Loading...
Item C19BOARD OF COUNTY COMMISSIONERS C ounty of M onroe A(I Mayor George Neugent, District 2 T he Fl orida Keys 4� �� m Mayor Pro Tem David Rice, District 4 l Danny L. Kolhage, District 1 „ Y „; ° W Heather Carruthers, District 3 Sylvia J. Murphy, District 5 County Commission Meeting June 21, 2017 Agenda Item Number: C.19 Agenda Item Summary #3050 BULK ITEM: Yes DEPARTMENT: Engineering / Roads TIME APPROXIMATE: STAFF CONTACT: Judith Clarke (305) 295 -4329 N/A AGENDA ITEM WORDING: Approval of Amendment 1 to Agreement for Construction Engineering and Inspection (CEI) Services for the Card Sound Bridge Repair Project reflecting corporate name change from Parsons Brinckerhoff, Inc. to WSP USA Inc. ITEM BACKGROUND: Monroe County entered into an agreement with Parsons Brinckerhoff, Inc. to provide Construction Engineering and Inspection (CEI) Services for the Card Sound Bridge Repair Project on January 20, 2016. County was notified by Parson Brinckerhoff that their corporate name was changing to WSP USA Inc. effective May 1, 2017. PREVIOUS RELEVANT BOCC ACTION: BOCC approval contract with Parsons Brinckerhoff, Inc. to provide CEI Services for the Card Sound Bridge Repair Project on January 20, 2016. CONTRACT /AGREEMENT CHANGES: Corporate name change STAFF RECOMMENDATION: Approval of Amendment DOCUMENTATION: Amendment 41 signed _Contract - Parsons - EXEC - 1 -20 -16 Letter from WSP- Parsons regarding name change FINANCIAL IMPACT: Effective Date: June 21, 2017 Expiration Date: 30 days after construction completion Total Dollar Value of Contract: $336,742.31 Total Cost to County: $84,185.58 Current Year Portion: Budgeted: Yes Source of Funds: FDOT & Fund 125 CPI: Indirect Costs: Estimated Ongoing Costs Not Included in above dollar amounts: Revenue Producing: No Grant: $252,556.73 County Match: $84,185.58 Insurance Required: Additional Details: If yes, amount: REVIEWED BY: Judith Clarke Completed 05/31/2017 11:21 AM Christine Limbert Completed 06/01/2017 11:10 AM Budget and Finance Completed 06/01/2017 11:24 AM Maria Slavik Completed 06/01/2017 11:26 AM Kathy Peters Completed 06/06/2017 6:19 PM Board of County Commissioners Pending 06/21/2017 9:00 AM FOR THE CARD SOUND BRIDGE REPAIR PROJECT This Amendment is entered into this 21" day of June, 2017, by and between Monroe County, a political subdivision of the State of Florida, hereafter COUNTY, and WSP USA Inc. (formerly known as Parsons Brinckerhoff, Inc., hereafter CONSULTANT. WHEREAS, on January 20, 2016, the COUNTY and Parsons Brinckerhoff, Inc. entered into an Agreement for Construction Engineering and Inspection (CEI) Services for the Card Sound Bridge Repair Project; and WHEREAS, County was notified by Parsons Brinckerhoff, Inc. that it changed its corporate name to WSP USA Inc. effective May 1, 2017; and WHEREAS, this amendment is needed only to reflect the new corporate name and will otherwise have no impact on the Agreement and CONSULTANT will continue to perform all of its obligations under the Agreement; and WHEREAS, it is in the mutual best interests of the COUNTY and CONSULTANT to amend the Agreement to reflect this corporate name change; NOW THEREFORE, in consideration of the mutual promises of the original agreement as amended herein, the parties agree as follows: Effective May 1, 2017 Parsons Brinckerhoff, Inc. changed its corporate name to WSP USA Inc. (no other changes to the Federal Tax Identification Number (FEIN), corporate business address, bank accounts, wiring instructions, or company management, technical staff and financial personnel). 2. CONSULTANT will continue to perform all of its duties, responsibilities, and obligations under the Agreement. Where the corporate name Parsons Brinckerhoff, Inc. appears in the original Agreement as amended, the name shall be hereinafter amended to read WSP USA Inc. 4. The remaining provisions of the agreement dated January 20, 2016, not inconsistent herewith, remain in full force and effect. REMAINDER OF PAGE INTENTIONALLY LEFT BLANK Page 1 of 2 Date: ?=<»t» < 0 WWWW" \yam egoin nstru:17101 ty; now be» 7uc this 7 201, by day i.whois( )personally known lorneor( hroduced a driver's ficen as identificalion. 2T. Print, type «s! mp commissioned name notary MONROE COUNTY ATTORNEY AGREEMENT FOR CONSTRUCTION ENGINEERING AND INSPECTION (CEI) SERVICES FOR THE CARD SOUND BRIDGE REPAIR PROJECT This Agreement ( "Agreement ") made and entered into this 20th day of January, 2016 by and between Monroe County, a political subdivision of the State of Florida, whose address is 1100 Simonton Street, Key West, Florida, 33040, its successors and assigns, hereinafter referred to as "COUNTY," through the Monroe County Board of County Commissioners ( "BOCC "), AND Parsons Brinckerhoff, Inc., a Corporation of the State of New York, whose address is One Penn Plaza, New York NY 10119 its successors and assigns, hereinafter referred to as "CONSULTANT ", WITNESSETH: WHEREAS, COUNTY desires to employ the professional services of CONSULTANT construction engineering and inspection (CEI) services for the Card Sound Bridge Repair Project; and WHEREAS, CONSULTANT has agreed to provide professional services which shall include but not be limited to providing construction engineering and inspection (CEI) services for the Card Sound Bridge Repair Project, which services shall collectively be referred to as the "Project "; NOW, THEREFORE, in consideration of the mutual promises, covenants and agreements stated herein, and for other good and valuable consideration, the sufficiency of which is hereby acknowledged, COUNTY and CONSULTANT agree as follows: FORM OF AGREEMENT ARTICLE 1 1.1 REPRESENTATIONS AND WARRANTIES By executing this Agreement, CONSULTANT makes the following express representations and warranties to the COUNTY: 1.1.1 The CONSULTANT shall maintain all necessary licenses, permits or other authorizations necessary to act as CONSULTANT for the Project until the CONSULTANT'S duties hereunder have been fully satisfied; 1.1.2 The CONSULTANT has become familiar with the Project site and the local conditions under which the Work is to be completed. 1.1.3 The CONSULTANT shall prepare all documentation required by this Agreement in such a manner that they shall be accurate, coordinated and adequate for use in verifying work completed and shall be in conformity and comply with all applicable law, codes and regulations. The CONSULTANT warrants that the documents prepared as a part of this Agreement will be adequate and sufficient to document costs in a manner that is acceptable for reimbursement by government agencies, therefore eliminating any additional cost due to missing or incorrect information; 1.1.4 The CONSULTANT assumes full responsibility to the extent allowed by law with regards to his performance and those directly under his employ. 1.1.5 The CONSULTANT'S services shall be performed as expeditiously as is consistent with professional skill and care and the orderly progress of the Project. In providing all services pursuant to this agreement, the CONSULTANT shall abide by all statutes, ordinances, rules and regulations pertaining to, or regulating the provisions of such services, including those now in effect and hereinafter adopted. Any violation of said statutes, ordinances, rules and regulations shall constitute a material breach of this agreement and shall entitle the Board to terminate this contract immediately upon delivery of written notice of termination to the CONSULTANT. 1.1.6 At all times and for all purposes under this agreement the CONSULTANT is an independent contractor and not an employee of the Board of County Commissioners for Monroe County. No statement contained in this agreement shall be construed so as to find the CONSULTANT or any of his /her employees, contractors, servants, or agents to be employees of the Board of County Commissioners for Monroe County. 1.1.7 The CONSULTANT shall not discriminate against any person on the basis of race, creed, color, national origin, sex, age, or any other characteristic or aspect which is not job related, in its recruiting, hiring, promoting, terminating, or any other area affecting employment under this agreement or with the provision of services or goods under this agreement. 1.1.8 The CONSULTANT shall complete the scope of services no later than 30 days after Final Completion of the Card Sound Road Bridge Repair Project by the contractor. ARTICLE II SCOPE OF BASIC SERVICES 2.1 DEFINITION CONSULTANT'S Scope of Basic Services consist of those described in Attachment A. The CONSULTANT shall commence work on the services provided for in this Agreement promptly upon his receipt of a written notice to proceed from the COUNTY. 2.2 CORRECTION OF ERRORS, OMISSIONS, DEFICIENCIES The CONSULTANT shall, without additional compensation, promptly correct any errors, omissions, deficiencies, or conflicts in the work product of the CONSULTANT or its subconsultants, or both. 2.3 NOTICE REQUIREMENT All written correspondence to the COUNTY shall be dated and signed by an authorized representative of the CONSULTANT. Any notice required or permitted under this agreement shall be in writing and hand delivered or mailed, postage pre -paid, to the COUNTY by certified mail, return receipt requested, to the following: Ms. Judith Clarke, P.E. Director of Engineering Services Monroe County 1100 Simonton Street, Room 2 -216 Key West, Florida 33040 And: Mr. Roman Gastesi, Jr. Monroe County Administrator 1100 Simonton Street, Room 2 -205 Key West, Florida 33040 For the Consultant: Parsons Brinckerhoff, Inc. Kenneth B. Spillett, P.E. Southeast/MidAtlantic CS R egional Manager 2202 North West Shore Boulevard, Suite 300 Tampa, Florida 33607 ARTICLE III ADDITIONAL SERVICES 3.1 Additional services are services not included in the Scope of Basic Services. Should the COUNTY require additional services they shall be paid for by the COUNTY at rates or fees negotiated at the time when services are required, but only if approved by the COUNTY before commencement. 