05/18/2011 AgreementDANNYL. KOLHAGE
CLERK OF THE CIRCUIT COURT
DATE: May 19, 2011
TO: Lynda Stuart, Office Manager (via e-mail)
Tourist Development Council
ATTN: Maxine Pacini
Administrative Assistant
FROM: Pamela G. Hanc ck, . C.
At the May 18, 2011, Board of County Commissioners meeting, the Board granted
approval and authorized execution of the following:
Item Dl Agreement with Dolphin Research Center, Inc. for the Gift Shop Doors project,
in an amount not to exceed $3,725 DAC III FY 2011 Capital Resources.
Item D2 Agreement with The Marathon Community Theatre, Inc. covering the kitchen
and bathroom renovation project in an amount not to exceed $8,000 DAC III FY 2011 Capital
Resources.
Item D3 Agreement with Key West Film Society, Inc. for the Tropic Cinema Phase Six:
Renovations and Upgrades project in an amount not to exceed $35,000 DAC I FY 2011 Capital
Resources.
Item D4 Agreement with Marine Mammal Conservancy, Inc. to extend agreement for the
Marine Mammal Conservancy Phase II Project in an amount not to exceed $28,180.
Item D5 Agreement with Key West Players, Inc. covering the Air Conditioning
Modernization project in an amount not to exceed $24,950 DAC I FY 2011 Capital Resources.
Item D6 Agreement with the Studios of Key West, Inc. for the Nature Center project in an
amount not to exceed $60,000 DAC I, FY 2011 Capital Resources.
Item D7 Agreement with The City of Marathon for the Installation of a Kayak Dock and
Boardwalk in an amount not to exceed $20,000 DAC III, FY 2011 Capital Resources.
Item D8 Agreement with The City of Marathon for the Volley Ball project on Sombrero
Beach in an amount not to exceed $19,750 DAC III, FY 2011 Capital Resources.
Item D9 Agreement with The Key West Harry S Truman Foundation, Inc. covering the
Energy Conservation at The Little White House project in an amount not to exceed $5,250 DAC
I, FY 2011 Capital Resources.
Item D 10 Agreement with Mitchell Wolfson Family Foundation, Inc. covering the
Interpreting History — Audubon House Outbuildings project in an amount not to exceed $61,780,
DAC 1, FY 2011 Capital Resources.
Item D 11 Agreement with The Studios of Key West, Inc. covering the Replacement of
Central Air conditioning project at the Historic Armory in an amount not to exceed $25,000,
DAC I, FY 2011 Capital Resources.
Item D 12 Agreement with Florida Keys Land & Sea Trust, Inc. covering the Crane Point
Eco-Adventure Canopy Tour Program in an amount not to exceed $85,000, DAC III, FY 2011
Capital Resources.
Item D 13 Agreement with Dolphin Research Center, Inc. to purchase land for the purpose
of additional parking for the Dolphin Research Center in an amount not to exceed $152,250,
DAC III, FY 2011 Capital Resources.
Item D 15 Amendment to Agreement with Florida Keys Community College and the
Letters FKCC covering the FKCC Keys Chorale Concert Series to revise Exhibit C — Schedule of
Events.
Attached is the electronic copy of the above -mentioned for your handling. Should you
have any questions, please feel free to contact me.
cc: County Attorney
Finance via e-mail
File
Grant Award Agreement
THIS AGREEMENT (Agreement) is entered into this day of
141,2011 by and between MONROE COUNTY, a political subdivision of the State
of Flori a (County or Grantor) and The Marathon Community Theatre, Inc. a not for
profit organized and operating under the laws of the state of Florida (Grantee).
WHEREAS, the district pennies of Tourist Development Tax may be used
to acquire, construct, extend, enlarge, remodel, repair or improve, convention centers,
sports stadiums, sports arenas, coliseums, auditoriums, fishing piers, museums, zoological
parks, nature centers, beach improvements and beach park facilities which are publicly
owned and operated or owned and operated by not -for -profit corporations, and
WHEREAS, Grantee has applied for funding for the Kitchen and Restroom
Renovation project; and
WHEREAS, the Grantor and Tourist Development Council (TDC) have
determined that it is in the best interest of the County, for purposes of promoting tourism
and preserving the heritage of the community, to attract tourists, and improve the property
for use as an auditorium that is open to the public;
NOW, THEREFORE, in consideration of the mutual covenants and
payments contained herein, the Grantee and the Grantor have entered into this Agreement
on the terms and conditions as set forth below.
1. GRANT AGREEMENT PERIOD. This Agreement is for the period of May 18, 2011
through to September 30, 2011. This Agreement shall remain in effect for the stated period
unless one party gives to the other written notification of termination pursuant to and in
compliance with paragraphs 7, 12 or 13 below.
2. SCOPE OF AGREEMENT. The Grantee shall provide the following scope of
services: Materials and labor required to renovate the kitchen and bathroom facilities at
Marathon Community Theatre. Segment(s) of the work is/are more particularly described
in Exhibit(s) A, detailing the work and the cost allocable to each segment, attached hereto
and incorporated herein by reference. All work for which grant funds are to be expended
must be completed by the stated termination date of September 30, 2011 and all invoices
pertaining to this project shall be submitted to the Finance Department of Monroe County
no later than September 30, 2011 to be considered for payment. Acknowledgement:
Grantee shall be required to permanently display and maintain at Grantee's
expense, public acknowledgement of the support of the Monroe County Tourist
Development Council in a publicly prominent area of their facility in the following
form: "This project was made possible with the financial support of the Monroe
FY 2011 Funding — 2"d round
Kitchen and Restroom Facilities
Contract ID#: 856
County Tourist Development Council." If the Grantee has already compiled with this
requirement through previous funding, said acknowledgement fulfills this
condition. A photograph of said acknowledgment shall be provided with the final
request for reimbursement outlined in Exhibit A of this agreement.
a) There shall be a project manager to acknowledge receipt of goods or work
performed. This Project Manager shall be Loretta Geotis, 5101 Overseas Highway,
Marathon, FL 33050 (Telephone: 305-7430408 — e-mail: gm @ marathontheater.org).
Should there be a change in the project manager specified in the Grantee's application, a
new project manager shall be designated and notice with new contact information shall be
provided in writing to the TDC administrative office.
b) If, and to the extent that, Grantee contracts for any of the work funded under this
Agreement to be performed or completed, Grantee shall give notice to County of the
contractual relationship, provide County with a copy of any and all contracts and shall
require the contractor(s) to comply with all the terms of this contract. Should Grantee
contract the work and then decrease the scope of work to be performed by a contractor,
Grantee shall provide County with an amended contract executed by Grantee and its
contractor.
