Loading...
FY2014 05/21/2014 2nd RoundAMY HEAVILIN, CPA CLERK OF CIRCUR COURT &COMPTROLLER MowroE couim, FLORIDA DATE: June 4, 2014 TO: Lynda Stuart, Office Manager Tourist Development Council ATTN. • Maxine Pacini Administrative Assistant FROM: Lindsey Ballard, D. C. VV At the May 21, 2014, Board of County Commissioner's meeting the Board granted approval and authorized execution of the following items: Item D1 Amendment to Agreement with the Islamorada Chamber of Commerce, Inc. to exercise option to extend agreement for two (2) additional years to September 30, 2016 with a five (5) percent increase in compensation for Visitor Information Services ( "VIS "), and revised public records language. Item D2 Amendment to agreement with the Key Largo Chamber of Commerce, Inc. to exercise option to extend agreement for two (2) additional years to September 30, 2016 with a five (5) percent increase in compensation for Visitor Information Services ( "VIS "), and revised public records language. Item D3 Amendment to agreement with the Lower Keys Chamber of Commerce, Inc. to exercise option to extend agreement for two (2) additional years to September 30, 2016 with a five (5) percent increase in compensation for Visitor Information Services ( "VIS "), and revised public records language. Item D4 Amendment to agreement with the Greater Marathon Chamber of Commerce, Inc. to exercise option to extend agreement for two (2) additional years to September 30, 2016 with a five (5) percent increase in compensation for Visitor Information Services ( "VIS "), and revised public records language. Item D5 Amendment to agreement with the Greater Key West Chamber of Commerce, Inc. to exercise option to extend agreement for two (2) additional years to September 30, 2016 with a five (5) percent increase in compensation for Visitor Information Services ( "VIS "), and revised public records language. Item D6 Amendment to Agreement with the City of Key West for the Rest Beach Renourishment project (in an amount not to exceed $245,000), to extend termination date to September 30, 2015. Item D7 Amendment to Agreement with the City of Key West for the Rest Beach Renourishment project (in an amount not to exceed $207,000), to extend termination date to September 30, 2015. 500 Whitehead Street Suite 101, PO Box 1980, Key West FL 33040 Phone: 305- 295 -3130 Fax. 305- 295 -3663 3117 Overseas Highway, Marathon, FL 33050 Phone: 305- 289 -6027 Fax: 305 - 289 -6025 88820 Overseas Highway, Plantation Key, FL 33070 Phone: 852 -7145 Fax. 305 - 852 -7146 Item D8 Agreement with The Key West Harry S. Truman Foundation, Inc. to cover the Truman Little White House Kitchen Restoration, Lawn Lighting, Paving project in an amount not to exceed $19,500, DAC I, FY 2014 Capital Resources. Item D9 Agreement with The Florida Keys History of Diving Museum, Inc. to cover the Dive Museum Exhibit Enhancement project in an amount not to exceed $37,603, DAC IV, FY 2014 Capital Resources. Item D10 Agreement with Key West Art and Historical Society, Inc. to cover the Custom House Fire Protection Improvements Project in an amount not to exceed $20,912, DAC I, FY 2014 Capital Resources. Item D11 Agreement with City of Marathon to cover the Sombrero Beach Park: Replace Sand in Volleyball courts & Landscaping Improvements project in an amount not to exceed $25,000, DAC III, FY 2014 Capital Resources. Item D12 Agreement with City of Marathon to cover the Marathon Oceanfront Park Phase 4: Road Paving, Safety Elements & Commercial Fishing Monument project in an amount not to exceed $150,000, DAC III, FY 2014 Capital Resources. Item D13 Agreement with Key West Art and Historical Society, Inc. to cover the Custom House Major & Minor Electrical Repairs project in an amount not to exceed $21,011, DAC 1, FY 2014 Capital Resources. Item D14 Agreement with Key West Botanical Garden Society, Inc. to cover the Key West Botanical Garden Security and Accessibility, Phase 3 project in an amount not to exceed $24,900, DAC I, FY 2014 Capital Resources. Item D15 Amendment to Agreement with Smith Travel Research, Inc. to provide for additional Public Records language as required by Florida Statute 119.0701. Item D16 Agreement with Dolphin Research Center, Inc. to cover the Replace Ice Machine project in an amount not to exceed $4,500, DAC III, FY 2014 Capital Resources. Item D17 Agreement with Dolphin Research Center, Inc. to cover the DRC Construct Dolphin & Sea Lion Shade structures project in an amount not to exceed $40,000, DAC III, FY 2014 Capital Resources. Item D18 Agreement with Dolphin Research Center, Inc. to cover the DRC Install UV Sanitizer in Sprayground project in an amount not to exceed $10,000, DAC III, FY 2014 Capital Resources. Item D19 Agreement with The Studios of Key West, Inc. to cover the Scottish Rite Masonic Center Elevator, Wiring, Stairway Renovation project in an amount not to exceed $151,000, DAC I, FY 2014 Capital Resources. Item D20 Agreement with The Coral Restoration Foundation, Inc. to cover the Coral Reef Restoration — Marathon, Islamorada and Key Largo Waters in an amount not to exceed $115,276 (DAC III - $25,450, DAC IV = $30,013, DAC V = $59,813), FY 2014 Capital Resources. 500 Whitehead Street Suite 101, PO Box 1980, Key West, FL 33040 Phone: 305 -295 -3130 Fax. 305 -295 -3663 3117 Overseas Highway, Marathon, FL 33050 Phone: 305 - 289 -6027 Fax: 305 - 289 -6025 88820 Overseas Highway, Plantation Key, FL 33070 Phone: 852 -7145 Fax: 305 - 852 -7146 Item D21 Rescind the fishing agreement with Charlie's Coconuts, LLC, for the Coconuts Dolphin Tournament due to the event Contractor cancelling the event. Item D22 One (1) "At Large" appointment to the Tourist Development Council District II Advisory Committee. Attached is a duplicate original of the above mentioned for your handling. Should you have any questions, please feel free to contact our office. Thank you. cc: County Attorney Finance File 500 Whitehead Street Suite 101, PO Box 1980, Key West FL 33040 Phone: 305- 295 -3130 Fax: 305 - 295 -3663 3117 Overseas Highway, Marathon, FL 33050 Phone: 305 - 289 -6027 Fax. 305- 289 -6025 88820 Overseas Highway, Plantation Key, FL 33070 Phone: 852 -7145 Fax: 305- 852 -7146 Inter -local Grant Award Aureement THIS AGREEMENT (agreement) s entered into this �O y of 9 ) e Y 2014 by and between MONROE COUNTY, a political subdivision of the State of Florida (County or Grantor) and City of Marathon a Government organized and operating under the laws of the state of Florida (Grantee). WHEREAS, the district pennies of Tourist Development Tax may be used to acquire, construct, extend, enlarge, remodel, repair, improve, or promote one or more publicly owned and operated convention centers, sports stadiums, sports arenas, coliseums, or auditoriums within the boundaries of the county or subcounty special taxing district in which the tax is levied; aquariums or museums that are publicly owned and operated or owned and operated by not - for - profit organizations and open to the public, within the boundaries of the county or subcounty special taxing district in which the tax is levied; or zoological parks, fishing piers or nature centers which are public owned and operated and operated by not - for - profit organizations; and to finance beach park facilities or beach improvement, maintenance, re- nourishment, restoration, and erosion control. WHEREAS, Grantee has applied to TDC District III for funding for the Oceanfront Park Phase 4: Road Paving, Safety Elements and Commercial Fishing Monument project; and WHEREAS, the Grantor and Tourist Development Council (TDC) have determined that it is in the best interest of the County, for purposes of promoting tourism and preserving the heritage of the community, to attract tourists, and improve the property for use as a beach or beach park facility open to the public; NOW, THEREFORE, in consideration of the mutual covenants and payments contained herein, the Grantee and the Grantor have entered into this agreement on the terms and conditions as set forth below. 