10/18/2017 Agreement0I WuRr"
O 5 ° ° °° °y. Kevin Madok, cPA
: p
;o? Clerk of the Circuit Court & Comptroller — Monroe County, Florida
H •...
R aa couN
DATE: January 29, 2018
TO: Rhonda Haag, Director Sustunability
County Administrator's 011ice
VIA: Lindsey Ballard
Aide to the County Administrator
FROM: Pamela G. HancocC.
SUBJECT: October 18 "' BOCC Meeting
Attached is a duplicate original ol' Itcnn M3, Contract with Adventure Environmental, Inc.
for the backfilling of* canal 75 in Key Largo for $1,216,000.00 funded in full by tic $1.5M DEP
Stewardsliip Grant LP44073, for your Handling.
Should you have any questions, please feel free to contact me at ext. 3130. Tliank you.
cc: County Attorney
Finance
File
KEY WEST MARATHON PLANTATION KEY
500 Whitehead Street 3117 Overseas Highway 88820 Overseas Highway
Key West, Florida 33040 Marathon, Florida 33050 Plantation Key, Florida 33070
305 - 294 -4641 305 - 289 -6027 305 - 852 -7145
PK/ROTH BUILDING
50 High Point Road
Plantation Key, Florida 33070
305 - 852 -7145
AGREEMENT
Between Owner and Contractor
Monroe County BOCC
This AGREEM�NNT is:
0
Made as of the 2fLh Day of , 2017
BETWEEN the Owner: Monroe County Board of County Commissioners
1100 Simonton Street
The Gato Building, Room 2 -205"
Key West, Florida 33040
And the Contractor: Adventure Environmental Inc.
12895 Southwest 87th Avenue
Miami, Florida 33176
For the following Project: Backfilling Water Quality Improvement Project Canal #75
Rock Harbor, Key Largo, Monroe County, FL
This Agreement represents one of the canal restoration demonstration projects approved
by the Monroe County BOCC, whose public purpose is to improve the water quality in
Monroe County.
Scope of the Work
1. Project Overview
The Scope of Work for Canal #75 located between Ocean Drive and Coral Way in
Rock Harbor on Key Largo, Florida consists of backfilling the canal due to
excessive depths, the water column is stratified, with anoxia (depleted oxygen)
present in the lower portion of the water column which prevents the inhabitance of
fish or other marine organisms.
2. General Project Intent and Scope
Provide all labor, supervision, engineering, materials, supplies, equipment, tools,
transportation, surveying, layout, and protection for the proper execution and completion
of all the work in accordance with the Contract Documents. The Work shall include but
not be limited to that shown on the Drawings and detailed in the Technical Specifications
if any included in this Contract.
3. General Requirements
A. Construction work times shall be limited to:
AGREEMENT Page 1 of 154
8AM to 6PM Mon -Fri, excluding County holidays
B. Contractor needs to be aware of weather and location and plan accordingly.
C. Contractor must remain aware of the community residences and plan accordingly.
Coordination of each day's works shall be done in advance with approval from
AMEC /Engineer.
D. The Scope of Work shall include, but not be limited to, all work shown and listed in
the Project Drawings (Exhibit A). The Contractor is required to provide a complete
job as contemplated by the drawings and specifications, which are a part of this
contract. The Contractor shall furnish all labor, supervision, materials, power, tools,
equipment, supplies and any other means of construction necessary or proper for
performing and completing the Scope of Work, unless otherwise specifically
stated.
Monroe County has made all reasonable efforts to obtain the required permits for this
project. If the Contractor is aware of another permit that is required, it is up to them to
obtain it.
SPECIAL PROVISIONS
The following Special Provisions are intended to clarify the scope of work, or
highlight features of the work, or modify, change, add to, or delete from the General Scope
of this Proposal Package.
All licenses required in order to perform the scope of work in the specified
location, shall be procured and maintained by the contractor and his
subcontractors. Contractor shall submit copies to AMEC prior to notice to
proceed. Contractor's license shall accompany proposal.
2. Contractor is to review Division 1 General Requirements for additional
responsibilities required in order to perform this Work.
3. If in the event of conflicting, or overlapping requirements in any area of the
proposal documents, technical specifications, or drawings, the most
stringent condition shall be proposed and constructed Notify Sustainability
Manager in any event, in order to not compromise the Owner's right to make
appropriate decisions.
4. Contractor shall maintain As -Built Drawings (Record Drawings per Section
01720), of his work progression.
5. Contractor will be responsible for following the permit conditions in the
South Florida Water Management District, U.S. Army Corp of Engineers,
Florida Keys National Marine Sanctuary and Monroe County permits.
AGREEMENT Page 2 of 154
6. Contractor shall provide suitable storage container, and be responsible for
disposal off -site of all debris and trash.
7. The Contractor shall coordinate with Owner's representative on available
hours for Job Site access. Job site will have limited 8AM -6PM work hours
Mon - Friday. Contractor will need to schedule work shifts typically from
8AM -6PM weekly. Any change to the agreed upon schedule must be
obtained in writing with a minimum of 72 hrs. advanced notice.
8. Coordination of each days works shall be done in advance with approval
from AMEC / Engineer.
9. The Contractor shall repair all damage and restore all properties within the
project footprint to original or better than pre- construction conditions,
including County and private right of way and roads. For roads, repairs shall
be provided only for items beyond normal wear and tear. No additional cost
to the County shall be allowed.
The Engineer is: Amec Foster Wheeler Environment & Infrastructure
Greg Corning
5845 NW 158th Street
Miami Lakes, FL 33014
314 - 920 -8359
The Owner and Contractor agree as set forth below.
ARTICLE 1
The Contract Documents
The Contract Documents consist of this Agreement, Conditions of the Contract (General,
Supplementary and other Conditions), the RFP and its attachments /exhibits, Drawings,
Specifications, Proposal Documents, Addenda issued prior to execution of this
Agreement, together with the response to RFP and all required insurance
documentation, and Modifications issued after execution of this Agreement The Contract
represents the entire and integrated agreement between the parties hereto and
supersedes prior negotiations, representations or agreements, either written or oral. An
enumeration of the Contract Documents, other than Modifications, appears in Article 9.
In the event of a discrepancy between the documents, precedence shall be determined
by the order of the documents as just listed.
ARTICLE 2
The Work of this Contract .
The Contractor shall execute the entire Work described in the Contract Documents,
except to the extent specifically indicated in the Contract Documents to be the
responsibility of others, or as follows: N/A
AGREEMENT Page 3 of 154
ARTICLE 3
Date of Commencement and Substantial Completion
3.1 The date of commencement is the date to be fixed in a notice to proceed issued
by the Owner.
The Contractor shall accomplish Substantial Completion of the construction of the backfill
for Canal #75 within Ninety (90) calendar days from Notice to Proceed for the completion
of the backfill activities and Final Completion 30 days from Substantial. The time or times
stipulated in the contract for completion of the work of the contract or of specified phases
of the contract shall be the calendar date or dates listed in the milestone schedule.
Liquidated damages will be based on the Final Completion Date for all work, modified by
all approved extensions in time as set forth by the Sustainability /Projects Director's
signature of approval on the Certificate of Final Completion. The liquidated damages
table below shall be utilized to determine the amount of liquidated damages.
The Contractor's recovery of damages and sole remedy for any delay caused by the
Owner shall be an extension of time on the Contract.
ARTICLE 4
Contract Sum
4.1 The owner shall pay the Contractor in current funds for the Contractor's
performance of the Contract for the Backfill of Canal #75 the Contract Sum of One
Million Two Hundred and Sixteen Thousand Dollars ($1,216,000.00) subject to
additions and deductions as provided in the Contract Documents.
4.2 The Contract Sum is based upon the following alternates, if any, which are
described in the Contract Documents and are hereby accepted by the Owner: No
Alternatives.
ARTICLE 5
Progress Payments
5.1 Based upon Applications for Payment submitted by the Contractor to the
Sustainability /Projects Director, and upon approval for payment issued by the
Sustainability /Projects Director, and Engineer, the Owner shall make progress payments
AGREEMENT Page 4 of 154
FIRST
SECOND
31ST DAY &
CONTRACT AMOUNT
15 DAYS
15 DAYS
THEREAFTER
Under $50,000.00
$50.00 /Day
$100.00 /Day
$250.00 /Day
$50,000.00 - 99,999.00
100.00 /Day
200.00 /Day
750.00 /Day
$100,000.00- 499,999.00
200.00 /Day
500.00 /Day
2,000.00 /Day
$500,000.00 and Up
500.00 /Day
1,000.00 /Day
3,500.00 /Day
The Contractor's recovery of damages and sole remedy for any delay caused by the
Owner shall be an extension of time on the Contract.
ARTICLE 4
Contract Sum
4.1 The owner shall pay the Contractor in current funds for the Contractor's
performance of the Contract for the Backfill of Canal #75 the Contract Sum of One
Million Two Hundred and Sixteen Thousand Dollars ($1,216,000.00) subject to
additions and deductions as provided in the Contract Documents.
4.2 The Contract Sum is based upon the following alternates, if any, which are
described in the Contract Documents and are hereby accepted by the Owner: No
Alternatives.
ARTICLE 5
Progress Payments
5.1 Based upon Applications for Payment submitted by the Contractor to the
Sustainability /Projects Director, and upon approval for payment issued by the
Sustainability /Projects Director, and Engineer, the Owner shall make progress payments
AGREEMENT Page 4 of 154
on account of the Contract Sum to the contractor as provided below and elsewhere in the
Contract Documents.
5.2 The period covered by each Application for payment shall be one calendar month
ending on the last day of the month, or other time interval approved by the
Sustainability /Projects Director.
5.3 Payment will be made by the Owner in accordance with the Florida Local
Government Prompt Payment Act, section 218.735, Florida Statutes.
5.4 Each Application for Payment shall be based upon the Schedule of Values
submitted by the Contractor in accordance with the Contract Documents. The Schedule
of Values shall allocate the entire Contract Sum among the various portions of the Work
and be prepared in such form and supported by such data to substantiate its accuracy as
the Sustainability /Projects Director may require. This schedule, unless objected to by the
Sustainability /Projects Director, shall be used as a basis for reviewing the Contractor's
Applications for Payment.
5.5 Applications for Payment shall indicate the percentage of completion of each
portion of the Work as of the end of the period covered by the Application for Payment.
5.6 Subject to the provisions of the Contract Documents, the amount of each progress
payment shall be computed as follows:
5.6.1 Take that portion of the Contract Sum properly allocable to completed Work as
determined by multiplying the percentage completion of each portion of the Work by the
share of the total Contract Sum allocated to that portion of the Work in the Schedule of
Values, less retainage of Ten Percent 10 %. Pending final determination of cost to the
owner of changes in the Work, amounts not in dispute may be included in Applications
for Payment. The amount of credit to be allowed by the Contractor to the Owner for a
deletion or change which results in a net decrease in the Contract Sum shall be the net
cost to the Owner, less Overhead, Profit and Documented Costs incurred prior to the
change Request, as indicated in the corresponding line item in the Approved Schedule of
Values for that line item as confirmed by the Sustainability Program Manager. When both
additions and credits covering related Work or substitutions are involved in a change the
allowance for overhead and profit shall be figured on the basis of net increase, if any, with
respect to that change.
5.6.2 Add that portion of the Contract Sum properly allocable to materials and equipment
delivered and suitably stored at the site for subsequent incorporation in the completed
construction (or, if approved in advance by the Owner, suitably stored off the site at a
location agreed upon in writing), less retainage,
5.6.3 Subtract the aggregate of previous payments made by the Owner; and
5.6.4 Subtract amounts, if any, for which the Sustainability /Projects Director has withheld
or nullified a Certificate for Payment as provided in Paragraph 9.5 of the General
Conditions.