0) A Grantee which is a governmental entity shall comply with the procurement
regulations and policies to which it is subject, and shall provide Grantor documentation of
the procurement requirements applicable to the project and compliance therewith.
(ii) A Grantee which is a not -for -profit entity shall undergo procurement processes
for those parts of the project to be contracted (not performed by the entity's employees),
which shall, at a minimum, require the acquisition of two written quotes for work expected
to be under $25,000 or a notarized statement as to why such written quotes were not
feasible. For work expected to be $25,000 or more, a competitive bid process must be
performed. County procurement policies and procedures may be used by the Grantee as
a guideline.
c) Grantee shall exercise good internal controls to assure that the project as described in
the funding application shall be completed on a timely basis within the proposed budget
and shall provide to County any certifications, including those by the architect, engineer,
contractor or an independent consultant if necessary, required to establish that materials
which are purported to be applied to the project are in fact so applied. Further verification
shall be required to show that equipment and other fixtures and personal property covered
by this Agreement are delivered to and installed in the project site. When any permit is
required by any governmental agency, copies of plans and other documents which are
submitted to the applicable agency shall be submitted to the County Engineering Division
to enable verification that the scope of services under this Agreement has been provided.
3. AMOUNT OF AGREEMENT AND PAYMENT. The Grantor shall provide an
amount not to exceed $8,000 for materials and services used to improve the property.
FY 2011 Funding — 2"d round
Kitchen and Restroom Facilities
Contract ID#: 856
E
Reimbursement request must show that Grantee has paid in full for materials and services
relating to the segment prior to seeking the 50% (fifty percent) reimbursement from
Grantor. Payment shall be 50% (fifty percent) reimbursement of the total cost of the
segment, subject to the cap on expenditures for that segment as set forth in Exhibit A.
Reimbursement can be sought after each segment of the Agreement is completed and
signed by the Monroe County Engineering Department as outlined in 3.a. The Board of
County Commissioners and the Tourist Development Council assume no liability to fund
this Agreement for an amount in excess of this award. Monroe County's performance and
obligation to pay under this Agreement is contingent upon an annual appropriation by the
BOCC.
a) Payment shall be made upon the completion of a specific segment as outlined in
the Scope of Services and Exhibit A. Payment for expenditures permissible by law and
County policies shall be made through reimbursement to Grantee upon presentation of
Application for Payment Summary— AIA Document G702 or similar certification as required
below for governmental entities and not -for -profit entities, invoices, canceled checks and
other documentation necessary to support a claim for reimbursement. Included in said
documentation shall be proof that the Grantee has received the property, realty or
personalty, for each segment of Agreement as outlined in Exhibit A and paid an amount
equal to or greater than the amount invoiced to the Grantor. It shall be necessary for the
Grantee to contact the County Engineering Division and to arrange for inspections upon
the completion of each segment. The documentation needed to support the payment
request shall be in the form necessary for submission and available to the County
Engineer at the time of inspection. All submissions for payment shall have a proposed
schedule of values for segment(s) and indicate the percentage of completion of the overall
project as of the submission. This document should be signed by the project architect,
engineer, general contractor or project manager. Photos of the progress of the work shall
also be submitted with the payment application. It shall be the responsibility of the project
architect, engineer, general contractor or project manager to initiate the communication
with the Monroe County Engineering Division to facilitate the inspection(s) of the segment
of the project. All submissions requesting payment shall be approved in writing, and
signed, by the Monroe County Engineering Division as to the completion of the segment of
the project for which payment is requested. The application for payment document must
be certified through a statement signed by an officer of the organization and notarized,
declaring that representations in the invoice are true and factual. Grantee shall also
provide partial releases of liens or certifications of non -lien if applicable. Grantor shall
retain 10% of any payment on work in progress until the Grantee has provided a Final
Release of Lien for each vendor/Contractor for whom payment is requested. For projects
exceeding $25,000 in TDC funding under this Agreement, final payment will not be made
until the following documents are complete and submitted to the Grantor:
AIA Document
G-702 Application for Payment Summary
AIA Document
G-704 Certificate of Substantial Completion
AIA Document
G-706 Contractor's Affidavit of Debts & Claims
AIA Document
G-706A Contractor's Affidavit of Release of Liens
FY 2011 Funding - 2„ d round
Kitchen and Restroom Facilities
Contract ID#: 856
3
AIA Document G-707 Consent of Surety to Final Payment (when applicable)
Final Release of Lien or Affidavit and Partial Release of Lien
For projects for which TDC funding under this Agreement is $25,000 or less, the AIA
documentation is not required, but sufficient documentation must be submitted to County
to provide similar assurances that the work has been completed and contractors/suppliers
paid.
All payment requests must be submitted no later than the completion of project of
September 30, 2011. Invoices received after September 30, 2011 will not be considered
for payment.
b) Documentation shall be submitted to the TDC Administrative Office to show the
receipt and application of in -kind donations of goods, professional services, and materials.
Said documentation should include invoices, bills of lading, etc., and be verified as
received and applied to the project through a notarized statement of the project architect,
engineer, general contractor or project manager. The receipt and application to the project
of volunteer labor are to be documented and verified by notarized signature of the project
architect, engineer, general contractor or project manager, and said documentation
submitted to the TDC Administrative Office. All submissions shall identify the items
included in Exhibit A and grantee shall complete the Application for Payment form which is
provided within the payment/reimbursement kit provided to the grantee, listing the
schedule of values which are sought to be reimbursed and shall indicate the percentage of
completion of the overall project as of the submission. This document should be signed by
the project architect, engineer, general contractor or project manager. Photographs
showing progress on project shall be included in any payment request. The Project
Manager shall certify delivery to the project site and installation therein of any goods or
services provided other than through an architect, engineer or contractor. All work
performed and goods received on site and incorporated into the project shall be verified by
one of the foregoing. Submission of any documentation which is untrue, falsified, or
otherwise misrepresents the work which has been completed, paid, or donated shall
constitute a breach of agreement, for which breach the contract may be immediately
terminated at the discretion of the County, whose decision shall be final.
c) Grantee must submit all documentation for final payment on or before the termination
date of this grant of September 30, 2011. Invoices received after September 30, 2011 will
not be considered for payment.
d) At any time that the documentation requirement policies of Monroe County are
revised, such as to require annual inventory reports for equipment purchased under a TDC
capital project grant, Grantee shall comply thereafter with such increased requirements, or
further funding under the Agreement may be terminated by County.
