County representative will ascertain the facts and
the extent of the delay and notify the Contractor
within a reasonable time of her decision in the
matter.
If the Contractor fails to complete the work within
the time limit, and if the County should nevertheless
permit the Contractor to continue and complete the
same without official extension of time in writing,
such permission shall not modify nor waive any
liability of the Contractor for damages arising from
non -completion of work within the time limit, but all
such liabilities shall be subject to continuation of
full force against the Contractor.
7. CHANGES AND INSPECTION: The navigational and/or regulatory
aids herein considered are to be installed for the County
by the Contractor in accordance with the Specifications.
The County may give instructions or directions to supplement
the Specifications. These shall be binding upon the
Contractor and upon all of his subcontractors, employees and
agents of every kind.
All work and .every process and operation shall be
subject to inspections at all times, by the County
and their representatives and they shall have free access to
all aspects of the work. The Contractor shall remove, or
make good, as may be directed, without charge, any
defective materials. The right is reserved to change the
Specifications consistent with regard to the general
intention of the Contract for any part of the work
or materials, either before or after work has begun. Notice
of such changes shall be given in writing to the Contractor;
such changes are not to be grounds for any claim by the
Contractor for damages, nor for the forfeiture of the
Contract.
AUDIT RIGHTS:As a provision of the grant from the
State of Florida to the County, and if so requested by the
State, the successful bidder agrees to provide access to
all records and allow the audit of any books, documents
and papers related to this project for a period of up to
one year during and after termination of the Contract.
9. CONTRACT AWARD: The County reserves the right to
evaluate the submitted bids and to award a contract to
bidder other than the bidder submitting the lowest bid.
10. PREWORK CONFERENCE: A meeting will be necessary
involving a representative of the County, the Contractor
and other parties with direct involvement prior to the
commencement of the work. The time and place of this
Conference will be set by the County representative. At
this time the Contractor shall provide the County with a
schedule as to the order in which he proposes to install
the listed aids to navigation and or regulatory aids. The
Contractor must also provide transportation to the proposed
project site for placement of temporary markers. The
location of these temporary markers will be provided by the
County representatives. Temporary markers can be
provided, as requested, by the County.
11. EXECUTION OF CONTRACT DOCUMENTS: Due to the time
frame involved with this project, the Contractor upon
notification that he is to be awarded the Contract,
shall return said documents properly executed along
with his insurance within Ten Working Days. With the
Contractor's cooperation, if this period can be reduced, it
will assist in acceleration of the execution of the
contract documents. The Contractor, by virtue of signing
the Contract, acknowledges that he and all his
subcontractors have satisfied themselves as to the nature
and location of work, the general and local conditions,
including, but not restricted to, those bearing upon
transportation, handling, and the character of equipment
and facilities needed to perform the work. Failure on the
part of the Contractor to completely or properly evaluate
any factors of his costs prior to bidding shall not form a
basis for additional compensation if he is awarded the
Contract.
If for any reason, not acceptable to the County, the
Contractor does not perform, the County shall have the right
to levy liquidated damages against the Contractor.
Liquidated damages shall be assessed against the Contractor
for any bid item awarded to him which is not completed and
accepted by the County within the number of calendar days
specified in the Contract. Liquidated damages are
accumulative.
12. NOTICE TO PROCEED: The Contractor shall commence
upon this project on the effective date of the Notice to
Proceed and perform in a continuous manner until
completion and acceptance by the County. For Contracts
wherein a specified number of days for completion is stated
in the Contract the effective date of the "Notice to
Proceed with Contract Work" will establish the
"beginning date" of the project.
. 9
13.TERMINATION Of CONTRACT:This Contract may be
terminated by the County, without cause, giving up to ten
(10) days written notice to the Contractor; said notice
shall be sufficient if delivered to the party personally
or mailed by certified mail to his mailing address as
specified on the accepted Bid.
14. FINAL CLEAN-UP: Upon completion of the work specified
here in and before acceptance and final payment
shall be made, the Contractor shall remove from the
sites all machinery, equipment, surplus and discarded
materials and temporary structures. All disposal of
materials, rubbish and debris shall be made at a legal
disposal site.
