Loading...
The URL can be used to link to this page
Your browser does not support the video tag.
04/15/2015 Agreement
,,, .:-------, ,. , ,A..0,.„ lt. .,„ „..., ,, AMY HEAVILIN, CPA CLERK OF CIRCUIT COURT & COMPTROLLER r MONROE COUNTY, FLORIDA �i a DATE: April 24, 2015 TO: Kevin Wilson Director of Engineering ATTN: Pamela Hancock FROM: Lindsey Ballard, D. At the April 15, 2015 Board of County Commissioner's meeting the Board granted approval and authorized execution of Item C12 Approval of a contract with Burke Construction Group, Inc. for the Senior Nutrition Center Renovations in Key West, in the amount of $528,714.00. This project is funded through the one -cent infrastructure tax. .Enclosed is a duplicate original executed on behalf of Monroe County, for your handling. Should you have any questions, please feel free to contact me. CC: County Attorney Finance ,/ File 500 Whitehead Street Suite 101, PO Box 1980, Key West, FL 33040 Phone: 305 - 295 -3130 Fax: 305- 295 -3663 3117 Overseas Highway, Marathon, FL 33050 Phone: 305 - 289 -6027 Fax: 305- 289 -6025 S CANNED 88820 Overseas Highway, Plantation Key, FL 33070 Phone: 852 -7145 Fax: 305 - 852 -7146 f $ Agreement Between Owner and Contractor Where the basis of payment is a STIPULATED SUM AGREEMENT Made as of the Fifteenth Day of April Two Thousand and Fifteen BETWEEN the Owner: Monroe County Board of County Commissioners 500 Whitehead Street Key West, Florida 33040 And the Contractor: Burke Construction Group, Inc. 3210 Flagler Avenue Key West, FL 33040 For the following Project: SENIOR NUTRITION CENTER RENOVATIONS 1200 Truman Avenue Key West, FL 33040 Scope of the Work 1 Project Overview Roof Replacement, spalling repairs, window and door replacement, electrical upgrades, finishes, and demolition. 2 General Project Intent and Scope Provide all labor, supervision, engineering, materials, supplies, equipment, tools, transportation, surveying, layout, and protection for the proper execution and completion of all the work in accordance with the Contract Documents. The Work shall include but not be limited to that shown on the Drawings and detailed in the Technical Specifications if any included in this Contract. 3 General Requirements A. Construction work times shall be limited to: 7AM to 5PM Mon -Fri B. Contractor needs to be aware of weather and location and plan accordingly. AGREEMENT 1 of 46 t , C. Contractor needs to be aware of the facility, its vendors and staff with unusual schedules and plan accordingly. Coordination of each days works shall be done in advance with approval from County. All spaces interior and exterior shall be cleaned and returned to normal work period/ day. D. The Scope of Work shall include, but not be limited to, all work shown and listed in the Project Drawings. The Contractor is required to provide a complete job as contemplated by the drawings and specifications, which are a part of this bid package. The Contractor shall furnish all labor, supervision, materials, power, tools, equipment, supplies and any other means of construction necessary or proper for performing and completing the Scope of Work, unless otherwise specifically stated. E. The contractor will be responsible to obtain all additional necessary permits and approvals for the demolition and /or construction of this Project, including but not limited to permits from any City, County State of Federal regulatory agency as applicable. SPECIAL PROVISIONS The following Special Provisions are intended to clarify the scope of work, or highlight features of the work, or modify, change, add to, or delete from the General Scope of this Proposal Package. 1. All licenses required in order to perform the scope of work in the specified location, shall be procured and maintained by the contractor and his subcontractors. Contractor shall submit copies to Project Management prior to notice to proceed. Contractor's license shall accompany proposal. 2. Provide, replace, and maintain any safety rails and barricades as necessary during the process of work, or during deliveries of materials or equipment. 3. Contractor is to review Division 1 General Requirements for additional responsibilities required in order to perform this Work. 4. If in the event of conflicting, or overlapping requirements in any area of the proposal documents, technical specifications, or drawings, the most stringent condition shall be proposed and constructed. Notify Project Management in any event, in order to not compromise the Owner's right to make appropriate decisions. 5. Contractor shall maintain As -Built Drawings, (Record Drawings per Section 01720), of his work progression. 6. The Contractor shall not store materials, tools or debris inside the building with out written permission. Contractor shall provide suitable storage container, and be responsible for disposal off -site of all debris and trash. AGREEMENT 2 of 46 7. The Contractor shall coordinate with Owner's representative on available hours for Job Site access. Job site will have limited 7AM -5PM work hours. Contractor will need to schedule work shifts typically from 7AM- 5PM weekly. Any change to agreed upon schedule must be obtained in writing with a minimum of 72 hrs advanced notice. 8. Coordination of each days works shall be done in advance with approval from County. All spaces interior and exterior shall be cleaned and returned to normal each work period. 9. ADDITIONAL SPECIAL PROVISIONS OR DELETE ARTICLE 1 The Contract Documents The Contract Documents consist of this Agreement, Conditions of the Contract (General, Supplementary and other Conditions), Drawings, Specifications, Proposal Documents, Addenda issued prior to execution of this Agreement, together with the response to RFP and all required insurance documentation, and Modifications issued after execution of this Agreement. The Contract represents the entire and integrated agreement between the parties hereto and supersedes prior negotiations, representations or agreements, either written or oral. An enumeration of the Contract Documents, other than Modifications, appears in Article 9. In the event of a discrepancy between the documents, precedence shall be determined by the order of the documents as just listed. ARTICLE 2 The Work of this Contract The Contractor shall execute the entire Work described in the Contract Documents, except to the extent specifically indicated in the Contract Documents to be the responsibility of others, or as follows: ARTICLE 3 Date of Commencement and Substantial Completion 3.1 The date of commencement is the date to be fixed in a notice to proceed issued by the Owner. The Contractor shall achieve Substantial Completion of the entire Work not later than One Hundred and Eighty (180) calendar days after the date of commencement or issuance of a Notice to Proceed. The time or times stipulated in the contract for completion of the work of the contract or of specified phases of the contract shall be the calendar date or dates listed in the milestone schedule. Liquidated damages will be based on the Substantial Completion Date for all work, modified by all approved extensions in time as set forth by the Director of Project Management's signature of approval on the Certificate of Substantial Completion. The liquidated damages table below shall be utilized to determine the amount of liquidated damages. AGREEMENT 3 of 46 . , • ' ) , FIRST SECOND 31ST DAY & CONTRACT AMOUNT 15 DAYS 15 DAYS THEREAFTER Under $50,000.00 $50.00 /Day $100.00/Day $250.00/Day $50,000.00- 99,999.00 100.00 /Day 200.00 /Day 750.00 /Day $100,000.00 - 499,999.00 200.00 /Day 500.00 /Day 2,000.00 /Day $500,000.00 and Up 500.00 /Day 1,000.00 /Day 3,500.00 /Day The Contractor's recovery of damages and sole remedy for any delay caused by the Owner shall be an extension of time on the Contract. ARTICLE 4 Contract Sum 4.1 The owner shall pay the Contractor in current funds for the Contractor's performance of the Contract the Contract Sum of Four Hundred Forty - Four Thousand Nine Hundred Sixty - Nine and 00/100 Dollars ($444,969.00), subject to additions and deductions as provided in the Alternates described below and as provided in the Contract Documents. 4.2 The Contract Sum above does not include the following alternates, which are described in the Contract Documents and are hereby accepted by the Owner: Alternate #1 Forty - One Thousand Six Hundred Sixty - Two Dollars $41,662.00 In lieu of a flat roofing assembly, provide tapered insulation per details sheet A -3.1 to achieve positive drainage and provide an Average R value of approximately R -38. Included is a new continuous aluminum gutter around the full perimeter of the building. Alternate #2 Eleven Thousand One Hundred Eighty - Two Dollars $11,182.00 In lieu of the demolition of the existing walkway cover from Georgia Street to the building entry. Provide repairs and roof replacement as detailed on sheet A -7 and noted throughout the drawings. Work to include sidewalk repairs as required to maintain ADA accessibility. Alternate #3 Seventeen Thousand Two Hundred Nineteen Dollars $17,219.00 Exterior stucco finish: Spalling repairs, opening and infill repairs and removal of loose or deteriorated stucco will account for a large portion of the exterior stucco finish being removed and new stucco applied (under base bid). This alternate calls for any remaining stucco on the building exterior surfaces to be removed and a new 3 coat stucco exterior finish appied to the whole building resulting in a smooth, sand finish, consistent finished product ready for final painting. Alternate #4 Thirteen Thousand Six Hundred Eighty - Two $13,682.00 Lightning protection; provide a price to provide a fully grounded lightning protection system on the roof of the building. System shall be based on a shop drawing to be prepared by a licensed specialty subcontractor and in compliance with NFPA 780 and other applicable codes. 4.3 Unit prices, if any, are as follows: One Hundred Eighty - One Dollars /Cubic Foot $181.00 /Cubic Foot Unit price for additional spalling repairs in dollars and cents per cubic foot. Unit price includes all labor, materials, equipment, taxes, fees, profit, overhead and services associated with the measurement or quantity established. AGREEMENT 4 of 46 4.4 The Owner shall pay the Contractor in current funds for the Contractor's performance of the Contract the Contract Sum including all four alternates a grand total of Five Hundred Twenty -Eight Thousand Seven Hundred Fourteen and 00/100 Dollars ($528,714.00). In addition to the Contract Sum including all four alternates, Owner shall pay the Contractor for additional spalling repairs at One Hundred Eighty -One Dollars ($181.00) per Cubic Foot. ARTICLE 5 Progress Payments 5.1 Based upon Applications for Payment submitted by the Contractor to the Director of Project Management, and upon approval for payment issued by the Director of Project Management and Architect, the Owner shall make progress payments on account of the Contract Sum to the contractor as provided below and elsewhere in the Contract Documents. 5.2 The period covered by each Application for payment shall be one calendar month ending on the last day of the month, or as follows: 5.3 Payment will be made by the Owner in accordance with the Florida Local Government Prompt Payment Act, section 218.735, Florida Statutes. 5.4 Each Application for Payment shall be based upon the Schedule of Values submitted by the Contractor in accordance with the Contract Documents. The Schedule of Values shall allocate the entire Contract Sum among the various portions of the Work and be prepared in such form and supported by such data to substantiate its accuracy as the Director of Project Management may require. This schedule, unless objected to by the Director of Project Management, shall be used as a basis for reviewing the Contractor's Applications for Payment. 5.5 Applications for Payment shall indicate the percentage of completion of each portion of the Work as of the end of the period covered by the Application for Payment. 5.6 Subject to the provisions of the Contract Documents, the amount of each progress payment shall be computed as follows: 5.6.1 Take that portion of the Contract Sum properly allocable to completed Work as determined by multiplying the percentage completion of each portion of the Work by the share of the total Contract Sum allocated to that portion of the Work in the Schedule of Values, less retainage of Ten Percent 10 %. Pending final determination of cost to the owner of changes in the Work, amounts not in dispute may be included in Applications for Payment. The amount of credit to be allowed by the Contractor to the Owner for a deletion or change which results in a net decrease in the Contract Sum shall be the net cost to the Owner, less Overhead, Profit and Documented Costs incurred prior to the change Request, as indicated in the corresponding line item in the Approved Schedule of Values for that line item as confirmed by the Director of Project Management. When both additions and credits covering related Work or substitutions are involved in a change the allowance for overhead and profit shall be figured on the basis of net increase, if any, with respect to that change. 5.6.2 Add that portion of the Contract Sum properly allocable to materials and equipment delivered and suitably stored at the site for subsequent incorporation in the completed construction (or, if approved in advance by the Owner, suitably stored off the site at a location agreed upon in writing), Tess retainage; AGREEMENT 6 of 46 5.6.3 Subtract the aggregate of previous payments made by the Owner; and 5.6.4 Subtract amounts, if any, for which the Director of Project Management has withheld or nullified a Certificate for Payment as provided in Paragraph 9.5 of the General Conditions. 5.7 Retainage of 10% will be withheld in accordance with section 218.735 (8(b), Florida Statutes. 5.8 Reduction or limitation of retainage, if any, shall be as follows: Monroe County is exempt from and not subject to Florida Statutes 255.078, "Public Construction Retainage". Reduction or limitation of retainage, if any, shall be reduced incrementally at the discretion of and upon the approval of the Director of Project Management. ARTICLE 6 Final Payment Final payment, constituting the entire unpaid balance of the Contract Sum, shall be made by the Owner to the Contractor when (1) the Contract has been fully performed by the Contractor except for the Contractor's responsibility to correct nonconforming Work as provided in Subparagraph 12.2.2 of the General Conditions and to satisfy other requirements, if any, which necessarily survive final payment, and (2) a final approval for payment has been issued by the Director of Project Management. Such final payment shall be made by the Owner not more than 20 days after the issuance of the final approval for payment. The following documents (samples in section 1027) are required for Final Payment: (1) Application and Certificate for Payment (2) Continuation Sheet (3) Certificate of Substantial Completion (4) Contractor's Affidavit of Debts and Claims (5) Contractor's Affidavit of Release of Liens (6) Final Release of Lien (7) Contractor shall provide two (2) hard copies in tabulated divided binders and one (1) saved electronically tabbed and indexed in Adobe Acrobat file (.PDF) format delivered on a downloadable CD /DVD of all the following but not limited to: A .Project Record Documents (As Built Documents). B. Operating and maintenance data, instructions to the Owner's personnel. C. Warranties, bond and guarantees. D. Keys and keying schedule. E. Spare parts and maintenance materials. F. Electronic copies of approved submittals G. Evidence of payment and final release of liens and consent of surety to final release (includes final release from all utilities and utility companies). AGREEMENT 6 of 46 ARTICLE 7 Miscellaneous Provisions 7.1 Where reference is made in this Agreement to a provision of the General Conditions or another Contract Document, the reference refers to that provision as amended or supplemented by other provisions of the Contract Documents. 7.2 Payment shall be made according to the Florida Local Government Prompt Payment Act and Monroe County Code. 7.3 Temporary facilities and services: As described in Article 34 of the General Conditions 7.4 Monroe County's performance and obligation to pay under this contract is contingent upon an annual appropriation by the Board of County Commissioners. 7.5 A person or affiliate who has been placed on the convicted vendor list following a conviction for public entity crime may not submit a bid on a contract to provide any goods or services to a public entity, may not submit a proposal on a contract with a public entity for the construction or repair of a public building or public work, may not submit proposals on leases of real property to public entity, may not be awarded or perform work as contractor, supplier, subcontractor, or consultant under a contract with any public entity, and may not transact business with any public entity in excess of the threshold amount provided in Section 287.017, for CATEGORY TWO for a period of 36 months from the date of being placed on the convicted vendor list. 7.6 The following items are included in this contract: a) Contractor shall maintain all books, records, and documents directly pertinent to performance under this Agreement in accordance with generally accepted accounting principles consistently applied. Each party to this Agreement or their authorized representatives shall have reasonable and timely access to such records of each other party to this Agreement for public records purposes during the term of the Agreement and for four years following the termination of this Agreement. If an auditor employed by the County or Clerk determines that monies paid to Contractor pursuant to this Agreement were spent for purposes not authorized by this Agreement, the Contractor shall repay the monies together with interest calculated pursuant to Sec. 55.03, FS, running from the date the monies were paid to Contractor. b) Governing Law, Venue, Interpretation, Costs, and Fees: This Agreement shall be governed by and construed in accordance with the laws of the State of Florida applicable to contracts made and to be performed entirely in the State. In the event that any cause of action or administrative proceeding is instituted for the enforcement or interpretation of this Agreement, the County and Contractor agree that venue shall lie in the appropriate court or before the appropriate administrative body in Monroe County, Florida. The Parties waive their rights to trial by jury. The County and Contractor agree that, in the event of conflicting interpretations of the terms or a term of this Agreement by or between any of them the issue shall be submitted to mediation prior to the institution of any other administrative or legal proceeding, pursuant to Section XVI of this agreement. c) Severability. If any term, covenant, condition or provision of this Agreement (or the application thereof to any circumstance or person) shall be declared invalid or unenforceable to AGREEMENT 7 of 46 any extent by a court of competent jurisdiction, the remaining terms, covenants, conditions and provisions of this Agreement, shall not be affected thereby; and each remaining term, covenant, condition and provision of this Agreement shall be valid and shall be enforceable to the fullest extent permitted by law unless the enforcement of the remaining terms, covenants, conditions and provisions of this Agreement would prevent the accomplishment of the original intent of this Agreement. The County and Contractor agree to reform the Agreement to replace any stricken provision with a valid provision that comes as close as possible to the intent of the stricken provision. d) Attorney's Fees and Costs. The County and Contractor agree that in the event any cause of action or administrative proceeding is initiated or defended by any party relative to the enforcement or interpretation of this Agreement, the prevailing party shall be entitled to reasonable attorney's fees and court costs as an award against the non - prevailing party, and shall include attorney's fees and courts costs in appellate proceedings. e) Binding Effect. The terms, covenants, conditions, and provisions of this Agreement shall bind and inure to the benefit of the County and Contractor and their respective legal representatives, successors, and assigns. f) Authority. Each party represents and warrants to the other that the execution, delivery and performance of this Agreement have been duly authorized by all necessary County and corporate action, as required by law. Each party agrees that it has had ample opportunity to submit this Contract to legal counsel of its choice and enters into this agreement freely, voluntarily and with advise of counsel. g) Claims for Federal or State Aid. Contractor and County agree that each shall be, and is, empowered to apply for, seek, and obtain federal and state funds to further the purpose of this Agreement; provided that all applications, requests, grant proposals, and funding solicitations shall be approved by each party prior to submission. h) Adjudication of Disputes or Disagreements. County and Contractor agree that all disputes and disagreements shall be attempted to be resolved by meet and confer sessions between representatives of each of the parties. If the issue or issues are still not resolved to the satisfaction of the parties, then any party shall have the right to seek such relief or remedy as may be provided by this Agreement or by Florida law. This Agreement is not subject to arbitration. i) Cooperation. In the event any administrative or legal proceeding is instituted against either party relating to the formation, execution, performance, or breach of this Agreement, County and Contractor agree to participate, to the extent required by the other party, in all proceedings, hearings, processes, meetings, and other activities related to the substance of this Agreement or provision of the services under this Agreement. County and Contractor specifically agree that no party to this Agreement shall be required to enter into any arbitration proceedings related to this Agreement. j) Nondiscrimination. County and Contractor agree that there will be no discrimination against any person, and it is expressly understood that upon a determination by a court of competent jurisdiction that discrimination has occurred, this Agreement automatically terminates without any further action on the part of any party, effective the date of the court order. County or Contractor agree to comply with all Federal and Florida statutes, and all local ordinances, as applicable, relating to nondiscrimination. These include but are not limited to: 1) Title VI of the Civil Rights Act of 1964 (PL 88 -352) which prohibits discrimination on the basis of race, color or AGREEMENT 8 of 46 national origin; 2) Title IX of the Education Amendment of 1972, as amended (20 USC ss. 1681- 1683, and 1685 - 1686), which prohibits discrimination on the basis of sex; 3) Section 504 of the Rehabilitation Act of 1973, as amended (20 USC s. 794), which prohibits discrimination on the basis of handicaps; 4) The Age Discrimination Act of 1975, as amended (42 USC ss. 6101- 6107) which prohibits discrimination on the basis of age; 5) The Drug Abuse Office and Treatment Act of 1972 (PL 92 -255), as amended, relating to nondiscrimination on the basis of drug abuse; 6) The Comprehensive Alcohol Abuse and Alcoholism Prevention, Treatment and Rehabilitation Act of 1970 (PL 91 -616), as amended, relating to nondiscrimination on the basis of alcohol abuse or alcoholism; 7) The Public Health Service Act of 1912, ss. 523 and 527 (42 USC ss. 690dd -3 and 290ee -3), as amended, relating to confidentiality of alcohol and drug abuse patient records; 8) Title VIII of the Civil Rights Act of 1968 (42 USC s. et seq.), as amended, relating to nondiscrimination in the sale, rental or financing of housing; 9) The Americans with Disabilities Act of 1990 (42 USC s. 1201 Note), as maybe amended from time to time, relating to nondiscrimination on the basis of disability; 10) Any other nondiscrimination provisions in any Federal or state statutes which may apply to the parties to, or the subject matter of, this Agreement. k) Covenant of No Interest. County and Contractor covenant that neither presently has any interest, and shall not acquire any interest, which would conflict in any manner or degree with its performance under this Agreement, and that only interest of each is to perform and receive benefits as recited in this Agreement. I) Code of Ethics. County agrees that officers and employees of the County recognize and will be required to comply with the standards of conduct for public officers and employees as delineated in Section 112.313, Florida Statutes, regarding, but not limited to, solicitation or acceptance of gifts; doing business with one's agency; unauthorized compensation; misuse of public position, conflicting employment or contractual relationship; and disclosure or use of certain information. m) No Solicitation /Payment. The County and Contractor warrant that, in respect to itself, it has neither employed nor retained any company or person, other than a bona fide employee working solely for it, to solicit or secure this Agreement and that it has not paid or agreed to pay any person, company, corporation, individual, or firm, other than a bona fide employee working solely for it, any fee, commission, percentage, gift, or other consideration contingent upon or resulting from the award or making of this Agreement. For the breach or violation of the provision, the Contractor agrees that the County shall have the right to terminate this Agreement without liability and, at its discretion, to offset from monies owed, or otherwise recover, the full amount of such fee, commission, percentage, gift, or consideration. n) Public Access. The County and Contractor shall allow and permit reasonable access to, and inspection of, all documents, papers, letters or other materials in its possession or under its control subject to the provisions of Chapter 119, Florida Statutes, and made or received by the County and Contractor in conjunction with this Agreement; and the County shall have the right to unilaterally cancel this Agreement upon violation of this provision by Contractor. Contractor is required to: (1) Keep and maintain public records that ordinarily and necessarily would be required by the public agency in order to perform the service. (2) Provide the public with access to public records on the same terms and conditions that the public agency would provide the records and at a cost that does not exceed the cost provided in this chapter or as otherwise provided by law. AGREEMENT 9 of 46 (3) Ensure that public records that are exempt or confidential and exempt from public records disclosure requirements are not disclosed except as authorized by law. (4) Meet all requirements for retaining public records and transfer, at no cost, to the public agency all public records in possession of the contractor upon termination of the contract and destroy any duplicate public records that are exempt or confidential and exempt from public records disclosure requirements. All records stored electronically must be provided to the public agency in a format that is compatible with the information technology systems of the public agency. o) Non - Waiver of Immunity. Notwithstanding the provisions of Sec. 768.28, Florida Statutes, the participation of the Contractor and the County in this Agreement and the acquisition of any commercial liability insurance coverage, self- insurance coverage, or local government liability insurance pool coverage shall not be deemed a waiver of immunity to the extent of liability coverage, nor shall any contract entered into by the County be required to contain any provision for waiver. p) Privileges and Immunities. All of the privileges and immunities from liability, exemptions from laws, ordinances, and rules and pensions and relief, disability, workers' compensation, and other benefits which apply to the activity of officers, agents, or employees of any public agents or employees of the County, when performing their respective functions under this Agreement within the territorial limits of the County shall apply to the same degree