Loading...
Performance/Payment BondOctober 11, 2017 MONROE COUNTY 1100 Simonton Street Key West, FL 33040 RE: Kenmar General Contracting, LLC Project: Key West International Airport Noise Insulation Program Construction of KWBTS "Pilot Project" Building B Floors 1 & 2 and Two (2) Single Family Homes Bond No. 1001089817 To Whom It May Concern: We have executed the enclosed bonds on behalf of the above captioned contractor in favor of Monroe County. Please note that we have not dated the bonds or the Power of Attorney. The copy of the contract we received was not dated and as the bonds follow the contract they should not be dated prior to the contract. Please accept this letter as authorization to date the enclosed Performance bond(s), Payment bond(s), and the attached Power of Attorney for the captioned project. Please date these items concurrently with the contract date and fax a copy to our office at 305-328-4838 or email to dawn cgaltersurety com so that we can activate the bond coverage. Please do not hesitate to contact our office should you have any questions in this regard. Thank you. Yours truly, Americ ontractors IndemnityCompany ot Warren M. Alter, Attorney -in -Fact 5979 N.W. 151st Street • Suite 202 • Miami lakes, Florida 33014 Phone:305-517-3803 • Fax:305-328-4838 ALTER SURETY GROUP, INC. Bond Department - Public Works Bond In compliance with Florida Statute Chapter 255.05, the provisions and limitations of section 255.05 Florida Statutes, including but not limited to, the notice and time limitations in Sections 255.05(2) and 255.05(10) are incorporated in this bond by reference. Bond Number 1001089817 Contractor Kenmar General Contracting, LLC Address & 1075 Duval Street C21PMB150 Phone No. Key West, FL 33040 305-320-0407 Surety American Contractors Indemnity Company Address & 601 South Figueroa Street, 16th Floor Phone No. Los Angeles, CA 90017 (310) 649-0990 Owner Name Monroe County 1100 Simonton Street Address & Key West, FL 33040 Phone No. (305) 295-3130 Contracting Public Entity (if different from the owner) Address & Phone No. Contract/Project Number NIA Project Name Key West International Airport Noise Insulation Program Construction of KWBTS "Pilot Project' Building B Floors 1 & 2 and Two (2) Single Family Homes Project Location 2601 S. Roosevelt Boulevard, Key West, FL 33040 1717 Jamaica Drive, Key West, FL 33040 2827 Venetian Drive, Key West, FL 33040 Legal Description 2601 S. Roosevelt Boulevard, Key West, FL 33040 And Street Address 1717 Jamaica Drive, Key West, FL 33040 2827 Venetian Drive, Key West, FL 33040 Description of Improvement: Airport Noise Insulation Program Construction of KWBT$ "Pilot Project' Building B Floors 1 & 2 and Two (2) Single Family Homes This bond is given to comply with section 255.05 Florida Statutes and any action instituted by a claimant under this bond for payment must be in accordance with the notice and time limitation provisions in Section 255.05(2) and (10), Florida Statutes. Any provision of this bond which conflict with or purports to grant broader or more expanded coverage in excess of the minimum requirements of the applicable statute shall be deemed deleted herefrom. This bond is a statutory bond, not a common law bond. This is the front page of the bond. All other page(s) are deemed subsequent to this page regardless of any page number(s) that may be pre-printed thereon. Iml;- A1A Document A312 20 0 TM _ 1 Performance Bond CONTRACTOR: (Name, legal status and oddness) Kenmar General Contracting, LLC 1075 Duval Street C21 PMB150 Key West, FL 33040 OWNER: (Nance, legal status and address) Monroe County 1100 Simonton Street Key West, FL 33040 CONSTRUCTION CONTRACT Date: Amount: $2,012,570.39 Bond Number 1001089817 SURETY: bi ed (Name, legal status and piyncipal place of business) American Contractors Indemnity Compafys 601 South Figueroa Street, 16th Floor document has important legal Los Angeles, CA 90017 consequences. Consultation with an attorney Is encouraged with respect to Its completion or modification. Any singular reference to Contractor, Surety, owner or other party shall be considered plural where applicable. ALA Document A312-2010 combines two separate bonds, a Performance Bond and a Payment Bond, Into one form. Thls i t i I Description: s no a s ng a corn n (Nance and location) Key West International Airport