15. Certification: Bidder must also certify, upon
completion of the project, all installations were in
accordance with these specifications, the Florida
Department of Environmental Protection permit requirements,
the US Coast Guard permit requirements, and the US Army
Corp of Engineers permit requirements and associated
attachments.
16. PAYMENT:Payment will be upon completion by the Contractor
and acceptance by the Board of County Commissioners.
Contractor mgst submit complete documentation,
including the required photographs for the work for
which payment is being requested. The Contractor must
provide transportation, upon request by the County
representative, to the installed site for review of
work either in progress or completed.
In addition, property, public or private, if damaged
during the work or removed for the convenience of the
work, shall be repaired or replaced at the expense of
the Contractor in a manner acceptable to the County
prior to final payment for contracted work.
17. NON -COLLUSION AFFIDAVIT: Acceptance of the Bid is
contingent upon receipt of the signed and endorsed Non -
Collusion Affidavit form (attached).
18. ETHICS CLAUSE: Acceptance of the Bid is contingent
upon receipt of the signed and endorsed Ethics Clause
form (attached).
19. DRUG FREE WORK PLACE FORM: Acceptance of the Bid is
contingent upon receipt of the signed Drug Free Work
Place form (attached).
April 22, 199.1
Im 1`rinling
MONROE COUNTY, FLORIDA
INSURANCE CHECKLIST
FOR
VENDORS SUBMITTING PROPOSALS
FOR WORK
To assist in the development of your proposal, the insurance coverages marked with an "X" will
be required in the event an award is made to your firm. Please review this form with your
insurance agent and have him/her sign it in the place provided. It is also required that the bidder
sign the form and submit it with each proposal.
X
WC]
WC2
WC3
WCUSLH
WCJA x
WORKERS'COMPENSATION
AND
EMPLOYERS' LIABILITY
Workers' Compensation
Employers Liability
Employers Liability
Employers Liability
US Longshoremen &
Harbor Workers Act
Federal Jones Act
Statutory Limits
$ 100,000' 1$500,000/$ 100,000
$500, 000/$500, 000/$500, 000
$1,000,000/$1, 000,000/$1, 000, 000
Same as Employers'
Liability
Same as Employers'
Liability
Adminkmlive ladnidion
H4709.01
1NSCKLST 1
Aptit 22. 199.1
1c1 I'rinling
GENERAL LIABILITY
As a minimum, the required general liability coverages will include-
• Premises Operations Products and Completed Operations
• Blanket Contractual Personal Injury
• Expanded Definition
of Property Damage
Required Limits:
GLI X $100,000 per Person; $300,000 per Occurrence
$50,000 Property Damage
or
$300,000 Combined Single Limit
GL2 $250,000 per Person; $500,000 per Occurrence
$50,000 Property Damage
or
$500,000 Combined Single Limit
GL3 $500,000 per Person; $1,000,000 per Occurrence
$100,000 Property Damage
or
11,000,000 Combined Single Limit
Required Endorsement:
GLXCU Underground, Explosion and Collapse (XCU)
GLLIQ Liquor Liability
All endorsements are required to have the same limits as the basic policy.
Adminittrative Jrntmclinn INSCKLS1' 2
04709.01
April 22. 1991
Im 1'rinlint,
VEHICLE LIABILITY
As a minimum, coverage should extend to liability for:
• Owned; Nonowned; and Hired Vehicles
Required Limits:
VLl $50,000 per Person: $100,000 per Occurrence
$25,000 Property Damage
or
$100,000 Combined Single Limit
VI-2 $100,000 per Person; $300,000 per Occurrence
$50,000 Property Damage
or
$300,000 Combined Single Limit
VL3 $500,000 per Person; $1,000,000 per Occurrence
$100,000 Property Damage
or -
$1,000,000 Combined Single Limit
' MISCELLANEOUS COVERAGES
BR 1
Builders'
Limits equal to the
Risk
completed project.
MVC
Motor Truck
Limits equal to the maximum
Cargo
value of any one shipment.
