Loading...
The URL can be used to link to this page
Your browser does not support the video tag.
07/20/2016 Agreement
AMY HEAVILIN, CPA CLERK OF CIRCUIT COURT &COMPTROLLER MONROECOUNiY,FLORIDA DATE: September 14, 2016 TO: Judith Clarke Director of Engineering ATTN.- Breanne Erickson, Senior Engineering Technician FROM. • Cheryl Robertson Executive Aide to the Clerk of Court & Comptroller YC- At the July 20, 2016 Board of County Commissioner's meeting the Board granted approval and authorized execution of Items: Cl Approval of Amendment 8 to the contract with Metric Engineering, Inc for Engineering Design and Permitting Services for the US 1 Bayside Shared Use Path/Pedestrian Bridge Over Marvin Adams Waterway Project to extend the expiration date of the contract to March 31, 2017 at no additional cost. C2 Approval of Change Order 2 to the construction contract with Douglas N. Higgins, Inc for the Lake Surprise Estates (Key Largo) Roadway and Drainage Improvements Project to incorporate sea level rise adaptation and to adjust some quantities to actual vs "as bid" amounts for an additional cost of $397,468.43. C3 Approval to award bid and approve a contract with H&R Paving, Inc. For Construction of the Sexton Cove Estates (Key Largo) Roadway and Drainage Improvements project in the amount of $1,105,342.35. C8 Approval of Amendment 1 to the contract with Metric Engineering Inc for Engineering Design and Permitting Services for the Pigeon Key Ramp Restoration Project to transfer funds from the Foundation Investigation task to the Geotechnical task for a lead survey, with no change to the original total contract amount. C 14 Approval of Amendment 1 to Agreement with T. Y. Lin International For Engineering Design and Permitting Services for the Stock Island I Roadway and Drainage Improvement Project for additional design services for the sea level rise adaptation initiative at an additional cost of $34,752.00. Enclosed is a duplicate original executed on behalf of Monroe County, for your handling. Should you have any questions, please feel free to contact me. CC: County Attorney, Finance, and File ✓ 500 Whitehead Street Suite 101, PO Box 1980, Key West FL 33040 Phone: 305-295-3130 Fax: 305-295-3663 3117 Overseas Highway, Marathon, FL 33050 Phone: 305-289-6027 Fax. 305-289-6025 88820 Overseas Highway, Plantation Key, FL 33070 Phone: 852-7145 Fax: 305-852-7146 y Standard Form of Agreement Between Owner and Contractor Where the basis of payment is a STIPULATED SUM AGREEMENT Made as of the 20t' day of July in the year of Two Thousand and Sixteen. BETWEEN the Owner: Monroe County Board of County Commissioners ("BOCC") 1100 Simonton Street Key West, Florida 33040 ("Owner") And the Contractor: H & R Paving, Inc. 1955 NW 110 Avenue ("Contractor") Miami, FL 33172 For the following Project: Sexton Cove Roadway and Drainage Improvement Project Key Largo Monroe County, Florida ("Project") Oversight for Owner: RS&H, Inc. 10748 Deerwood Park Blvd South Jacksonville, Florida 32256 Engineer: CDM Smith, Inc. 2301 Maitland Center Parkway, Suite 300 Maitland, Florida 32751 The Owner and Contractor agree as set forth below. Page 1 of 14 ARTICLE 1 The Contract Documents The Contract Documents consist of this Agreement, Conditions of the Contract (General, Supplementary and other Conditions), Drawings, Specifications, Insurance Requirements and Documents, Milestone Schedule, Bid Documents and Contractor's Bid, Addenda issued prior to execution of this Agreement, other documents listed in this Agreement and Modifications issued after execution of this Agreement. These form the Contract, and are as fully a part of the Contract as if attached to this Agreement or repeated herein. The Contract represents the entire and integrated agreement between the parties hereto and supersedes prior negotiations, representations or agreements, either written or oral. ARTICLE 2 The Work of this Contract The Contractor shall execute the entire Work described in the Contract Documents, except to the extent specifically indicated in the Contract Documents to be the responsibility of others, or as follows: Scope of Work is as specified in the Contract Documents, and shown on the Drawings and in the specifications. The contract constitutes the entire and exclusive agreement between the Owner and the Contractor with reference to the Sexton Cove Roadway and Drainage Improvement Proiect. ARTICLE 3 Date of Commencement and Substantial Completion 3.1 The date of commencement is the date from which the Contract Time of Paragraph 3.2 is measured, and shall be the date of this Agreement, as first written above, unless a different date is stated below or provision is made for the date to be fixed in a notice to proceed issued by the Owner as stated in Section 00350, milestone schedule. Unless the date of commencement is established by a notice to proceed issued by the Owner, the Contractor shall notify the Owner, in writing not less than five days before commencing the Work. The date of commencement shall be the date specified in the Notice to Proceed issued to the Contractor. 3.2 The Contractor shall achieve Substantial Completion of the entire Work not later than 173 Days after the Date of Commencement, subject to adjustments of the Contract Time as provided by the Contract Document. Page 2 of 14 LIQUIDATED DAMAGES Liquidated damages will be based on the Substantial Completion Date for all work, modified by all approved extension in time as set forth by the Owner's signature of approval on the Certificate of Substantial Completion. The liquidated damages table below shall be utilized to determine the amount of liquidated damages. FIRST SECOND 31s` DAY & CONTRACT AMOUNT 15 DAYS 15 DAYS THEREAFTER Under 50,000.00 $50.00/DAY $100.00/DAY $250.00/DAY $50,000.00-$99,999.00 100.00/DAY 200.00/DAY 750.00/DAY $100,000.00-499,999.00 200.00/DAY 500.00/DAY 2,000.00/DAY $500,000.0 and Up 500.00/DAY 1,000.00/DAY 3,500.00/DAY The Contractor's recovery of damages and sole remedy for any delay caused by the Owner shall be an extension of time on the Contract. Balance of Page Intentionally Left Blank Page 3 of 14 ARTICLE 4 Contract Sum 4.1 The owner shall pay the Contractor in current funds for the Contractor's performance of the Contract, for the Sexton Cove Roadway and Drainage Improvement Project the Contract Sum of ONE MILLION ONE HUNDRED FIVE THOUSAND THREE HUNDRED FORTY TWO DOLLARS AND THIRTY FIVE CENTS, ($1,105,342.35), subject to additions and deductions as provided in the Contract Documents. 4.2 The Contract Sum is based upon the following alternates, if any, which are described in the Contract Documents and are hereby accepted by the Owner: None 4.3 Unit prices, if any, are as follows: As specified in Section 00110. ARTICLE 5 Progress Payments 5.1 Based upon Applications for Payment submitted by the Contractor to the Owner, and upon Project Applications and Certificates for Payment, the Owner shall make progress payments on account of the Contract Sum to the contractor as provided below and elsewhere in the Contract Documents. 5.2 The period covered by each Application for payment shall be one calendar month ending on the last day of the month. 5.3 County shall pay pursuant to the Local Government Prompt Payment Act 218.70. 5.4 Each Application for Payment shall be based upon the Schedule of Values submitted by the Contractor in accordance with the Contract Documents. The Schedule of Values shall allocate the entire Contract Sum among the various portions of the Work and be prepared in such form and supported by such data to substantiate its accuracy as the Owner may require. This schedule, unless objected to by the Owner, shall be used as a basis for reviewing the Contractor's Applications for Payment. 5.5 Applications for Payment shall indicate the percentage of completion of each portion of the Work as of the end of the period covered by the Application for Payment. 5.6 Subject to the provisions of the Contract Documents, the amount of each progress payment shall be computed as follows: 5.6.1 Take that portion of the Contract Sum properly allocable to completed Work as determined by multiplying the percentage completion of each portion of the Work by the share of the total Contract Sum allocated to that portion of the Work in the Schedule of Values, less retainage of Ten percent (10%). Pending final determination of cost to the Owner of changes in the Work, amounts not in dispute may be included in applications for Payment. The amount of credit to be allowed by the Contractor to the Owner for a deletion or change which results in a net decrease in the Contract Sum shall be actual net cost as confirmed by the Owner. When both additions and credits covering related Page 4of14 Work or substitutions are involved in a change the allowance for overhead and profit shall be figured on the basis of net increase, if any, with respect to that change. 