Noise Insulation Program Performance and Payment Bond. Construction of KWBTS "Pilot Project" Building B Floors 1 & 2 and Two (2) Single Family Homes BOND Date: (Not em•lier than Construction Conhact Date) Amount: $2,012,570.39 Modifications to this Bond: 1ANone ❑ See Section 16 CONTRACTOR AS PRINCIPAL SURETY Company: (Corporate Seal Company: otporate Seal Kenmar General Contracting, LL8 American Contractor Indemnity Company Signature: Signature: Name Name and Title: J` AD and Title: Warren Alter, Attomey-in-Fact Arts c, a VA-r (Any additional signatin•es appem• on the last page of this Performance Bond) (FOR INFORMATION ONLY— Name, address and telephone) AGENT or BROKER: OWNER'S REPRESENTATIVE: Alter Surety Group, Inc. (Architect, Engineer or otherparty:) 5979 NW 151st Street, #202 Miami Lakes, FL 33014 305-517-3803 Init AIA Document AM" — 2010. The American Institute of Architects. mills 1 § 1 The Contractor and Surety, jointly and severally, bind themselves, their heirs, executors, administrators, successors and assigns to the Owner for the performance of the Construction Contract, which is incorporated herein by reference. § 2 If the Contractor performs the Construction Contract, the Surety and the Contractor shall have no obligation under this Bond, except when applicable to participate in a conference as provided in Section 3. § 3 If there is no Owner Default under the Construction Contract, the Surety's obligation under this Bond shall arise after .1 the Owner first provides notice to the Contractor and the Surety that the Owner is considering declaring a Contractor Default. Such notice shall indicate whether the Owner is requesting a conference among the Owner, Contractor and Surety to discuss the Contractor's performance. If the Owner does not request a conference, the Surety may, within five (5) business days after receipt of the Owner's notice, request such a conference. if the Surety timely requests a conference, the Owner shall attend. Unless the Owner agrees otherwise, any conference requested under this Section 3.1 shall be held within ten (10) business days of the Surety's receipt of the Owner's notice. If the Owner, the Contractor and the Surety agree, the Contractor shall be allowed a reasonable time to perform the Construction Contract, but such an agreement shall not waive the Owner's right, if any, subsequently to declare a Contractor Default; .2 the Owner declares a Contractor Default, terminates the Construction Contract and notifies the Surety; and .3 the Owner has agreed to pay the Balance of the Contract Price in accordance with the terms of the Construction Contract to the Surety or to a contractor selected to perform the Construction Contract. § 4 Failure on the part of the Owner to comply with the notice requirement in Section 3.1 shall not constitute a failure to comply with a condition precedent to the Surety's obligations, or release the Surety from its obligations, except to the extent the Surety demonstrates actual prejudice. § 5 When the Owner has satisfied the conditions of Section 3, the Surety shall promptly and at the Surety's expense take one of the following actions: § 5.1 Arrange for the Contractor, with the consent of the Owner, to perform and complete the Construction Contract; § 5,2 Undertake to perform and complete the Construction Contract itself, through its agents or independent contractors; § 5.3 Obtain bids or negotiated proposals from qualified contractors acceptable to the Owner for a contract for performance and completion of die Construction Contract, arrange for a contract to be prepared for execution by the Owner and a contractor selected with the Owner's concurrence, to be secured with performance and payment bonds executed by a qualified surety equivalent to the bonds issued on the Construction Contract, and pay to the Owner the amount of damages as described in Section 7 in excess of the Balance of the Contract Price incurred by the Owner as a result of the Contractor Default; or § 5.4 Waive its right to perform and complete, arrange for completion, or obtain a new contractor and with reasonable promptness under the circumstances: .1 After investigation, detennine the amount for which it may be liable to the Owner and, as soon as practicable after the amount is determined, make payment to the Owner; or .2 Deny liability