PRO
Professional
$ 250,000 per Occurrence/$ 500,000 Agg.
PR02
Liability
$ 500,000 per Occurrence/$1,000,000 Agg.
PR03
$1,000,000 per Occurrence/$2,000,000 Agg.
POLL
Pollution
$ 500,000 per Occurrence/$1,000,000 Agg.
POL2
Liability
$1,000,000 per Occurrence/$2,000,000 Agg.
POL3
$5,000,000 per Occurrence/$10,000,000 Agg.
ED 1
_ Employee
$ 10,000
ED2
Dishonesty
$100,000
GK 1
Garage
$ 300,000 ($ 25,000 per Veh)
GK2
Keepers
$ 500,000 ($l00,000 per Veh)
GK3
$1,000,000 ($250,000 per Veh)
MEDI
Medical
$ 500,000/$ 1,000,000 Agg.
MED2
Professional
$1,000,000/$ 3,000,000 Agg.
MED3
$.5,000,000/$10,000,000 Agg.
AdminiArativc IrtsLmclion
n4709.01
INSCKLSf' 3
Alnif 22. 1993
1 %1 Printing
Ills
IF
Installation
Maximum value of Equipment
Floater
Installed
VLP I
Hazardous
$ 300,000 (Requires MCS-90)
VLP2
Cargo
$ 500,000 (Requires MCS-90)
VLP3
Transporter
$1,000,000 (Requires MCS-90)
BLL
Bailee Liab.
Maximum Value of Property
HKLI
Hangarkeepers
$ 300,000
HKL2
Liability
$ 500,000
H KL3
$ 1,000,000
AIR]
Aircraft
$25,000,000
AIR2
Liability
$ 1,000,000
'vim
$ 1,000,000
AEOI
AF-02
Architects Errors
$ 250,000 per Occurrence/$ 500,000 Agg.
AE03
& Omissions
$ 500,000 per Occurrence/$1,000,000 Agg.
$ 1,000,000 per Occurrence/$3,000,000 Agg.
WL1
% Watercraft
$500,000
LMRCE AGENT'S STATEMENT
I have reviewed
the above requirements with the bidder
named below. The following deductibles
apply to the corresponding policy.
POLICY
DEDUCTIBLES
Liability policies are — Occurrence _ Claims Made
Insurance Agency Signature
BIDDERS STATEMENT
I understand the insurance that will be mandatory if awarded the contract and will comply in full
with all the requirements.
Bidder
Signature
Ad-inisuzlivc lrtcan ctiou INSCKLS' 4
N4709.01
April 22. 1119.1
I sI IYinling
WORKERS' COMPENSATION
INSURANCE REQUIREMENTS
FOR
CONTRACT
BETWEEN
AIONROE COUNTY, FLORIDA
AND
Prior to the commencement of work governed by this contract, the Contractor shall obtain
Workers' Compensation Insurance with limits sufficient to respond to Florida Statute 440.
In addition, the Contractor shall obtain Employers' Liability Insurance with limits of not less than:
$100,000 Bodily Injury by Accident
$500,000 Bodily Injury by Disease, policy limits
$100,000 Bodily Injury by Disease, each employee
Coverage shall be maintained throughout the entire term of the contract.
Coverage shall be provided by a company or companies authorized to transact business in the
state of Florida and the company or companies must maintain a minimum rating of A -VI, as
assigned by the A.M. Best Company.
If the Contractor has been approved by the Florida's Department of Labor, as an authorized self -
insurer, the County shall recognize and honor the Contractor's status. The Contractor may be
required to submit a Letter of Authorization issued by the Department of Labor and a Certificate
of Insurance, providing details on the Contractor's Excess Insurance Program.
If the Contractor participates in a self-insurance fund, a Certificate of Insurance will be required.
In addition, the Contractor may be required to submit updated financial statements from the fund
upon request from the County.
Adminktralive Latruelion WC 1
d4709.1
I
WORKERS' COA1PENSATION
INSURANCE REQUIREMENT'S
FOR
CONTRACT
BET VEEN
MONROE COUNTY, FLORIDA
AND
Recognizing that the work governed by this contract involves Maritime Operations, the
Contractor's Workers' Compensation Insurance Policy shall include coverage for claims subject to
the Federal Jones Act (46 U.S.C.A. subsection 688) with limits not less than those specified for
Employers Liability.