1. GRANT AGREEMENT PERIOD. This agreement is for the period of May 21, 2014 through to September 30, 2015. This agreement shall remain in effect for the stated period unless one party gives to the other written notification of termination pursuant to and in compliance with paragraphs 7, 12 or 13 below. 2. SCOPE OF AGREEMENT. The representations made by the Grantee in its proposal submitted to the TDC are incorporated herein by reference. The Grantee shall provide the following scope of services: Materials and labor required to complete the project. Segment(s) of the work is /are more particularly described in Exhibit A, detailing the work and the cost allocable to each segment, attached hereto, and incorporated herein by reference. Anything not referenced within Exhibit A will not be reimbursed. All work for which grant funds are to be expended must be completed by the stated termination date of September 30, 2015 and all invoices pertaining to this project shall be submitted to the Finance Department of Monroe County no later than September 30, 2015 to be City of Marathon — Oceanfront Park FY 2014 Funding — 2" Round Contract ID #: 1336 MP /LS 3114 considered for payment. Acknowledgement Grantee shall be required to permanently display and maintain at Grantee's expense, public acknowledgement of the support of the Monroe County Tourist Development Council in a publicly prominent area of their facility in the following form: "This project was made possible with the financial support of the Monroe County Tourist Development Council." If the Grantee has already complied with this requirement through previous funding, said acknowledgement fulfills this condition. A photograph of said acknowledgment shall be provided with the final request for reimbursement outlined in Exhibit A of this agreement. a.) There shall be a project manager to acknowledge receipt of goods or work performed. This Project Manager shall be Debra London, 9805 Overseas Highway, Marathon, FL 33050 (Tel: (305) 289 - 4103 /Email: londond @ci.marathon.fl.us). Should there be a change in the project manager specified in the Grantee's application, a new project manager shall be designated, and notice with new contact information shall be provided in writing to the TDC administrative office. b.) If, and to the extent that, Grantee contracts for any of the work funded under this agreement to be performed or completed, Grantee shall give notice to County of the contractual relationship, provide County with a copy of any and all contracts and shall require the contractor(s) to comply with all the terms of this contract. Should Grantee contract the work and then decrease the scope of work to be performed by a contractor, Grantee shall provide County with an amended contract executed by Grantee and its contractor. (i) A Grantee which is a governmental entity shall comply with the procurement regulations and policies to which it is subject, and shall provide Grantor documentation of the procurement requirements applicable to the project and compliance therewith. (ii) A Grantee which is a not - for - profit entity shall use procurement processes for those parts of the project to be contracted (not performed by the entity's employees) as follows. For work expected to be under $50,000, the not - for - profit shall document in the file two written quotes or a notarized statement as to why such written quotes were not feasible for the goods or services. For work expected to be $50,000 or more, a competitive bid process must be performed following Monroe County's procurement policies and procedures must be followed, unless the commodities or services will be provided by a "sole source" provider, in which case the not - for -profit must submit a notarized statement with its request for payment explaining why the vendor is the only source for the commodities or services. c.) Grantee shall exercise good internal controls to assure that the project as described in the funding application shall be completed on a timely basis within the proposed budget and shall provide to County any certifications, including those by the architect, engineer, contractor or an independent consultant if necessary, required to establish that materials which are purported to be applied to the project City of Marathon — Oceanfront Park FY 2014 Funding — 2" Round Contract ID #: 1336 MP /LS 3/14 2 are in fact so applied. Further verification shall be required to show that equipment and other fixtures and personal property covered by this agreement are delivered to and installed in the project site. When any permit is required by any governmental agency, copies of plans and other documents which are submitted to the applicable agency shall be submitted to the County Engineering Division to enable verification that the scope of services under this agreement has been provided. 3. AMOUNT OF AGREEMENT AND PAYMENT. The Grantor shall provide an amount not to exceed $150,000 (TDC District III funding) for materials and services used to improve the property. Reimbursement request must show that Grantee has paid in full for materials and services relating to the segment prior to seeking the 50% (fifty percent) reimbursement from Grantor. Payment shall be 50% (fifty percent) reimbursement of the total cost of the segment, subject to the cap on expenditures for that segment as set forth in Exhibit A. Reimbursement can be sought after each segment of the agreement is completed and signed by the Monroe County Engineering Department as outlined in 3.a. The Board of County Commissioners and the Tourist Development Council assume no liability to fund this agreement for an amount in excess of this award. Monroe County's performance and obligation to pay under this agreement is contingent upon an annual appropriation by the BOCC. a.) Payment shall be made upon the completion of a specific segment as outlined in the Scope of Services and Exhibit A. Payment for expenditures permissible by law and County policies shall be made through reimbursement to Grantee upon presentation of Application for Payment Summary, AIA Document G702 or similar certification as required below for governmental entities and not -for- profit entities, invoices, canceled checks and other documentation necessary to support a claim for reimbursement. Included in said documentation shall be proof that the Grantee has received the property, real or personal, for each segment of agreement as outlined in Exhibit A and