in whole or in part and notify the Owner, citing the reasons for denial. § 6 If the Surety does not proceed as provided in Section 5 with reasonable promptness, the Surety shall be deemed to be in default on this Bond seven days after receipt of an additional written notice from the Owner to the Surety demanding that the Surety perform its obligations under this Bond, and the Owner shall be entitled to enforce any remedy available to the Owner. If the. Surety proceeds as provided in Section 5.4, and the Owner refuses the payment or the Surety has denied liability, in whole or in part, without further notice the Owner shall be entitled to enforce any remedy available to the Owner. Init. AIA Document A3121" — 2010. The American Institute of Archilects. 1 § 7 If the Surety elects to act under Section 5.1, 5.2 or 5.3, then the responsibilities of the Surety to the Owner shall not be greater than those of the Contractor under the Construction Contract, and the responsibilities of the Owner to the Surety shall not be greater than those of the Owner under the Construction Contract. Subject to the commitment by the Owner to pay the Balance of the Contract Price, the Surety is obligated, without duplication, for .1 the responsibilities of the Contractor for correction of defective work and completion of the Construction Contract; .2 additional legal, design professional and delay costs resulting from the Contractor's Default, and resulting from the actions or failure to act of the Surety under Section 5; and .3 liquidated damages, or if no liquidated damages are specified in the Construction Contract, actual damages caused by delayed performance or non-performance of the Contractor. § 8 If the Surety elects to act under Section 5.1, 5.3 or 5.4, the Surety's liability is limited to the amount of this Bond. § 9 The Surety shall not be liable to the Owner or others for obligations of the Contractor that are unrelated to the Construction Contract, and the Balance of the Contract Price shall not be reduced or set off on account of any such unrelated obligations. No right of action shall accrue on this Bond to any person or entity other than the Owner or its heirs, executors, administrators, successors and assigns. § 10 The Surety hereby waives notice of any change, including changes of time, to the Construction Contract or to related subcontracts, purchase orders and other obligations. § 11 Any proceeding, legal or equitable, under this Bond may be instituted in any court of competent jurisdiction in the location in which the work or part of the work is located and shall be instituted within two years after a declaration of Contractor Default or within two years after the Contractor ceased working or within two years after the Surety refuses or fails to perform its obligations under this Bond, whichever occurs first. if the provisions of this Paragraph are void or prohibited by law, the minimum period of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable. § 12 Notice to the Surety, the Owner or the Contractor shall be mailed or delivered to the address shown on the page on which their signature appears. § 13 When this Bond has been furnished to comply with a statutory or other legal requirement in the location where the construction was to be performed, any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefrom and provisions conforming to such statutory or other legal requirement shall be deemed incorporated herein. When so furnished, the intent is that this Bond shall be construed as a statutory bond and not as a common law bond. § 14 Definitions § 14.1 Balance of the Contract Price. The total amount payable by the Owner to the Contractor under the Constriction Contract after all proper adjustments have been made, including allowance to the Contractor of any amounts received or to be received by the Owner in settlement of insurance or other claims for damages to which the Contractor is entitled, reduced by all valid and proper payments made to or on behalf of the Contractor under the Construction Contract. § 14.2 Construction Contract. The agreement between the Owner and Contractor identified on the cover page, including all Contract Documents and changes made to the agreement and the Contract Documents. § 14.3 Contractor Default. Failure of the Contractor, which has not been remedied