AGREEMENT Page 5 of 154
5.7 Retainage of 10% will be withheld in accordance with section 218.735 (8(b),
Florida Statutes.
5.8 Reduction or limitation of retainage, if any, shall be as follows:
Monroe County .is exempt from and not subject to Florida Statutes 255.078, "Public
Construction Retainage". Reduction or limitation of retainage, if any, shall be reduced
incrementally at the discretion of and upon the approval of the Sustainability /Projects
Director.
ARTICLE 6
Final Payment
Final payment, constituting the entire unpaid balance of the Contract Sum, shall be made
by the Owner to the Contractor when (1) the Contract has been fully performed by the
Contractor except for the Contractor's responsibility to correct nonconforming Work as
provided in Subparagraph 12.2.2 of the General Conditions and to satisfy other
requirements, if any, which necessarily survive final payment, and (2) a final approval for
payment has been issued by the Sustainability /Projects Director. Such final payment
shall be made by the Owner not more than 20 days after the issuance of the final approval
for payment. The following documents ( samples in section 1027 are required for Final
Payment:
(1) Application and Certificate for Payment
(2) Continuation Sheet
(3) Certificate of Substantial Completion
(4) Contractor's Affidavit of Debts and Claims
(5) Contractor's Affidavit of Release of Liens
(6) Final Release of Lien
(7) Contractor shall provide two (2) hard copies in tabulated divided binders
and one (1) saved electronically tabbed and indexed in Adobe Acrobat file
(.PDF) format delivered on a downloadable CD /DVD or flash drive of all the
following but not limited to:
A .Project Record Documents (As Built Documents).
B. Operating and maintenance data, instructions to the Owner's
personnel.
C. Warranties, bond and guarantees.
D. Keys and keying schedule.
E. Spare parts and maintenance materials.
F. Electronic copies of approved submittals
G. Evidence of payment and final release of liens and consent of
surety to final release (includes final release from all utilities
and utility companies).
AGREEMENT Page 6 of 154
ARTICLE 7
Miscellaneous Provisions
7.1 Where reference is made in this Agreement to a provision of the General
Conditions or another Contract Document, the reference refers to that provision as
amended or supplemented by other provisions of the Contract Documents.
7.2 Payment shall be made according to the Florida Local Government Prompt
Payment Act and Monroe County Code.
7.3 Temporary facilities and services: As described in Article 34 of the General
Conditions
7.4 Monroe County's performance and obligation to pay under this contract is
contingent upon an annual appropriation by the Board of County Commissioners.
7.5 A person or affiliate who has been placed on the convicted vendor list following a
conviction for public entity crime may not submit a bid on a contract to provide any goods
or services to a public entity, may not submit a proposal on a contract with a public entity
for the construction or repair of a public building or public work, may not submit proposals
on leases of real property to public entity, may not be awarded or perform work as
contractor, supplier, subcontractor, or consultant under a contract with any public entity,
and may not transact business with any public entity in excess of the threshold amount
provided in Section 287.017, for CATEGORY TWO for. a period of 36 months from the
date of being placed on the convicted vendor list.
7.6 INSURANCE REQUIREMENTS.
7.6.1 GENERAL INSURANCE REQUIREMENTS.
Prior to the commencement of work governed by this contract (including the pre- staging
of personnel and material), the Contractor shall obtain, at his /her own expense, insurance
as specified below, which are made part of this contract. The Contractor will ensure that
the insurance obtained will extend protection to all Sub - Contractors engaged by the
Contractor. As an alternative, the Contractor may require all Subcontractors to obtain
insurance consistent with the attached schedules.
The Contractor will not be permitted to commence work governed by this contract
(including pre- staging of personnel and material) until satisfactory evidence of the
required insurance has been furnished to the County as specified below. Delays in the
commencement of work, resulting from the failure of the Contractor to provide satisfactory
evidence of the required insurance, shall not extend deadlines specified in this contract
and any penalties and failure to perform assessments shall be imposed as if the work
commenced on the specified date and time, except for the Contractor's failure to provide
satisfactory evidence.
The Contractor shall maintain the required insurance throughout the entire term of this
contract and any extensions specified in any attached schedules. Failure to comply with
AGREEMENT Page 7 of 154
this provision may result in the immediate suspension of all work until the required
insurance has been reinstated or replaced. Delays in the completion of work resulting
from the failure of the Contractor to maintain the required insurance shall not extend
deadlines specified in this contract and any penalties and failure to perform assessments
shall be imposed as if the work had not been suspended, except for the Contractor's
failure to maintain the required insurance.
The Contractor shall provide, to the County, as satisfactory evidence of the required
insurance, either:
• Certificate of Insurance
or
• A certified copy of the actual insurance policy.
The County, at its sole option, has the right to request a certified copy of any or all
insurance policies required by this contract.
All insurance policies must specify that they are not subject to cancellation, nonrenewal,
material change, or reduction in coverage unless a minimum of thirty (30) days prior
notification is given to the County by the insurer.
The acceptance and /or approval of the Contractor's insurance shall not be construed as
relieving the Contractor from any liability or obligation assumed under this contract or
t imposed by law.
The Monroe County Board of County Commissioners, its employees and officials will be
included as "Additional Insured" on all policies, except for Workers' Compensation.
In addition, the County will be named as an Additional Insured and Loss Payee on all
policies covering County -owned property.
7.6.2 WORKERS' COMPENSATION INSURANCE REQUIREMENTS
Prior to the commencement of work governed by this contract, the Contractor shall obtain
Workers' Compensation Insurance with limits sufficient to respond to the applicable state
statutes.
In addition, the Contractor shall obtain Employers' Liability Insurance with limits of not
less than:
WC3:
$1,000,000 Bodily Injury by Accident
$1,000,000 Bodily Injury by Disease, policy limits
$1,000,000 Bodily Injury by Disease, each employee
WCUSLH US Longshoremen & Harbor Workers Act
WCJA Federal Jones Act - Same as Employer's Liability
AGREEMENT Page 8 of 154
Coverage shall be maintained throughout the entire term of the contract. Coverage shall
be provided by a company or companies authorized to transact business in the state of
Florida.
If the Contractor has been approved by the Florida's Department of Labor, as an
authorized self- insurer, the County shall recognize and honor the Contractor's status. The
Contractor may be required to submit a Letter of Authorization issued by the Department
of Labor and a Certificate of Insurance, providing details on the Contractor's Excess
Insurance Program.
If the Contractor participates in a self- insurance fund, a Certificate of Insurance will be
required. In addition, the Contractor may be required to submit updated financial
statements from the fund upon request from the County.
7.6.3 GENERAL LIABILITY INSURANCE REQUIREMENTS
Prior to the commencement of work governed by this contract, the Contractor shall obtain
General Liability Insurance. Coverage shall be maintained throughout the life of the
contract and include, as a minimum:
Premises Operations
Products and Completed Operations
Blanket Contractual Liability
Personal Injury Liability
Expanded Definition of Property Damage
The minimum limits acceptable shall be:
GL4 $2,000,000 Combined Single Limit (CSL)
An Occurrence Form policy is preferred. If coverage is provided on a Claims Made policy,
its provisions should include coverage for claims filed on or after the effective date of this
contract. In addition, if coverage is provided on a Claims Made policy, the period for which
claims may be reported should extend for a minimum of twelve (12) months following the
acceptance of work by the County. If the Contractor has an Occurrence Form policy then
the above referenced period for which claims may be reported extending for a minimum
of twelve (12) months following the acceptance of work by the County does not apply.
The Monroe County Board of County Commissioners shall be named as Additional
Insured on all policies issued to satisfy the above requirements.
7.6.4 VEHICLE LIABILITY INSURANCE REQUIREMENTS
Recognizing that the work governed by this contract requires the use of vehicles, the
Contractor, prior to the commencement of work, shall obtain Vehicle Liability Insurance.
Coverage shall be maintained throughout the life of the contract and include, as a
minimum, liability coverage for:
AGREEMENT Page 9 of 154
Owned, Non - Owned, and Hired Vehicles
The minimum limits acceptable shall be:
VL3 $1,000,000 Combined Single Limit (CSL)
The Monroe County Board of County Commissioners shall be named as Additional
Insured on all policies issued to satisfy the above requirements.
7.6.5 WATERCRAFT / POLLUTION LIABLITY
Recognizing that the work governed by this contract requires the use of watercraft and
pollution may occur, the Contractor, prior to the commencement of work, shall obtain
Watercraft and Pollution Liability Insurance. Coverage shall be maintained throughout
the life of the contract and include, as a minimum, liability coverage for:
WL2 $1,000,000 Combined Single Limit (CSL)
POL2 $2,000,000 Combined Single Limit (CSL)
The Monroe County Board of County Commissioners shall be named as Additional
Insured on all policies issued to satisfy the above requirements.
7.7 MISCELLANEOUS: The following items are included in this contract:
a) Contractor shall maintain all books, records, and documents directly pertinent
to performance under this Agreement in accordance with generally accepted accounting
principles consistently applied. Each party to this Agreement or their authorized
representatives shall have reasonable and timely access to such records of each other
party to this Agreement for public records purposes during the term of the Agreement and
for four years following the termination of this Agreement. If an auditor employed by the
County or Clerk determines that monies paid to Contractor pursuant to this Agreement
were spent for purposes not authorized by this Agreement, the Contractor shall repay the
monies together with interest calculated pursuant to Sec. 55.03, FS, running from the
date the monies were paid to Contractor.
b) Governing Law, Venue, Interpretation, Costs, and Fees: This Agreement shall
be governed by and construed in accordance with the laws of the State of Florida
applicable to contracts made and to be performed entirely in the State. In the event
that any cause of action or administrative proceeding is instituted for the enforcement or
interpretation of this Agreement, the County and Contractor agree that venue shall lie in
the appropriate court or before the appropriate administrative body in Monroe County,
Florida. The Parties waive their rights to trial by jury. The County and Contractor agree
that, in the event of conflicting interpretations of the terms or a term of this Agreement by
or between any of them the issue shall be submitted to mediation prior to the institution
of any other administrative or legal proceeding, pursuant to Section XVI of this agreement.
AGREEMENT Page 10 of 154
c) Severability. If any term, covenant, condition or provision of this Agreement (or
J the application thereof to any circumstance or person) shall be declared invalid or
unenforceable to any extent by a court of competent jurisdiction, the remaining terms,
covenants, conditions and provisions of this Agreement, shall not be affected thereby;
and each remaining term, covenant, condition and provision of this Agreement shall be
valid and shall be enforceable to the fullest extent permitted by law unless the
enforcement of the remaining terms, covenants, conditions and provisions of this
Agreement would prevent the accomplishment of the original intent of this Agreement.
The County and Contractor agree to reform the Agreement to replace any stricken
provision with a valid provision that comes as close as possible to the intent of the stricken
provision.
d) Attorney's Fees and Costs. The County and Contractor agree that in the event
any cause of action or administrative proceeding is initiated or defended by any party
relative to the enforcement or interpretation of this Agreement, the prevailing party shall
be entitled to reasonable attorney's fees and court costs as an award against the non -
prevailing party, and shall include attorney's fees and courts costs in appellate
proceedings.
e) Binding Effect. The terms, covenants, conditions, and provisions of this
Agreement shall bind and inure to the benefit of the County and Contractor and their
respective legal representatives, successors, and assigns.
f) Authority. Each party represents and warrants to the other that the execution,
delivery and performance of this Agreement have been duly authorized by all necessary
County and corporate action, as required by law. Each party agrees that it has had ample
opportunity to submit this Contract to legal counsel of its choice and enters into this
agreement freely, voluntarily and with advice of counsel.
g) Claims for Federal or State Aid. Contractor and County agree that each shall
be, and is, empowered to apply for, seek, and obtain federal and state funds to further
the purpose of this Agreement; provided that all applications, requests, grant proposals,
and funding solicitations shall be approved by each party prior to submission.
h) Adjudication of Disputes or Disagreements. County and Contractor agree that
all disputes and disagreements shall be attempted to be resolved by meet and confer
sessions between representatives of each of the parties. If the issue or issues are still
not resolved to the satisfaction of the parties, then any party shall have the right to seek
such relief or remedy as may be provided by this Agreement or by Florida law. This
Agreement is not subject to arbitration.
i) Cooperation. In the event any administrative or legal proceeding is instituted
against either party relating to the formation, execution, performance, or breach of this
Agreement, County and Contractor agree to participate, to the extent required by the
other party, in all proceedings, hearings, processes, meetings, and other activities related
to the substance of this Agreement or provision of the services under this Agreement.