and extent to the performance of such functions and duties of such officers, agents, volunteers, or employees outside the territorial limits of the County. q) Legal Obligations and Responsibilities: Non - Delegation of Constitutional or Statutory Duties. This Agreement is not intended to, nor shall it be construed as, relieving any participating entity from any obligation or responsibility imposed upon the entity by law except to the extent of actual and timely performance thereof by any participating entity, in which case the performance may be offered in satisfaction of the obligation or responsibility. Further, this Agreement is not intended to, nor shall it be construed as, authorizing the delegation of the constitutional or statutory duties of the County, except to the extent permitted by the Florida constitution, state statute, and case law. r) Non - Reliance by Non - Parties. No person or entity shall be entitled to rely upon the terms, or any of them, of this Agreement to enforce or attempt to enforce any third -party claim or entitlement to or benefit of any service or program contemplated hereunder, and the County and the Contractor agree that neither the County nor the Contractor or any agent, officer, or employee of either shall have the authority to inform, counsel, or otherwise indicate that any particular individual or group of individuals, entity or entities, have entitlements or benefits under this Agreement separate and apart, inferior to, or superior to the community in general or for the purposes contemplated in this Agreement. s) Attestations. Contractor agrees to execute such documents as the County may reasonably require, to include a Public Entity Crime Statement, an Ethics Statement, and a Drug -Free Workplace Statement. t) No Personal Liability. No covenant or agreement contained herein shall be deemed to be a covenant or agreement of any member, officer, agent or employee of Monroe County in his or her individual capacity, and no member, officer, agent or employee of Monroe County AGREEMENT 10 of 46 shall be liable personally on this Agreement or be subject to any personal liability or accountability by reason of the execution of this Agreement. u) Execution in Counterparts. This Agreement may be executed in any number of counterparts, each of which shall be regarded as an original, all of which taken together shall constitute one and the same instrument and any of the parties hereto may execute this Agreement by signing any such counterpart. v) Hold Harmless and Indemnification. Notwithstanding any minimum insurance requirements prescribed elsewhere in this agreement, Contractor shall defend, indemnify and hold the COUNTY and the COUNTY's elected and appointed officers and employees harmless from and against (i) any claims, actions or causes of action, (ii) any litigation, administrative proceedings, appellate proceedings, or other proceedings relating to any type of injury (including death), Toss, damage, fine, penalty or business interruption, and (iii) any costs or expenses that may be asserted against, initiated with respect to, or sustained by, any indemnified party by reason of, or in connection with, (A) any activity of Contractor or any of its employees, agents, contractors or other invitees during the term of this Agreement, (B) the negligence or willful misconduct of Contractor or any of its employees, agents, sub - contractors or other invitees, or (C) Contractor's default in respect of any of the obligations that it undertakes under the terms of this Agreement, except to the extent the claims, actions, causes of action, litigation, proceedings, costs or expenses arise from the intentional or sole negligent acts or omissions of the COUNTY or any of its employees, agents, contractors or invitees (other than Contractor). Insofar as the claims, actions, causes of action, litigation, proceedings, costs or expenses relate to events or circumstances that occur during the term of this Agreement, this section will survive the expiration of the term of this Agreement or any earlier termination of this Agreement. In the event that the completion of the project (to include the work of others) is delayed or suspended as a result of the Contractor s failure to purchase or maintain the required insurance, the Contractor shall indemnify the County from any and all increased expenses resulting from such delay. Should any claims be asserted against the County by virtue of any deficiency or ambiguity in the plans and specifications provided by the Contractor, the Contractor agrees and warrants that the Contractor shall hold the County harmless and shall indemnify it from all losses occurring thereby and shall further defend any claim or action on the County's behalf. The first ten dollars ($10.00) of remuneration paid to the Contractor is for the indemnification provided for the above. w) Section Headings. Section headings have been inserted in this Agreement as a matter of convenience of reference only, and it is agreed that such section headings are not a part of this Agreement and will not be used in the interpretation of any provision of this Agreement. x) Disadvantaged Business Enterprise (DBE) Policy and Obligation. It is the policy of the County that DBE's, as defined in C.F.R. Part 26, as amended, shall have the opportunity to participate in the performance of contracts financed in whole or in part with County funds under this agreement. The DBE requirements of applicable federal and state laws and regulations apply to this Agreement. The County and its Contractor agree to ensure that DBE's have the opportunity to participate in the performance of the Agreement. In this regard, all recipients and contractors shall take all necessary and reasonable steps in accordance with applicable federal and state laws and regulations to ensure that DBE's have the opportunity to compete and perform contracts. The County and Contractor and subcontractors shall not discriminate on the AGREEMENT 11 of 46 basis of race, color, national origin or sex in award and performance of contracts, entered pursuant to this Agreement. y) Agreements with Subcontractors. In the event that the Contractor subcontracts any or all of the work in this project to any third party, the Contractor specifically agrees to identify the COUNTY as an additional insured on all insurance policies required by the County. In addition, the Contractor specifically agrees that all agreements or contracts of any nature with his subcontractors shall include the COUNTY as additional insured. z) Florida Green Building Coalition Standards. Monroe County requires its buildings to conform to Florida Green Building Coalition standards. Special Conditions, if any are detailed in Section 00990 of the Project Manual for this Project. ARTICLE 8 Termination or Suspension 8.1 The Contract may be terminated by the Owner as provided in Article 14 of the General Conditions. ARTICLE 9 Enumeration of Contract Documents 9.1 The Contract Documents, except for Modifications issued after execution of this Agreement, are enumerated as follows: (Insert information here). a) Drawings: A -1, A -2, A -3, A -3 -A, A -4, A -5, A -6, A -7, A -8, A -9, A -10, A -11, A -12, A -13, LS -1, S -1. b) Project Manual: January, 2015 9.1.1 The Agreement is this executed Standard Form of Agreement Between Owner and Contractor. 9.1.2 The General Conditions are the General Conditions of the Contract for Construction. 9.1.3 The Supplementary and other Conditions of the Contract are those contained in the Project Manual dated: 9.1.6 The Addenda, if any, are as follows: Number Date Pages 1 February 19, 2015 42 2 February 20, 2015 4 9.1.7 The Alternates, if any, are as follows: Alternate No. 1: New Insulated roof Alternate No. 2: Demolition of Exterior Walk Way Alternate No. 3: Remaining Stucco removal w /new three coat stucco finish Alternate No. 4: Lightening Protection AGREEMENT 12 of 46 END ALTERNATES This Agreement is entered into as of the day and year first written above and is executed in at least four original copies of which one is to be delivered to the Contractor. Execution by the Contractor must be by a person with authority to bind the entity. SIGNATURE OF THE PERSON EXECUTING THE DOCUMENT MUST BE NOTARIZED AND WITNESSED BY ANOTHER OFFICER OF THE ENTITY. (SEAL) BOARD OF COUNTY COMMISSIONERS Attest: Amy Heavilin, Clerk OF MONROE COUNTY, FLORIDA r C By: "41,7' By: Deputy Clerk Mayor /Cha an Date '172k7 I ", d2/5 (SEAL) CONTRACTOR BURKE CONSTRU ION GRO •, INC. Attest: ' � . 4 By: By: Print Name: Print name: ' i Y1/� Z Title: Title: V P Date: Date: � - c(/ And: M QNR • B COUNTY ATTORNEY VEDA TO F"O -M: Print Name: AT1LEE..E W. CASSEL ,, Title: SISTANT Cc..INTY •TTCF? Date: Date _ STATE OF FLORRA COUNTY OF 009 OQthi ( day ? Yipt, 20LS me ,the undersigned notary public, Personally appeared ,j )i i dU 1 nown to me to be the person whose name is subscribed above or who produced as identification, and acknowledged that he /she is the person who executed the above contract with Monroe County for the Senior Nutrition Center Renovations. for the purpose therein contained. 4 Not..A - - - - - - - - - - - -- Print ame 1 �a ANTHONY BURKE 1 Notary Public • State of Florida ` My Comm. Expires Feb 10. 2018 My commission expires: _21 l O fi C Seal •, ;' Commissio # FF 071783 AGREEMENT 13 of 46 Senior Nutrition Center Renovations General Conditions of the Contract for Construction Where Project Management is Not a Constructor Table of Articles 1. General Provisions 2. Owner 3. Contractor 4. Administration of the Contract 5. Subcontractors 6. Construction by Owner or By Other Contractors 7. Changes in the Work 8. Time 9. Payments and Completion 10. Protection of Persons and Property 11. Insurance and Bonds 12. Uncovering and Correction of Work 13. Miscellaneous Provisions 14.Termination or Suspension of the Contract GENERAL CONDITIONS Page 14 of 46 Senior Nutrition Center Renovations SECTION 00750 GENERAL CONDITIONS OF THE CONTRACT 1.0 GENERAL PROVISIONS 1.1 Basic Definitions 1.1.1 The Contract Documents: The Contract Documents consist of the Agreement between Owner and Contractor, Conditions of the Contract (General, Supplementary and other Conditions), Drawings, Specifications, addenda issued prior to execution of the Contract, Owners proposal documents, other documents listed in the Agreement and Modifications issued after execution of the Contract, and the Contractor's proposal and supporting documentation. A Modification is (1) a written amendment to the Contract signed by both parties, (2) a Change Order, (3) a Construction Change Directive or (4) a written order for a minor change in the Work issued by Project Management. 1.1.2 The Contract: The Contract represents the entire and integrated agreement between the parties hereto and supersedes prior negotiations, representations or agreements, either written or oral. The Contract may be amended or modified only by a Modification. The Contract Documents shall not be construed to create a contractual relationship of any kind (1) between the Architect and Contractor, (2) between Project Management and Contractor, (3) between the Architect and Project Management, (4) between the Owner and a Subcontractor or (5) between any persons or entities other than the Owner and Contractor. The Owner shall, however, be entitled to enforce the obligations under the Contract intended to facilitate performance of the duties of Project Management and Architect. 1.1.3 The Work: The term "Work" means the construction and services required by the Contract Documents, whether completed or partially completed, and includes all other labor, materials, equipment and services provided or to be provided by the Contractor to fulfill the Contractor's obligations. The Work may constitute the whole or a part of the Project. 1.1.4 The Project: The Project is the total construction of which the Work performed under the Contract Documents may be the whole or a part and which may include construction by other Contractors and by the Owner's own forces including persons or entities under separate contracts not administered by Project Management. 1.1.5 The Drawings: The Drawings are the graphic and pictorial portions of the Contract Documents, wherever located and whenever issued, showing the design, location and dimensions of the Work, generally including plans, elevations, sections, details, schedules and diagrams. 1.1.6 The Specifications: The Specifications are that portion of the Contract Documents consisting of the written requirements for materials, equipment, construction systems, standards and workmanship for the Work, and performance of related services. 1.1.7 The Project Manual: The Project Manual is the volume usually assembled for the Work which may include the proposal requirements, sample forms, Conditions of the Contract and Specifications. 1.2 Execution, Correlation and Intent 1.2.2 Execution of the Contract by the Contractor is a representation that the Contractor has visited the site, become familiar with local conditions under which the Work is to be performed and correlated personal observations with requirements of the Contract Documents. GENERAL CONDITIONS Page 15 of 46 Senior Nutrition Center Renovations 1.2.3 The intent of the Contract Document is to include all items necessary for the proper execution and completion of the Work by the contractor. The Contract Documents are complementary, and what is required by one shall be as binding as if required by all; performance by the Contractor shall be required only to the extent consistent with the Contract Documents and reasonably inferable from them as being necessary to produce the intended results. 1.2.4 Organization of the Specifications into divisions, sections and articles, and arrangement of Drawings shall not control the Contractor in dividing the Work among Subcontractors or in establishing the extent of Work to be performed by any trade. 1.2.5 Unless otherwise stated in the Contract Documents, words which have well -known technical or construction industry meanings are used in the Contract Documents in accordance with such recognized meanings. 1.2.6 Where on any of the drawings a portion of the Work is drawn out and the remainder is indicated in outline, the parts drawn out shall also apply to all other like portions of the Work. 1.3 Ownership and Use of Architect's Drawings, Specifications and Other Documents 1.3.1 The Drawing, Specifications and other documents prepared by the Architect are instruments of the Architect's service through which the Work to be executed by the Contractor is described. The Contractor may retain one contract record set. Neither the Contractor nor any Subcontractor, Sub - subcontractor or material or equipment supplier shall own or claim a copyright in the Drawings, Specifications and other documents prepared by the Architect. All copies of them, except the Contractor's record set, shall be returned or suitably accounted for to Project Management, on request, upon completion of the Work. The Drawings, Specifications and other documents prepared by the Architect, and copies thereof furnished to the Contractor, are for use solely with respect to the Project. They are not to be used by the Contractor or any Subcontractor, Sub - subcontractor or material or equipment suppliers unless they are granted a limited license to use and reproduce applicable portions of the Drawings, Specifications and other documents prepared by the Architect appropriate to and for use in the execution of their Work under the Contract Documents. All copies made under this license shall bear the statutory copyright notice, if any, shown on the Drawings, Specifications and other documents prepared by the Architect. Submittal or distribution to meet official regulatory requirements or for other purposes in connection with this Project is not to be construed as publication in derogation of copyright or other reserved rights 1.3.2 Unless otherwise provided in the Contract Documents, the Contractor will be furnished, two (2) original sealed copies and one (1) electronic copy of Drawings, Specifications and the Project Manual free of charge for the execution of the Work. Additional copies may be obtained from Project Management at a fee of $5.00 per page for full size drawings (.25 per page for written specifications or 11"x 17" drawings). 1.4 Capitalization 1.4.1 Terms capitalized in these General Conditions include those which are (1) specifically defined, (2) the titles of numbered articles and identified references to Paragraphs, Subparagraphs and Clauses in the document or (3) the titles of other documents published by the American Institute of Architects. 1.5 Interpretation 1.5.1 In the interest of brevity the Contract Documents frequently omit modifying words such as "all" and "any" and articles such as "the" and "an," but the fact that a modifier or an article is GENERAL CONDITIONS Page 16 of 46 Senior Nutrition Center Renovations absent from one statement and appears in another is not intended to affect the interpretation of either statement. 2.0 OWNER 2.1 Definition 2.1.1 The Owner is Monroe County. The term "Owner" means the Owner or the Owner's authorized representative. 2.2 Information and Services Required of the Owner 2.2.2 The owner shall furnish initial site surveys describing physical characteristics, legal limitations and utility locations for the site of the Project, and a legal description of the site. 2.2.3 For existing facilities the Owner shall secure and pay for necessary approvals, easements, assessments and charges, required for construction, use or occupancy of permanent structures or for permanent changes in existing facilities except for permits and fees which are the responsibility of the Contractor under the Contract Documents. It is the Contractor's responsibility to secure and pay for the building permit(s) for the project. 2.2.4 Information or services under the Owner's control shall be furnished by the Owner with reasonable promptness to avoid delay in orderly progress of the Work. 2.2.5 Unless otherwise provided in the Contract Documents, the Contractor will be furnished two (2) original sealed copies and one (1) electronic copy of Drawings, Specifications and the Project Manual free of charge for the execution of the Work as provided in Subparagraph 1.3.2. 2.2.6 The Owner shall forward all communications to the Contractor through Project Management and may contemporaneously provide the same communications to the Architect. 2.2.7 The foregoing are in addition to other duties and responsibilities of the Owner enumerated herein and especially those in respect to Article 6 (Construction by Owner or by Other Contractors), Article 9 (Payments and Completion) and Article 11 (Insurance and Bonds). 2.3 Owner's Right to Stop the Work 2.3.1 If the Contractor fails to correct Work which is not in accordance with the requirements of the contract Documents as required by Paragraph 12.2 or persistently fails to carry out Work in accordance with the Contract Documents, the Owner, by written order signed personally or by an agent specifically so empowered by the Owner, may order the Contractor to stop the Work, or any portion thereof, until the cause for such order has been eliminated; however, the right of the Owner to stop the Work shall not give rise to a duty on the part of the Owner to exercise this right for the benefit of the Contractor or any other person or entity. 2.4 Owner's Right to Carry Out the Work 2.4.1 If the Contractor defaults or neglects to carry out the Work in accordance with the Contract Documents and fails within a three -day period after receipt of written notice from the Owner to commence and continue correction of such default or neglect with diligence and promptness, the Owner may after such three -day period give the Contractor a second written notice to correct such deficiencies within a three -day period. If the Contractor within such second three -day period after receipt of such second notice fails to commence and continue to correct any deficiencies, the Owner may, without prejudice to other remedies the Owner may have, correct such deficiencies. In such case an appropriate Change Order shall be issued GENERAL CONDITIONS Page 17 of 46 Senior Nutrition Center Renovations deducting from payments then or thereafter due the Contractor the cost of correcting such deficiencies, including compensation for another contractor or subcontractor or Project Management's and Architect's and their respective consultants' additional services and expenses made necessary by such default, neglect or failure. If payments then, or thereafter, due the Contractor are not sufficient to cover such amounts, the Contractor shall pay the difference to the Owner. In the event of clean -up issues, Owner has right to provide a minimum of 24 hours notice. In the event of safety issues determined to be of a serious nature, as determined by Project Management, notice will be given, and contractor is required to rectify deficiency immediately. 3.0 CONTRACTOR 3.1 Definition 3.1.1 The Contractor is the person or entity identified as such in the Agreement and is referred to throughout this Agreement as if singular in number. The term "Contractor" means the Contractor or the Contractor's authorized representative. 3.1.2 The plural term "Contractors" refers to persons or entities who perform construction under Conditions of the Contract that are administered by Project Management, and that are identical or substantially similar to these Conditions. 3.2 Review of Contract Documents and Field Conditions by Contractor 3.2.1 The Contractor shall carefully study and compare the Contract Documents with each other and with information furnished by the Owner pursuant to Subparagraph 2.2.2 and shall at once report to Project Management and Architect errors, inconsistencies or omissions discovered. The Contractor shall not be liable to the Owner, Project Management or Architect for damage resulting from errors, inconsistencies or omissions in the Contract Documents unless the Contractor recognized such error, inconsistency or omission and knowingly failed to report it to Project Management and Architect. If the Contractor performs any construction activity knowing it involves a recognized error, inconsistency or omission in the Contract Documents without such notice to Project Management and Architect, the Contractor shall assume appropriate responsibility for such performance and shall bear an appropriate amount of the attributable costs for correction. 3.2.2 The Contractor shall take field measurements and verify field conditions and shall carefully compare such field measurements and conditions and other information known to the Contractor with the Contract Documents before commencing activities. Errors, inconsistencies or omissions discovered shall be reported to Project Management and Architect at once. 3.2.3 The Contractor shall perform the Work in accordance with the Contract Documents and submittals approved pursuant to Paragraph 3.12. 3.3 Supervision and Construction Procedures 3.3.1 The Contractor shall supervise and direct the Work, using the Contractor's best skill and attention. The Contractor shall be solely responsible for and have control over construction means, methods, techniques, sequences and procedures and for coordinating all portions of the Work under this Contract, subject to overall coordination of Project Management as provided in Subparagraphs 4.6.3 and 4.6.5. 3.3.2 The Contractor shall be responsible to the Owner for acts and omissions of the Contractor's employees, Subcontractors and their agents and employees, and other persons performing portions of the Work under a contract with the Contractor. GENERAL CONDITIONS Page 18 of 46 Senior Nutrition Center Renovations 3.3.3 The Contractor shall not be relieved of obligations to perform the Work in accordance with the Contract Documents either by activities or duties of Project Management in its administration of the Contract, or by test, inspections or approvals required or performed by persons other than the Contractor. 3.3.4 The Contractor shall inspect portions of the Project related to the Contractor's Work in order to determine that such portions are in proper condition to receive subsequent work. 3.3.5 The Contractor shall verify that the Construction Documents being worked with are the most recent and updated available, including all Addenda information. Also the Contractor will perform the work strictly in accordance with this contract. 3.4 Labor and Materials 3.4.1 Unless otherwise provided in the Contract Documents, the Contractor shall provide and pay for labor, materials, equipment, tools, construction equipment and machinery, water, heat, utilities, transportation, and other facilities and services necessary for proper execution and completion of the Work, whether temporary or permanent and whether or not incorporated or to be incorporated in the Work. 3.4.2 The Contractor shall enforce strict discipline and good order among the Contractor's employees and other persons carrying out the Contract. The Contractor shall not permit employment of unfit persons or persons not skilled in tasks assigned to them. 3.4.3 The Contractor is responsible for the conduct of his employees at all times. Misconduct, destruction of property, unsafe practices, or violation of any Federal or State regulations including abuse of alcohol or drugs, will be cause for permanent dismissal from the project. If any Contractor's employee is determined to be detrimental to the Project, as deemed by Project Management, the Contractor will remove and /or replace the employee at the request of Project Management. Employees dismissed from the project will be transported from the job site at the Contractor's expense. 3.4.4 The Contractor shall be totally responsible for the security of his work, materials, equipment, supplies, tools, machinery, and construction equipment. 3.4.5 The Contractor shall be responsible for complete, timely and accurate field measurements as necessary for proper coordination, fabrication and installation of his materials and equipment. The Contractor agrees to cooperate with Project Management, if required, to accommodate any discovered variations or deviations from the Drawings and Specifications so that the progress of the Work is not adversely affected. 3.5 Warranty 3.5.1 The Contractor warrants to the Owner, Project Management and Architect that materials and equipment furnished under the Contract will be of good quality and new unless otherwise required or permitted by the Contract Documents, that the Work will be free from defects not inherent in the quality required or permitted, and that the Work will conform with the requirements of the Contract Documents. Work not conforming to these requirements, including substitutions not properly approved and authorized, may be considered defective. The Contractor's warranty excludes remedy for damage or defect caused by abuse, modifications not executed by the Contractor, improper or insufficient maintenance, improper operation, or normal wear and tear under normal usage. If required by Project Management, the Contractor shall furnish satisfactory evidence as to the kind and quality of materials and equipment. 3.6 Taxes GENERAL CONDITIONS Page 19 of 46 Senior Nutrition Center Renovations 3.6.1 The Contractor shall pay sales, consumer, use and similar taxes for the Work or portions thereof provided by the Contractor which are legally enacted when bids are received or negotiations concluded, whether or not yet effective or merely scheduled to go into effect. 3.7 Permits, Fees and Notices 3.7.1 The Contractor shall secure and pay for all permits, impact fees, governmental fees, licenses, inspections, testing, surveys and utility fees required by Federal, State, Municipal or Utility entities having jurisdiction over the project for the proper execution and completion of the Work which are customarily secured after execution of the Contract and which are legally required at the time bids are received. The Contractor will be responsible for all building permit costs or impact fees required for this project. The Contractor shall secure and pay for all building and specialty permits including plumbing, electrical, HVAC, etc. 3.7.2 The Contractor shall comply with and give notices required by laws, ordinances, rules, regulations and lawful orders of public authorities bearing on performance of the Work. 3.7.3 It is not the Contractor's responsibility to ascertain that the Contract Documents are in accordance with applicable laws, statutes, ordinances, building codes, and rules and regulations. However, if the Contractor observes that portions of the Contract Documents are at variance therewith, the Contractor shall promptly notify Project Management, Architect and Owner in writing, and necessary changes shall be accomplished by appropriate Modification. 