or waived, to perform or otherwise to comply with a material term of the Construction Contract. § 14.4 Owner Default. Failure of the Owner, which has not been remedied or waived, to pay the Contractor as required under the Construction Contract or to perform and complete or comply with the other material terms of the Construction Contract. § 14.5 Contract Documents. All the documents that comprise the agreement between the Owner and Contractor. § 15 If this Bond is issued for an agreement between a Contractor and subcontractor, the term Contractor in this Bond shall be deemed to be Subcontractor and the term Owner shall be deemed to be Contractor. Init. AIA Document A312T0 — 2010. The Amedcan Insthule of Archilects. 3 § 16 Modifications to this bond are as follows: (Space is provided below for additional signatffres of added parries, other Than those appearing on the cover page.) CONTRACTOR AS PRINCIPAL SURETY Company: (Cofporate Seal) Company: (Cofporate Seal) Signature: Name and Title: Address Signature: Name and Title: Address CAUTION: You should sign an original AIA Contract Document, on which this text appears In RED. An original assures that changes will not be obscured. Init. AIA Document A312TM — 2010. The American Institute of Archilecls. 4 -�IA Document 312TM .2010 Payment Bond CONTRACTOR: (Name, legal stales arid address) Kenmar General Contracting, LLC 1075 Duval Street C21 PMB150 Key West, FL 33040 OWNER: (Marne, legal status and address) Monroe County 1100 Simonton Street Key West, FL 33040 CONSTRUCTION CONTRACT Bond Number 1001089817 SURETY: (None, legal status andprincipal place of business) American Contractors Indemnity Comppan�r 601 South Figueroa Street, 16th Floor "is ocument has Important legal consequences. Consultation with Los Angeles, CA 90017 an attorney Is encouraged with respect to its completion or modification. Any singular reference to Contractor, Surety, owner or other party shall be considered plural where applicable. Date: AIA Document A312-2010 combines two separate bonds, a Amount: $2,012,570.39 Performance Bond and a Payment Bond, Into one form. Description: This is not a single combined (Name and locallolr) Key West International Airport Noise Insulation Program Performance and Payment Bond. Construction of KWBTS "Pilot Project' Building B Floors 1 & 2 and Two (2) Single Family Homes BOND Date: (Not earlier than Consh•rrction Contract .Date) Amount: $2,012,570.39 Modifications to this Bond: ❑ None M See Section 18 CONTRACTOR AS PRINCIPAL SURETY Company: (Corporate Seal) Company:ontractors por•ate Seal) Kenmar General Contracting, LLC American Cdemnity C pany Signature: Signature:y Name vim,, 4wt.,Ab Name Warren Alter, Attomey-in-Fact and Title: 40r441 eAAAk T- and Title: (Any additiorfal signatrn es appear on the last page of this Payment Bond) (FOR INFORAMTION ONLY— Name, address and telephone) AGENT or BROKER: OWNER'S REPRESENTATIVE: (Architect, Engineer or other part) :) Alter Surety Group, Inc. 5979 NW 151 st Street, #202 Miami Lakes, FL 33014 305-517-3803 InIL AIA Document A312T° — 2010. The American Institute of Archilects. 051110 § 1 The Contractor and Surety, jointly and severally, bind themselves, their heirs, executors, administrators, successors and assigns to the Owner to pay for labor, materials and equipment furnished for use in the performance of the Construction Contract, which is incorporated herein by reference, subject to the following terms. § 2 If the Contractor promptly makes payment of all sums due to Claimants, and defends, indemnifies and holds harmless the Owner from claims, demands, liens or suits by any person or entity seeking payment for labor, materials or equipment furnished for use in the performance of the Construction Contract, then the Surety and the Contractor shall have no obligation under this Bond. § 3 If there is no Owner Default under the Construction Contract, the Surety's obligation to the Owner under this Bond shall arise after the Owner has promptly notified the Contractor and the Surety (at the address described in Section 13) of claims, demands, liens or suits against the Owner or the Owner's property by any person or entity seeking payment for labor, materials or equipment furnished for use in the performance of the Construction Contract and tendered defense of such claims, demands, liens