3rd Amendment 09/17/2014AMY NEAVILIN, CPA
CLERK OF CIRCUIT COURT & COMPTROLLER
WxRIM cWmy aonwa
DATE: October 03, 2014
TO: Kevin Wilson
Project Management
ATTN. Ann Riger
FROM. • Lindsey Ballard, D. CN
At the September 17, 2014, Board of County Commissioner's meeting the Board granted
approval and execution of the following Item C29 Third Amendment to Contract for Professional
Services for the ADA Compliance Segments #1 & #2 Combined Contract with K2M Design, Inc.
adjusting the Architectural fee based on the actual construction costs. This contract is funded from the
one -cent infrastructure tax.
Enclosed is a duplicate original of the above - mentioned for your handling. Should you have any
questions, please feel free to contact our office.
cc: County Attorney
Finance
File
500 Whitehead Street Suite 101, PO Box 1980, Key West, FL 33040 Phone: 305 - 295 -3130 Fax: 305- 295 -3663
3117 Overseas Highway, Marathon, FL 33050 Phone: 305- 289 -6027 Fax. 305 - 289 -6025
88820 Overseas Highway, Plantation Key, FL 33070 Phone: 852 -7145 Fax: 305 - 852 -7146
THIRD AMENDMENT TO CONTRACT FOR PROFESSIONAL SERVICES
BETWEEN OWNER AND ARCHITECT /ENGINEER
FOR ADA COMPLIANCE SEGMENTS #1 & #2 COMBINED, AND
CONSENT TO ASSIGNMENT
This THIRD Amendment to Contract (herein after "Amendment ") between Owner and
Architect /Engineer for Professional Services ( "Contract "), entered into between Monroe County
( "Owner" or "County ") and K2M Design Inc. ( "Architect /Engineer ") for ADA Compliance Segments 1 & 2
Combined, is made and entered into this 17 day of September 2014, in order to amend the Contract as
follows:
W ITN ESSETH
WHEREAS, on December 16, 2009, the parties entered into a continuing contract for Professional
Services, pursuant to Florida Statute 287.055 (2) (g) where services are to be rendered for projects in
which the estimated construction costs of each individual project under the contract does not exceed
Two Million dollars ($2,000,000.00), or for study activity if the fee for Professional Services for each
individual study under the contract does not exceed Two Hundred Thousand Dollars ($200,000.00); and
WHEREAS, on October 16 2013, the parties entered into an Agreement for architectural and
engineering design services to complete the American with Disabilities Act (ADA) Compliance projects
for the existing ADA Compliance Segment #1 and the ADA Compliance Segment #2, which is referred to
as one project identified ad ADA Compliance Segments #1 & #2 Combined; and
WHEREAS, the parties entered into a First Amendment dated November 20, 2013 renewing the
continuing contract for the first of two one -year renewals effective December 16, 2013 and terminating
December 16, 2014; and
WHEREAS, the parties entered into a Second Amendment dated February 19 2014 formally publicly
changing the Architect's name from MBI /K2M Architecture, Inc. to K2M Design Inc.; and
WHEREAS, in accordance to the contract dated October 16, 2013 for Professional Services to complete
the ADA Compliance Segment #1 & #2 Combined project, paragraph 4 (A) stipulates that when the
actual construction cost is known the Architect's fee shall be adjusted either upward or downward;
NOW THEREFORE, in consideration of the mutual promises, covenants and agreements stated herein,
and for other good and valuable consideration, the sufficiency of which hereby acknowledged, the
Owner and Architect agree as follows:
1. Based on the actual construction cost of $689,070 to be paid to the Contractor, architect's
fee shall be adjusted upward at 10% of the actual construction cost or $68,907. Architects
fee therefore increases by $17,918.00, from $50,989.00 to $68,907.00.
2. Paragraph 4 of the Second Amendment to Contract, Consent to Assignment, dated February
2014, shall be deleted in it's entirety.
3. In all other respects, the original Continuing Contract dated December 16, 2009, as renewed
on November 20, 2013, and as Amended on February 19, 2014, and the contract for
Professional Services dated October 16, 2013, shall remain unchanged.
IN WITNESS WHEREOF, each party caused this Agreement to be executed by its duly authorized
written above.
ARCH ITE
By:
K2M Design, Inc.
Date: g•22 ,1c.�
BOARD OF COUNTY COMMISSIONERS
OF MONROE COUNTY, FLORIDA
MONROE COUNTY ATTORNEY
'ROVED AS TO FORM:
NA ILEENE W CASSEL
ASSISTANT COUNTY ATTORNEY
Date
STATE OF FLORIDA
COUNTY QF
aO O his �� day of � , 2014, before me, the undersigned notary public, personally appeared
/T 1 � Ckv n , kn n to me to be the person whose name is subscribed above, or who produced
as identification, and acknowledged that he /she is the person who executed the above Contract
with Monroe County for Professional Services for ADA Compliance Segments #1 & #2 Combined, for the purposes
therein contained.
OTARY LIC
My Commission expires: F`
`lam
DAGMARA SAMUEL
Notary Public, State of Florida
$
Commission # EE 878826
My Comm. expires Feb. 27, 2pt7
I' AMENDMENT TO CONTRACT FOR
PROFESSIONAL SERVICES
BETWEEN OWNER AND ARCHTIECT /ENGINEER
FOR THE EXTENSION OF THE CONTINUING CONTRACT
This First Amendment to Contract (herein after "Amendment ") between Owner and Architect /Engineer
for the Continuing Contract for Professional Services ( "Contract "), entered into between Monroe County
( "Owner" or "County ") and MBI /K2M Architecture, Inc. ( "Architect /Engineer ") is made and entered into
this 20 day of November, 2013, in order to amend the Contract as follows:
WITNESSETH
WHEREAS, on December 16, 2009, the parties entered into a continuing contract for Professional
Services, pursuant to Florida Statute 287.055 (2) (g) where services are to be rendered for projects in
which the estimated construction costs of each individual project under the contract does not exceed
Two Million Dollars ($2,000,000.00), or for study activity if the fee for Professional Services for each
individual study under the contract does not exceed Two Hundred Thousand Dollars ($200,000.00); and
WHEREAS, the Continuing Contract stipulates that a separate contract for each project awarded to the
Architect by the Owner be provided each with specific scopes of work, time schedules, charges and
payment conditions, and additional terms and conditions applicable to that specific contract; and
WHEREAS, in accordance to the Continuing Contract the Professional Services will be for a period of four
years commencing on the date of the contract, with options for the Owner to renew on an annual basis
for two additional one year periods;
NOW THEREFORE, in consideration of the mutual promises, covenants and agreements stated herein,
and for other good and valuable consideration, the sufficiency of which hereby acknowledged, the
Owner and the Architect agree as follows:
1. The Continuing Contract for Professional Services dated December 16, 2009 and terminating on
December 15, 2013, shall be renewed for the first of two one -year periods effective on December 16,
2013 and terminating December 16, 2014.
2. The following shall be added to Article XVII of the original Continuing Contract dated December
16, 2009:
a) Architect shall not disclose, publish, or authorize others to disclose or publish, design data,
drawings, specifications, reports, or other information pertaining to the services performed
by the Architect or other information to which the Architect has had access during the Term
of this Master Agreement without the prior written approval of the County, during the Term
of this Master Agreement and for a period of two (2) years after the termination of this
Master Agreement. Nevertheless, the parties agree that the Architect may use and publish
the County's name and give a general description of the work provided by the Architect for
the purpose of informing other clients and potential clients of the Architect's work
experience and qualifications.
b) Should the County receive a request for documents pursuant to Chapter 119, Florida
Statutes, Architect shall cooperate with the County to facilitate the County's compliance
with Chapter 119, Florida Statutes. Should the Architect assert any exemptions to the
requirements of Chapter 119 and related statutes, the burden of establishing such
exemption, by way of injunctive or other relief as provided by law, shall be upon the
Architect. Failure by the Architect to cooperate with the County in connection with a Public
Records request shall be grounds for immediate unilateral cancellation of this Master
Agreement by the County."
3. In all other respects, the original Continuing Contract dated December 16, 2009 remains
unchanged.
IN WITNESS WHEREOF, each party caused this Agreement to be executed by its duly authorized
representative on the day and year first written above.
MY HEAVILN, CPA, Clerk
4 Deputy Clerk
WITNESS to Architect's
WITNES Sign ure
b Q
Print Witness Name
Date: t S-Z U l3
MONROE COUNTY ATTORNEY
APPROVED AS TO FORM -h
NATILEENE W. CASSEL
ASSISTANT COUNTY ATTORNEY
Date !i • 3 3 `-i 14 A
BOARD OF COUNTY COMMISSIONERS
2' AMENDMENT TO CONTRACT FOR PROFESSIONAL SERVICES
BETWEEN OWNER AND ARCHITECT /ENGINEER
FOR ADA COMPLIANCE SEGMENTS #1 & #2 COMBINED, AND
CONSENT TO ASSIGNMENT
This Second Amendment to Contract (herein after "Amendment") between Owner and
Architect/Engineer for Professional Services ( "Contract "), entered into between Monroe County
( "Owner" or "County ") and MBI /K2M Architecture, Inc., hereafter Assignor, and K2M Design Inc..,
hereafter Assignee, and ( "Architect/Engineer') is made and entered into this 19` day of February 2014,
in order to amend the Contract as follows:
WITNESSETH
WHEREAS, on December 16, 2009, the parties entered into a continuing contract for Professional
Services, pursuant to Florida Statute 287.055 (2) (g) where services are to be rendered for projects in
which the estimated construction costs of each individual project under the contract does not exceed
Two Million dollars ($2,000,000.00), or for study activity if the fee for Professional Services for each
individual study under the contract does not exceed Two Hundred Thousand Dollars ($200,000.00); and
WHEREAS, on October 16 2013, the parties entered into an Agreement for architectural and
engineering design services to complete the American with Disabilities Act (ADA) Compliance projects
for the existing ADA Compliance Segment #1 and the ADA Compliance Segment #2, which is referred to
as one project identified ad ADA Compliance Segments #1 & #2 Combined; and
WHEREAS, the parties entered into a First Amendment dated November 20, 2013 renewing the
continuing contract for the first of two one -year renewals effective December 16, 2013 and terminating
December 16, 2014; and
WHEREAS, effective June 1, 2013 MBI /K2M Architecture, Inc. formally publicly change it's name to K2M
Design Inc.;
NOW THEREFORE, in consideration of the mutual promises, covenants and agreements stated herein,
and for other good and valuable consideration, the sufficiency of which hereby acknowledged, the
Owner and Architect agree as follows:
1. Effective June 1, 2013, the contract for Professional Services for the Marathon Sewer
Connections, between Monroe County and MBI /K2M Architecture, Inc. is amended to
reflect the name change from MBI /K2M Architecture, Inc. to K2M Design, Inc.
2. The Assignee agrees to the changes in Florida Statute 119.0701(2) related to public records
requests which require the Assignee to:
(a) Keep and maintain public records that ordinarily and necessarily would be required by
the public agency in order to perform the service.
(b) Provide the pub1c with access to public records on the same terms and conditions that
the public agency would provide the records and at a cost that does not exceed the cost
provided in this chapter or as otherwise provided by law.
(c) Ensure that public records that are exempt or confidential and exempt from public
records disclosure requirements are not disclosed except as authorized by law.
(d) Meet all requirements for retaining public records and transfer, at no cost, to the public
agency all public records in possession of the contractor upon termination of the
contract and destroy any duplicate public records that are exempt or confidential and
exempt from public records disclosure requirements. All records stored electronically
must be provided to the public agency in a format that is compatible with the
information technology systems of the public agency.
3. Inconsideration for such consent, the Assignee agrees to be bound by all the terms and
conditions of the original agreement, as amended above.
4. In all other respects, the original Contract for Marathon Sewer Connections remains
unchanged.
IN WITNESS WHEREOF, each party caused this Agreement to be executed by its duly authorized
on the day and year first written above.
MY HEAVILIN, CPA, CLERK BOARD OF COUNTY COMMISSIONERS
OF MONROE COUNTY, FLORIDA
r'
r'
By:
Deputy Clerk Mayor /Chairman
WITNESS to Architect's Signature:
By: W By:
JN If VA X
KK Vt I MY VA
(M� �II��
Witness Signature M0NROE S *kT ORNEY
9 L - r. 5-i u1Ash8VCM
Print Witness Name
Date: a II 4I 1
PROVED AS
NATrLEENE W. CASSEL
ASSIST NT COUNTY ATTORNEY
Date _
Artkln ePAmandment
Mtkka of lam viatlon
of
Ph
r3 �/ . {•,�,il, fl.t illy.
MSIIK2M Architecture, Inc. At 9.• /3
(MM of Caeesntlea as ear�lly Alad artllr tt o PteAds Uaol. of state)
P05000048146
(Dooun>ent Number of Cotpor.tlon (if known)
Pmmst to the provhions of saotion 607.1006. Florida Swuta. this 17erfds Preffl Corperadon adopts Ike favowiag amendatem(s) to
Its Anloks of Inampomt1m:
A. N laa asps, entK i1,a son eat pf ee�atlsnr
K2M Desicn.
name soot be &U&SW table and conmlh the word "cotporarlm " `i
IV.��•.. " low.. " or Cm ," or the deulRnatlae "Corp " 1W, A- or "Co'.
vmW "chwured " "pro adomd muodadw, " or the abbmvladon "P.A. "
L
AddamaLMOOMWK
1M�4� 4pW edlhW )
,: , I i if �:. i J • • . ,
( Mrtdo ttroi additw)
New Rssiltered Me ddness . Florida
ME red Anmd�s IIESIAMWLAMIMMLAM6
I hereby ocmpt tin oppoUUwenf ae ra&(ared agra 1 aw fastllim• wllk and aeeept site a ftadoas of sha paskloe.