paid an amount equal to or greater than the amount invoiced to the Grantor. It shall be necessary for the Grantee to contact the County Engineering Division and to arrange for inspection upon the completion of each segment. The documentation needed to support the payment request shall be in the form necessary for submission and available to the County Engineer at the time of inspection. All submissions for payment shall have a proposed schedule of values for segment(s) and indicate the percentage of completion of the overall project as of the submission. This document should be signed by the project architect, engineer, general contractor or project manager. Photos of the progress of the work shall also be submitted with the payment application. It shall be the responsibility of the project architect, engineer, general contractor or project manager to initiate the communication with the Monroe County Engineering Division to facilitate the inspection of the segment of the project. All submissions requesting payment shall be approved in writing, and signed, by the Monroe County Engineering Division as to the completion of the segment of the project for which payment is requested. The application for payment document must be certified through a statement signed by an officer of the organization and notarized, declaring that representations in the invoice are true and factual. Grantee shall also City of Marathon — Oceanfront Park FY 2014 Funding — 2" Round Contract ID #. 1336 MP /LS 3/14 3 provide partial releases of liens or certifications of non -lien if applicable. Grantor shall retain 10% of any payment on work in progress until the Grantee has provided a Final Release of Lien for each vendor /contractor for whom payment is requested. For projects exceeding $50,000 in TDC funding under this agreement, final payment will not be made until the following documents are complete and submitted to the Grantor: AIA Document G -702 Application for Payment Summary AIA Document G -704 Certificate of Substantial Completion AIA Document G -706 Contractor's Affidavit of Debts & Claims AIA Document G -706A Contractor's Affidavit of Release of Liens AIA Document G -707 Consent of Surety to Final Payment (when applicable) Final Release of Lien or Affidavit and Partial Release of Lien For projects for which TDC funding under this agreement is $50,000 or less, the AIA documentation is not required, but sufficient documentation must be submitted to County to provide similar assurances that the work has been completed and contractors /suppliers paid. All payment requests must be submitted no later than September 30, 2015. Invoices received after September 30, 2015 will not be considered for payment. b.) If in -kind services were noted within your application, and you are applying them to this project, documentation shall be submitted to the TDC Administrative Office. to show the receipt and application of in -kind donations of goods, professional services, and materials. Said documentation should include invoices, bills of lading, etc., and be verified as received and applied to the project through a notarized statement of the project architect, engineer, general contractor or project manager. The receipt and application to the project of volunteer labor are to be documented and verified by notarized signature of the project architect, engineer, general contractor, or project manager, and said documentation submitted to the TDC Administrative Office. All submissions shall identify the items included in Exhibit A and Grantee shall complete the Application for Payment form which is provided within the payment/reimbursement kit provided to the Grantee, listing the schedule of values which are sought to be reimbursed and shall indicate the percentage of completion of the overall project as of the submission. This document should be signed by the project architect, engineer, general contractor or project manager. Photographs showing progress on project shall be included in any payment request. The Project Manager shall certify delivery to the project site and installation therein of any goods or services provided other than through an architect, engineer or contractor. All work performed and goods received on site and incorporated into the project shall be verified by one of the foregoing. Submission of any documentation which is untrue, falsified, or otherwise misrepresents the work which has been City of Marathon — Oceanfront Park FY 2014 Funding — 2" Round Contract ID #. 1336 MP /LS 314 4 completed, paid, or donated shall constitute a breach of agreement, for which breach the contract may be immediately terminated at the discretion of the County, whose decision shall be final. c.) At any time that the documentation requirement policies of Monroe County are revised, such as to require annual inventory reports for equipment purchased under a TDC capital project grant, Grantee shall comply thereafter with such increased requirements, or further funding under the agreement may be terminated by County. d.) Upon successful completion of this Grant agreement, the Grantee may retain ownership of the real and personal property acquired and /or improved with funding under this Grant agreement. However, the Grantee shall maintain, preserve, and operate the property which was acquired or improved under this agreement for the uses and purposes which qualified the Grantee for tourist development tax funding. Grantee shall complete and sign a Property Reporting Form upon request for personal property and forward said completed form to the TDC Administrative Office. Real property acquired or improved through funding under this agreement shall remain dedicated for the purposes set forth herein or for other purposes which promote tourism and ownership of said property shall be retained by the Grantee. The following terms shall apply: (i) The Grantee shall have the use of the property, including both real and personal, acquired with funding under this agreement, at the project site for so long as the facility is operated by Grantee, open to the public, and has a primary purpose of promoting tourism. At such time as any of the conditions in the preceding sentence shall cease to exist, the Grantee shall transfer ownership and possession of equipment and personal property to a local government or another not - for - profit organization which is a facility for which tourist development taxes may be used pursuant to Florida Statute 125.0104 with prior approval from TDC and BOCC. (ii) At any time that the Grantee: (a) elects to stop the project or otherwise decide not to place into service for tourist - related purposes the facility acquired, constructed, or renovated with tourist development tax funding, (b) demolishes the project facility or divests itself of ownership or possession of the real property, or (c) ceases the use of the property with a primary purpose of promoting tourism, Grantee shall, pursuant to the formula set forth hereafter, refund to the County the Tourist Development funding. This provision shall survive the termination date of all other provisions of this contract for a period of ten years. Should the demolition, transfer of ownership, or change to a non - tourist related purpose occur after the facility has been used for tourist - related purposes for at least three (3) years, the amount of refund shall be pro -rated based on a useful life of ten (10) years. City of Marathon — Oceanfront Park FY 2014 Funding — 2 nd Round Contract /D #. 