6th Change Order 02/03/2017MONROE COUNTY /ENGINEERING/ PROJECT
MANAGEMENT
CONTRACT CHANGE ORDER
PROJECT TITLE:
East Martello Museum ADA Upgrades
TO CONTRACTOR:
Barracuda Builders of Key West, Inc.
5601 3` avenue, Key West, FL 33040
CHANGE ORDER NO: 6
INITIATION DATE: 1130/2017
CONTRACT DATE: 3/23/2016
The Contract is changed as follows:
The original (Contract Sum (Guaranteed Maximum Price) .............. ....................$149,780.00
Net change by previously authorized Change Orders ....................... .....................$53,290.50
The (Contract Sum (Guaranteed Maximum Price) prior to this Change order was ... $203,070.50
The (Contract Sum (Guaranteed Maximum Price) will be (increased) (decreased)
(unchanged) by this Change Order ....... $00.00
The new (Contract Sum) (Guaranteed Maximum Price) including this Change Order is ...... $203,070.50
The Contract Time will be increased (decreased) (unchanged) by ......................15 Days
The date of Substantial Completion as of the date of this Change Order is........... 3/10/2017
Detailed description of change order and justification:
No cost Change Order to add 15 days to the schedule due to unforeseen manufacturer lead time
needed to construct the New Storefront Door.
This chance Order is 0.0% of the original contract Price
ARCHITECT:
CONTRACTOR:
DIRECTOR PROJECT MANAGEMENT:
COUNTY /ASSISTANT ADMINISTRATOR:
Date
Rivera -Chris
r ' �
From:
Cheryl Chavka <cheryl @barracudabuilders.com>
Sent:
Wednesday, January 25, 2017 9:36 AM
To:
Rivera -Chris
Cc:
Bert Bender
Subject
East Martello - Substantial Completion Date
Attachments:
East Martello CO #5 - Masonry Wall for Lift.pdf
Good morning Chris,
Currently our Substantial Completion Date for East Martello is 2/21/2017. This date does not include
Change Order #5 Masonry Wall for Lift. This is the change order we submitted and thought we'd be
swapping this for the brick damage, which we are not doing per County request. You then stated
you'd create the official change order paperwork for this. This would increase our Substantial
Completion Date by two days to 2/23/17.
Aside from these two extra days, we do need to add more time to our contract for the New
Storefront. The manufacturer was closed for their annual calibration and maintenance thus causing a
delay in producing the new store front. The tentative delivery date is Wednesday March ist and then
we'll need to install the door and windows... A No Cost Change Order will need to be created to add
(15) days to our contract, with Substantial Completion then being Friday 3/10 Please let me know
if I need to create this Change Order.
Also, if you'd like us to do the Retaining Wall at the Courtyard Ramp and Stairs we need plans in
order to give you a proposal.
Warm regards,
Cheryl Chavka
Office Manager & Assistant PM
Barracuda Builders of Key West, Inc
56o1 3rd Avenue
Key West, FL 33040
Ofc: (305).q96
Fax: (305) 30 -7832
www.bar racudabuilders.com
he 1 b lac da uildei .com