3.7.4 If the Contractor performs Work knowing it to be contrary to laws, statutes, ordinances, building codes, and rules and regulations without such notice to Project Management, Architect and Owner, the Contractor shall assume full responsibility for such Work and shall bear the attributable costs. 3.9 Superintendent 3.9.1 The Contractor shall employ a competent superintendent and necessary assistants who shall be in attendance at the Project site during performance of the Work. The superintendent shall represent the Contractor, and communications given to the superintendent shall be as binding as if given to the Contractor. Important communications shall be confirmed in writing. Other communications shall be similarly confirmed on written request in each case. The superintendent shall be satisfactory to Project Management and shall not be changed except with the consent of Project Management, unless the superintendent proves to be unsatisfactory to the Contractor or ceases to be in his employ. 3.10 Contractor's Construction Schedule 3.10.1 The Contractor, promptly after being awarded the Contract, shall prepare and submit for the Owner's and Architect's information and Project Management's approval a Contractor's Construction Schedule for the Work. Such schedule shall not exceed time limits current under the Contract Documents, shall be revised at appropriate intervals as required by the conditions of the Work and Project, shall be related to the entire Project construction schedule to the extent required by the Contract Documents, and shall provide for expeditious and practicable execution of the Work. This schedule, to be submitted within fourteen (14) days after Contract Award, shall indicate the dates for the starting and completion of the various stages of construction, shall be revised as required by the conditions of the Work, and shall be subject to Project Management's approval. 3.10.2 The Contractor shall cooperate with Project Management in scheduling and performing the Contractor's Work to avoid conflict, delay in or interference with the Work of other Contractors or the construction or operations of the Owner's own forces. 3.10.4 The Contractor shall conform to the most recent schedules. GENERAL CONDITIONS Page 20 of 46 Senior Nutrition Center Renovations 3.10.5 Project Management will schedule and conduct a project meeting at a minimum of one meeting per month in each month which the Contractor shall attend. At this meeting, the parties can discuss jointly such matters as progress, scheduling, and problems. 3.11 Documents and Samples at the Site 3.11.1 The Contractor shall maintain at the site for the Owner one record copy of the Drawings, Specifications, addenda, Change Orders and other Modifications, in good order and marked currently to record changes and selections made during construction, and in addition approved Shop Drawings, Product Data, Samples and similar required submittals. These shall be available to Project Management and Architect and shall be delivered to Project Management for submittal to the Owner upon completion of the Work. 3.12 Shop Drawings, Product Data and Samples 3.12.1 Shop Drawings are drawings, diagrams, schedules and other data specially prepared for the Work by the Contractor or a Subcontractor, Sub - subcontractor, manufacturer, supplier or distributor to illustrate some portion of the Work. 3.12.2 Product Data are illustrations, standard schedules, performance charts, instructions, brochures, diagrams and other information furnished by the Contractor to illustrate materials or equipment for some portion of the Work. 3.12.3 Samples are physical examples which illustrate materials, equipment or workmanship and establish standards by which the Work will be judged. 3.12.4 Shop Drawings, Product Data, Samples and similar submittals are not Contract Documents. The purpose of their submittal is to demonstrate for those portions of the Work for which submittals are required the way the Contractor proposes to conform to the information given and the design concept expressed in the Contract Documents. Review by Project Management is subject to the limitations of Subparagraph 4.6.12. 3.12.5 The Contractor shall review, approve and submit to Project Management, in accordance with the schedule and sequence approved by Project Management, Shop Drawings, Product Data, Samples and similar submittals required by the Contract Documents. The Contractor shall cooperate with Project Management in the coordination of the Contractor's Shop Drawings, Product Data, Samples and similar submittals with related documents submitted by other Contractors. Submittals made by the Contractor which are not required by the Contract Documents may be returned without action. 3.12.6 The Contractor shall perform no portion of the Work requiring submittal and review of Shop Drawings, Product Data, Samples or similar submittals until the respective submittal has been approved by Project Management. Such Work shall be in accordance with approved submittals. 3.12.7 By approving and submitting Shop Drawings, Product Data, Samples and similar submittals, the Contractor represents that the Contractor has determined and verified materials, field measurements and field construction criteria related thereto, or will do so, and has checked and coordinated the information contained within such submittals with the requirements of the Work and of the Contract Documents. 3.12.8 The Contractor shall not be relieved of responsibility for deviations from requirements of the Contract Documents by Project Management approval of Shop Drawings, Product Data, Samples or similar submittals unless the Contractor has specifically informed Project Management and Architect in writing of such deviation at the time of submittal and Project Management have given written approval to the specific deviation. The Contractor shall not be GENERAL CONDITIONS Page 21 of 46 Senior Nutrition Center Renovations relieved of responsibility for errors or omissions in Shop Drawings, Product Data, Samples or similar submittals by Project Management's approval thereof. 3.12.9 The Contractor shall direct specific attention, in writing or on resubmitted Shop Drawings, Product Data, Samples or similar submittals, to revisions other than those requested by Project Management and Architect on previous submittals. 3.12.10 Informational submittals upon which Project Management are not expected to take responsive action may be so identified in the Contract Documents. 3.12.11 When professional certification of performance criteria of materials, systems or equipment is required by the Contract Documents, Project Management and Architect shall be entitled to rely upon the accuracy and completeness of such calculations and certifications. 3.12.12 If materials specified in the Contract Documents are not available on the present market, the Contractor may submit data on substitute materials to Project Management for approval by the Owner. 3.13 Use of Site 3.13.1 The Contractor shall confine operations at the site to areas permitted by law, ordinances, permits and the Contract Documents and shall not unreasonably encumber the site with materials or equipment. 3.13.2 The Contractor shall coordinate the Contractor's operations with, and secure the approval of, Project Management before using any portion of the site. 3.14 Cutting and Patching 3.14.1 The Contractor shall be responsible for cutting, fitting or patching required to complete the Work or to make its parts fit together properly; He shall also provide protection of existing work as required. 3.14.2 The Contractor shall not damage or endanger a portion of the Work or fully or partially completed construction of the Owner's own forces or of other Contractors by cutting, patching, excavating or otherwise altering such construction. The Contractor shall not cut or otherwise alter such construction by other Contractors or by the Owner's own forces except with written consent of Project Management, Owner and such other contractors: such consent shall not be unreasonably withheld. The Contractor shall not unreasonably withhold from the other Contractors or the Owner the Contractor's consent to cutting or otherwise altering the Work. When structural members are involved, the written consent of Project Management shall also be required. The Contractor shall not unreasonably withhold from Project Management or any separate contractor his consent to cutting or otherwise altering the Work. 3.14.3 The Contractor shall arrange for any blockouts, cutouts, or openings required for the installation of his materials and equipment and the execution of his work, whether or not shown or indicated on the Drawings. The Contractor shall be further responsible for sealing and /or finishing, in an acceptable fashion and meeting any applicable code requirements, and such block -out, cutout opening, or other hole in any fire- related floor, ceiling, wall, security wall, or any other finished surface. 3.15 Cleaning Up 3.15.1 The Contractor shall keep the premises and surrounding area free from accumulation of waste materials or rubbish caused by operations under the Contract. At completion of the Work the Contractor shall remove from and about the project waste materials rubbish, the Contractor's tools, construction equipment, machinery and surplus materials. Clean up shall be performed to the satisfaction of the Owner or Project Management. GENERAL CONDITIONS Page 22 of 46 Senior Nutrition Center Renovations 3.15.2 If the Contractor fails to clean up as provided in the Contract Documents, Project Management may do so with the Owner's approval and the cost thereof shall be charged to the Contractor. 3.16 Access to Work 3.16.1 The Contractor shall provide the Owner, Project Management and Architect access to the Work in preparation and progress wherever located. 3.17 Royalties and Patents 3.17.1 The Contractor shall pay all royalties and license fees. The Contractor shall defend suits or claims for infringement of patent rights and shall hold the Owner, Project Management and Architect harmless from Toss on account thereof, but shall not be responsible for such defense or Toss when a particular design, process or product of a particular manufacturer or manufacturers is required by the Contract Documents. However, if the Contractor has reason to believe that the required design, process or product is an infringement of a patent, the Contractor shall be responsible for such loss unless such information is promptly furnished to the Architect and Project Management. 3.18 Indemnification and Hold Harmless 3.18.1 Notwithstanding any minimum insurance requirements prescribed elsewhere in this agreement, Contractor shall defend, indemnify and hold the COUNTY and the COUNTY's elected and appointed officers and employees harmless from and against (i) any claims, actions or causes of action, (ii) any litigation, administrative proceedings, appellate proceedings, or other proceedings relating to any type of injury (including death), loss, damage, fine, penalty or business interruption, and (iii) any costs or expenses that may be asserted against, initiated with respect to, or sustained by, any indemnified party by reason of, or in connection with, (A) any activity of Contractor or any of its employees, agents, contractors or other invitees during the term of this Agreement, (B) the negligence or willful misconduct of Contractor or any of its employees, agents, sub - contractors or other invitees, or (C) Contractor's default in respect of any of the obligations that it undertakes under the terms of this Agreement, except to the extent the claims, actions, causes of action, litigation, proceedings, costs or expenses arise from the intentional or sole negligent acts or omissions of the COUNTY or any of its employees, agents, contractors or invitees (other than Contractor). Insofar as the claims, actions, causes of action, litigation, proceedings, costs or expenses relate to events or circumstances that occur during the term of this Agreement, this section will survive the expiration of the term of this Agreement or any earlier termination of this Agreement. In the event that the completion of the project (to include the work of others) is delayed or suspended as a result of the Contractor's failure to purchase or maintain the required insurance, the Consultant shall indemnify the County from any and all increased expenses resulting from such delay. Should any claims be asserted against the County by virtue of any deficiency or ambiguity in the plans and specifications provided by the Contractor, the Contractor agrees and warrants that the Contractor shall hold the County harmless and shall indemnify it from all losses occurring thereby and shall further defend any claim or action on the County's behalf. The first ten dollars ($10.00) of remuneration paid to the Contractor is for the indemnification provided for the above. 4.0 ADMINISTRATION OF THE CONTACT 4.1 Architect/Engineer GENERAL CONDITIONS Page 23 of 46 Senior Nutrition Center Renovations 4.1.1 The Architect and /or Engineer is the person lawfully licensed to practice architecture /engineering or any entity lawfully practicing architecture /engineering identified as such in the Agreement and is referred to throughout the Contract Documents as if singular in number. The term "Architect" means the Architect or the Architect's authorized representative. 4.2 Project Management 4.2.1 Project Management is the person or entity identified as such in the Agreement and is referred to throughout the Contract Documents as if singular in number. The term "Project Management" means Monroe County Project Management Department or Project Management's authorized representative. 4.3 Duties, responsibilities and limitations of authority of Project Management and Architect as set forth in the Contract Documents shall not be restricted, modified or extended without written consent of the Owner, Project Management, Architect and Contractor. Consent shall not be unreasonably withheld. 4.4 In case of termination of employment of Architect, the Owner shall appoint an Architect whose status under the Contract Documents shall be that of the former Architect. 4.5 Not Used 4.6 Administration of the Contract 4.6.1 Project Management and Engineer will provide administration of the Contract as described in the Contract Documents, and will be the Owner's representatives (1) during construction, (2) until final payment is due and (3) with the Owner's concurrence, from time to time during the correction period described in Paragraph 12.2. Project Management and Engineer will advise and consult with the Owner and will have authority to act on behalf of the Owner only to the extent provided in the Contract Document, unless otherwise modified by written instrument in accordance with other provision of the Contract. 4.6.2 Project Management and Engineer will determine in general that the Work is being performed in accordance with the requirements of the Contract Documents, will keep the Owner informed of the progress of the Work, and will endeavor to guard the Owner against defects and deficiencies in the Work. 4.6.3 Project Management will provide for coordination of the activities of other Contractors and of the Owner's own forces with the Work of the Contractor, who shall cooperate with them. The Contractor shall participate with other Contractors and Project Management and Owner in reviewing their construction schedules when directed to do so. The Contractor shall make any revisions to the Construction schedule deemed necessary after a joint review and mutual agreement. The construction schedules shall constitute the schedules to be used by the Contractor, other Contractors, Project Management and the Owner until subsequently revised. 4.6.4 Not used. 4.6.5 Project Management will visit the site at intervals appropriate to the stage of construction to become generally familiar with the progress and quality of the completed Work and to determine in general if the Work is being performed in a manner indicating that the Work, when completed, will be in accordance with the Contract Documents. However, Project Management will not be required to make exhaustive or continuous onsite inspections to check quality or quantity of the Work. On the basis of on -site observations as an architect, Project Management will keep the Owner informed of progress of the Work, and will endeavor to guard the Owner against defects and deficiencies in the work. GENERAL CONDITIONS Page 24 of 46 Senior Nutrition Center Renovations 4.6.6 Project Management will not have control over or charge of and will not be responsible for construction means, method, techniques, sequences or procedures, or for safety precautions and programs in connection with the Work, since these are solely the Contractor's responsibility as provided in Paragraph 3.3, and neither will be responsible for the Contractor's failure to carry out the Work in accordance with the Contract Documents. Neither Project Management nor the Architect will have control over, or charge of, or be responsible for acts or omissions of the Contractor, Subcontractors, or their agents or employees, or of any other persons performing portions of the Work. 4.6.7 Communications Facilitating Contract Administration. Except as otherwise provided in the Contract Documents or when direct communications have been specially authorized, the Owner and Contractor shall communicate through Project Management, and shall contemporaneously provide the same communications to the Architect. Communications by and with the Architect's consultants shall be through the Architect. Communications by and with Subcontractors and material suppliers shall be through the Contractor. Communications by and with other Contractors shall be through Project Management and shall be contemporaneously provided to the Architect. 4.6.8 Project Management will review and certify all Applications for Payment by the Contractor, including final payment. Project Management will assemble each of the Contractor's Applications for Payment with similar Applications from other Contractor into a Project Application for Payment. After reviewing and certifying the amounts due the Contractors, the Project Application for Payment, along with the applicable Contractors' Applications for Payment, will be processed by Project Management. 4.6.9 Based on Project Management's observations and evaluations of Contractors' Applications for Payment, Project Management will certify the amounts due the Contractors and will issue a Project Approval for Payment. 4.6.10 Project Management will have authority to reject Work which does not conform to the Contract Documents, and to require additional inspection or testing, in accordance with Subparagraphs 13.5.2 and 13.5.3, whether or not such Work is fabricated, installed or completed, but will take such action only after notifying Project Management. Subject to review, Project Management will have the authority to reject Work which does not conform to the Contract Documents. Whenever Project Management considers it necessary or advisable for implementation of the intent of the Contract Documents, Project Management will have authority to require additional inspection or testing of the work in accordance with Subparagraphs 13.5.2 and 13.5.3, whether or not such Work is fabricated, installed or completed. The foregoing authority of Project Management will be subject to the provisions of Subparagraphs 4.6.18 through 4.6.20 inclusive, with respect to interpretations and decisions of the Architect. However, neither the Architect's nor Project Management's authority to act under this Subparagraph 4.6.10 nor a decision made by either of them in good faith either to exercise or not to exercise such authority shall give rise to a duty or responsibility of the Architect or Project Management to the Contractor, Subcontractors, material and equipment suppliers, their agents or employees, or other persons performing any of the Work. 4.6.11 Project Management will receive from the Contractor and review and approve all Shop Drawings, Product Data and Samples, coordinate them with information received from other Contractors, and review those recommended for approval. Project Management actions will be taken with such reasonable promptness as to cause no delay in the Work of the Contractor or in the activities of other Contractors or the Owner. 4.6.12 Project Management will review and approve or take other appropriate action upon the Contractor's submittals such as Shop Drawings, Product Data and Samples, but only for the limited purpose of checking for conformance with information given and the design concept GENERAL CONDITIONS Page 25 of 46 Senior Nutrition Center Renovations expressed in the Contract Documents. Project Management action will be taken with such promptness consistent with the constraints of the project schedule so as to cause no delay in the Work of the Contractor or in the activities of the other Contractors, the Owner, or Project Management, while allowing sufficient time to permit adequate review. Review of such submittals is not conducted for the purpose of determining the accuracy and completeness of other details such as dimensions and quantities, or for substantiating instructions for installation or performance of equipment or systems, all of which remain the responsibility of the Contractor as Contractor as required by the Contract Documents. Project Management review of the Contractor's submittals shall not relieve the Contractor of the obligations under Paragraphs 3.3, 3.5 and 3.12. Project Management's review shall not constitute approval of safety precautions or, unless otherwise specifically stated by Project Management, of any construction means, methods, techniques, sequences or procedures. Project Management's approval of a specific item shall not indicate approval of an assembly of which the item is a component. 4.6.13 Project Management will prepare Change Orders and Construction Change Directives. 4.6.14 Following consultation with the Owner, Project Management will take appropriate action on Change Orders or Construction Change Directives in accordance with Article 7 and will have authority to order minor changes in the Work as provided in Paragraph 7.4. 4.6.16 The Contractor will assist Project Management in conducting inspections to determine the dates of Substantial completion and final completion, and will receive and forward to Project Management written warranties and related documents required by the Contract and assembled by the Contractor. Project Management will review and approve a final Project Application for Payment upon compliance with the requirements of the Contract Documents. 4.6.17 Project Management will provide one or more project representatives to assist in carrying out his responsibilities at the site. The duties, responsibilities and limitations of authority of such project representatives shall be as set forth in an exhibit to be incorporated in the Contract Documents. 4.6.18 Project Management will interpret and decide matters concerning performance under and requirements of the Contract Documents on written request of the Owner or Contractor. Project Management's response to such requests will be made with reasonable promptness and within any time limits agreed upon. If no agreement is made concerning the time within which interpretations required of Project Management shall be furnished in compliance with this Paragraph 4.6, then delay shall not be recognized on account of failure by Project Management to furnish such interpretations until 15 days after written request is made for them. 4.6.19 Interpretations and decisions of Project Management will be consistent with the intent of and reasonably inferable from the Contract Documents and will be in writing or in the form of drawings. When making such interpretations and decisions, Project Management will endeavor to secure faithful performance by both Owner and Contractor, will not show partiality to either and will not be liable for results of interpretations or decisions so rendered in good faith. 4.6.20 Project Management's decisions on matters relating to aesthetic effect will be final if consistent with the intent expressed in the Contract Documents. 4.7 Claims and Disputes 4.7.1 Definition. A Claim is a demand or assertion by one of the parties seeking, as a matter of right, adjustment or interpretation of Contract terms, payment of money, extension of time or other relief with respect to the terms of the Contract. The term "Claim" also includes other disputes and matters in question between the Owner and Contractor arising out of or relating to the Contract. Claims must be made by written notice. The responsibility to substantiate Claims shall rest with the party making the claim. GENERAL CONDITIONS Page 26 of 46 Senior Nutrition Center Renovations 4.7.2 Meet and Confer. The Contractor and Project Management shall try to resolve the claim or dispute with meet and confer sessions to be commenced within 15 days of the dispute or claim. Any claim or dispute that the parties cannot resolve shall be decided by the Circuit Court, 16 Judicial Circuit, Monroe County, Florida. 4.7.3 Time Limits on Claims. Claims by either party must be made within 21 days after occurrence of the event giving rise to such Claim or within 21 days after the claimant first recognizes the condition giving rise to the Claim, whichever is later. Claims must be made by written notice. An additional Claim made after the initial Claim has been implemented by Change Order will not be considered unless submitted in a timely manner. This notice is not a condition precedent to any other legal action or suit. 4.7.4 Continuing Contract Performance. Pending final resolution of a Claim unless otherwise agreed in writing the Contractor shall proceed diligently with performance of the Contract and the Owner shall continue to make payments in accordance with the Contract Documents. 4.7.5 Waiver of Claims: Final Payment. The making of final payment shall constitute a waiver of Claim by the Owner except those arising from: .1 liens, Claims, security interests or encumbrances arising out of the Contract and unsettled; .2 failure of the Work to comply with the requirements of the Contract Documents; or .3 terms of special warranties required by the Contract Documents. 4.7.6 Claims for Concealed or Unknown Conditions. If conditions are encountered at the site which are (1) subsurface or otherwise concealed physical conditions which differ materially from those indicated in the Contract Documents or (2) unknown physical conditions of an unusual nature, which differ materially from those ordinarily found to exist and generally recognized as inherent in construction activities of the character provided for in the Contract Documents, then notice by the observing party shall be given to the other party promptly before conditions are disturbed and in no event later than 21 days after first observance of the conditions. Project Management will promptly investigate such conditions, and the parties will follow the procedure in paragraph 4.7.2. 4.7.7 Claims for Additional Cost. If the Contractor wishes to make Claim for an increase in the Contract Sum, written notice as provided herein shall be given before proceeding to execute the Work. Prior notice is not required for Claims relating to an emergency endangering life or property arising under Paragraph 10.3 If the Contractor believes additional cost is involved for reasons including but not limited to (1) a written interpretation from Project Management, (2) a written order for a minor change in the Work issued by Project Management, (3) failure of payment by the Owner, (4) termination of the Contract by the Owner, (5) Owner's suspension or (6) other reasonable grounds, Claim shall be filed in accordance with the procedure established herein. 