or suits to the Contractor and the Surety. § 4 When the Owner has satisfied the conditions in Section 3, the Surety shall promptly and at the Surety's expense defend, indemnify and hold harmless the Owner against a duly tendered claim, demand, lien or suit. § 5 The Surety's obligations to a Claimant under this Bond shall arise after the following: § 5.1 Claimants, who do not have a direct contract with the Contractor, .1 have furnished a written notice of non-payment to the Contractor, stating with substantial accuracy the amount claimed and the name of the party to whom the materials were, or equipment was, furnished or supplied or for whom the labor was done or performed, within ninety (90) days after having last performed labor or last furnished materials or equipment included in the Claim; and .2 have sent a Claim to the Surety (at the address described in Section 13). § 5.2 Claimants, who are employed by or have a direct contract with the Contractor, have sent a Claim to the Surety (at the address described in Section 13). § 6 If a notice of non-payment required by Section 5.1.1 is given by the Owner to the Contractor, that is sufficient to satisfy a Claimant's obligation to fiimish a written notice of non-payment under Section 5.1.1. § 7 When a Claimant has satisfied the conditions of Sections 5.1 or 5.2, whichever is applicable, the Surety shall promptly and at the Surety's expense take the fallowing actions: § 7.1 Send an answer to the Claimant, with a copy to the Owner, within sixty (60) days after receipt of the Claim, stating the amounts that are undisputed and the basis for challenging any amounts that are disputed; and § T.2 Pay or arrange for payment of any undisputed amounts. § 7.3 The Surety's failure to discharge its obligations under Section 7.1 or Section 7.2 shall not be deemed to constitute a waiver of defenses the Surety or Contractor may have or acquire as to a Claim, except as to undisputed amounts for which the Surety and Claimant have reached agreement. If, however, the Surety fails to discharge its obligations under Section 7.1 or Section 7.2, the Surety shall indemnify the Claimant for the reasonable attorney's fees the Claimant incurs thereafter to recover any sums found to be due and owing to the Claimant. § 8 The Surety's total obligation shall not exceed the amount of this Bond, plus the amount of reasonable attorney's fees provided under Section 7.3, and the amount of this Bond shall be credited for any payments made -in good faith by the Surety. § 9 Amounts owed by the Owner to the Contractor under the Construction Contract shall be used for the performance of the Construction Contract and to satisfy claims, if any, under any construction performance bond. By the Contractor furnishing and the Owner accepting this Bond, they agree that all funds earned by the Contractor in the performance of the Construction Contract are dedicated to satisfy obligations of the Contractor and Surety under this Bond, subject to the Owner's priority to use the funds for the completion of the work. Init. AIA Document =2TM — 2010. The American Institute of Architects. § 10 The Surety shall not be liable to the Owner, Claimants or others for obligations of the Contractor that are unrelated to the Construction Contract. The Owner shall not be liable for the payment of any costs or expenses of any Claimant under this Bond, and shall have under this Bond no obligation to make payments to, or give notice on behalf of, Claimants or otherwise have any obligations to Claimants under this Bond. § 11 The Surety hereby waives notice of any change, including changes of time, to the Construction Contract or to related subcontracts, purchase orders and other obligations. § 12 No suit or action shall be commenced by a Claimant under this Bond other than in a court of competent jurisdiction in the state in which the project that is the subject of the Construction Contract is located or after the expiration of one year from the date (1) on which the Claimant sent a Claim to the Surety pursuant to Section 5.1.2 or 5.2, or (2) on which the last labor or service was performed by anyone or the last materials or equipment were furnished by anyone under the Construction Contract, whichever of (1) or (2) first occurs. If the provisions of this Paragraph are void or prohibited bylaw, the minimum