1336 MP /LS 3114 5 (iii) The Grantee is responsible for the implementation of adequate maintenance procedures to keep the real and personal property in good operating condition. (iv) The Grantee is responsible for any loss, damage, or theft of, and any loss, damage or injury caused by the use of, real or personal property or equipment purchased through funding under this agreement. 4. RECORDS AND REPORTS. The Grantee shall keep such records as are necessary to document the performance of the agreement and expenses as incurred, and give access to these records at the request of the TDC, the County, the State of Florida or authorized agents and representatives of said government bodies. The Grantee shall also provide such access to the personal Property and equipment purchased under this agreement. It is the responsibility of the Grantee to maintain appropriate records in accordance with generally accepted accounting principles consistently applied to insure a proper accounting of all funds and expenditures. The Grantee understands that it shall be responsible for repayment of any and all audit exceptions which are identified by the Auditor General for the State of Florida, the Clerk of Court for Monroe County, the Board of County Commissioners for Monroe County, or their agents and representatives. If an audit determines that monies paid to the Grantee pursuant to this agreement were spent for purposes not authorized by this agreement, the Grantee shall repay the monies together with interest calculated pursuant to Sec. 55.03, F.S. running from the date the monies were paid to Grantee. In the event of an audit exception, the current fiscal year grant award or subsequent grant awards will be offset by the amount of the audit exception. In the event the grant is not renewed or supplemented in future years, the Grantee will be billed by the Grantor for the amount of the audit exception and shall promptly repay any audit exception. a.) Public Access. The County and Grantee shall allow and permit reasonable access to, and inspection of, all documents, papers, letters or other materials in its possession or under its control subject to the provisions of Chapter 119, Florida Statutes, and made or received by the County and Grantee in conjunction with this agreement; and the County shall have the right to unilaterally cancel this agreement upon violation of this provision by Grantee. 5. MODIFICATIONS AND AMENDMENTS. Any and all modifications of the terms of this agreement shall be only amended in writing and approved by the Board of County Commissioners for Monroe County. The terms, covenants, conditions, and provisions of this agreement shall bind and inure to the benefit of the County and Grantee and their respective legal representatives, successors, and assigns. 6. INDEPENDENT CONTRACTOR. At all times and for all purposes hereunder, the Grantee is an independent contractor and not an employee of the Board of County Commissioners of Monroe County. No statement contained in this agreement shall be construed as to find the Grantee or any of its employees, contractors, servants or agents City of Marathon — Oceanfront Park FY 2014 Funding — 2" Round Contract ID #. 1336 MP /LS 3/14 6 to the employees of the Board of County Commissioners of Monroe County, and they shall be entitled to none of the rights, privileges or benefits of employees of Monroe County. a.) No Personal Liability. No covenant or agreement contained herein shall be deemed to be a covenant or agreement of any member, officer, agent or employee of Monroe County in his or her individual capacity, and no member, officer, agent or employee of Monroe County shall be liable personally on this agreement or be subject to any personal liability or accountability by reason of the execution of this agreement. 7. COMPLIANCE WITH LAW. In carrying out its obligations under this agreement, the Grantee shall abide by all statutes, ordinances, rules and regulations pertaining to or regulating the provisions of this agreement, including those now in effect and hereafter adopted. Any violation of said statutes, ordinances, rules or regulations shall constitute a material breach of this agreement and shall entitle the Grantor to terminate this agreement immediately upon delivery of written notice of termination to the Grantee. 8. RESTRICTIONS ON AGREEMENTS AGREEMENT. The Grantee shall include in all the following terms: ENTERED PURSUANT TO THIS agreements funded under this agreement a.) Anti - discri mination. Contractor agrees that it will not discriminate against any employees or applicants for employment or against persons for any other benefit or service under this agreement because of their race, color, religion, sex, national origin, or physical or mental handicap where the handicap does not affect the ability of an individual to perform in a position of employment, and to abide by all federal and state laws regarding non - discrimination. b.) Anti - kickback. Contractor warrants that no person has been employed or retained to solicit or secure this agreement upon an agreement or understanding for a commission, percentage, brokerage or contingent fee, and that no employee or officer of the Contractor has any interest, financially or otherwise, in County. For breach or violation of this warranty, the County shall have the right to annul this agreement without liability or, in its discretion, to deduct from the agreement price or consideration, the full amount of such commission, percentage, brokerage or contingent fee. Contractor acknowledges that it is aware that funding for this agreement is available at least in part through the County and that violation of this paragraph may result in the County withdrawing funding for the project. c.) Hold harmless /indemnification. Contractor acknowledges that this agreement is funded at least in part by the County and agrees to indemnify and hold harmless the County and any of its officers and employees from and against any and all claims, liabilities, litigation, causes of action, damages, costs, expenses (including but not limited to fees and expenses arising from any factual investigation, discovery or preparation for litigation), and the payment of any and all of the foregoing or any demands, settlements or judgments (collectively claims) City of Marathon — Oceanfront Park FY 2014 Funding — 2" Round Contract ID #: 1336 MP /LS 3/14 7 arising directly or indirectly from any negligence or criminal conduct on the part of contractor in the performance of the terms of this agreement. The contractor shall immediately give notice to the County of any suit, claim or action made against the contractor that is related to the activity under this agreement, and will cooperate with the County in the investigation arising as a result of any suit, action or claim related to this agreement. d.) Insurance. Contractor agrees that it maintains in force at its own expense a liability insurance policy which will insure and indemnify the contractor and the County from any suits, claims or actions brought by any person or persons and from all costs and expenses of litigation brought against the contractor for such injuries to persons or damage to property occurring during the agreement or thereafter that results from performance by contractor of the obligations set forth in this agreement. At all times during the term of this agreement and for one year after acceptance of the project, contractor shall maintain on file with the County a certificate of the insurance of the carriers showing that the aforesaid insurance policy is in effect. The following coverage's shall be provided: 1. Workers' Compensation insurance as required by Florida Statutes. 