4.7.8 Claims for Additional Time. 4.7.8.1. If the Contractor wishes to make Claim for an increase in the Contract Time, written notice as provided herein shall be given. 4.7.8.2 If adverse weather conditions are the basis for a Claim for additional time, such Claim shall be documented by data substantiating that weather conditions were abnormal for the period of time and could not have been reasonably anticipated, and that weather conditions had an adverse effect on the scheduled construction. GENERAL CONDITIONS Page 27 of 46 Senior Nutrition Center Renovations 4.7.9 Injury or Damage to Person or Property. If either party to the Contract suffers injury or damage to person or property because of an act or omission of the other party, of any of the other party's employees or agents, or of others for whose acts such party is legally liable, written notice of such injury or damage, whether or not insured, shall be given to the other party within a reasonable time not exceeding 21 days after first observance. The notice shall provide sufficient detail to enable the other party to investigate the matter. If a Claim for additional cost or time related to this Claim is to be asserted, it shall be filed as provided in Subparagraphs 4.7.7 or 4.7.8. 5.0 SUBCONTRACTORS 5.1 Definitions 5.1.1 A Subcontractor is a person or entity who has a direct contract with the Contractor to perform a portion of the Work at the site. The term "Subcontractor" is referred to throughout the Contract Documents as if singular in number and means a Subcontractor or an authorized representative of the Subcontractor. The term "Subcontractor" does not include other Contractors or subcontractors of other Contractors. 5.1.2 A Sub - subcontractor is a person or entity who has a direct or indirect contract with a Subcontractor to perform a portion of the Work at the site. The term "Sub - subcontractor" is referred to throughout the Contract Documents as if singular in number and means a Sub - subcontractor or an authorized representative of the Sub - subcontractor. 5.2 Award of Subcontracts and Other Contracts for Portions of the Work 5.2.1 Unless otherwise stated in the Contract Documents or the bidding requirements, the Contractor, as soon as practicable after award of the Contract, shall furnish in writing to Project Management for review by the Owner and Project Management the names of persons or entities (including those who are to furnish materials or equipment fabricated to a special design) proposed for each principal portion of the Work. Project Management will promptly reply to the Contractor in writing stating whether or not the Owner or Project Management, after due investigation, has reasonable objection to any such proposed person or entity. Failure of Project Management to reply promptly shall constitute notice of no reasonable objection. 5.2.2 The Contractor shall not contract with a proposed person or entity to which the Owner or Project Management has made reasonable and timely objection. The Contractor shall not be required to contract with anyone to whom the Owner or Project Management has made reasonable objection. 5.2.3 If the Owner or Project Management refuses to accept any person or entity on a list submitted by the Contractor in response to the requirements of the Contract Documents, the Contractor shall submit an acceptable substitute; however, no increase in the Contract Sum shall be allowed for any such substitution. 5.2.4 The Contractor shall not change a Subcontractor, person or entity previously selected if the Owner or Project Management makes reasonable objection to such change. 5.3 Subcontractual Relations 5.3.1 By appropriate written agreement, the Contractor shall require each Subcontractor, to the extent of the Work to be performed by the Subcontractor, to be bound to the Contractor by terms of the Contract Documents, and to assume toward the Contractor all the obligations and responsibilities which the Contractor, by these Documents, assumes toward the Owner or Project Management. Each subcontract agreement shall preserve and protect the rights of the Owner or Project Management under the Contract Documents with respect to the Work to be GENERAL CONDITIONS Page 28 of 46 Senior Nutrition Center Renovations performed by the Subcontractor so that subcontracting thereof will not prejudice such rights. When appropriate, the Contractor shall require each Subcontractor to enter into similar agreements with Sub - subcontractors. The Contractor shall make available to each proposed Subcontractor, copies of the Contract Documents which the Subcontractor will be bound, and, upon written request of the Subcontractor, identify to the Subcontractor terms and conditions of the proposed subcontract agreement which may be at variance with the Contract Documents. Subcontractors shall similarly make copies of applicable portions of such documents available to their respective proposed Sub - subcontractors. 5.4 Contingent Assignment of Subcontracts 5.4.1 Each subcontract agreement for a portion of the Work is assigned by the Contractor to the Owner provided that: .1 assignment is effective only after termination of the Contract by the Owner for cause pursuant to Paragraph 14.2 and only for those subcontract agreements which the Owner accepts by notifying the Subcontractor in writing; and .2 assignment is subject to the prior rights of the surety, if any, obligated under public construction bond covering the Contract. i. If the work has been suspended for more than 30 days, the Subcontractor's compensation shall be equitably adjusted. 6.0 CONSTRUCTION BY OWNER OR BY OTHER CONTRACTORS 6.1 Owner's Right to Perform Construction with Own Forces and to Award Other Contracts 6.1.1 The Owner reserves the right to perform construction or operations released to the Project with the Owner's own forces, which include persons or entities under separate contracts not administered by Project Management. The Owner further reserves the right to award other contracts in connection with other portions of the Project or other construction or operations on the site under Conditions of the Contract identical or substantially similar to these including those portions related to insurance and waiver or subrogation. 6.1.2 When the Owner performs construction or operations with the Owner's own forces including persons or entities under separate contracts not administered by Project Management, the Owner shall provide for coordination of such forces with the Work of the Contractor who shall cooperate with them. 6.1.3 It shall be the responsibility of the Contractor to coordinate his work with the work of other contractors on the site. The Owner and Project Management shall be held harmless for any and all costs associated with improper coordination. 6.2 Mutual Responsibility 6.2.1 The Contractor shall afford the Owner's own forces, Project Management and other contractors reasonable opportunity for introduction and storage of their materials and equipment and performance of their activities, and shall connect and coordinate the Contractor's construction and operations with theirs as required by the Contract Documents. 6.2.2 If part of the Contractor's Work depends for proper execution or results upon construction or operations by the Owner's own forces or other contractors, the Contractor shall, prior to proceeding with that portion of the Work, promptly report to Project Management any apparent discrepancies or defects in such other construction that would render it unsuitable for GENERAL CONDITIONS Page 29 of 46 Senior Nutrition Center Renovations such proper execution and results. Failure of the Contractor so to report shall constitute an acknowledgment that the Owner's own forces or other contractors' completed or partially completed construction is fit and proper to receive the Contractor's Work, except as to defects not then reasonably discoverable. 6.2.3 Costs caused by delays or by improperly timed activities or defective construction shall be borne by the Contractor. The Contractor's sole remedy as against the Owner for costs caused by delays or improperly timed activities or defective construction shall be an extension of time. 6.2.4 The Contractor shall promptly remedy damage wrongfully caused by the Contractor to completed or partially completed construction or to property of the Owner or other contractors as provided in Subparagraph 10.2.5. 6.2.5 Claims and other disputes and matters in question between the Contractor and other contractors shall be subject to the provisions of Paragraph 4.7 provided the other contractors have reciprocal obligations. 6.2.6 The Owner and other contractors shall have the same responsibilities for cutting and patching as are described for the Contractor in Paragraph 3.14. 6.2.7 Should the Contractor contend that he is entitled to an extension of time for completion of any portion or portions of the work, he shall, within (72) hours of the occurrence of the cause of the delay, notify Project Management in writing, of his contention: setting forth (A) the cause for the delay, (B) a description of the portion or portions of work affected thereby, and (C) all details pertinent thereto. A subsequent written application for the specific number of days of extension of time requested shall be made by the Contractor to Project Management within (72) hours after the delay has ceased to exist. .1 It is a condition precedent to the consideration or prosecution of any claim for an extension of time that the foregoing provisions be strictly adhered to in each instance and, if the Contractor fails to comply, he shall be deemed to have waived the claim. .2 The Contractor agrees that whether or not any delay, regardless of cause, shall be the basis for an extension of time he shall have no claim against the Owner or Project Management for an increase in the Contract price, nor a claim against the Owner or Project Management for a payment or allowance of any kind for damage, Toss or expense resulting from delays; nor shall the Contractor have any claim for damage, loss or expense resulting from interruptions to, or suspension of, his work to enable other contractors to perform their work. The only remedy available to the Contractor shall be an extension of time. 6.3 Owner's Right to Clean Up 6.3.1 If a dispute arises among the Contractor, other contractors and the Owner as to the responsibility under their respective contracts for maintaining the premises and surrounding area free from waste materials and rubbish as described in Paragraph 3.15, the Owner may clean up and allocate the cost among those responsible as Project Management determines to be just. 7.0 CHANGES IN THE WORK 7.1 Changes 7.1.1 Changes in the Work may be accomplished after execution of the Contract, and without invalidating the Contract, by Change Order, Construction Change Directive or order for a minor GENERAL CONDITIONS Page 30 of 46 Senior Nutrition Center Renovations change in the Work, subject to the limitations stated in this Article 7 and elsewhere in the Contract Documents. 7.1.2 A Change Order shall be based upon agreement among the Owner, Project Management and Contractor; a Construction Change Directive require agreement by the Owner, Project Management and may or may not be agreed to by the Contractor; an order for a minor change in the Work may be issued by Project Management alone. 7.1.3 Changes in the Work shall be performed under applicable provisions of the Contract Documents, and the Contractor shall proceed promptly, unless otherwise provided in the Change Order, Construction Change Directive or order for a minor change in the Work. 7.1.4 If unit prices are stated in the Contract Documents or subsequently agreed upon, and if quantities originally contemplated are so changed in a proposed Change Order or Construction Change Directive that application of such unit prices to quantities of Work proposed will cause substantial inequity to the Owner or Contractor, the applicable unit prices shall be equitably adjusted. 7.2 Change Orders 7.2.1 A change Order is a written instrument prepared by Project Management and signed by the Owner, Project Management and Contractor stating their agreement upon all of the following: .1 a change in the Work; .2 the amount of the adjustment in the Contract Sum, if any; and .3 the extent of the adjustment in the Contract Time, if any. 7.2.2 The cost or credit to the Owner resulting from a change in the Work shall be determined in one or more of the following methods: .1 mutual acceptance of lump sum properly itemized and supported by sufficient substantiating data to permit evaluation and payment, and approved by the appropriate authority in writing; .2 unit prices stated in the Contract Documents or subsequently agreed upon, and approved by the appropriate authority in writing; .3 cost to be determined in a manner agreed upon by the parties and a mutually acceptable fixed or percentage fee; .4 or by method provided in subparagraph 7.2.3. 7.2.3 If none of the methods set forth in Clauses 7.2.1 or 7.2.2 is agreed upon, the Contractor, provided a written order signed by the Owner or Project Management is received, shall promptly proceed with the Work involved. The cost of such Work shall then be determined by daily force accounts in a form acceptable to the Owner and Project Management. The daily force account forms shall identify Contractor and /or Subcontractor personnel by name, total hours for each man, each piece of equipment and total hours for equipment and all material(s) by type for each extra Work activity claim. Each daily force account form shall be signed by the designated Project Management representative no later than the close of business on the day the Work is performed to verify the items and hours listed. Extended pricing of these forms shall be submitted to Project Management with all supporting documentation required by Project Management for inclusion into a change order. Unless otherwise provided in the Contract Documents, cost shall be limited to the following: cost of materials, including sales tax and cost of delivery; cost of labor, including social security, old age and unemployment insurance, and GENERAL CONDITIONS Page 31 of 46 Senior Nutrition Center Renovations fringe benefits required by agreement or custom; works' or workmen's compensation insurance; and the rental value of equipment and machinery. Markups for overhead and profit will be in accordance with subparagraph 7.2.4. Pending final determination of cost, payments on account shall be made as determined by Project Management. The amount of credit to be allowed by the Contractor for any deletion or change, which results in a net decrease in the Contract Sum, will be the amount of the actual net cost to the Owner as confirmed by Project Management. When both additions and credits covering related Work or substitutions are involved in any one change, the allowance for overhead and profit shall be figured on the basis of the net increase, if any with respect to that change. 7.2.4 The actual cost of Changes in the Work may include all items of labor or material, power tools, and equipment actually used, utilities, pro rata charges for foreman, and all payroll charges such as Public Liability and Workmen's Compensation Insurance. No percentage for overhead and profit shall be allowed on items of Social Security and Sales Tax. If deductions are ordered the amount of credit shall be net cost to Owner as defined in section 5.6.1 of the Contract. Items considered as overhead shall include insurance other than that mentioned above, bond or bonds, superintendent, timekeeper, clerks, watchmen, use of small tools, miscellaneous supplies, incidental job costs, warranties, and all general home /field office expenses. The actual cost of Changes in the Work (other than those covered by unit prices set forth in the Contract Documents) shall be computed as follows: .1 if the Contractor performs the actual Work, the maximum percentage mark -up for overhead shall be five percent (5 %) and the maximum percentage for profit shall be five percent (5 %); .2 if the Subcontractor performs the actual Work, the subcontractor's percentage mark- up for overhead and profit shall be a maximum addition of ten percent (10 %). If the Contractor does not perform the Work, the maximum mark -up for managing the Work will be five percent (5 %); 3. If the Subcontractor performs part of the actual Work, his percentage mark -up for overhead and profit shall be a maximum addition of ten percent (10 %) on his direct Work only. If the Contractor performs part of the actual Work, his percentage mark -up for overhead and profit shall be a maximum addition of ten percent (10 %) on his direct Work only. 7.2.5 The Contractor shall furnish to the Owner through Project Management, an itemized breakdown of the quantities and prices used in computing the value of any change that might be ordered. Any additional supporting documentation requested by Project Management such as certified quotations or invoices shall be provided by the Contractor to Project Management at no additional cost to the Owner. 7.2.6 If the Contractor claims that any instructions given to him by Project Management, by drawings or otherwise, involve extra Work not covered by the Contract, he shall give Project Management written notice thereof within five (5) days after the receipt of such instructions and before proceeding to execute the work, except in emergencies endangering life or property, in which case the Contractor shall proceed in accordance with Paragraph 10.3. .1 The written notice to Project Management for the Extra Work shall include a complete description of the extra Work, the total cost and a detailed cost breakdown by labor, material and equipment for each additional activity required to be performed. Mark -ups shall be limited as specified elsewhere in this Article. .2 Except as otherwise specifically provided, no claim for additional cost shall be allowed unless the complete notice specified by this subparagraph is given by the Contractor. GENERAL CONDITIONS Page 32 of 46 Senior Nutrition Center Renovations 7.2.7 Unless otherwise agreed in writing, the Contractor shall carry on the Work and maintain its progress during any dispute or claim proceeding, and Owner shall continue to make payments to the Contractor in accordance with the Contract Documents. Disputes unresolved shall be settled in accordance with subparagraph 4.7. The Contractor shall maintain completed daily force account forms in accordance with subparagraph 7.2.3 for any dispute or claim item. 7.3 Authority 7.3.1 Project Management will have authority to order minor changes in the Work not involving adjustment in the Contract sum or extension of the Contract Time and not inconsistent with the intent of the Contract Documents. Such changes shall be effected by written order issued through Project Management and shall be binding on the Owner and Contractor. The Contractor shall carry out such written order promptly. 8.0 TIME 8.1 Definitions 8.1.1 Unless otherwise provided, Contract Time is the period of time, including authorized adjustments, allotted in the Contract Documents for Substantial Completion of the Work. 8.1.2 The date of commencement of the Work is the date established in the Agreement. The date shall not be postponed by the failure to act of the Contractor or of persons or entities for which the Contractor is responsible. 8.1.3 The date of Substantial Completion is the date certified by Project Management in accordance with Paragraph 9.8. 8.1.4 The term "day" as used in the Contract Documents shall mean calendar day unless otherwise specifically defined. 8.1.5 The Owner /Project Management shall be the final judge as to whether Substantial Completion has been achieved and certifies the date to the Contractor. 8.2 Progress and Completion 8.2.1 Time limits stated in the Contract Documents are of the essence of the Contract. By executing the Agreement the Contractor confirms that the Contract Time is a reasonable period for performing the Work. 8.2.2 The Contractor shall not knowingly, except by agreement or instruction of the Owner in writing, prematurely commence operations on the site or elsewhere prior to the effective date of insurance required by Article 11 to be furnished by the Contractor. The date of commencement of the Work shall not be changed by the effective date of such insurance. 8.2.3 The Contractor shall proceed expeditiously with adequate forces and shall achieve Substantial Completion within the Contract Time. 8.3 Delays and Extensions of Time 8.3.1 If the Contractor is delayed, at any time, in the progress of the Work by any act or neglect of the Owner, Project Management, or the Architect/Engineer, or by any employee of either, or by any separate contractor employed by the Owner, or by changes ordered in the Work, or by fire, unusual delay in transportation, adverse weather conditions not reasonably anticipatable, unavoidable casualties or any causes beyond the Contractor's control, or by delay authorized by the Owner, Project Management, or by any other cause which Project GENERAL CONDITIONS Page 33 of 46 Senior Nutrition Center Renovations Management determines may justify the delay, then the Contract Time shall be extended by no cost Change Order for such reasonable time as Project Management may determine, in accordance with subparagraph 6.2.7. 8.3.2 Any claim for extension of time shall be made in writing to Project Management not more than Seventy -two (72) hours after the commencement of the delay in accordance with paragraph 6.2.7; otherwise it shall be waived. Any claim for extension of time shall state the cause of the delay and the number of days of extension requested. If the cause of the delay is continuing, only one claim is necessary, but the Contractor shall report the termination of the cause for the delay within seventy -two (72) hours after such termination in accordance with paragraph 6.2.7; otherwise, any claim for extension of time based upon that cause shall be waived. 8.3.3 No claim for an increase in the Contract Sum for either acceleration or delay will be allowed for extensions of time pursuant to this Paragraph 8.3 or for other changes in the Construction Schedules. 8.3.4 If the Project is delayed as a result of the Contractor's refusal or failure to begin the Work on the date of commencement as defined in Paragraph 8.1.2, or his refusal or failure to carry the Work forward expeditiously with adequate forces, the Contractor causing the delay shall be liable for, but not limited to, delay claims from other Contractors which are affected. 9.0 PAYMENTS AND COMPLETION 9.1 Contract Sum 9.1.1 The Contract Sum is stated in the Agreement and, including authorized adjustments, is the total amount payable by the Owner to the Contractor for performance of the Work under the Contract Documents. 9.2 Schedule of Values 9.2.1 Before submittal of the first Application for Payment, the Contractor shall submit to Project Management, a schedule of values allocated to various portions of the Work, prepared in such form and supported by such data to substantiate its accuracy as Project Management may require. This schedule, unless objected to by Project Management, shall be used as a basis for reviewing the Contractor's Applications for Payment. 9.3 Applications for Payment 9.3.1 At least fifteen days before the date established for each progress payment, the Contractor shall submit to Project Management an itemized Application for Payment for Work completed in accordance with the schedule of values. Such application shall be notarized and supported by such data substantiating the Contractor's right to payment as the Owner or Project Management may require, such as copies of requisitions from Subcontractors and material suppliers, and reflecting retainage if provided for elsewhere in the Contract Documents. .1 Such applications may include request for payment on account of changes in the Work which have been properly authorized by Construction Change Directives but not yet included in Change Orders. GENERAL CONDITIONS Page 34 of 46 Senior Nutrition Center Renovations .2 Such applications may not include requests for payment of amounts the Contractor does not intend to pay to a Subcontractor or material supplier because of a dispute or other reason. 9.3.2 Unless otherwise provided in the Contract Documents, payments shall be made on account of materials and equipment delivered and suitably stored at the site for subsequent incorporation in the Work. If approved in advance by the Owner, payment may similarly be made for materials and equipment suitably stored off the site at a location agreed upon in writing. Payment for materials and equipment stored on or off the site shall be conditioned upon compliance by the Contractor with procedures satisfactory to the Owner to establish the Owner's title to such materials and equipment or otherwise protect the Owner's interest, and shall include applicable insurance, storage and transportation to the site for such materials and equipment stored off the site. 9.3.3 The Contractor warrants that title to all Work covered by an Application for Payment will pass to the Owner no later than the time of payment. The Contractor further warrants that upon submittal of an Application for Payment all Work for which approval for payment have been previously issued and payments received from the Owner shall, to the best of the Contractor's knowledge, information and belief, be free and clear of liens, claims security interests or encumbrances in favor of the Contractor, Subcontractors, material suppliers, or other persons or entities making a claim by reason of having provided labor, materials and equipment relating to the Work. All Subcontractors and Sub - subcontractors shall execute an agreement stating that title will so pass, upon their receipt of payment from the Contractor. The warranties are for the administrative convenience of the Owner only and do not create an obligation on the part of the Owner to pay directly any unpaid subcontractor, laborer or materialmen. Such persons must seek payment from the Contractor or his public construction bond surety only. 9.4 Approval for Payment 9.4.1 Project Management will assemble a Project Application for Payment by combining the Contractor's applications with similar applications for progress payments from other Contractors and certify the amounts due on such applications. 9.4.2 After the Project Management's receipt of the Project Application for Payment, Project Management will either approve the Application for Payment, with a copy to the Contractor, for such amount as Project Management determine is properly due, or notify the Contractor in writing of Project Management's reasons for withholding approval in whole or in part as provided in Subparagraph 9.5.1. 9.4.3 The issuance of a separate Approval for Payment will constitute representations made by Project Management to the Owner, based on their individual observations at the site and the data comprising the Application for Payment submitted by the Contractor, that the Work has progressed to the point indicated and that, to the best of Project Management's knowledge, information and belief, quality of the Work is in accordance with the Contract Documents. The foregoing representations are subject to an evaluation of the Work for conformance with the Contract Documents upon Substantial Completion, to results of subsequent tests and inspections, to minor deviations from the Contract Documents correctable prior to completion and to specific qualifications expressed by Project Management. The issuance of a separate Approval for Payment will further constitute a representation that the Contractor is entitled to payment in the amount approved. However, the issuance of a separate Approval for Payment will not be a representation that Project Management has (1) made exhaustive or continuous on -site inspections to check the quality or quantity of the Work, (2) reviewed the Contractor's construction means, methods, techniques, sequences or procedures, (3) reviewed copies of GENERAL CONDITIONS Page 35 of 46 Senior Nutrition Center Renovations requisitions received from Subcontractors and material suppliers and other data requested by the Owner to substantiate the Contractor's right to payment or (4) made examination to ascertain how or for what purpose the Contractor has used money previously paid on account of the Contract Sum. 9.5 Decisions to Withhold Approval 9.5.1 Project Management may decline to approve an Application for Payment if, in his opinion, the application is not adequately supported. If the Contractor and Project Management cannot agree on a revised amount, Project Management shall process the Application for the amount it deems appropriate. Project Management may also decline to approve any Application for Payment because of subsequently discovered evidence or subsequent inspections. It may nullify, in whole or part, any approval previously made to such extent as may be necessary in its opinion because of: (1) defective Work not remedied; (2) third party claims filed or reasonable evidence indicating probable filing of such claims; (3) failure of the Contractor to make payments properly to Subcontractors or for labor, materials, or equipment; (4) reasonable evidence that the Work cannot be completed for the unpaid balance of the Contract Sum; (5) damage to Project Management, the Owner, or another contractor working at the project; (6) reasonable evidence that the Work will not be completed within the contract time; (7) persistent failure to carry out the Work in accordance with the Contract Documents. No payment shall be made to the Contractor until certificates of insurance or other evidence of compliance by the Contractor, with all the requirements of Article 11, have been filed with the Owner and Project Management. 