period of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable. § 13 Notice and Claims to the Surety, the Owner or the Contractor shall be mailed or delivered to the address shown on the page on which their signature appears. Actual receipt of notice or Claims, however accomplished, shall be sufficient compliance as of the date received. § 14 When this Bond has been furnished to comply with a statutory or other legal requirement in the location where the construction was to be performed, any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefrom and provisions conforming to such statutory or other legal requirement shall be deemed incorporated herein. When so furnished, the intent is that this Bond shall be construed as a statutory bond and not as a common law bond. § 15 Upon request by any person or entity appearing to be a potential beneficiary of this Bond, the Contractor and Owner shall promptly furnish a copy of this Bond or shall permit a copy to be made. § 16 Definitions § 16.1 Claim. A written statement by the Claimant including at a minimum: .1 the name of the Claimant; .2 the name of the person for whom the labor was done, or materials or equipment furnished; .3 a copy of the agreement or purchase order pursuant to which labor, materials or equipment was furnished for use in the performance of the Construction Contract; .4 a brief description of the labor, materials or equipment furnished; .5 the date on which the Claimant last performed labor or last furnished materials or equipment for use in the performance of the Construction Contract, .6 the total amount earned by the Claimant for labor, materials or equipment furnished as of the date of the Claim; .7 the total amount of previous payments received by the Claimant; and .8 the total amount due and unpaid to the Claimant for labor, materials or equipment furnished as of the date of the Claim. § 16.2 Claimant. An individual or entity having a direct contract with the Contractor or with a subcontractor of the Contractor to furnish labor, materials or equipment for use in the performance of the Construction Contract. The term Claimant also includes any individual or entity that has rightfully asserted a claim under an applicable mechanic's lien or similar statute against the real property upon which the Project is located. The intent of this Bond shall be to include without limitation in the terms "labor, materials or equipment" that part of water, gas, power, light, heat, oil, gasoline, telephone service or rental equipment used in the Construction Contract, architectural and engineering services required for performance of the work of the Contractor and the Contractor's subcontractors, and all other items for which a mechanic's lien may be asserted in the jurisdiction where the labor, materials or equipment were furnished. § 16.3 Construction Contract. The agreement between the Owner and Contractor identified on the cover page, including all Contract Documents and all changes made to the agreement and the Contract Documents. Init. AIA Document A3121° — 2010. The American Institute of Architects. § 16.4 Owner Default. Failure of the Owner, which has not been remedied or waived, to pay the Contractor as required under the Construction Contract or to perform and complete or comply with the other material terms of the Construction Contract. § 16.5 Contract Documents. All the documents that comprise the agreement between the Owner and Contractor. § 171f this Bond is issued for an agreement between a Contractor and subcontractor, the term Contractor in this Bond shall be deemed to be Subcontractor and the term Owner shall be deemed to be Contractor. § 18 Modifications to this bond are as follows: TIN provisions and limitadwo of section 255.05 Florida 91m6 ss, including but not Nmibd to the nn01- and d" Nm Nation in Sections 255.05(2) and 255.05(10), an incorporated in this bond by n*fsrence. (Space is provided below for additional signahu•es of added parties, other Than those appearing of the covet -page.) CONTRACTOR AS PRINCIPAL SURETY Company: (Corporate Seal) Company: (Corporate Seal) Signature: Name and Title: Address Signature: Name and Title: Address CAUTION: You should sign an original AIA Contract Document, on which this text appears In RED. An original assures that changes will not be obscured. Init. AIA Document A31210 — 2010. The American Institute of Architects. 