2. Commercial General Liability Insurance with minimum limits of $500,000 per occurrence for bodily injury, personal injury and property damage. 3. Comprehensive Auto Liability Insurance with minimum limits of $300,000 combined single limit per occurrence. The contractor, the County and the TDC shall be named as additional insured, exempt workers' compensation. The policies shall provide no less than 30 days notice of cancellation, non - renewal or reduction of coverage. At all times during the term of this agreement and for one year after acceptance of the project, contractor shall maintain on file with the County a certificate of insurance showing that the aforesaid insurance coverage are in effect. e.) Licensing and Permits. Contractor warrants that it shall have, prior to commencement of work under this agreement and at all times during said work, all required licenses and permits whether federal, state, county or city. f.) Right to Audit. The contractor shall keep such records as are necessary to document the performance of the agreement and expenses as incurred, and give access to these records at the request of the TDC, the County, the State of Florida or authorized agents and representatives of said government bodies. 9. HOLD HARMLESS /INDEMNIFICATION. The Grantee hereby agrees to indemnify and hold harmless the BOCC/TDC and the 3406 North Roosevelt Blvd. Corporation or any of its officers and employees from and against any and all claims, liabilities, litigation, City of Marathon — Oceanfront Park FY 2014 Funding — 2" Round Contract ID #: 1336 MP /LS 3114 8 causes of action, damages, costs, expenses (including but not limited to fees and expenses arising from any factual investigation, discovery or preparation for litigation), and the payment of any and all of the foregoing or any demands, settlements or judgments arising directly or indirectly under this agreement. The Grantee shall immediately give notice to the Grantor of any suit, claim or action made against the Grantor that is related to the activity under this agreement, and will cooperate with the Grantor in the investigation arising as a result of any suit, action or claim related to this agreement. a.) Non - Waiver of Immunity. Notwithstanding the provisions of Sec. 768.28, Florida Statutes, the participation of the County and the Grantee in this agreement and the acquisition of any commercial liability insurance coverage, self- insurance coverage, or local government liability insurance pool coverage shall not be deemed a waiver of immunity to the extent of liability coverage, nor shall any contract entered into by the County be required to contain any provision for waiver. b.) Privileges and Immunities. All of the privileges and immunities from liability, exemptions from laws, ordinances, and rules and pensions and relief, disability, workers' compensation, and other benefits which apply to the activity of officers, agents, or employees of any public agents or employees of the County, when performing their respective functions under this agreement within the territorial limits of the County shall apply to the same degree and extent to the performance of such functions and duties of such officers, agents, volunteers, or employees outside the territorial limits of the County. 10. NONDISCRIMINATION. County and Grantee agree that there will be no discrimination against any person, and it is expressly understood that upon a determination by a court of competent jurisdiction that discrimination has occurred, this agreement automatically terminates without any further action on the part of any party, effective the date of the court order. County or Grantee agree to comply with all Federal and Florida statutes, and all local ordinances, as applicable, relating to nondiscrimination. These include but are not limited to: 1) Title VI of the Civil Rights Act of 1964 (PL 88 -352) which prohibits discrimination on the basis of race, color or national origin; 2) Title IX of the Education Amendment of 1972, as amended (20 USC ss. 1681 -1683, and 1685 - 1686), which prohibits discrimination on the basis of sex; 3) Section 504 of the Rehabilitation Act of 1973, as amended (20 USC s. 794), which prohibits discrimination on the basis of handicaps; 4) The Age Discrimination Act of 1975, as amended (42 USC ss. 6101 -6107) which prohibits discrimination on the basis of age; 5) The Drug Abuse Office and Treatment Act of 1972 (PL 92 -255), as amended, relating to nondiscrimination on the basis of drug abuse; 6) The Comprehensive Alcohol Abuse and Alcoholism Prevention, Treatment and Rehabilitation Act of 1970 (PL 91 -616), as amended, relating to nondiscrimination on the basis of alcohol abuse or alcoholism; 7) The Public Health Service Act of 1912, ss. 523 and 527 (42 USC ss. 690dd -3 and 290ee -3), as amended, relating to confidentiality of alcohol and drug abuse patent records; 8) Title VIII of the Civil Rights Act of 1968 (42 USC s. et seq.), as amended, relating to nondiscrimination in the sale, rental or financing of housing; 9) The Americans with Disabilities Act of 1990 (42 USC s. 1201 Note), as maybe amended from time to time, relating to nondiscrimination on City of Marathon — Oceanfront Park FY 2014 Funding — 2" Round Contract ID #: 1336 MP /LS 3114 9 the basis of disability; 10) any other nondiscrimination provisions in any Federal or state statutes which may apply to the parties to, or the subject matter of, this agreement. 11. ANTI - KICKBACK. The Grantee warrants that no person has been employed or retained to solicit or secure this agreement upon an agreement or understanding for a commission, percentage, brokerage or contingent fee, and that no employee or officer of the County or TDC has any interest, financially or otherwise, in the said funded project, except for general membership. For breach or violation of this warranty, the Grantor shall have the right to annul this agreement without liability or, in its discretion, to deduct from the agreement price or consideration, the full amount of such commission, percentage, brokerage or contingent fee. 12. TERMINATION. This agreement shall terminate on September 30, 2015. Termination prior thereto shall occur whenever funds cannot be obtained or cannot be continued at a level sufficient to allow for the continuation of this agreement pursuant to the terms herein. In the event that funds cannot be continued at a level sufficient to allow the continuation of this agreement pursuant to the terms specified herein, this agreement may then be terminated immediately by written notice of termination delivered in person or by mail to Grantee. The Grantor may terminate this agreement without cause upon giving written notice of termination to Grantee. The Grantor shall not be obligated to pay for any services or goods provided by Grantee after Grantee has received written notice of termination. 