9.5.2 When the above reasons for withholding approval are removed, approval will be made for amounts previously withheld. 9.6 Progress Payments 9.6.1 After Project Management has issued an Approval for Payment, the Owner shall make payment in the manner and within the time provided in the Contract Documents, and shall so notify Project Management. From the total of the amount determined to be payable on a progress payment, a retainage in accordance with the Florida Local Government Prompt Payment Act, Chapter 218, Florida Statutes will be deducted and retained by the Owner until the final payment is made. The balance of the amount payable, less all previous payments, shall be approved for payment. .1 It is understood and agreed that the Contractor shall not be entitled to demand or receive progress payment based on quantities of Work in excess of those provided in the proposal or covered by approved change orders, except when such excess quantities have been determined by Project Management to be a part of the final quantity for the item of Work in question. .2 No progress payment shall bind the Owner to the acceptance of any materials or Work in place, as to quality or quantity. All progress payments are subject to correction at the time of final payments. 9.6.2 The Contractor shall promptly pay each Subcontractor, upon receipt of payment from the Owner, out of the amount paid to the Contractor on account of such Subcontractor's portion of the Work, the amount to which said Subcontractor is entitled, reflecting percentages actually retained from payments to the Contractor on account of such Subcontractor's portion of the Work. The Contractor shall, by appropriate agreement with each Subcontractor, require each Subcontractor to make payments to Sub - subcontractors in similar manner. GENERAL CONDITIONS Page 36 of 46 • Senior Nutrition Center Renovations 9.6.3 Project Management will, on request, furnish to a Subcontractor, if practicable, information regarding percentages of completion or amounts applied for by the Contractor and action taken thereon by the Owner and Project Management on account of portions of the Work done by such Subcontractor. 9.6.4 Neither the Owner nor Project Management shall have an obligation to pay, or to see to, the payment of money to a Subcontractor except as may otherwise be required by law. 9.6.5 Payment to material suppliers shall be treated in a manner similar to that provided in Subparagraphs 9.6.2, 9.6.3 and 9.6.4. 9.6.6 A progress payment, or partial or entire use or occupancy of the Project by the Owner shall not constitute acceptance of Work not in accordance with the Contract Documents. 9.6.7 All material and work covered by partial payments made shall thereupon become the sole property of the Owner, and by this provision shall not be construed as relieving the Contractor from the sole responsibility for the materials and Work upon which payments have been made or the restoration for any damaged material, or as a waiver of the right of the Owner or Project Management to require the fulfillment of all the terms of the Contract. 9.6.8 Except in case of bona fide disputes, or where the Contractor has some other justifiable reason for delay, the Contractor shall pay for all transportation and utility services not later than the end of the calendar month following that in which services are rendered and for all materials, tools, and other expendable equipment which are delivered at the site of the Project. The Contractor shall pay to each of his Subcontractors, not later than the end of the calendar month in which each payment is made to the Contractor, the representative amount allowed the Contractor on account of the Work performed by the Subcontractor. The Contractor shall, by an appropriate agreement with each Subcontractor, also require each Subcontractor to make payments to his suppliers and Sub - subcontractors in a similar manner. 9.8 Substantial Completion 9.8.1 Substantial Completion is the stage in the progress of the Work when the Work or designated portion thereof is sufficiently complete in accordance with the Contract Documents so the Owner can occupy or utilize the Work for its intended use. 9.8.2 When the Contractor considers that the Work, or a portion thereof which the Owner agrees to accept separately, is substantially complete, the Contractor and Project Management shall jointly prepare a comprehensive list of items to be completed or corrected. The Contractor shall proceed promptly to complete and correct items on the list. Failure to include an item on such list does not alter the responsibility of the Contractor to complete all Work in accordance with the Contract Documents. Upon receipt of the list, Project Management will make an inspection to determine whether the Work or designated portion thereof is substantially complete. If the inspection discloses any item, whether or not included on the list, which is not in accordance with the requirements of the Contract Documents, the Contractor shall, before issuance of the Certificate of Substantial Completion, complete or correct such item upon notification by Project Management. The Contractor shall then submit a request for another inspection by Project Management, to determine Substantial Completion. When the Work or designated portion thereof is substantially complete, Project Management will prepare a Certificate of Substantial Completion, shall establish responsibilities of the Owner and Contractor for security, maintenance, heat, utilities, damage to the Work and insurance, and shall fix the time within which the Contractor shall finish all items on the list accompanying the Certificate. Warranties required by the Contract Documents shall commence on the date of Substantial Completion of the Work or designated portion thereof unless otherwise provided in the Certificate of Substantial Completion. The Certificate of Substantial Completion shall be GENERAL CONDITIONS Page 37 of 46 Senior Nutrition Center Renovations submitted to the Owner and Contractor for their written acceptance of responsibilities assigned to them in such Certificate. 9.8.3 Upon Substantial Completion of the Work or designated portion thereof and upon application by the Contractor and certification by Project Management, the Owner shall make payment, reflecting adjustment in retainage, if any, for such Work or portion thereof as provided in the Contract Documents. 9.9 Partial Occupancy or Use 9.9.1 The Owner may occupy or use any completed or partially completed portion of the Work at any stage when such portion is designated by separate agreement with the Contractor, provided such occupancy or use is consented to by the insurer as required under Subparagraph 11.3.1 and authorized by public authorities having jurisdiction over the Work. Such partial occupancy or use may commence whether or not the portion is substantially complete, provided the Owner and Contractor have accepted in writing the responsibilities assigned to each of them for payments, retainage if any, security, maintenance, heat, utilities, damage to the Work and insurance, and have agreed in writing concerning the period for correction of the Work and commencement of warranties required by the Contract Documents. When the Contractor considers a portion substantially complete, the Contractor and Project Management shall jointly prepare a list as provided under Subparagraph 9.8.2. Consent of the Contractor to partial occupancy or use shall not be unreasonably withheld. The stage of the progress of the Work shall be determined by written agreement between the Owner and Contractor or, if no agreement is reached, by decision of Project Management. 9.9.2 Immediately prior to such partial occupancy or use, the Owner, Project Management and Contractor shall jointly inspect the area to be occupied or portion of the Work to be used in order to determine and record the condition of the Work. 9.9.3 Unless otherwise agreed upon, partial occupancy or use of a portion or portions of the Work shall not constitute acceptance of Work not complying with the requirements of the Contract Documents. 9.10 Final Completion and Final Payment 9.10.1 Upon completion of the Work, the Contractor shall forward to Project Management a written Notice that the Work is ready for final inspection and acceptance and shall also forward to Project Management a final Contractor's Application for Payment. Upon receipt, Project Management will promptly make such inspection. When Project Management, finds the Work acceptable under the Contract Documents and the Contract fully performed, Project Management will promptly issue a final Approval for Payment stating that to the best of their knowledge, information and belief, and on the basis of their observations and inspections, the Work has been completed in accordance with terms and conditions of the Contract Documents and that the entire balance found to be due the Contractor and noted in said final Approval is due and payable. Project Management's final Approval for Payment will constitute a further representation that conditions listed in Subparagraph 9.10.2 as precedent to the Contractor's being entitled to final payment have been fulfilled. 9.10.2 Neither final payment nor any remaining retained percentage shall become due until the Contractor submits to Project Management (1) an affidavit that payrolls, bills for materials and equipment, and other indebtedness connected with the Work for which the Owner or the Owner's property might be responsible or encumbered (less amounts withheld by Owner) have GENERAL CONDITIONS Page 38 of 46 Senior Nutrition Center Renovations been paid or otherwise satisfied, (2) a certificate evidencing that insurance required by the Contract Documents to remain in force after final payment is made, is currently in effect and will not be canceled or allowed to expire until at least 30 days' prior written notice has been given to the Owner, (3) a written statement that the Contractor knows of no substantial reason that the insurance will not be renewable to cover the period required by the Contract Documents, (4) consent of surety, if any, to final payment and (5), if required by the Owner, other data establishing payment or satisfaction of obligations, such as receipts, releases and waivers of liens, claims, security interests or encumbrances arising out of the Contract. The following documents (samples included in section 1027) are required for Final Payment: (1) Application and Certificate for Payment (2) Continuation Sheet (3) Certificate of Substantial Completion (4) Contractor's Affidavit of Debts and Claims (5) Contractor's Affidavit of Release of Liens (6) Final Release of Lien (7) Contractor shall provide two (2) hard copies in tabulated divided binders and one (1) saved electronically tabbed and indexed in Adobe Acrobat file (.PDF) format delivered on a downloadable CD /DVD of all the following but not limited to: A .Project Record Documents (As Built Documents). B. Operating and maintenance data, instructions to the Owner's personnel. C. Warranties, bond and guarantees. D. Keys and keying schedule. E. Spare parts and maintenance materials. F.Electronic copies of approved submittals G. Evidence of payment and final release of liens and consent of surety to final release (includes final release from all utilities and utility companies). 9.10.3 Acceptance of final payment by the Contractor, a Subcontractor or material supplier shall constitute a waiver of claims by that payee except those previously made in writing and identified by that payee as unsettled at the time of final Application for Payment. Such waivers shall be in addition to the waiver described Subparagraph 4.7.5. 9.11 Payment of Subcontractors 9.11.1 Any requirement of this Article 9 that the Contractor furnish proof to the Owner or Project Management that the subcontractors and materialmen have been paid is for the protection and convenience of the Owner only. Unpaid subcontractors and materialmen may only seek payment from the Contractor and the surety that provided the Contractor's Public Construction Bond. The Contractor must insert this paragraph 9.11 in all its contracts with subcontractors and materialmen. 10.0 PROTECTION OF PERSONS AND PROPERTY GENERAL CONDITIONS Page 39 of 46 Senior Nutrition Center Renovations 10.1 Safety Precautions and Programs 10.1.1 The Contractor shall be responsible for initiating, maintaining and supervising all safety precautions and programs in connection with the performance of the Contract. The Contractor shall submit the Contractor's safety program to Project Management for review, approval and coordination with the safety programs of other Contractors. 10.1.2 In the event the Contractor encounters on the site material reasonably believed to be asbestos or polychlorinated biphenyl (PCB) which has not been rendered harmless, the Contractor shall immediately stop Work in the area affected and report the condition to the Owner and Project Management in writing. The Work in the affected area shall not thereafter be resumed except by written agreement of the Owner and Contractor if in fact the material is asbestos or polychlorinated biphenyl (PCB) and has not been rendered harmless. The Work in the affected area shall be resumed in the absence of asbestos or polychlorinated biphenyl (PCB), or when it has been rendered harmless, by written agreement of the Owner and Contractor. 10.1.3 The Contractor shall not be required pursuant to Article 7 to perform without consent any Work relating to asbestos or polychlorinated biphenyl (PCB). 10.1.5 If reasonable precautions will be inadequate to prevent foreseeable bodily injury or death to persons resulting from a material or substance encountered on the site by the Contractor, the Contractor shall, upon recognizing the condition, immediately stop Work in the affected area and report the condition to Project Management in writing. The Owner, Contractor and Project Management shall then proceed in the same manner described in Subparagraph 10.1.2. 10.1.6 The Owner shall be responsible for obtaining the services of a licensed laboratory to verify a presence or absence of the material or substance reported by the Contractor and, in the event such material or substance is found to be present, to verify that it has been rendered harmless. Unless otherwise required by the Contract Documents, the Owner shall furnish in writing to the Contractor and Project Management the names and qualifications of persons or entities who are to perform tests verifying the presence or absence of such material or substance or who are to perform the task of removal or safe containment of such material or substance. The Contractor and Project Management will promptly reply to the Owner in writing stating whether or not any of them has reasonable objection to the persons or entities proposed by the Owner. If the Contractor or Project Management has an objection to a person or entity proposed by the Owner, the Owner shall propose another to whom the Contractor and Project Management have no reasonable objection. 10.2 Safety of Persons and Property 10.2.1 The Contractor shall take reasonable precautions for safety of, and shall provide reasonable protection to prevent damage, injury or Toss to: .1 employees on the Work and other persons who may be affected thereby; .2 the Work and materials and equipment to be incorporated therein, whether in storage on or off the site, under care, custody or control of the Contractor or the Contractor's Subcontractors or Sub - subcontractors; .3 other property at the site or adjacent thereto, such as trees, shrubs, lawns, walks, pavements, roadways, structures and utilities not designated for removal, relocation or replacement in the course of construction; and .4 construction or operations by the Owner or other Contractors. GENERAL CONDITIONS Page 40 of 46 Senior Nutrition Center Renovations 10.2.2 The Contractor shall give notices and comply with applicable laws, ordinances, rules, regulations and lawful orders of public authorities bearing on safety of persons or property or their protection from damage, injury or loss. 10.2.3 The Contractor shall erect and maintain, as required by existing conditions and performance of the Contract, reasonable safeguards for safety and protection, including posting danger signs and other warnings against hazards, promulgating safety regulations and notifying owners and users of adjacent sites and utilities. 10.2.4 When use or storage of explosives or other hazardous materials or equipment or unusual methods are necessary for execution of the Work, the Contractor shall exercise utmost care and carry on such activities under supervision of properly qualified personnel. 10.2.5 The Contractor shall promptly remedy damage and loss to property referred to in Clauses 10.2.1.2, 10.2.1.3, 10.2.1.4 caused in whole or in part by the Contractor, a Subcontractor, a Sub - subcontractor, or anyone directly or indirectly employed by any of them, or by anyone for whose acts they may be liable and for which the Contractor is responsible under Clauses 10.2.1.2, 10.2.1.3 and 10.2.1.4, except damage or Toss attributable to acts or omissions of the Owner, Project Management or Architect or anyone directly or indirectly employed by any of them, or by anyone for whose acts any of them may be liable, and not attributable to the fault or negligence of the Contractor. The foregoing obligations of the Contractor are in addition to the Contractor's obligations under Paragraph 3.18. 10.2.6 The Contractor shall designate a responsible member of the Contractor's organization at the site whose duty shall be the prevention of accidents. This person shall be the Contractor's superintendent unless otherwise designated by the Contractor in writing to the Owner or Project Management. 10.2.7 The Contractor shall not Toad or permit any part of the construction or site to be loaded so as to endanger its safety. 10.3 Emergencies 10.3.1 In an emergency affecting safety of persons or property, the Contractor shall act, at the Contractor's discretion, to prevent threatened damage, injury or loss. Additional compensation or extension of time claimed by the Contractor on account of an emergency shall be determined as provided in Paragraph 4.7 and Article 7. 10.4 Site Specific Safety Plan See Section 00970 for minimum requirements of job site safety plan. 11.0 INSURANCE AND BONDS 11.1.1 Prior to commencement of Work governed by this contract (including the pre- staging of personnel and material), the Contractor shall obtain, at its own expense, insurance as specified in the schedule set forth in Section 00110 Bid Form which are made part of this Agreement. The Contractor will ensure that the insurance obtained will extend protection to all subcontractors engaged by the Contractor. As an alternative the Contractor may require all subcontractors to obtain insurance consistent with the attached schedules. 11.1.2 The Contractor will not be permitted to commence Work governed by the Agreement (including pre- staging of personnel and material) until satisfactory evidence of the required insurance has been furnished to the County as specified below. Delays in the commencement of Work resulting from the failure of the Contractor to provide satisfactory evidence of the GENERAL CONDITIONS Page 41 of 46 Senior Nutrition Center Renovations required insurance shall not extend deadlines specified in this Agreement and any penalties and failure to perform assessments shall be imposed as if the Work commenced on the specified date and time, except for the Contractor's failure to provide satisfactory evidence of insurance. 11.1.3 The Contractor shall maintain the required insurance throughout the entire term of this contract and any extensions specified in any attached schedules. Failure to comply with this provision may result in the immediate suspension of all Work until the required insurance has been reinstated or replaced. Delays in the completion of Work resulting from the failure of the Contractor to maintain the required insurance shall not extend deadlines specified in this Agreement and any penalties and failure to perform assessments shall be imposed as if the Work commenced on the specified date and time, except for the Contractor's failure to provide satisfactory evidence of insurance. 11.1.4 The Contractor shall provide, to the County in care of Project Management as satisfactory evidence of the required insurance, either: Certificate of Insurance Or A certified copy of the actual insurance policy 11.1.5 The County, at its sole option, has the right to request a certified copy of any or all insurance policies required by this Contract. 11.1.6 All insurance policies must specify that they are not subject to cancellation, nonrenewal, material change, or reduction in coverage unless a minimum of thirty (30) days prior notification is given to the County by the insurer. 11.1.7 The acceptance and /or approval of the Contractor's insurance shall not be construed as relieving the Contractor from any liability or obligation assumed under this contract or imposed by law. 11.1.8 The Monroe County Board of County Commissioners, its employees and officials will be included as "Additional Insured" on all policies, except for Worker's Compensation. 11.1.9 In addition, the County will be named as an additional insured and loss payee on all policies covering County -owned property. 11.1.10 Any deviations from these General Insurance Requirements must be requested in writing on the County prepared form entitled "Request for Waiver of Insurance Requirements" and approved by the Monroe County's Risk Manager. 11.2 Builder's Risk Insurance: Required 11.3 Public Construction Bond 11.3.1 A Public Construction Bond in the amount of the cost of construction is a requirement of this Contract. 12.0 UNCOVERING AND CORRECTION OF WORK GENERAL CONDITIONS Page 42 of 46 Senior Nutrition Center Renovations 12.1 Uncovering of Work 12.1.1 If a portion of the Work is covered contrary to Project Management's request or to requirements specifically expressed in the Contract Documents, it must, if required in writing by Project Management, be uncovered for their observation and be replaced at the Contractor's expense without change in the Contract Time. 12.1.2 If a portion of the Work has been covered which Project Management has not specifically requested to observe prior to its being covered, Project Management may request to see such Work and it shall be uncovered by the Contractor, if such Work is in accordance with the Contract Documents, costs of uncovering and replacement shall, by appropriate Change Order, be charged to the Owner, if such Work is not in accordance with the Contract Documents, the Contractor shall pay such costs unless the condition was caused by the Owner or one of the other Contractors in which event the Owner shall be responsible for payment of such costs. 12.2 Correction of Work 12.2.1 The Contractor shall promptly correct Work rejected by Project Management or failing to conform to the requirements of the Contract Documents, whether observed before or after Substantial Completion and whether or not fabricated, installed or completed. The Contractor shall bear costs of correcting such rejected Work, including additional testing and inspections and compensation for Project Management's services and expenses made necessary thereby. 12.2.2 If, within one year after the date of Substantial Completion of the Work or designated portion thereof, or after the date for commencement of warranties established under Subparagraph 9.9, or by terms of an applicable special warranty required by the Contract Documents, any of the Work is found to be not in accordance with the requirements of the Contract Documents, the Contractor shall correct it promptly after receipt of written notice from the Owner to do so unless the Owner has previously given the Contractor a written acceptance of such condition. This period of one year shall be extended with respect to portions of Work first performed after Substantial Completion by the period of time between Substantial Completion and the actual performance of the Work. This obligation under this Subparagraph 12.2.2 shall survive acceptance of the Work under the Contract and termination of the Contract. The Owner shall give such notice promptly after discovery of the condition. 12.2.3 The Contractor shall remove from the site portions of the Work which are not in accordance with the requirements of the Contract Documents and are neither corrected by the Contractor nor accepted by the Owner. 12.2.4 If the Contractor fails to correct nonconforming Work within a reasonable time, the Owner may correct it in accordance with Paragraph 2.4. If the Contractor does not proceed with correction of such nonconforming Work within a reasonable time fixed by written notice from Project Management, the Owner may remove it and store the salvageable materials or equipment at the Contractor's expense. If the Contractor does not pay costs of such removal and storage within ten days after written notice, the Owner may upon ten additional days' written notice sell such materials and equipment at auction or at private sale and shall account for the proceeds thereof, after deducting costs and damages that should have been borne by the Contractor, including compensation for Project Management's services and expenses made necessary thereby. If such proceeds of sale do not cover costs which the Contractor should have borne, the Contract Sum shall be reduced by the deficiency. If payments then or thereafter due the Contractor are not sufficient to cover such amount, the Contractor shall pay the difference to the Owner. GENERAL CONDITIONS Page 43 of 46 Senior Nutrition Center Renovations 12.2.5 The Contractor shall bear the cost of correcting destroyed or damaged construction, whether completed or partially completed, of the Owner or other Contractors caused by the Contractor's correction or removal of Work which is not in accordance with the requirements of the Contract Documents. 12.2.6 Nothing contained in this Paragraph 12.2 shall be construed to establish a period of limitation with respect to other obligations which the Contractor might have under the Contract Documents. Establishment of the time period of one year as described in Subparagraph 12.2.2, relates only to the specific obligation of the Contractor to correct the Work, and has no relationship to the time within which the obligation to comply with the Contract Documents may be sought to be enforced, nor to the time within which proceedings may be commenced to establish the Contractor's liability with respect to the Contractor's obligations other than specifically to correct the Work. 12.3 Acceptance of Nonconforming Work 12.3.1 If the Owner prefers to accept Work which is not in accordance with the requirements of the Contract Documents, the Owner may do so instead of requiring its removal and correction, in which case the Contract Sum will be reduced as appropriate and equitable. Such adjustment shall be effected whether or not final payment has been made. 13.0 MISCELLANEOUS PROVISIONS 13.1 Governing Law 13.1.1 The contract shall be governed by the laws of the State of Florida. Venue for any claims or disputes arising under this contract shall be in the Circuit Court of the 16th Judicial Circuit of the State of Florida. 