5.6.2 Add that portion of the Contract Sum properly allocable to materials and equipment delivered and suitably stored at the site for subsequent incorporation in the completed construction (or, if approved in advance by the Owner, suitably stored off the site at a location agreed upon in writing), less retainage of Ten percent (10%): 5.6.3 Subtract the aggregate of previous payments made by the Owner; and 5.6.4 Subtract amounts, if any, for which the Owner has withheld or nullified a Certificate for Payment as provided in Paragraph 9.5 of the General conditions. 5.7 The progress payment amount determined in accordance with Paragraph 5.6 shall be further modified under the following circumstances: 5.7.1 Add, upon Substantial Completion of the Work, a sum sufficient to increase the total payments to Nine percent (90%) of the Contract Sum, less such amounts as the Owner recommends and determines for incomplete Work and unsettled claims; and 5.7.2 Add, if final completion of the Work is thereafter materially delayed through no fault of the Contractor, any additional amounts payable in accordance with Subparagraph 9.10.3 of the General Conditions. 5.8 Reduction or limitation of retainage, if any, shall be as follows: None ARTICLE 6 Final Payment Final payment, constituting the entire unpaid balance of the Contract Sum, shall be made by the Owner to the Contractor when (1) the Contract has been fully performed by the Contractor except for the Contractor's responsibility to correct nonconforming Work as provided in Subparagraph 12.2.2 of the General Conditions and to satisfy other requirements, if any, which necessarily survive final payment: and (2) a final Project Certificate for Payment has been issued by the Project Manager: such final payment shall be made by the Owner not more than 20 days after the issuance of the final Project Certificate for Payment. ARTICLE 7 Miscellaneous Provisions 7.1 Where reference is made in this Agreement to a provision of the General Conditions or another Contract Document, the reference refers to that provision as amended or supplemented by other provisions of the Contract Documents. 7.2 Payments due and unpaid under the Contract shall bear interest pursuant to the Local Government Prompt Payment Act 218.735 Page 5 of 14 7.3 Temporary facilities and services: None. 7.4 Monroe County's performance and obligation to pay under this contract is contingent upon an annual appropriation by the Board of County Commissioners. 7.5 Public Entities Crimes By signing this Agreement, Contractor represents that the execution of this Agreement will not violate the Public Entities Crime Act (Section 287.133, Florida Statutes). Violation of this section shall result in termination of this Agreement and recovery of all monies paid hereto, and may result in debarment from County's competitive procurement activities. In addition to the foregoing, Contractor further represents that there has been no determination, based on an audit, that it or any subcontractor has committed an act defined by Section 287.133, Florida Statutes, as a "public entity crime" and that it has not been formally charged with committing an act defined as a "public entity crime" regardless of the amount of money involved or whether Contractor has been placed on the convicted vendor list. Contractor will promptly notify the County if it or any subcontractor is formally charged with an act defined as a "public entity crime" or has been placed on the convicted vendor list. A person or affiliate who has been placed on the convicted vendor list following a conviction for public entity crime may not submit a bid on a contract to provide any goods or services to a public entity, may not submit a bid on a contract with a public entity for the construction or repair of a public building or public work, may not submit bids on leases of real property to public em.,-y, may not be awarded or perform work as contractor, supplier, subcontractor, or consultant under a contract with any public entity, and may not transact business with any public entity in excess of the threshold amount provided in Section 287.017, for CATEGORY TWO for a period of 36 months from the date of being placed on the convicted vendor list. 7.6 The following items are part of this contract: a) Maintenance of Records: Contractor shall maintain all books, records, and documents directly pertinent to performance under this Agreement in accordance with generally accepted accounting principles consistently applied. Each party to this Agreement or their authorized representatives, or designee, shall have reasonable and timely access to such records of each other party to this Agreement for public records purposes during the term of the Agreement and for four years following the termination of this Agreement. If an auditor employed by the County or Clerk determines that monies paid to Contractor pursuant to this Agreement were spent for purposes not authorized by this Agreement, the Contractor shall repay the monies together with interest calculated pursuant to Sec. 55.03; FS, running from the date the monies were paid to Contractor. b) Governing Law, Venue, Interpretation, Costs, and Fees: This Agreement shall be governed by and construed in accordance with the laws of the State of Florida applicable to contracts made and to be performed entirely in the State. In the event that any cause of action or administrative proceeding is instituted for the enforcement or interpretation of this Agreement, the County and Contractor agree that venue shall lie in the appropriate court or before the appropriate administrative body in Monroe County, Florida. This Agreement shall not be subject to arbitration. Page 6 of 14 c) Severability: If any term, covenant, condition or provision of this Agreement (or the application thereof to any circumstance or person) shall be declared invalid or unenforceable to any extent by a court of competent jurisdiction, the remaining terms, covenants, conditions and provisions of this Agreement, shall not be affected thereby; and each remaining term, covenant, condition and provision of this Agreement shall be valid and shall be enforceable to the fullest extent permitted by law unless the enforcement of the remaining terms, covenants, conditions and provisions of this Agreement would prevent the accomplishment of the original intent of this Agreement. The County and Contractor agree to reform the Agreement to replace any stricken provision with a valid provision that comes as close as possible to the intent of the stricken provision. d) Attorney's Fees and Costs: The County and Contractor agree that in the event any cause of action or administrative proceeding is initiated or defended by any party relative to the enforcement or interpretation of this Agreement, the prevailing party shall be entitled to reasonable attorney's fees and court costs, as an award against the non -prevailing parry, and shall include attorney's fees and courts costs in appellate proceedings. Mediation proceedings initiated and conducted pursuant to this Agreement shall be in accordance with the Florida Rules of Civil Procedure and usual and customary procedures required by the circuit court of Monroe County. e) Binding Effect: The terms, covenants, conditions, and provisions of this Agreement shall bind and inure to the benefit of the County and Contractor and their respective legal representatives, successors, and assigns. 