The Contractor shall be permitted to provide Jones Act Covera(through a separate Protection
and Indemnity Policy, in so far as the coverage provided is no less restrictive than would have
been provided by a Workers' Compensation policy.
Adminirtralivc Instruction WCJA
#4709.1
April 22. 1993
lst Priming
GENERAL LIABILITY
INSURANCE REQUIREMENTS
FOR
CONTRACT
BETWEEN
MONROE COUNTY, FLORIDA
AND
Prior to the commencement of work governed by this contract, the Contractor shall obtain
General Liability Insurance. Coverage shall be maintained throughout the He of the contract and
include, as a minimum:
• Premises Operations
• Products and Completed Operations
• Blanket Contractual Liability
• Personal Injury Liability
• Expanded Definition of Property Damage
The minimum limits acceptable shall be-
$300,000 Combined Single Limit (CSL)
If split limits are provided, the'minimum limits acceptable shall be:
$100,000 per Person
$300,000 per Occurrence
$ 50,000 Property Damage
An Occurrence Form policy is preferred. If coverage is provided on a Claims Made policy, its
provisions should include coverage for claims filed on or after the effective date of this contract.
In addition, the period for which claims may be reported should extend for a minimum of twelve
(12) months following the acceptance of work by the County.
The Monroe County Board of County Commissioners shall be named as Additional Insured on all
policies issued to satisfy the above requirements.
Admink.limiivc lm1ruc1i,,n GL I
N4 709.1
April 22. 1993
lst Prinfing
WATER CRAFT LIABILITY
INSURANCE REQUIREMENTS
FOR
CONTRACT
BETWEEN
MONROE COUNTY, FLORIDA
AND
Prior to the commencement of work governed by this contract, the Contractor shall obtain
Water Craft Liability Insurance with tcrms no less restrictive than those found in the
standard "American Institute Hull Clauses" -(June 2, 1977 edition). Coverage shall be
maintained throughout the life of the contract and include, as a minintuln:
• Injury (including death) to any Person
• Damage to Fixed or Movable Objects
• Costs Associated with the Removal of Wrecked Vessels
• Contractual Liability with Respect to this Contract
If the policy obtained states that coverage applies for the "Acts or Omissions of a Vessel",
it shall be endorsed to provide coverage for the legal liability of the shipowner.
The minimum limits acceptable shall be:
$500,000 Combined Single Limit (CSL)
Coverage pro,6ded by a Protection and Indemnity Club (P&I) shall be subject to the
approval of the County.
The Monroe County Board of County Commissioners shall be named as Additional
Insured on all policies issued to satisfy the above requirements.
Admini%tm ive Irntnidion «�L
#4709.1
DRUG -FREE WORKPLACE FORM
The undersigned vendor in accordance with Florida Statute 287.087 hereby certifies that:
(Name of Business)
1. Publish a statement notifying employees that the unlawful manufacture, distribution, dispens-
ing, possession, or use of a controlled substance is prohibited in the workplace and specifying the
actions that will be taken against employees for violations of such prohibition.
2. Inform employees about the dangers of drug abuse in the workplace, the business's policy of
maintaining a drug -free workplace, any available drug counseling; rehabilitation, and employee
assistance programs, and the penalties that may be imposed upon employees for drug abuse
violations.
3. Give each employee engaged in providing the commodities or contractual services that are
under bid a copy of the statement specified in subsection (1).
4. In the statement specified in subsection (1), notify the employees that, as a condition of working
on the commodities or contractual services that are under bid, the employee will abide by the terms
of the statement and "rill notify the employer of any conviction of, or plea of guilty or nolo
contendere to, any violation of Chapter 893 (Mbrida Statutes) or of any controlled substance law
of the United States or any state, for a violation occurring in the workplace no later than five (5)
days after such conviction.