4ttotrea of Now Rediskred AReal, (fdo thin$
rapt sf d
,
i
I
if m,,W a{ do offlo r sailer f)Irnmw% mow dw Ntle mad woos of eat & eflkerhReeetsr bled re•swd Rai d"% aeea, and
addeaoe of" OOleer ead/or Dhower being oddodt
(Anach mtk LIW sb", IVNM wy)
Pkaoe nose the ~&Wtor Nrk by tArJwf /Wier of du spa u*:
P - PnaUnW. V- F7ao Pmsfdatr. 7 Ttrarsnr, S- SwMaryt D- Dkwtor: 71- 7Ywtw.' C - Chalnnon or Ckr*. CDO - Cblef
Eucruve QMw, CFO - Chkf Fl wwid O lwr, If an ojkrddrretor holdr man than an tide, fix; the: fist latter gfeach qpw
held PrwWWf, Freaarrr. Dbwfor wadd be PW
Ch o%wz shoal/ be noted to the folfovlad ammer. Carmody John Doe fs listed er the PST ad Mfb Jonas IF lined as fho V Thm k
a d wqm Mike JitM kayos Nis aorpaodan, Sally Slabb k named do V ad S. I%= should be noted as Jalw Doe, PT ar a cww.
Milan Jam. V of Row n. and Salty SodA SV ar an Add
zu"Ples
X Remove Y MWAS
Add SY SWW SIM
LML2fAlft .M NI= kMfs
(Chad One)
1) __ Cheade
Add
Remove
2) _Chop
Add
3) —Chew
Add
Remove
d) __ Chmp
_, Add
Remove
!) _.._ ChAw
Add
Remove
Add
Remove
Poke t of 4
A
I
i
i
I
(AWe4 addMoeol rJnra. irmem aro. (Br *w( )
R .
(Ifso
H=r3of4
The date of aa4 awaedasset(s) edepiker June 1, 2013
CMadve daa gAMdMd&
( „o moor ohm 90 dayt afla aeendfwauJii. dots)
Adiap lon of Ae endsma (s) ( OWCALQM
■ The neeadnssnt(s) wadwaw adopted by do shwholdare. Mw number of votes cut fbr the smandment(s)
by the sis WWdets wadwers suMclest fm approvd.
0 TIM ametdetaa(s) wadwau approved by the shareholders thrw# voting Stoups. The joiiowin stmeatrw!
went bs xpanalsbPrnvidkd fvr sseh votingpoep eaNthd io vote sepww* on d e awewsiusat(s).
"71te amber of votes cut fir the snmdmeat(s) was/wets suffick t for approval
by »
(valkv arsuP�
D The se>esdewrn(s) w adwwee adopted by the bawd of diractore withont shatsholdersWon and dweboWer
saioe was wt r ke&
Cl The wnsndteaat(s) wadwars adopted by do kaorponion widwA shareholder swim and dwabolder
maim was am ttegdnd.
6 -15 -2013
SiMMUM
tsy a director #sident or Mm oilfcar— if diftm or otTicen have not boon
selecaik by an incawwr — if in tb hands of a receiver. trt m% or other court
appointed fWwWy by that fiduciary)
Shelly R. LaSalvia, Esq.
(Typed or printed name of parson sipdtrt;)
Attomey -in -Fact
(ThIc of pamm Aping)
Popus 4 ord
Ate' - CERTIFICATE OF LIABILITY INSURANCE I f„ ' ""
THIS CERTIF"TE IS WSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGM UPON THE CERTIFICATE HOLDER, THIS
CERTIFICATE DOES NOT AFFIRMATIVELY OR NEMATIVELY AMEND. EXTEND OR ALTtEt THE COVERAGE AFFORDED BY THE POLE
BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE RUING MIL AUTHORIZED
REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER
BAPOR ANT: the I'll oe holder 1r an ADDITIONAL INSURED. the poky0n) mot be endossaL K SUBROGATION ellbjM to
the ter! - s and comMione of the policy, certain poSda may require art endoesempnt. A stoonw t on tide oo0cab does rtot conhr sigh!* to the
cordlicalls hoMw in Mee of such endonmim
"DOU N
he .lames B. Oswald Company I ff NZ2 1 & 0128 15
100 Superior Avenue, Suite 1500
davelend OH 44114 MEE -.4 P, jj I r-10- i
INSURE MBIK21
K2M Design
1001 Whitehead St.. Suite 101
Key West FL 33040 -7522
NUMBER:204524032
THIS 15 TO CEFITIFY THAT THE FM= OF I BELOW HAVE BEEN ISSUED TO THE INSURED NAMED POLICY PERIOD
INDICATED. NOTVNTHSTANDINO ANY REQUIREIYEW. TEAM OR CONDITION OF ANY CONTRACT OR OTHER DOCISAENT WITH .RESPECT TO NMHC1 THIS
CERTIFICATE MAY BE ISSUED OR MAY PERTAN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS,
EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS.
TYPE 0f ebDlduNx
LaRTe
ACCORDANCE WITH THE POLICY PROVISIONS.
gB1e1AL L111eLmr Y ;Y SBAI0700e 4@01 iM1014
EACH OCCURmNCE
31 009 006
COMMERCIALGENERAI.UABILMY t (
s1 000.090
CGAMS.yADE F OCCUR i I
MEOEXh Lie
_
ft 000
$1,000,000
AI Pd=ly a ! l i
PERSONAL a ADV IN
_
000
6X I100.090
X Nan- Cont<bumly i i ' j (
R. AGGREGATE
! 32000000 _
OENt AGGRE tW1TAP I I 1 +
LPRODUCTS -COMPfOPAGO
_
POUCY X ix x U ( i
+
$
I UTONOeI1.tLAANUI P Y Y {45SBA107006 9114=13 W
0�
_,_T ANY AUTO k 1
( BODILY VU URY !Par nur
pey
3
ALLUMED
AUTO NOT NON -O OM�MED
BODILY VJ RJRY (PSI 0=41114
-- �R
3
fS�....`-
i
IX S
HMAUTOS AUTOS
Ems-. --,-^
,� AI Pdnwlr
S
IN ims"UIW ix OCCUR
Y , Y 4SSBA107009 W1412013 iWi4rAI4
EA CH OCCURRENCE S 1.000,000
@IlC Ee3LP0 I i CWMS44 WE
i
I
AG GREGATE 31 ,009,0 00
aP� x I REMMMA
`
Exdudee PFGMU W 3
110N
Y AOSBA107003 911412013 'I14*014
ONST OAP
AND laPIATO e' LMALITY YIN
ANY UTN@
FN
NIA;
ELEACHACCIDEI 0 000 00
OffIClRMBAaOCE>tCUA7EM
(1Mr1dw M wo
{ i
E. L. DISEASE - EA EM
( tl - an g om ammw bsbw
E L OISFASF, - POUCY LUT ' 111,000,000
a 1 aei0ral LhbieY N Y DPR9715582 pH2/2014 W1212015
EE 53.000,000
==
Included
MCI I I
PoYulion 8 En%w Lob
09@CRWTWN OF OPOtAIMM I LOCATIONS 1 VOaCL95 ~ACORD 101, Ad*J& l i;= 3ohs". 11 own @$Po N nwAnd)
ftionai Insured and Waiver of Subrogation as designated above is provided when required of the Named Insured by written contract or
,o ro
Mk-13142 Monroe ADA Segment 1 & 2
onroe County Board of County Commissioners is an additional Insured as noted above
W
cDrM IIATF uru TWO rAucs:l I A,Tln"
W IWM -AUTO A% ;UKU WKrUKA I 1Un. An ngMM reserves.
ACORD 25 (2010!05) The ACORD name and logo are registered marks of ACORD
SHOULD ANY OF THE ABOVE DESCRIeED POLICIES BE CANCELLED BEFORE
THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN
Monroe County Board of County Commissioners
ACCORDANCE WITH THE POLICY PROVISIONS.
Attn• Ann Rigor
1100 Simonton Street, Room 2 -218
Key West FL 33040
�RKIM TATIVE
t:i��(ZrrL
W IWM -AUTO A% ;UKU WKrUKA I 1Un. An ngMM reserves.
ACORD 25 (2010!05) The ACORD name and logo are registered marks of ACORD
1013 /2014
MONROE COUNTY BUSINESS TAX RECEIPT
EXPIRES SEFMNBER 30, 2014
RECEIPT# 4n61- 103202
Business Name: M8Mf4 ARCHITECNRE' INC
Owner Name: MICHAEL B IMM1 Business Location: 1001 W"MHEAD ST
MeiOnq Address: KEY WEST, FL 33040
1001 WKM* EAO ST Business Phone: 305- 292 -7722
KEY WE6T, FL 33040 Business Type: MISCELLANEOUS SERVICE (PARKING LOT)
Employees 1
Tax Amount Transfer Pee Sub -Total Penalty Prior Yesnt Collection tbet Total Paid
22.001 OAO 1 22.00 t 0.00 0.00 0.00 22.00
Paid 110-12 - 00002385 08115/2013 22.00
THIS BECOMES A TAX RECEIPT Danlse D. Henriqu!ez, CFC, Tax Collector THIS IS ONLY A TAX.
WHEN VALIDATED FO Box 33211, Key West, FL 33081 COUNTY AND/OR
MUNICIPALITY PLANNING
AND ZONING REQUIREMENTS.
NONROE COUNTY BUSYNESS TAX RECEIPT
P.O. Box 1129, Key West, FL 33041 -1129
EXPIRES SEPTEMBER 30, 2014
Business Name:
1451 ARCHITECTURE, INC RECEIPT# 47161 - 103202
Business Location: 1001 WHITEHEAD ST
Owner Name: MICHAEL B INGRAM KEY WEST, FL 33040
Owne Address 1001 WHITEFIEAD ST Business Phone: 305- 292 -7722
KEY WEST, FL 33040 Business Type: MISCELLANEOUS SERVICE (PARIINO LOT)
Employees 1
Tax Amount
Transfer Fee
Sub -Total
Penalty
Prior Yaere
Ccisecdon Cost
Total Pold
22.00
0.00
22.00
0.00
0.00
0.00
22.00
Paid 110 -12- 00002385 08/15/2013 ZZ.UU
o�
�a
g�
Z�
v
co
co
Go
m
�
�W
a�
t3
cr
W
:2 Ix
a�
}
g
a
6 c
w
co
S2
r
o z
Up
RO
CONTRACT FOR
PROFESSIONAL SERVICES
BETWEEN OWNER AND ARCHITECT/ENGINEER
FOR
ADA COMPI iAXCE SEGMENTS #1 & # 2 COMBINED
THIS CONTRACT made as of the 16 day of October, 2013, FOR PROFESSIONAL
SERVICES BETWEEN OWNER AND ARCHITECT/ENGINEER (the "Contract" or
"Agtament'l is made and entered into by MONROE COUNTY, BOARD OF COUNTY
COMMISSIONERS ("Owner" or "County"), a political subdivision of the State of
Florida, whose address is 1100 Simonton Street, Key West, Florida 33040, its suers
and assigns through the Monroe County Board of County Commissioners ("BOCC"), and
MBI/K2M ARCHITECTURE, INC. the ( "Architect" ), whose address is 1001
Whitehead Street Suite 101, Key West, FL 33040, its successors and assigns.
NOW, THEREFORE, in consideration of the mutual promises, covenants and
agreements stated herein, and for other good and valuable consideration, the sufficiency
of which hereby acknowledged, the Owner and the Architect agree:
1. This Conbvd is in accordance to the Continuing Contract as approved by the
BOCC on December 16, 2009 where professional services are to be rendered for projects
in which the estimated construction costs of each individual project under contract does
not exceed Two Million Dollars (r2, 000,000.00). All terms and conditions of the
in full herein. Modifications to the existing contract consist of the following:
A. PROJECT DESOtEMON AND SCOPE OF WORK
Architect shall provide architectural and engineering design services to complete
the American with Disabilities Ad (ADA) Compliance projects for the existing ADA
Compliance Segment #1 and the ADA Compliance Segment #2, which shall
henceforth be referred to as one project identified as ADA Compliance Segments #1
and #2 Combined. The project Scope of Work includes, but is not limited to, 38
individual locations throughout Monroe County that were identified with specific
ADA deficiencies that need compliance. These locations are as follows:
1. KL. Animal Shelter
2. K.L. Friendship Park
3. KL. Sunset Point Park
4. K.L. Harry Harris Park
5. P.K. Annex
6. P.K Government Center
7. P.K. Children's Center
8. P.K Roth Building
9. P.K Public Works
10. Islamorada Library
11. Marathon Animal Shelter
12. Marathon Annex
22. Cudjoe Key Transfer Station
23. Cudjoe Key Sheriff Substation
24. Baypoint Park
25. Big Coppitt Wilhehnina Harvey Park
26. Big Coppitt Fire Rescue
27. KW. Bayshore Manor
28. KW. Animal Shelter
29. KW. Juvenile Justice Center
30. K W. Detention Center
31. KW. Sheriffs Headquarters
32. KW. Driver's License Bureau
33. KW. Historic Gato Building
ADA Compliance Segments #1 & 02 Combined Page 1
13. Marathon Health Department
14. Marathon Driver's License
15. Marathon Senior Center
16. Marathon Library
17. Marathon Government Center
18. Veterans Park
19. B.P. Watson Field
20. B.P. Palm Villa Park
21. B.P. Blue Heron park
34. KW. Harvey Government Center
35. KW. Senior Nutrition Center
36. KW. Lester Building
37. KW. Old Courthouse
38. KW. May Hill Russell Library
Architect's Scope of Work shall include site visits at the start of the project to each
project location for assessment of the unfinished portions of Segments #1 and #2 with
Monroe County Staff~
Architect and County Staff shall conduct Design Review meetings.