County and Contractor specifically agree that no party to this Agreement shall be required
to enter into any arbitration proceedings related to this Agreement.
AGREEMENT Page 11 of 154
j) Nondiscrimination. County and Contractor agree that there will be no
discrimination against any person, and it is expressly understood that upon a
determination by a court of competent jurisdiction that discrimination has occurred, this
Agreement automatically terminates without any further action on the part of any party,
effective the date of the court order. County or Contractor agree to comply with all Federal
and Florida statutes, and all local ordinances, as applicable, relating to nondiscrimination.
These include but are not limited to: 1) Title VI of the Civil Rights Act of 1964 (PL 88 -352)
which prohibits discrimination on the basis of race, color or national origin; 2) Title IX of
the Education Amendment of 1972, as amended (20 USC ss. 1681 -1683, and 1685-
1686), which prohibits discrimination on the basis of sex; 3) Section 504 of the
Rehabilitation Act of 1973, as amended (20 USC s. 794), which prohibits discrimination
on the basis of handicaps; 4) The Age Discrimination Act of 1975, as amended (42 USC
ss. 6101 -6107) which prohibits discrimination on the basis of age; 5) The Drug Abuse
Office and Treatment Act of 1972 (PL 92 -255), as amended, relating to nondiscrimination
on the basis of drug abuse; 6) The Comprehensive Alcohol Abuse and Alcoholism
Prevention, Treatment and Rehabilitation Act of 1970 (PL 91 -616), as amended, relating
to nondiscrimination on the basis of alcohol abuse or alcoholism; 7) The Public Health
Service Act of 1912, ss. 523 and 527 (42 USC ss. 690dd -3 and 290ee -3), as amended,
relating to confidentiality of alcohol and drug abuse patient records; 8) Title VIII of the Civil
Rights Act of 1968 (42 USC s. et seq.), as amended, relating to nondiscrimination in the
sale, rental or financing of housing; 9) The Americans with Disabilities Act of 1990 (42
USC s. 1201 Note), as maybe amended from time to time, relating to nondiscrimination
on the basis of disability; 10) Any other nondiscrimination provisions in any Federal
or state statutes which may apply to the parties to, or the subject matter of, this
Agreement.
k) Covenant of No Interest. County and Contractor covenant that neither presently
has any interest, and shall not acquire any interest, which would conflict in any manner
or degree with its performance under this Agreement, and that only interest of each is to
perform and receive benefits as recited in this Agreement.
1) Code of Ethics. County agrees that officers and employees of the County
recognize and will be required to comply with the standards of conduct for public officers
and employees as delineated in Section 112.313, Florida Statutes, regarding, but not
limited to, solicitation or acceptance of gifts; doing business with one's agency;
unauthorized compensation; misuse of public position, conflicting employment or
contractual relationship; and disclosure or use of certain information.
m) No Solicitation /Payment. The County and Contractor warrant that, in respect
to itself, it has neither employed nor retained any company or person, other than a bona
fide employee working solely for it, to solicit or secure this Agreement and that it has not
paid or agreed to pay any person, company, corporation, individual, or firm, other than a
bona fide employee working solely for it, any fee, commission, percentage, gift, or other
consideration contingent upon or resulting from the award or making of this Agreement.
For the breach or violation of the provision, the Contractor agrees that the County shall
have the right to terminate this Agreement without liability and, at its discretion, to offset
AGREEMENT Page 12 of 154
from monies owed, or otherwise recover, the full amount of such fee, commission,
percentage, gift, or consideration.
n) Public Records Compliance. Contractor must comply with Florida public
records laws, including but not limited to Chapter 119, Florida Statutes and Section 24 of
article I of the Constitution of Florida. The County and Contractor shall allow and permit
reasonable access to, and inspection of, all documents, records, papers, letters or other
"public record" materials in its possession or under its control subject to the provisions of
Chapter 119, Florida Statutes, and made or received by the County and Contractor in
conjunction with this contract and related to contract performance. The County shall have
the right to unilaterally cancel this contract upon violation of this provision by the
Contractor. Failure of the Contractor to abide by the terms of this provision shall be
deemed a material breach of this contract and the County may enforce the terms of this
provision in the form of a court proceeding and shall, as a prevailing party, be entitled to
reimbursement of all attorney's fees and costs associated with that proceeding. This
provision shall survive any termination or expiration of the contract.
The Contractor is encouraged to consult with its advisors about Florida Public
Records Law in order to comply with this provision.
Pursuant to F.S. 119.0701 and the terms and conditions of this contract, the
Contractor is required to:
(1) Keep and maintain public records that would be required by the County to
perform the service.
(2) Upon receipt from the County's custodian of records, provide the County
with a copy of the requested records or allow the records to be inspected or copied
within a reasonable time at a cost that does not exceed the cost provided in this
chapter or as otherwise provided by law.
(3) Ensure that public records that are exempt or confidential and exempt from
public records disclosure requirements are not disclosed except as authorized by
law for the duration of the contract term and following completion of the contract if
the contractor does not transfer the records to the County.
(4) Upon completion of the contract, transfer, at no cost, to the County all public
records in possession of the Contractor or keep and maintain public records that
would be required by the County to perform the service. If the Contractor transfers
all public records to the County upon completion of the contract, the Contractor
shall destroy any duplicate public records that are exempt or confidential and
exempt from public records disclosure requirements. If the Contractor keeps and
maintains public records upon completion of the contract, the Contractor shall meet
all applicable requirements for retaining public records. All records stored
electronically must be provided to the County, upon request from the County's
custodian of records, in a format that is compatible with the information technology
systems of the County.
(5) A request to inspect or copy public records relating to a County contract must
be made directly to the County, but if the County does not possess the requested
records, the County shall immediately notify the Contractor of the request, and the
AGREEMENT Page 13 of 154
Contractor must provide the records to the County or allow the records to be
inspected or copied within a reasonable time.
IF THE CONTRACTOR HAS QUESTIONS REGARDING THE APPLICATION OF
CHAPTER 119, FLORIDA STATUTES, TO THE CONTRACTOR'S DUTY TO
PROVIDE PUBLIC RECORDS RELATING TO THIS CONTRACT, CONTACT
THE CUSTODIAN OF PUBLIC RECORDS, BRIAN BRADLEY, AT (305) 292 -3470
o) Non - Waiver of Immunity. Notwithstanding the provisions of Sec. 768.28,
Florida Statutes, the participation of the Contractor and the County in this Agreement and
the acquisition of any commercial liability insurance coverage, self- insurance coverage,
or local government liability insurance pool coverage shall not be deemed a waiver of
immunity to the extent of liability coverage, nor shall any contract entered into by the
County be required to contain any provision for waiver.
p) Privileges and Immunities. All of the privileges and immunities from liability,
exemptions from laws, ordinances, and rules and pensions and relief, disability, workers'
compensation, and other benefits which apply to the activity of officers, agents, or
employees of any public agents or employees of the County, when performing their
respective functions under this Agreement within the territorial limits of the County shall
apply to the same degree and extent to the performance of such functions and duties of
such officers, agents, volunteers, or employees outside the territorial limits of the County.
q) Legal Obligations and Responsibilities: Non - Delegation of Constitutional or
Statutory Duties. This Agreement is not intended to, nor shall it be construed as, relieving
any participating entity from any obligation or responsibility imposed upon the entity by
law except to the extent of actual and timely performance thereof by any participating
entity, in which case the performance may be offered in satisfaction of the obligation or
responsibility. Further, this Agreement is not intended to, nor shall it be construed as,
authorizing the delegation of the constitutional or statutory duties of the County, except
to the extent permitted by the Florida constitution, state statute, and case law.
r) Non- Reliance by Non - Parties. No person or entity shall be entitled to rely upon
the terms, or any of them, of this Agreement to enforce or attempt to enforce any third -
party claim or entitlement to or benefit of any service or program contemplated hereunder,
and the County and the Contractor agree that neither the County nor the Contractor or
any agent, officer, or employee of either shall have the authority to inform, counsel, or
otherwise indicate that any particular individual or group of individuals, entity or entities,
have entitlements or benefits under this Agreement separate and apart, inferior to, or
superior to the community in general or for the purposes contemplated in this Agreement.
s) Attestations. Contractor agrees to execute such documents as the County may
reasonably require, to include a Public Entity Crime Statement, an Ethics Statement, and
a Drug -Free Workplace Statement.
t) No Personal Liability. No covenant or agreement contained herein shall be
deemed to be a covenant or agreement of any member, officer, agent or employee of
AGREEMENT Page 14 of 154
Monroe County in his or her individual capacity, and no member, officer, agent or
employee of Monroe County shall be liable personally on this Agreement or be subject to
any personal liability or accountability by reason of the execution of this Agreement.
u) Execution in Counterparts. This Agreement may be executed in any number
of counterparts, each of which shall be regarded as an original, all of which taken together
shall constitute one and the same instrument and any of the parties hereto may execute
this Agreement by signing any such counterpart.
v) Hold Harmless and Indemnification. Notwithstanding any minimum insurance
requirements prescribed elsewhere in this agreement, the Contractor covenants and
agrees that he shall indemnify and hold the COUNTY and the COUNTY's elected and
appointed officers and employees harmless from and against (i) claims, actions or causes
.of action, (ii) litigation, administrative proceedings, appellate proceedings, or other
proceedings relating to any type of injury (including death), loss, damage, fine, penalty or
business interruption, and (iii) costs or expenses that may be asserted against, initiated
with respect to, or sustained by the County and the COUNTY's elected and appointed
officers and employees and the property owner upon which the work is performed from
liabilities damages, losses and costs, including but not limited to, reasonable attorney's
fees, to the extent caused by the negligence, recklessness, or intentional wrongful
misconduct of the Contractor and persons employed or utilized by the indemnifying party
in the performance of the construction contract. The monetary limitation of liability under
this contract shall be not less than $1 million per occurrence pursuant to F. S. 725.06.
Insofar as the claims, actions, causes of action, litigation, proceedings, costs or expenses
relate to events or circumstances that occur during the term of this Agreement, this
section will survive the expiration of the term of this Agreement or any earlier termination
of this Agreement.
In the event the completion of the project (including the work of others) is delayed or
suspended as a result of the Contractor's failure to purchase or maintain the required
insurance, the Contractor shall indemnify the County from any and all increased expenses
resulting from such delay.
In the event the completion of the project (including the work of others) is delayed or
suspended as a result of the Contractor's failure to purchase or maintain the required
insurance, the Contractor shall indemnify the County from any and all increased expenses
resulting from such delay.
The first ten dollars ($10.00) of remuneration paid to the Contractor is for the
indemnification provided for above.
The extent of liability is in no way limited to, reduced, or lessened by the insurance
requirements contained elsewhere within this agreement.
w) Section Headings. Section headings have been inserted in this Agreement as
a matter of convenience of reference only, and it is agreed that such section headings
are not a part of this Agreement and will not be used in the interpretation of any provision
of this Agreement.