13. TERMINATION FOR BREACH. The Grantor may immediately terminate this agreement for any breach of the terms contained herein. Such termination shall take place immediately upon receipt of written notice of said termination. Any waiver of any breach of covenants herein contained to be kept and performed by Grantee shall not be deemed or considered as a continuing waiver and shall not operate to bar or prevent the Grantor from declaring a forfeiture for any succeeding breach either of the same conditions or of any other conditions. Failure to provide Grantor with certification of use of matching funds or matching in -kind services at or above the rate of request for reimbursement or payment is a breach of agreement, for which the Grantor may terminate this agreement upon giving written notification of termination. 14. ENTIRE AGREEMENT. This agreement constitutes the entire agreement of the parties hereto with respect to the subject matter hereof and supersedes any and all prior agreements with respect to such subject matter between the Grantee and the Grantor. 15. GOVERNING LAW, VENUE, INTERPRETATION, COSTS, AND FEES. This agreement shall be governed by and construed in accordance with the laws of the State of Florida applicable to contracts made and to be performed entirely in the state. This agreement is not subject to arbitration. Mediation proceedings initiated and conducted pursuant to this agreement shall be in accordance with the Florida Rules of Civil Procedure and usual and customary procedures required by the circuit court of Monroe County. City of Marathon — Oceanfront Park FY 2014 Funding — 2" Round Contract ID #: 1336 MP /LS 3/14 10 a.) Venue. In the event that any cause of action or administrative proceeding is instituted for the enforcement or interpretation of this agreement, the County and Grantee agree that venue shall lie in the appropriate court or before the appropriate administrative body in Monroe County, Florida. b.) Severability. If any term, covenant, condition or provision of this agreement (or the application thereof to any circumstance or person) shall be declared invalid or unenforceable to any extent by a court of competent jurisdiction, the remaining terms, covenants, conditions and provisions of this agreement, shall not be affected thereby; and each remaining term, covenant, condition and provision of this agreement shall be valid and shall be enforceable to the fullest extent permitted by law unless the enforcement of the remaining terms, covenants, conditions and provisions of this agreement would prevent the accomplishment of the original intent of this agreement. The County and Grantee agree to reform the agreement to replace any stricken provision with a valid provision that comes as close as possible to the intent of the stricken provision. c.) Attorney's Fees and Costs. The County and Grantee agree that in the event any cause of action or administrative proceeding is initiated or defended by any party relative to the enforcement or interpretation of this agreement, the prevailing party shall be entitled to reasonable attorney's fees, court costs, investigative, and out -of- pocket expenses, as an award against the non - prevailing party, and shall include attorney's fees, court costs, investigative, and out -of- pocket expenses in appellate proceedings. d.) Adjudication of Disputes or Disagreements. County and Grantee agree that all disputes and disagreements shall be attempted to be resolved by meet and confer sessions between representatives of each of the parties. If the issue or issues are still not resolved to the satisfaction of the parties, then any party shall have the right to seek such relief or remedy as may be provided by this agreement or by Florida law. This agreement shall not be subject to arbitration. e.) Cooperation. In the event any administrative or legal proceeding is instituted against either party relating to the formation, execution, performance, or breach of this agreement, County and Grantee agree to participate, to the extent required by the other party, in all proceedings, hearings, processes, meetings, and other activities related to the substance of this agreement or provision of the services under this agreement. County and Grantee specifically agree that no party to this agreement shall be required to enter into any arbitration proceedings related to this agreement. 16. ETHICS CLAUSE: Grantee warrants that he has not employed, retained or otherwise had act on his behalf any former County officer or employee in violation of Section 2 or Ordinance No. 10 -1990 or any County officer or employee in violation of Section 3 of Ordinance No. 10 -1990. For breach or violation of the provision the Grantor City of Marathon — Oceanfront Park FY 2014 Funding — 2" Round Contract /D #. 1336 MP /LS 3/14 11 may, at its discretion terminate this agreement without liability and may also, at its discretion, deduct from the agreement or purchase price, or otherwise recover, the full amount of any fee, commission, percentage, gift, or consideration paid to the former or present County officer or employee. The County and Grantee warrant that, in respect to itself, it has neither employed nor retained any company or person, other than a bona fide employee working solely for it, to solicit or secure this agreement and that it has not paid or agreed to pay any person, company, corporation, individual, or firm, other than a bona fide employee working solely for it, any fee, commission, percentage, gift, or other consideration contingent upon or resulting from the award or making of this agreement. For the breach or violation of the provision, the Grantee agrees that the County shall have the right to terminate this agreement without liability and, at its discretion, to offset from monies owed, or otherwise recover, the full amount of such fee, commission, percentage, gift, or consideration. a.) Covenant of No Interest. County and Grantee covenant that neither presently has any interest, and shall not acquire any interest, which would conflict in any manner or degree with its performance under this agreement, and that only interest of each is to perform and receive benefits as recited in this agreement. b.) Code of Ethics. County agrees that officers and employees of the County recognize and will be required to comply with the standards of conduct for public officers and employees as delineated in Section 112.313, Florida Statutes, regarding, but not limited to, solicitation or acceptance of gifts; doing business with one's agency; unauthorized compensation; misuse of public position; conflicting employment or contractual relationship; and disclosure or use of certain information. 