Architect shall obtain all approvals needed, and coordination with the City of Key West
HARC when necessary.
Architect shall assist County in preparing proposal documents, including drawings and
specifications, respond to bidding questions via preparing the addenda, attendance at the
pre -bid conference, review ofproposals, and contract recommendation
Architect shall coordinate with the Building Department for permit approval.
Architect shall respond to Requests for Information during construction, and review and
respond to submittals. Architect shall not attend progress meetings or review Payment
Requests.
Architect shall prepare as -built drawings using owner - verified redline drawings provided
by the Contractor.
Monroe County agrees to provide Construction Management oversight, and handle the
verification and approvals of Payment Applications, Lien Releases, etc.
Architect shall comply with any and all requirements provided by the Department of
Economic Opportunity, the Housing Authority, and Meridian Community Services
Group, Inc.
In providing opinions of probably construction cost, the County understands that the
Architect has no control over the cost or availability of labor, equipment or materials, or
over market conditions or the Contractor's method ofpricing, and that the Architect's
opinion of probable construction costs are made on the basis of the Architect's
professional judgment and oTerience. The Architect makes no warranty, express or
implied, that the proposals or the negotiated cost of the work will not vary from the
Architect's opinion ofprobable construction cost.
ADA Compliance Segments #1 & 02 Combined P age 2
2. ADDIP— NAL SERVICES
Additional services are those which arise as a result ofunforeseen circumstances
during the design of a project and which is not included as basic services. Such
additional services, when requested in writing by the County, shall be permed at
hourly rates established on exhibit "A". Additional services shall include services in
connection with evaluating substitutions proposed by the contractor, and making
subsequent revisions resulting therefrom, and deciding disputes betwem owner and
Contractor(s).
Record Drawings — Record drawings will be prepared utilizing Contractor "as-
builts ", and fee contemplates a normal amount of modifications to base drawings as
typical with the construction process. If significant changes are made during
construction, Record Drawing costs may require re- evahration. The drawings will be
Prepared by Architect's Design Professionals' drafting staff only. Architect will maintain
electronic files for this project and provide one digital set to County.
3. ARCffiTECT AND COUN'T'Y & TIONS
A. Certain items will be provided by the COUNTY, ifthey are in the
County's possession or control, if requested in writing by the architect:
• Any existing documents relating to ADA Compliance for Segments #1 and
#2, will be provided if available to staff and if provided by the Sbrmer
contractor.
• Elevation certificate showing flood designation from FEMA maps.
• Asbestoshnold abatement survey.
• Topographic and boundary surveying.
4. COMPENSATION
A. A fee percentage of 10 0 /9 of the estimated construction cost of $509,890 shall
be used to calculate the Architect's fixed fee of Filly Thousand Nine Hundred
Eighty -Nine Dollars ($50,989.00). This fee shall be adjusted either upward or
downward when the actual construction cost is lmown.
Invoicing shall be monthly based on the percentage of completion, and as outlined
below:
• Design 90 0 /0
• Bidding and Permitting 5%
• Construction 5%
The following expenses are included in the design phase as described above:
• Ten (10) signed and sealed 11 x 17 drawing sets for each of the thirty-
eight (38) locations, and one electronic copy which includes aIL. This
includes seven (7) sets for permit submission and three (3) sets for as -built
submission.
• Initial visits and evaluations with County staff
ADA Compliance Segments #1 & #2 Combined Page 3
B. Monroe County and the Architect agree that the architect designed
portions of Segment #1 for Mailloux & Sons, Inc., that work remains
unpaid in the amount of $5,723.50. The design was completed by the
Architect and will be used by the County, therefore the County will pay
this amount as additional compensation to the Architect (see attachments
to Exhibit "A').
C. REIMBURSABLE EXPENSES
Reimbursable upmses shall be paid when submitted by Architect, in writing, but
only to the extent and in the amounts authorized by Section 112.061 Florida
Statutes, and/or Monroe County Code, whichever is more restrictive. Allowable
reimbursable expenses are as follows:
• Reproductions as requested only by the Owner beyond 10 signed and
sealed 11 x 17 sets, and one electronic copy.
• Renderings and models requested by the County.
• Postage of drawings and specifications except for those charges for
postage between the Architect's branch offices and between the Architect
and his Consultants.
5. SCHEDULE
The architect shall perform its services as expeditiously as is consistent with
professional skill and care and the orderly progress ofthe Work. Architect shall
remain within the scheduled deadlines provided by the Department of Economic
Opportunity, The Housing Authority, and Meridian Community Services Group,
Inc. The architect understands the urgency to commence design work upon
BOCC approval, and agrees to an assessment tour with a member of the Project
Management team Subsequent to the assessment tour, Architect shall submit
design drawings to the County for approval in approximately two weeks.
6. The Architect shall not disclose, publish, or authorize others to disclose or publish,
design data, drawings, specifications, reports, or other information pertaining to the
services performed by Architect or other information to which the Architect has had
access during the term of the Continuing Contract without the prior written approval
of the County, during the term of the Continuing Contract and for a period of two
years after the termination of the Continuing Contract. Nevertheless, the parties agree
the Architect may use and publish the County's name and give a general description
of the work provided by the Architect for the purpose of informing other clients and
potential clients of the, Architect's work experience and qualifications.
7. Should the County receive a request for documents pursuant to Chapter 119 Florida
Statutes, Architect shall cooperate with the county to facilitate the County's
compliance with Chapter 119, Florida Statutes. Should the Architect assert any
exemptions to the requirements of chapter 119 and related statutes, the burden of
establishing such exemption, by way of injunctive or other relief as provided by law,
shall be upon the Architect. - Failure by the Architect to cooperate with the County in
connection with a Public Records request shall be grounds for immediate unilateral
cancellation of the Continuing Contract by the County.
ADA Compliance Segments #1 & #2 Combined Page 4
All of the terms and conditions of the Continuing Contract dated December 16, 2009,
and attached as Exhrbit `B shall apply to this contract as if written herein in their
entirety. If the terms of this contract differ with the tams of the contract dated
December 16, 2009, the tams of this contract shall take precedence.
IN WITNESS WHEREOF, each party caused this Agreement to be executed by its duly
authorized representative on the day and year first above written.
BOARD OF COUNTY COMMISSIONERS
AMY HEAVILIN, Clerk OF MONROE COUNTY, FLORIDA
AFIVI ! WA -
Witnesses
Witness l:
Print Nam
Date` 1
Witness 2:
Print Name: v
Data I b S /zot
ARCEMCT/ENGINEER
i nn' 1(l :,•
flit
STATE OF FLORIDA
COUNTY OQ.MONROE
On this "6 day of T 2013, before me, the undmWed notary public, personally
appeared known, to me p be the person whose name is subscribed
above, or who 14--4 as identification, and acknowledged that
helshe is the person ho executed the above Contact with Monroe County for Architect/Engineering
services for the ADA Compliance Segments #1 & #2 Combined, for the purposes therein contained.
NOTARY P
My Commission Expires: / '�;'L 7 ; C,/
N
0
MONROE COUNTY ATTORNEY
PPROVED AS TO FO M: —
0
NATILEENE W. CASSEL
ASSISTANT ' OUNTY ATTORNEY
Date 'LL
ADA Compliance Segments #1 & #2 Combined
r - -
m
C:U
'T1
U
c�
0
0
>����
1 i�Y sa a
CwwiuW 0 E 8807t8
My mmm. 8 0m Jan. 27.2011
N
0
MONROE COUNTY ATTORNEY
PPROVED AS TO FO M: —
0
NATILEENE W. CASSEL
ASSISTANT ' OUNTY ATTORNEY
Date 'LL
ADA Compliance Segments #1 & #2 Combined
r - -
m
C:U
'T1
U
c�
0
0
EXHIBIT "A"
Hourly Rates
The following is a listing of hourly rates assigned by staffing type for mbi/k2m
Architecture, Inc. and only applies for services authorized beyond those defined in the
Contract for ADA Compliance Segments #1 & #2 Combined, or identified as Additional
Services. Hourly rates quoted are for the current calendar year and are subject to change
thereafter:
ARCHITECTURE/INTERIOR DESIGN
Principal
$225.00/hour
Director
$175.00/hour
Project Manager, Architect II
$150.00/hour
Senior Designer
$135.00/hour
Project Coordinator /CA
$125.00/hour
Purchasing Agent
$125.00/hour
Staff Designer/Draftsman I
$ 97.50/hour
Draftsman II
$80.00/hour
Junior Designer
$75.00/hour
Administration
$60.00/hour
Intern
$42.50/hour
ENGINEERING
Director
Senior Engineer, Manager
Project Engineer, Manager
Engineer, Specialist
Graduate Engineer, Designer
Administrative Secretary
Technician, Intern
Secretary, Clerical
$195.00/hour
$165.00/hour
$135.00/hour
$105.00/hour
$85.00/hour
$85.00/hour
$60.00/hour
$60.00/hour
Additional Compensation — Invoices attached.
ADA Compliance Segments #1 & #2 Combined Page 6
mbi I k2m
ARCHITECTURE, INC.
Bill To
Mailloux and Sons
Attn: Mr. Jade Mailloux
150015th Ave. Dr. East Suite 103
Palmetto, FL 34221
cc: jsdo®maillomrandsons.com
3121 BRIDGE AVENUE
CLEVELAND, OHIO 44113
PHONE: 216.357.2794
FAX: 216.357.2796
PROF. REG. NO. AA26001059
Invoice
Date
Invoice #
3/152013
6509
Contract #
Terms
Project:
Job No.
Location
Net 30
Monroe County ADA - Segment #1
MK -12239
FL
Description
Contract Amt
Prior Amt 881...
Cuff % Bill...
Total % Billed
Amount
Design professional shall provide architectural and
52,080.00
46,872.00
10.00%
100.00%
5,208.00
V*Rcaing services as required for Monroe County -
ADA Compliance Segment # 1 - MM112-47
Design/Build Response
In house prints for January
308.30
Thank you for your business.
Total $5,516.30
REMIT TO ADDRESS
Payments /Credits $0.00
3121 Bridge Ave.
Cleveland, OH 44113
Balance Due $5,516.30
mbi I
k2m
ARCHITECTURE, INC.
Printing Log MONTH OF:
0020 MAO so.40 stso :1250
Date
6.5 x 11 ca10r
I 11 z 17
11 x17 Color
2112/2013
11
17
711
2
Job Name / No. Mk -12239
MC ADA Segment #1
Jan -13
$3.75
Ad65 p`'cm �Amoun
308.30
*ft fs%Us=%N%0b=ft Doe ewftTgent print ftegey WesfW ADA Segment #1
mbi I k2m
ARCHITECTURE, INC.
Bill To
Mailloux and Sons
Attu: Mr. lade Mailloux
150015th Ave. Dr. East Suite 103
Palmetto, FL 34221
cc: jade®maillouxandsons.com
3121 BRIDGE AVENUE
CLEVELAND, OHIO 44113
PHONE: 216.357.2794
FAX: 216.357.2796
PROF. REG. NO. AA26001059
Invoice
Date
Invoice 0
4/1x2013
6569
P.O. Number
Terms
Project:
MBI I K2M Job No.
Location
Net 30
Monroe County ADA - Seg=t N1
MK -12239
FL
Description
Quantity
Price Each
Amount
REIMBURSABLE EXPENSES
In house Prints
1
90.40
90.40
Thank you for your business.
Total $90.40
Payments /Credits $0.00
REMIT TO ADDRESS:
3121 Bridge Ave.
Balance Due $90.40
Cleveland, OH 44113
P/
mbi I k2m
ARCHITECTURE, INC.
Printing Log MONTH OF:
60.20 61.10 MM
Job Name / No. Mk -12239
MC ADA Segment #1
Mar -13
11mbH61USMVwesW—ft Dooumerft%CIWA pAnt b9afty WeetW AQ A Segment 81
mbi I k2m
ARCHITECTURE, INC.
Bill To
Mailloux and Sons
Attn: Mr. Jade Mailloux
150015th Ave. Dr, past Suite 103
Palmetto. FL 34221
cc: jade&naillouxaadsons.com
3121 BRIDGE AVENUE
CLEVELAND, OHIO 44113
PHONE: 216.357.2794
FAX: 216.357.2796
PROF. REG. NO. AA26001059
Invoice
Date
Invoice #
6/5/2013
6775
P.O. Number
Terms
Project
MBI I K2M Job No.
Location
Net 30
Monroe County ADA - Segment #I
MK -12239
FL
Description
Quantity
Price Each
Amount
REIMBURSABLE, EXPENSES
In house prints
1
116.80
116.80
Thank you for your business.
Total $116.80
Payments /Credits $0.00
REMIT TO ADDRESS:
3121 Bridge Ave.
Balance Due $116.80
Cleveland, OH 44113
ti"/
mbi I k2m
ARCHITECTURE, INC.