8 I�MOFATTQMEY 01EM ANY- G�COMPANY AMERIC*NCONTRACTO JIN, MTV COMP - --MARSONJOIN UMTED19T ATES SURETY COMPANY U.S. SPMATYINSURANCE COMPANY KNOW ALL MEN BY THESE PRESENTS: That American Contractors Indemnity Company, a California corporation, Texas Bonding -C-ornpapy, an assumed name of American Contractors Indemnity Company, United States Surety Company, a Maryland----- Umpirly a octively, the 110 Specialty Insures Q TV= corporation (co I ��Oaniel do by thesop"Inum xonstituft atufappoint: Ip, Warren Alter of Nflaml Lakes, Florida its -true an"llawft"Itorney(s)-in-fact, c P to capacity if more than one ismamle, with full power and authority rAy!qq name, plac stead,e acknowledge andAkftergan"n"�-ds, recognizant esandertal iur WidilithJUMnients or contr s nclude riders, aqwq-ftt&ts�dAJiAsedats of surety, praviding Ae bond 1"entv does not exceed ***** ** �"kl*l Dollars (S !"11),000.01l --ilien **�V Five Milllon*llell!" - This Power of Attorney shall expire without further action on November 3,2019. This Power of Attorney is granted under and by authority of the following resolutions adopted by the Boards of Directors of the Companies: Be it Resolved, that President, any Vice President, any Assistant -Vice -President, any Secretary or any Assistant, 'Secretary shall be and is hereby vested with full --- in Fact to re �Mpent and act for be f of the Company 4*ectAo 10wiri any one or more4impall lis��S)- know -Atmqw�t�niay be given full "llindAmilhoft libenameofandonbeh4ni.com powe W cute, Re ledge anvm aw arilial contracts, agreements or indemnityand other conditional or obligatory Ini&Ittall. gS,1 including any and all consents for e o retained percentages and/or final estimates on engineering and construction contracts, and any and all notices and documents canceling or terminating the Company's liability thereunder, and any such instruments so executed by any such Attorney -in -Fact shall be binding upon the Company as if signed by the President and sealed and effected by the Corporate Secretary. B" Resohw4 thiMille signature of any authorized officer eal heretofore or hereafteraffixed 1wany power of attorney or any certificate relating auds �ftheCompany erew li�icsiifflffl Certificate kles�imile signature or flicsiffibetsealVididand5binding upon the Company with respect to any —ei y power of alto e$ or 01ertifi EEF EN xFnrich it is attached, I II III - IN WITNESS WHEREOF, The Companies have caused this instrument to beligned and -their corporate seals to be hereto affixed, this I st day of November, 2016. AMERICAN CONTRACTORS INDEMNITY COMPANY TEXAS BONDING COMPANY UNITED STATES SURETY COMPANY U.S. SPECIALTY INSURANIC OMPANY ell, I'%, MBT'! � 1 y,. Daniel P. Aguilar, Vice Pres cut officer completing this certific ' (only the identity of the individuaLwhomigned the I not I � , certificate is all I =ss accuracy, orb iiiiiiiihith 04to, and no SS: On this 1st day of November, 2016, before me, Sabina Morgenstein, a notary public, personally appeared Daniel P. Aguilar, Vice President of American Contractors Indemnity Company, Texas Bonding Company, United States Surety Company and U.S. Specialty Insurance Company who proved to me on the basis of satisfil evidence to be the person whose name "bscribed to the within instrument and aclu� wledged to me that he executed the same in and that by his sigq#=-mthe�ldflihe person, or the entity upon behalf of whi I �0 person acted. executed=thp-instri�—, c" -TY OF PERJUKY��s true and correct t c-crtifyAnAlih MAL CaliforniaCalifii ia tluit�i p - - ---- -- , i 1: foregoing =�SS my hand and official seal. - - - - - - - SABINA MORGENSTEN Commission # 2129258 Signature (Seal) Notary Public - California Los Anplas County ft WMAWA Secretary of Amt p�u Contractors Company, Texig-l&cM!WCoo-Unite�&States Surety Company and U.S. Specialty Insurance Company, do hereby certify that the above and foregoing iki irelt arl of a Power of Attorney, executed by said 0T CAW Companies, which is still in full force and effect; furthermore, the resolutilonq-�Ymej Ards 3f Dfirctors, set out in the Power of Attorney are in full force and effect. IaNitnes&Whel I have hereunto set my hand and affixed the s-;W 6f saidR.mpamics atuAngeles, California this davfn� iorporate Seals 4iA— Bond No, Kio Lo, Assistant Secretary