FY 2011 Funding - 2"d round
Kitchen and Restroom Facilities
Contract IDA 856
4
e) Upon successful completion of this Grant Agreement, the Grantee may retain
ownership of the real and personal property acquired and/or improved with funding under
this Grant Agreement. However, the Grantee shall maintain, preserve and operate the
property which was acquired or improved under this Agreement for the uses and purposes
which qualified the Grantee for tourist development tax funding. Grantee shall complete
and sign a Property Reporting Form (provided within paymentireimbursement package) for
personal property and forward said completed form with the appropriate invoice to the TDC
Administrative Office. Real property acquired or improved through funding under this
Agreement shall remain dedicated for the purposes set forth herein or for other purposes
which promote tourism and ownership of said property shall be retained by the Grantee.
The following terms shall apply:
(i) The Grantee shall have the use of the property, including both realty and personalty
acquired with funding under this agreement, at the project site for so long as the facility is
operated by Grantee, open to the public, and has a primary purpose of promoting tourism.
At such time as any of the conditions in the preceding sentence shall cease to exist, the
Grantee shall transfer ownership and possession of equipment and personal property to a
local government or another not -for -profit organization which is a facility for which tourist
development taxes may be used pursuant to Florida Statute with prior approval from TDC
and BOCC.
(ii) At any time that the Grantee: (a) elects to stop the project or otherwise decide not to
place into service for tourist -related purposes the facility acquired, constructed, or
renovated with tourist development tax funding, (b) demolishes the project facility or
divests itself of ownership or possession of the real property, or (c) ceases the use of the
property with a primary purpose of promoting tourism, Grantee shall, pursuant to the
formula set forth hereafter, refund to the County the Tourist Development funding. This
provision shall survive the termination date of all other provisions of this contract for a
period of ten years. Should the demolition, transfer of ownership, or change to a non -
tourist related purpose occur after the facility has been used for tourist -related purposes for
at least three (3) years, the amount of refund shall be pro -rated based on a useful life of
ten (10) years.
(iii) The Grantee is responsible for the implementation of adequate maintenance
procedures to keep the real and personal property in good operating condition.
(iv) The Grantee is responsible for any loss, damage, or theft of, and any loss, damage
or injury caused by the use of, real or personal property or equipment purchased through
funding under this Agreement.
4. RECORDS AND REPORTS. The Grantee shall keep such records as are necessary to
document the performance of the Agreement and expenses as incurred, and give access
to these records at the request of the TDC, the County, the State of Florida or authorized
agents and representatives of said government bodies. The Grantee shall also provide
such access to the personal property and equipment purchased under this Agreement. It is
the responsibility of the Grantee to maintain appropriate records in accordance with
FY 2011 Funding — 2id round
Kitchen and Restroom Facilities
Contract ID#. 856
5
generally accepted accounting principles consistently applied to insure a proper
accounting of all funds and expenditures. The Grantee understands that it shall be
responsible for repayment of any and all audit exceptions which are identified by the
Auditor General for the State of Florida, the Clerk of Court for Monroe County, the Board of
County Commissioners for Monroe County, or their agents and representatives. In the
event of an audit exception, the current fiscal year grant award or subsequent grant
awards will be offset by the amount of the audit exception. In the event the grant is not
renewed or supplemented in future years, the Grantee will be billed by the Grantor for the
amount of the audit exception and shall promptly repay any audit exception.
(a) Public Access. The County and Grantee shall allow and permit reasonable access to,
and inspection of, all documents, papers, letters or other materials in its possession or
under its control subject to the provisions of Chapter 119, Florida Statutes, and made or
received by the County and Grantee in conjunction with this Agreement; and the County
shall have the right to unilaterally cancel this Agreement upon violation of this provision by
Grantee.
5. MODIFICATIONS AND AMENDMENTS. Any and all modifications of the terms of this
Agreement shall be only amended in writing and approved by the Board of County
Commissioners for Monroe County. The terms, covenants, conditions, and provisions of
this Agreement shall bind and inure to the benefit of the County and Grantee and their
respective legal representatives, successors, and assigns.
6. INDEPENDENT CONTRACTOR. At all times and for all purposes hereunder, the
Grantee is an independent contractor and not an employee of the Board of County
Commissioners of Monroe County. No statement contained in this Agreement shall be
construed as to find the Grantee or any of its employees, contractors, servants or agents
to the employees of the Board of County Commissioners of Monroe County, and they shall
be entitled to none of the rights, privileges or benefits of employees of Monroe County.
(a) No Personal Liability. No covenant or Agreement contained herein shall be deemed to
be a covenant or Agreement of any member, officer, agent or employee of Monroe County
in his or her individual capacity, and no member, officer, agent or employee of Monroe
County shall be liable personally on this Agreement or be subject to any personal liability
or accountability by reason of the execution of this Agreement.
7. COMPLIANCE WITH LAW. In carrying out its obligations under this Agreement, the
Grantee shall abide by all statutes, ordinances, rules and regulations pertaining to or
regulating the provisions of this Agreement, including those now in effect and hereafter
adopted. Any violation of said statutes, ordinances, rules or regulations shall constitute a
material breach of this Agreement and shall entitle the Grantor to terminate this Agreement
immediately upon delivery of written notice of termination to the Grantee.
FY 2011 Funding — 2"d round
Kitchen and Restroom Facilities
Contract ID#: 856
8. RESTRICTIONS ON AGREEMENTS ENTERED PURSUANT TO THIS AGREEMENT.
The Grantee shall include in all Agreements funded under this Agreement the following
terms:
a) Anti -discrimination. Contractor agrees that it will not discriminate against any
employees or applicants for employment or against persons for any other benefit or
service under this Agreement because of their race, color, religion, sex, national origin, or
physical or mental handicap where the handicap does not affect the ability of an individual
to perform in a position of employment, and to abide by all federal and state laws regarding
non-discrimination.
b) Anti -kickback. Contractor warrants that no person has been employed or retained to
solicit or secure this Agreement upon an Agreement or understanding for a commission,
percentage, brokerage or contingent fee, and that no employee or officer of the Contractor
has any interest, financially or otherwise, in County. For breach or violation of this
warranty, the County shall have the right to annul this Agreement without liability or, in its
discretion, to deduct from the Agreement price or consideration, the full amount of such
commission, percentage, brokerage or contingent fee. Contractor acknowledges that it is
aware that funding for this Agreement is available at least in part through the County and
that violation of this paragraph may result in the County withdrawing funding for the
Project.