Printing Log MONTH OF:
$0" f1 -lo
Job Name / No Mk -12239
ADA Segment #1
MaY43
Date
hp MAd
&5 x 11 0
- -
8.5x 11 Dolor
oil
11 x17
.,.a�
12 x 18
101.00
11 x 17 odor
$2.50
24 x 3e
Amount
5/8/2013
20
282
118.80
116.80
1lmbWUserstlweshbumWAy Documentskalent print IOgslKey West1ADA Segment #1
2013 /2014
MONROE COUNTY BUSINESS TAX RECEIPT
EXPIRES SEPTEMBER 30, 2014
Business Name: MBI/K2M ARCHITECTURE, INC
RECEIPT# 47161 - 103202
Owner Name: M 04AM B INGRAM Business Location: 1001 WHITEHEAD ST
Mailing Address: KEY WEST, FL 33040
1001 WHITEHEAD ST Business Phone: 305 -292 -7722
KEY WEST, FL 33040 Business Type: MISCELLANEOUS SERVICE (PARKING LOT)
Employees 1
Tax Amount
I Transfer Fee
I Sub -Total
I Penalty
I Prior Years
I Collection Cost
ITotal Paid
22.00
0.00
22.001
0.00
1 0.00
1 0.00
22.00
Paid 110 -12- 00002385 08/15/2013 22.00
THIS BECOMES A TAX RECEIPT Danlse D. Henriques, CFC, Tax Collector THIS IS ONLY A TAX.
WHEN VALIDATED PO Box 1129, Key West, ILL 33041 YOU MUST MEET ALL
COUNTY AND /OR
MUNICIPALITY PLANNING
AND ZONING REQUIREMENTS.
MONROE COUNTY BUSINESS TAX RECEIPT
P.O. Box 1129, Key West, FL 33041 -1129
EXPIRES SEPTEMBER 30, 2014
Business Name: M8I/K2M ARCHITECTURE, INC RECEIFr# 47161 - 103202
MICHAEL B INGRAM Business Location: 1001 WHITEHEAD ST
Owner Name: KEY WEST, FL 33040
Mailing Address: 1001 WHITEHEAD ST Business Phone: 305 -292 -7722
KEY WEST, FL 33040 Business Type: MISCELLANEOUS SERVICE (PARKING LOT)
Employees
1
Tax Amount Transfer Fee I Sub -Total Penalty Prior Years I Collection Cost Total Paid
22.001 0.001 22.001 0.001 0.001 0.001 22.00
Paid 110 -12- 00002385 08/15/2013 22.00
CERTIFICATE OF LIABILITY INSURANCE I om mw%ds°°'"'"
TM fMStTlIDATE N N M A MATTER W "W" MW MY MO CM WO W MGM W= THE CB UWA M MO TlM
CMRI"CME DOES NOT AMFIM MMLY OR NMOATNELY AMM M ffM OR ALTER DR COVE MM M AFFORDED NY TM POUCH
OMLAW. TINS CM M7CAIM OP MOM" " NO NOT tM WffM E A CONTRACT METIYNMII TM WWW NUNMRM A M"==
RMPRM>lMNTA f 1Y M OR PRODUCER. AND THE CMRTIFICATE MOUML
RAPOffANP its* SNUMM)6 povo ow mmol be - Ndotaai ESIJDROQA
tlo wms MM) M a— d oo pcowl. NdO polilia Mir M*ft MI WN McMM WL A abIMlaMIt in fdi aMMkdo dm nd =Ww daft iota
m
d - mm 1800
101
MIQA17!>L NOT11MiFINTANONlUI ANY REGIAILMINNT. TOW QR Cp10fT10N OF�ANY CddIRIIQT OR OTF�t OOGCINBtT wliH FNePECT 10 M#pi
COMPMATE AMY NN =UW OR MAY PWMK THE N UE APPCRDND BY 71M POIJCN:B OmGM� IM Ni MUNd M ALL 7FM 7lR
NXC MD OONOMCW CF MUCH POLUCMN. LW YB SHOrM MAY NAVE M MMMXMD SY PAtD CLAML
...........�.. Lam
iM11N tMRJ1Y Y Y OBBARNM I MMS IM4W4
CL*As*W X occm MMM! aa�
Nomamwbudr n
MMLMXWVl ATmUwrAPPLIMIPmt
X i
MITOMONUURN dlr Y Y 40MO pL W14=3 W14014
A iOOLYiul�lenprrr.aq i
SW M AUI iOCi.YNiNJItY�rr i
L H m mnam • X AvlOi '
AI Pftm
i
MMIUA LMM N MM Y 40NNA107OOi N MM4
mum M.Y_W.�
CYns M�
1.00QOW
9cWGPMWTl $LOQAM=lVMMp.N~AV= M.AdMlmdRsmmMsSdwdmf%Ne vpmb - -
kwjW NW Wdm Of Subl gMm m ded8n W dove Is p vAdod whon regal a .mW by wftm COfdnact
�l PW CudDms and Mader. W43008 By
'
W
8HOU ANYOF T IMAOM DlIQM POLK W CA N I LLMD MMOW
TM MM71M mm �A Ar MMPOL=V PROVONOM L IrR.L N DR== M
Atln Ann M R�per AC Y
1100 Skwnbn Street. Rwn 2-218
Key WVsit FL 39040 Aunlon® IIlINIfM71Y[
Q•r�r twi. � L�. L.s+•
O 1MSd010 ACORD CORPORATION. AN dgtft eeeerwd.
ACORD 26(2010" 7Ue ACORD nM and hW ant mW*W d n■Ate of ACORD
A
H
0
N
01
• � o p
L
0% O
c*! o
0 0�
a a ' °
In H v
� U �.
(� •� k p O
0 U c�jA
V1 4) m M H p O
^ � a a u a
CCS � 0 p
m a w w o
' ) � C/2 N
M
W m �" o `
v 40 N o
0 0 U-
Ch
�rw Nc-
O a o 0 0 0 0 o U
•b H d• r•I O th V} ter t/f H
H X
F4 � U
'd v k m
(�
C x a z Hui m tr) ..
U 4-) W S4 m
N •� m A OD U �
•�� m (d(d �
0
M a i l H - ri Pa H U
>�
�a
ar
r4
c H
a
a�
r
H
0
ri
H a�i
3 �
0
C)
ri
H
t
H
U
0
.0
GQ H
a
F-I H
H
H 0
0
m
M
a
w
W
W
o
�
g�
ZV
W
co
J m
�Ib W
W
r
O CO)
g
a
oCO)
Wo
�lr
0
UIX
Up
20
Exhibit "B"
Continuing Contract
ADA Compliance Segments #1 & #2 Combined Page 7
CONTRACT FOR
PROFESSIONAL SERVICES
BETWEEN OWNER AND ARCHITECT/ENGINEER
THIS CONTRACT FOR PROFESSIONAL SERVICES BETWEEN OWNER AND
ARCHTTECUENGINEER (the "Contract" or "Agreement') is made and entered into by
Monroe County ("Owner" or "County), a political subdivision of the State of Florida,
whose address is 1 100 Simonton Street, Key West, Florida 33040, its successors and
assigns through the Monroe County Board Of County Commissioners ( "BOCC'), and
MBUK2M Archbe — MKe Inc the( "Architect')., whose address is 1001 Whitehead
MM , its successors and assigns.
This contract shall be effective on the date of execution by the last party signatory to the
contract.
This contract is issued as a continuing contract pursuant to Florida Statute 287.055(2) (g).
The professional services required by this Contract are to be rendered for projects in
which the estimated construction costs of each individual project under the contract does
not exceed Two Million Dollar: ($2,000,000.00), or for study activity, if the fee for
professional services for each individual study under the contract does not exceed Two
Hundred Thousand Dollars ($200,000.00).
The parties shall enter into a separate contract for each project awarded to the Architect
by the Owner. The specific services to be performed under these separate contracts will
be determined by the Owner and agreed to by the Architect. Each separate contract will
contain specific scope of work, time schedule, charges and payment conditions, and
additional terms and conditions applicable to that specific contract. Architect will be
chosen pursuant to Owner policy and work will be distributed among all contractors who
have signed a continuing contract.
The professional services required by this contract will be for services in the form of a
continuing contract, commencing on the effective date of this contract and ending four
years thereafter, with options for Owner to renew on an annual basis for two additional
years.
The terns and conditions of this Contract shall apply to any separate contract, unless
expressly modified in the provisions of the separate contract. Where the terms of this
Contract differ from the terms of the separate contract, the terms of the separate contract
shall take precedence. The separate contract will contain its specific scope of work and it
is anticipated by this Contract that the scope of work in the separate contract will be in
addition to the scope of work outlined in this Contract
NOW, THEREFORE, in consideration of the mutual promises, covenants and
agreements stated herein, and for other good and valuable consideration, the sufficiency
of which hereby acknowledged, the Owner and the Architect agree:
FORM OF AGREEMENT
ART I — CLE 1
1.1 REPRESENTATIONS AND WARRANTIES
By executing this Contract, Architect makes the following express representations and
warranties to the Owner.
1.1.1 The Architect is a professional qualified to act as the Architect for the Project and
is licensed to practice Architecture/Engineering by all public entities having jurisdiction
over the Architect/Engineer and the Project;
1.1.2 The Architect shall maintain all necessary licenses, permits or other
authorizations necessary to act as Architect for the Project until the Architect's duties
hereunder have been fully satisfied;
1.1.3 The Architect shall become familiar with the individual Project site and the local
conditions under which the Project is to be designed, constructed, and operated prior to
entering a separate contract for any specific Project.
UA The Architect shall prepare all documents required by this Contract including, but
not limited to, all contract plans and specifications, in such a manner that they shall be in
conformity and comply with all applicable law, codes and regulations. The Architect
warrants that the documents prepared as a part of this Contract will be adequate and
sufficient to accomplish the purposes of the Project; therefore, eliminating any additional
construction cost due to missing or incorrect design elements in the contract documents,
1.1.5 The Architect assumes full responsibility to the extent allowed bylaw with
regards to his performance and those directly under his employ as Architect of Record.
1.1.6 The Architect's services shall be performed as expeditiously as is consistent with
professional skill and care and the orderly progress of the Work. The Architect shall
submit, for the Owner's and Monroe County Project Management Department's
information, a schedule for the performance of the Architect's services which may be
adjusted as the Project proceeds if approved by the Owner, and shall include allowances
for periods of time required for the Owner's and Monroe County Project Management
Department's review, and for approval of submission by authorities having jurisdiction
over the Project. Time limits established by this schedule and approved by the Owner
may not be exceeded by the Architect except for delay caused by events not within the.
control of the Architect or foreseeable by him.
1.1.7 In providing all services pursuant to this agreement, the Architect shall abide by
all statutes, ordinances, rules and regulations pertaining to, or regulating such services,
including those now in effect and hereinafter adopted. Any violation of said statutes,
ordinances, rules and regulations shall constitute a material breach of this agreement and
shall entitle the COUNTY to terminate this agreement immediately upon delivery of
written notice of termination to the Architect.
ART -- ICLE II
SCOPE OF ARCHITECT /ENGINEER'S BASIC SERVICE
2.1 DEFINITION
2.1.1 Architect's Basic Services consist of those described in Paragraphs 2.2 through
2.8, and other services identified as part of Basic Services, and include normal, civil,
structural, mechanical, and electrical engineering services,
2.1.2 The Design for Construction shall include, but shall not necessarily be limited to,
Plans and specifications which describe all systems, elements, details, components,
materials, equipment, and other information necessary for construction. The Design for
Construction shall be accurate, coordinated and in all respects adequate for construction
and shall be in conformity, and comply, with all applicable law, codes, permits, and
regulations. Products, equipment and materials specified for use shall be readily
available unless written authorization to the contrary is given by the Owner. The
Architect shall be responsible for designing the Project in accordance with the analyses
and recommendations of the geotechnical information furnished by the Owner.
2.1.3 These services shall include, but not be limited to: Preparation and completion of
the design program for space requirements and relationships, schematic design, design
development, preparation of contract documents for bids, preparation and advertisement
for Request for Bids, tabulation and review of bids, recommendation of contract awards,
cost estimating during design and document preparation, administration of contract
documents, consultation and on -site inspections during construction, review and
recommend approval of contractor invoices, preparation and submittal perm
of it
applications, zoning applications, public presentations and presentations to the County
Commission. Architect shall arrange his schedule in order to be available to perform the
listed services for one or for several projects if requested by COUNTY and with the
understanding that for any individual project the construction costs will not exceed the
limits under F.S. 287.055 (2)(g).
2.2 SCHEMATIC DESIGN PHASE
2.2.1 The Architect shall review the County's program, schedule and construction
budget furnished by the Owner to ascertain the requirements of the Project and shall
arrive at a mutual understanding of such requirements with the Owner.
2.2.2 The Architect shall review with the Owner and Monroe County Project
Management Department's proposed site use and improvements, required permits,
zoning, selection of materials, building systems and equipment; and method of Project
delivery.
SECTION FIVE
INSURANCE REQUIREMENTS AND INDEMNIFICATION STATEMENT
Insurance keen cement
Worker's Compensation
Employer's Liability
General Liability
Vehicle Liability
Professional Liability
Statutory Limits
$100,0=$500,0001$100,000
S 100,000 Combined Single Limit
S 100,000 Combined Single Unfit per
Occurrence/S 1,000,000 Aggregate
$500,000 per occurrence/ 51,000,000
Aggregate
RIJ • a
The Architect/Consultant covenants and agrees to indemnify, hold harmless and defend
Monroe County, its commissioners, officers, employees, agents and servants from any
and all claims for bodily injury, including death, personal injury, and property damage,
including property owned by Monroe County, and any other losses, damages, and
expenses of any kind, including attorney's fees, court costs and expenses, which arise out
o1; in connection with, or by reason of services provided by the Architect or Consultant
or any of its Subcontractor(s) in any tier, occasioned by the negligence, errs, or other
wrongful act or omission of the Architect/Consultant, including its Subcontractor(s) in
any tier, their officers, employees, servants or agents.