AGREEMENT Page 15 of 154
x) Disadvantaged Business Enterprise (DBE) Policy and Obligation. It is the policy
of the County that DBE's, as defined in C.F.R. Part 26, as amended, shall have the
opportunity to participate in the performance of contracts financed in whole or in part with
County funds under this agreement. The DBE requirements of applicable federal and
state laws and regulations apply to this Agreement. The County and its Contractor agree
to ensure that DBE's have the opportunity to participate in the performance of the
Agreement. In this regard, all recipients and contractors shall take all necessary and
reasonable steps in accordance with applicable federal and state laws and regulations to
ensure that DBE's have the opportunity to compete and perform contracts. The County
and Contractor and subcontractors shall not discriminate on the basis of race, color,
national origin or sex in award and performance of contracts, entered pursuant to this
Agreement.
y) Agreements with Subcontractors. In the event that the Contractor subcontracts
any or all of the work in this project to any third party, the Contractor specifically agrees
to identify the COUNTY as an additional insured on all insurance policies required by the
County. In addition, the Contractor specifically agrees that all agreements or contracts of
any nature with his subcontractors shall include the COUNTY as additional insured.
z) Florida Green Building Coalition Standards. Monroe County requires its
buildings to conform to Florida Green Building Coalition standards.
Special Conditions, if any are detailed in Section 00990 of the Project Manual for this
Project.
ARTICLE 8
Termination or Suspension
8.1 The Contract may be terminated by the Owner as provided in Article 14 of the
General Conditions.
ARTICLE 9
Enumeration of Contract Documents
9.1 The Contract Documents, except for Modifications issued after execution of this
Agreement, are enumerated as follows: (Insert information here).
a) Drawings:
b) Project Manual:
9.1.1 The Agreement is this executed Standard Form of Agreement between Owner
and Contractor.
9.1.2 The General Conditions are the General Conditions of the Contract for
Construction.
AGREEMENT Page 16 of 154
9.1.3 The Supplementary and other Conditions of the Contract are those contained in
the Project Manual dated:
9.1.4 The Addenda, if any, are as follows:
Number Date
Addendum No 1 06/06/2017
Addendum No 2 06/13/2017
Addendum No 3 06/29/2017
9.1.5 The Alternates, if any, are as follows:
Alternate No. 1: Not Applicable
END ALTERNATES
AGREEMENT Page 17 of 154
- This Agreement is entered into as of the day and year first written above and is
executed in at least four original copies of which one is to be delivered to the
Contractor. Execution ,by the Contractor must be by a person with authority to bind the
RE OF THE PERSON EXECUTING THE DOCUMENT MUST BE
:D AND WITNESSED BY ANOTHER OFFICER OF THE ENTITY.
BOARD OF COUNTY COMMISSIONERS
,
7 Clerk OF MONROE COUNTY, FLORIDA
y. By. �a
Dep u Clerk Mayor /Chairman
Date (G -2 - f
M ' - i ;; m
A PROVED �'iEt1li
(SEAL) Adventure Environmental, Inc.
Attest: ASS 4 °f .;v� � AFT )RNEY
(� ( r7 By:
0
ca � ' i. H—
nt Shame:
�
.. TR V
i:�
La- cv
AatEq
v
W
�,J C�
' nd
By:
Title:
-
STATE OF FLORIDA
Print
Title:
Date:
Print Name:
Date:
COUNTY F f" IGhcr��
On this y 20a, before me the undersigned notary public,
Perso all appka`ed -v� , known to me to be the
Per: h na a is subsc 4 ed above or who produced
As id " fic do acknowledged that he /she is the person who executed th
abo e o tra nroe County for the t�r�i ► �?n- ;c, ( A- r, � -� �
Prooc�orOrpur�jesxerein contai��
No ary ublic
Print Name
My commission expires:
AGREEMENT
�H;,,, ANTHONY A COLARUSSO
J • ? Notary Public - State of Florida
,9 . My Comm. Expires Aug 16, 2018
oP,• c ommission # FF 133078
Seal
Page 18 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
Section 00750
Section 00970
Section 00980
Section 00990
Section 01010
Section 01015
Section 01027
Section 01030
Section 01040
Section 01045
Section 01050
Section 01200
Section 01301
Section 01310
Section 01370
Section 01385
Section 01395
Section 01400
Section 01410
Section 01421
Section 01500
Section 01520
Section 01550
Section 01560
Section 01590
Section 01595
Section 01600
Section 01630
Section 01640
Section 01700
Section 01710
Section 01720
Section 01730
Section 01740
GENERAL REQUIREMENTS
General Conditions
Project Safety and Health Plan
Contractor Quality Control Plan
Special Conditions
Summary of Work
Contractor's Use of the Premises
Application for Payment
Alternates
Project Coordination
Cutting and Patching
Field Engineering
Project Meetings
Submittals
Progress Schedules
Schedule of Values
Daily Construction Reports
Request for Information — (RFI)
Quality Control
Testing Laboratory Services
Reference Standards and Definitions
Temporary Facilities
Construction Aids
Access Roads and Parking Areas
Temporary Controls
Field Offices and Sheds
Construction Cleaning
Material and Equipment
Post - Proposal Substitutions
Product Handling
Contract Closeout
Final Cleaning
Project Record Documents
Operation and Maintenance Data
Warranties
GENERAL REQUIREMENTS Page 19 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
SECTION 00750 — GENERAL REQUIREMENTS
General Conditions of the Contract for Construction
Table of Articles
1. General Provisions
2. Owner
3. Contractor
4. Administration of the Contract
5. Subcontractors
6. Construction by Owner or By Other Contractors
7. Changes in the Work
8. Time
9. Payments and Completion
10. Protection of Persons and Property
r ' 11. Insurance and Bonds
12. Uncovering and Correction of Work
13. Miscellaneous Provisions
14. Termination or Suspension of the Contract
GENERAL REQUIREMENTS Page 20 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
SECTION 00750 - GENERAL CONDITIONS OF THE CONTRACT
1.0 GENERAL PROVISIONS
1.1 Basic Definitions
1.1.1 The Contract Documents: The Contract Documents consist of the Agreement between
Owner and Contractor, Conditions of the Contract (General, Supplementary and other
Conditions), Drawings, Specifications, addenda issued prior to execution of the Contract, Owners
proposal documents, other documents listed in the Agreement and Modifications issued after
execution of the Contract, and the Contractor's proposal and supporting documentation. A
Modification is (1) a written amendment to the Contract signed by both parties, (2) a Change
Order, (3) a Construction Change Directive or (4) a written order for a minor change in the Work
issued by AMEC /Engineer.
1.1.2 The Contract: The Contract represents the entire and integrated agreement between the
parties hereto and supersedes prior negotiations, representations or agreements, either written
or oral. The Contract may be amended or modified only by a Modification. The Contract
Documents shall not be construed to create a contractual relationship of any kind (1) between the
Engineer and Contractor, (2) between Sustainability /Projects Director and Contractor, (3)
between the AMEC /Engineer and Sustainability /Projects Director, (4) between the Owner and a
Subcontractor or (5) between any persons or entities other than the Owner and Contractor. The
Owner shall, however, be entitled to enforce the obligations under the Contract intended to
facilitate performance of the duties of Sustainability /Projects Director and AMEC /Engineer.
1.1.3 The Work: The term "Work" means the construction and services required by the
Contract Documents, whether completed or partially completed, and includes all other labor,
materials, equipment and services provided or to be provided by the Contractor to fulfill the
Contractor's obligations. The Work may constitute the whole or a part of the Project.
1.1.4 The Project: The Project is the total construction of which the Work performed under the
Contract Documents may be the whole or a part and which may include construction by other
Contractors and by the Owner's own forces including persons or entities under separate contracts
not administered by Sustainability /Projects Director.
1.1.5 The Drawings: The Drawings are the graphic and pictorial portions of the Contract
Documents, wherever located and whenever issued, showing the design, location and
dimensions of the Work, generally including plans, elevations, sections, details, schedules and
diagrams.
1.1.6 The Specifications: The Specifications are that portion of the Contract Documents
consisting of the written requirements for materials, equipment, construction systems, standards
and workmanship for the Work, and performance of related services.
1.1.7 The Project Manual: The Project Manual is the volume usually assembled for the Work
which may include the proposal requirements, sample forms, Conditions of the Contract and
Specifications.
GENERAL CONDITIONS OF CONTRACT 00750 -Page 21 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
1.2 Execution, Correlation and Intent
1.2.2 Execution of the Contract by the Contractor is a representation that the Contractor has
visited the site, become familiar with local conditions under which the Work is to be performed
and correlated personal observations with requirements of the Contract Documents.
1.2.3 The intent of the Contract Document is to include all items necessary for the proper
execution and completion of the Work by the contractor. The Contract Documents are
complementary, and what is required by one shall be as binding as if required by all; performance
by the Contractor shall be required only to the extent consistent with the Contract Documents and
reasonably inferable from them as being necessary to produce the intended results.
1.2.4 Organization of the Specifications into divisions, sections and articles, and arrangement
of Drawings shall not control the Contractor in dividing the Work among Subcontractors or in
establishing the extent of Work to be performed by any trade.
1.2.5 Unless otherwise stated in the Contract Documents, words which have well -known
technical or construction industry meanings are used in the Contract Documents in accordance
with such recognized meanings.
1.2.6 Where on any of the drawings a portion of the Work is drawn out and the remainder is
indicated in outline, the parts drawn out shall also apply to all other like portions of the Work.
1.3 Ownership and Use of Engineer's Drawings, Specifications and Other Documents
1.3.1 The Drawing, Specifications and other documents prepared by the AMEC /Engineer are
instruments of the Engineer's service through which the Work to be executed by the Contractor
is described. The Contractor may retain one contract record set. Neither the Contractor nor any
Subcontractor, Sub - subcontractor or material or equipment supplier shall own or claim a copyright
in the Drawings, Specifications and other documents prepared by the AMEC /Engineer. All copies
of them, except the Contractor's record set, shall be returned or suitably accounted for to
AMEC /Engineer on request, upon completion of the Work. The Drawings, Specifications and
other documents prepared by the Engineer, and copies thereof furnished to the Contractor, are
for use solely with respect to the Project. They are not to be used by the Contractor or any
Subcontractor, Sub - subcontractor or material or equipment suppliers unless they are granted a
limited license to use and reproduce applicable portions of the Drawings, Specifications and other
documents prepared by the Engineer appropriate to and for use in the execution of their Work
under the Contract Documents. All copies made under this license shall bear the statutory
copyright notice, if any, shown on the Drawings, Specifications and other documents prepared by
the Engineer. Submittal or distribution to meet official regulatory requirements or for other
purposes in connection with this Project is not to be construed as publication in derogation of
copyright or other reserved rights
1.3.2 Unless otherwise provided in the Contract Documents, the Contractor will be furnished,
two (2) original sealed copies and one (1) electronic copy of Drawings, Specifications and the
Project Manual free of charge for the execution of the Work. Additional copies may be obtained
from AMEC /Engineer at a fee of $5.00 per page for full size drawings (.25 per page for written
specifications or 11 "x 17" drawings).
GENERAL CONDITIONS OF CONTRACT 00750 -Page 22 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
1.4 Capitalization
1.4.1 Terms capitalized in these General Conditions include those which are (1) specifically
defined, (2) the titles of numbered articles and identified references to Paragraphs,
Subparagraphs and Clauses in the document or (3) the titles of other documents published by
the American Institute of Architects.
1.5 Interpretation
1.5.1 In the interest of brevity the Contract Documents frequently omit modifying words such as
"all" and "any" and articles such as "the" and "an," but the fact that a modifier or an article is absent
from one statement and appears in another is not intended to affect the interpretation of either
statement.
2.0 OWNER
2.1 Definition
2.1.1 The Owner is Monroe County. The term "Owner" means the Owner or the Owner's
authorized representative.
2.2 Information and Services Required of the Owner
2.2.2 Not applicable
2.2.3 Not applicable
2.2.4 Information or services under the Owner's control shall be furnished by the Owner with
reasonable promptness to avoid delay in orderly progress of the Work.