c) Hold harmless/indemnification. Contractor acknowledges that this Agreement is funded
at least in part by the County and agrees to indemnify and hold harmless the County and
any of its officers and employees from and against any and all claims, liabilities, litigation,
causes of action, damages, costs, expenses (including but not limited to fees and
expenses arising from any factual investigation, discovery or preparation for litigation), and
the payment of any and all of the foregoing or any demands, settlements or judgments
(collectively claims) arising directly or indirectly from any negligence or criminal conduct on
the part of Contractor in the performance of the terms of this Agreement. The Contractor
shall immediately give notice to the County of any suit, claim or action made against the
Contractor that is related to the activity under this Agreement, and will cooperate with the
County in the investigation arising as a result of any suit, action or claim related this
Agreement.
d) Insurance. Contractor agrees that it maintains in force at its own expense a liability
insurance policy which will insure and indemnify the Contractor and the County from any
suits, claims or actions brought by any person or persons and from all costs and expenses
of litigation brought against the Contractor for such injuries to persons or damage to
property occurring during the Agreement or thereafter that results from performance by
Contractor of the obligations set forth in this Agreement. At all times during the term of this
Agreement and for one year after acceptance of the project, Contractor shall maintain on
file with the County a certificate of the insurance of the carriers showing that the aforesaid
insurance policy is in effect. The following coverage's shall be provided:
FY 2011 Funding - 2"d round
Kitchen and Restroom Facilities
Contract ID#: 856
7
1. Workers Compensation insurance as required by Florida Statutes.
2. Commercial General Liability Insurance with minimum limits of $500,000 per
occurrence for bodily injury, personal injury and property damage.
3. Comprehensive Auto Liability Insurance with minimum limits of $300,000
combined single limit per occurrence.
The Contractor, the County and the TDC shall be named as additional insured, exempt
workers compensation. The policies shall provide no less than 30 days notice of
cancellation, non -renewal or reduction of coverage.
At all times during the term of this Agreement and for one year after acceptance of the
project, Contractor shall maintain on file with the County a certificate of insurance showing
that the aforesaid insurance coverage's are in effect.
e) Licensing and Permits. Contractor warrants that it shall have, prior to commencement
of work under this Agreement and at all times during said work, all required licenses and
permits whether federal, state, County or City.
f) Right to Audit. The Contractor shall keep such records as are necessary to
document the performance of the Agreement and expenses as incurred, and give access
to these records at the request of the TDC, the County, the State of Florida or authorized
agents and representatives of said government bodies.
9. HOLD HARMLESS/INDEMNIFICATION. The Grantee hereby agrees to indemnify and
hold harmless the BOCC/TDC and the 3406 North Roosevelt Blvd. Corporation or any of
its officers and employees from and against any and all claims, liabilities, litigation, causes
of action, damages, costs, expenses (including but not limited to fees and expenses
arising from any factual investigation, discovery or preparation for litigation), and the
payment of any and all of the foregoing or any demands, settlements or judgments arising
directly or indirectly under this Agreement. The Grantee shall immediately give notice to
the Grantor of any suit, claim or action made against the Grantor that is related to the
activity under this Agreement, and will cooperate with the Grantor in the investigation
arising as a result of any suit, action or claim related to this Agreement.
(a) Non -Waiver of Immunity. Notwithstanding he provisions of Sec. 768.28, Florida
Statutes, the participation of the County and the Grantee in this Agreement and the
acquisition of any commercial liability insurance coverage, self-insurance coverage, or
local government liability insurance pool coverage shall not be deemed a waiver of
immunity to the extent of liability coverage, nor shall any contract entered into by the
County be required to contain any provision for waiver.
(b) Privileges and Immunities. All of the privileges and immunities from liability,
exemptions from laws, ordinances, and rules and pensions and relief, disability, workers'
FY 2011 Funding — 2"d round
Kitchen and Restroom Facilities
Contract ID#: 856
E�
compensation, and other benefits which apply to the activity of officers, agents, or
employees of any public agents or employees of the County, when performing their
respective functions under this Agreement within the territorial limits of the County shall
apply to the same degree and extent to the performance of such functions and duties of
such officers, agents, volunteers, or employees outside the territorial limits of the County.
10. NONDISCRIMINATION. County and Grantee agree that there will be no
discrimination against any person, and it is expressly understood that upon a
determination by a court of competent jurisdiction that discrimination has occurred, this
Agreement automatically terminates without any further action on the part of any party,
effective the date of the court order. County or Grantee agree to comply with all Federal
and Florida statutes, and all local ordinances, as applicable, relating to nondiscrimination.
These include but are not limited to: 1) Title VI of the Civil Rights Act of 1964 (PL 88-352)
which prohibits discrimination on the basis of race, color or national origin; 2) Title IX of the
Education Amendment of 1972, as amended (20 USC ss. 1681-1683, and 1685-1686),
which prohibits discrimination on the basis of sex; 3) Section 504 of the Rehabilitation Act
of 1973, as amended (20 USC s. 794), which prohibits discrimination on the basis of
handicaps; 4) The Age Discrimination Act of 1975, as amended (42 USC ss. 6101-6107)
which prohibits discrimination on the basis of age; 5) The Drug Abuse Office and
Treatment Act of 1972 (PL 92-255), as amended, relating to nondiscrimination on the basis
of drug abuse; 6) The Comprehensive Alcohol Abuse and Alcoholism Prevention,
Treatment and Rehabilitation Act of 1970 (PL 91-616), as amended, relating to
nondiscrimination on the basis of alcohol abuse or alcoholism; 7) The Public Health
Service Act of 1912, ss. 523 and 527 (42 USC ss. 690dd-3 and 290ee-3), as amended,
relating to confidentiality of alcohol and drug abuse patent records; 8) Title VIII of the Civil
Rights Act of 1968 (42 USC s. et seq.), as amended, relating to nondiscrimination in the
sale, rental or financing of housing; 9) The Americans with Disabilities Act of 1990 (42
USC s. 1201 Note), as maybe amended from time to time, relating to nondiscrimination on
the basis of disability; 10) Any other nondiscrimination provisions in any Federal or state
statutes which may apply to the parties to, or the subject matter of, this Agreement.
11. ANTI -KICKBACK. The Grantee warrants that no person has been employed or
retained to solicit or secure this Agreement upon an agreement or understanding for a
commission, percentage, brokerage or contingent fee, and that no employee or officer of
the County or TDC has any interest, financially or otherwise, in the said funded project,
except for general membership. For breach or violation of this warranty, the Grantor shall
have the right to annul this Agreement without liability or, in its discretion, to deduct from
the Agreement price or consideration, the full amount of such commission, percentage,
brokerage or contingent fee.