5. Impose a sanction on, or require the satisfactory participation in a drug abuse assistance or
rehabilitation program if such is available in the employee's community, or any employee who is
so convicted.
6. Make a good faith effort to continue to maintain a drug -free workplace through implementation
of this section.
As the person authorized to sign the statement, I certify that this firm complies fully with the above
requirements.
idder's Signature
`3 s �J
Date
MCP#5 REV. 6/91
almejamirma
ETHICS CLAUSE
—� �/ �3, r warrants that he/it has not employed, retained
or otherwise had act on his/its behalf any former County officer or employee in violation of
Section 2 of Ordinance no. 10-1990 or any County officer or employee in violation of
Section 3 of Ordinance No_ 10-1990. For breach or violation of this provision the County
may, in its discretion, terminate this contract without liability and may also, in its discretion,
deduct from the contract or purchase price, or otherwise recover, the full amount of any fee,
commission, percentage, gift, or consideration paid to the former County officer or employee.
(signature)
Date: _;��� /
STATE OF
COUNTY OF _ <-2le
PERSONALLY APPEARED BEFORE ME, the undersigned authority,
who, after first being sworn by me, affixed his/her
signature (name/off individual signing) in the space provided above on this day of
NOTARY PUBLIC
My commission expires:
Glorla K. McBee
OMB -MCP FORM #4 s* *" WFISSIONNCC529329EXPIRE'
�a ,:o�= March 24. 199'%
Q. BOM TWJJ TROY FAIN INSURANCE. INC
NON -COLLUSION AFFIDAVIT
I, v��-,�/f�-'� of the
amity of off0, according to law on my oath, and
under penalty of perjury, depose and say that;
1) 1 am.
the Proposal for
e project described as follows:
the bidder making
2) The prices in this bid have been arrived at independently without collusion,
consultation, communication oragreementforthe purpose of restricting competition, as
to any matter relating to such prices with any other bidder or with any competitor;
3) Unless otherwise required by law, the prices which have been quoted in this
bid have not been knowingly disclosed by the bidder and will not knowingly be disclosed
by the bidder prior to bid opening, directly or indirectly, to any other bidder or to any
competitor; and
4) No attempt has been made or will be made by the bidder to induce any other
person, partnership or corporation to submit, or not to submit, a bid for the purpose of
restricting competition;
5) The statements contained in this affidavit are true and correct, and made with
full knowledge that Monroe County relies upon the truth of the statements contained in
this affidavit in awarding contracts for said project.
STATE OFF
(Signature of Bidder)
COUNTY OF Zl `1 faE
DATE
PERSONALLY APPEARED BE/FORE ME, the undersigned authority,
/ O'/ / who, after first being sworn by me, (name of
individual signing) affixed his/her signature in the space provided above on this
-�/ day of /��/ %3l, 19
NOTARY PUBLIC '
��+� "$� G101fa K. AAC&e
NIN COANYMSSION N 1W29 EXPIRES
MerOh 24, 1998
My commission expires: °01D1D1'a1T00N1'"" "�
MCP 41
6SUE DATE —
A000.11e CER�`1FtC,�4'�'E F INSUR�4,�ICE
,. ' ... .._. .:...... ..............
.........: ....
THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND
CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICAT
ROGERS ATKINS GUNTER & ASSOC
AMEND,DOES NOT EXTEND OR ALTER THE COVERAGE AFFORDED By T}il
FOREHAND INSURANCE AGENCY INC
POLICIES BELOW
P 0 BOX 25598
COMPANIES AFFORDING COVERAGE
TAMPA FL 33622-5598
__ ............................................................
COMPANYLEITEA
R PROGRAM UNDERWRITERS INC
. ......................... . ..........................
.......................... .
.
COMPANY 8 .-
INSURED-
LETTER
SEA TOW FLORIDA KEYS
............................................................. _...............................
.....................
DUKE H PONTIN SPIRIT TOWING
COMPANY
LETTER
P 0 BOX 244 BIG PINE KEY
................................................. fl .................................
KEY WEST FL 33043 .......................................
COMPAND.
Y
LETTERD
...............
. ................