13.2 Successors and Assigns 13.2.1 The Owner or Project Management (as the case may be) and the Contractor each binds himself, his partners, successors, assigns, and legal representatives of such other party in respect to all covenants, agreements, and obligations contained in the Contract Documents. Neither party to the Contract shall assign the Contract or sublet it as a whole without the written consent of the other. 13.2.2 The Contractor shall not assign any monies due or to become due under this Contract without prior written consent of the Owner or Project Management. 13.3 Written Notice 13.3.1 Any written notices or correspondence given pursuant to this contract shall be sent by United States Mail, certified, return receipt requested, or by courier with proof of delivery. Notice shall be sent to the following persons: For Contractor: Burke Construction Group, Inc. 10145 NW 19 Street Doral, FL 33172 For Owner: Director of Project Management County Administrator 1100 Simonton St., Room 2 -216 1100 Simonton St. Key West, Florida 33040 Key West Florida 33040 GENERAL CONDITIONS Page 44 of 46 Senior Nutrition Center Renovations 13.4 Rights and Remedies 13.4.1 Duties and obligations imposed by the Contract Documents and rights and remedies available thereunder shall be in addition to and not a limitation of duties, obligations, rights and remedies otherwise imposed or available by law. 13.4.2 No action or failure to act by the Owner, Project Management, Architect or Contractor shall constitute a waiver of a right or duty afforded them under the contract, nor shall such action or failure to act constitute approval of or acquiescence in a breach thereunder, except as may be specifically agreed in writing. 13.5 Tests and Inspections 13.5.1 Tests, inspections and approvals of portions of the Work required by the Contract Documents or by laws, ordinances, rules, regulations or orders of public authorities having jurisdiction shall be made at an appropriate time. Unless otherwise provided, the Contractor shall make arrangements for such tests, inspections and approvals with an independent testing laboratory or entity acceptable to the Owner, or with the appropriate public authority, and shall bear all related costs of tests, inspections and approvals. The Contractor shall give Project Management timely notice of when and where tests and inspections are to be made so Project Management may observe such procedures. The Owner shall bear costs of test, inspections or approvals which do not become requirements until after bids are received or negotiations concluded. 13.5.2 If Project Management, Owner or public authorities having jurisdiction determine that portions of the Work require additional testing, inspection or approval not included under Subparagraph 13.5.1, Project Management will, upon written authorization from the Owner, instruct the Contractor to make arrangements for such additional testing, inspection or approval by an entity acceptable to the Owner, and the Contractor shall give timely notice to Project Management of when and where tests and inspections are to be made so Project Management may observe such procedures. The Owner shall bear such costs except as provided in Subparagraph 13.5.3. 13.5.3 If such procedures for testing, inspection or approval under Subparagraphs 13.5.1 and 13.5.2 reveal failure of the portions of the Work to comply with requirements established by the Contract Documents, the Contractor shall bear all costs made necessary by such failure including those of repeated procedures and compensation for Project Management's services and expenses. 13.5.4 Required certificates of testing, inspection or approval shall, unless otherwise required by the Contract Documents, be secured by the Contractor and promptly delivered to Project Management. 13.5.5 If Project Management is to observe tests, inspections or approvals required by the Contract Documents, Project Management will do so promptly and, where practicable, at the normal place of testing. 13.5.6 Test or inspections conducted pursuant to the Contract Documents shall be made promptly to avoid unreasonable delay in the Work. 13.7 Commencement of Statutory Limitation Period 13.7.1 The statute of limitations applicable to this contact are as provided in Section 95.11 (3) (C), Florida Statutes. GENERAL CONDITIONS Page 45 of 46 Senior Nutrition Center Renovations SECTION 00110 PROPOSAL FORM Revised 2/20/2015 PROPOSAL TO: MONROE COUNTY BOARD OF COUNTY COMMISSIONERS c/o PURCHASING DEPARTMENT 1100 SIMONTON STREET ROOM 1 -213 KEY WEST, FLORIDA 33040 PROPOSAL FROM: Burke Construction Group, Inc. 3210 Flagler Avenue Key West, FL 33040 The undersigned, having carefully examined the Work and reference Drawings, Specifications, Proposal, and Addenda thereto and other Contract Documents for the construction of: SENIOR NUTRITION CENTER RENOVATIONS and having carefully examined the site where the Work is to be performed, having become familiar with all local conditions including labor affecting the cost thereof, and having familiarized himself with material availability, Federal, State, and Local laws, ordinances, rules and regulations affecting performance of the Work, does hereby propose to furnish all labor, mechanics, superintendents, tools, material, equipment, transportation services, and all incidentals necessary to perform and complete said Work and work incidental hereto, in a workman -like manner, in conformance with said Drawings, Specifications, and other Contract Documents including Addenda issued thereto. The undersigned further certifies that he has personally inspected the actual location of where the Work is to be performed, together with the local sources of supply and that he understands the conditions under which the Work is to be performed. The successful proposer shall assume the risk of any and all costs and delays arising from the existence of any subsurface or other latent physical condition which could be reasonably anticipated by reference to documentary information provided and made available, and from inspection and examination of the site. The Base Proposal shall be furnished below in words and numbers. If there is an inconsistency between the two the Proposal in words shall control. Four Hundred Forty - Four Thousand Nine Hundred Sixty - Nine Dollars. (Total Base Proposal- words) $ 444,969.00 (Total Base Proposal — numbers) I acknowledge Alternates as follows: 1. Alternate #1 Forty - One Thousand Six Hundred Sixty - Two Dollars (Alternate #1- words) PROPOSAL FORM 00110 -Page 18 of 205 Senior Nutrition Center Renovations 14.0 TERMINATION OR SUSPENSION OF THE CONTRACT 14.1 Termination by the Owner for Cause 14.1.1 The Owner may terminate the Contract if the Contractor: .1 persistently or repeatedly refuses or fails to supply enough properly skilled workers or proper materials; .2 fails to make payment to Subcontractors for materials or labor in accordance with the respective agreements between the Contractor and the Subcontractors; .3 persistently disregards laws, ordinances, or rules, regulations or orders of a public authority having jurisdiction; .or .4 Otherwise is guilty of substantial breach of a provision of the Contract Documents. 14.1.2 When any of the above reasons exist, the Owner, after consultation with Project Management, and upon certification by Project Management that sufficient cause exists to justify such action, may without prejudice to any other rights or remedies of the Owner and after giving the Contractor and the Contractor's surety, if any, 72 hours written notice, terminate employment of the Contractor and may, subject to any prior rights of the surety: .1 take possession of the site and of all materials, equipment, tools, and construction equipment and machinery thereon owned by the Contractor; .2 accept assignment of subcontracts pursuant to Paragraph 5.4; and .3 finish the Work by whatever reasonable method the Owner may deem expedient. 14.1.3 When the Owner terminates the Contract for one of the reasons stated in Subparagraph 14.1.1, the Contractor shall not be entitled to receive further payment until the Work is finished. 14.2 Suspension or Termination by the Owner for Convenience 14.2.1 The Owner may, without cause, order the Contractor in writing to terminate, suspend, delay or interrupt the Work in whole or in part for such period of time as the Owner may determine. 14.2.2 In the event of Termination the Owner shall pay for work completed to date of Termination. GENERAL CONDITIONS Page 46 of 46 Senior Nutrition Center Renovations $ 41,662.00 (Alternate #1— numbers) 2. Alternate #2 Eleven Thousand One Hundred Eighty - Two Dollars (Alternate #2 words) $ 11,182.00 (Alternate #2— numbers) 3. Alternate #3 Seventeen Thousand Two Hundred Nineteen (Alternate #3 words) Dollars $ 17,219.00 (Alternate #3— numbers) 4. Alternate #4 Thirteen Thousand Six Hundred Eighty -Two Dollars (Alternate #4- words) $ 13,682.00 (Alternate #4— numbers) 1. Unit Price #1 One Hundred Eighty - One Dollars /Cubic Foot (Unit Price #1 - words) $ 181.00 /Cubic Foot (Unit Price #1 — numbers) I acknowledge receipt of Addenda No.(s) No. 1 Dated 2/19/15 No. 2 Dated 2/20/15 No. Dated No. Dated PROPOSAL FORM 00110 -Page 19 of 205 Senior Nutrition Center Renovations Proposer, states by his check mark in the blank beside the form and by his signature that he has provided the following forms (located in Section 00110): a. Proposal Form X , b. Proposal Security (Bid Bond) X c. Non - Collusion Affidavit X , d. Lobbying and Conflict of Interest Clause X , e. Drug -Free Workplace Form x , f. Subcontractor Listing Form X g. Proposer's Insurance and Indemnification Statement X , h. Insurance Agents Statement (signed by agent)X , and i. Local Preference Form and requirements (if applicable), In addition, Proposer states that he has included a certified copy of Contractor's License, and Monroe County Occupational License. (Check mark items above, as a reminder that they are included.) Mailing Address: 10145 NW 19th St Dora!, FL 33172 Phone Number: (305) 468 -6604 C 3/11/15 Date: Signed_ David Martinez (Name) VP (Title) Witness: `� (Seal) PROPOSAL FORM 00110 -Page 20 of 205 Senior Nutrition Center Renovations SECTION 00110 PROPOSAL FORM The Proposal shall be submitted on the forms included in this section of the Proposal Documents as previously instructed herein. Item Description Pages 1. Proposal Form 18-19 2. Bid Bond (Proposal Security) 20 3. Non - Collusion Affidavit 21 4. Lobbying and Conflict of Interest Clause 22 5. Drug -Free Workplace Form 23 6. Local Preference Form 24 7. Subcontractor Listing Form 25 8. Insurance Checklist 26 9. Workers Compensation and Employers' Liability 27 10. General Liability 28 11. Not Used 29 12. Vehicle Liability 30 13. Not Used 14. Proposer's Insurance and Indemnification Statement 31 15. Insurance Agent's Statements 32 16. Contractor License Current Copy to Be Submitted with Proposal Subcontractor Licenses to Be Submitted Prior to Award of Notice to Proceed 17. In order to determine if the persons or entity submitting proposals are responsible, all Proposals for contracts to be awarded under this section must contain the following information: A. A list of the entity's shareholders with five (5) percent or more of the stock or, if a general partnership, a list of the general partners; or, if a limited liability company, a list of its members; if a solely owned proprietorship, names(s) of owner(s). A copy of PROPOSAL FORM 00110 -Page 15 of 205 Senior Nutrition Center Renovations documentation demonstrating that the entity is a legally viable entity shall be attached. B. A list of the officers and directors of the entity; C. Relevant Experience: The number of years the person or entity has been operating and, if different, the number of years it has been providing the service, goods, or construction services called for in the proposal specifications (include a list of similar projects); D. The number of years the person or entity has operated under its present name and any prior names; E. Answers to the following questions regarding claims and suits: a. Has the person or entity ever failed to complete work or provide the goods for which it has contracted? (If yes, provide details of the job, including where the job was located and the name of the owner.) b. Are there any judgments, claims, arbitration proceeding or suits pending or outstanding against the person, principal of the entity, or entity, or its officers, directors, or general partners (this specifically includes any present or prior entities in which the person, principal, entity, officer, director or general partner of the proposing entity has been involved as a person, principal, entity, officer, director or general partner in the last five (5) years)? (If yes, provide details, include enough information about the judgment, claim, arbitration or suit so that the Owner will able to obtain a copy of the judgment or claim or locate the suit by location and case number.) c. Has the person, principal of the entity, entity, or its officers, major shareholders or directors within the last five (5) years, been a party to any law suits or arbitrations with regard to a contract for services, goods or construction services similar to those requested in the specifications with private or public entities? This specifically includes any present or prior entities in which the person, principal, entity, officer, director or general partner of the proposing entity has been involved as a person, principal, entity, officer, director or general partner in the last five (5) years. (If yes, provide details, include enough information about the judgment, claim, arbitration or suit so that the Owner will able to obtain a copy of the judgment or claim or locate the suit by location and case number.) d. Has the person, principal of the entity, or its officers, owners, partners, major shareholders or directors, ever initiated litigation against the County or been sued by the County in connection with a contract to provide services, goods or construction services? This specifically includes any present or prior entities in which the person, principal, entity, officer, director or general partner of the proposing entity has been involved as a person, principal, entity, officer, director or general partner in the last five (5) years. Of yes, provide details, include enough information about the judgment, claim, arbitration or suit so that the Owner will able to obtain a copy of the judgment or claim or locate the suit by location and case number.) PROPOSAL FORM 00110 -Page 16 of 205 Senior Nutrition Center Renovations e. Whether, within the last five (5) years, the Owner, an officer, general partner, controlling shareholder or major creditor of the person or entity was an officer, general partner, controlling shareholder or major creditor of any other entity that failed to perform services or furnish goods similar to those sought in the request for bids; f. Customer references (minimum of three), including name, current address and current telephone number; Credit References (minimum of three), including name, current address and current telephone number; g. Financial statements for the prior three years. Please provide in a separate sealed envelope for the Contractor's confidentiality, and clearly label the envelope "CONFIDENTIAL" one (1) original copv. ( "Any financial statement that an agency requires a prospective bidder to submit in order to prequalify for bidding or for responding to a bid for a road or any other public works project is exempt from s. 119.07(1) and s.24(a), Art. 1 of the State Constitution. ") PROPOSAL FORM 00110 -Page 17 of 205 in URKE Construction Group Inc. Senior Nutrition Center Renovations • A. List of Shareholders: a. Anthony Burke 50% b. David Martinez 50% B. Officers and directors: a. Anthony Burke President b. David Martinez VP /Secretary C. Relevant Experience: a. 8 years as Burke Construction Group, Inc. b. Owners have 30 years providing Construction Services c. List of similar projects — See Attached D. Operating under present name: a. 8 years under present name E. Answers regarding claims and lawsuits: a. Has the entity ever failed to complete work? No b. Are there any judgments or claims against? No c. Has the entity been a party to lawsuits etc? Yes(see attached) d. Has the entity initiated any claims against the county In the last 5 years? No e. Has the entity failed to perform in the last 5 yrs? No f. Customer and credit references See Attached g. Financial statements last 3 years Submitted separately 10145 NW 19 St. Doral, FL 33172 • 3210 Flagler Ave. Key West, FL 33040 P: 305.468.6604 • F: 305.468.6654 • www.burkeconstructiongroup.com General Contractors 1 Construction Management 1 Design -Build 1 Pre - Construction 1 Site Development 1 Green Construction 1 Interior Improvements CGCA# 38309 i Burke Construction Group, Inc., ' - Recently Completed Projects with Similar Scope of Work B U K / Construction Group Inc. Description pates of Work Value Sh over Job Address 1 Contact Pone Score of Work Tiw buildings oaa Boole campus totaling 24.00u square fau.7his project is consists of tilt-up concrete constriction. naiad light gamge metal musics omgice,d to plumate high wind moods. The (milky includes administration okra a wfdaiolauditarion, chamois 6855 SW ISZnd SL and a omnafim. This school provides na4of -0uei facilities al amtingcd} emimuniemion fa 1200 1 Westminster Christian School Cafetorium 2008 -2009 $3.9M Westminster Christian School atnt• FL Jeff Springer (305) 7206630 nmmdan. 2 Dote Animal Centre 9400NW 58th Street 2009 -2010 f2.3M Donal Centre Animal Clinic Dord, FL Animate iuniadamo and bunion for Veterinary Clink Mimate Cabeza ( 305) 598-1234 iduding onkel, kennels, surgery MU."' nuiidout of 3,a0 sf high std nxu ant uiu exrcas 746 Weshongtun Avg li g hti ng hen s qu ip em a non • includingingo *Wien °fall 3 Hot Tuna of Miami Beach 2010 S1.9M Hot Tuna of Miami Beads, hi Miami Beads, FL kitchen mapd m bar and bar resonation aril P S Systems ReRiru Agro (954) 829.5448 d:ogmami . mcsenation °d POS 56,000 aC tk - bug th innior idd including 1,000 sincloo y ddin di wi a wors rsw mesa . nm 10045 NW 19th Si. odia awes, rclauioa studio. kitchen. bookstore. coffer 4 Mew Life Church 2007 -2008 54.7M Metro Life Church bar and mdtipkoffum and canferace rooms. Including Dotal, FL Pastor Amtado Gomez (303) 592 -5100 14 Ckr000ans 19600 South Diode Hwy. Deno mdsommrmaian of college facility including 5 Potties College 2010-2011 SI.7M Badtwck Furniture and More Cutler moose. bathrooms. mechanical room. olT.o Cutler Bay. FL TO Brown (361) 694458E and conform= rooms 6 Aircraft Electrical Motors 5800 NW 163rd SI. 24.69110 Ines* Witham Milt sum of the an clecuinl 2011 -2012 SI.3M CapEest Associates Mian4 Lakes, FL Ed Easton, Jr. (305) 593.2222 and msmufaumuing 7 Dotal 9690 Retail Center 9690 NW 41st St. Dotal, Dames csimi° 1ws g 2013 81.6M Dotal Properties, LLC FI, g try °fun a Building ad comma new Darcy Itaskel (786) 5536929 13,577 sf real coma with bank trice dusegh faciltics 8 Shinn Bay Dermatology Center 2013 S1.3M Bay Demutololry & Cosmetic C FL Lauderdale, FL Expansion °foisting mmudic soggy coma with full S Rich Goren J561) 6376262 medical aceomadmions Sept. 2013 to 9 Mimi Intemmionsi Logistics March 2015 S1.2M Keating Resources alesh• FL Gerard 1(630) 246.9969 Dew and retrofit warehossta k offices Msy 2014 to Sept 10 Tri -Netra OBGYN Clinic 2014 3315K Adler Group Dorul FL Jesus Corte! (305) 333-1749 Dew ofeximig dams and retrofit for mncdicalfmgq• I1 Marotta Estates 17301 Old Cutler Demo and remotion°rhetorical raidcmiol 2014 S500K Village of Palmetto Bay Palmetto Bay, FL Fanny n Cemsau (303) 720 -7584 ]7wlaia E states pmn Demo este-Moraine 6 may office building and replace with eanahwoll system. Deem interior and nylace 12_ Emeadd Hills Office Building 2014-2015 56.7M GRE Properties VAC, Ekaric ad plumbing in cn6ra building Replace Hollywood, Holvwood FL David Loper (954)985 -2400_ roof and pads concrete, {! $ w c w ° C p f0 0 U N G 1 al U 0 U u w u W P a 41 N a a c 'L d N' to � r L a ar a to co w co t r. M N N vb e N E vs OZ V a 0 co r VI a 4' co c 1 i ' to 3 it v m r ` 7 t .. U 7 M 7 co LT: 1 1-4 0 0 0 . -I U 0 cc 0 m m I $5 et 1 z p ; o N 7 CJ ': m G mm a m a 0 b N U cn N 00 W N tT N O ci ac an tL O N m O ry w ri Q O r1 9 Q U Q 0 O .-4 N vi U i O 0 li C C c > L 1 ' t t t f0 4 .a t) �! 2 2 2 c 2 • V.. < �+ d; c u C V C U O 0 D I U C ( C Q C M C c0 C Q U C L. U CU L. O p Y 7 �" U y 3 Y 7 ° o w O O 03 CO C7 m C7 m l7 2 co m ` CO CO m vi C 00 , C C e co ) Oa h t/ w m p 2 M C a V 7 to d Q m a c C7 O. Q OS FO- E 0 w m c W u 111 2 Vf C Q C U. O .0 CO 0 m. m a Y a U m m o `o o `o a - o v '^ v to CO 76 -p O p O 7 03 C VI W C C O W t of 'p +.. .p 4.. 7 ) CU G.. m e v o Ip L. 0 O �. a �i E-C E ° N C w U to U to > w c c -6 a / v a� Q w m w C o °i v v p m p > E v y ' C N d o p , C co 0 ".0 >. C N >. 0 0) O .-t V 0 C i _ c 00 a s O. CO a a . . ot oc7 m 7 ... c c v 40 RI 111 3 _' L c y c C � a) ti d I. t V I 0 y .1. c CO Y ° u E c u E c E to fa- m, 3 to m 3 in o v — o ' • � c E .. c In 0. 0 N a 0 0 u 0 0 .0 0 u v I C o i N N c e� r4 Kt N t0 r 1 — 1 CC IA 0 Burke Construction Group, Inc. References FINANCIAL: TRADE: Stonegate Bank Advanced Builders Contractors 8630 NW 25th Street (786) 953 -7625 Doral, Florida 33122 Contact: Miguel Velez Maymi PH: 786 - 762 -4841 Contact: Scott Hertzog Titan Interiors Group jrusuRANCE; (954) 434 -9291 Contact: Tania Drago Collinsworth, Alter, Fowler Hernandez Ornamental 8000 Governors Square Blvd. (305) 970 -4145 Miami Lakes, Florida 33016 Contact: Andre Hernandez PH: 305- 822 -7800 Contact: Dick French B&L Beneway BOND AGENTS (305) 481 -3539 Contact: Nick Zappone Nielson & Company, Inc. STG Contracting Group 8000 Governors Square Blvd. (904) 287 -9898 Miami Lakes, Florida 33016 Contact: Mike Gresser PH: 305 - 722 -2663 Contact: David Hoover Florida Keys Electric LE�l4 (305) 296 -4028 Contact: Raymond Vazquez Elder & Lewis ]LM Associates 1500 San Remo Ave., Suite 214 (305) 987 -4177 Coral Gables, Florida 33146 Contact: Marty Salamida PH: 305 - 667 -4774 Contact: David Elder Merit Floors (305) 360-4762 Contact: Tony Paraga Client References Metro Life Church Westminster Christian School Doral, FL Palmetto Bay, FL (305) 592-5100 (305) 720-6650 Contact: Pastor Armando Gomez Contact: Jeff Springer Easton & Associates City Of Key West Doral, FL Key West, FL (305) 593-2222 (305) 809-3747 Contact: Paul Douglas Contact: Devon.Steckley Doral Animal Clinic Monroe County Doral, FL Key West, FL (305) 761-7766 (305) 797-1584 Contact: Dr. Cabeza Contact: Mike Nalepa Senior Nutrition Center Renovations SECTION 00110 NON - COLLUSION AFFIDAVIT David Martinez Miami Florida of the city according to law on my oath, and under penalty of perjury, depose and say that 1. I am Vice- President of the firm of Burke Construction Group, Inc. the proposer making the Proposal for the project described in the notice for calling for proposals for. Senior Nutrition Center Renovations and that I executed the said proposal with full authority to do so; 2. The prices in this proposal have been arrived at independently without collusion, consultation, communication or agreement for the purpose of restricting competition, as to any matter relating to such prices with any other proposer or with any competitor, 3. Unless otherwise required by law, the prices which have been quoted in this proposal have not been knowingly disclosed by the proposer and will not knowingly be disclosed by the proposer prior to proposal opening, directly or indirectly, to any other proposer or to any competitor, and 4. No attempt has been made or will be . de by the proposer to induce any other person, partnership or corporation to submit, or not to sub i , a proposal for the purpose of restricting competition; and 5. The statements ccj tai -. in this a' •a ' ar- . le and correct, and made with full knowledge that said project 10 3/11/15 • Proposer) (Date) STATE OF: Florida COUNTY OF: Monroe PERSONALLY APPEARED BEFORE ME, the undersigned authority, David Martinez who, after first being swom by me, (name of individual signing) affixed his /her signature in the space provided above on this 11 day of March 20 15 `'ti' ANTHONY BURKE 4 = 4 , '.- 1 Notary Public - State of Florida 1 ; i ., My Comm. Expires Feb 10, 2018 OTARY PUBL �,;"4 "7 -d';.' Commission # FF 071783 My commission Ir 5: -- PROPOSAL FORM 00110 -Page 22 of 205 Senior Nutrition Center Renovations LOBBYING AND CONFLICT OF INTEREST CLAUSE SWORN STATEMENT UNDER ORDINANCE NO. 010-1990 MONROE COUNTY, FLORIDA ETHICS CLAUSE Burke Construction Group, Inc (Company) warrants that he/t has not employed, retained or otherwise had act on hisfits behalf any former County officer or employee in violation of Section 2 of Ordinance No. 010 -1990 or any County officer or employee in violation of Section 3 of Ordinance No. 010 -1990. For breach or violation of this provision the County may, in its discretion, terminate this contract without liability and may also, in its discretion, deduct from the contract or purchase price, or otherwise recover, the full amount of any fee, commission, percentage, gift, or consideration paid to the former County officer or employee ". 3/11/15 Date: STATE OF: Florida COUNTY OF: Monroe Subscribed and swom to (or affirmed) before me on March 11, 201 (date) b David Martinez (name of affiant). He /She is Qersonally known to me or has produced identification. of identification) / (Type x op °, e p ANTHONY BURKE r* ; ' Notary Public - State of Florida i . / is • �� : ` :d a My Comm. Expires Feb 10, 2018 NOTARY PUBLIC / '%;;o,.,tlt: Commission i FF 071783 _ My commissiof PROPOSAL FORM 00110 -Page 23 of 205 Senior Nutrition Center Renovations DRUG -FREE WORKPLACE FORM The undersigned vendor in accordance with Florida Statute 287.087 hereby certifies that: Burke Construction Group, Inc. (Name of Business) 1. Publishes a statement notifying employees that the unlawful manufacture, distribution, dispensing, possession, or use of a controlled substance is prohibited in the workplace and specifying the actions that will be taken against employees for violations of such prohibition. 2. Informs employees about the dangers of drug abuse in the workplace, the business's policy of maintaining a drug -free workplace, any available drug counseling, rehabilitation, and employee assistance programs, and the penalties that may be imposed upon employees for drug abuse violations. 3. Gives each employee engaged in providing the commodities or contractual services that are under proposal a copy of the statement specified in subsection (1). 4. In the statement specified in subsection (1), notifies the employees that, as a condition of working on the commodities or contractual services that are under proposal, the employee will abide by the terms of the statement and will notify the employer of any conviction of, or plea of guilty or nolo contendere to, any violation of Chapter 893 (Florida Statutes) or of any controlled substance law of the United States or any state, for a violation occurring in the workplace no later than five (5) days after such conviction. 5. Imposes a sanction on, or require the satisfactory participation in a drug abuse assistance or rehabilitation program if such is available in the employee's community, or any employee who is so convicted. 6. Makes a good faith effort to continue to maintain a drug -free workplace through implementation of this section. As the person authorized to sign the statement, I edify that this irm comply fully with the above requirements. Propo er's is nature 3/11/15 D -te PROPOSAL FORM 00110 -Page 24 of 205 ENCLOSURE (4)e. LOCAL PREFERENCE FORM A. Vendors claiming a local preference according to Ordinance 023 -2009, as amended by Ordinance No. 004 -2015, must complete this form. Name of Bidder/Responder Burke Construction Group, Inc. 3/11/15 Date: 1. Does the vendor have a valid receipt for the business tax paid to the Monroe County Tax Collector dated at least one year prior to the notice of request for bids or proposals? 