12. TERMINATION. This Agreement shall terminate on September 30, 2011.
Termination prior thereto shall occur whenever funds cannot be obtained or cannot be
continued at a level sufficient to allow for the continuation of this Agreement pursuant to
the terms herein. In the event that funds cannot be continued at a level sufficient to allow
the continuation of this Agreement pursuant to the terms specified herein, this Agreement
FY 2011 Funding - 2"d round
Kitchen and Restroom Facilities
Contract ID#: 856
60]
may then be terminated immediately by written notice of termination delivered in person or
by mail to Grantee. The Grantor may terminate this Agreement without cause upon giving
written notice of termination to Applicant. The Grantor shall not be obligated to pay for any
services or goods provided by Grantee after Grantee has received written notice of
termination.
13. TERMINATION FOR BREACH. The Grantor may immediately terminate this
Agreement for any breach of the terms contained herein. Such termination shall take
place immediately upon receipt of written notice of said termination. Any waiver of any
breach of covenants herein contained to be kept and performed by Grantee shall not be
deemed or considered as a continuing waiver and shall not operate to bar or prevent the
Grantor from declaring a forfeiture for any succeeding breach either of the same conditions
or of any other conditions. Failure to provide Grantor with certification of use of matching
funds or matching in -kind services at or above the rate of request for reimbursement or
payment is a breach of Agreement, for which the Grantor may terminate this Agreement
upon giving written notification of termination.
14. ENTIRE AGREEMENT. This Agreement constitutes the entire Agreement of the
parties hereto with respect to the subject matter hereof and supersedes any and all prior
Agreements with respect to such subject matter between the Grantee and the Grantor.
15. GOVERNING LAW, VENUE, INTERPRETATION, COSTS, AND FEES.
This Agreement shall be governed by and construed in accordance with the laws of the
State of Florida applicable to contracts made and to be performed entirely in the State.
This Agreement is not subject to arbitration. Mediation proceedings initiated and
conducted pursuant to this Agreement shall be in accordance with the Florida Rules of
Civil Procedure and usual and customary procedures required by the circuit court of
Monroe County.
(a) Venue. In the event that any cause of action or administrative proceeding is
instituted for the enforcement or interpretation of this Agreement, the County and Grantee
agree that venue shall lie in the appropriate court or before the appropriate administrative
body in Monroe County, Florida.
(b) Severability. If any term, covenant, condition or provision of this Agreement (or the
application thereof to any circumstance or person) shall be declared invalid or
unenforceable to any extent by a court of competent jurisdiction, the remaining terms,
covenants, conditions and provisions of this Agreement, shall not be affected thereby; and
each remaining term, covenant, condition and provision of this Agreement shall be valid
and shall be enforceable to the fullest extent permitted by law unless the enforcement of
the remaining terms, covenants, conditions and provisions of this Agreement would
prevent the accomplishment of the original intent of this Agreement. The County and
Grantee agree to reform the Agreement to replace any stricken provision with a valid
provision that comes as close as possible to the intent of the stricken provision.
FY 2011 Funding - 2"d round
Kitchen and Restroom Facilities
Contract ID#. 856
10
(c) Attorney's Fees and Costs. The County and Grantee agree that in the event any
cause of action or administrative proceeding is initiated or defended by any party relative
to the enforcement or interpretation of this Agreement, the prevailing party shall be entitled
to reasonable attorney's fees, court costs, investigative, and out-of-pocket expenses, as an
award against the non -prevailing party, and shall include attorney's fees, courts costs,
investigative, and out-of-pocket expenses in appellate proceedings.
(d) Adjudication of Disputes or Disagreements. County and Grantee agree that all
disputes and disagreements shall be attempted to be resolved by meet and confer
sessions between representatives of each of the parties. If the issue or issues are still not
resolved to the satisfaction of the parties, then any party shall have the right to seek such
relief or remedy as may be provided by this Agreement or by Florida law. This agreement
shall not be subject to arbitration.
(e) Cooperation. In the event any administrative or legal proceeding is instituted
against either party relating to the formation, execution, performance, or breach of this
Agreement, County and Grantee agree to participate, to the extent required by the other
party, in all proceedings, hearings, processes, meetings, and other activities related to the
substance of this Agreement or provision of the services under this Agreement. County
and Grantee specifically agree that no party to this Agreement shall be required to enter
into any arbitration proceedings related to this Agreement.
16. ETHICS CLAUSE: Grantee warrants that he has not employed, retained or
otherwise had act on his behalf any former County officer or employee in violation of
Section 2 or Ordinance No. 10-1990 or any County officer or employee in violation of
Section 3 of Ordinance No. 10-1990. For breach or violation of the provision the Grantor
may, at its discretion terminate this Agreement without liability and may also, at its
discretion, deduct from the Agreement or purchase price, or otherwise recover, the full
amount of any fee, commission, percentage, gift, or consideration paid to the former or
present County officer or employee. The County and Grantee warrant that, in respect to
itself, it has neither employed nor retained any company or person, other than a bona fide
employee working solely for it, to solicit or secure this Agreement and that it has not paid
or agreed to pay any person, company, corporation, individual, or firm, other than a bona
fide employee working solely for it, any fee, commission, percentage, gift, or other
consideration contingent upon or resulting from the award or making of this Agreement.
For the breach or violation of the provision, the Grantee agrees that the County shall have
the right to terminate this Agreement without liability and, at its discretion, to offset from
monies owed, or otherwise recover, the full amount of such fee, commission, percentage,
gift, or consideration.
(a) Covenant of No Interest. County and Grantee covenant that neither presently has
any interest, and shall not acquire any interest, which would conflict in any manner or
FY 2011 Funding — 2"d round
Kitchen and Restroom Facilities
Contract ID#: 856
11
degree with its performance under this Agreement, and that only interest of each is to
perform and receive benefits as recited in this Agreement.
(b) Code of Ethics. County agrees that officers and employees of the County recognize
and will be required to comply with the standards of conduct for public officers and
employees as delineated in Section 112.313, Florida Statutes, regarding, but not limited to,
solicitation or acceptance of gifts; doing business with one's agency; unauthorized
compensation; misuse of public position, conflicting employment or contractual
relationship; and disclosure or use of certain information.
17. PUBLIC ENTITY CRIME STATEMENT: A person or affiliate who has been placed
on the convicted vendor list following a conviction for public entity crime may not submit a
bid on an Agreement to provide any goods or services to a public entity, may not submit a
bid on a Agreement with a public entity for the construction or repair of a public building or
public work, may not submit bids on leases of real property to public entity, may not be
awarded or perform work as a contractor, supplier, sub -contractor, or consultant under a
Agreement with any public entity, and may not transact business with any public entity in
excess of the threshold amount provided in Section 287.017, Florida Statutes, for
CATEGORY TWO for a period of 36 months from the date of being placed on the
convicted vendor list. By executing this document grantee warrants that it is in compliance
with this paragraph.