In the event that the completion of the project (to include the work of others) is delayed
or suspended as a result of the Architcct/Consultant's failure to purchase or maintain the
required insurance, the Architect/Consultant shall indemnify the County from any and all
increased expenses resulting from such delay. Should any claims be asserted against the
COUNTY by virtue of any deficiency or ambiguity in the plans and specifications
provided by the Architect/Consultant, the Architect/Consultant agrees and warrants that
Architect/Consultant shall hold the County harmless and shall indemnify it from all
losses occurring thereby and shall further defend any claim or action on the County's
behalf.
The first ten dollars ($ 10.00) of remuneration paid to the Architect/Consultant is
consideration for the indemnification provided for above.
20
The extent of liability is in no way limited to, reduced, or lessened by the insurance
requirements contained elsewhere within this agreement.
This indemnification shall survive the expiration or earlier termination of the Agreement.
RESPONDENT'
I understand the insurance that will be m tojif ard ed the con d will comply
in full with all the requirements. fl
�, IA 4 C, �I
Respond t
0 1 �6 6�- �Iw� Inc
l
21
INSURANCE AGENT'S STATEMENT
I have reviewed the above requirements with the Architect named below. The following
deductibles apply to the corresponding policy.
POLICY
Professional #AEE7204502
General Liab #45SBAI07008
Auto Liab #45SBAI07088
DEDUCTIBLES
$15,000 per claim (Claims -Made)
No Deductible (Occurrence)
No Deductible (Occurrence)
Liability policies are X Occurrence X Claims Made
Insurance Agency Signature
Selvaggio, Teske & Assocs., Inc.
.3401 Enterprise Parkway, Suite 101 Print None Sa l e m L. Simer
Beachwood, OH 44122
(216) 839 -2800
Wonroe courty
Pro er " rn I
NOV 2. V. 9
v%a
.,tr. 22
SECTION SIX
COUNTY RESPONSE FORMS
RESPOND TO: MONROE COUNTY BOARD OF COUNTY COMMISSIONERS
C/o PURCHASING DEPARTMENT
GATO BUILDING, ROOM 1 -213
1100 SIMONTON STREET
KEY WEST, FLORIDA 330
I acknowledge receipt of Addenda No.(s) - �1v�y 2 2 • Ay iu& S, U . 1
I have included:
• The Response Form
• Lobbying and Conflict of Interest Clause ✓
• Non - Collusion Affidavit ✓
• Drug Free Workplace Form
• Respondent's Insurance and Ind Statement
• Insurance Agent's Statement /
• Professional and Occupational Licenses
I have included a current copy of the following professional and occupational licenses:
EL 66 &41mm m Au jieii g �6�,
tCh, mark items above, as a re i nder i tha tth they are n Igded 1
Mailing Address: 4ya _ 6u td u� HA14
Telephone: '�Or, 2°12 772, Far, 2 56, 12.2
Date:
Signed:
c.
f�` �( lance
(Name)
(Title)
I i
1 � I • Li
(Seal)
RENEE WASHBURN
NOTARY PUBLIC
STATE OF OHIO
Comm. Expires
June 13, 2014
23
LOBBYING AND CONFLICT OF INTEREST CLAUSE
SWORN STATEMENT UNDER ORDINANCE NO.010 -1990
MONROE COUNTY, FLORIDA
ETHICS CLAUSE
I ^c -
(Company)
"... warrants that heAt has not employed, retained or otherwise had act on histits
behalf any former County officer or employee in violation of Section 2 of Ordinance No.
010.1990 or any County officer or employee in violation of Section 3 of Ordinance No.
010 -1990. For breach or violation of this provis' the County may, in its discretion,
terminate this Agreement without liability and ma al , in its discretion, deduct the
Agreement or purchase price, or otherwise er, the full a4unt any fee,
commission, percentage, gik or consideration p ' to the f arty officer or
employee".
Date:
STATE OF: O A l O
COUNTY OF: — Q,%) An 1, od A
Subscribed and sworn to (or affirmed) before me on IU Cs y C mEgj& 20 . d00 9
(date) by S e o -- m H Lo Illy (name of affian ®(She is
personally known to me or has produced j e C.1 GE ASE
as identification. (type of identification)
RENEE WASHBURN
NOTARY PUBLIC NOTARY PUBLIC
STATE OF OHIO My commission expiresa 15 3. )y
Comm. Explros
JU 15, 2014
24
DRUG -FREE WORKPLACE FORM
The undersigned vendor in accordance with Florida Statute 287.087 hereby certifies
that:
2. Inform employees about the dangers of drug abuse in the workplace, the business's
policy of maintaining a drug -free workplace, any available drug counseling, rehabilitation,
and employee assistance programs, and the penalties that may be imposed upon
employees for drug abuse violations.
3. Give each employee engaged in providing the commodities or contractual services
that are under bid a copy of the statement specified in subsection (1).
4. In the statement specified in subsection (I� notify the employees that, as a condition
of working on the commodities or contractual services that are under bid, the employee
PAR abide by the terms of the statement and will notify the employer of any conviction of,
or plea of guilty or nob contendere to, any violation of Chapter 893 (Florida Statutes) or
of any controlled substance law of the United States or any state, for a violation
occurring in the workplace no later than five (5) days after such conviction.
5. Impose a sanction on, or require the satisfactory participation In a drug abuse
assistance or rehabilitation program N such is available in the employee's community, or
any employee who is so convicted.
6. Make a good faith effort to continue to maintain a drug -free workplace through
implementation of this section.
As the person aL#qorIzed to sign the s ment, I certify that this firm compiles fully with
the above requi ants.
espondent's Signsfure
111 01 0
Date
23
1. Publish a statement notifying employees that the unlawful manufacture, distribution,
dispensing, possession, or use of a controlled substance is prohibited in the workplace
and specifying the actions that will be taken against employees for violations of such
prohibition.
NON - COLLUSION AFFIDAVIT
JLIdWM of the city of _ _ 6"( Wt+
according to law on my oath, d under penalty of perjury, depose and say that:
1. I am D1 f C L 6 104 .0 - MAJA
of the firm of b8 613-k- -6 L,966 I n C
the bidder making the Proposal for the project described in the Request for
X%44"
(Ir.k.19218. _ /
I �4V I h>u11
f1 i'Md Or (�% vlL�vl►k -5 . at I executed the said proposal with full autho 'ty to do so:
2. the prices in this bid have been arrived at independently without collusion,
consultation, communication or agreement for the purpose of restricting
competition, as to any matter relating to such prices with any other bidder or
with any competitor,
3. unless otherwise required by law, the prices which have been quoted in this
bid have not been knowingly disclosed by the bidder and will not knowingly
be disclosed by the bidder prior to bid opening, directly or indirectly, to any
other bidder or to any competitor, and
4. no attempt has been made or will be made by the bidder to induce any other
person, partnership or corporation to submit, or not to submit, a bid for the
purpose of r 'cting competition;
S. the statem contained in this affidavit are true and correct, and made with
full knowl that Mo relies upon the truth of the statements
contained ' 's a g contracts for said project.
(Signature o den (Date)
STATE OF: SAM_ 1 C i
C OUNTY • 1 •
i
PERSONALLY APPEARED BEFORE ME, the undersigned authority,
)►'� who, after first being sworn by me, (name of individual signing) affixed
his/her signature in the space provided above on this XQ day of K3t3\1 E m6l- f-
20 - Q_q_ .
NOTARY PUBLIC
RENEE WASHBURN
NOTARY PUBLIC My Commission Expires:
STATE OF OHIO
Comm. Expires
June 15, 2014 26
IDEMNIFICATION AND HOLD HARMLESS FOR CONSULTANTS AND
SUBCONSULTANTS
The Architect/Consultant covenants and agrees to indemnify, hold harmless and defend
Monroe County, its commissioners, officers, employees, agents and servants from any
and all claims for bodily injury, including death, personal injury, and property damage,
including property owned by Monroe County, and any other losses, damages, and
expenses of any kind, including attorney's fees, court costs and expenses, which arise out
of, in connection with, or by reason of services provided by the Architect or Consultant
or any of its Subcontractor(s) in any tier, occasioned by the negligence, errors, or other
wrongful act or omission of the Architect/Consultant, including its Subcontractors) in
any tier, their officers, employees, servants or agents.
In the event that the completion of the project (to include the work of others) is delayed
or suspended as a result of the Architect/Consultant's failure to purchase or maintain the
required insurance, the ArchiteWConsultant shall indemnify the County from any and all
increased expenses resulting from such delay. Should any Bairns be asserted against the
COUNTY by virtue of any deficiency or ambiguity in the plans and specifications
provided by the Architect/ Consultant, the Architect/Consultant agrees and warrants that
Architect/Consultant shall hold the County harmless and shall indemnify it from all
losses occurring ring thereby and shall father defend any claim or action on the County's
behalf.
The first ten dollars ($ 10.00) of remuneration paid to the Architect/Consultant is
consideration for the indemnification provided for above.
The extent of liability is in no way limited to, reduced, or lessened by the insurance
requirements contained elsewhere within this agreement.
This indemnification shall survive the expiration or earlier termination of the Agreement.
1: 'a ►1) ►1 I y
I understand the insurance that will be mand
in full with all the requirements.
Respondent
1W I kA �rri4�. 4u�nre / re
27
EXHIBIT A
-c
EXHIBIT A
The following is a listing of hourly rates assigned by staffing type for mbi I k2m Architecture,
Inc. and only applies for Work authorized beyond that as defined in Appendix A.
ARCHITECTURE
Principal, Architect 1
$215.00 / hour
Project Manager, Architect II
$185.00 / hour
Project Manager
$120.00 / hour
Construction Administration
$120.00 / hour
Project Coordinator
$ 90.00 /hour
Draftsman If
$ 70.00 / hour
Administration
$ 55.00 / hour
Intern
$ 37.50 / hour
INTERIOR DESIGN
Principal
$202.00 / hour
Senior Designer
$135.00 / hour
Purchasing Agent
$120.00 / hour
Staff Designer /Designer
$ 90.00 /hour
Junior Designer
$ 67.00 / hour
Administrative
$ 55.00 / hour
SPECIAL SERVICES
HARC or evening jurisdictional $300.00 / hour
approval meetings
Inv
:VI i
2.23 The Architect shall review with the Owner and Monroe County Project
Management Department's alternative approaches to design and construction of the
Project.
2.2.4 Based on the mutually agreed -upon program, schedule and construction budget
requirements, the Architect shall prepare, for approval by the Owner, Schematic Design
Documents consisting of drawings and other documents illustrating the scale and
relationship of Project components.
2.2.5 Upon completion of the Schematic Design Phase, the Architect shall provide
drawings, outline specifications, estimate of anticipated cost in accordance with the
schematic designs, and other documents for the Owner's approval and the Monroe
County Project Management Department's information.
2.2.6 The Schematic Design must be approved in writing, by the Owner prior to
Architect continuing to the Design Development Phase.
2.3 DESIGN DEVELOPMENTIDOCUMENT PHASE
2.3.1 Upon completion of the Design Development Phase, the Architect shall provide
drawings, outline specifications and other documents for the Owner's approval and the
Monroe County Project Management Department's information. The Architect shall
provide an estimate of anticipated costs in accordance with the design development
phase.
2.3.2 The Design Development Documents must be approved in writing, by the Owner
prior to Architect continuing to the Construction Documents Phase.
2.4 CONSTRUCTION DOCUMENTS PHASE
2.4.1 The Architect shall provide Drawings and Specifications for the Owner's and the
Monroe County Project Management Department's review.
2.4.2 The Architect shall assist the Owner and Monroe County Project Management
Department in the preparation of the necessary bidding information, bidding forms, the
Conditions of Contracts, and the forms of Agreement between the Owner and the
Contractors.
2.4.3 The Architect's construction documents (plans, specifications, etc.) will conform
to all written codes and regulations of the federal govenvnent, county, state,
municipalities, agencies and state departments, in effect at the date of this Agreement,
and shall be of such completion as to receive all permits when applied for. If permits are
4
denied, then the Architect will conform the construction documents in such manner to
receive permits upon such plans. Work required from the Architect to conform the
documents to federal, state, city, county, or agency specifications and permit
requirements to allow them to be approved shall be completed at no charge or cost to the
Owner.
2.5 BIDDING OR NEGOTIATION PHASE
2.5.1 The Architect, following the Owner's approval of the Construction Documents
and the Architect's latest estimate of Construction Cost, shall assist the Monroe County
Project Management Department in obtaining bids or negotiated proposals and assist in
preparing contracts for construction.
2.5.2 The Architect shall assist the Monroe County Project Management Department in
issuing bidding documents to bidders and conducting pre -bid conferences with
prospective bidders. The Architect, with the assistance of the Monroe County project
Management Department, shall respond to questions from bidders, and shall issue
addenda.
2.6 CONSTRUCTION PHASE - ADMINISTRATION OF THE
CONSTRUCTION CONTRACT
2.6.1. The Architect's responsibility to provide Basic Services for the Construction
Phase under this Agreement commences with the award of the Contract for construction
and terminates with the issuance to the Owner of the final Project Certificate for Payment
including the submission of all project close -out documents by the Architect and
Contractor. The Architect will administer the Owner's contract as provided for in that
document. The Architect agrees to perform a project check prior to the end of the
warranty period as a part of the contract. The check shall not exceed one working day
unless additional time is approved by the Owner.