3.2 If Additional Services are required the COUNTY shall issue a letter requesting and describing the requested services to the CONSULTANT. The CONSULTANT shall respond with a fee proposal to perform the requested services. Only after receiving an amendment to the Agreement and a notice to proceed from the COUNTY, shall the CONSULTANT proceed with the Additional Services. ARTICLE IV COUNTY'S RESPONSIBILITIES 4.1 The COUNTY shall provide full information regarding requirements for the Project including physical location of work, county maintained roads, maps. 4.2 The COUNTY shall designate a representative to act on the COUNTY's behalf with respect to the Project. The COUNTY or its representative shall render decisions in a timely manner pertaining to documents submitted by the CONSULTANT in order to avoid unreasonable delay in the orderly and sequential progress of the CONSULTANT'S services. 4.3 Prompt written notice shall be given by the COUNTY and its representative to the CONSULTANT if they become aware of any fault or defect in the Project or non- conformance with the Agreement Documents. Written notice shall be deemed to have been duly served if sent pursuant to paragraph 2.3. 4.4 The COUNTY shall furnish the required information and services and shall render approvals and decisions as expeditiously as necessary for the orderly progress of the CONSULTANT'S services and work of the contractors. 4.5 The COUNTY's review of any documents prepared by the CONSULTANT or its subconsultants shall be solely for the purpose of determining whether such documents are generally consistent with the COUNTY' criteria, as, and if, modified. No review of such documents shall relieve the CONSULTANT of responsibility for the accuracy, adequacy, fitness, suitability or coordination of its work product. 4.6 The COUNTY shall provide copies of necessary documents required to complete the work. 4.7 Any information that may be of assistance to the CONSULTANT that the COUNTY has immediate access to will be provided as requested. ARTICLE V INDEMNIFICATION AND HOLD HARMLESS 5.1 The CONSULTANT covenants and agrees to indemnify and hold harmless COUNTY /Monroe County and Monroe County Board of County Commissioners, its officers and employees from liabilities, damages, losses and costs, including but not limited to, reasonable attorneys' fees, to the extent caused by the negligence, recklessness, or intentional wrongful conduct of the CONSULTANT, subcontractor(s) and other persons employed or utilized by the CONSULTANT in the performance of the contract. 5.2 The first ten dollars ($10.00) of remuneration paid to the CONSULTANT is for the indemnification provided for above. The extent of liability is in no way limited to, reduced, or lessened by the insurance requirements contained elsewhere within this agreement. Should any claims be asserted against the COUNTY by virtue of any deficiency or ambiguity in the plans and specifications provided by the CONSULTANT, the CONSULTANT agrees and warrants that he shall hold the COUNTY harmless and shall indemnify him from all losses occurring thereby and shall further defend any claim or action on the COUNTY'S behalf. 5.3 In the event the completion of the project (to include the work of others) is delayed or suspended as a result of the CONSULTANT'S failure to purchase or maintain the required insurance, the CONSULTANT shall indemnify COUNTY from any and all increased expenses resulting from such delays. Should any claims be asserted against COUNTY by virtue of any deficiencies or ambiguity in the plans and specifications provide by the CONSULTANT the CONSULTANT agrees and warrants that CONSULTANT hold the COUNTY harmless and shall indemnify it from all losses occurring thereby and shall further defend any claims or action on the COUNTY'S behalf. 5.4 The extent of liability is in no way limited to, reduced or lessened by the insurance requirements contained elsewhere within the Agreement. 5.5 This indemnification shall survive the expiration or early termination of the Agreement. 5.6 To the fullest extent permitted by law, the Consultant shall indemnify and hold harmless the State of Florida Department of Transportation, and its officers and employees from liabilities, damages, losses, and costs, including but not limited to, reasonable attorney fees to the extent caused, in whole or in part, by the professional negligence, error or omission, recklessness, or intentional wrongful conduct of the Consultant or persons employed or utilized by the Consultant in the performance of this Agreement. This indemnification shall survive the termination of the agreement. Nothing contained in this paragraph is intended to nor shall it constitute a waiver of the State of Florida and the County's sovereign immunity. ARTICLE VI PERSONNEL 6.1 PERSONNEL The CONSULTANT shall assign only qualified personnel to perform any service concerning the project. At the time of execution of this Agreement, the parties anticipate that the following named individuals will perform those functions as indicated: FUNCTION Senior Project Engineer Senior Inspector Inspector So long as the individuals named above remain actively employed or retained by the CONSULTANT, they shall perform the functions indicated next to their names. If they are replaced the CONSULTANT shall notify the COUNTY of the change immediately. ARTICLE VII COMPENSATION 7.1 PAYMENT SUM 7.1.1 The COUNTY shall pay the CONSULTANT monthly in current funds for the CONSULTANT'S performance of this Agreement based on the hourly rates outline in Attachment B. The Total Not to Exceed Amount of Three Hundred Thirty Six Thousand Seven Hundred Forty Two Dollars and Thirty One Cents ($336,742.31) will apply to this Agreement. 7.2 PAYMENTS 7.2.1 For its assumption and performances of the duties, obligations and responsibilities set forth herein, the CONSULTANT shall be paid monthly. Payment will be made pursuant to the Local Government Prompt Payment Act 218.70, Florida Statutes. (A) If the CONSULTANT'S duties, obligations and responsibilities are materially changed by amendment to this Agreement after execution of this Agreement, compensation due to the CONSULTANT shall be equitably adjusted, either upward or downward; (B) As a condition precedent for any payment due under this Agreement, the CONSULTANT shall submit monthly, unless otherwise agreed in writing by the COUNTY, a proper invoice to COUNTY requesting payment for services properly rendered and reimbursable expenses due hereunder. The CONSULTANT'S invoice shall describe with reasonable particularity the service rendered. The CONSULTANT'S invoice shall be accompanied by such documentation or data in support of expenses for which payment is sought at the COUNTY may require. 7.3 REIMBURSABLE EXPENSES 7.3.1 Reimbursable expenses include expenses incurred by the CONSULTANT in the interest of the project: a. Expenses of transportation submitted by CONSULTANT, in writing, and living expenses in connection with travel authorized by the COUNTY, in writing, but only to the extent and in the amounts authorized by Section 112.061, Florida Statutes; b. Cost of reproducing maps or drawings or other materials used in performing the scope of services; c. Postage and handling of reports; 7.4 BUDGET 7.4.1 The CONSULTANT may not be entitled to receive, and the COUNTY is not obligated to pay, any fees or expenses in excess of the amount budgeted for this contract in each fiscal year (October 1 - September 30) by COUNTY's Board of County Commissioners. The budgeted amount may only be modified by an affirmative act of the COUNTY's Board of County Commissioners. 7.4.2 The COUNTY's performance and obligation to pay under this Agreement is contingent upon an annual appropriation by the Board of County Commissioners and the approval of the Board members at the time of contract initiation and its duration. ARTICLE VIII INSURANCE 8.1 The CONSULTANT shall obtain insurance as specified and maintain the required insurance at all times that this Agreement is in effect. In the event the completion of the project (to include the work of others) is delayed or suspended as a result of the CONSULTANT'S failure to purchase or maintain the required insurance, the CONSULTANT shall indemnify the COUNTY from any and all increased expenses resulting from such delay. 8.2 The coverage provided herein shall be provided by an insurer with an A.M. Best rating of VI or better, that is licensed to business in the State of Florida and that has an agent for service of process within the State of Florida. The coverage shall contain an endorsement providing sixty (60) days notice to the COUNTY prior to any cancellation of said coverage. Said coverage shall be written by an insurer acceptable to the COUNTY and shall be in a form acceptable to the COUNTY. 