2.2.5 Unless otherwise provided in the Contract Documents, the Contractor will be furnished
two (2) original sealed copies and one (1) electronic copy of Drawings, Specifications and the
Project Manual free of charge for the execution of the Work as provided in Subparagraph 1.3.2.
2.2.6 The Owner shall forward all communications to the Contractor through
Sustainability /Projects Director and may contemporaneously provide the same communications
to the Engineer.
2.2.7 The foregoing are in addition to other duties and responsibilities of the Owner enumerated
herein and especially those in respect to Article 6 (Construction by Owner or by Other
Contractors), Article 9 (Payments and Completion) and Article 11 (Insurance and Bonds).
2.3 Owner's Right to Stop the Work
2.3.1 If the Contractor fails to correct Work which is not in accordance with the requirements of
the contract Documents as required by Paragraph 12.2 or persistently fails to carry out Work in
accordance with the Contract Documents, the Owner, by written order signed personally or by an
agent specifically so empowered by the Owner, may order the Contractor to stop the Work, or
any portion thereof, until the cause for such order has been eliminated; however, the right of the
Owner to stop the Work shall not give rise to a duty on the part of the Owner to exercise this right
for the benefit of the Contractor or any other person or entity.
GENERAL CONDITIONS OF CONTRACT 00750 -Page 23 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
2.4 Owner's Right to Carry Out the Work
2.4.1 If the Contractor defaults or neglects to carry out the Work in accordance with the Contract
Documents and fails within a three -day period after receipt of written notice from the Owner to
commence and continue correction of such default or neglect with diligence and promptness, the
Owner may after such three -day period give the Contractor a second written notice to correct
such deficiencies within a three -day period. If the Contractor within such second three -day period
after receipt of such second notice fails to commence and continue to correct any deficiencies,
the Owner may, without prejudice to other remedies the Owner may have, correct such
deficiencies. In such case an appropriate Change Order shall be issued deducting from payments
then or thereafter due the Contractor the cost of correcting such deficiencies, including
compensation for another contractor or subcontractor or Sustainability /Projects Director's and
Engineer's and their respective consultants' additional services and expenses made necessary
by such default, neglect or failure. If payments then, or thereafter, due the Contractor are not
sufficient to cover such amounts, the Contractor shall pay the difference to the Owner. In the
event of clean -up issues, Owner has right to provide a minimum of 24 hours' notice. In the event
of safety issues determined to be of a serious nature, as determined by AMEC /Engineer, notice
will be given, and contractor is required to rectify deficiency immediately.
3.0 CONTRACTOR
3.1 Definition
3.1.1 The Contractor is the person or entity identified as such in the Agreement and is referred
to throughout this Agreement as if singular in number. The term "Contractor' means the
Contractor or the Contractor's authorized representative.
3.1.2 The plural term "Contractors" refers to persons or entities who perform construction under
Conditions of the Contract that are administered by Sustainability /Projects Director, and that are
identical or substantially similar to these Conditions.
3.2 Review of Contract Documents and Field Conditions by Contractor
3.2.1 The Contractor shall carefully study and compare the Contract Documents with each other
and with information furnished by the Owner pursuant to Subparagraph 2.2.2 and shall at once
report to AMEC /Engineer errors, inconsistencies or omissions discovered. The Contractor shall
not be liable to the Owner, Sustainability /Projects Director or AMEC /Engineer for damage
resulting from errors, inconsistencies or omissions in the Contract Documents unless the
Contractor recognized such error, inconsistency or omission and knowingly failed to report it to
AMEC /Engineer. If the Contractor performs any construction activity knowing it involves a
recognized error, inconsistency or omission in the Contract Documents without such notice to
AMEC /Engineer, the Contractor shall assume appropriate responsibility for such performance
and shall bear an appropriate amount of the attributable costs for correction.
3.2.2 The Contractor shall take field measurements and verify field conditions and shall carefully
compare such field measurements and conditions and other information known to the Contractor
with the Contract Documents before commencing activities. Errors, inconsistencies or omissions
discovered shall be reported to AMEC /Engineer at once.
3.2.3 The Contractor shall perform the Work in accordance with the Contract Documents and
submittals approved pursuant to Paragraph 3.12.
GENERAL CONDITIONS OF CONTRACT 00750 -Page 24 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
t 3.3 Supervision and Construction Procedures
3.3.1 The Contractor shall supervise and direct the Work, using the Contractor's best skill and
attention. The Contractor shall be solely responsible for and have control over construction
means, methods, techniques, sequences and procedures and for coordinating all portions of the
Work under this Contract, subject to overall coordination of AMEC /Engineer as provided in
Subparagraphs 4.6.3 and 4.6.5.
3.3.2 The Contractor shall be responsible to the Owner for acts and omissions of the
Contractor's employees, Subcontractors and their agents and employees, and other persons
performing portions of the Work under a contract with the Contractor.
3.3.3 The Contractor shall not be relieved of obligations to perform the Work in accordance with
the Contract Documents either by activities or duties of Sustainability /Projects Director or
AMEC /Engineer in its administration of the Contract, or by test, inspections or approvals required
or performed by persons other than the Contractor.
3.3.4 The Contractor shall inspect portions of the Project related to the Contractor's Work in
order to determine that such portions are in proper condition to receive subsequent work.
3.3.5 The Contractor shall verify that the Construction Documents being worked with are the
most recent and updated available, including all Addenda information. Also the Contractor will
perform the work strictly in accordance with this contract.
3.4 Labor and Materials
- 3.4.1 Unless otherwise provided in the Contract Documents, the Contractor shall provide and
pay for labor, materials, equipment, tools, construction equipment and machinery, water, heat,
utilities, transportation, and other facilities and services necessary for proper execution and
completion of the Work, whether temporary or permanent and whether or not incorporated or to
be incorporated in the Work.
3.4.2 The Contractor shall enforce strict discipline and good order among the Contractor's
employees and other persons carrying out the Contract. The Contractor shall not permit
employment of unfit persons or persons not skilled in tasks assigned to them.
3.4.3 The Contractor is responsible for the conduct of his employees at all times. Misconduct,
destruction of property, unsafe practices, or violation of any Federal or State regulations including
abuse of alcohol or drugs, will be cause for permanent dismissal from the project. If any
Contractor's employee is determined to be detrimental to the Project, as deemed by
AMEC /Engineer, the Contractor will, remove and /or replace the employee at the request of
AMEC /Engineer. Employees dismissed from the project will be transported from the job site at
the Contractor's expense.
3.4.4 The Contractor shall be totally responsible for the security of his work, materials,
equipment, supplies, tools, machinery, and construction equipment.
3.4.5 The Contractor shall be responsible for complete, timely and accurate field measurements
as necessary for proper coordination, fabrication and installation of his materials and equipment.
The Contractor agrees to cooperate with AMEC /Engineer, if required, to accommodate any
discovered variations or deviations from the Drawings and Specifications so that the progress of
the Work is not adversely affected.
GENERAL CONDITIONS OF CONTRACT 00750 -Page 25 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
3.5 Warranty
3.5.1 The Contractor warrants to the Owner, Sustainability /Projects Director and
AMEC /Engineer that materials and equipment furnished under the Contract will be of good quality
and new unless otherwise required or permitted by the Contract Documents, that the Work will be
free from defects not inherent in the quality required or permitted, and that the Work will conform
with the requirements of the Contract Documents. Work not conforming to these requirements,
including substitutions not properly approved and authorized, may be considered defective. The
Contractor's warranty excludes remedy for damage or defect caused by abuse, modifications not
executed by the Contractor, improper or insufficient maintenance, improper operation, or normal
wear and tear under normal usage. If required by AMEC /Engineer, the Contractor shall furnish
satisfactory evidence as to the kind and quality of materials and equipment.
3.6 Taxes
3.6.1 The Contractor shall pay sales, consumer, use and similar taxes for the Work or portions
thereof provided by the Contractor which are legally enacted when bids are received or
negotiations concluded, whether or not yet effective or merely scheduled to go into effect.
3.7 Permits, Fees and Notices
3.7.1 The County and /or the Engineer /AMEC has applied for the aoplicable environmental
and County permits The Contractor shall secure and pay for licenses, inspections, testing, and
surveys required by Federal, State, or Municipal entities having jurisdiction over the project for
the proper execution and completion of the Work which are customarily secured after execution
of the Contract and which are legally required at the time bids are received.
3.7.2 The Contractor shall comply with and give notices required by laws, ordinances, rules,
regulations and lawful orders of public authorities bearing on performance of the Work.
3.7.3 It is not the Contractor's responsibility to ascertain that the Contract Documents are in
accordance with applicable laws, statutes, ordinances, building codes, and rules and regulations.
However, if the Contractor observes that portions of the Contract Documents are at variance
therewith, the Contractor shall promptly notify Sustainability /Projects Director, AMEC /Engineer
and Owner in writing, and necessary changes shall be accomplished by appropriate Modification.
3.7.4 If the Contractor performs Work knowing it to be contrary to laws, statutes, ordinances,
building codes, and rules and regulations without such notice to Sustainability /Projects Director,
AMEC /Engineer and Owner, the Contractor shall assume full responsibility for such Work and
shall bear the attributable costs.
3.8 Not applicable
3.9 Superintendent
3.9.1 The Contractor shall employ a competent superintendent and necessary assistants who
shall be in attendance at the Project site during performance of the Work. The superintendent
shall represent the Contractor, and communications given to the superintendent shall be as
binding as if given to the Contractor. Important communications shall be confirmed in writing.
Other communications shall be similarly confirmed on written request in each case. The
superintendent shall be satisfactory to AMEC /Engineer and shall not be changed except with the
consent of AMEC /Engineer, unless the superintendent proves to be unsatisfactory to the
_ Contractor or ceases to be in his employ.
GENERAL CONDITIONS OF CONTRACT 00750 -Page 26 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
3.10 Contractor's Construction Schedule
3.10.1 The Contractor, promptly after being awarded the Contract, shall prepare and submit for
the Owner's and AMEC /Engineer's information and Sustainability /Projects Director's approval a
Contractor's Construction Schedule for the Work. Such schedule shall not exceed time limits
current under the Contract Documents, shall be revised at appropriate intervals as required by
the conditions of the Work and Project, shall be related to the entire Project construction schedule
to the extent required by the Contract Documents, and shall provide for expeditious and
practicable execution of the Work. This schedule, to be submitted within 7 days after Notice to
Proceed, shall indicate the dates for the starting and completion of the various stages of
construction, shall be revised as required by the conditions of the Work, and shall be subject to
Sustainability /Projects Director's approval.
3.10.2 The Contractor shall cooperate with AMEC /Engineer in scheduling and performing the
Contractor's Work to avoid conflict, delay in or interference with the Work of other Contractors or
the construction or operations of the Owner's own forces.
3.10.4 The Contractor shall conform to the most recent schedules.
3.10.5 AMEC /Engineer will schedule and conduct a project meeting at a minimum of one meeting
per week in each month which the Contractor shall attend. At this meeting, the parties can
discuss jointly such matters as progress, scheduling, and problems.
3.11 Documents and Samples at the Site
3.11.1 The Contractor shall maintain at the site for the Owner one record copy of the Drawings,
Specifications, addenda, Change Orders and other Modifications, in good order and marked
currently to record changes and selections made during construction, and in addition approved
Shop Drawings, Product Data, Samples and similar required submittals. These shall be available
to Sustainability /Projects Director and AMEC /Engineer and shall be delivered to AMEC /Engineer
for submittal to the Owner upon completion of the Work.
3.12 Shop Drawings, Product Data and Samples
3.12.1 Shop Drawings are drawings, diagrams, schedules and other data specially prepared for
the Work by the Contractor or a Subcontractor, Sub - subcontractor, manufacturer, supplier or
distributor to illustrate some portion of the Work.