2.6.2 The Architect shall at all times have access to the Work whenever it is in
preparation or progress.
2.6.3 The Architect shall, as contemplated herein and in the Construction Contract, but
not otherwise, act on behalf, and be the agent, of the Owner throughout construction of
the Project. Instructions, directions, and other appropriate communications from the
Owner to the Contractor shall be given to the Contractor by the Architect or Monroe
County Project Management Department.
2.6A The Architect shall have authority, after notification to the Monroe County
Project Management Department to reject Work, which does not conform to the Contract
Documents.
2.6.5 The Architect shall review and signor take other appropriate action on Change
Orders and Construction Change Directives prepared by the Monroe County Project
Management Department for the Owner's approval and execution in accordance with the
Contract Documents.
2.6.6 The Architect shall promptly provide appropriate interpretations as necessary for
the proper execution of the work as long as there is no change in Contract price.
2.6.7 The Architect shall require inspection or re- inspection and testing or retesting of
the work, to include architectuml/enguieering, structural, mechanical and electrical
engineering portions of the work, in accordance with the provisions of the Construction
Contract whenever appropriate,
2.6.3 The Archited, assisted by the Monroe County Project Management Department,
shall conduct inspections to determine the dates of Substantial Completion and the date
of Final Completion.
2.6.9 The Architect shall interpret and decide matters concerning performance of the
Contractor under the requirements of the Contract Documents upon written request.
2.6.10 Interpretations and decisions of the Architects shall be consistent with the intent
of and reasonably inferable from the Contract Documents and shall be in writing or in the
form of drawings and submitted on proper Construction Change Directives.
2.6.11 The Architect shall render written decisions within a reasonable time on all
claims, disputes or other matters in question between Owner and Contractors relating to
the execution or progress of the Work as provided in the Contract Documents.
2.6.12 Duties, responsibilities and limitations of authority of the Architect shall not be
restricted, modified or extended without written agreement of the Owner and Architect.
2.6.13 The Architect shall be a representative of and shall advise and consult with the
Owner (1) during construction until final payment to the Contractor is due and (2) as a
Basic Service at the Owner's direction from time to time during the correction period
described in the Contract for Construction.
2.6.14 The Architect shall transmit to the Owner all manuals, operating instructions, as-
built plans, warranties, guarantees and other documents and things required by the
Construction Contract and submitted by the Contractor.
2.6.15 The Architect shall not have control over or charge of and shall not be responsible
for construction means, methods, techniques, sequences or procedures, or for safety
precautions and programs in connection with the Work, since these are solely the
Contractor's responsibility under the Contract for Construction. The Architect shall not
be responsible for the Contractor's schedules or failure to cagy out the work in
accordance with the contract documents. The Architect shall not have control over or
charge of acts or omissions of the Contractor, Subcontractors, or their agents or
employees, or of any other persons performing portions of the work.
2.6.16 The Architect shall make available to the Owner any personnel or consultants
employed or retained by the Architect for the purpose of reviewing, studying, analyzing
or investigating any claims, contentions, allegations, or legal actions relating to, or arising
out of, the design or construction of the project.
2.6.17 The Architect shall review any as -built drawings furnished by the Contractor and
shall certify to the Owner that same are adequate and complete.
2.6.18 The Architect shall, without additional compensation, promptly correct any errors,
omissions, deficiencies, or conflicts in the work product of the Architect or its
consultants, or both.
2.6.19 The Architect must reimburse the Owner for any added costs paid by the Owner
during construction that were incurred as the result of any omission, deficiency, or
conflict in the work product of the Architect, its consultants, or both. This added expense
is defined as the difference in cost from that which the Owner would have paid if the
work was included in the bid, and the actual cost presented by the Contractor.
3.1 GENERAL
3.1.1 The services described in this Article III are not included in Basic Services. They
shall be paid for by the Owner as provided in this agreement as an addition to the
compensation paid for the Basic Services but only if approved by the Owner before
commencement, and as follows:
A. Providing services of Architect for other than the previously listed consulting
scope of Project provided as a pad of Basic Services.
B. Providing any other services not otherwise included in this Agreement or not
customarily fin in accordance with generally accepted consulting
practice.
C. Providing representation before public bodies in connection with the Project,
upon approval by the Owner.
3.2 If Additional Services are required, such as those listed above, the Owner
shall issue a letter requesting and describing the requested services to the Architect. The
Architect shall respond with fee proposal to perform the requested services. Only after
receiving an amendment to the Agreement and a notice to proceed from the Owner
proceed with the Additional Services.
ARTICLE IV
OWNER'S RESPONSIBILITIN
4.1 The Owner shall designate Monroe County Project Management Department to
act on the Owner's behalf with respects to the Project. the Owner or Monroe County
Project Management Department shall render decisions in a timely manner pertaining to
documents submitted by the Architect in order to avoid unreasonable delay in the orderly
and sequential progress of the Architect's services. However, the parties acknowledge
that due to Monroe County Policy, Ordinances or State or Federal Statute there may be
times when a decision must be made by the BOCC, in which case any delay shall not be
attributed to Monroe County or its representative.
4.2 Prompt written notice shall be given by the Owner and Monroe County Project
Management Department to the Architect if they become aware of any f adt or defect in
the Project or non - conformance with the Contract Documents.
4.3 The Owner shall furnish the required information and services and shall render
approvals and decisions as expeditiously as necessary for the orderly progress of the
Architect's services and work of the contractors.
4.4 The Owner's review of any documents prepared by the Architect or its consultants
shall be solely for the purpose of determining whether such documents are generally
consistent with the Owners criteria, as and i4 modified. No review of such documents
shall relieve the Architect ofresponsibility for the accuracy, adequacy, fitness, suitability
or coordination of its work product.
5.1 The Construction Cost, if applicable, shall be defined in a contract for the specific
Project.
ARTICLE VI
INDEMNIFICATION AND HOLD HARMLESS
6.1 The Architect covenants and agrees to indemnify and hold harmless
Owner /Monroe County and Monroe County Board of County Commissioners from any
and all claims for bodily injury, including death, personal injury, and property damage,
including property owned by Monroe County, and any other losses, damages, and
expenses, including attorney's fees, court costs and expenses, which arise out of, in
connection with, or by reason of services provided by the Architect or its
Subcontractor(s), occasioned by the negligence, errors, or other wrongful act or omission
of the Architect, their employees, or agents.
6.2 The first ten dollars ($ 10.00) of remuneration paid to the Architect is for the
indemnification provided for above. Should any claims be asserted against the County by
virtue of any deficiency or ambiguity in the plans and specifications provided by the
Architect, the Architect agrees and warrants that he shall hold the County harmless and
shall indemnify him from all losses occurring thereby and shall further defend any claim
or action on the County's behalf.
63 In the event the completion of the project (to include the work of others) is delayed
or suspended as a result of the Architect's failure to purchase or maintain the required
insurance, the Architect shall indemnify County from any and all increased expenses
resulting from such delays. Should any claims be asserted against County by virtue of
any deficiencies or ambiguity in the plans and specifications provide by the Architect the
Architect agrees and warrants that Architect hold the County harmless and shall
indemnify it from all losses occurring thereby and shall ftnther defend any claims or
action on the County's behalf
6.4 The extent of liability is in no way limited to, reduced or lessened by the insurance
requirements contained elsewhere within the Agreement.
6.5 This indemnification shall survive the expiration or early termination of the
Agreement.
ARTICLE VII
7.1 PERSONNEL
The Architect shall assign only qualified personnel to perform any service concerning the
project.
ART -- I_VIII
8.1 PAYMENT
Terms of payment will be governed by state guidelines and/or hourly rates to be approved
by the County. Hourly rates are provided in Exhibit A and subject to annual affirmation.
Details of payment will be set out in the specific separate contract.
8.2 REIMBURSABLE EXPENSES
Shall be negotiated and agreed to prior to award of the separate contract, but only to the
extent and the amounts authorized by Section 112.061, Florida Statutes; however prior to
incurring any expense written approval for any reimbursable expense must be obtained
from the County.
8.3 BUDGET
8.3.1 The Architect may not be entitled to receive, and the County is not obligated to
pay, any fees or expenses in excess of the amount budgeted for this Agreement in each
fiscal year (October 1- September 30) by County's Board of County Commissioners. The
budgeted amount may only be modified by an affirmative act of the County's Board of
County Commissioners.
9
83.2 AVAILABILITY OF FUNDS. If funding cannot be obtained or cannot be
continued at a level sufficient to allow for continued reimbursement of expenditures for
services specified in this Contract or in the separate contracts for individual projects, the
agreement may be terminated immediately at the option of the County by written notice
of termination delivered to the Architect. The County shall not be obligated to pay for
any services provided by the Architect after the Architect has received written notice of
termination, unless otherwise required by law.
8.3.3 The County does not guarantee Architect any specific amount of work or
contracts under this agreement. The parties shall enter into a separate contract for each
project awarded to the Architect by the County. The specific services to be performed
under these separate contracts will be determined by the County and agreed to by the
Architect. Each separate contract will contain specific scope of work, time schedule,
charges and payment conditions, and additional terms and conditions applicable to that
specific contract. Archited will be chosen pursuant to County policy and work will be
distributed among all contractors who have signed a continuing contract.
83.4 Monroe County's performance and obligation to pay under this contract is
contingent upon an annual appropriation by the Board of County Commissioners and the
approval of the Board members at the time of contract initiation and its duration.
9.1 APPLICABLE LAW
This contract is governed by and construed in accordance with the laws of the State of
Florida applicable to contracts made and performed entirely in the State. Venue for any
mediation, dispute conferences or litigation arising under this contract must be in Monroe
County, Florida. The Parties waive their rights to a trial by jury.
10.1 OWNERSHIP OF THE PRELIMINARY DESIGN AND THE DESIGN
FOR CONSTRUCTION
10.1 The Drawings, Specifications and other documents prepared by the Architect for
this project are instruments of the Architect's service for use solely with respect to this
project, and the Architect shall be deemed the author of these documents and shall retain
all common law, statutory and other reserved rights, including reproducible copies, of the
Architect's Drawings, Specifications and other documents shall not be used by the Owner
or others on other projects except by agreement in writing and with appropriate
compensation to the Architect.
10.1.2 Submission or distribution of documents to meet official regulatory requirements
or for similar purposes in connection with the project is not to be construed as publication
in derogation of the Architect's reserved rights.
10
10.1.3 The As -Built drawings and specifications may be furnished by the Architect to the
Owner in electronic format in addition to the original As -Built documents.
101A The Owner may utilize the construction documents, As -Built documents, etc. as
required for reference on any necessary future work on the site, and for constructing,
using and maintaining the Project.
ARTICLE XI
11.1 SUCCESSORS AND ASSIGNS
The Architect shall not assign its right hereunder, excepting its right to payment, nor shall
it delegate any of its duties hereunder without the written consent of the Owner. The
Owner and Architect, respectively, bind themselves, their partners, successors, assigns
and legal representatives to the other party to this Agreement and to the partners,
successors, assigns and legal representatives of such other party with respect to all
covenants of this Agreement.
ARTICLE XII
NO THIRD PARTY BENEFICIARIES
AND INDEPENDENT CONTRACTOR RELATIONSHIP
12.1 NO THIRD PARTY BENEFICIARIES
Nothing contained herein shall create any relationship, contractual or otherwise, between
the parties which creates or gives rise to any rights in favor of, any third party.
12.2 INDEPENDENT CONTRACTOR RELATIONSHIP
The Architect is and shall be an independent contractor in the performance of all work,
services, and activities under this Agreement and is not an employee, agent or servant of
the County. The Architect shall exercise control over the means and manner in which it
and its employees perform the work and in all respects the Architect's relationship and
the relationship of its employees to the County shall be that of an independent contractor
and not as employees or agents of the County. The Architect does not have the power or
authority to bind the County in any promise, agreement or representation other than such
power and authority that is specifically provided for in this Agreement.
ARTICLE XIII
13.1 INSURANCE
13.1.1 The Architect shall obtain insurance as specified and maintain the required
insurance at all times that this Agreement is in effect. Professional Liability Insurance
shall also be maintained as specified. In the event the completion of the project (to
include the work of others) is delayed or suspended as a result of the Architect's failure to
LE
Purchase or maintain the required insurance, the Architect shall indemnify the County
from any and all increased expenses resulting from such delay.
13.1.2 The coverage provided herein shall be provided by an insurer with an A.M. Best
Rating of VI or better, that is licensed to do business in the State of Florida and that has
an agent for service of process within the State of Florida. The insurance certificate shall
contain an endorsement providing thirty (30) days notice to the County prior to any
cancellation of said coverage. Said coverage shall be written by an insurer acceptable to
the County and shall be in a form acceptable to the County.
13.1.3 Architect shall obtain and maintain the following policies;
A. Workers' Compensation insurance as required by the State of Florida
B. Employers Liability insurance with limits of $ 100,000.00 per Accident,
$500,000.00 Disease, policy limits, $ 100,000.00 Disease each employee.
C. Comprehensive business automobile and vehicle liability insurance covering
claims for injuries to members of the public and/or damages to property of
others arising fiom use of motor vehicles, including onsite and offsite
operations, and owned, hired or non -owned vehicles, with One Hundred
Thousand Dollars ($ 100,000.00) combined single limit and One Hundred
Thousand Dollars ($ 100,000.00) annual aggregate.