COMPANY E
LETTER
/
COVERAGE
THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW
INDICATED, NOTWIIrjMSTANDING
7777777
HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD
ANY REQUIREMENT, TERM OR CONDMON OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS
CERTIFICATE MAY `At ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL
EXCLUSIONS AND CONDITIONS OF SUCH POUCIES. LIMITS SHOWN
THE TERMS,
MAY HAVE BEEN REDUCED BY PAID CLAIMS.
CO
TR TYPE OF INSURANCE POLICY NUMBER
................
POLICY EFFECTIVE POLICY EXPIRATION
DATE (MMIDD/YY) DATE (MM/DD/YY) UNITS
A GENERAL LIABILITY PU7 9 5 0 4
4 10 9 6 4/ 1 O 9 7 GENERAL AGGREGATE 63 0 0 ,000
X_.....
COMMERCIAL GENERAL LIABILITY
... .
PRODUCTS-COMP/OP AGG. i
CLAIMS MADE OCCUR.
PERSONAL A ADV. INJURY =
OWNER'S M, CONTRACTOR'S PROT.
EACH OCCURRENCE 000, 0 0 0
FIRE DAMAGE (Any One Ire) L
MED. EXPENSE (Any One person) j
AUTOMOBILE LIABuM
ANY AUTO
COMBINED SINGLE j
LIMIT
ALL OWNED AUTOS
_.._
SCHEDULED AUTOS
BODILY INJURY(Per person) :
HIRED AUTOS
NON -OWNED AUTOS
BODILY INJURY =
(Per accidenl)
GARAGE LIABILITY
PROPERTY DAMAGE :
EXCESS UABLL.ITY
EACH OCCURRENCE i
UMBRELLA FORM
_..
AGGREGATE _
OTHER THAN d1MBRELUI FORM
».,.
WORKER'S COMPENSATION
STATUTORY LIMITS
` AND
_......_. __.. _. ::.._.,.::::::..........
EACH ACCIDENT _
EMPLOYERS' LIA RM
DISEASE —POLICY LIMIT j
DISEASE —EACH EMPLOYEE i
OTHER
DESCRIPTION OF OPERATIONSA-OCATIONSNEHICLES/SPECIAL ITEMS
COMPANY A IS SPHERE DRAKE INSURANCE
CO - MONROE COUNTY BOARD OF COUNTY
COMMISSIONERS IS ADDITIONAL INSURED
BUT ONLY OPERATIONS PERFORMED BY THE
NAMED INSURED - DOES NOT PROVIDE COVERAGE
FOR TOWING & SALVAGE -PREMISES ONLY
CERTIFICATE HOLDER
CANCELLATION
SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE
MONROE COUNTY BOARD OF COUNTY
EXPIRATION DATE THEREOF, THE ISSUING COMPANY WILL ENDEAVOR TO
COMMISSIONERS KIM B�i&GEE"
MAIL DAYS WRITTEN NOTICE TO THE CERTIFICATE HOLDER NAMED TO THE
OR
5100 COLLEGE ROAD
LEFT' BUT FAILURE TO MAIL SUCH NOTICE SHALL IMPOSE NO OBLIGATION
KEY WEST FL 33040
LIABILITY OF ANY KIND UPON THE COMPANY, ITS AGENTS OR REPRESENTATIVES
AUTH REf ESENT TIVE
H B tOREHAND
DD(B)
ACORD 25-S (7/90)
...rrnlJ t991
vN%lwnv %lunrVn�••"
DATE ({poi
.. CER _F IURAI��C A(`Ot't! TCAT 10 15 g 6
.. nn:.... .. _..::: _. .. :' ..:..:.:. n....Svnvavri:•ptC- ''"w U. nv.':<.-n nnn ♦. n: n.N k.•nv.. .... .. ....