18. AUTHORITY: Grantee warrants that it is authorized by law to engage in the
performance of the activities encompassed by the project herein described. Each of the
signatories for the Grantee below certifies and warrants that the Grantee's name in this
Agreement is the full name as designated in its corporate charter (if a corporation); they
are empowered to act and contract for the Grantee, and this Agreement has been
approved by the Board of Directors of Grantee or other appropriate authority.
19. LICENSING AND PERMITS: Grantee warrants that it shall have, prior to
commencement of work under this Agreement and at all times during said work, all
required licenses and permits whether federal, state, County or City.
20. INSURANCE: Grantee agrees that it maintains in force at its own expense a liability
insurance policy which will insure and indemnify the Grantee and the Grantor from any
suits, claims or actions brought by any person or persons and from all costs and expenses
of litigation brought against the Grantee for such injuries to persons or damage to property
occurring during the Agreement or thereafter that results from performance by Grantee of
the obligations set forth in this Agreement. At all times during the term of this Agreement
and for one year after acceptance of the project, Grantee shall maintain on file with the
Grantor a certificate of the insurance of the carriers showing that the aforesaid insurance
policy is in effect. The following coverage's shall be provided:
1. Workers Compensation insurance as required by Florida Statutes.
FY 2011 Funding — 2nd round
Kitchen and Restroom Facilities
Contract ID#: 856
12
2. Commercial General Liability Insurance with minimum limits of $500,000
Combined Single Limit (CSL) If split limits are provided, the minimum limits acceptable
shall be $250,000 per Person $500,000 per occurrence $50,000 property damage.
3. Comprehensive Auto Liability Insurance with minimum limits of $300,000
combined single limit per occurrence.
The Grantee, the Grantor and the TDC shall be named as additional insured, except
workers compensation. The policies shall provide no less than 30 days notice of
cancellation, non -renewal or reduction of coverage.
Grantee shall provide, to the County, as satisfactory evidence of the required insurance,
including the insurance policy application and either:
• Original Certificate of Insurance
or
• Certified copy of the actual insurance policy
Or
• Certificate of Insurance e-mailed from Insurance Agent/Company to County
Risk Management - Telephone Maria Slavik at (305) 295-3178 for details
(Certificates can be e-mailed directly from the insurance agency to:
Slavik-Maria @ MonroeCounty-FL.Gov — The e-mail must state that this is a
certificate for a TDC project and should be forwarded to Maxine Pacini
at the TDC administrative office)
An original certificate or a certified copy of any or all insurance policies required by
this contract shall be filed with the Clerk of the BOCC prior to the contract being
executed by the Clerks office. The Insurance policy must state that the Monroe
County BOCC and Monroe County TDC is the Certificate Holder and additional
Insured for this contract (certificate only for worker's compensation coverage).
Insurance information should be mailed to:
Monroe County Board of County Commissioners
c/o Risk Management
P.O. Box 1026
Key West, FL 33041
21. NOTICE. Any notice required or permitted under this agreement shall be in writing
and had delivered or mailed, postage prepaid, to the other party by certified mail, returned
receipt requested to the following:
FY 2011 Funding - 2"d round
Kitchen and Restroom Facilities
Contract ID#: 856
13
For Grantee: Loretta Geotis
5101 Overseas Highway
Marathon, FL 33050
For Grantor: Lynda Stuart
Monroe County Tourist Development Council
1201 White Street, Suite 102
Key West, FL 33040
and
Cynthia Hall, Asst. County Attorney
P.O. Box 1026
Key West, FL 33041-1026
22. CLAIMS FOR FEDERAL OR STATE AID. Contractor and County agree
that each shall be, and is, empowered to apply for, seek, and obtain federal and state
funds to further the purpose of this Agreement; provided that all applications, requests,
grant proposals, and funding solicitations shall be approved by each party prior to
submission.
23. NON -DELEGATION OF CONSTITUTIONAL OR STATUTORY DUTIES. This
Agreement is not intended to, nor shall it be construed as, relieving any participating entity
from any obligation or responsibility imposed upon the entity by law except to the extent of
actual and timely performance thereof by any participating entity, in which case the
performance may be offered in satisfaction of the obligation or responsibility. Further, this
Agreement is not intended to, nor shall it be construed as, authorizing the delegation of the
constitutional or statutory duties of the County, except to the extent permitted by the
Florida constitution, state statute, and case law.
24. NON -RELIANCE BY NON-PARTIES. No person or entity shall be entitled to rely
upon the terms, or any of them, of this Agreement to enforce or attempt to enforce any
third -party claim or entitlement to or benefit of any service or program contemplated
hereunder, and the County and the Grantee agree that neither the County nor the Grantee
or any agent, officer, or employee of either shall have the authority to inform, counsel, or
otherwise indicate that any particular individual or group of individuals, entity or entities,
have entitlements or benefits under this Agreement separate and apart, inferior to, or
superior to the community in general or for the purposes contemplated in this Agreement.
25. ATTESTATIONS. Grantee agrees to execute such documents as the County may
reasonably require, to include a Public Entity Crime Statement, an Ethics Statement, and a
Drug -Free Workplace Statement.
26. NO PERSONAL LIABILITY. No covenant or Agreement contained herein shall be
deemed to be a covenant or Agreement of any member, officer, agent or employee of
FY 2011 Funding — 2"d round
Kitchen and Restroom Facilities
Contract ID#. 856
14
Monroe County in his or her individual capacity, and no member, officer, agent or
employee of Monroe County shall be liable personally on this Agreement or be subject to
any personal liability or accountability by reason of the execution of this Agreement.
27. FORCE MAJEURE. The Grantee shall not be liable for delay in performance or
failure to complete the project, in whole or in part, due to the occurrence of any
contingency beyond its control or the control of its contractors and subcontractors,
including war or act of war whether an actual declaration thereof is made or not, act of
terrorism impacting travel in the United States, insurrection, riot or civil commotion, act of
public enemy, epidemic, quarantine restriction, storm, flood, drought or other act of God, or
act of nature (including presence of endangered animal species which cannot be timely
removed in a safe manner or any act of any governmental authority which prohibits the
project from proceeding as described in the scope of services and incorporated references
and which the Grantee has exercised reasonable care in the prevention thereof.