3.12.2 Product Data are illustrations, standard schedules, performance charts, instructions,
brochures, diagrams and other information furnished by the Contractor to illustrate materials or
equipment for some portion of the Work.
3.12.3 Samples are physical examples which illustrate materials, equipment or workmanship and
establish standards by which the Work will be judged.
3.12.4 Shop Drawings, Product Data, Samples and similar submittals are not Contract
Documents. The purpose of their submittal is to demonstrate for those portions of the Work for
which submittals are required the way the Contractor proposes to conform to the information given
and the design concept expressed in the Contract Documents. Review by AMEC /Engineer is
subject to the limitations of Subparagraph 4.6.12.
3.12.5 The Contractor shall review, approve and submit to AMEC /Engineer, in accordance with
the schedule and sequence approved by Sustainability /Projects Director, Shop Drawings, Product
Data, Samples and similar submittals required by the Contract Documents. The Contractor shall
GENERAL CONDITIONS OF CONTRACT 00750 -Page 27 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
cooperate with AMEC /Engineer in the coordination of the Contractor's Shop Drawings, Product
Data, Samples and similar submittals with related documents submitted by other Contractors.
Submittals made by the Contractor which are not required by the Contract Documents may be
returned without action.
3.12.6 The Contractor shall perform no portion of the Work requiring submittal and review of Shop
Drawings, Product Data, Samples or similar submittals until the respective submittal has been
approved by AMEC /Engineer. Such Work shall be in accordance with approved submittals.
3.12.7 By approving and submitting Shop Drawings, Product Data, Samples and similar
submittals, the Contractor represents that the Contractor has determined and verified materials,
field measurements and field construction criteria related thereto, or will do so, and has checked
and coordinated the information contained within such submittals with the requirements of the
Work and of the Contract Documents.
3.12.8 The Contractor shall not be relieved of responsibility for deviations from requirements of
the Contract Documents by AMEC /Engineer approval of Shop Drawings, Product Data, Samples
or similar submittals unless the Contractor has specifically informed Sustainability /Projects
Director and AMEC /Engineer in writing of such deviation at the time of submittal and
AMEC /Engineer has given written approval to the specific deviation. The Contractor shall not be
relieved of responsibility for errors or omissions in Shop Drawings, Product Data, Samples or
similar submittals by AMEC /Engineer's approval thereof.
3.12.9 The Contractor shall direct specific attention, in writing or on resubmitted Shop Drawings,
Product Data, Samples or similar submittals, to revisions other than those requested by
' Sustainability /Projects Director and AMEC /Engineer on previous submittals.
3.12.10 Informational submittals upon which AMEC /Engineer are not expected to take responsive
action may be so identified in the Contract Documents.
3.12.11 When professional certification of performance criteria of materials, systems or equipment
is required by the Contract Documents, AMEC /Engineer shall be entitled to rely upon the accuracy
and completeness of such calculations and certifications.
3.12.12 If materials specified in the Contract Documents are not available on the present market,
the Contractor may submit data on substitute materials to AMEC /Engineer for approval by the
Owner.
3.13 Use of Site
3.13.1 The Contractor shall confine operations at the site to areas permitted by law, ordinances,
permits and the Contract Documents and shall not unreasonably encumber the site with materials
or equipment.
3.13.2 The Contractor shall coordinate the Contractor's operations with, and secure the approval
of, AMEC /Engineer before using any portion of the site.
3.14 Cutting and Patching
3.14.1 The Contractor shall be responsible for cutting, fitting or patching required to complete the
Work or to make its parts fit together properly; He shall also provide protection of existing work
as required.
3.14.2 The Contractor shall not damage or endanger a portion of the Work or fully or partially
-- " completed construction of the Owner's own forces or of other Contractors by cutting, patching,
GENERAL CONDITIONS OF CONTRACT 00750 -Page 28 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
excavating or otherwise altering such construction. The Contractor shall not cut or otherwise alter
such construction by other Contractors or by the Owner's own forces except with written consent
of AMEC /Engineer, Owner and such other contractors: such consent shall not be unreasonably
withheld. The Contractor shall not unreasonably withhold from the other Contractors or the Owner
the Contractor's consent to cutting or otherwise altering the Work. When structural members are
involved, the written consent of Sustainability /Projects Director shall also be required. The
Contractor shall not unreasonably withhold from AMEC /Engineer or any separate contractor his
consent to cutting or otherwise altering the Work.
3.14.3 The Contractor shall arrange for any blockouts, cutouts, or openings required for the
installation of his materials and equipment and the execution of his work, whether or not shown
or indicated on the Drawings. The Contractor shall be further responsible for sealing and /or
finishing, in an acceptable fashion and meeting any applicable code requirements, and such
block -out, cutout opening, or other hole in any fire - related floor, ceiling, wall, security wall, or any
other finished surface.
3.15 Cleaning Up
3.15.1 The Contractor shall keep the premises and surrounding area free from accumulation of
waste materials or rubbish caused by operations under the Contract. At completion of the Work
the Contractor shall remove from and about the project waste materials rubbish, the Contractor's
tools, construction equipment, machinery and surplus materials. Clean up shall be performed to
the satisfaction of the Owner or AMEC /Engineer.
3.15.2 If the Contractor fails to clean up as provided in the Contract Documents, AMEC /Engineer
may do so with the Owner's approval and the cost thereof shall be charged to the Contractor.
3.16 Access to Work
3.16.1 The Contractor shall provide the Owner, Sustainability /Projects Director and
AMEC /Engineer access to the Work in preparation and progress wherever located.
3.17 Royalties and Patents
3.17.1 The Contractor shall pay all royalties and license fees. The Contractor shall defend suits
or claims for infringement of patent rights and shall hold the Owner, Sustainability /Projects
Director and AMEC /Engineer harmless from loss on account thereof, but shall not be responsible
for such defense or loss when a particular design, process or product of a particular manufacturer
or manufacturers is required by the Contract Documents. However, if the Contractor has reason
to believe that the required design, process or product is an infringement of a patent, the
Contractor shall be responsible for such loss unless such information is promptly furnished to the
AMEC /Engineer and Sustainability /Projects Director.
3.18 Indemnification and Hold Harmless
3.18.1 Hold Harmless and Indemnification. Notwithstanding any minimum insurance
requirements prescribed elsewhere in this agreement, the Contractor covenants and agrees that
he shall indemnify and hold the COUNTY and the COUNTY's elected and appointed officers and
employees harmless from and against (i) claims, actions or causes of action, (ii) litigation,
administrative proceedings, appellate proceedings, or other proceedings relating to any type of
injury (including death), loss, damage, fine, penalty or business interruption, and (iii) costs or
expenses that may be asserted against, initiated with respect to, or sustained by the County and
the COUNTY's elected and appointed officers and employees and the property owner upon which
the work is performed from liabilities damages, losses and costs, including but not limited to,
GENERAL CONDITIONS OF CONTRACT 00750 -Page 29 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
reasonable attorney's fees, to the extent caused by the negligence, recklessness, or intentional
wrongful misconduct of the Contractor and persons employed or utilized by the indemnifying party
in the performance of the construction contract. The monetary limitation of liability under this
contract shall be not less than $1 million per occurrence pursuant to F. S. 725.06. Insofar as the
claims, actions, causes of action, litigation, proceedings, costs or expenses relate to events or
circumstances that occur during the term of this Agreement, this section will survive the expiration
of the term of this Agreement or any earlier termination of this Agreement.
In the event the completion of the project (including the work of others) is delayed or suspended
as a result of the Contractor's failure to purchase or maintain the required insurance, the
Contractor shall indemnify the County from any and all increased expenses resulting from such
delay.
In the event the completion of the project (including the work of others) is delayed or suspended
as a result of the Contractor's failure to purchase or maintain the required insurance, the
Contractor shall indemnify the County from any and all increased expenses resulting from such
delay.
The first ten dollars ($10.00) of remuneration paid to the Contractor is for the indemnification
provided for above.
The extent of liability is in no way limited to, reduced, or lessened by the insurance requirements
contained elsewhere within this agreement.
4.0 ADMINISTRATION OF THE CONTACT
4.1 Amec Foster Wheeler /Engineer
4.1.1 The Amec Foster Wheeler /Engineer is the person lawfully licensed to practice engineering
or any entity lawfully practicing engineering identified as such in the Agreement and is referred to
throughout the Documents as if singular in number.
4.2 Sustainability /Projects Director
4.2.1 Sustainability /Projects Director is the person identified as such in the Agreement and is
referred to throughout the Contract Documents. The term "Sustainability /Projects Director'
means Monroe County Sustainability /Projects Director or Sustainability /Projects Director's
authorized representative.
4.3 Duties, responsibilities and limitations of authority of Sustainability /Projects Director and
Amec Foster Wheeler /Engineer as set forth in the Contract Documents shall not be restricted,
modified or extended without written consent of the Owner, Sustainability /Projects Director,
Engineer and Contractor. Consent shall not be unreasonably withheld.
4.4 In case of termination of employment of Engineer, the Owner shall appoint an Engineer
whose status under the Contract Documents shall be that of the former Architect/Engineer.
4.5 Not Used
4.6 Administration of the Contract
GENERAL CONDITIONS OF CONTRACT 00750 -Page 30 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
4.6.1 Sustainability /Projects Director and AMEC /Engineer will provide administration of the
Contract as described in the Contract Documents, and will be the Owner's representatives (1)
during construction, (2) until final payment is due and (3) with the Owner's concurrence, from time
to time during the correction period described in Paragraph 12.2. Sustainability /Projects Director
and AMEC /Engineer will advise and consult with the Owner and will have authority to act on behalf
of the Owner only to the extent provided in the Contract Document, unless otherwise modified by
written instrument in accordance with other provision of the Contract.
4.6.2 AMEC /Engineer will determine in general that the Work is being performed in accordance
with the requirements of the Contract Documents, will keep the Owner informed of the progress
of the Work, and will endeavor to guard the Owner against defects and deficiencies in the Work.
4.6.3 AMEC /Engineer will provide for coordination of the activities of other Contractors and of
the Owner's own forces, if any, with the Work of the Contractor, who shall cooperate with them.
The Contractor shall participate with other Contractors or subcontractors and AMEC /Engineer
Owner in reviewing their construction schedules when directed to do so. The Contractor shall
make any revisions to the Construction schedule deemed necessary after a joint review and
mutual agreement. The construction schedules shall constitute the schedules to be used by the
Contractor, other Contractors, AMEC /Engineer and the Owner until subsequently revised.
4.6.4 Not used.
4.6.5 AMEC /Engineer will visit the site at intervals appropriate to the stage of construction to
become generally familiar with the progress and quality of the completed Work and to determine
in general if the Work is being performed in a manner indicating that the Work, when completed,
will be in accordance with the Contract Documents. However, AMEC or Sustain ability /Projects
Director will not be required to make exhaustive or continuous onsite inspections to check quality
or quantity of the Work. On the basis of on -site observations of AMEC /Engineer, AMEC will keep
the Owner informed of progress of the Work, and will endeavor to guard the Owner against defects
and deficiencies in the work.
4.6.6 Sustainability /Projects Director and AMEC /Engineer will not have control over or charge
of. and will not be responsible for construction means, method, techniques, sequences or
procedures, or for safety precautions and programs in connection with the Work, since these are
solely the Contractor's responsibility as provided in Paragraph 3.3, and neither will be responsible
for the Contractor's failure to carry out the Work in accordance with the Contract Documents.
Neither Sustainability /Projects Director nor AMEC /Engineer will have control over, or charge of,
or be responsible for acts or omissions of the Contractor, Subcontractors, or their agents or
employees, or of any other persons performing portions of the Work.