8.3 CONSULTANT shall obtain and maintain the following policies: A. Workers' Compensation insurance as required by the State of Florida, sufficient to respond to Florida Statute 440. B. Employers Liability Insurance with limits of $500,000 per Accident, $500,000 Disease, policy limits, $500,000 Disease each employee. C. Comprehensive business automobile and vehicle liability insurance covering claims for injuries to members of the public and /or damages to property of others arising from use of motor vehicles, including onsite and offsite operations, and owned, hired or non -owned vehicles, with $200,000 per person, $300,000 per Occurrence, $200,000 Property Damage or $300,000 combined single limit. D. Commercial general liability, including Personal Injury Liability, covering claims for injuries to members of the public or damage to property of others arising out of any covered act or omission of the CONSULTANT or any of its employees, agents or subcontractors or subconsultants, including Premises and /or Operations, Products and Completed Operations, Independent Contractors; Broad Form Property Damage and a Blanket Contractual Liability Endorsement with $300,000 per Person, $500,000 per Occurrence, $200,000 Property Damage or $500,000 Combined Single Limit. An Occurrence Form policy is preferred. If coverage is changed to or provided on a Claims Made policy, its provisions should include coverage for claims filed on or after the effective date of this contract. In addition, the period for which claims may be reported must extend for a minimum of 48 months following the termination or expiration of this contract. E. Professional liability insurance of $500,000 per occurrence and $1,000,000 annual aggregate. If the policy is a "claims made" policy, CONSULTANT shall maintain coverage or purchase a "tail" to cover claims made after completion of the project to cover the statutory time limits in Chapter 95 of the Florida Statutes. F. COUNTY shall be named as an additional insured with respect to CONSULTANT'S liabilities hereunder in insurance coverages identified in Paragraphs C and D. 9.1 9.2 9.3 G. CONSULTANT shall require its subconsultants to be adequately insured at least to the limits prescribed above, and to any increased limits of CONSULTANT if so required by COUNTY during the term of this Agreement. COUNTY will not pay for increased limits of insurance for subconsultants. H. CONSULTANT shall provide to the COUNTY certificates of insurance or a copy of all insurance policies including those naming the COUNTY as an additional insured. The COUNTY reserves the right to require a certified copy of such policies upon request. If the CONSULTANT participates in a self- insurance fund, a Certificate of Insurance will be required. In addition, the CONSULTANT may be required to submit updated financial statements from the fund upon request from the COUNTY. ARTICLE IX MISCELLANEOUS SECTION HEADINGS Section headings have been inserted in this Agreement as a matter of convenience of reference only, and it is agreed that such section headings are not a part of this Agreement and will not be used in the interpretation of any provision of this Agreement. OWNERSHIP OF THE PROJECT DOCUMENTS The documents prepared by the CONSULTANT for this Project belong to the COUNTY and may be reproduced and copied without acknowledgement or permission of the CONSULTANT. SUCCESSORS AND ASSIGNS The CONSULTANT shall not assign or subcontract its obligations under this agreement, except in writing and with the prior written approval of the Board of County Commissioners for Monroe County and the CONSULTANT, which approval shall be subject to such conditions and provisions as the Board may deem necessary. This paragraph shall be incorporated by reference into any assignment or subcontract and any assignee or subcontractor shall comply with all of the provisions of this agreement. Subject to the provisions of the immediately preceding sentence, each party hereto binds itself, its successors, assigns and legal representatives to the other and to the successors, assigns and legal representatives of such other party. 9.4 NO THIRD PARTY BENEFICIARIES Nothing contained herein shall create any relationship, contractual or otherwise, with or any rights in favor of, any third party. 9.5 9.6 9.7 TERMINATION A. In the event that the CONSULTANT shall be found to be negligent in any aspect of service, the COUNTY shall have the right to terminate this agreement after five days written notification to the CONSULTANT. B. Either of the parties hereto may cancel this Agreement without cause by giving the other party sixty (60) days written notice of its intention to do so. CONTRACT DOCUMENTS This contract consists of the Request for Proposals, any addenda, the Form of Agreement (Articles I -IX), the CONSULTANT'S response to the RFP, the documents referred to in the Form of Agreement as a part of this Agreement, including attachments A and B, and modifications made after execution by written amendment. In the event of any conflict between any of the Contract documents, the one imposing the greater burden on the CONSULTANT will control. PUBLIC ENTITIES CRIMES A person or affiliate who has been placed on the convicted vendor list following a conviction for public entity crime may not submit a bid on contracts to provide any goods or services to a public entity, may not submit a bid on a contract with a public entity for the construction or repair of a public building or public work, may not submit bids on leases of real property to public entity, may not be awarded or perform work as a contractor, supplier, subcontractor, or consultant under a contract with any public entity, and may not transact business with any public entity in excess of the threshold amount provided in Section 287.017 of the Florida Statutes, for CATEGORY TWO for a period of 36 months from the date of being placed on the convicted vendor list. By signing this Agreement, CONSULTANT represents that the execution of this Agreement will not violate the Public Entity Crimes Act (Section 287.133, Florida Statutes). Violation of this section shall result in termination of this Agreement and recovery of all monies paid hereto, and may result in debarment from COUNTY's competitive procurement activities. In addition to the foregoing, CONSULTANT further represents that there has been no determination, based on an audit, that it or any subconsultant has committed an act defined by Section 287.133, Florida Statutes, as a "public entity crime" and that it has not been formally charged with committing an act defined as a "public entity crime" regardless of the amount of money involved or whether CONUSULTANT has been placed on the convicted vendor list. CONSULTANT will promptly notify the COUNTY if it or any subcontractor or subconsultant is formally charged with an act defined as a "public entity crime" or has been placed on the convicted vendor list. 9.8 MAINTENANCE OF RECORDS CONSULTANT shall maintain all books, records, and documents directly pertinent to performance under this Agreement in accordance with generally accepted accounting principles consistently applied. Records shall be retained for a period of five years from the termination of this agreement. Each party to this Agreement or its authorized representatives shall have reasonable and timely access to such records of each other party to this Agreement for public records purposes during the term of the Agreement and for four years following the termination of this Agreement. If an auditor employed by the COUNTY or Clerk determines that monies paid to CONSULTANT pursuant to this Agreement were spent for purposes not authorized by this Agreement, or were wrongfully retained by the CONSULTANT, the CONSULTANT shall repay the monies together with interest calculated pursuant to Sec. 55.03, of the Florida Statutes, running from the date the monies were paid by the COUNTY. 9.9 GOVERNING LAW, VENUE, INTERPRETATION, COSTS, AND FEES This Agreement shall be governed by and construed in accordance with the laws of the State of Florida applicable to contracts made and to be performed entirely in the State. In the event that any cause of action or administrative proceeding is instituted for the enforcement or interpretation of this Agreement, COUNTY and CONSULTANT agree that venue shall lie in the 16 Judicial Circuit, Monroe County, Florida, in the appropriate court or before the appropriate administrative body. This agreement shall not be subject to arbitration. Mediation proceedings initiated and conducted pursuant to this Agreement shall be in accordance with the Florida Rules of Civil Procedure and usual and customary procedures required by the circuit court of Monroe County. 9.10 SEVERABILITY If any term, covenant, condition or provision of this Agreement (or the application thereof to any circumstance or person) shall be declared invalid or unenforceable to any extent by a court of competent jurisdiction, the remaining terms, covenants, conditions and provisions of this Agreement, shall not be affected thereby; and each remaining term, covenant, condition and provision of this Agreement shall be valid and shall be enforceable to the fullest extent permitted by law unless the enforcement of the remaining terms, covenants, conditions and provisions of this Agreement would prevent the accomplishment of the original intent of this Agreement. The COUNTY and CONSULTANT agree to reform the Agreement to replace any stricken provision with a valid provision that comes as close as possible to the intent of the stricken provision. 9.11 ATTORNEY'S FEES AND COSTS The COUNTY and CONSULTANT agree that in the event any cause of action or administrative proceeding is initiated or defended by any party relative to the enforcement or interpretation of this Agreement, the prevailing party shall be entitled to reasonable attorney's fees, court costs, investigative, and out -of- pocket expenses, as an award against the non - prevailing party, and shall include attorney's fees, courts costs, investigative, and out -of- pocket expenses in appellate proceedings. 9.12 BINDING EFFECT The terms, covenants, conditions, and provisions of this Agreement shall bind and inure to the benefit of the COUNTY and CONSULTANT and their respective legal representatives, successors, and assigns. 