0 Authority: Each party represents and warrants to the other that the execution, delivery and performance of this Agreement have been duly authorized by all necessary County and corporate action, as required by law. g) Claims for Federal or State Aid: Contractor and County agree that each shall be, and is, empowered to apply for, seek, and obtain federal and state funds to further the purpose of this Agreement; provided that all applications, requests, grant proposals, and funding solicitations shall be approved by each party prior to submission. h) Nondiscrimination: County and Contractor agree that there will be no discrimination against any person, and it is expressly understood that upon a determination by a court of competent jurisdiction that discrimination has occurred, this Agreement automatically terminates without any further action on the part of any party, effective the date of the court order. County or Contractor agree to comply with all Federal and Florida statutes, and all local ordinances, as applicable, relating to nondiscrimination. These include but are not limited to: 1) Title VI of the Civil Rights Act of 1964 (PL 88-352) which prohibits discrimination on the basis of race, color or national origin; 2) Title IX of the Education Amendment of 1972, as amended (20 USC ss.1681-1683, and 1685-1686), which prohibits discrimination on the basis of sex; 3) Section 504 of the Rehabilitation Act of 1973, as amended (20 USC s. 794), which prohibits discrimination on the basis of handicaps; 4) The Age Discrimination Act of 1975, as amended (42 USC ss. 6101-6107) which prohibits discrimination on the basis of age; 5) The Drug Abuse Office and Treatment Act of 1972 (PL 92-255), as amended, relating to nondiscrimination on the basis of drug abuse; 6) The Comprehensive Alcohol Abuse and Alcoholism Prevention, Treatment and Rehabilitation Act of 1970 (PL 91-616), as amended, relating to nondiscrimination on the basis of alcohol abuse or alcoholism; 7) The Public Health Service Act of 1912, ss. 523 and 527 (42 USC ss. 690dd-3 and 290ee-3), as amended, relating to confidentiality of alcohol and drug abuse patent records; 8) Title VIII of the Civil Rights Act of 1968 (42 USC s. et seq.), as amended, relating to nondiscrimination in the sale, rental or financing of housing; 9) The Americans with Disabilities Act of 1990 (42 USC s. 1201 Note), as maybe amended from time to Page 7 of 14 time, relating to nondiscrimination on the basis of disability; 10) Monroe County Code Chapter 13, Article VI, which prohibits discrimination on the basis of race, color, sex, religion, national origin, ancestry, sexual orientation, gender identity or expression, familial status or age; 11) Any other nondiscrimination provisions in any Federal or state statutes which may apply to the parties to, or the subject matter of, this Agreement. i) Covenant of No Interest: County and Contractor covenant that neither presently has any interest, and shall not acquire any interest, which would conflict in any manner or degree with its performance under this Agreement, and that only interest of each is to perform and receive benefits as recited in this Agreement. j) Code of Ethics: County agrees that officers and employees of the County recognize and will be required to comply with the standards of conduct for public officers and employees as delineated in Section 112.313, Florida Statutes, regarding, but not limited to, solicitation or acceptance of gifts; doing business with one's agency; unauthorized compensation; misuse of public position, conflicting employment or contractual relationship; and disclosure or use of certain information. k) No Solicitation/Payment: The County and Contractor warrant that, in respect to itself, it has neither employed nor retained any company or person, other than a bona fide employee working solely for it, to solicit or secure this Agreement and that it has not paid or agreed to pay any person, company, corporation, individual, or firm, other than a bona fide employee working solely for it, any fee, commission, percentage, gift, or other consideration contingent upon or resulting from the award or making of this Agreement. For the breach or violation of the provision, the Contractor agrees that the County shall have the right to terminate this Agreement without liability and, at its discretion, to offset from monies owed, or otherwise recover, the full amount of such fee, commission, percentage, gift, or consideration. 1) Public Records Compliance. Contractor must comply with Florida public records laws, including but not limited to Chapter 119, Florida Statutes and Section 24 of article I of the Constitution of Florida. The County and Contractor shall allow and permit reasonable access to, and inspection of, all documents, records, papers, letters or other "public record" materials in its possession or under its control subject to the provisions of Chapter 119, Florida Statutes, and made or received by the County and Contractor in conjunction with this contract and related to contract performance. The County shall have the right to unilaterally cancel this contract upon violation of this provision by the Contractor. Failure of the Contractor to abide by the terms of this provision shall be deemed a material breach of this contract and the County may enforce the terms of this provision in the form of a court proceeding and shall, as a prevailing party, be entitled to reimbursement of all attorney's fees and costs associated with that proceeding. This provision shall survive any termination or expiration of the contract. The Contractor is encouraged to consult with its advisors about Florida Public Records Law in order to comply with this provision. Pursuant to F.S. 119.0701 and the terms and conditions of this contract, the Contractor is required to: (1) Keep and maintain public records that would be required by the County to perform the service. Page 8 of 14 (2) Upon receipt from the County's custodian of records, provide the County with a copy of the requested records or allow the records to be inspected or copied within a reasonable time at a cost that does not exceed the cost provided in this chapter or as otherwise provided by law. (3) Ensure that public records that are exempt or confidential and exempt from public records disclosure requirements are not disclosed except as authorized by law for the duration of the contract term and following completion of the contract if the contractor does not transfer the records to the County. (4) Upon completion of the contract, transfer, at no cost, to the County all public records in possession of the Contractor or keep and maintain public records that would be required by the County to perform the service. If the Contractor transfers all public records to the County upon completion of the contract, the Contractor shall destroy any duplicate public records that are exempt or confidential and exempt from public records disclosure requirements. If the Contractor keeps and maintains public records upon completion of the contract, the Contractor shall meet all applicable requirements for retaining public records. All records stored electronically must be provided to the County, upon request from the County's custodian of records, in a format that is compatible with the information technology systems of the County. (5) A request to inspect or copy public records relating to a County contract must be made directly to the County, but if the County does not possess the requested records, the County shall immediately notify the Contractor of the request, and the Contractor must provide the records to the County or allow the records to be inspected or copied within a reasonable time. If the Contractor does not comply with the County's request for records, the County shall enforce the public records contract provisions in accordance with the contract, notwithstanding the County's option and right to unilaterally cancel this contract upon violation of this provision by the Contractor. A Contractor who fails to provide the public records to the County or pursuant to a valid public records request within a reasonable time may be subject to penalties under section 119.10, Florida Statutes. The Contractor shall not transfer custody, release, alter, destroy or otherwise dispose of any public records unless or otherwise provided in this provision or as otherwise provided by law. IF THE CONTRACTOR HAS QUESTIONS REGARDING THE APPLICATION OF CHAPTER 119, FLORIDA STATUTES, TO THE CONTRACTOR'S DUTY TO PROVIDE PUBLIC RECORDS RELATING TO THIS CONTRACT, CONTACT THE CUSTODIAN OF PUBLIC RECORDS, BRIAN BRADLEY AT PHONE# 305-292-3470 BRADLEY- BRIANAMONROECOUNTY-FL.GOV, MONROE COUNTY ATTORNEY'S OFFICE 1111 12TH Street, SUITE 408, KEY WEST, FL 33040. m) Non -Waiver of Immunity: Notwithstanding the provisions of Sec. 768.28, Florida Statutes, the participation of the County and the Contractor in this Agreement and the acquisition of any commercial liability insurance coverage, self-insurance coverage, or local government liability Page 