17. PUBLIC ENTITY CRIME STATEMENT: A person or affiliate who has been placed on the convicted vendor list following a conviction for public entity crime may not submit a bid on an agreement to provide any goods or services to a public entity, may not submit a bid on an agreement with a public entity for the construction or repair of a public building or public work, may not submit bids on leases of real property to public entity, may not be awarded or perform work as a contractor, supplier, sub - contractor, or consultant under an agreement with any public entity, and may not transact business with any public entity in excess of the threshold amount provided in Section 287.017, Florida Statutes, for CATEGORY TWO for a period of 36 months from the date of being placed on the convicted vendor list. By executing this document grantee warrants that it is in compliance with this paragraph. 18. AUTHORITY: Grantee warrants that it is authorized by law to engage in the performance of the activities encompassed by the project herein described. Each of the signatories for the Grantee below certifies and warrants that the Grantee's name in this agreement is the full name as designated in its corporate charter (if a corporation); they are empowered to act and contract for the Grantee; and this agreement has been approved by the Board of Directors of Grantee or other appropriate authority. City of Marathon — Oceanfront Park FY 2014 Funding — 2" Round Contract ID #: 1336 MP /LS 3/14 12 19. LICENSING AND PERMITS: Grantee warrants that it shall have, prior to commencement of work under this agreement and at all times during said work, all required licenses and permits whether federal, state, county or city. 20. INSURANCE: Grantee agrees that it maintains in force at its own expense a liability insurance policy which will insure and indemnify the Grantee and the Grantor from any suits, claims or actions brought by any person or persons and from all costs and expenses of litigation brought against the Grantee for such injuries to persons or damage to property occurring during the agreement or thereafter that results from performance by Grantee of the obligations set forth in this agreement. At all times during the term of this agreement and for one year after acceptance of the project, Grantee shall maintain on file with the Grantor a certificate of the insurance of the carriers showing that the aforesaid insurance policy is in effect. The following coverage's shall be provided: 1. Workers' Compensation insurance as required by Florida Statutes. 2. Commercial General Liability Insurance with minimum limits of $500,000 Combined Single Limit (CSL) If split limits are provided, the minimum limits acceptable shall be $250,000 per Person $500,000 per occurrence $50,000 property damage. 3. Comprehensive Auto Liability Insurance with minimum limits of $300,000 combined single limit per occurrence. The Grantee, the Grantor and the TDC shall be named as additional insured, except workers' compensation. The policies shall provide no less than 30 days notice of cancellation, non - renewal or reduction of coverage. Grantee shall provide to the County, as satisfactory evidence of the required insurance, including the insurance policy application and either: • Original Certificate of Insurance, OR • Certified copy of the actual insurance policy, OR • Certificate of Insurance e- mailed from Insurance Agent/Company to County Risk Management - Telephone Maria Slavik at (305) 295 -3178 for details (Certificates can be e- mailed directly from the insurance agency to: Slavik-Mariae- Mon roeCounty-FL.Gov — The e-mail must state that this is a certificate for a TDC project and should be forwarded to Maxine Pacini at the TDC administrative office) An original certificate or a certified copy of any or all insurance policies required by this contract shall be filed with the Clerk of the BOCC prior to the contract being executed by the Clerk's office. The Insurance policy must state that the Monroe County BOCC and Monroe County TDC is the Certificate Holder and additional Insured for this contract City of Marathon — Oceanfront Park FY 2014 Funding — 2 „ d Round Contract ID #: 1336 MP /LS 3/14 13 (certificate only for workers' compensation coverage). Insurance information should be mailed to: Monroe County Board of County Commissioners c/o Risk Management P.O. Box 1026 Key West, FL 33041 21. NOTICE. Any notice required or permitted under this agreement shall be in writing and had delivered or mailed, postage prepaid, to the other party by certified mail, returned receipt requested to the following: For Grantee: Debra London City of Marathon 9805 Overseas Highway Marathon, FL 33050 For Grantor: Lynda Stuart Monroe County Tourist Development Council 1201 White Street, Suite 102 Key West, FL 33040 and Ms. Christine Limbert- Barrows, Asst. County Attorney P.O. Box 1026 Key West, FL 33041 -1026 22. CLAIMS FOR FEDERAL OR STATE AID. Grantee and County agree that each shall be, and is, empowered to apply for, seek, and obtain federal and state funds to further the purpose of this agreement; provided that all applications, requests, grant proposals, and funding solicitations shall be approved by each party prior to submission. 23. NON - DELEGATION OF CONSTITUTIONAL OR STATUTORY DUTIES. This agreement is not intended to, nor shall it be construed as, relieving any participating entity from any obligation or responsibility imposed upon the entity by law except to the extent of actual and timely performance thereof by any participating entity, in which case the performance may be offered in satisfaction of the obligation or responsibility. Further, this agreement is not intended to, nor shall it be construed as, authorizing the delegation of the constitutional or statutory duties of the County, except to the extent permitted by the Florida constitution, state statute, and case law. 24. NON - RELIANCE BY NON - PARTIES. No person or entity shall be entitled to rely upon the terms, or any of them, of this agreement to enforce or attempt to enforce any third -party claim or entitlement to or benefit of any service or program contemplated hereunder, and the County and the Grantee agree that neither the County nor the Grantee or any agent, officer, or employee of either shall have the authority to inform, counsel, or City of Marathon — Oceanfront Park FY 2014 Funding — 2" Round Contract /D #. 1336 MP /LS 3/14 14 otherwise indicate that any particular individual or group of individuals, entity or entities, have entitlements or benefits under this agreement separate and apart, inferior to, or superior to the community in general or for the purposes contemplated in this agreement. 25. ATTESTATIONS. Grantee agrees to execute such documents as the County may reasonably require, to include a Public Entity Crime Statement, an Ethics Statement, and a Drug -Free Workplace Statement. 26. NO PERSONAL LIABILITY. No covenant or agreement contained herein shall be deemed to be a covenant or agreement of any member, officer, agent or employee of Monroe County in his or her individual capacity, and no member, officer, agent or employee of Monroe County shall be liable personally on this agreement or be subject to any personal liability or accountability by reason of the execution of this agreement. 