9.13 AUTHORITY Each party represents and warrants to the other that the execution, delivery and performance of this Agreement have been duly authorized by all necessary County and corporate action, as required by law. 9.14 CLAIMS FOR FEDERAL OR STATE AID CONSULTANT and COUNTY agree that each shall be, and is, empowered to apply for, seek, and obtain federal and state funds to further the purpose of this Agreement; provided that all applications, requests, grant proposals, and funding solicitations shall be approved by each party prior to submission. 9.15 ADJUDICATION OF DISPUTES OR DISAGREEMENTS COUNTY and CONSULTANT agree that all disputes and disagreements shall be attempted to be resolved by meet and confer sessions between representatives of each of the parties. If no resolution can be agreed upon within 30 days after the first meet and confer session, the issue or issues shall be discussed at a public meeting of the Board of County Commissioners. If the issue or issues are still not resolved to the satisfaction of the parties, then any party shall have the right to seek such relief or remedy as may be provided by this Agreement or by Florida law. This provision does not negate or waive the provisions of paragraph 9.5 concerning termination or cancellation. 9.16 COOPERATION In the event any administrative or legal proceeding is instituted against either party relating to the formation, execution, performance, or breach of this Agreement, COUNTY and CONSULTANT agree to participate, to the extent required by the other party, in all proceedings, hearings, processes, meetings, and other activities related to the substance of this Agreement or provision of the services under this Agreement. COUNTY and CONSULTANT specifically agree that no party to this Agreement shall be required to enter into any arbitration proceedings related to this Agreement. 9.17 NONDISCRIMINATION CONSULTANT and COUNTY agree that there will be no discrimination against any person, and it is expressly understood that upon a determination by a court of competent jurisdiction that discrimination has occurred, this Agreement automatically terminates without any further action on the part of any party, effective the date of the court order. CONSULTANT or COUNTY agrees to comply with all Federal and Florida statutes, and all local ordinances, as applicable, relating to nondiscrimination. These include but are not limited to: 1) Title VI of the Civil Rights Act of 1964 (PL 88 -352) which prohibits discrimination on the basis of race, color or national origin; 2) Title IX of the Education Amendment of 1972, as amended (20 USC ss. 1681 -1683, and 1685 - 1686), which prohibits discrimination on the basis of sex; 3) Section 504 of the Rehabilitation Act of 1973, as amended (20 USC s. 794), which prohibits discrimination on the basis of handicaps; 4) The Age Discrimination Act of 1975, as amended (42 USC ss. 6101 -6107) which prohibits discrimination on the basis of age; 5) The Drug Abuse Office and Treatment Act of 1972 (PL 92 -255), as amended, relating to nondiscrimination on the basis of drug abuse; 6) The Comprehensive Alcohol Abuse and Alcoholism Prevention, Treatment and Rehabilitation Act of 1970 (PL 91 -616), as amended, relating to nondiscrimination on the basis of alcohol abuse or alcoholism; 7) The Public Health Service Act of 1912, ss. 523 and 527 (42 USC ss. 690dd -3 and 290ee -3), as amended, relating to confidentiality of alcohol and drug abuse patient records; 8) Title VIII of the Civil Rights Act of 1968 (42 USC s. et seq.), as amended, relating to nondiscrimination in the sale, rental or financing of housing; 9) The Americans with Disabilities Act of 1990 (42 USC s. 1201 Note), as may be amended from time to time, relating to nondiscrimination on the basis of disability; 10) Monroe County Code Chapter 13, Article VI, which prohibits discrimination on the basis of race, color, sex, religion, national origin, ancestry, sexual orientation, gender identity or expression, familial status or age; 11) Any other nondiscrimination provisions in any Federal or state statutes which may apply to the parties to, or the subject matter of, this Agreement. 9.18 COVENANT OF NO INTEREST CONSULTANT and COUNTY covenant that neither presently has any interest, and shall not acquire any interest, which would conflict in any manner or degree with its performance under this Agreement, and that only interest of each is to perform and receive benefits as recited in this Agreement. 9.19 CODE OF ETHICS COUNTY agrees that officers and employees of the COUNTY recognize and will be required to comply with the standards of conduct for public officers and employees as delineated in Section 112.313, Florida Statutes, regarding, but not limited to, solicitation or acceptance of gifts; doing business with one's agency; unauthorized compensation; misuse of public position, conflicting employment or contractual relationship; and disclosure or use of certain information. 9.20 NO SOLICITATION /PAYMENT The CONSULTANT and COUNTY warrant that, in respect to itself, it has neither employed nor retained any company or person, other than a bona fide employee working solely for it, to solicit or secure this Agreement and that it has not paid or agreed to pay any person, company, corporation, individual, or firm, other than a bona fide employee working solely for it, any fee, commission, percentage, gift, or other consideration contingent upon or resulting from the award or making of this Agreement. For the breach or violation of the provision, the CONSULTANT agrees that the COUNTY shall have the right to terminate this Agreement without liability and, at its discretion, to offset from monies owed, or otherwise recover, the full amount of such fee, commission, percentage, gift, or consideration. 9.21 PUBLIC ACCESS. The CONSULTANT and COUNTY shall allow and permit reasonable access to, and inspection of, all documents, papers, letters or other materials in its possession or under its control subject to the provisions of Chapter 119, Florida Statutes, and made or received by the CONSULTANT and COUNTY in connection with this Agreement; and the COUNTY shall have the right to unilaterally cancel this Agreement upon violation of this provision by CONSULTANT. Pursuant to F.S. 119.0701, Contractor and its subcontractors shall comply with all public records laws of the State of Florida, including but not limited to: (a) Keep and maintain public records that ordinarily and necessarily would be required by Monroe County in order to perform the service. (b) Provide the public with access to public records on the terms and conditions that Monroe County would provide the records and at a cost that does not exceed the cost provided in Florida Statutes, Chapter 119 or as otherwise provided by law. (c) Ensure that public records that are exempt or confidential and exempt from public records disclosure requirements are not disclosed except as authorized by law. (d) Meet all requirements for retaining public records and transfer, at no cost, to Monroe County all public records in possession of the contractor upon termination of the contract and destroy any duplicate public records that are exempt or confidential and exempt from public records disclosure requirements. All records stored electronically must be provided to Monroe County in a format that is compatible with the information technology systems of Monroe County. 9.22 NON - WAIVER OF IMMUNITY Notwithstanding the provisions of Sec. 768.28, Florida Statutes, the participation of the CONSULTANT and the COUNTY in this Agreement and the acquisition of any commercial liability insurance coverage, self- insurance coverage, or local government liability insurance pool coverage shall not be deemed a waiver of immunity to the extent of liability coverage, nor shall any contract entered into by the COUNTY be required to contain any provision for waiver. 9.23 PRIVILEGES AND IMMUNITIES All of the privileges and immunities from liability, exemptions from laws, ordinances, and rules and pensions and relief, disability, workers' compensation, and other benefits which apply to the activity of officers, agents, or employees of any public agents or employees of the COUNTY, when performing their respective functions under this Agreement within the territorial limits of the COUNTY shall apply to the same degree and extent to the performance of such functions and duties of such officers, agents, volunteers, or employees outside the territorial limits of the COUNTY. 9.24 LEGAL OBLIGATIONS AND RESPONSIBILITIES Non - Delegation of Constitutional or Statutory Duties. This Agreement is not intended to, nor shall it be construed as, relieving any participating entity from any obligation or responsibility imposed upon the entity by law except to the extent of actual and timely performance thereof by any participating entity, in which case the performance may be offered in satisfaction of the obligation or responsibility. Further, this Agreement is not intended to, nor shall it be construed as, authorizing the delegation of the constitutional or statutory duties of the COUNTY, except to the extent permitted by the Florida constitution, state statute, and case law. 9.25 NON - RELIANCE BY NON - PARTIES No person or entity shall be entitled to rely upon the terms, or any of them, of this Agreement to enforce or attempt to enforce any third -party claim or entitlement to or benefit of any service or program contemplated hereunder, and the CONSULTANT and the COUNTY agree that neither the CONSULTANT nor the COUNTY or any agent, officer, or employee of either shall have the authority to inform, counsel, or otherwise indicate that any particular individual or group of individuals, entity or entities, have entitlements or benefits under this Agreement separate and apart, inferior to, or superior to the community in general or for the purposes contemplated in this Agreement. 