9of14 insurance pool coverage shall not be deemed a waiver of immunity to the extent of liability coverage, nor shall any contract entered into by the County be required to contain any provision for waiver. n) Privileges and Immunities: All of the privileges and immunities from liability, exemptions from laws, ordinances, and rules, pensions and relief, disability, workers' compensation, and other benefits which apply to the activity of officers, agents, or employees of any public agents or employees of the County, when performing their respective functions under this Agreement within the territorial limits of the County shall apply to the same degree and extent to the performance of such functions and duties of such officers, agents, volunteers, or employees outside the territorial limits of the County. o) Legal Obligations and Responsibilities: Non -Delegation of Constitutional or Statutory Duties. This Agreement is not intended to, nor shall it be construed as, relieving any participating entity from any obligation or responsibility imposed upon the entity by law except to the extent of actual and timely performance thereof by any participating entity, in which case the performance may be offered in satisfaction of the obligation or responsibility. Further, this Agreement is not intended to, nor shall it be construed as, authorizing the delegation of the constitutional or statutory duties of the County, except to the extent permitted by the Florida constitution, state statute, and case law. p) Non -Reliance by Non -Parties: No person or entity shall be entitled to rely upon the terms, or any of them, of this Agreement to enforce or attempt to enforce any third -party claim or entitlement to or benefit of any service or program contemplated hereunder, and the County and the Contractor agree that neither the County nor the Contractor or any agent, officer, or employee of either shall have the authority to inform, counsel, or otherwise indicate that any particular individual or group of individuals, entity or entities, have entitlements or benefits under this Agreement separate and apart, inferior to, or superior to the community in general or for the purposes contemplated in this Agreement. q) Attestations: Contractor agrees to execute such documents as the County may reasonably require, including a Public Entity Crime Statement, an Ethics Statement, and a Drug -Free Workplace Statement. r) No Personal Liability: No covenant or agreement contained herein shall be deemed to be a covenant or agreement of any member, officer, agent or employee of Monroe County in his or her individual capacity, and no member, officer, agent or employee of Monroe County shall be liable personally on this Agreement or be subject to any personal liability or accountability by reason of the execution of this Agreement. s) Execution in Counterparts: This Agreement may be executed in any number of counterparts, each of which shall be regarded as an original, all of which taken together shall constitute one and the same instrument and any of the parties hereto may execute this Agreement by signing any such counterpart. t) Section Headings: Section headings have been inserted in this Agreement as a matter of convenience of reference only, and it is agreed that such section headings are not a part of this Agreement and will not be used in the interpretation of any provision of this Agreement. u) Special Conditions, if any are detailed in Section 01000 of the Project Manual for this Project. Page 10 of 14 v) Hold Harmless and Indemnification: Notwithstanding any minimum insurance requirements prescribed elsewhere in this agreement, the Contractor covenants and agrees that he shall defend, indemnify and hold the COUNTY and the COUNTY's elected and appointed officers and employees harmless from and against (1) claims, actions or causes of action, (ii) litigation, administrative proceedings, appellate proceedings, or other proceedings relating to any type of injury (including death), loss, damage, fine, penalty or business interruption, and (iii) costs or expenses that may be asserted against, initiated with respect to, or sustained by the County and the COUNTY's elected and appointed officers and employees from liabilities damages, losses and costs, including but not limited to, reasonable attorney's fees, to the extent caused by the negligence, recklessness, or intentional wrongful misconduct of the Contractor and persons employed or utilized by the indemnifying party in the performance of the construction contract. The monetary limitation of liability under this contract shall be not less than $1 million per occurrence pursuant to F. S. 725.06. Insofar as the claims, actions, causes of action, litigation, proceedings, costs or expenses relate to events or circumstances that occur during the term of this Agreement, this section will survive the expiration of the term of this Agreement or any earlier termination of this Agreement. In the event the completion of the project (including the work of others) is delayed or suspended as a result of the Contractor's failure to purchase or maintain the required insurance, the Contractor shall indemnify the County from any and all increased expenses resulting from such delay. The first ten dollars ($10.00) of remuneration paid to the Contractor is for the indemnification provided for above. The extent of liability is in no way limited to, reduced, or lessened by the insurance requirements contained elsewhere within General Insurance Requirements Section 900. In the event any claims are brought or actions are filed against the County with respect to the indemnity contained herein, the Contractor agrees to defend against any such claims or actions regardless of whether such claims or actions are rightfully or wrongfully brought or filed. The Contractor agrees that the County may select the attorneys to appear and defend such claims or actions on behalf of the County. The Contractor further agrees to pay at the Contractor's expense the attorneys' fees and costs incurred by those attorneys selected by the County to appear and defend such actions or claims on behalf of the County at both the trial and appellate levels. The County at its sole option, shall have the sole authority for the direction of the defense, and shall be the sole judge of the acceptability of any compromise or settlement of any claims or actions against the County. w) Adjudication of Disputes or Disagreements: The Owner and Contractor agree that all disputes and disagreement shall be attempted to be resolved by meet and confer sessions between representatives of each of the parties. If no resolution can be agreed upon within 30 days after the first meet and confer session, the issue or issues shall be discussed at public meeting of the Board of County Commissioners. If the issue or issues are still not resolved to the satisfaction of the parties, then any party shall have the right to seek such relief or remedy as may be provided by this Agreement or by Florida law. This provision does not negate or waive the provisions of Paragraph X concerning cancellation. x) Cancellation: In the event that the Contractor shall be found to be negligent in any aspect of installation, stocking, maintenance, repair, or service, the County shall have the right to terminate this agreement after five days written notification to the Contractor. Page 11 of 14 y) Cooperation: In the event any administrative or legal proceeding is instituted against either party relating to the formation, execution, performance, or breach of this Agreement, County and Contractor agree to participate, to the extent required by the other party, in all proceedings, hearings, processes, meetings, and other activities related to the substance of this Agreement or provision of the services under this Agreement. County and Contractor specifically agree that no parry to this Agreement shall be required to enter into any arbitration proceedings related to this Agreement. z) Insurance: Prior to commencement of work the Contractor will provide satisfactory evidence of insurance as required in Specification Section 00900 General Insurance Requirements for Construction Contractors and Subcontractors. The Contractor shall name the Monroe County Board of County Commissioners, its employees and officials as "Additional Insured" on all policies except for Worker's Compensation. 