1 'e (Please furnish copy.) has City of Key West license py') 2. Does the vendor have a physical business address located within Monroe County from which the vendor operates or performs business on a day to day basis that is a substantial component of the goods or services being offered to Monroe County? Yes but his not registered as the principal address with the State of Florida (The physical business address must be registered as its principal place of business with the Florida Department of State for at least one year prior to the notice of request for bid or proposal.) List Address: 3210 Flagler Ave., Key West, FL 33040 Telephone Number: (305) 916 -5050 (786) 376 -6088 B. Does the vendor /prime contractor intend to subcontract 50% or more of the goods, services or construction to local businesses meeting the criteria above as to licensing and location? Yes If yes, please provide: 1. Copy of Receipt of the business tax paid to the Monroe County Tax Collector by the subcontractor dated at least one year prior to the notice or request for bid or proposal. 2. Subcontractor's physical business address within Monroe County from which the subcontractor operates: (The physical business address must be registered as its principal place of business with the Florida Department of State for at least one year prior to the notice of request for bids or proposals) See Attached Subcontra or List Addres 1 Tel. Number � Print Name: e David Martinez _• and Ti a of Au on d Signatory for • idder/Responder STATE OF Florida COUNTY OF —N►onroe On this 11 day of March , 2015 , before me, the undersigned notary public, personally appeared _ David Martinez , known to me to be the person whose name is subscribed above or who produced as identifi .';on, and acknowledged that he /she is the person who executed the above Local Preference Form for the , . oses therein contained. My co I ° ° °' °` 9'••,, ANTHONY BURKE Notary Public • \) Notary Public - State of Florida (Seal) ���, My Comm. Expires Feb 10, 2018 ► Anthony Burk .� .':;•' Commission re FF 071783 I r Print Name Rev. BOCC 1/21/15 (M -6) Senior Nutrition Center Renovations SUBCONTRACTOR LISTING FORM Division Subcontractor Contact Person Ph # wlarea Fax: Cell: Address code SEE ATTACHED SUB -LIST PROPOSAL FORM 00110 -Page 26 of 205 N N CO Cr) V1 in OO 000 N V1 V1 !-I N. N. m %-I N. N O1 t0 Z t (--.4 Ol LC) N co O O1 O1 OO N 0 Cr CO CL M CO CO N 00 Cr) M m 00 N 0 i11 O O O O O M 0 M Q1 M m M M M 4-+ J H ll. J t y) c O as 0 0 4/ V m O O m O O co Tr Cr et et et C m m O c m m LL imY1 Cr) 4) O J J M 0. J J J C V +-r 4-.P J 0 Y. LL 4) LL LL 0 W N L1. n. in in �j y H '0 N 4) m 3 ? a) 3 3 c >. > 3 4) Y 00 ` 4) 4) �+ 4) 4 0) >. O Y Y >• V) Y Y 4) Y Y MI • 0) 7 0) Y N 3 7 Q 4) O cC 4) 4 > 4 c c o > c c (IS > > ' > > > o Q Q D r� Q < N Q 00 C .4.7.. W m m m Z d1 m m m LL c co cc O O T-I 0 o ei r1 d' 0 0 W O Q V1 of in O N m V1 V1 N M � O C N C C (0 1.- L 0 c c C C o C C r C 0 y 4-7 v ii 0 a 0 CU co 0 3 3 3 C > > > >. 4) N a) Y Y Y Y 0 v V) O O u " C m O 0 _ ++ L L L _ cc 4) 4 Y Y H C O -° - c -o -°'a a) 4 t G �= T w m m o c c c cc m m � ° n 00 o `o > ) 1— 3 N H '8 'n C � H Y a) O m m Q (5 m n, 5 W u � 6 -a Z w CO CO V O ,_ i O D N D L L '�. CO m m m m m io u m m m m O 0 H F- m CO H H O < 1- CO CO V) I— t o tL c L O 0 i✓ (0 7 i V 0 C W = 0 o c o o 2 O 0 :. 0s = a t C Y p In Off L +' op 4., N O E y C L N t 4) 3 3 D CO O O o2 S > V 6L a) 4) �, d 0 N d U a) ++ CO N O y C !Z 00 v i 00 c V 4) J W U a ILI 4-) w c m ' �-^ c o c 3 c a) o N v) u 2 2 2 i cc u.. a o a 2 CU w a co E. c • .?... o _, G fV m 'ct V1 N I. CO CO 01 01 Cr) V1 LO t Ea O 0 0 0 0 0 0 0 0 0 0 .-i .-i U U m Senior Nutrition Center Renovations SECTION 00120 INSURANCE REQUIREMENTS AND FORMS MONROE COUNTY, FLORIDA Insurance Checklist FOR Proposer Workers' Compensation X Workers' Compensation Statutory Limits Bodily Injury by Accident/Bodily Injury by Disease, policy limits /Bodily Injury by Disease each employee WC1 Employers Liability $100,000/$500,000 /$100,000 WC2 Employers Liability $500,000/$500,000 /$500,000 WC3 X Employers Liability $1,000,000/$1,000,000 /$1,000,000 WCUSLH US Longshoremen & Same as Employers' Harbor Workers Act Liability WCJA Federal Jones Act Same as Employers' Liability INSURANCE REQUIREMENTS AND FORMS 00120 - Page 27 of 205 Senior Nutrition Center Renovations General Liability As a minimum, the required general liability coverages will include: • Premises Operations • Products and Completed Operations • Blanket Contractual • Personal Injury • Expanded Definition of Property Damage Required Limits: GL1 $200,000 per Person; $300,000 per Occurrence $200,000 Property Damage or $300,000 Combined Single Limit GL2 $300,000 per Person; $500,000 per Occurrence $200,000 Property Damage or $500,000 Combined Single Limit GL3 X $500,000 per Person; $1,000,000 per Occurrence $100,000 Property Damage or $1,000,000 Combined Single Limit GL4 $2,000,000 Combined Single Limit Required Endorsement: GLXCU X Underground, Explosion and Collapse (XCU) GLLIQ Liquor Liability GLS Security Services All endorsements are required to have the same limits as the basic policy. INSURANCE REQUIREMENTS AND FORMS 00120 -Page 28 of 205 Senior Nutrition Center Renovations Vehicle Liability As a minimum, coverage should extend to liability for: • Owned; Non - owned; and Hired Vehicles Required Limits: VL1 $50,000 per Person: $100,000 per Occurrence $25,000 Property Damage or $100,000 Combined Single Limit (The use of VL1 should be limited to special projects that involve other governmental entities or "Not for Profit" organizations. Risk Management must approve the use of this form). VL2 $200,000 per Person; $300,000 per Occurrence $200,000 Property Damage or $300,000 Combined Single Limit VL3 X $500,000 per Person; $1,000,000 per Occurrence $100,000 Property Damage or $1,000,000 Combined Single Limit VL4 $5,000,000 Combined Single Limit Miscellaneous Coverages BR1 X Builders' Limits equal to the Risk completed project. • MVC Motor Truck Limits equal to the maximum Cargo value of any one shipment. PRO1 Professional $ 300,000 per Occurrence/$ 500,000Agg. PRO2 Liability $ 500,000 per Occurrence /$1,000,000 Agg. PRO3 $1,000,000 per Occurrence /$2,000,000 Agg. POL1 Pollution $ 500,000 per Occurrence /$1,000,000 Agg. POL2 Liability $1,000,000 per Occurrence /$2,000,000 Agg. POL3 $5,000,000 per Occurrence /$10,000,000 Agg. EDI Employee $ 10,000 INSURANCE REQUIREMENTS AND FORMS 00120 -Page 29 of 205 Senior Nutrition Center Renovations ED2 Dishonesty $100,000 GK2 Garage $ 300,000 ($ 25,000 per Veh) GK2 Keepers $ 500,000 ($100,000 per Veh) $1,000,000 ($250,000 per Veh) MEDI Medical $ 300,000/$ 750,000 Agg. MED2 Professional $ 500,000/$ 1,000,000 Agg. MED3 $1,000,000/$ 3,000,000 Agg. $ Agg. IF Installation Maximum value of Equipment Floater Installed VLP2 Hazardous $ 300,000 (Requires MCS -90) VLP2 Cargo $ 500,000 (Requires MCS -90) Transporter $1,000,000 (Requires MCS -90) BLL Bailee Liab. Maximum Value of County Property that will be in the Bailee's possession. HKL1 Hangarkeepers $ 300,000 HKL2 Liability $ 500,000 HKL3 $ 1,000,00 AIR1 Aircraft $ 1,000,000 AIR2 Liability $ 5,000,000 AI R3 $50,000,000 AEO1 Architects Errors $ 300,000 per Occurrence /$ 500,000 Agg. AEO2 & Omissions $ 500,000 per Occurrence /$1,000,000 Agg. AEO3 $ 1,000,000 per Occurrence /$3,000,000 Agg. E01 Engineers Errors $ 300,000 per Occurrence /$ 500,000 Agg. E02 & Omissions $ 500,000 per Occurrence /$1,000,000 Agg. E03 $ 1,000,000 per Occurrence /$3,000,000 Agg. INSURANCE REQUIREMENTS AND FORMS 00120 -Page 30 of 205 Senior Nutrition Center Renovations WORKERS' COMPENSATION INSURANCE REQUIREMENTS FOR CONTRACT: SENIOR NUTRITION CENTER RENOVATIONS BETWEEN MONROE COUNTY, FLORIDA AND Prior to the commencement of work governed by this contract, the Contractor shall obtain Workers' Compensation Insurance with limits sufficient to respond to the applicable state statutes. In addition, the Contractor shall obtain Employers' Liability Insurance with limits of not less than: $1,000,000 Bodily Injury by Accident $1,000,000 Bodily Injury by Disease, policy limits $1,000,000 Bodily Injury by Disease, each employee Coverage shall be maintained throughout the entire term of the contract. Coverage shall be provided by a company or companies authorized to transact business in the state of Florida. If the Contractor has been approved by the Florida's Department of Labor, as an authorized self - insurer, the County shall recognize and honor the Contractor's status. The Contractor may be required to submit a Letter of Authorization issued by the Department of Labor and a Certificate of Insurance, providing details on the Contractor's Excess Insurance Program. If the Contractor participates in a self - insurance fund, a Certificate of Insurance will be required. In addition, the Contractor may be required to submit updated financial statements from the fund upon request from the County. INSURANCE REQUIREMENTS AND FORMS 00120 - Page 31 of 205 Senior Nutrition Center Renovations GENERAL LIABILITY INSURANCE REQUIREMENTS FOR CONTRACT: SENIOR NUTRITION CENTER RENOVATIONS BETWEEN MONROE COUNTY, FLORIDA AND Prior to the commencement of work governed by this contract, the Contractor shall obtain General Liability Insurance. Coverage shall be maintained throughout the life of the contract and include, as a minimum: • Premises Operations • Products and Completed Operations • Blanket Contractual Liability • Personal Injury Liability • Expanded Definition of Property Damage • GLXCU Required Endorsement The minimum limits acceptable shall be: $500,000 per Person; $1,000,000 per Occurrence $100,000 Property Damage or $1,000,000 Combined Single Limit Required Endorsement: GLXCU Underground, Explosion and Collapse An Occurrence Form policy is preferred. If coverage is provided on a Claims Made policy, its provisions should include coverage for claims filed on or after the effective date of this contract. In addition, the period for which claims may be reported should extend for a minimum of twelve (12) months following the acceptance of work by the County. The Monroe County Board of County Commissioners shall be named as Additional Insured on all policies issued to satisfy the above requirements. GL INSURANCE REQUIREMENTS AND FORMS 00120 -Page 32 of 206 Senior Nutrition Center Renovations VEHICLE LIABILITY INSURANCE REQUIREMENTS FOR CONTRACT: SENIOR NUTRITION CENTER RENOVATIONS BETWEEN MONROE COUNTY, FLORIDA AND Recognizing that the work governed by this contract requires the use of vehicles, the Contractor, prior to the commencement of work, shall obtain Vehicle Liability Insurance. Coverage shall be maintained throughout the life of the contract and include, as a minimum, liability coverage for: • Owned, Non - Owned, and Hired Vehicles The minimum limits acceptable shall be: $1,000,000 Combined Single Limit (CSL) If split limits are provided, the minimum limits acceptable shall be: $500,000 per Person $1,000,000 per Occurrence $100,000 Property Damage The Monroe County Board of County Commissioners shall be named as Additional Insured on all policies issued to satisfy the above requirements. VL INSURANCE REQUIREMENTS AND FORMS 00120 -Page 33 of 205 Senior Nutrition Center Renovations BUILDER'S RISK INSURANCE REQUIREMENTS FOR CONTRACT: SENIOR NUTRITION CENTER RENOVATIONS BETWEEN MONROE COUNTY, FLORIDA AND The Contractor shall be required to purchase and maintain, throughout the life of the contract, and until the project is accepted by the County, Builder's Risk Insurance on an All Risk of Loss form. Coverage shall include: Theft Aircraft Windstorm Vehicles Hail Smoke Explosion Fire Riot Collapse Civil Commotion Flood The policy limits shall be no less than the amount of the finished project and coverage shall be provided on a completed value basis. Property located on the construction premises, which is intended to become a permanent part of the building, shall be included as property covered. The policy shall be endorsed permitting the County to occupy the building prior to completion without effecting the coverage. The Monroe County Board of County Commissioners shall be named as Additional Insured and Loss Payee. BR 1 INSURANCE REQUIREMENTS AND FORMS 00120 -Page 34 of 205 Senior Nutrition Center Renovations PROPOSER'S INSURANCE AND INDEMNIFICATION STATEMENT INSURANCE REQUIREMENTS Worker's Compensation Statutory Limits Employers Liability $1,000,000 Bodily Injury by Accident $1,000,000 Bodily Injury by Disease Policy Limits $1,000,000 Bodily Injury by Disease, each employee General Liability, including $1,000,000 Combined Single Limit Premises Operations or Products and Completed Operations $500,000 Per Person Blanket Contractual Liability $1,000,000 Per Occurance Personal Injury Liability $100,000 Property Damage Expanded Definition of Property Damage Required Endorsement: GLXCU Underground, Explosion and Collapse (XCU) Builder's Risk: Required Vehicle Liability (Owned, non - owned, and hired vehicles) $1,000,000 Combined Single Limit If split limits are preferred: $500,000 per Person $1,000,000 per Occurrence $100,000 Property Damage Hold Harmless and Indemnification. Notwithstanding any minimum insurance requirements prescribed elsewhere in this agreement, Contractor shall defend, indemnify and hold the COUNTY and the COUNTY's elected and appointed officers and employees harmless from and against (i) any claims, actions or causes of action, (ii) any litigation, administrative proceedings, appellate proceedings, or other proceedings relating to any type of injury (including death), Toss, damage, fine, penalty or business interruption, and (iii) any costs or expenses that may be asserted against, initiated with respect to, or sustained by, any indemnified party by reason of, or in connection with, (A) any activity of Contractor or any of its employees, agents, contractors or other invitees during the term of this Agreement, (B) the negligence or willful misconduct of Contractor or any of its employees, agents, sub - contractors or other invitees, or (C) Contractor's default in respect of any of the obligations that it undertakes under the terms of this Agreement, except to the extent the claims, actions, causes of action, litigation, proceedings, costs or expenses arise from the intentional or sole negligent acts or omissions of the COUNTY or any of its employees, agents, contractors or invitees (other than Contractor). Insofar as the claims, actions, causes of action, litigation, proceedings, costs or expenses relate to events or circumstances that occur during the term of this Agreement, this section will survive the expiration of the term of this Agreement or any earlier termination of this Agreement. In the event that the completion of the project (to include the work of others) is delayed or suspended as a result of the Contractor s failure to purchase or maintain the required insurance, the Contractor shall indemnify the County from any and all increased expenses resulting from such delay. Should any claims be asserted against the County by virtue of any deficiency or ambiguity in the plans and specifications provided by the Contractor, the Contractor agrees and warrants that the Contractor shall hold the County harmless and shall indemnify it from all losses occurring thereby and shall further defend any claim or action on the County's behalf. INSURANCE REQUIREMENTS AND FORMS 00120 -Page 35 of 205 Senior Nutrition Center Renovations The first ten dollars ($10.00) of remuneration paid to the Contractor is for the indemnification provided for the above. The extent of liability is in no way limited to, reduced, or lessened by the insurance requirements contained elsewhere within this AGREEMENT. PROPOSER'S STATEMENT I understand the insurance that will be mandatory if awarded the contract and will comply in full with all the requirements. I fully accept the indemnification a - .Id harmle s as set out on page 00110 -12 of this proposal. i , Burke Construction Group, Inc. ` %) i l PROPOSER ' - ire t) INSURANCE REQUIREMENTS AND FORMS 00120 -Page 36 of 205 , . Senior Nutrition Center Renovations INSURANCE AGENT'S STATEMENT I have reviewed the above requirements with the proposer named above. The following deductibles apply to the corresponding policy. POLICY DEDUCTIBLES GL2053366 -0- CA2053364 -0- Liability policies are X Occurrence Claims Made Collinsworth Alter Fowler & French LLC R I Insurance Agency Signature INSURANCE REQUIREMENTS AND FORMS 00120-Page 37 of 205 c rzo v' BURKCON.o1 8EWIGGs ' F... 3 CERTIFICATE OF LIABILITY INSURANCE 1 °A , " "" TES CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTMICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(8), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. IMPORTANT: If the cvUlleate holder Is an ADDmONAL INSURED, the poficy(les) must be endorsed. N SUBROGATION IS WANED, subject to the teems and conditions of the policy, certain policies may require an endorsement. A statement on this certificate dons not confer rights to the certificate holder In lieu of such endorsement(s). PRODUCER - CONTACT ,— NAME 8000 Governors Suite 301 Alter, er &d French, LLC ( ) 822 I . Nod ( 362 - 2143 Miami Lakes, FL 33016 Aos IDEUREDMIAFFORDING COVERAGE HNC 0 INSURED INSURER A :Ametisure Mutual Ins Co 23396 INSURER 6: Burke Construction Group Inc INSURER C: 10145 N.W.19 Street INSURER!): Dorai, FL 33172 INSURER E : INSURER F: COVERAGES CERTIFICATE NUMBER: REVISION NUMBER: THIS IS TO CERTIFY THAT THE POUCIES OF INSURANCE USTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POUCY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACTOR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POUCIES DESCRIBED HEREIN IS SUBJECT TOALL THE TERMS, p EXCWSIONS AND CONDRION6 OF SUCH POUCIES. UNITS SHOWN MAY HAVE BEEN REDUCED BY PM) CLAIMS. I, TR TYPE OFWgURAUCE PNsa nMNa NM POLICY Y fl a gATTYYYI UNITS GENERAL LIAEIJTY EACH OCCURRENCE I 1,00%000 A X CommERd u.oese A.wourY GL2053366 411012014 411612015 Pp N oe ow n nea i $ 300,000 CLAIMS -MADE © OCCUR MED EXP (Any one person) 1 10,000 PERSONAL. II ADV INJURY 1 1,000,000 GENERAL AGGREGATE s 2 7 PENt AGGREGATE UMir APPLIES PER: PRODUCTS - COMP/OP AGO s 2,000,000 POLICY n f l Loc $ AUTOMOBILE LIABILITY $Ma11NEDSINOLE 1,000,000 A ANY AUro CA2053364 �W $ — �� D — SCHEDULED D 411612014 411612015 BODILY INAIRY(Pppsrton) s BOOILY INJURY (Per meklentj I X HIRED WrOs X" D P _ ry q f X IMBRI UA u*a X =cm E f A EXCESS LuAS EACH OCCURRENCE _ 1 4,000,000 CLAIIMPAAOE CU2082067 411612014 4116/2015 AGGREGATE $ 4,000,000 OED 1 1 RETENTION S WORKERS AND COMPENSATION AM�ITIJ. $ A ANY PrtOPRETORIPARTNERIEXECUTIVE WC2053365 X 'T� Y PER OFRCEMMEMeER EX LUDED? © NIA 4116/2014 411612015 E.L EACH ACdOENT 8 1,000,000 Filesdelory daa um E.L. DISEASE • EA EMPLOYEE I 1,000,000 OESC.RIPUO y OF OPERATIONS below E.L. DISEASE -POLICY LIMIT $ 1,000,000 DESCRIPTION OF OPERATIONS I LOCATIONS mucus (Attach AC ORD 101, Add$UanN Remed s Seheduie.I more apace b requIred) CERTIFICATE HOLDER CANCELLATION SHOULD ANY OF THE ABOVE DESCRIBED POUCIES BE CANCELLED BEFORE Monroe Cotmty Building Department THE EXPIRATION DATE THEREOF, NOTICE WILL lM DELIVERED IN 2798 Overseas Highway ACcoRDANcE WITH THE POLICY PROVISIONS. Suite 300 Marathon, FL 33080 AUTHORIZED REPRESENTATIVE R ACORD 25 (2010105) The ACORD name and logo are ®19882010 ACORD CORPORATION. Alt rights reserved. og registered marks of ACORD , . • . State of Florida Department of State I certify from the records of this office that BURKE CONSTRUCTION GROUP, INC. is a corporation organized under the laws of the State of Florida, filed on July 2, 2007, effective June 25, 2007. The document number of this corporation is P07000075715. I further certify that said corporation has paid all fees due this office through December 31, 2015, that its most recent annual report/uniform business report was filed on February 2, 2015, and its status is active. I further certify that said corporation has not filed Articles of Dissolution. Given under my hand and the Great Seal of the State of Florida at Tallahassee, the Capital, this the Second day of February, 2015 � � - " off ± L.,..._, ��tf q a _,,..z. _ 7 ...,.4„ le..,„ 04...,. . Secretary of State Authentication ID: CC4474968611 To authenticate this certificate,visit the following site,enter this ID, and then follow the instructions displayed. https: / /efile .sunbiz.org /certauthver.html . . • CITY k !..1( • a S ; 1 I • Business Tax Receipt This Document is a business tax receipt Holder must meet all City zoning and use provisions. P.O. Box 1409, Key West, Florida 33040 (305) 809 -3955 Business Name BURKE CONSTRUCTION GROUP, INC. Ct1Nbr:0022855 Location Addr 1107 KEY PLAZA Lic NBR /Class 15- 00028182 CONTRACTOR - CERT GENERAL CONTRACTOR Issue•Date: August 22, 2014 Expiration Date:September 30, 2015 License Fee $309.75 Add. Charges $0.00 Penalty $0.00 Total $309.75 truer: KEYOLu Type; CC Drawer: ! Comments: Date: 8/22/14 51 Receipt no: 38s3i 2615 26162 it GCiUPla1foo; 1.61 $139.75 This document must be prominently) pW'ed. 3.6.1.24a8 BURKE CO Di '1ZLT 'i , 53:19 )5 �TION GROUP, INC BURKE CONSTRUCTION GROUP, INC. Trans date: 8/22/14 1S:4if.2 3210 FLAGLER AVE KEY WEST FL 33040 t r s 4 STATE OF FLORIDA DEPARTMENT OF BUSINESS AND PROFESSIONAL REGULATION t 7 CONSTRUCTION INDUSTRY LICENSING BOARD (850) 487 -1395 ' 1940 NORTH MONROE STREET TALLAHASSEE FL 32399 -0783 • BURKE, ANTHONY JOHN JR BURKE CONSTRUCTION GROUP INC 6730 ROYAL PALM DRIVE MIAMI FL 33157 Congratulations! With this license you become one cif the nearly • one million Floridians licensed by the Department of Business and Professional Regulation. Our professionals and businesses range STATE OF FLORIDA from architects to yacht brokers, from boxers to barbeque restaurants, DEPARTMENT OF BUSINESS AND and they keep Florida's economy strong. •ui_r• PROFESSIONAL REGULATION Every day we work to improve the way we do business in order to CGCA38309 ISSUED: 08/20/2014 serve you better. For information about our services, please log onto www.myfloridalicense.com. There you can find more information CERTIFIED GENERALCONTRACTOR about our divisions and the regulations that impact you subscribe BURKE, ANTHONY' JOHN.JR to department newsletters and team more about the Department's BURKE CONSTRUCTION GROUP INC initiatives. Our mission at the Department is: License Efficiently, Regulate Fairly. We constantly strive to serve you better so that you can serve your customers. Thank you for doing business in Florida, IS CERTIFIED under the provisions of Ch.489 FS. and congratulations on your new license! Expiration date : AUG 31, 2016 L1408200001635 • DETACH HERE RICK SCOTT, GOVERNOR KEN LAWSON, SECRETARY STATE OF FLORIDA DEPARTMENT OF BUSINESS AND PROFESSIONAL REGULATION CONSTRUCTION INDUSTRY LICENSING BOARD l LICENSE NUMBER y CGCA38309 The GENERAL CONTRACTOR Named below IS CERTIFIED Under the provisions of Chapter 489 FS. Expiration date: AUG 31, 2016 ❑� ❑ BURKE, ANTHONY JOHN JR , BURKE CONSTRUCTION: GROUP INC . ' , r.. 10145 NW 19TH STREET.. - � DORAL FL 33172 ' { ❑•`r .:�o • ISSUED: 08/20/2014 DISPLAY AS REQUIRED BY LAW SEQ# L1408200001535. ♦ PM W. BURKCON -01 STWIGGS I DATA (MIeDDfYYYY) A o CERTIFICATE OF LIABILITY INSURANCE 4/1712015 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON TH CERTIFICATE HOLDER. THIS CERTIRCATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POUCIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder Is an ADDITIONAL INSURED, the pollcy(ies) must be endorsed If SUBROGATION 15 WAIVED, subject to the teens and condkions of the policy, certain policies may require an endorsement A statement on this certificate does not confer rights to the certificate holder In lieu of such endorsement(s). ACT PRODUCER Collinsworth, Aker, Fowler 3 French, LLC IL 0* (305) 822 7800 No ( ) 3524443 6000 Governors Square Blvd MAn auks 301 ADO"JSS'- Mianli Lakes, FL 33016 N$Unews) AFFOR0INO comma MAC e INSURER A : Amerisurs Mutual Ins Co 23388 INSURED INSURER s : North River Insurance Company 21105 Burke Construction Group Inc INSURER c INSURER 0: 10145 N.W. 19 Street Doral, FL 33172 INSURER E : INSURER F : COVERAGES CERTIFICATE NUMBER: REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT 1MTH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES UMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAMS LISTS LTR TYPE OF N1SURAIA;a PISD F vD R POLICY NUMNER AI i gi Y) ( 1 �QQQ�QQO A X COMMERCIAL GENERAL uAe*UTY EACH OCCURRENCE $ X o ccuR X 0 L2053386 04!1612015 0411612016 S (Ea ! $ 300,000 RENTED CLAIMS MADE 10,000 MED ExP IAa+r as per! $ PERSONAL S AO/ INJURY $ 1,000,000 GENERAL AGGREGATE S 2,000,000 GUM AGGREGATE LIMB APPLIES PER PROOUC18. COMP/OP AEG $ 2,000,000 POLIouCY X J� La f OTHER COMBINEDSIN0.ELIMiI $ 1,000,000 (es swam AUTOM y AU LIAeMJTY 0411612015 0411612016 sooty muter (Por p $ ALL A ANY Aura X CA2053364 e00ILY amity OW seadsnt) $ AUTOS ED AUTO LEO PROPERTY DAMAGE $ X NON OY ED (Pr aeoO ng MREDAUTOS X AUTOS S X UTASItgLA LIAe X occuR EACH OCCURRENCE $ 4,000,000 B EXCESS MAO CLAIMS.MADE 5811049062 0411612015 0411812016 AGGREGATE $ 8,000,000 S - OED RETENTION; X P ER OTH. WORKERS COMPENsATON STAT UTE ER AND EMPLOYERS' LUIMUTY YIN WC2053366 0411812015 0411612016 E L EACN ACCIDENT a 1,000,000 A ANY PROPRI o ld') RTNERIE>MCUtIVE NIA IMsnWwy hold') E L DISEASE • EA EMPLOYEE $ 1,000,000 OFFICER/MISER EXCLUDED? E L DISEASE • pOLCY LIMIT $ 1,000,000 OPERATK7NStaN°W DISEASE 04116/2015 04116/2016 wIS000. Mod 3000 A Leased/Rented Equip IM2075933 00, ossournos co OPIRATrONB I LOGl1o0S 1 VEMICLES (ACORD 101. Add$Ion* Remarks Schedule, may be attached N mere spsa M rsquksd) Proyect Key West Senior Center Monroe County BOCC is named as additional insured with respects to General Liability and Auto policies. Excess1Umbrella follow form. 30 Day Notice of Cancellation except 10 Days for Non Payment Mem+ AP .• . . ,r; . , IM'if►;-*!a! W : r CERTIFICATE HOLDER CANCELLATION SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTE VNLL BE DELIVERED IN Monroe County ACCORDANCE WITH THE POLICY PROVISIONS. EnglneerktgfProject Management/Wastewater 1100 Simonton Street Room 2416 . AUTHORIZED Key West, FL 33040 � J ���� G ® 1968 -2014 ACORD CORPORATION. All rights resorts ACORD 25 (2014101) The ACORD name and logo are registered marks of ACORD • Bond No. SU1126485 Document A312 — 2010 Conforms with The American Institute of Architects AIA Document 312 Mo „nos �ct iifies Dg clod Performance Bond n( R m enf PR CONTRACTOR: SURETY: 1 U r Er (Name, legal status and address) (fame, legal status and principal place of business) TIME: Burke Construction Group, Inc. Arch Insurance Company RECEIVED BY: 10145 N.W. 19th Street 300 Plaza Three This document has important legal Donal FL 33172 Jersey City NJ 07311 consequences. Consultation with Mailing Address for Notices an attomey Is encouraged with respect to its completion or OWNER: (Same as Above) modification. Any singular reference to (Name, legal status and address) Contractor, Surety, Owner or other party shall be considered Monroe County Board of County Commissioners plural where applicable. 