9.26 ATTESTATIONS AND TRUTH IN NEGOTIATION CONSULTANT agrees to execute such documents as COUNTY may reasonably require, including a Public Entity Crime Statement, an Ethics Statement, and a Drug - Free Workplace Statement. Signature of this Agreement by CONSULTANT shall act as the execution of a truth in negotiation certificate stating that wage rates and other factual unit costs supporting the compensation pursuant to the Agreement are accurate, complete, and current at the time of contracting. The original contract price and any additions thereto shall be adjusted to exclude any significant sums by which the agency determines the contract price was increased due to inaccurate, incomplete, or concurrent wage rates and other factual unit costs. All such adjustments must be made within one year following the end of the Agreement. 9.27 NO PERSONAL LIABILITY No covenant or agreement contained herein shall be deemed to be a covenant or agreement of any member, officer, agent or employee of Monroe County in his or her individual capacity, and no member, officer, agent or employee of Monroe County shall be liable personally on this Agreement or be subject to any personal liability or accountability by reason of the execution of this Agreement. 9.28 EXECUTION IN COUNTERPARTS This Agreement may be executed in any number of counterparts, each of which shall be regarded as an original, all of which taken together shall constitute one and the same instrument and any of the parties hereto may execute this Agreement by signing any such counterpart. 9.29 Disadvantaged Business Enterprise (DBE) Policy and Obligation - It is the policy of the COUNTY that DBE's, as defined in 49 C.F.R. Part 26, as amended, shall have the opportunity to participate in the performance of contracts financed in whole or in part with COUNTY funds under this Agreement. The DBE requirements of applicable federal and state laws and regulations apply to this Agreement. The COUNTY and its CONSULTANT agree to ensure that DBE's have the opportunity to participate in the performance of this Agreement. In this regard, all recipients and contractors shall take all necessary and reasonable steps in accordance with applicable federal and state laws and regulations to ensure that the DBE's have the opportunity to compete for and perform contracts. The COUNTY and the CONSULTANT and subcontractors shall not discriminate on the basis of race, color, national origin or sex in the award and performance of contracts, entered pursuant to this Agreement. IN WITNESS WHEREOF, each party has caused this Agreement to be executed by its duly authorized representative on the day and year first above written. PARSONS i* RINC ERHOF , INC. BY: G. Dewey Martin III, P.E. Title Construction Serices Least Group Ma nager I7; fb— o my t was acknowledged before me this day of 2916, by I 0 ,, & Who is (X) personally known to me or ) produced a driver's license as idea " ication. NOTARY PUBLIC, STATE OF FLOI�,IDA ATTACHMENT A SCOPE OF SERVICES 1.0 2.0 The Consultant shall provide Construction Engineering and Inspection Services for the Card Sound Bridge Repair project. Pursuant to Section 4.1.4 of the FDOT's Construction Project Administration Manual (CPAM), the authority of the Consultant's lead person, such as the Senior Project Engineer, and the Consultant's Project Administrator shall be identical to the Department's Resident Engineer and Project Administrator respectively and shall be interpreted as such. Services provided by the Consultant shall comply with FDOT manuals, procedures, and memorandums in effect as of the date of execution of the Task Order unless otherwise directed in writing by the County. On a single Construction Contract, it is a conflict of interest for a professional firm to receive compensation from both the County and the Contractor either directly or indirectly. The Consultant shall utilize the U.S. Department of Homeland Security's E- Verify system to verify the employment eligibility of all new employees hired by the Consultant during the term of the Contract and shall expressly require any subconsultants performing work or providing services pursuant to the Contract to likewise utilize the U.S. Department of Homeland Security's E- Verify system to verify the employment eligibility of all new employees hired by the subconsultant during the Contract term. LENGTH OF SERVICE The Consultant services for the Construction Contract shall begin upon written notification to proceed by County. The Consultant Senior Project Engineer will track the execution of the Construction Contract such that the Consultant is given timely authorization to begin work. While no personnel shall be assigned until written notification by the County has been issued, the Consultant shall be ready to assign personnel within two weeks of notification. For the duration of the project, the Consultant shall coordinate closely with the County and Contractor to minimize rescheduling of Consultant activities due to construction delays or changes in scheduling of Contractor activities. For estimating purposes, the Consultant will be allowed an accumulation of thirty (30) working days to perform preliminary administrative services prior to the issuance of the Contractor's notice to proceed and thirty (30) calendar days to demobilize after final acceptance of the Construction Contract. 3.0 DEFINITIONS A. Resident Engineer The Engineer assigned to a particular Project or area to administer Construction Contracts for the County. B. Construction Project Manager The County employee assigned to manage the Construction Engineering and Inspection Contract and represent the County during the performance of the services covered under this Agreement. C. Engineer of Record The Engineer noted on the Construction plans as the responsible person for the design and preparation of the plans. D. Consultant The Consulting firm under contract to the County for administration of Construction Engineering and Inspection services. E. Agreement The Professional Services Agreement between the County and the Consultant setting forth the obligations of the parties thereto, including but not limited to the performance of the work, furnishing of services, and the basis of payment. F. Consultant Senior Project Engineer The Engineer assigned by the Consultant to be in charge of providing Construction Contract administration for one or more Construction Projects. This person may supervise other Consultant employees and act as the lead Engineer for the Consultant. G. Consultant Project Administrator The employee assigned by the Consultant to be in charge of providing Construction Contract administration services one or more Construction Projects. H. Contractor The individual, firm, or company contracting with the County for performance of work or furnishing of materials. I. Construction Contract The written agreement between the County and the Contractor setting forth the obligations of the parties thereto, including but not limited to the performance of the work, furnishing of labor and materials, and the basis of payment. J. CPAM Florida Department of Transportation, Construction Project Administration manual; latest. K. Department Florida Department of Transportation L. F.D.O.T. Florida Department of Transportation. M. County Monroe County Board of County Commissioners. 4.0 REQUIREMENTS 4.1 General It shall be the responsibility of the Consultant to administer, monitor, and inspect the Construction Contract such that the project is constructed in reasonable conformity with the plans, specifications, and special provisions for the Construction Contract. The Consultant shall observe the Contractor's work to determine the progress and quality of work, identify discrepancies, report significant discrepancies to the County, and direct the Contractor to correct such observed discrepancies. The Consultant is hereby designated by the County to negotiate Supplemental Agreements. However, the Consultant must seek input from the Construction Project Manager. The Consultant shall prepare the Supplemental Agreement as a recommendation to the County, which the County may accept, modify or reject upon review. The Consultant shall consult with the Construction Project Manager, as it deems necessary and shall direct all issues, which exceed its delegated authority to the Construction Project Manager for County action or direction. 