7.7 Ownership of the Project Documents: The documents prepared by the Contractor for this Project belong to the County and may be reproduced and copied without acknowledgement or permission of the Contractor. 7.8 Successors and Assigns: The Contractor shall not assign or subcontract its obligations under this agreement, except in writing and with the prior written approval of the Board of County Commissioners for Monroe County, which approval shall be subject to such conditions and provisions as the Board may deem necessary. This paragraph shall be incorporated by reference into any assignment or subcontract and any assignee or subcontractor shall comply with all of the provisions of this Agreement. Subject to the pro --:ions of the immediately preceding sentence, each party hereto binds itself, its successors, assigns and legal representatives to the other and to the successors, assigns and legal representatives of such other party. 7.9 No third Party Beneficiaries: Nothing contained herein shall create any relationship, contractual or otherwise, with or any rights in favor of, any third parry. 7.10 Americans with Disabilities Act of 1990 (ADA) -The CONTRACTOR will comply with all the requirements as imposed by the ADA, the regulations of the Federal government issued thereunder, and the assurance by the CONTRACTOR pursuant thereto. ARTICLE 8 Termination or Suspension 8.1 The Contract may be terminated by the Owner or the Contractor as provided in Article 14 of the General Conditions. 8.2 The Work may be suspended by the Owner as provided in Article 14 of the General Conditions. ARTICLE 9 Enumeration of Contract Documents 9.1 The Contract Documents, except for Modifications issued after execution of this Agreement, are enumerated as follows: See Article 1 Page 12 of 14 9.1.1 The Agreement is this executed Standard Form of Agreement between Owner and Contractor. 9.1.2 The General Conditions are the General Conditions of the Contract for Construction. 9.1.3 The Supplementary and other Conditions of the Contract are those contained in the Project Manual dated April 2016 and are as follows: As listed in Table of Contents, Section 00001 of the Project Manual for this project. 9.1.4 The Specifications are those contained in the Project Manual dated as in Subparagraph 9.1.3, and are as follows: As listed in Table of Contents, Section 00001 of the Project Manual for this project. 9.1.5 The Drawings are as follows, and are dated on each individual drawing unless a different date is shown below: CDM Signed and Sealed March 2016: Sheets 1 to 25. 9.1.6 The Addenda, if any, are as follows: Addenda 1 and 2. Portions of Addenda relating to bidding requirements are not part of the Contract Documents unless the bidding requirements are also enumerated in this Article 9. 9.1.7 Other documents, if any, forming part of the contract Documents are as follows: Monroe County Bid Form in Section 00110. See Article 1. Page 13 of 14 IN WITNESS WHEREOF the parties hereto have executed this Agreement on the day and date first written above in four (4) counterparts, each of which shall, without proof or accounting for the other counterparts, be deemed an original contract. (SEAL),. Attest: By: x Title: SPG �1 BOARD OF COUNTY COMMISSIONERS OF MONROE jCO;TY, FLORIDA By Mayor H&R PAVING, INC. (CONTRACTOR) By: Title: I/f./ -0 v1 t Filli Ii,;, _. iRGVVS ASS!-",i { Data _r Page 14 of 14 aP-.) 'T M R, n Cn LO �► iv _-_7 H&RPA-2 OP ID: LR A`ORO CERTIFICATE OF LIABILITY INSURANCE DATE/07/20r oso7/2o6 1s THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsements . PRODUCER CONTACT NAME: Ramon A Rodri uez BROWN & BROWN OF FLORIDA INC 14900 NW 79th Court Suite#200 WC, X .305-364-7800 FAXNo, 305-714-4401 E-MAIL ADDRESS: Miami Lakes, FL 33016-5869 Ramon A Rodriguez INSURER(S) AFFORDING COVERAGE NAIC A INSURER A:*Allied World Specialty Ins Co 16624 INSURED H & R Paving, Inc. INSURER B :*Great American Insurance Co* 16691 1955 NW 110th Ave INSURERC:*Westchester Surplus Lines Ins 10172 Miami, FL 33172-1911 IrIsuRERD:*Allied World Nat'l Assurance 10690 SURER E : INSURER F : COVERAGES CERTIFICATE NUMBER: REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR LTR TYPE OF INSURANCE ADDL SUBR POLICY NUMBER POLICY EFF MM/DD POLICY EXP MM/DD/YYYY LIMITS D X COMMERCIAL GENERAL LIABILITY EACH OCCURRENCE $ 1,000,00 CLAIMS -MADE o OCCUR X 03101212 05/01/2016 05/01/2017 DAMAGE TO RENTED PREMISES Ea occurrence $ 100,00 MED EXP (Any one person) $ 5,00 A�PP7 ES�PK M GEME PERSONAL & ADV INJURY $ 1,000,00 AGGREGATE LIMIT APPLIES PER: GENERAL AGGREGATE $ 2,000,00 GEN'L BY POLICY PRO ❑ LOC JECT ` DATE PRODUCTS - COMP/OP AGG $ 2,000,00 lEmp Ben. $ 1,000,00 OTHER: 9 AUTOMOBILE LIABILITY WAIVER TAT,__ COMBINED SINGLE LIMIT Ea accident $ 1,000,000 X BODILY INJURY (Per person) $ A ANY AUTO X 60000232. 05/01/2016 05/01/2017 ALLOWNED SCHEDULED AUTOS AUTOS BODILY INJURY (Per accident) $ NON -OWNED HIRED AUTOS AUTOS PROPERTY DAMAGE Per accident $ $ X UMBRELLA LIAR X OCCUR EACH OCCURRENCE $ 10,000,00 AGGREGATE $ 10,000,00 B EXCESS LIAB CLAIMS -MADE T00048352603 05/01/2016 05/01/2017 DED X RETENTION $ 0 $ WORKERS COMPENSATION AND EMPLOYERS' LIABILITY YIN ANY PROPRIETOR/PARTNER/EXECUTIVE ❑ OFFICERIMEMBER EXCLUDED? N / A PER OTH- STATUTE ER E.L. EACH ACCIDENT $ E.L. DISEASE - EA EMPLOYE $ (Mandatory in NH) If yes, describe under DESCRIPTION OF OPERATIONS below E.L. DISEASE - POLICY LIMIT $ C Pollution X G24275516005 05/01/2016 05/01/2017 Limits 1,000,00 DESCRIPTION OF OPERATIONS I LOCATIONS I VEHICLES (ACORD 101, Additional Remarks Schedule, may be attached if more space is required) Sexton Cove Roadway and Drainage Improvement Project, Key Largo, Monroe County, Florida Certificate Holder is listed as additional insured with respects to General Liability, Auto Liability, & Pollution Liability when required by written contract. CERTIFICATE HOLDER CANCELLATION MONROEC SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE Monroe Count Board of Count Y y THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. Commissioners ("BOCC") 1100 Simonton Street Key West, FL 33040 AUTHORIZED REPRESENTATIVE Brown and Brown of Florida, Inc. ©1988-2014 ACORD CORPORATION. All rights reserved. ACORD 25 (2014101) The ACORD name and logo are registered marks of ACORD ALTER SURETY GROUP, INC. Bond Department - Public Works Bond In compliance with Florida Statute Chapter 255.05, the provisions and limitations of section 255.05 Florida Statutes, including but not limited to, the notice and time limitations in Sections 255.05(2) and 255.05(10) are incorporated in this bond by reference. Bond Number Contractor Address & Phone No. PB12159900028 H & R Paving, Inc. 1955 NW 110th Avenue Miami, FL 33172 305-261-3005 Surety Philadelphia Indemnity Insurance Company Address & One Bala Plaza, Suite 100 Phone No. Bala Cynwyd, PA 19004 610-617-7900 Owner Name Monroe County Board of County Commissioners Address & 1100 Simonton Street Phone No. Key West, FL 33040 305-292-4453 Contracting Public Entity N/A (if different from the owner) Address & Phone No. Contract/Project Number Bid No.: 82-0-2016 Project Name Sexton Cove Roadway and Drainage Improvement Project Project Location Key Largo, Monroe County Florida Legal Description Key Largo, Monroe County Florida And Street Address Description of Improvement: Roadway and Drainage Improvements This bond is given to comply with section 255.05 Florida Statutes and any action instituted by a claimant under this bond for payment must be in accordance with the notice and time limitation provisions in Section 255.05(2) and (10), Florida Statutes. Any provision of this bond which conflict with or purports to grant broader or more expanded coverage in excess of the minimum requirements of the applicable statute shall .be deemed deleted herefrom. This bond is a statutory bond, not a common law bond. This is the front page of the bond. All other page(s) are deemed subsequent to this page regardless of any page number(s) that may be pre-printed thereon. Bond No.: PB12159900028 AIA Document A3121"' 2010 Performance Bond CONTRACTOR: SURETY: (Name, legal status and address) (Nrmre, legal status and principal place H & R Paving, Inc. of business) 1955 NW 110 Avenue Philadelphia Indemnity Insurance CompanyThis document has important legal Miami, FL 33172 One Bala Plaza, Suite 100, consequences. consultation with OWNER: Bala Cynwyd, PA 19004-1403 an attorney Is encouraged with (Name, legal status and address) respect to Its completion or modificalron. Monroe County Board of County Commissioners 1100 