However, lack of planning for normal and expected weather conditions for the time of year
the project is to be executed shall not constitute an act of God excusing a delay. Any
delay or failure due to the causes stated shall not constitute a breach of the Agreement;
however, the BOCC shall have the right to determine if there will be any reduction to the
amount of funds due to the Grantee after consideration of all relevant facts and
circumstances surrounding the delay in performance or failure to complete the project
within the contract period. Upon demand of TDC or BOCC, the Grantee must furnish
evidence of the causes of such delay or failure. BOCC shall not pay for any goods
received or services provided after the date(s) described in paragraph 1 and Scope of
Services.
28. EXECUTION IN COUNTERPARTS. This Agreement may be executed in any
number of counterparts, each of which shall be regarded as an original, all of which taken
together shall constitute one and the same instrument and any of the parties hereto may
execute this Agreement by singing any such counterpart.
29. SECTION HEADINGS. Section headings have been inserted in this Agreement as
a matter of convenience of reference only, and it is agreed that such section headings are
not a part of this Agreement and will not be used in the interpretation of any provision of
this Agreement.
REMAINDER OF PAGE INTENTIONALLY LEFT BLANK
FY 2011 Funding — 2"d round
Kitchen and Restroom Facilities
Contract IDA 856
15
,!
IN WITNESS WHEREOF, the parties
executed the day and year first above written.
Attest:% Qdtft- Kolhage, Clerk
Deputy Clerk
(CORPORATE SEAL)
Attest:
By.
Secretary
Print Name
Date:
OR TWO WITNESSES
(1)
(1)
Print Name
Date:
FY 2011 Funding — 2nd round
Kitchen and Restroom Facilities
Contract IDA SM
hereto have caused this Agreement to be
Board of County Commissioners
The Marathon Community Theatre, Inc-,
16
Pr silent
L I e 1 A l'
Print Name
Date: Z —
(2)
(2)
Print Name
Date:
8
MONR COUNTYATTORNE
APP VED S TO�F
CY THIA L. ALL
ASSISTAN OUNTYATTORNEY
gate.._ f IS - 21911
D
E
O
C
O
L
N
~� U
W
H �
PO
Z I=
W a.
00
Q Q
Z Z
E
o ;°
a
ya
a
u 'o
a=
G� p
o a
o
a� Q
as
E as
pug
6. rn
� •N
a_
3 �
p p
a �
H
0-0
E`
L
p 0
ni
� � E
L°E2
C �
0 p p 0 .0
� 'H 2 E
C = c .�
E ° o:
V) Vl
E
Z c Z �.
LU �
1) a
LU :E :E
LL =
0 C 3
w p aci
cm U E
u—'
Z zl a S
0
0
0
00
0
0
O
O
U
�
U
o
�
>
o
No
O
a�
_
tN
U
U
O
cn
i--
O
C
= u
O N L
s✓ O
v
0
c � ~ '-
�-
N
4
m
n
N U _
Q•cr
E
O
�p
o
sy
d
°1OE�
C:
00
N
7�
V
Q.
t•Q
E
3 o yt
O V
N
=
'3 0
Y O Q
u O
m o
o� H
o a
m
i
O c
C N
m a Q.
•�
Z)N
V
y>
ND
W
d C cif
ooa)
o
WE�,°E�°
•F
N ti-
N
C
Q L
U
� d Q
u
+- Q
t d
•C d 76
V
a
.0 a
a�E�
pu
�c
a
d�ooc
•y o
2 a
0 05
E GN '- y U
Tt O Q
N
m •g
rn- E y
V
C
u? �
NT Q C N
k
�
•�2
C U t
C
y O y d I
m E E y-
+-
O 3
L
O
0 0�
L C
vm= c)o
a� p�
3�s
'-'•°p�2d
U
a O°
V 0 3
'd
Y
N
GO
0
O c y
Z 0 W
C C3 E U w
..� Q 0
0
0
CL
19% Edition
MONROE COUNTY, FLORIDA
Request For Waiver
of
Insurance Requirements
It is requested that the insurance requirements, as specified in the County's Schedule of Insurance
Requirements, be waived or modified on the following contract.
Contractor: Marathon Community Theatre
Contract for:
Address of Contractor: 5101 Overseas Highway, Marathon. Florida 33050
Phone: 305-743-0408
Scope of Work: Update kitchen and add restroom facility in front -of -the -house
Reason for Waiver: Marathon Community Theatre does not own or lease any vehicles
Policies Waiver will
apply to:
Signature of Contractor:
iawq—
Risk Management: //� ��) � I C��l/ S�
Date: ` - 1-11
County Administrator Appeal:
Approved _
Date:
Board of County Commissioners Appeal:
Approved
Meeting Date:
Administration Instruction
#4709.2
Not Approved
Not Approved
Not Approved
OP ID: KK
DATE (MMIDDIYYT'T)
CERTIFICATE OF LIABILITY INSURANCE 03131111
THIS CERTIFICATE 1$ ISSUED AS A MATTER OF IMFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS
CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, W(TEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES
BELOW. THIS CEKnrICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUM INSURER(S). AUTHORIZED
REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER.
IMPORTANT: If the certf' � eft holler is an ADDITIONAL INSURED, the policAies) must be endorsed. N SUBROGATION IS WAIVED, subject to
the terns and conditions of the policy, certain policies may require an endorsement. A stubmnent an this cwbhcata does not confer rights to the
eertlBcab holder In lieu of such s .
►RODU 30di-28"213 T
ER
Tha Johnsone Insurance Agency (A► r+.1 _
��I13M OOasahHighway Ac
nMm.u ADDRESS:.MMAT-4
MMMMM APPaRoxro CMERAGE MAIL ■
■AWRED Marathon Community Theatre PIS~ A; Burfl Insurance COm
ATTN: LORETTA GEOTIS mmiam a: Florida Retail Federation
P.O. Box $00124 srsuRoe c
Marathon, FL -1
NNSUPIER Ds— —•— -._.. _.. _ ..--
IMSURER E
INSURM F r
wwu�w. wrw A�er.oA rc w.uo�o. DEWMAAIY YIIY06�•
THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD
INDICATED. NOTWITHSTANDING ANY REQURENENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS
CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS,
EXCLUSIONS AND CONDITIONS OF SUCH POLICIES- LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIM&
MER rift OF IN9URN41 - _ POLICY IHIMlER ---OUNDDITTYn Ir LINTS
cEMEaAL waLlrr
EACH oceURROICE
S 1,000.0001
= 100,00
A
X COMMERCIAL GENERAL LVMUTY
X
2998004963
10127110
10127111
MM EXP (Aar arse parmn)
i 6.