4.6.7 Communications Facilitating Contract Administration. Except as otherwise provided in the
Contract Documents or when direct communications have been specially authorized, the Owner
and Contractor shall communicate through Sustainability /Projects Director, and shall
contemporaneously provide the same communications to the AMEC /Engineer. Communications
by and with the Engineer's consultants shall be through the Engineer. Communications by and
with Subcontractors and material suppliers shall be through the Contractor. Communications by
and with other Contractors shall be through Sustainability /Projects Director and shall be
contemporaneously provided to the AMEC /Engineer.
4.6.8 AMEC /Engineer will review and certify all Applications for Payment by the Contractor,
including final payment. AMEC /Engineer will assemble each of the Contractor's Applications for
Payment with similar Applications from other Contractor into a Project Application for Payment.
GENERAL CONDITIONS OF CONTRACT 00750 -Page 31 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
After reviewing and certifying the amounts due the Contractors, the Project Application for
Payment, along with the applicable Contractors' Applications for Payment, will be processed by
Sustainability /Projects Director.
4.6.9 Based on AMEC /Engineer's observations and evaluations of Contractors' Applications for
Payment, AMEC /Engineer will certify the amounts due the Contractors and will issue a Project
Approval for Payment.
4.6.10 AMEC /Engineer will have authority to reject Work which does not conform to the Contract
Documents, and to require additional inspection or testing, in accordance with Subparagraphs
13.5.2 and 13.5.3, whether or not such Work is fabricated, installed or completed, but will take
such action only after notifying Sustainability /Projects Director. Subject to review,
Sustainability /Projects Director will have the authority to reject Work which does not conform to
the Contract Documents. Whenever AMEC /Engineer considers it necessary or advisable for
implementation of the intent of the Contract Documents, AMEC /Engineer have authority to require
additional inspection or testing of the work in accordance with Subparagraphs 13.5.2 and 13.5.3,
whether or not such Work is fabricated, installed or completed. The foregoing authority of
Sustainability /Projects Director will be subject to the provisions of Subparagraphs 4.6.18 through
4.6.20 inclusive, with respect to interpretations and decisions of AMEC /Engineer. However,
neither AMEC /Engineer's nor Sustainability /Projects Director's authority to act under this
Subparagraph 4.6.10 nor a decision made by either of them in good faith either to exercise or not
to exercise such authority shall give rise to a duty or responsibility of AMEC /Engineer or
Sustainability /Projects Director to the Contractor, Subcontractors, material and equipment
suppliers, their agents or employees, or other persons performing any of the Work.
4.6.11 AMEC /Engineer will receive from the .Contractor and review and approve all Shop
Drawings, Product Data and Samples, coordinate them with information received from other
Contractors, and review those recommended for approval. AMEC /Engineer's actions will be
taken with such reasonable promptness as to cause no delay in the Work of the Contractor or in
the activities of other Contractors or the Owner.
4.6.12 AMEC /Engineer will review and approve or take other appropriate action upon the
Contractor's submittals such as Shop Drawings, Product Data and Samples, but only for the
limited purpose of checking for conformance with information given and the design concept
expressed in the Contract Documents. AMEC /Engineer's action will be taken with such
promptness consistent with the constraints of the project schedule so as to cause no delay in the
Work of the Contractor or in the activities of the other Contractors, the Owner, or
Sustainability /Projects Director, while allowing sufficient time to permit adequate review. Review
of such submittals is not conducted for the purpose of determining the accuracy and
completeness of other details such as dimensions and quantities, or for substantiating instructions
for installation or performance of equipment or systems, all of which remain the responsibility of
the Contractor as Contractor as required by the Contract Documents. AMEC /Engineer's review
of the Contractor's submittals shall not relieve the Contractor of the obligations under Paragraphs
3.3, 3.5 and 3.12. AMEC /Engineer's review shall not constitute approval of safety precautions or,
unless otherwise specifically stated by AMEC /Engineer, of any construction means, methods,
techniques, sequences or procedures. AMEC /Engineer's approval of a specific item shall not
indicate approval of an assembly of which the item is a component.
4.6.13 Sustainability /Projects Director will prepare Change Orders and Construction Change
Directives, in consultation with AMEC /Engineer.
GENERAL CONDITIONS OF CONTRACT 00750 -Page 32 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
4.6.14 Following consultation with AMEC /Engineer, Sustainability /Projects Director will take
appropriate action on Change Orders or Construction Change Directives.
4.6.16 The Contractor will assist AMEC /Engineer in conducting inspections to determine the
dates of Substantial completion and final completion, and will receive and forward to
AMEC /Engineer written warranties and related documents required by the Contract and
assembled by the Contractor. AMEC /Engineer will review and approve a final Project Application
for Payment upon compliance with the requirements of the Contract Documents.
4.6.17 AMEC /Engineer will provide one or more project representatives to assist in carrying out
their responsibilities at the site. The duties, responsibilities and limitations of authority of such
project representatives shall be as set forth in an Exhibit to be incorporated in the Contract
Documents.
4.6.18 AMEC /Engineer will interpret and decide matters concerning performance under and
requirements of the Contract Documents on written request of the Owner or Contractor.
AMEC /Engineer's response to such requests will be made with reasonable promptness and within
any time limits agreed upon. If no agreement is made concerning the time within which
interpretations required of Engineer shall be furnished in compliance with this Paragraph 4.6, then
delay shall not be recognized on account of failure by Engineer to furnish such interpretations
until 15 days after written request is made for them.
4.6.19 Interpretations and decisions of Sustainability /Projects Director will be consistent with the
intent of and reasonably inferable from the Contract Documents and will be in writing or in the
form of drawings. When making such interpretations and decisions, Sustainability /Projects
Director will endeavor to secure faithful performance by both Owner and Contractor, will not show
partiality to either and will not be liable for results of interpretations or decisions so rendered in
good faith.
4.6.20 Sustainability /Projects Director's decisions on matters relating to aesthetic effect will be
final if consistent with the intent expressed in the Contract Documents.
4.7 Claims and Disputes
4.7.1 Definition. A Claim is a demand or assertion by one of the parties seeking, as a matter
of right, adjustment or interpretation of Contract terms, payment of money, extension of time or
other relief with respect to the terms of the Contract. The term "Claim" also includes other disputes
and matters in question between the Owner and Contractor arising out of or relating to the
Contract. Claims must be made by written notice. The responsibility to substantiate Claims shall
rest with the party making the claim.
4.7.2 Meet and Confer. The Contractor and Sustainability /Projects Director shall try to resolve
the claim or dispute with meet and confer sessions to be commenced within 15 days of the dispute
or claim. Any claim or dispute that the parties cannot resolve shall be decided by the Circuit
Court, 16 Judicial Circuit, Monroe County, Florida.
4.7.3 Time Limits on Claims. Claims by either party must be made within 21 days after
occurrence of the event giving rise to such Claim or within 21 days after the claimant first
recognizes the condition giving rise to the Claim, whichever is later. Claims must be made by
written notice. An additional Claim made after the initial Claim has been implemented by Change
Order will not be considered unless submitted in a timely manner. This notice is not a condition
precedent to any other legal action or suit.
GENERAL CONDITIONS OF CONTRACT 00750 -Page 33 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
4.7.4 Continuing Contract Performance. Pending final resolution of a Claim unless otherwise
agreed in writing the Contractor shall proceed diligently with performance of the Contract and the
Owner shall continue to make payments in accordance with the Contract Documents.
4.7.5 Waiver of Claims: Final Payment. The making of final payment shall constitute a waiver
of Claim by the Owner except those arising from:
.1 liens, Claims, security interests or encumbrances arising out of the Contract and
unsettled;
2 failure of the Work to comply with the requirements of the Contract Documents; or
3 terms of special warranties required by the Contract Documents.
4.7.6 Claims for Concealed or Unknown Conditions. If conditions are encountered at the
site which are (1) subsurface or otherwise concealed physical conditions which differ materially
from those indicated in the Contract Documents or (2) unknown physical conditions of an unusual
nature, which differ materially from those ordinarily found to exist and generally recognized as
inherent in construction activities of the character provided for in the Contract Documents, then
notice by the observing party shall be given to the other party promptly before conditions are
disturbed and in no event later than 21 days after first observance of the conditions.
Sustainability /Projects Director will promptly investigate such conditions, and the parties will follow
the procedure in paragraph 4.7.2.
4.7.7 Claims for Additional Cost. If the Contractor wishes to make Claim for an increase in
the Contract Sum, written notice as provided herein shall be given before proceeding to execute
the Work. Prior notice is not required for Claims relating to an emergency endangering life or
�- property arising under Paragraph 10.3 If the Contractor believes additional cost is involved for
reasons including but not limited to (1) a written interpretation from Sustainability /Projects
Director, (2) a written order for a minor change in the Work issued by AMEC /Engineer, (3) failure
of payment by the Owner, (4) termination of the Contract by the Owner, (5) Owner's suspension
or (6) other reasonable grounds, Claim shall be filed in accordance with the procedure established
herein.
4.7.8 Claims for Additional Time.
4.7.8.1 If the Contractor wishes to make Claim for an increase in the Contract Time, written notice
as provided herein shall be given.
4.7.8.2 If adverse weather conditions are the basis for a Claim for additional time, such Claim
shall be documented by data substantiating that weather conditions were abnormal for the period
of time and could not have been reasonably anticipated, and that weather conditions had an
adverse effect on the scheduled construction.
4.7.9 Injury or Damage to Person or Property. If either party to the Contract suffers injury or
damage to person or property because of an act or omission of the other party, of any of the other
party's employees or agents, or of others for whose acts such party is legally liable, written notice
of such injury or damage, whether or not insured, shall be given to the other party within a
reasonable time not exceeding 21 days after first observance. The notice shall provide sufficient
detail to enable the other party to investigate the matter. If a Claim for additional cost or time
related to this Claim is to be asserted, it shall be filed as provided in Subparagraphs 4.7.7 or 4.7.8.
5.0 SUBCONTRACTORS
GENERAL CONDITIONS OF CONTRACT 00750 -Page 34 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
5.1 Definitions
5.1.1 A Subcontractor is a person or entity who has a direct contract with the Contractor to
perform a portion of the Work at the site. The term "Subcontractor" is referred to throughout the
Contract Documents as if singular in number and means a Subcontractor or an authorized
representative of the Subcontractor. The term "Subcontractor" does not include other Contractors
or subcontractors of other Contractors.
5.1.2 A Sub - subcontractor is a person or entity who has a direct or indirect contract with a
Subcontractor to perform a portion of the Work at the site. The term "Sub- subcontractor" is
referred to throughout the Contract Documents as if singular in number and means a Sub -
subcontractor or an authorized representative of the Sub - subcontractor.
5.2 Award of Subcontracts and Other Contracts for Portions of the Work
5.2.1 Unless otherwise stated in the Contract. Documents or the bidding requirements, the
Contractor, as soon as practicable after award of the Contract, shall furnish in writing to
Sustainability /Projects Director for review by the Owner and Sustainability /Projects Director the
names of persons or entities (including those who are to furnish materials or equipment fabricated
to a special design) proposed for each principal portion of the Work. Sustainability /Projects
Director will promptly reply to the Contractor in writing stating whether or not the Owner or
Sustainability /Projects Director, after due investigation, has reasonable objection to any such
proposed person or entity. Failure of Sustainability /Projects Director to reply promptly shall
constitute notice of no reasonable objection.
5.2.2 The Contractor shall not contract with a proposed person or entity to which the Owner or
Sustainability /Projects Director has made reasonable and timely objection. The Contractor shall
not be required to contract with anyone to whom the Owner or Sustainability /Projects Director has
made reasonable objection.
5.2.3 If the Owner or Sustainability /Projects Director refuses to accept any person or entity on
a list submitted by the Contractor in response to the requirements of the Contract Documents, the
Contractor shall submit an acceptable substitute; however, no increase in the Contract Sum shall
be allowed for any such substitution.
5.2.4 The Contractor shall not change a Subcontractor, person or entity previously selected if
the Owner or Sustainability /Projects Director makes reasonable objection to such change.