Simonton Street Key West, FL 33040 CONSTRUCTION CONTRACT Date: July 20th, 2016 Amount: $1,105,342.35 Description; (Name and location) Sexton Cove Roadway and Drainage Improvement Project Key Largo, Monroe County, Florida BOND Date: July 20th, 2016 (Not earlier than Construction Contracr Date) Amount: $1,105,342.35 Modifications to this Bond: ® None ❑ See Section 16 Any singular reference to Contractor, Surely, owner or other party shall be considered plural where applicable. AIA Document AM-2010 combines two separate bonds, a Performance Bond and a Payment Bond, Into one form. This Is not a single combined Performance and Payment Bond. CONTRACTOR AS PRINCIPAL SURETY Company: (Corpo 'ate Seal) Company: Corporate Seal) H & R Paving,Winc. Philadelphia Ind em surance Company Signature _ Signature:` Name <Z a �a atine, Attorney -in -Fact and Title: �lS� �iN and Title: (Any addit on signatures appear on the last page of this per rmance Bond) (FOR INFORMATION ONLY— Nanre, address and telephone) AGENT or BROKER: OWNER'S REPRESENTATIVE: Alter Surety Group, Inc. (Architect, Engineer or other party) 5979 NW 151 st Street, #202 Miami Lakes, FL 33014 305-517-3803 Init. AIA Document A312'" — 2010. The Ameflcan institute of Architects, 051110 § 1 The Contractor and Surety, jointly and severally, bind themselves, their heirs, executors, administrators, successors and assigns to the Owner for the performance of the Construction Contract, which is incorporated herein by reference. § 2 If the Contractor performs the Construction Contract, the Surety and the Contractor shall have no obligation under this Bond, except when applicable to participate in a conference as provided in Section 3. § 3 If there is no Owner Default under the Construction Contract, the Surety's obligation under this Bond shall arise after 1 the Owner first provides notice to the Contractor and the Surety that the Owner is considering declaring a Contractor Default. Such notice shall indicate whether the Owner is requesting a conference among the Owner, Contractor and Surety to discuss the Contractor's performance, If the Owner does not request a conference, the Surety may, within five (5) business days after receipt of the Owner's notice, request such a conference. If the Surety timely requests a conference, the Owner shall attend. Unless the Owner agrees otherwise, any conference requested under this Section 3.1 shall be held within ten (10) business days of the Surety's receipt of the Owner's notice. If the Owner, the Contractor and the Surety agree, the Contractor shall be allowed a reasonable time to perform the Construction Contract, but such an agreement shall not waive the Owner's right, if any, subsequently to declare a Contractor Default; .2 the Owner declares a Contractor Default, terminates the Construction Contract and notifies the Surety; and .3 the Owner has agreed to pay the Balance of the Contract Price in accordance with tite terms of the Construction Contract to the Surely or to a contractor selected to perform the Construction Contract. § 4 Failure oil the part of the Owner to comply with the notice requirement in Section 3.1 shall not constitute a failure to comply with a condition precedent to the Surety's obligations, or release the Surety from its obligations, except to the extent the Surety demonstrates actual prejudice. § 5 When the Owner has satisfied the conditions of Section 3, the Surety shall promptly and at the Surety's expense take one of the following actions: § 51 Arrange for the Contractor, with the consent of the Owner, to perform and complete the Construction Contract; § 5,2 Undertake to perform and complete the Construction Contract itself, through its agents or independent contractors; § 5.3 Obtain bids or negotiated proposals from qualified contractors acceptable to the Owner t'or a contract for performance and completion of the Construction Contract, arrange for a contract to be prepared for execution by the Owner and a contractor selected with the Owner's concurrence, to be secured with performance and payment bonds executed by a qualified surety equivalent to the bonds issued on the Construction Contract, and pay to the Owner the amount of damages as described in Section 7 in excess of the Balance of the Contract Price incurred by the Owner as a result of the Contractor Default; or § 5.4 Waive its right to perform and complete, arrange for completion, or obtain a new contractor and with reasonable promptness under the circumstances: .1 After investigation, determine the amount for which it may be liable to the Owner and, as soon as practicable after the amount is determined, make payment to the Owner; or .2 Deny liability in whole or in part and notify the Owner, citing the reasons for denial, § 6 If the Surety does not proceed as provided in Section 5 with reasonable promptness, the Surety shall be deemed to be in default on this Bond seven days after receipt of an additional written notice from the Owner to the Surety demanding that the Surety perform its obligations under this Bond, and the Owner shall be entitled to enforce any remedy available to the Owner. If the Surety proceeds as provided in Section 5.4, and the Owner refuses the payment or the Surety has denied liability, in whole or in part, without further notice the Owner shall be entitled to enforce any remedy available to the Owner. Init. AIA DocumentA312TM —20% The American tnslitule of Archllecls. § 7 If the Surety elects to act under Section 5, I, 5.2 or 5.3, then the responsibilities of the Surety to the Owner shall not be greater than those of the Contractor under the Construction Contract, and the responsibilities of the Owner to the Surety shall not be greater than those of the Owner under the Construction Contract. Subject to the commitment by the Owner to pay the Balance of the Contract Price, the Surety is obligated, without duplication, for .1 the responsibilities of the Contractor for correction of defective work and completion of the Construction Contract; .2 additional legal, design professional and delay costs resulting from the Contractor's Default, and resulting from the actions or failure to act of the Surety under Section 5; and .3 liquidated damages, or if no liquidated damages are specified in the Construction Contract, actual damages caused by delayed performance or non-performance of the Contractor. § 8 If the Surety elects to act under Section 5.1, 53 or 5.4, the Surety's liability is limited to the amount of this Bond. § 9 The Surety shall not be liable to the Owner or others for obligations of the Contractor that are unrelated to the Construction Contract, and the Balance of the Contract Price shall not be reduced or set off on account of any such unrelated obligations, No right of action shall accrue on this Bond to any person or entity other than the Owner or its heirs, executors, administrators, successors and assigns. § 10 The Surety hereby waives notice of any change, including changes of time, to the Construction Contract or to related subcontracts, purchase orders and other obligations. § 11 Any proceeding, legal or equitable, under this Bond may be instituted in any court of competent jurisdiction in the location in which the work or part of the work is located and shall be instituted within two years after a declaration of Contractor Default or within two years after the Contractor ceased working or within two years after the Surety refuses or fails to perform its obligations under this Bond, whichever occurs first. If the provisions of this Paragraph are void or prohibited by law, the minimum period of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable, § 12 Notice to the Surety, Elie Owner or the Contractor shall be mailed or delivered to the address shown on the page on which their signature appears, § 13 When this Bond has been furnished to comply with a statutory or other legal requirement in the location where the construction was to be performed, any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefrotn and provisions conforming to such statutory or other legal requirement shall be deemed incorporated herein. When so furnished, the intent is that this Bond shall be construed as a statutory bond and not as a common law bond. § 14 Definitions § 14,1 Balance of the Contract Price. The total amount payable by the Owner to the Contractor under the Construction Contract after all proper adjustments have been made, including allowance to the Contractor of any