CUUM& AADE r ^ r OCCUR
PERSONAL aADVINJURY
s 1,8N.04
GENERAL AGGREGATE
f 100,
GEM AGGREGATE LIAR APPLIES PER:
PRODUCTS- COMPIOP AGG
s INCLUDE
3
F_jPRO- LOC
AUT011100ILE UAMLITr
ANY AUTO
(fin
COMBINED SINGLE LIMB
(E� A.DrirleaU
9
BODILY INJURY (Per person)
$
ALL OWNED AUTOS
SCHEOULEO AUTOS
HIRED AUTOS
11� �
3
J
e00ILY INJURY (PR accidww
_
PROPERTY DAMAGE ...
(
Ni
i
i
NON-0WWO AUTOS
]�
=
l
LLA UAII
EACH OCCURRENCE
S
A00MOATE
$
EXCE33 Wie
CLAIMs MADE
DEDUCTIBLE
i
S
I
-RETENTION
WOMERS CMIDEMSATIDM
WC STATU- I OTH•
I ER
LlMrM
TORYACCIDENT
B
AND E WL0YM' LuUNM
ANY PROPRIETORA?ARTNERAFxECUTnrt TIN
OFFICERNEMBER EXCLUDED?
IMerrdelarr b NIq
N / A
19475
01/01/11
01101/12
EL. EACH
t . 100,0
f 1001
CIL, OISGASE - EA EMPLOYEE
E.L.. ol3FwsE - POLICY L■ieT
s
II yyeess, "
OESCder�fEenear RA edw
rommembi APPfta
I I
I
i -
j
DE9CItlPT10N OF OPS1111 ONi r LOCATMA I VEHICLES UlMedr I CORD 101, Addlller A A■n■Irft Ikb Wuls, M mw* Is hAllabvd)
Movie Theatre S Llve ThealreTHEATRE - OTHER THAN NOT FOR PROFIT
rental hall
Monroe County Board of County
Commissions
C/o risk management
PO Box1026
Key West FL 33041-1026
MONRO2g
SHOULD ANY OF THE ABOVE DESCRIBED POUCES BE CANCELLED BEFORE
THE EXpWATNON DATE THEREOF. NOTICE MLL BE DELIVI!RED IN
ACCORDANCE uMTH THE POLICY PROVISIONS,
® I9S6-ZUUV AGVKY GVKr'VKA I IVPN. All ngnp■ FV""Vea-
ACORD 25 (20M09) The ACORD name and logo are registered marks of ACORD
OP ID: KK
CERTIFICATE OF LIABILITY INSURANCE DAT03131DlTTTT)
111
TM CERTIFN;ATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE FIOLOM THIS
CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES
BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER M AUTHORIZED
REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLOER.
IMPORTANT: If the ooR) m* holder is an ADDITIONAL INSURED, the pol"low) must be endorsed. ff SUBROGATION 18 WAIVED, subject to
Ow terms and conditions of the policy, certain policlee may require an endorsement. A statement on this certificate does not confer ragha to the
PRODUCrrit 3054894M3
On Johnsons Irwrance Agency
Z;IOverseas Fighway
Maratlgn, FL 33050
sen�n �sr.a■.v. rrwrwve+.
,anromM.IO II; MARAT4
SMUMMMAIVORMOCOVIIIIIIAM NAIL x
MauRED ftmthon Community Theatre INSURER A : Burn Insurance Cmpwq
ATTN: LORETTA GEOTIS MNBuR a: Rxida Retail Federation
P.O. Box SM124 MNgumm c :
Marathon, FL 33050
NNiURER E • .
N1eURER F :
wv�w�w�a NCIb'r CY`wTmica QSNISIEIM NIl1BgER•
THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD
INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS
CERTIFICATE MAY BE ISSUED OR MAY PERTAIN. THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS.
EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAMS.
SISR TYPE OF INSURANCE POLICY NUYSER POLICY EFF PpLIGII O[P Lem
TRIL
A
GEMMRAL LIAbN.ITY
X COM MERCIAL GENERAL LIABILITY
CLAIMS -MADE u OCCUR
GEN•LAGGREGATELIMITAPPLIESPER:
POLICY PRO• LOC
X
I=
211190004993
1W27MO
IW27111
EACH OCCURRENCE
f 1,000,
-E0316ES.(E8 eaall►F- ).-._
MED ExP Wn one pmm
5 100,
$ 5,
PERSONAL A ADV INJURY
5 1,000,
OENERALAGGREGATE
I 1.0111111.
PRODUCTS. COMPTF AGG
5 INCLUDE
AUIOYOBLE
W WLrTr
ANY AUTO
ALL OWNED AUTOS
SCNEOULED AUTOS
HIREDAUTQ$
NON-OWNEDAUTOS
'
COMBINED SINGLE LIMIT
$
BOOZY MIJURY (Per poor)
S
SODLY INJURY (Per neOdW#)
5
PROPERTY DAMAGE
(PW-&&Wt)
:
UMBRELLA UAa
ExCEss UAe
OCCUR
cLAIMS'.M ADE
EACH OCCURRENCE
5•_.. _ .. _
S _
S
AGGREGATE
DEDUCTELE
RETENTION:
B
WOMERS COMPENSATION
AND EMPLOYERS• LIIUNLn Y
ANY PR�RIETORIPARTNERIMCVTNE YI—I
OPFK*Td EMQER EXCLUDED?
IM��lNl!aeleell In NK)
DESCRW'TION OF OPERATIONS below
N ! A
62019475
01101MI
01/01112
WG STATU- OTH-
TORT, LIM7S
E.L. EACH ACCIDENT
$ 10010
EL DMEAW - EA EMPLOYE
5 1 0,
E.L. CKMASE - POLICY LINYT
S �
Commemial Appllp
BEsCAWT10N OF OPERATMM I LOCATIONS ! VE=LEs (A+MIft ACORD 91. AtlII*WI Reru - IeMdeM, N NIIeP1 fOw le eegrNW)
Movie Theatre A Live ThNobvTHEATRE - OTHER THAN NOT FOR PROFIT
rental hall
TOURIa
SHOULD ANY OF THE ABOVE Ug$CpjoW POUC1E8 BE CANCM.LED BEFORE
Tourist Dwelopemerlt COUnGII THE EXPWAT10N DATE THEREOF, NOTICE WI.L BE DELIVERED IN
ou st De l pemSWO 102 ACCO IMTH THE voter PROVISION$.
Key West, FL 33040
M 16084M ACORD CORPORATION, AN rights reserved.
ACORD 25 (2009109) The ACORD name and logo are registered marks of ACORD