4.2 4.3 The Consultant shall advise the Construction Project Manager of any significant omissions, substitutions, defects, and deficiencies noted in the work of the Contractor and the corrective action that has been directed to be performed by the Contractor. Work provided by the Consultant shall not relieve the Contractor of responsibility for the satisfactory performance of the Construction Contract. Survey Control The Consultant shall check or establish the survey control baseline(s) along with sufficient baseline control points and bench marks at appropriate intervals along the project in order to: (1) make and record such measurements as are necessary to calculate and document quantities for pay items; (2) make and record pre- construction and final cross section surveys of the project site in those areas where earthwork (i.e., embankment, excavation, subsoil excavation, etc.) is part of the construction project; and (3) perform incidental engineering surveys. The Senior Project Engineer will establish the specific survey requirements for each project prior to construction. Any questions or requests for "Waiver of Survey" should be directed to the Senior Project Engineer. On -site Inspection The Consultant shall monitor the Contractor's on -site construction activities and inspect materials entering into the work in accordance with the plans, specifications, and special provisions for the Construction Contract to determine that the projects are constructed in reasonable conformity with such documents. The County will monitor all off -site activities and fabrication. The Consultant shall keep detailed accurate records of the Contractor's daily operations and of significant events that affect the work. Consultant shall be responsible for monitoring and inspection of Contractor's Work Zone traffic control plan and review of modifications to the Work Zone Traffic Control Plan, including alternate Work Zone Traffic Control Plan, in accordance with F.D.O.T. procedures. Consultant employees performing such services shall be qualified in accordance with F.D.O.T. department procedure. 4.4 Sampling and Testing The Consultant shall perform sampling and testing of component materials and completed work in accordance with the Construction Contract documents.The minimum sampling frequencies set out in the Department's Materials Sampling, Testing and Reporting Guide shall be met. In complying with the aforementioned guide, the Consultant shall provide daily surveillance of the Contractor's Quality Control activities at the project site and perform the sampling and testing of materials and completed work items that are normally done in the vicinity of the project for verification and acceptance. The Consultant shall be specifically responsible for job control samples determining the acceptability of all materials and completed work items on the basis of either test results or verification of a certification, certified mill analysis, DOT label, DOT stamp, etc. Sampling, testing and laboratory methods shall be as required by the Department's Standard Specifications, Supplemental Specifications or as modified by the special provisions of the Construction Contract. Documentation reports on sampling and testing shall be submitted to responsible parties during the same week that the construction work is done. If required, the Consultant will transport samples to be tested in a Department laboratory to the appropriate laboratory or appropriate local FDOT facility. The Consultant will review and approve contractor samples in FDOT's LIMS system. The Consultant will input verification testing information and data into the Department's LIMS system database using written instructions provided by the Department. 4.5 Enaineerina Services: The Consultant shall coordinate the Construction Contract administration activities of all parties other than the Contractor involved in completing the construction project. Notwithstanding the above, the Consultant is not liable to the County for failure of such parties to follow written direction issued by the Consultant. Services include maintaining the required level of surveillance of Contractor activities, interpreting plans, specifications, and special provisions for the Construction Contract, maintaining complete, accurate records of all activities and events relating to the project, and properly documenting all significant project changes. (1) Schedule and attend, within ten (10) days after the Notice to Proceed, a pre- construction conference for the project. The Consultant shall provide appropriate staff to attend and participate in the pre- construction meeting. (2) The Consultant shall record a complete and concise record of the proceedings of the pre- construction meeting and distribute copies of this summary to the participants and other interested parties within seven days. (3) Analyze the Contractor's schedule(s) (i.e. baseline(s), revised baseline(s), updates, as- built, etc.) for compliance with the contract documents. Elements including, but not limited to, completeness, logic, durations, activity, flow, milestone dates, concurrency, resource allotment, and delays will be reviewed. Verify the schedule conforms with the construction phasing and MOT sequences, including all contract modifications. Provide a written review of the schedule identifying significant omissions, improbable or unreasonable activity durations, errors in logic, and any other concerns as detailed in CPAM. (4) Verify that the Contractor is conducting inspections, preparing reports and monitoring all storm water pollution prevention measures associated with the project. (5) Analyze problems that arise on a project and proposals submitted by the Contractor, endeavor to resolve such issues, and process the necessary paperwork. (6) Produce reports, verify quantity calculations, field measure for payment purposes as needed to prevent delays in Contractor operations and ensure prompt processing of such information in order for the County to make timely payment to the Contractor. (7) Provide Public Information services as required to manage inquiries from the public, public officials, and the news media. Prepare newsletters for distribution to adjacent property owners. The County Construction Project Manager shall approve all notices, brochures, responses to news media, etc., prior to release. (8) Prepare and submit to the Construction Project Manager monthly, a Construction Status Reporting System (CSRS) report. (9) Schedule and conduct a meeting with the County Engineering Office at least forty -five (45) calendar days prior to project final acceptance. The purpose of this meeting is to discuss the required documentation, including as- builts, necessary to close out the permit(s). (10) Video tape the pre- construction conditions throughout the project limits. Provide a digital photo log or video of project activities, with heavy emphasis on potential claim items /issues and on areas of real /potential public controversy. (11) The Consultant shall have a digital camera for photographic documentation of noteworthy incidents or events to cover the following areas: (a). Pre - construction photographs (b). Normal and exceptional progress of work (c). Critical path activities (d). Accidents showing damage (e). Unsafe working conditions (f). Unusual construction techniques (g). Damaged equipment or materials (h). Any activity, which may result in claims These photographs will be filed and maintained on the Consultant's computer. Copies of photographs will be electronically transferred to the County at an interval determined by the Senior Project Engineer and the Construction Project Manager. The taking of the photographs shall begin the day prior to the start of construction and continue regularly throughout this project. Photographs shall be taken the days of Conditional, Partial and /or Final Acceptance. (13) Provide a Resident Compliance Specialist for surveillance of the Contractor's compliance with Construction Contract requirements. (14) As needed, prepare and make presentation before the Dispute Review Boards in connection with the project covered by this Agreement 5.0 ITEMS TO BE FURNISHED BY THE COUNTY TO CONSULTANT A. The County, on as needed basis, will furnish the following Construction Contract documents for this project. These documents may be provided in either paper or electronic format. 1 Construction Documents (drawings, specifications) 2 Special Provisions 3 Copy of the executed Construction Contract. 6.0 ITEMS FURNISHED BY THE CONSULTANT 6.1 County Documents All applicable documents referenced herein shall be a condition of this Agreement. 62 Vehicles Vehicles will be equipped with appropriate safety equipment and must be able to effectively carry out requirements of this Agreement. Vehicles shall have the name and phone number of the consulting firm visibly displayed on both sides of the vehicle. 6.3 Field Equipment The Consultant shall supply survey, inspection and testing equipment, essential in order to carry out the work under this Agreement. Such equipment includes those non - consumable and non - expendable items, which are normally needed for a CEI project and are essential in order to carry out the work under this Agreement. Hard hats shall have the name of the consulting firm visibly displayed. Equipment described herein and expendable materials under this Agreement will remain the property of the Consultant and shall be removed at completion of the work. The Consultant's handling of nuclear density gauges shall be in compliance with their license. The Consultant shall retain responsibility for risk of loss or damage to said equipment during performance of this Agreement. Field office equipment shall be maintained and in operational condition at all times. 6.4 Licensing for Equipment Operations The Consultant will be responsible for obtaining proper licenses for equipment and personnel operating equipment when licenses are required. The Consultant shall make the license and supporting documents available to the County, for verification, upon request. Radioactive Materials License for use of Surface Moisture Density Gauges shall be obtained through the State of Florida Department of Health. 7.0 LIAISON The Consultant shall keep the Construction Project Manager informed of all significant activities, decisions, correspondence, reports, and other communications related to its responsibilities under this Agreement, and seek input from the Construction Project Manager in order for the Construction Project Manager to oversee the Consultant's performance. Agreement administrative duties relating to Invoice Approval Requests, Personnel Approval Requests, User ID Requests, Time Extension Requests, and Amendment and Supplemental Amendment Requests shall be reviewed and approved by the Construction Project Manager. 