amounts received or to be received by the Owner in settlement of insurance or other claims for damages to which the Contractor is entitled, reduced by all valid and proper payments made to or on behalf of the Contractor under the Construction Contract. § 14.2 Construction Contract. The agreement between the Owner and Contractor identified oil the cover page, including all Contract Documents and changes made to the agreement and the Contract Documents. § 14.3 Contractor Default. Failure of the Contractor, which Ilas not been remedied or waived, to perform or otherwise to comply with a material term of the Construction Contract. § 14.4 Owner Default. Failure of the Owner, which has not been remedied or waived, to pay the Contractor as required under the Construction Contract or to perform and complete or comply with the other material terms of the Construction Contract. § 14,5 Contract Documents. All the documents that comprise the agreement between the Owner and Contractor. § 151f this Bond is issued for an agreement between a Contractor and subcontractor, the term Contractor in this Bond shall be deemed to be Subcontractor and the term Owner shall be deemed to be Contractor. Init. AIA Document A312IY — 2010. The American Inslllule of Archltocts. § 16 Modifications to (his bond are as follows: (Space is provided below for additional signatures of added pat -ties, other than those appearing on the cover page.) CONTRACTOR AS PRINCIPAL SURETY Company: (Corporate Seat) Company: (Corporate Seal) Signature: Name and Title: Address Signature: Name and'ritie: Address You nhould !;iy)o ;!n L-!i(p0(.l AIA '.A`X:11j(if-;*;';. oo tlit:t lv1:J ;t :11 HE"). !'-.I% nu.�ur.-'t N.- ../ill not t')r. Init. AlA Document A312m - 2010. The American Insiltute of Architects. Bond No.: PB12159900028 e :.s. AIA Document A312TM — 2010 Payment Bond CONTRACTOR: SURETY: (Nance, legal status and address) (Name, legal stales and principal place H & R Paving, Inc. of business) 1955 NW 110 Avenue Philadelphia Indemnity Insurance Companyrhisdocument has important legal Miami, FL 33172 One Bala Plaza, Suite 100, consequences. Consultation with Bala Cynwyd, PA 19004-1403 an attorney Is encouraged with OWNER: respect to Its completion or (Name, legal status and address) modification. Monroe County Board of County Commissioners Any singular reference to 1100 Simonton Street 11 Contractor, Surety, Owner or Y West, FL 330re other party shall be considered CONSTRUCTION CONTRACT plural where applicable. Date: July 20th, 2016 AIA Document A312-2010 combines two separate bonds, a A Amount: $1,105,342.35 Performance Bond and a Payment Bond. Into one form. This is not a single combined Description: p Performance and Payment Bond. (Nance and location) Sexton Cove Roadway and Drainage Improvement Project Key Largo, Monroe County, Florida BOND Date: July 20th, 2016 (Not earlier than Construction Contract Date) Amount: $1,105,342.35 Modifications to this Bond: ❑ None 18 See Section 18 CONTRACTOR AS PRINCIPAL SURETY Company: (Corporate Seal) Company: (Corporate Seal) M & R Paving, Inc. Philadelphia Indem ' urance Company Signature: Signattcr : Name am Wo id T. Satine, Attorney -in -Fact and Tittle: 15� and Title: (Any addit onal signatures appear on the last page of this aI ment Bond.) (FOR INFORMATION ONLY -- Name, address and telephone) AGENT or BROKER: OWNER'S REPRESENTATIVE: Alter Surety Group, Inc. (Architect, Engineer or other party.) 5979 NW 151st Street, #202 Miami Lakes, FL 33014 305-517-3803 Init. AIA Document AMT4 -2010. The American Institute of Architects. 061110 5 § 1 The Contractor and Surety, jointly and severally, bind themselves, their heirs, executors, administrators, successors and assigns to the Owner to pay for labor, materials and equipment furnished for use in the performance of the Construction Contract, which is incorporated herein by reference, subject to the following terms. § 21f the Contractor promptly makes payment of all sums due to Claimants, and defends, indemnifies and holds harmless the Owner from claims, demands, liens or suits by any person or entity seeking payment for labor, materials or equipment furnished for use in the performance of the Construction Contract, then the Surety and the Contractor shall have no obligation under this Bond. § 3 If there is no Omer Default under the Construction Contract, the Surety's obligation to the Owner under this Bond shall arise after the Owner has promptly notified the Contractor and the Surety (at the address described in Section 13) of claims, demands, I ions or suits against the Owner or the Owner's property by any person or entity seeking payment for labor, materials or equipment furnished for use in the performance of the Construction Contract and tendered defense of such claims, demands, liens or suits to the Contractor and the Surety. § 4 When the Owner has satisfied the conditions in Section 3, the Surety shall promptly and at the Surety's expense defend, indemnify and hold harmless the Owner against a duly tendered claim, demand, lien or suit, § 5 The Surety's obligations to a Claimant under this Bond shall arise after the following: § 5.1 Claimants, who do not have a direct contract with the Contractor, 1 have fundshed a written notice of non-payment to the Contractor, stating with substantial accuracy the amount claimed and the name of the party to whom the materials were, or equipment was, furnished or supplied or for whom the labor was done or performed, within ninety (90) days after having last performed labor or last furnished materials or equipment included in the Claim; and .2 have sent a Claim to the Surety (at the address described in Section 13). § 5.2 Claimants, who are employed by or have a direct contract with the Contractor, have sent a Claim to the Surety (at the address described in Section I3). § 8 If a notice of non-payment required by Section 5.1.1 is given by the Owner to the Contractor, that is sufficient to satisfy a Claimant's obligation to furnish a written notice of non-payment under Section 5.1.1. § 7 When a Claimant has satisfied the conditions of Sections 5.1 or 5.2, whichever is applicable, the Surety shall promptly and at the Surety's expense take the following actions: § 7.1 Send an answer to the Claimant, with a copy to the Owner, within sixty (60) days after receipt of the Claim, stating the amounts that are undisputed and the basis for challenging any amounts that are disputed; and § 7.2 Pay or arrange for payment of any undisputed amounts. § 7.3 The Surety's failure to discharge its obligations under Section 7.1 or Section 7.2 shall not be deemed to constitute a waiver of defenses the Surety or Contractor may have or acquire as to a Claim, except as to undisputed amounts for which the Surety and Claimant have reached agreement. If, however, the Surety fails to discharge its obligations under Section 7.1 or Section 7.2, the Surety shall indemnify the Claimant for the reasonable attor ney's fees the Claimant incurs thereafter to recover any sums found to be due and owing to the Claimant. § 8 The Surety's total obligation shall not exceed the amount of this Bond, plus the amount of reasonable attorney's fees provided under Section 7.3, and the amount of this Bond shall be credited for any payments made in good faith by the Surety. § 9 Amounts owed by the Owner to the Contractor under the Construction Contract shall be used for the performance of the Construction Contract and to satisfy claims, if any, under any construction performance bond. By the Contractor furnishing and the Owner accepting this Bond, they agree that all funds earned by the Contractor in the performance of the Construction Contract are dedicated to satisfy obligations of die Contractor and Surety under this Bond, subject to the Owner's priority to use the fiends for the completion of the work. Init. AIA Document A312m — 2010. The American Institute of Architects. § 10 The Surety shall not be liable to the Owner, Claimants or others for obligations of the Contractor that are unrelated to the Construction Contract. The Owner shall not be liable for the payment of any costs or expenses of any Claimant under this Bond, and shall have under this Bond no obligation to make payments to, or give notice on behalf of, Claimants or otherwise have any obligations to Claimants under this Bond. § 11 The Surety hereby waives notice of any change, including changes of time, to the Construction Contract or to related subcontracts, purchase