D. Commercial general liability covering claims for injuries to members of the
public or damage to property of others arising out of any covered act or
omission of the Architect or any of its employees, agents or subcontractors or
subconsultants. including Premises and/or Operations, Independent
Contractors; Broad Form Property Damage and a Contractual Liability
Endorsement with Five Hundred Thousand Dollars ($500,000.00) per
occurrence and annual aggregate.
E. Professional liability insurance of Five Hundred Thousand Dollars
($500,000.00) per claim and One Million Dollars ($1,000,000.00) annual
aggregate. If the policy is a "claims made" policy, Architect shall maintain
coverage or purchase a "tail" to cover claims made after completion of the
project to cover the statutory time limits in Chapter 95 of the Florida Statutes.
F. County shall be named as an additional insured with respect to Architect's
liabilities hereunder in insurance coverage identified in Paragraphs C and D.
G. Architect shall require its subconsultants to be adequately insured at least to
the limits prescribed above, and to any increased limits of Architect if so
required by County during the term of this Agreement. County will not pay
for increased limits of insurance for subconsultants.
12
H. Architect shall provide to the County certificates of insurance or a copy of all
insurance policies including those naming the County as an additional insured
by including any subsection thereunder. The County reserves the right to
require a certified copy of such policies upon request.
ARTICLE XIV
TERMINATION
14.1 Either party hereto may terminate this contract prior to expiration upon giving
seven (7) days written notice to the other in the event that such other party negligently or
for any reason substantially fails to perform its material obligations set forth herein. No
termination expenses shall be paid by the Owner after the date of notice of termination.
14.2 The Owner may terminate this Contract without cause by giving the other party
sixty (60) days written notice of its intention to do so. Termination expenses shall include
expenses available under the contract through the date on the notice of termination and
shall not include any additional services required in order to stop performance of
services, unless agreed to in writing by the County and subject to audit for the purpose of
verification.
�1
15.1 This contract constitutes of the form of agreement, the exhibits that are attached
and made a part of the contract, and the documents refereed to in the form of agreement
as a part of this contract. In the event any conflict between any of those contract
documents, the one imposing the greater burden on the Architect will control.
15.2 A person or affiliate who has been place on the convicted vendor list following a
conviction for public entity crime may not submit a bid on contract to provide any goods
or services to a public entity, may not submit a bid on a contract with a public entity for
the property to public entity, may not be awarded or perform work as a
contractor, supplier, subcontractor, or consultant under a contnret with any public entity,
and may not transact business with any public entity in excess of the threshold amount
provided in Section 287.017 of the Florida Statutes, for CATEGORY TWO for a period
of 36 months from the date of being placed on the convicted vendor list.
ARTICLE XVI
DISPUTE RESOLUTION
16.1 County and Architect agree that all disputes and disagreements shall first be
attempted to be resolved by meet and confer sessions between representatives of each of
the parties. If no resolution can be agreed upon within 30 days after the first meet and
confer session, the issue or issues shall be submitted to mediation before a mediator
13
mutually agreed to by the parties. The cost of mediation shall be shared equally. The
parties agree that mediation is a condition precedent to the institution of legal or equitable
proceedings by either party. Request for mediation shall be in writing and sent to the
other party. The parties shall agree on a mediator to hear the dispute.
16.2 Mediation shall be held in Monroe County Florida in a location in Key West; the
location may be moved only by mutual agreement of the parties.
16.3 Agreements reached in mediation shall be reduced to writing and signed by the
representative of each party; however agreements must be approved by the Board of
County Commissioners to be enforceable. Agreements reached in mediation shall be
enforceable as settlement agreements in any court having jurisdiction in Monroe County.
16.4 Nothing in this Agreement shall be construed to interfere with a subsequent order
from any court of competent jurisdiction ordering the parties to enter into mediation after
institution of legal or equitable proceedings.
16.5 Arbitration is specifically rejected by the parties as a method of settling disputes
which arise under this agreement; neither of the parties shall be compelled by the other to
arbitrate a dispute which may arise under this Agreement.
17.1 The following items are part of this contract:
a) Architect shall maintain all books, records, and documents directly pertinent to
performance under this Agreement in accordance with generally accepted accounting
pimples consistently applied. Each party to this Agreement or their authorized
representatives shall have reasonable and timely access to such records of each other
party to this Agreement for public records purposes during the term of the Agreement and
for four years following the termination of this Agreement. if an auditor employed by the
County or Clerk determines that monies paid to Architect pursuant to - this Agreement
were spent for purposes not authorized by this Agreement, the Architect shall repay the
monies together with interest calculated pursuant to F.S. Sec. 55.03, running from the
date the monies were paid to County.
b) Governing Law, Venue, Interpretation, Costs, and Fees: This Agreement
shall be governed by and construed in accordance with the laws of the State of Florida
applicable to contracts made and to be performed entirely in the State. In the event that
any cause of action or administrative proceeding is instituted for the enforcement or
interpretation of this Agreement, the County and Architect agree that venue will lie in the
appropriate court or before the appropriate administrative body in Monroe County,
Florida The Parties waive their rights to a trial by jury. The County and Architect agree
that, in the event of conflicting interpretations of the terms or a term of this Agreement by
or between any of them the issue shall be submitted to mediation prior to the institution
14
of any other administrative or legal proceeding, pursuant to Section XV1 of this
agreement.
c) Severability. If any term, covenant, condition or provision of this
Agreement (or the application thereof to any circumstance or person) shall be declared
invalid or unenforceable to any extent by a court of competent jurisdiction, the remaining
terms, covenants, conditions and provisions of this Agreement, shall not be affected
thereby; and each remaining term, covenant, condition and provision of this Agreement
shall be valid and shall be enforceable to the fullest extent permitted by law unless the
enforcement of the remaining terms, covenants, conditions and provisions of this
Agreement would prevent the accomplishment of the original intent of this Agreement.
The County and Architect agree to reform the Agreement to replace any stricken
provision with a valid provision that comes as close as possible to the intent of the
stricken provision.
d) Attorney's Fees and Costs. The County and Architect agree that in the
event any cause of action or administrative proceeding is initiated or defended by any
party relative to the enforcement or interpretation of this Agreement, the prevailing party
shall be entitled to reasonable attorney's fees and court costs expenses, as an award
against the non - prevailing party, and shall include attorney's fees and courts costs
expenses in appellate proceedings.
e) Binding Effect. The terms, covenants, conditions, and provisions of this
Agreement shall bind and inure to the benefit of the County and Architect and their
respective legal representatives, successors, and assigns.
fl Authority. Each party represarts and warrants to the other that the
execution, delivery and performance of this Agreement have been duly authorized by all
necessary County and corporate aWon, as required by law. Each party agrees that it has
had ample opportunity to submit this Contract to legal counsel of its choice and enters
into this agreement freely, voluntarily and with advise of counsel.
g) Claims for Federal or State Aid Architect and County agree that each
shall be, and is, empowered to apply for, seek, and obtain federal and state funds to
further the purpose of this Agreement; provided that all applications, requests, grant
proposals, and funding solicitations shall be approved by each party prior to submission.
h) Adjudication of Disputes or Disagreements. County and Architect agree
that all disputes and disagreements shall be attempted to be resolved under Section XVI
of this agreement. If no resolution can be agreed upon within 30 days after mediation,
then any party shall have the right to seek such relief or remedy as may be provided by
this Agreement or by Florida law.
i) Cooperation. In the event any administrative or legal proceeding is
instituted against either party relating to the formation, execution, performance, or breach
of this Agreement, County and Architect agree to participate, to the extent required by the
15
other party, in all proceedings, hearings, processes, meetings, and other activities related
to the substance of this Agreement or provision of the services under this Agreement.
County and Architect specifically agree that no party to this Agreement shall be required
to enter into any arbitration proceedings related to this Agreement.
j) Nondiscrimination. Architect and County agree that there will be no
discrimination against any person, and it is expressly understood that upon a
determination by a court of competent jurisdiction that discrimination has occurred, this
Agreement automatically terminates without any further action on the part of any party,
effective the date of the court order. Architect or County agree to comply with all
Federal and Florida statutes, and all local ordinances, as applicable, relating to
nondiscrimination. These include but are not limited to: 1) Title VI of the Civil Rights
Act of 1964 (PL 88 -352) which prohibits discrimination on the basis of race, color or
national origin; 2) Title IX of the Education Amendment of 1972, as amended (20 USC
ss. 1681 -1683, and 1685- 1686), which prohibits discrimination on the basis of sex; 3)
Section 504 of the Rehabilitation Act of 1973, as amended (20 USC s. 794), which
prohibits discrimination on the basis of handicaps; 4) The Age Discrimination Act of
1975, as amended (42 USC ss. 6101 -6107) which prohibits discrimination on the basis of
age; 5) The Drug Abuse Office and Treatment Act of 1972 (PL 92 -255), as amended,
relating to nondiscrimination on the basis of drug abuse; 6) The Comprehensive Alcohol
Abuse and Alcoholism Prevention, Treatment and Rehabilitation Act of 1970 (PL 91-
616), as amended, relating to nondiscrimination on the basis of alcohol abuse or
alcoholism; 7) The Public Health Service Act of 1912, ss. 523 and 527 (42 USC ss.
690dd -3 and 290ee -3), as amended, relating to confidentiality of alcohol and drug abuse
patent records; 8) Tide VIII of the Civil Rights Act of 1968 (42 USC s. et seq.), as
amended, relating to nondiscrimination in the sale, rental or financing of housing; 9) The
Americans with Disabilities Act of 1990 (42 USC s. 1201 Note), as maybe amended from
time to time, relating to nondiscrimination on the basis of disability, 10) Any other
nondiscrimination provisions in any Federal or state statutes which may apply to the
parties to, or the subject matter of, this Agreement.
k) Covenant of No Interest. Architect and County covenant that neither
presently has any interest, and shall not acquire any interest, which would conflict in any
manner or degree with its performance under this Agreement, and that only interest of
each is to perform and receive benefits as recited in this Agreement.
1) Code of Ethics. County agrees that officers and employ= of the County
recognize and will be required to comply with the standards of conduct for public officers
and employees as delineated in Section 112.313, Florida Statutes, regarding, but not
limited to, solicitation or acceptance of gifts; doing business with one's agency;
unauthorized compensation; misuse of public position, conflicting employment or
contractual relationship; and disclosure or use of certain information.
m) No Solicitation /Payment. The Architect and County warrant that, in
respect to itself, it has neither employed nor retained any company or person, other than a
bona fide employee working solely for it, to solicit or secure this Agreement and that it
16
has not paid or agreed to pay any person, company, corporation, individual, or firm, other
than a bona fide employee working solely for it, any fee, commission, percentage, gift, or
other consideration contingent upon or resulting from the award or making of this
Agreement. For the breach or violation of the provision, the Architect agrees that the
County shall have the right to terminate this Agreement without liability and, at its
discretion, to offset from monies owed, or otherwise recover, the full amount of such fee,
commission, percentage, gift, or consideration.
n) Public Access. The Architect and County shall allow and permit
reasonable access to, and inspection of, all documents, papers, letters or other materials in
its possession or under its control subject to the provisions of Chapter 119, Florida
Statutes, and made or received by the Architect and County in conjunction with this
Agreement; and the Architect shall have the right to unilaterally cancel this Agreement
upon violation of this provision by County.
o) Non - Waiver of Immunity. Notwithstanding he provisions of Sec. 286.28,
Florida Statutes, the participation of the Architect and the County in this Agreement and
the acquisition of any commercial liability insurance coverage, self - insurance coverage,
or local government liability insurance pool coverage shall not be deemed a waiver of
immunity to the extent of liability coverage, nor shall any contract entered into by the
County be required to contain any provision for waiver.
p) Privileges and Immunities. All of the privileges and immunities from
liability, exemptions from laws, ordinances, and rules and pensions and relief, disability,
workers' compensation, and other benefits which apply to the activity of officers, agents,
or employees of any public agents or employees of the County, when performing their
respective functions under this Agreement within the territorial limits of the County shall
apply to the same degree and extent to the performance of such functions and duties of
such officers, agents, volunteers, or employees outside the territorial limits of the County.
q) Legal Obligations and Responsibilities: Non - Delegation of Constitutional
or Statutory Duties. This Agreement is not intended to, nor shall it be construed as,
relieving any participating entity from any obligation or responsibility imposed upon the
entity by law except to the extent of actual and timely performance thereof by any
participating entity, in which case the performance may be offered in satisfaction of the
obligation or responsibility. Further, this Agreement is not intended to, nor shall it be
construed as, authorizing the delegation of the constitutional or statutory duties of the
County, except to the extent permitted by the Florida constitution, state statute, and case
law.
r) Non - Reliance by Non - Parties. No person or entity shall be entitled to rely
upon the terms, or any of them, of this Agreement to enforce or attempt to enforce any
third -party claim or entitlement to or benefit of any service or program contemplated
hereunder, and the Architect and the County agree that neither the Architect nor the
County or any agent, officer, or employee of either shall have the authority to inform,
counsel, or otherwise indicate that any particular individual or group of individuals, entity
17
or entities, have entitlements or benefits under this Agreement separate and apart, inferior
to, or superior to the community in general or for the purposes contemplated in this
Agreement.
S) Attestations. Architect agrees to execute such documents as the County
may reasonably require including a Public Entity Crime Statement, an Ethics Statement,
and a Drug -Free Workplace Statement.
t) No Personal Liability. No covenant or agreement contained herein shall
be deemed to be a covenant or agreement of any member, officer, agent or employee of
Monroe County in his or her individual capacity, and no member, officer, agent or
employee of Monroe County shall be liable personally on this Agreement or be subject to
any personal liability or accountability by reason of the execution of this Agreement.