500 Whitehead Street Key West FL 33040 CONSTRUCTION CONTRACT Date: Amount $ 528,714.00 Five Hundred Twenty Eight Thousand Seven Hundred Fourteen Dollars and 00/100 Description: (Name and location) Senior Nutrition Center Renovations, 1200 Truman Avenue, Key West, FL 33040 BOND Date: (Not earlier than Construction Contract Date) Amount $528,714.00 Five Hundred Twenty Eight Thousand Seven Hundred Fourteen Dollars and 00/100 Modifications to this Bond: © None Scc Scction 16 CONTRACTOR AS PRINCIPAL SURETY Company: (Corporate Seal) Company: (Corporate Seal) Burke •nstruction G i • p, Inc/ Arch Insur a mp t Signature: . I A. Signature: i /J01-4` /J01-4` Name Charles J. Nielson Name M and Title: \/78 and Title: Attorney - - Fact (Attu additional signatures appear on the last page of this Pmfonnance Bond.) (FOR INFORMATION ONLY —Name, address and telephone) AGENT or BROKER: OWNER'S REPRESENTATIVE: Nielson, Hoover & Associates ( Architect, Engineer or other party:) 8000 Governors Square Blvd. #101 Miami Lakes FL 33016 305 - 722 -2663 8- 1852/AS 8 /10 § 1 The Contractor and Surety, jointly and severally, bind themselves, their heirs, executors, administrators, successors and assigns to the Owner for the performance of the Construction Contract, which is incorporated herein by reference. § 2 If the Contractor performs the Construction Contract, the Surety and the Contractor shall have no obligation undcr this Bond, except when applicable to participate in a conference as provided in Section 3. § 3 If there is no Owner Default under the Construction Contract, the Surety's obligation under this Bond shall arise after .1 the Owner first provides notice to the Contractor and the Surety that the Owner is considering declaring a Contractor Default. Such notice shall indicate whether the Owner is requesting a conference among the Owner, Contractor and Surety to discuss the Contractor's performance. If the Owner docs not request a conference, the Surety may, within five (5) business days after receipt of the Owner's notice, request such a conference. If the Surety timely requests a conference, the Owner shall attend. Unless the Owner agrees otherwise, any conference requested under this Section 3.1 shall be held within ten (10) business days of the Surety's receipt of the Owner's notice. If the Owner, the Contractor and the Surety agree, the Contractor shall be allowed a reasonable time to perform the Construction Contract, but such an agreement shall not waive the Owner's right, if any, subsequently to declare a Contractor Default; .2 the Owner declares a Contractor Default, terminates the Construction Contract and notifies the Surety; and .3 the Owner has agreed to pay the Balance of the Contract Price in accordance with the terms of the Construction Contract to the Surety or to a contractor selected to perform the Construction Contract. § 4 Failure on the part of the Owner to comply with the noticc requirement in Section 3.1 shall not constitute a failure to comply with a condition precedent to the Surety's obligations, or release the Surety from its obligations, except to the extent the Surety demonstrates actual prejudice. § 5 When the Owner has satisfied the conditions of Section 3, the Surety shall promptly and at the Surety's expense take one of the following actions: § 5.1 Arrange for the Contractor, with the consent of the Owner, to perfatm and complete the Construction Contract; § 5.2 Undertake to perfotm and complete the Construction Contract itself, through its agents or independent contractors; § 6.3 Obtain bids or negotiated proposals from qualified contractors acceptable to the Owner for a contract for performance and completion oldie Construction Contract, arrange for a contract to be prepared for execution by the Owner and a contractor selected with the Owner's concurrence, to be secured with performance and payment bonds executed by a qualified surety equivalent to the bonds issued on the Construction Contract, and pay to thc Owner the amount of damages as described in Section 7 in excess of the Balance of the Contract Price incurred by the Owner as a result of the Contractor Default; or § 5.4 Waive its right to perform and complete, arrange for completion, or obtain a new contractor and with reasonable promptness under the circumstances: .1 After investigation, determine thc amount for which it may be liable to the Owner and, as soon as practicable after the amount is determined, make payment to the Owner, or .2 Deny liability in whole or in part and notify the Owner, citing the reasons for denial. § 6 If the Surety does not proceed as provided in Section 5 with reasonable promptness, thc Surety shall be deemed to be in default on this Bond seven days after receipt of an additional written notice from the Owner to the Surety dcmanding that the Surety perform its obligations under this Bond, and the Owner shall be entitled to cnforcc any remedy available to the Owner. If the Surety proceeds as provided in Section 5.4, and the Owner refuses the payment or the Surety has denied liability, in whole or in part, without further notice the Owner shall be entitled to enforce any remedy available to the Owner. S- 1852/AS 8/10 § 7 If the Surety elects to act under Section 5.1, 5.2 or 5.3, then the responsibilities of the Surety to the Owner shall not be greater than those of the Contractor under the Construction Contract, and the responsibilities of the Owner to the Surety shall not be greater than those of thc Owner undcr the Construction Contract. Subject to the commitment by the Owner to pay the Balance of the Contract Price, the Surety is obligated, without duplication, for .1 the responsibilities of the Contractor for correction of defective work and completion of the Construction Contract; .2 additional legal, design professional and delay costs resulting from the Contractor's Default, and resulting from the actions or failure to act oldie Surety under Section 5; and .3 •liquidated damages, or if no liquidated damages are specified in the Construction Contract, actual damages caused by delayed performance or non - performance of the Contractor. § 8 If the Surety elects to act under Section 5.1, 5.3 or 5.4, the Surety's liability is limited to the amount of this Bond. § 9 The Surety shall not be liable to the Owner or others for obligations of the Contractor that are unrelated to the Construction Contract, and the Balance of the Contract Price shall not be reduced or set off on account of any such unrelated obligations. No right of action shall accrue on this Bond to any person or entity other than the Owner or its heirs, executors, administrators, successors and assigns. § 10 The Surety hereby waives notice of any change, including changes of time, to the Construction Contract or to related subcontracts, purchase orders and other obligations. § 11 Any proceeding, legal or equitable, under this Bond may be instituted in any court of competent jurisdiction in the location in which the work or part of the work is located and shall be instituted within two years after a declaration of Contractor Default or within two years after the Contractor ceased working or within two years after the Surety refuses or fails to perform its obligations under this Bond, whichever occurs first. If the provisions of this Paragraph are void or prohibited by law, the minimum period of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable. § 12 Notice to the Surcty, the Owner or thc Contractor shall be mailed or delivered to the address shown on the page on which their signature appears. § 13 When this Bond has been famished to comply with a statutory or other legal requirement in the location where the construction was to be performed, any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefrom and provisions conforming to such statutory or other legal requirement shall be deemed incorporated herein. When so furnished, the intent is that this Bond shall be construed as a statutory bond and not as a common law bond. § 14 Definitions § 14.1 Balance of the Contract Price. The total amount payable by the Owner to the Contractor under the Construction Contract after all proper adjustments have been made, including allowance to the Contractor of any amounts received or to be received by the Owner in settlement of insurance or other claims for damages to which the Contractor is entitled, reduced by all valid and proper payments made to or on behalf of the Contractor under the Construction Contract. § 14.2 Construction Contract. The agreement between the Owner and Contractor identified on the cover page, including all Contract Documents and changes made to the agreement and the Contract Documents. § 14.3 Contractor Default. Failure of the Contractor, which has not been remedied or waived, to perform or otherwise to comply with a material term of the Construction Contract. § 14.4 Owner Default. Failure of the Owner, which has not been remedied or waived, to pay the Contractor as required under the Construction Contract or to perform and complete or comply with the other material terms of the Construction Contract. § 14.6 Contract Documents. All the documents that comprise the agreement between the Owner and Contractor. § 15 If this Bond is issued for an agreement between a Contractor and subcontractor, the term Contractor in this Bond shall be deemed to be Subcontractor and the term Owner shall be deemed to be Contractor. S- 1852/AS 8/10 § '16 Modifications to this bond are as follows: (Space is provided below for additional signatures of added parties, other than those appearing on the cover page.) CONTRACTOR AS PRINCIPAL SURETY Company: (Corporate Seal) Company: (Corporate Seal) Signature: Signature: Name and Title: Name and Title: Address Address S- 1852/AS 8/10 Bond No. SU1126485 Document A312 TM - 2010 Conforms with The American Institute of Architects AIA Document 312 Payment Bond CONTRACTOR: SURETY: (Name, legal status and address) (Nance, legal status and principal place of business) Burke Construction Group, Inc. Arch Insurance Company 10145 N.W. 19th Street 300 Plaza Three This document has important legal Jersey City NJ 07311 consequences. Consultation with Dora! FL 33172 Mailing Address for Notices an attomey is encouraged with respect to its completion or (Same as Above) modification. OWNER: Any singular reference to (Name, legal status and address) Contractor, Surety, Owner or other party shall be considered Monroe County Board of County Commissioners plural where applicable. 500 Whitehead Street Key West FL 33040 CONSTRUCTION CONTRACT Date: Amount: s528,714.00 Five Hundred Twenty Eight Thousand Seven Hundred Fourteen Dollars and 00/100 Description: (Nance and location) Senior Nutrition Center Renovations, 1200 Truman Avenue, Key West, FL 33040 BOND Date: (Not earlier than Construction Contract Date) Amount: $ 528,714.00 Five Hundred Twenty Eight Thousand Seven Hundred Fourteen Dollars and 00/100 Modifications to this Bond: © None El See Section 18 CONTRACTOR AS PRINCIPAL SURETY Company: (Corporate Seal) Company: (Corporate Seal) Burke instruction G p, Inc) Arch Insur C pa y Si gna't Signature: Name t PV(/ I 7 it z Name Charles J. ielson �/ and Title: ,P and Title: Attorney -in -Fact (Any additional signatures appear on the last page of this Payment Bond) (FOR INFORMATION ONLY — Name, address and telephone) AGENT or BROKER: OWNER'S REPRESENTATIVE: Nielson, Hoover & Associates (Architect, Engineer or other party;) 8000 Governors Square Blvd. #101 Miami Lakes FL 33016 305 - 722 -2663 S- 2149/AS 8/10 § 1 The Contractor and Surety, jointly and severally, bind themselves, their heirs, executors, administrators, successors and assigns to the Owner to pay for labor, materials and equipment furnished for use in the performance of the Construction Contract, which is incorporated herein by reference, subject to the following terms. § 2 If the Contractor promptly makes payment of all sums due to Claimants, and defends, indemnifies and holds harmless the Owner from claims, demands, liens or suits by any person or entity seeking payment for labor, materials or equipment furnished for use in the performance of the Construction Contract, then the Surety and thc Contractor shall have no obligation under this Bond. § 3 If there is no Owner Default under the Construction Contract, the Surcty's obligation to the Owner under this Bond shall arise after the Owner has promptly notified thc Contractor and thc Surety (at thc address described in Section 13) of claims, demands, liens or suits against the Owner or the Owner's property by any person or entity seeking payment for labor, materials or equipment furnished for use in the performance of the Construction Contract and tendered defense of such claims, demands, liens or suits to the Contractor and the Surety. § 4 When the Owner has satisfied the conditions in Section 3, the Surety shall promptly and at the Surety's expense defend, indemnify and hold harmless the Owner against a duly tendered claim, demand, lien or suit. § 5 The Surety's obligations to a Claimant under this Bond shall arise after the following: § 6.1 Claimants, who do not have a direct contract with the Contractor, .1 have furnished a written notice ofnon- payment to the Contractor, stating with substantial accuracy the amount claimed and the name of the party to whom the materials were, or equipment was, furnished or supplied or for whom the labor was done or performed, within ninety (90) days after having last performed labor or last furnished materials or equipment included in the Claim; and .2 have sent a Claim to thc Surety (at the address described in Section 13). § 6.2 Claimants, who arc employed by or have a direct contract with the Contractor, have sent a Claim to the Surety (at the address described in Section 13). § 6 If a notice of non - payment required by Section 5.1.1 is given by the Owner to the Contractor, that is sufficient to satisfy a Claimant's obligation to furnish a written notice of non - payment under Section 5.1.1. § 7 When a Claimant has satisfied the conditions of Sections 5.1 or 5.2, whichever is applicable, the Surety shall promptly and at the Surety's expense take the following actions: § 7.1 Send an answer to the Claimant, with a copy to the Owner, within sixty (60) days after receipt of the Claim, stating thc amounts that are undisputed and the basis for challenging any amounts that are disputed; and § 7.2 Pay or arrange for payment of any undisputed amounts. § 7.3 The Surety's failure to discharge its obligations under Section 7.1 or Section 7.2 shall not be deemed to constitute a waiver of defenses the Surety or Contractor may have or acquire as to a Claim, except as to undisputed amounts for which thc Surety and Claimant have reached agreement. If, however, the Surety fails to discharge its obligations undcr Section 7.1 or Section 7.2, the Surety shall indemnify the Claimant for the reasonable attorney's fees the Claimant incurs thereafter to recover any sums found to be due and owing to the Claimant. § 8 The Surety's total obligation shall not exceed the amount of this Bond, plus the amount of reasonable attorney's fees provided under Section 7.3, and the amount of this Bond shall be credited for any payments made in good faith by the Surety. § 9 Amounts owed by the Owner to the Contractor undcr the Construction Contract shall be used for the performance of the Construction Contract and to satisfy claims, if any, under any construction performance bond. By the Contractor furnishing and the Owner accepting this Bond, they agree that all funds earned by the Contractor in the performance of the Construction Contract are dedicated to satisfy obligations of the Contractor and Surety under this Bond, subject to the Owner's priority to use the funds for the completion of the work. , S-2149/AS 8/10 § 10 The Surety shall not be liable to the Owner, Claimants or others for obligations of the Contractor that are unrelated to the Construction Contract. The Owner shall not be liable for the payment of any costs or expenses of any Claimant undcr this Bond, and shall have under this Bond no obligation to make payments to, or give notice on behalf of, Claimants or otherwise have any obligations to Claimants under this Bond. § 11 The Surety hereby waives notice of any change, including changes of time, to the Construction Contract or to related subcontracts, purchase orders and other obligations. § 12 No suit or action shall be commenced by a Claimant under this Bond other than in a court of competent jurisdiction in the state in which the project that is the subject of the Construction Contract is located or after the expiration of one year from the date (l) on which the Claimant sent a Claim to the Surcty pursuant to Section 5.1.2 or 5.2, or (2) on which the last labor or service was performed by anyone or the last materials or equipment were furnished by anyone under the Construction Contract, whichever of (1) or (2) first occurs. If the provisions of this Paragraph arc void or prohibited by law, the minimum period of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable. § 13 Notice and Claims to the Surety, the Owner or the Contractor shall be mailed or delivered to the address shown on the page on which their signature appears. Actual receipt of notice or Claims, however accomplished, shall be sufficient compliance as of the date received. § 14 When this Bond has been furnished to comply with a statutory or other legal requirement in the location where the construction was to be performed, any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefrom and provisions conforming to such statutory or other legal requirement shall be deemed incorporated herein. When so furnished, the intent is that this Bond shall be construed as a statutory bond and not as a common law bond. § 15 Upon request by any person or entity appearing to be a potential beneficiary of this Bond, the Contractor and Owner shall promptly furnish a copy of this Bond or shall permit a copy to be made. § 16 Definitions § 16.1 Claim. A written statement by the Claimant including at a minimum: .1 the name of the Claimant; .2 the name of the person for whom the labor was done, or materials or equipment furnished; .3 a copy of the agreement or purchase order pursuant to which labor, materials or equipment was furnished for use in the performance of the Construction Contract; .4 a brief description of the labor, materials or equipment furnished; .6 the date on which the Claimant last performed labor or last furnished materials or equipment for use in the performance of the Construction Contract; .6 the total amount tamed by the Claimant for labor, materials or equipment famished as of the date of the Claim; .7 the total amount of previous payments received by the Claimant; and .8 the total amount due and unpaid to the Claimant for labor, materials or equipment furnished as of the date of the Claim. § 16.2 Claimant. An individual or entity having a direct contract with the Contractor or with a subcontractor of the Contractor to furnish labor, materials or equipment for use in the performance of the Construction Contract. The term Claimant also includes any individual or entity that has rightfully asserted a claim under an applicable mechanic's lien or similar statute against the real property upon which the Project is located. The intent of this Bond shall be to include without limitation in the terms "labor, materials or equipment" that part of water, gas, power, light, heat, oil, gasoline, telephone service or rental equipment used in the Construction Contract, architectural and engineering services required for performance of the work of the Contractor and the Contractor's subcontractors, and all other items for which a mechanic's lien may be asserted in the jurisdiction where the labor, materials or equipment were furnished. § 16.3 Construction Contract. The agreement between the Owner and Contractor identified on the cover page, including all Contract Documents and all changes made to the agreement and the Contract Documents. S-2149/AS 8/10 § 16.4 Owner Default. Failure of the Owner, which has not been remedied or waived, to pay the Contractor as required undcr the Construction Contract or to perform and complete or comply with the other material terms of the Construction Contract. § 16.6 Contract Documents. All the documents that comprise the agreement between the Owner and Contractor. § 17 If this Bond is issued for an agreement between a Contractor and subcontractor, the term Contractor in this Bond shall be deemed to be Subcontractor and the term Owner shall be deemed to be Contractor. § 18 Modifications to this bond are as follows: The provisions and limitations of Section 255.05 Florida Statutes , including but not limited to the notice and incorporated in thisbond Sections 255.05(2) and 255.05(10) are by reference. (Space is provided below for additional signatures of added parties, other than those appearing on the cover page.) CONTRACTOR AS PRINCIPAL SURETY Company: (Corporate Seal) Company: (Corporate Seal) Signature: Signature: Name and Title: Name and Title: Address Address S- 2149/AS 8/10 . d diX4';47177irh,i, _ ._, i 11 iii ii ii i 1 11 11 11 11 11 i11 1 111, = --= - -= _---=-. • • iiii 1 ii 1 i 1 1 1 1 dl Id , _ _ .= • . 1111 1 II 1 I II 1 1 1 1 1111,I1111 111 I i 11111111 __ - 111111111111qt -___ _ AIC 0000120724 THIS POWER OF ATTORNEY IS NOT VALID UNLESS IT IS PRINTED ON BLUE BACKGROUND. I d 11 1 1 - - -- 1 1 1 0 1 ;01 i i e cj i - "WIWtvet'n:Wornev limits th a t those e terein bind im tora In W Vw . * II I 1 1 1 , 1 1, , and t M bind the Co and -end the extent hereltke . Not V II f ortgage, Ne-Wumul--Ws-MreMit, Bank Depcodtlinlern: -- - Interest Rate or Residential Value Guarantees. POIAER OF ATTORNEY II 1 1 1 1q111 1 1 111 1 1 1 id 1 11 Kr aaf At=ftrsons BThese Presefm_7 - -= 111 hi ii 1 11 iii - - __ _ ii - 1 11111 1 11 iiil That the Arch Insurance Company, a corporation organized and existing under the laws of the State of Missouri, having its principal administrative office in Jersey City, New Jersey (hereinafter referred to as the "Company") does hereby appoint: 11 i ii I i i i = ft.iMv■fflima Walley, Audria RfiVliatX1 Brett Roi ii!iCharles D. NixtEmr.:ftrs Jaiim David R. Hooxnu wItrerT_ . vriv_c =_ .U R. Neu, Ke4, and i 16 1, Mosholder oMiie Mcce_MCW 1 iiill T its true and lawful Attomey(s)in-Fact, to make, execute, seal, and deliver from the date of issuance of this power for and on its behalf as surety, and as itsact and deed: 11 - - = - 1 1 11 11 1 11i i dil 1 Any artiialEtiondstndertakings, tWo0-2mclwaeaiairety obligatiori , 1 he penal ed i dled ilOxceeding -- =_ Ninelv Million Dollars ($90.000.000 ---- - - iiii, i I I di ii di id This authority does not permit the same obligation to be split into two or more bonds In order to bring each such bond within the dollar limit of authority as set forth herein. i 11 1 d ' 1 ii i i = TWI:Mct&Te=liMich bonds, uoi slogs, ree..ogO ns and other stmatlft'Islcoi,utance of theseviimershEil in4n - r - ' - rie said CompanY a1 and itirriOI 1 td all intents Mme had bee holacactiM - ii acknowledged by its regularly elected officers at its principal administrative office in Jersey City, New Jersey. This Power of Attorney is executed by authority of resolutions adopted by unanimous consent of the Board of Directors of the Company ortZeirtitkerAl., 2011, true and accurate cw ch are hereinafter set forth and aril Ihereby certified to Oythe_undelsAjne SeVreWy asb4n ' full force anct-Wftt =.- _==- -== 1 1 1 II I i 1 1 11 1111 11 I I I 1 1 1 I d 1 1H 1 1 - - - - - 1 il i d , i iii 1 ii i‘ 1111.4 ii I 'VOTED, That the Chairman of the the President, or the Executive rresident, or any Senior Vice Pre the Business Division, or their appointees designated in writing and filed with the Secretary, or the Secretary shall have the power and authority to appoint agents and attorneys-in-fact, and to authorize them subject to the limitations set forth in their respective powers of attomw-Ae_extimte on behalf of the company . and 7 oh the seal of the Company thereto, bids, undertakings, recognizances ancL= __ etv:WWions obligatory iri 1 th nd e nature tiirifl 11 any such off --- meMorsunr - Xnay appoint agents_AirAwarnirce 1 1 1 11 1 1 1 i i di ii 1 i hid 1 11111 This Power of Attomey is signed, sealed and certified by facsimile under and by authority of the following resolution adopted by the unanimous consent of the Board of Directors of the Company on September 15, 2011: = 1111 I VOTED That 111ignature of the Gh *NI eto Ah ir_e President, o I iMi4lExecutive vi i i Osident, or any Sm' Wailefti=hi= -. of Itie DivisionOir wallgoirth:cMignated in wri IN filed widtjti;1 elifOecretary, ancMWa_Ws. WIM -= Seemtary, the seal of the Compalt4rtitkatiorrzuby the Secretary, lailk4 affixed by a 'mho on any powelEiltMurbmi executed pursuant to the resolution adopted by the Board of Directors on September 15, 2011, and any such power so executed, sealed and certified with respect to any bond or undertaking to which it is attached, shall continue to be valid and binding upon the Company. 1 i 111 1111 i d 11 i 11 1 1 1 1 1 1 1 1 1 1 i il i 11 1 OOMLOQI3 0003 03 Page 1 of 2 Printed in U.S.A. IIIiII i ii 11 II i I 1 i 1 i A . AIC 0000120724 In Testimony Whereof, the Company has caused this instrument to be signed and its corporate seal to be affixed by their authorized officers,this 5th day of June, 2014. Attested and Certified Arch Insurance Company "ranee oos / / W U SEAL _ kii_ �.� i„,,,, ir,if . a dolma 1971 Patrick K. Nails,Secretary J David M. in e stein, Executive Vice President STATE OF PENNSYLVANIA SS MiOyf� COUNTY OF PHILADELPHIA SS I, Helen Szafran, a Notary Public, do hereby certify that Patrick K. Nails and David M. Finkelstein personally known to me to be the same persons whose names are respectively as Secretary and Executive Vice President of the Arch Insurance Company, a Corporation organized and existing under the laws of the State of Missouri, subscribed to the foregoing instrument, appeared before me this day in person and severally acknowledged that they being thereunto duly authorized signed, sealed with the corporate seal and delivered the said instrument as the free and voluntary act of said corporation and as their own free and voluntary acts for the uses and purposes therein set forth. .po moNweAL.THOf PENNSYLVANIA NOTARIAL SEAL HELEN SZAFRAN,Notary Public City of Philadelphia,Pith.County Pity Corrinfasion Expires October 3,2017 elen Szafran, tary/tflitkt.1‘—*/ My commission expires 10/03/2017 CERTIFICATION I, Patrick K. Nails, Secretary of the Arch Insurance Company, do hereby certify that the attached Power of Attorney dated June 5, 2014 on behalf of the person(s) as listed above is a true and correct copy and that the same has been in full force and effect since the date thereof and is in full force and effect on the date of this certificate; and I do further certify that the said David M. Finkelstein, who executed the Power of Attorney as Executive Vice President, was on the date of execution of the attached Power of Attorney the duly elected Executive Vice President of the Arch Insurance Company. IN TESTIMONY WHEREOF, I have hereunto subscribed my name and affixed the corporate seal of the Arch Insurance Company on this day of ,20_ 5 /, ///+ f Patrick K. Nails,Secretary This Power of Attorney limits the acts of those named therein to the bonds and undertakings specifically named therein and they have no authority to bind the Company except in the manner and to the extent herein stated. PLEASE SEND ALL CLAIM INQUIRIES RELATING TO THIS BOND TO THE FOLLOWING ADDRESS: Arch Insurance—Surety Division . 3 Parkway,Suite 1500 (iance 0 Philadelphia,PA 19102 / SEAL 19T1 00ML0013 00 03 03 Page 2 of 2 Printed in U.S.A. c TGARRIDO AC " DATE (MMIOO/YYYY) EVIDENCE OF PROPERTY INSURANCE 6/29/2015 THIS EVIDENCE OF PROPERTY INSURANCE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE ADDITIONAL INTEREST NAMED BELOW. THIS EVIDENCE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS EVIDENCE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE ADDITIONAL INTEREST. AGENCY N , 822-7800 COMPANY CoNinsworth, Alter, Fowler & French, LLC General Star Indemnity Co. 6000 Governors Square Blvd Suite 301 Miami Lakes, FL 33016 FAX N, 362 -2443 ADDRESS: CODE: SUB CODE: Man m e BURKCON -01 INURED Bu rke Construction Group Inc and Monroe Country Board of LOAN NUMBER POUCY MUMMER Country Commissioners IA0935559 10145 N.W. 19 Street Dorai, FL 33172 EFFECTIVE DATE E%PNMTION DATE CONTINUED UNTIL 6/26/2015 12/26/2015 TERMWATEDIFCHECKED THIS REPLACES PRIOR EVNENCE DATED: PROPERTY INFORMATION LOCATIONIDESCNIPTION Builders Risk Coverage Form Project Located ® 1016 Georgia Street., Key West, F1 33040 THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT. TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS EVIDENCE OF PROPERTY INSURANCE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. COVERAGE INFORMATION COVERAGE I PEALS /FORMS AMOUNT OF INSURANCE INDUCTILE Limit at location Limit Property Located 1016 Georgia Street, Key West, Fl 33040 5528,714 5,000 WIND & HAIL DEDUCTIBLE - 5% DEductibie value of prop at the time of Toss subject to 25,000. Minimum 5 REMARKS (Including Special Conditions) Special Conditions: Property Located at 1016 Georgia Street, Key West, Fl 33040 MEN? • • , : Additional Covsrages A d� l' •∎ Transit Coverage 520,000. 4111111/5// Temporary Storage 120,000. W . • CANCELLATION SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POUCY PROVISIONS. ADDITIONAL INTEREST NAME AHD ADDRESS 1 • lht ` ;�N� MORTGAGEE X ADDITIONAL NSURED 1 a ` SG LOSS PAYEE LOAN k Monroe County Board of County CommIsslonens crawl Eft Olt Employees and Officials �t 77 oRLzEO REPRESENTATIVE 1100 Simonton Street 6!i :a "v Room 2-213 (11 eta/ Key West, FL 33040 V.4 %.f ACORD 27 (2009112) ®1993 -2009 ACORD CORPORATION. API rights reserved. The ACORD name and logo are registered marks of ACORD