8.0 PERSONNEL 8.1 General Requirements The Consultant shall staff the project with the qualified personnel necessary to efficiently and effectively carry out its responsibilities under this Agreement. Not all positions listed below may be required; however, personnel performing a specific task must have the qualifications required for the task. Unless otherwise agreed by the County, the County will not compensate straight overtime or premium overtime for the positions of Senior Project Engineer, Project Administrator, Contract Support Specialist, and Associate Contract Support Specialist. 8.2 Personnel Qualifications The Consultant shall utilize only competent personnel, qualified by experience, and education. The Consultant shall submit in writing to the Construction Project Manager the names of personnel proposed for assignment to the project, including a detailed resume for each containing at a minimum salary, education, and experience. The Consultant Action Request form for personnel approval shall be submitted to the Construction Project Manager at least two weeks prior to the date an individual is to report to work. Personnel identified in the Consultant technical proposal are to be assigned as proposed and are committed to performing services under this Agreement. Personnel changes will require written approval from County. Previously approved staff, whose performance is unsatisfactory, shall be replaced by the Consultant within one week of County notification. Before the project begins, all project staff shall have a working knowledge of the current CPAM and must possess all the necessary qualifications /certifications for obtaining the duties of the position they hold. Cross training of the Consultant's project staff is highly recommended to ensure a knowledgeable and versatile project inspection team but shall not be at any additional cost to the County and should occur as workload permits. Visit the training page on the State Construction Office website for training dates. Minimum qualifications for the Consultant personnel are set forth as follows. Exceptions to these minimum qualifications will be considered on an individual basis. The County Engineer or designee will have the final approval authority. CEI SENIOR PROJECT ENGINEER - A Civil Engineer degree and be registered in the State of Florida as a Professional Engineer (or if registered in another state, the ability to obtain registration in the State of Florida within six months) and six years of engineering experience (two years of which are in major road and bridge construction), or for non - degreed personnel the aforementioned registration and ten (10) years of engineering experience (two years of which are in major road or bridge construction). Qualifications include the ability to communicate effectively in English (verbally and in writing); direct highly complex and specialized construction engineering administration and inspection program; plans and organizes the work of subordinate and staff members; develops and /or reviews policies, methods, practices, and procedures; and reviews programs for conformance with County standards. Also must have the following: Qualification: FDOT Advanced MOT Pass the CTQP examination covering the training video "Grouting of Bridge Post - tensioning Tendons" (If applicable) Attend the CTQP Quality Control Manager course and pass the examination. Certifications None A Master's Degree in Engineering may be substituted for one (1) year engineering experience. CEI PROJECT ADMINISTRATOR -A Civil Engineering degree plus two (2) years of engineering experience in construction of major road or bridge structures, or eight (8) years of responsible and related engineering experience, two (2) years of which involved construction of major road and bridge structures. Receives general instructions regarding assignments and is expected to exercise initiative and independent judgment in the solution of work problems. Directs and assigns specific tasks to inspectors and assists in all phases of the construction project. Will be responsible for the progress and final estimates throughout the construction project duration. Must have the following: Qualifications FDOT Intermediate MOT Pass the CTQP examination covering the training video "Grouting of Bridge Post - tensioning Tendons" (If applicable) CTQP Final Estimates Level II Certifications None Other Attend CTQP Quality Control Manager Course and pass the examination A Master's Degree in Engineering may be substituted for one (1) year of engineering experience CEI CONTRACT SUPPORT SPECIALIST - A Civil Engineering Degree or High School diploma or equivalent and four years of road & bridge construction engineering inspection (CEI) experience having performed /assisted in project related duties (i.e., progress and final estimates, EEO compliance, processing Construction Contract changes, etc.) or a Civil Engineering degree. Should exercise independent judgment in planning work details and making technical decisions related to the office aspects of the project. Should be familiar with the County's Procedures covering the project related duties as stated above and be proficient in the computer programs necessary to perform these duties. Shall become trained in CTQP Final Estimates Level II course and maintain a current qualification. CEI SENIOR INSPECTOR/ CEI SENIOR ENGINEER INTERN — High school graduate or equivalent plus four years of experience in construction inspection, two years of which shall have been in bridge and /or roadway construction inspection. Must have the following: Qualifications CTQP Concrete Field Inspector Level I CTQP Concrete Transportation Construction Inspector (CTCI) Level II (all bridges) CTQP Asphalt Roadway Level I (If applicable) CTQP Asphalt Roadway Level II (If applicable) CTQP Earthwork Construction Inspection Level I CTQP Earthwork Construction Inspection Level II CTQP Pile Driving Inspection (If applicable) CTQP Drilled Shaft Inspection (If applicable) CTQP Grouting Technician Level I (If applicable) CTQP Post - Tensioning Technician Level I (If applicable) FDOT Intermediate MOT CTQP Final Estimates Level I Certifications Nuclear Radiation Safety Or a Civil Engineering degree and one year of road & bridge CEI experience with the ability to earn additional required qualifications within one year. (Note: Senior Engineer Intern classification requires one year experience as an Engineer Intern.) Responsible for performing highly complex technical assignments in field surveying and construction layout, making, and checking engineering computations, inspecting construction work, and conducting field tests and is responsible for coordinating and managing the lower level inspectors. Work is performed under the general supervision of the Project Administrator. 8.3 Staffing Once authorized, the Consultant shall establish and maintain an appropriate staff through the duration of construction and completion of the final estimate. Responsible personnel, thoroughly familiar with all aspects of construction and final measurements of the various pay items, shall be available to resolve disputed final pay quantities until the appropriate Construction Contract has been paid off. Construction engineering and inspection forces will be required of the Consultant at all times while the Contractor is working. If Contractor operations are substantially reduced or suspended, the Consultant will reduce its staff appropriately. In the event that the suspension of Contractor operations requires the removal of Consultant forces from the project, the Consultant will be allowed ten (10) days maximum to demobilize, relocate, or terminate such forces. 9.0 QUALITY ASSURANCE (QA) PROGRAM 9.1 Quality Reviews The Consultant shall conduct semi - annual reviews to make certain his own organization is in compliance with the requirements cited in the Scope of Services. Quality Reviews shall be conducted to evaluate the adequacy of materials, processes, documentation, procedures, training, guidance, and staffing included in the execution of this Agreement. Quality Reviews shall also be developed and performed to achieve compliance with specific QA provisions contained in this Agreement. The semi - annual reviews shall be submitted to the Construction Project Manager in written form no later than one month after the review. 9.2 On short duration CCEI projects (nine months or less), the CCEI shall perform an initial QA review within the first two months of the start of construction. QA Plan Within thirty days after receiving award of an Agreement, the Consultant shall furnish a QA Plan to the Construction Project Manager. The QA Plan shall detail the procedures, evaluation criteria, and instructions of the Consultant's organization to assure conformance with the Agreement. Unless specifically waived, no payment shall be made until the County approves the Consultant QA Plan. Significant changes to the work requirements may require the Consultant to revise the QA Plan. It shall be the responsibility of the Consultant to keep the plan current with the work requirements. The Plan shall include, but not be limited to, the following areas: A. Organization A description is required of the Consultant QA Organization and its functional relationship to the part of the organization performing the work under the Agreement. The authority, responsibilities and autonomy of the QA organization shall be detailed as well as the names and qualifications of personnel in the quality control organization. B. Quality Reviews The Consultant QA shall detail the methods used to monitor and achieve organization compliance with Agreement requirements for services and products. C. Quality Records The Consultant will outline the types of records, which will be generated and maintained during the execution of his QA program. D. Control of Sub - consultants and Vendors The Consultant will detail the methods used to control sub - consultants and vendor quality. E. Quality Assurance Certification An officer of the Consultant firm shall certify that the inspection and documentation was done in accordance with FDOT specifications, plans, standard indexes, and County procedures. 