27. FORCE MAJEURE. The Grantee shall not be liable for delay in performance or failure to complete the project, in whole or in part, due to the occurrence of any contingency beyond its control or the control of its contractors and subcontractors, including war or act of war whether an actual declaration thereof is made or not, act of terrorism impacting travel in the United States, insurrection, riot or civil commotion, act of public enemy, epidemic, quarantine restriction, storm, flood, drought or other act of God, or act of nature (including presence of endangered animal species which cannot be timely removed in a safe manner) or any act of any governmental authority which prohibits the project from proceeding as described in the scope of services and incorporated references and which the Grantee has exercised reasonable care in the prevention thereof. However, lack of planning for normal and expected weather conditions for the time of year the project is to be executed shall not constitute an act of God excusing a delay. Any delay or failure due to the causes stated shall not constitute a breach of the agreement; however, the Grantor shall have the right to determine if there will be any reduction to the amount of funds due to the Grantee after consideration of all relevant facts and circumstances surrounding the delay in performance or failure to complete the project within the contract period. Upon demand of TDC or Grantor, the Grantee must furnish evidence of the causes of such delay or failure. Grantor shall not pay for any goods received or services provided after the date(s) described in paragraph 1 and Scope of Services. 28. EXECUTION IN COUNTERPARTS. This agreement may be executed in any number of counterparts, each of which shall be regarded as an original, all of which taken together shall constitute one and the same instrument and any of the parties hereto may execute this agreement by signing any such counterpart. 29. SECTION HEADINGS. Section headings have been inserted in this agreement as a matter of convenience of reference only, and it is agreed that such section headings are not a part of this agreement and will not be used in the interpretation of any provision of this agreement. 30. MISCELLANEOUS: As used herein, the terms "contract' and "agreement" shall be read interchangeably. City of Marathon — Oceanfront Park FY 2014 Funding — 2" Round Contract ID #: 1336 MP /LS 3/14 15 WHEREOF. do Partin hemb have caused ON am mart do be s aed ow Bd above Milan. kmwft Clark ( CORPORA TE S Agog By. - b , c kauwL, , City Clark luny, c1cwet- P** Mama alm 3 - 1 l-tq DSW Board of County COIri dubrlarra of Morwas County IFF Ckw d N admon 0 z or m:K ocI I c 2 cti. -- t ��a Mayor (k iti'v cm N S cn ill _7- 7 -, r m U0- co~i *f= ie Z uQ r r WUM . r. m rn 0 rn J z 0 pI CO W c r v O U W O LU Q Z U W m$ a _ O_ C O; C Z Q k d .. A y w ,C y w .0 'd V Z O � •O d C � E " 4 c N .0 V 3 d � d O � w C d E O w V C d d O � O � C O o 0. a Q U E :`a V � CL O y Z N ED •b b w N a U- O w c E U d Z zI C� ----------------------------------------------------------------------------------------------------- N } ^ W > 5. .X N �} -v- E •� > of Q �UL= O O N 'C L L } O -I.- U N � C C = U cn o O Vf m 4- O 4- O D U 00 •3���N N N 4 Q c W 3 Zn L o Q 00 �y N CO N CN *k � O z O N •X N O Q vi I T W i X W O O 0 O LO C O O U ------------------------------------------------------------------------------------------------------- a� � cn 00 a C; M O z U o .. O o u r ON E O c V } c.° O C O h E oo °o '�� >£ °° Qa �� �� a `yb..0 U� O 0 U u U U O} N � � N y " t >° O O O N 0� +� O 0) p c a� �.. j O O O u 0 CN 3 �� O � N o �.. D .- �� a N O -0 E 66- O E p G01 c w a C) N — — O O V H - O a O N N O H y b t c H . c U ,� O 0 .0 H O :-0 -0 O c � } c O E c E N 70 O N O N - c O c O t rD O` N O c LL p O C 41-0 „ N D O O C1 �Q C1 N U +- O •U U O G1 O °o o� O °D N O ) 'O O > )o `oca -you a • • • 0 • c u c 0 u O v> U ' ° ° H ° CERTIFICATE OF COVERAGE Certificate Holder Administrator Issue Date 3/7/14 MONROE COUNTY BOARD OF COUNTY COMMISSIONERS Florida League of Cities,Inc. MONROE COUNTY TOURIST DEVELOPMENT COUNCIL Department of Insurance and Financial Services P.O.Box 530065 241 TRUMBO ROAD Orlando,Florida 32853-0065 KEY WEST, FL 33041 COVERAGES THIS IS TO CERTIFY THAT THE AGREEMENT BELOW HAS BEEN ISSUED TO THE DESIGNATED MEMBER FOR THE COVERAGE PERIOD INDICATED.NOTWITHSTANDING ANY REQUIREMENT,TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN,THE COVERAGE AFFORDED BY THE AGREEMENT DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDIONS OF SUCH AGREEMENT COVERAGE PROVIDED BY: FLORIDA MUNICIPAL INSURANCE TRUST AGREEMENT NUMBER: FMIT 0928 COVERAGE PERIOD: FROM 10/1/13 COVERAGE PERIOD: TO 10/1/14 12:01 AM STANDARD TIME TYPE OF COVERAGE-LIABILITY TYPE OF COVERAGE-PROPERTY General Liability ® Buildings ❑X Miscellaneous IDComprehensive General Liability,Bodily Injury,Property Damage, 0 Basic Form Inland Marine Personal Injury and Advertising Injury © Special Form ❑X Electronic Data Processing ❑X Errors and Omissions Liability ❑X Personal Property ❑X Bond Q Employment Practices Liability D Basic Form O Employee Benefits Program Administration Liability ❑X Special Form 0 Medical Attendants'/Medical Directors'Malpractice Liability D Agreed Amount Q Broad Form Property Damage 0 Deductible $5,000 El Law Enforcement Liability © Coinsurance 90% O Underground,Explosion&Collapse Hazard ❑ Blanket • Limits of Liability © Specific *Combined Single Limit 0 Replacement Cost Deductible$1,000 ❑ Actual Cash Value Automobile Liability Limits of Liability on File with Administrator IN All owned Autos(Private Passenger) TYPE OF COVERAGE-WORKERS'COMPENSATION 0 All owned Autos(Other than Private Passenger) IX Statutory Workers'Compensation ❑X Hired Autos 0 Employers Liability $1,000,000 Each Accident ® Non-Owned Autos $1,000,000 By Disease $1,000,000 Aggregate By Disease Limits of Liability ❑ Deductible N/A *Combined Single Limit ❑ SIR Deductible N/A Deductible N/A Automobile/Equipment-Deductible • © Physical Damage Per Schedule-Comprehensive-Auto Per Schedule-Collision-Auto Per Schedule-Miscellaneous Equipment Other *The limit of liability is$200,000 Bodily Injury and/or Property Damage per person or$300,000 Bodily Injury and/or Property Damage per occurrence.These specific limits of liability are increased to$1,000,000(combined single limit)per occurrence,solely for any liability resulting from entry of a claims bill pursuant to Section 768.28(5)Florida Statutes or liability/settlement for which no claims bill has been filed or liability imposed pursuant to Federal Law or actions outside the State of Florida. Description of Operations/Locations/Vehicles/Special Items RE: Grant for Capital Projects: Oceanfront Park Phase 4—engineering,road paving,roadside landscaping,_boulder bollard installation for traffic control,fenced dog run,commercial fishing monument bronze lobsterman for a total project amount of$300,000(50%City match$150,000).Sombrero Beach Park—replenish sand in 2 volleyball courts,uplift and trim trees for proper wind flow,replace vegetation in poor condition,remove exotic invasive plants,add sea oat plantings for erosion ___ control for a total project amount of$50;000(50%City match$25,000). The certificate holder is hereby added as an additional insured,except for Workers'Compensation and Employers Liability,as respects the member's