U) Americans with Disabilities Act of 1990 (ADA) and Florida Accessibility
Code (FAC), current edition, whichever is required for the specific project. The
Architect will comply with all the requirements as imposed by the ADA, the regulations
of the Federal government issued thereunder, and the assurance by the Architect pursuant
thereto.
v) Disadvantaged Business Enterprise (DBE) Policy And Obligation. It is the
Policy of the County that DBE's, as defined in C.F.R. Part 26, as amended, shall have the
oPportuaity to participate in the performance of contracts financed in whole or in part
with County funds under this Agreement. The DBE requirements of applicable federal
and state laws and regulations apply to this Agreement. The County and its Architect
agree to ensure that DBE's have the opportunity to participate in the performance of the
Agreement. In this reSNA all recipients and contractors shall take all necessary and
reasonable steps in accordance with applicable federal and state laws and regulations to
ensure that DBE's have the opportunity to compete and perform contracts. The County
and the Architect and subcontractors shall not discriminate on the basis of race, color,
national origin or sex in the award and performance of contracts, entered pursuant to this
Agreement.
w) Execution in Counterparts. This Agreement may be executed in any
number of counterparts, each of which shall be regarded as an original, all of which taken
together shall constitute one and the same instrument and any of the parties hereto may
execute this Agreement by singing any such counterpart.
is
x) Section Headings. Section headings have been inserted in this Agreement
as a matter of convenience of reference only, and it is agreed that such section headings
are not a part of this Agreement and will not be used in the interpretation of any provision
of this Agreement.
W WITNESS WHEREOF, each party caused this Agreement to be executed by its duly
authorized representative on the day and year first above written.
(SEAL)
Attest::DANNY L. KOLHAGE, Clerk
1911 W1 �
,71 =0 r- rl
WITNESS TO Architect's Sig nature:
By: " en 0 Q Li 0"j 1 Ujum
WITNESS Signature
E F. UAS h 6 1 A A!
Print Witness Name
Date: j1 �- Z 6 - 4 9
BOARD OF COUNTY COMMISSIONERS
OF MONROE COUNTY, FLORIDA
By:
Ma /Chairman
Date: dq
b. + ccFurc �rc.
Sot C , al
Print Name of Corporate A ent
Date:
;V
3
END OF AGREEMENT
SECTION FIVE
INSURANCE REQUIREMENTS AND INDEMNIFICATION STATEMENT
Insurance Requirement
Worker's Compensation
Employer's Liability
General Liability
Vehicle Liability
Professional Liability
Required Limits
Statutory Limits
$100,000 /$500,000 /$100,000
$100,000 Combined Single Limit
$100,000 Combined Single Limit per
Occurrence!$ 1,000,000 Aggregate
$500,000 per occurrence/ $1,000,000
Aggregate
IDEMNIFICATION AND HOLD HARMLESS FOR CONSULTANTS AND
SUBCONSULTANTS
The Architect/Consultant covenants and agrees to indemnify, hold harmless and defend
Monroe County, its commissioners, officers, employees, agents and servants from any
and all claims for bodily injury, including death, personal injury, and property damage,
including property owned by Monroe County, and any other losses, damages, and
expenses of any kind, including attorney's fees, court costs and expenses, which arise out
of, in connection with, or by reason of services provided by the Architect or Consultant
or any of its Subcontractor(s) in any tier, occasioned by the negligence, errors, or other
wrongful act or omission of the Architect/Consultant, including its Subcontractor(s) in
any tier, their officers, employees, servants or agents.
In the event that the completion of the project (to include the work of others) is delayed
or suspended as a result of the Architect/Consultant's failure to purchase or maintain the
required insurance, the Architect/Consultant shall indemnify the County from any and all
increased expenses resulting from such delay. Should any claims be asserted against the
COUNTY by virtue of any deficiency or ambiguity in the plans and specifications
provided by the Architect/Consultant, the Architect/Consultant agrees and warrants that
Architect/Consultant shall hold the County harmless and shall indemnify it from all
losses occurring thereby and shall further defend any claim or action on the County's
behalf.
The first ten dollars ($10.00) of remuneration paid to the Architect/Consultant is
consideration for the indemnification provided for above.
20
The extent of liability is in no way limited to, reduced, or lessened by the insurance
requirements contained elsewhere within this agreement.
This indemnification shall survive the expiration or earlier termination of the Agreement.
1 understand the insurance that will be mand tory if a arded the contr c d will comply
in full with all the requirements.
�, w4 c. M 41
Respond t lure
M � �k6
21
INSURANCE AGENT'S STATEMENT
Auto Liab #45SBAIO7088
I have reviewed the above requirements with the Architect named below. The following
deductibles apply to the corresponding policy.
POLICY DEDUCTIBLES
Professional #AEE7204502 $15,000 per claim (Claims -Made)
General Liab #45SBAIO7008 No Deductible (Occurrence)
No Deductible (Occurrence)
Liability policies are X Occurrence X Claims Made �p
/] • ' A�
Insurance Agency Signature
Selvaggio, Teske & Assocs., Inc.
3401 Enterprise Parkway, Suite 101 Print Name: Salena L. Simer
Beachwood, OH 44122
(216) 839 -2800
Pro, ft-, 1 099 er „ - i
22
SECTION SIX
COUNTY RESPONSE FORMS
RESPOND TO: MONROE COUNTY BOARD OF COUNTY COMMISSIONERS
c/o PURCHASING DEPARTMENT
GATO BUILDING, ROOM 1 -213
1100 SIMONTON STREET
KEY WEST, FLORIDA 33040
I acknowledge receipt of Addenda No.(s) 4- 3j 2 U01 ' 2 • Aqt& i, zo o
I have included:
• The Response Form /
• Lobbying and Conflict of Interest Clause
• Non - Collusion Affidavit V
• Drug Free Workplace Form
• Respondent's Insurance and Inde7nification Statement
• Insurance Agent's Statement /
• Professional and Occupational Licenses
I have included a current copy of the following professional and occupational licenses:
9
ro�" irnAt IIttpuj
(001 1N q yar f ,J 9 /
X05 212.2 162
Mailing Address:
Telep
Date:
Signe(
(Name) �—
(Title)
Witness: �Qg 2 i0a-4lu
(Seal)
RENEE WASHBURN
NOTARY PUBLIC
STATE' OF OHIO
Comm. Expires
June 15, 2014
23
LOBBYING AND CONFLICT OF INTEREST CLAUSE
SWORN STATEMENT UNDER ORDINANCE NO. 010-1990
MONROE COUNTY, FLORIDA
ETHICS CLAUSE
(Company)
warrants that he/it has not employed, retained or otherwise had act on his /its
behalf any former County officer or employee in violation of Section 2 of Ordinance No.
010 -1990 or any County officer or employee in violation of Section 3 of Ordinance No.
010 -1990. For breach or violation of this provision the County may, in its discretion,
terminate this Agreement without liability and ma al o, in its discretion, deduct fr9m the
Agreement or purchase price, or otherwise co er, the full unt any fee,
commission, percentage, gift, or consideration p ' to the f�m unty officer or
employee ". U
Date:
STATE OF: O A t O
COUNTY OF: C,
Subscribed and sworn to (or affirmed) before me on Ili O U C r»b sr0, ZQ , AW g
(date) by s C QM- m H Qo A-1F- (name of affiant). She is
personally known tome or has produced • DQ w C Q, L..1 G6 tys E
as identification. (type of identification)
M" O
RENEE WASHBURN
NOTARY PUBLIC
STATE OF OHIO
Comm. Expires
June 15, 2014
NOTARY PUBLIC
My commission expiresu. •�-C 1 5 1 \}
24
DRUG -FREE WORKPLACE FORM
The undersigned vendor in accordance with Florida Statute 287.087 hereby certifies
that:
1. Publish a statement notifying employees that the unlawful manufacture, distribution,
dispensing, possession, or use of a controlled substance is prohibited in the workplace
and specifying the actions that will be taken against employees for violations of such
prohibition.
2. Inform employees about the dangers of drug abuse in the workplace, the business's
policy of maintaining a drug -free workplace, any available drug counseling, rehabilitation,
and employee assistance programs, and the penalties that may be imposed upon
employees for drug abuse violations.
3. Give each employee engaged in providing the commodities or contractual services
that are under bid a copy of the statement specified in subsection (1).
4. In the statement specified in subsection (1), notify the employees that, as a condition
of working on the commodities or contractual services that are under bid, the employee
will abide by the terms of the statement and will notify the employer of any conviction of,
or plea of guilty or nolo contendere to, any violation of Chapter 893 (Florida Statutes) or
of any controlled substance law of the United States or any state, for a violation
occurring in the workplace no later than five (5) days after such conviction.
5. Impose a sanction on, or require the satisfactory participation in a drug abuse
assistance or rehabilitation program if such is available in the employee's community, or
any employee who is so convicted.
6. Make a good faith effort to continue to maintain a drug -free workplace through
implementation of this section.
As the
the abc
am
Date
implies fully with
25
NON - COLLUSION AFFIDAVIT
I,
C b � of the city of 6AJ We
according to law on my oath, a4d under penalty of perjury, depose and say that:
1. I am D i f C C 6 k J A-
of the firm of N b 1 T
the bidder making the Proposal for the project described in the Request for
Qualifications for; n A o
T - I�'Ny CY I
I executed the said proposal with full
to do so:
2. the prices in this bid have been arrived at independently without collusion,
consultation, communication or agreement for the purpose of restricting
competition, as to any matter relating to such prices with any other bidder or
with any competitor;
3. unless otherwise required by law, the prices which have been quoted in this
bid have not been knowingly disclosed by the bidder and will not knowingly
be disclosed by the bidder prior to bid opening, directly or indirectly, to any
other bidder or to any competitor, and
4. no attempt has been made or will be made by the bidder to induce any other
person, partnership or corporation to submit, or not to submit, a bid for the
purpose of r tncting competition;
5. the stateme contained in this affidavit are true and correct, and made with
full knowl4die that Monro relies upon the truth of the statements
contained i his a a ar 'ng contracts for said project.
(Signature o pondent (Da ee
STATE OF: CA I C
COUNTY OF: G L) •1 O Q r4
PERSONALLY APPEARED BEFORE ME, the undersigned authority,S Q
(YRQ._� )±' F- who, after first being sworn by me, (name of individual signing) affixed
his/her signature in the space provided above on this - ;k,� day of K)J 3\{ I mIzor
R a V!C m_u Lo r
�P S NOTARY PUBLIC
O••'��� �I /j y RENEE WASHBURN
2= . j•..r My Commission Expires:
NOTARY PUBLIC
*' * STATE OF OHIO
N \ a Comm. Expires
June 15, 2014 26
F p•F O
I E�l Nam
IDEMNIFICATION AND HOLD HARMLESS FOR CONSULTANTS AND
SUBCONSULTANTS
The Architect /Consultant covenants and agrees to indemnify, hold harmless and defend
Monroe County, its commissioners, officers, employees, agents and servants from any
and all claims for bodily injury, including death, personal injury, and property damage,
including property owned by Monroe County, and any other losses, damages, and
expenses of any kind, including attorney's fees, court costs and expenses, which arise out
of, in connection with, or by reason of services provided by the Architect or Consultant
or any of its Subcontractor(s) in any tier, occasioned by the negligence, errors, or other
wrongful act or omission of the Architect/Consultant, including its Subcontractor(s) in
any tier, their officers, employees, servants or agents.
In the event that the completion of the project (to include the work of others) is delayed
or suspended as a result of the Architect/Consultant's failure to purchase or maintain the
required insurance, the Architect/Consultant shall indemnify the County from any and all
increased expenses resulting from such delay. Should any claims be asserted against the
COUNTY by virtue of any deficiency or ambiguity in the plans and specifications
provided by the Architect/Consultant, the Architect/Consultant agrees and warrants that
Architect/Consultant shall hold the County harmless and shall indemnify it from all
losses occurring thereby and shall further defend any claim or action on the County's
behalf.
The first ten dollars ($10.00) of remuneration paid to the Architect/Consultant is
consideration for the indemnification provided for above.
The extent of liability is in no way limited to, reduced, or lessened by the insurance
requirements contained elsewhere within this agreement.
This indemnification shall survive the expiration or earlier termination of the Agreement.
RESPONDENT'S STATEMENT
1 understand the insurance that will be mandatory if ded the contract and will comply
in full with all the requirements. . I
AA I "A-
Respondent
Nb I k� &fzlk
27
EXHIBIT A
EXHIBIT A
The following is a listing of hourly rates assigned by staffing type for mbi I k2m Architecture,
Inc. and only applies for Work authorized beyond that as defined in Appendix A.
ARCHITECTURE
Principal, Architect 1 $215.00 / hour
Project Manager, Architect 11 $185.00 / hour
Project Manager
$120.00 / hour
Construction Administration
$120.00 / hour
Project Coordinator
$ 90.00 /hour
Draftsman 11
$ 70.00 / hour
Administration
$ 55.00 / hour
Intern
$ 37.50 / hour
INTERIOR DESIGN
Principal
Senior Designer
Purchasing Agent
Staff Designer /Designer
Junior Designer
Administrative
$202.00 / hour
$135.00 / hour
$120.00 / hour
$ 90.00 /hour
$ 67.00 /hour
$ 55.00 / hour
SPECIAL SERVICES
HARC or evening jurisdictional $300.00 / hour
approval meetings