orders and other obligations. § 12 No suit or action shall be commenced by a Claimant under (iris Bond other than in a court of competent jurisdiction in the stafe in which the project that is the subject of the Construction Contract is located or after the expiration of one year from the date (1) on which the Claimant sent a Claim to the Surety pursuant to Section 5.1.2 or 5.2, or (2) on which the last labor or service was performed by anyone or the last materials or equipment were furnished by anyone under the Construction Contract, whichever of (1) or (2) first occurs. If the provisions of this Paragraph are void or prohibited by law, the minimum period of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable. § 13 Notice and Claims to the Surety, the Owner or the Contractor shall be mailed or delivered to the address shown on the page on which their signature appears. Actual receipt of notice or Claims, however accomplished, shall be sufficient compliance as of the date received, § 14 When this Bond has been furnished to comply with a statutory or other legal requirement in the location where the construction was to be performed, any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefrorn and provisions conforming to such statutory or other legal requirement shall be deemed incorporated herein. When so furnished, the intent is that this Bond shall be construed as a statutory bond and not as a common law bond. § 15 Upon request by any person or entity appearing to be a potential beneficiary of this Bond, the Contractor and Owner shall promptly furnish a copy of this Bond or shall permit a copy to be made. § 16 Definitions § 16.1 Claim. A written statement by the Claimant including at a minimum; ,1 the name of the Claimant; ,2 the name of the person for whom the labor was done, or materials or equipment furnished; .3 a copy of the agreement or purchase order pursuant to which labor, materials or equipment was furnished for use in the performance of the Construction Contract; .4 a brief description of the labor, materials or equipment furnished; .5 the date on which the Claimant last performed labor or last furnished materials or equipment for use in the performance of the Construction Contract; .6 the total amount earned by the Claimant for labor, materials or equipment furnished as of the date of the Claim; ,7 the total amount of previous payments received by the Claimant; and .8 the total amount due and unpaid to the Claimant for labor, materials or equipment furnished as of the date of the Claim, § 16.2 Claimant. An individual or entity having a direct contract with the Contractor or with a subcontractor of the Contractor to furnish labor, materials or equipment for use in the performance of the Construction Contract. The term Claimant also includes any individual or entity that has rightfully asserted a claim under an applicable mechanic's lien or similar statute against the real property upon which the Project is located, The intent of this Bond shall be to include without limitation in the terms "labor, materials or equipment" that part of water, gas, power, light, heat, oil, gasoline, telephone service or rental equipment used in the Construction Contract, architectural and engineering services required for performance of the work of the Contractor and the Contractor's subcontractors, and all other items for which a mechanic's lien may be asserted in the jurisdiction where the labor, materials or equipment were furnished. § 16,3 Construction Contract. The agreement between the Owner and Contractor identified on the cover page, including all Contract Documents and all changes made to the agreement and the Contract Documents, Init, AIA Document A712'M — 2010, The American Institute of Architects. § 16.4 Owner Default. Failure of the Owner, which has not been remedied or waived, to pay the Contractor as required under the Construction Contract or to perform and complete or comply with the other material tenns of the Construction Contract. § 16,5 Contract Documents. All the documents that comprise the agreement between the Owner and Contractor. § 17 If this Bond is issued for an agreement between a Contractor and subcontractor, the term Contractor in tills Bond shall be deemed to be Subcontractor and the term Owner shall be deemed to be Contractor. § 18 Modifications to this bond are as follows: The provisions and Wn fatbns of section2$6.06 Florida SWules, including but not Mftd to the rnafte and Gm Nmifa/ions in Sections 266.06(2) and 266.06(10), are incorporated in this bond by reference. (Space is provided below for additional signatures of added parties, other than those appearing on the cover page.) CONTRACTOR AS PRINCIPAL SURETY Company: (Corporate Seal) Company: (Corporate Seal) Signature: Signature: Name and Title: Name and Title: Address Address CAUTI-ON: You . +uld :Igo till oVit)Lusl AU-1- ,'•nlifrat;; Dr;r;l+rt r.!, :::: iwhi'•h Ihilt !;i"r:: 1Ci; in REV; A:.n:!q rhant;<r.; not N! nn ;r._ rcfd. AIA Documont A31214 — 2010. The American Institute of Architects. 0 s 175 PHILADELPHIA INDEMNITY INSURANCE COMPANY One Bala Plaza, Suite 100 Bala Cynwyd, PA 19004-0950 Power of Attorney KNOW ALL PERSONS BY THESE PRESENTS: That PHILADELPHIA INDEMNITY INSURANCE COMPANY (the Company), a corporation organized and existing under the laws of the Commonwealth of Pennsylvania, does hereby constitute and David T. Satine and Warren M. Alter of Alter Surety Group, Inc its true and lawful Attorney -in -fact with full authority to execute on its behalf bonds, undertakings, recognizances and other contracts of indemnity and writings obligatory in the nature thereof, issued in the course of its business and to bind the Company thereby, in an amount not to exceed $25,000,000.00. This Power of Attomey is granted and is signed and sealed by facsimile under and by the authority of the following Resolution adopted by the Board of Directors of PHILADELPHIA INDEMNITY INSURANCE COMPANY at a meeting duly called the V day of July, 2011. RESOLVED: That the Board of Directors hereby authorizes the President or any Vice President of the Company to: (1) Appoint Attomey(s) in Fact and authorize the Attomey(s) in Fact to execute on behalf of the Company bonds and undertakings, contracts of indemnity and other writings obligatory in the nature thereof and to attach the seal of the Company thereto; and (2) to remove, at any time, any such Attorney -in -Fact and revoke the authority given. And, be it FURTHER RESOLVED: That the signatures of such officers and the seal of the Company may be affixed to any such Power of Attorney or certificate relating thereto by facsimile, and any such Power of Attorney so executed and certified by facsimile signatures and facsimile seal shall be valid and biding upon the Company in the future with the respect to any bond or undertaking to which it is attached. IN TESTIMONY WHEREOF, PHILADELPHIA INDEMNITY INSURANCE COMPANY HAS CAUSED THIS INSTRUMENT TO BE SIGNED AND ITS CORPORATE SEALTO BE AFFIXED BY ITS AUTHORIZED OFFICE THIS I OTH DAY OF JUNE 2013. (Seal) Robert D. O'Leary Jr., President & CEO Philadelphia Indemnity Insurance Company On this 10 ° day of June 2013, before me came the individual who executed the preceding instrument, to me personally known, and being by me duly sworn said that he is the therein described and authorized officer of the PHILADELPHIA INDEMNITY INSURANCE COMPANY; that the seal affixed to said instrument is the Corporate seal of said Company; that the said Corporate Seal and his signature were duly affixed. COMORWPOM OF PEN Y N" .1" UAWj NyCWn1VWFfr- DmI8eaxxr CORMObn 6ryFae We t6 2C16 naOetrrrisnvoewA99DwiwnarsDw Notary Public: residing at: Bala Cynwyd. PA (Notary Seal) My commission expires: December 18, 2016 I, Edward Sayago, Corporate Secretary of PHILADELPHIA INDEMNITY INSURANCE COMPANY, do herby certify that the foregoing resolution of the Board of Directors and this Power of Attorney issued pursuant thereto on this I OTH day of June 2013 true and correct and are still in full force and effect. I do further certify that Robert D. O'Leary Jr., who executed the Power of Attorney as President, was on the date of execution of the attached Power of Attorney the duly elected President of PHILADELPHIA INDEMNITY INSURANCE COMPANY, In Testimony Whereof I have subscribed my name and affixed the facsimile seal of each Company this 20tky of July, 201,E 1 927 Edward Sayago, Corporate Secretary PHILADELPHIA INDEMNITY INSURANCE COMPANY