9.3 Quality Records The Consultant shall maintain adequate records of the quality assurance actions performed by his organization (including subcontractors and vendors) in providing services and products under this Agreement. All records shall indicate the nature and number of observations made, the number and type of deficiencies found, and the corrective actions taken. These records shall be available to the County, upon request, during the Agreement term. All records shall be kept at the primary job site and shall be subject to audit review. 10.0 CERTIFICATION OF FINAL ESTIMATES 10.1 Final Estimate and As -Built Plans Submittal Prepare documentation and records in compliance with the Agreement, Consultant's approved QC Plan and the County's Procedures. Submit the Final Estimate(s) and three sets of final as built plans documenting Contractor's work (one record set with two copies) as follows: (a) Within thirty calendar days of final acceptance; or (b) Where all items of work are complete and conditional /partial acceptance is utilized (Lighting, Plant establishment, etc.) for a period exceeding thirty calendar days, the final estimate(s) will be due on the thirtieth (30th) day after conditional /partial acceptance. A memorandum with documentation will be transmitted to the Director of Engineering Services at final acceptance detailing any necessary revisions to the pay items covered under the conditional /partial acceptance. The Consultant shall be responsible for making any revisions to the Certified Final Estimate. 10.2 Certification Consultant personnel preparing the Certified Final Estimate Package shall be CTQP Final Estimates Level II qualified. Duly authorized representative of the Consultant firm will provide a notarized certification on a form pursuant to Department procedures. 11.0 SUBCONSULTANT SERVICES: Upon written approval by the Construction Project Manager and the County, and prior to performance of work, the Consultant may subcontract for engineering surveys, materials testing, or specialized professional services. 12.0 OTHER SERVICES Upon written authorization by the Director of Engineering Services or designee, the Consultant will perform additional services in connection with the project not otherwise identified in this Agreement. The following items are not included as part of this Agreement, but may be required by the County to supplement the Consultant services under this Agreement. A. Assist in preparing for arbitration hearings or litigation that occurs during the Agreement time in connection with the construction project covered by this Agreement. B. Provide qualified engineering witnesses and exhibits for any litigation or hearings in connection with the Agreement. C. Provide on- and off -site inspection services in addition to those provided for in this Agreement. 13.0 POST CONSTRUCTION CLAIMS REVIEW In the event the Contractor submits a claim for additional compensation and /or time after the Consultant has completed this Agreement, the Consultant shall, at the written request from the County, analyze the claim, engage in negotiations leading to settlement of the claim, and prepare and process the required documentation to close out the claim. Compensation for such services will be negotiated and effected through a Supplement to this Agreement. 14.0 CONTRADICTIONS In the event of a contradiction between the provisions of this Scope of Services and the Consultant's proposal as made a part of their Agreement, the provisions of the Scope of Services shall apply. 15.0 THIRD PARTY BENEFICIARY It is specifically agreed between the parties executing this Agreement that it is not intended by any of the provisions of any part of the Agreement to create in the public or any member thereof, a third party beneficiary hereunder, or to authorize anyone not a party to this Agreement to maintain a claim, cause of action, lien or any other damages or any relief of any kind pursuant to the terms or provisions of this Agreement. 16.0 COUNTY AUTHORITY The County shall be the final authority in considering contract modification of the Contractor for time, money or any other consideration except matters agreed to by the Contractor through contract changes negotiated by the Consultant, as authorized in Section 9.1 herein. ATTACHMENT B PARSONS BRINCKERHOFF, INC. PROJECT: CEI SERVICES FOR CARD SOUND ROAD BRIDGE REPAIR PROJECT MONROE COUNTY Rev. 12 -14 -15 PROJECT PROJECT PERSONNEL CLASSIFICATIONS PROJECT STAFF YEAR MONTH FIRM 2016 2017 TOTAL MAN MONTHS TOTAL MAN HOURS JAN FEB 1 MAR 2 APR 3 MAY 4 JUN 5 JUL 6 AUG 7 SEP 8 OCT 9 NOV 10 DEC JAN 11 12 I FEB 13 MAR 14 APR MAY JUN SR PROJECT ENGINEER- Pom Chakkaphak PB 0.10 0.10 0.10 0.10 0.10 0.10 0.10 0.10 0.10 0.10 0.10 0.10 0.10 0.10 1.40 231.00 CEI SR INSPECTOR- Keith Duke PB 1.00 1.00 1.00 1.00 1.00 1.00 1.00 1.00 1.00 1.00 1.00 1.00 1.00 1.00 14.00 2,310.00 CEI INSPECTOR- Roy Allen* PB 0.20 0.20 0.20 0.20 0.20 0.20 0.20 1 0.20 0.20 0.20 0.20 0.20 0.20 0.20 2.80 462.00 TOTAL IN MAN - MONTHS 1 1.30 1 1.30 1 1.301 1.301 1.301 1.301 1.301 1.3011 1.301 1.3011 1.30 ''. 1.30 1.30 1.30 18.201 3,003.00 * Eligible for Overtime JAN FEB MAR APR MAY JUN JUL AUG SEP OCT NOV DEC JAN FEB MAR APR MAY JUN 12/14/2015 -423 PM • a • • PARSONS BRINCKERHOFF, INC. PROJECT: CEI SERVICES FOR CARD SOUND ROAD BRIDGE REPAIR PROJECT MONROE COUNTY, FL GIBLE for OVERTIME Direct Labor Straight Overtime @ % of straight labor SUBTOTAL - Salary Related Costs Overhead & Fringe SUBTOTAL OPERATING MARGIN (% of Direct Labor) SUBTOTAL FCCM (% of Direct Labor) SUBTOTAL Direct Expenses - Temp Living & Storage Expenses Direct Expenses - per FDOT Allowable SUBTOTAL Premium Overtime $ 117,200.16 0% HRLY BILL - HOURS RATES DIRECT LABOR 115.40% PERSONNEL CLASSIFICATIONS 135,248.98 $ RATE SR PROJECT ENGINEER - Porn Chakkaphak 231.00 $ 73.36 $ 16,946.16 $ 210.54 CEI SR INSPECTOR - Keith Duke 2310.00 38.30 $ 88,473.00 $ 109.92 CEI INSPECTOR - Roy Allen * 462.00 25.50 $ 11,781.00 $ 73.19 GIBLE for OVERTIME Direct Labor Straight Overtime @ % of straight labor SUBTOTAL - Salary Related Costs Overhead & Fringe SUBTOTAL OPERATING MARGIN (% of Direct Labor) SUBTOTAL FCCM (% of Direct Labor) SUBTOTAL Direct Expenses - Temp Living & Storage Expenses Direct Expenses - per FDOT Allowable SUBTOTAL Premium Overtime Subtotal - Parsons Brinckerhoff, Inc. (Field) ntract Rate Multiplier: $ 336,742.31 2.87 12/14/20154:23 PM $ 117,200.16 0% - $ 117,200.16 115.40% 135,248.98 $ 252,449.14 34% 39,848.05 $ 292,297.19 0.353% 413.72 $ 292,710.91 30,694.02 11.38% 13,337.38 $ 336,742.31 Subtotal - Parsons Brinckerhoff, Inc. (Field) ntract Rate Multiplier: $ 336,742.31 2.87 12/14/20154:23 PM PARSONS BRINCKERHOFF, INC. PROJECT: CEI SERVICES FOR CARD SOUND ROAD BRIDGE REPAIR PROJECT Description Quantity Unit Cost TAX Extension Comment Living Expense x2 people 28.00 $ 950.00 $ 66.50 $ 28,462.00 Months are from Staffing Chart onthly Equipment and Record Storage 14.00 149.00 $ 10.43 $ 2,232.02 Months are from Staffing Chart Total Estimated Temporary Living & Storage Cost: $ 30,694.02 : April 28, 2017 Monroe County Board of County Commissioners Judy Clarke 1100 Simonton Street Key West, FL 33040 RE: Project Description: CEI Monroe County Dear Judy: 2202 North West Shore Blvd, Suite 300 Tampa, FL 33607 Tel: +1 613- 520 -4444 www.wsp - pb.com More than two years ago, Parsons Brinckerhoff joined the WSP family of companies. We are now moving forward by uniting under the WSP name worldwide. This name change reinforces what we have become, a diversified professional services firm that can take on the most complex assignments across different end markets — transportation, buildings, energy, water and the environment. Importantly, we also have the ability to manage interfaces between those markets with our advisory services and program management expertise. Effective on or about May 1, 2017, Parsons Brinckerhoff, Inc., will change its name to WSP USA Inc. We ask that you update your records to reflect this change. If your organization requires specific action or additional information from us to formalize this change in your records, please reply with that information so we may take the necessary actions. There is no change to our management, and we will continue to operate as we always have with a focus on our core values of integrity, teamwork, excellence and respect. Our contractual relationship with you is unaffected by this name change. Our Federal Identification Number (11- 1531569) remains unchanged and the existing insurance coverage on your project remains in full force and effect. We remain committed to providing the experienced people and technical skills to achieve the goals of your project. The project teams assigned to your organization — including project managers, project staff, and senior management — will not change, and we remain committed to making the full resources available to ensure your satisfaction with our work. We value our business relationship and look forward to that continuing in the future. Kind regards, Kenneth B. Spillett Senior Vice President Construction Services Manager - Florida