Paor�Ic4 w ....THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION
PROFESSIONAL INSURANCE CTR
ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE
HOLDER. THIS CERTIFICATE DOES NOT AMEND
ALTER THE COVERAGE AFFORDED BY THE POLICES gpOw
2003 W KENNEDY
COMPANIES AFFORDING COVERAGE
TAMPA FL 33606
COMPANY
A BANKERS & SHIPPERS INS COMPANY
INSURED
COMPANY
SPRIT TOWING
B
COMPANY
DBA DUKE PONTIN
PO BOX 244
BIG PINE KEY FL 33043
CAWPANY
D
COVERAO
... n......., ..................v.}4-.v}SnvJrvhw\wvvW:v}:}'fti4n rn..n.x. n.......x n:.:xn:•:v .... vx:::::::::. :::::::: ...... .. .m::i....
THIS IS TO CERTIFY THAT THE.POLICIE$ OF.INS11RANC,E LISTED jIF_LOW HAVE.SFEN ISSUED TO THE IN_CURFn NAMFn ARn%lr rncl T14F P1 If-Y Pcr;lOn
INDICATED, NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS
CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS,
EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS.
CO
LTA
TYPE OF INSURANCE
ii
POLICY NUMBER
POLICY EFFECTIVE
DATE (MMMONY)
POLICY EXPIRATION
DATE (MMMONY)
LIMITS
GENERAL
I IABLTTY
GENERAL AGGREGATE
i
PRODUCTS - COMP/OP AGG
i
COMMERCIAL GENERAL LIABILITY
CLAIMS MADE M OCCUR
PERSONAL L ADV INJURY
i
EACH OCCURRENCE
f
OWNER'S d CONTRACTOR'S PROT
FIRE DAMAGE (Any one in)
f
MED EXP (Any one porwn)
i
AUTOMOBILELIABLTY
CFL7376695•
11/06/96
05/06/97
- -
300,000
ANY AUTO
COMBINED SINGLE LIMIT
f
BODILY INJURY
(Per pwson)
f
ALL OWNED AUTOS
SCHEDULED AUTOS
X
f
HIRED AUTOS
NON -OWNED AUTOS
—�
- F/
BODILY INJURY
(P.r wdd.M)
----- --
PROPERTY DAMAGE
i
GARAGE LIABILITY
AUTO ONLY . EA ACCIDENT
S
OTHER THAN AUTO ONLY:
ANY AUTO
EACH ACCIDENT
f
AGGREGATE
i
EXCESS LIABILITY
1'(mfLD�a•.
-Ur)['
EACH OCCURRENCE
f
AGGREGATE
f
UMBRELLA FORM
BY_.d.L
f
OTHER THAN UMBRELLA FORM
WORKERS COMItENSATION AND _
EMPLOYERS' LIABLTY
THE PROPRIETOR/
PARTNERS/EXECUTIVERNCL
DATE / -3'2
II'!,'IIFR: NIAy -
cC
STATUTORY LIMITS
EACH ACCIDENT
f
DISEASE • POLICY LIMIT
i
DISEASE - EACH EMPLOYEEMPLOYEEI
f
OFFICERS ARE: EXCL
OTHER
DESCRIPTION OF OPERATIOHSILOCATIONSNEWCLESISPECIAL ITEMS
MARINE CONTRACTING
1979 GMC DUMP TRUCK SN: T16DA9V601349
ADDITIONAL INSURED: MONROE COUNTY BOARD OF COUNTY COMMISSIONERS
CERTIFICATE HOLDER
::::CANCELLATION....'
SHOULD ANY OF THE ABOVE DESCRIBED POUCIES BE CANCrtiFn BEFORE THE
MONROE COUNTY BOARD OF COUNTY
EXPIRATION DATE THEREOF, THE ISSUING COMPANY WILL ENDEAVOR TO MAL
COMMISSIONERS ATTN • K IM MCG EE
3 0 DAYS WRITTEN NOTICE TO THE CERTIFICATE HOLDER NAMED TO THE LEFT,
5100 COLLEGE
BUT F T MAIL SUCH NOTICE S LL NO OBLIGATION OR LIABILITY
KEY WEST,FLORIDA
EDITIDA 33040
of Y uP co E OR REPRESENTATIVES.
AUTHOa
�MN,
Kr"eLENTATIV/
M . !J A
ACORD 25•S (3/9(h)ACORD CORPORATION'