5.3 Subcontractual Relations
5.3.1 By appropriate written agreement, the Contractor shall require each Subcontractor, to the
extent of the Work to be performed by the Subcontractor, to be bound to the Contractor by terms
of the Contract Documents, and to assume toward the Contractor all the obligations and
responsibilities which the Contractor, by these Documents, assumes toward the Owner or
Sustainability /Projects Director. Each subcontract agreement shall preserve and protect the
rights of the Owner or Sustainability /Projects Director under the Contract Documents with respect
to the Work to be performed by the Subcontractor so that subcontracting thereof will not prejudice
such rights. When appropriate, the Contractor shall require each Subcontractor to enter into
similar agreements with Sub - subcontractors. The Contractor shall make available to each
proposed Subcontractor, copies of the Contract Documents which the Subcontractor will be
bound, and, upon written request of the Subcontractor, identify to the Subcontractor terms and
conditions of the proposed subcontract agreement which may be at variance with the Contract
GENERAL CONDITIONS OF CONTRACT 00750 -Page 35 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
Documents. Subcontractors shall similarly make copies of applicable portions of such documents
available to their respective proposed Sub - subcontractors.
5.4 Contingent Assignment of Subcontracts
5.4.1 Each subcontract agreement for a portion of the Work is assigned by the Contractor to the
Owner provided that:
.1 assignment is effective only after termination of the Contract by the Owner for cause
pursuant to Paragraph 14.2 and only for those subcontract agreements which the Owner accepts
by notifying the Subcontractor in writing; and
.2 assignment is subject to the prior rights of the surety, if any, obligated under public
construction bond covering the Contract.
i. If the work has been suspended for more than 30 days, the Subcontractor's
compensation shall be equitably adjusted.
6.0 CONSTRUCTION BY OWNER OR BY OTHER CONTRACTORS
6.1 Owner's Right to Perform Construction with Own Forces and to Award Other
Contracts
6.1.1 The Owner reserves the right to perform construction or operations released to the Project
with the Owner's own forces, which include persons or entities under separate contracts not
administered by Sustainability /Projects Director. The Owner further reserves the right to award
other contracts in connection with other portions of the Project or other construction or operations
on the site under Conditions of the Contract identical or substantially similar to these including
those portions related to insurance and waiver or subrogation.
6.1.2 When the Owner performs construction , or operations with the Owner's own forces
including persons or entities under separate contracts not administered by Sustainability /Projects
Director, the Owner shall provide for coordination of such forces with the Work of the Contractor
who shall cooperate with them.
6.1.3 It shall be the responsibility of the Contractor to coordinate his work with the work of other
contractors on the site. The Owner and Sustainability /Projects Director shall be held harmless
for any and all costs associated with improper coordination.
6.2 Mutual Responsibility
6.2.1 The Contractor shall afford the Owner's own forces, AMEC /Engineer and other
contractors' reasonable opportunity for introduction and storage of their materials and equipment
and performance of their activities, and shall connect and coordinate the Contractor's construction
and operations with theirs as required by the Contract Documents.
6.2.2 If part of the Contractor's Work depends for proper execution or results upon construction
or operations by the Owner's own forces or other contractors, the Contractor shall, prior to
proceeding with that portion of the Work, promptly report to any apparent discrepancies or defects
in such other construction that would render it unsuitable for such proper execution and results.
Failure of the Contractor so to report shall constitute an acknowledgment that the Owner's own
forces or other contractors' completed or partially completed construction is fit and proper to
receive the Contractor's Work, except as to defects not then reasonably discoverable.
GENERAL CONDITIONS OF CONTRACT 00750 -Page 36 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
6.2.3 Costs caused by delays or by improperly timed activities or defective construction shall be
borne by the Contractor. The Contractor's sole remedy as against the Owner for costs caused
by delays or improperly timed activities or defective construction shall be an extension of time.
6.2.4 The Contractor shall promptly remedy damage wrongfully caused by the Contractor to
completed or partially completed construction or to property of the Owner or other contractors as
provided in Subparagraph 10.2.5.
6.2.5 Claims and other disputes and matters in question between the Contractor and other
contractors shall be subject to the provisions of Paragraph 4.7 provided the other contractors
have reciprocal obligations.
6.2.6 The Owner and other contractors shall have the same responsibilities for cutting and
patching as are described for the Contractor in Paragraph 3.14.
6.2.7 Should the Contractor contend that he is entitled to an extension of time for completion of
any portion or portions of the work, he shall, within (72) hours of the occurrence of the cause of
the delay, notify Sustainability /Projects Director in writing, of his contention: setting forth (A) the
cause for the delay, (B) a description of the portion or portions of work affected thereby, and (C)
all details pertinent thereto. A subsequent written application for the specific number of days of
extension of time requested shall be made by the Contractor to Sustainability /Projects Director
within (72) hours after the delay has ceased to exist.
.1 It is a condition precedent to the consideration or prosecution of any claim for an
extension of time that the foregoing provisions be strictly adhered to in each instance and, if the
Contractor fails to comply, he shall be deemed to have waived the claim.
.2 The Contractor agrees that whether or not any delay, regardless of cause, shall be the
basis for an extension of time he shall have no claim against the Owner or
Sustainability /Projects Director for an increase in the Contract price, nor a claim against the
Owner or Sustainability /Projects Director for a payment or allowance of any kind for damage, loss
or expense resulting from delays; nor shall the Contractor have any claim for damage, loss or
expense resulting from interruptions to, or suspension of, his work to enable other contractors to
perform their work. The only remedy available to the Contractor shall be an extension of time.
6.3 Owner's Right to Clean Up
6.3.1 If a dispute arises among the Contractor, other contractors and the Owner as to the
responsibility under their respective contracts for maintaining the premises and surrounding area
free from waste materials and rubbish as described in Paragraph 3.15, the Owner may clean up
and allocate the cost among those responsible as Sustainability /Projects Director determines to
be just.
7.0 CHANGES IN THE WORK
7.1 Changes
7.1.1 Changes in the Work may be accomplished after execution of the Contract, and without
invalidating the Contract, by Change Order, Construction Change Directive or order for a minor
change in the Work, subject to the limitations stated in this Article 7 and elsewhere in the Contract
Documents.
GENERAL CONDITIONS OF CONTRACT 00750 -Page 37 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
7.1.2 A Change Order shall be based upon agreement among the Owner,
Sustainability /Projects Director, AMEC /Engineer and Contractor; a Construction Change
Directive requires agreement by the Owner and Sustainability /Projects Director and may or may
not be agreed to by the Contractor.
7.1.3 Changes in the Work shall be performed under applicable provisions of the Contract
Documents, and the Contractor shall proceed promptly, unless otherwise provided in the Change
Order, Construction Change Directive or order for a minor change in the Work.
7.1.4 If unit prices are stated in the Contract Documents or subsequently agreed upon, and if
quantities originally contemplated are so changed in a proposed Change Order or Construction
Change Directive that application of such unit prices to quantities of Work proposed will cause
substantial inequity to the Owner or Contractor, -the applicable unit prices shall be equitably
adjusted.
7.2 Change Orders
7.2.1 A change Order is a written instrument prepared by AMEC /Engineer and signed by the
Owner, Sustainability /Projects Director and Contractor stating their agreement upon all of the
following:
.1 a change in the Work;
.2 the amount of the adjustment in the Contract Sum, if any; and
.3 the extent of the adjustment in the Contract Time, if any.
7.2.2 The cost or credit to the Owner resulting from a change in the Work shall be determined
in one or more of the following methods:
.1 mutual acceptance of lump sum properly itemized and supported by sufficient
substantiating data to permit evaluation and payment, and approved by the appropriate authority
in writing;
.2 unit prices stated in the Contract Documents or subsequently agreed upon, and
approved by the appropriate authority in writing;
.3 cost to be determined in a manner agreed upon by the parties and a mutually
acceptable fixed or percentage fee;
.4 or by method provided in subparagraph 7.2.3.
7.2.3 If none of the methods set forth in Clauses 7.2.1 or 7.2.2 is agreed upon, the Contractor,
provided a written order signed by the Owner or Sustainability /Projects Director is received, shall
promptly proceed with the Work involved. The cost of such Work shall then be determined by
daily force accounts in a form acceptable to the Owner and Sustainability /Projects Director. The
daily force account forms shall identify Contractor and /or Subcontractor personnel by name, total
hours for each man, each piece of equipment and total hours for equipment and all material(s) by
type for each extra Work activity claim. Each daily force account form shall be signed by the
designated Sustainability /Projects Director representative no later than the close of business on
the day the Work is performed to verify the items and hours listed. Extended pricing of these
forms shall be submitted to Sustainability /Projects Director with all supporting documentation
required by Sustainability /Projects Director for inclusion into a change order. Unless otherwise
provided in the Contract Documents, cost shall be limited to the following: cost of materials,
including sales tax and cost of delivery; cost of labor, including social security, old age and
GENERAL CONDITIONS OF CONTRACT 00750 -Page 38 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
unemployment insurance, and fringe benefits required by agreement or custom; works' or
`-' workmen's compensation insurance; and the rental value of equipment and machinery. Markups
for overhead and profit will be in accordance with subparagraph 7.2.4. Pending final
determination of cost, payments on account shall be made as determined by
Sustainability /Projects Director. The amount of credit to be allowed by the Contractor for any
deletion or change, which results in a net decrease in the Contract Sum, will be the amount of the
actual net cost to the Owner as confirmed by Sustainability /Projects Director. When both
additions and credits covering related Work or substitutions are involved in any one change, the
allowance for overhead and profit shall be figured on the basis of the net increase, if any with
respect to that change.
7.2.4 The actual cost of Changes in the Work may include all items of labor or material, power
tools, and equipment actually used, utilities, pro rata charges for foreman, and all payroll charges
such as Public Liability and Workmen's Compensation Insurance. No percentage for overhead
and profit shall be allowed on items of Social Security and Sales Tax. If deductions are ordered
the amount of credit shall be net cost to Owner as defined in section 5.6.1 of the Contract. Items
considered as overhead shall include insurance other than that mentioned above, bond or bonds,
superintendent, timekeeper, clerks, watchmen, use of small tools, miscellaneous supplies,
incidental job costs, warranties, and all general home /field office expenses. The actual cost of
Changes in the Work (other than those covered by unit prices set forth in the Contract Documents)
shall be computed as follows:
.1 if the Contractor performs the actual Work, the maximum percentage mark -up for
overhead shall be five percent (5 %) and the maximum percentage for profit shall be five percent
(5 %);
.2 if the Subcontractor performs the actual Work, the subcontractor's percentage mark-
up for overhead and profit shall be a maximum addition of ten percent (10 %). If the Contractor
does not perform the Work, the maximum mark -up for managing the Work will be five percent
(5 %);
3. If the Subcontractor performs part of the actual Work, his percentage mark -up for
overhead and profit shall be a maximum addition of ten percent (10 %) on his direct Work only. If
the Contractor performs part of the actual Work, his percentage mark -up for overhead and profit
shall be a maximum addition of ten percent (10 %) on his direct Work only.
7.2.5 The Contractor shall furnish to the Owner through Sustainability /Projects Director, an
itemized breakdown of the quantities and prices used in computing the value of any change that
might be ordered. Any additional supporting documentation requested by Sustainability /Projects
Director such as certified quotations or invoices shall be provided by the Contractor to
Sustainability /Projects Director at no additional cost to the Owner.
7.2.6 If the Contractor claims that any instructions given to him by AMEC /Engineer, by drawings
or otherwise, involve extra Work not covered by the Contract, he shall give Sustainability /Projects
Director written notice thereof within five (5) days after the receipt of such instructions and before
proceeding to execute the work, except in emergencies endangering life or property, in which
case the Contractor shall proceed in accordance with Paragraph 10.3.
.1 The written notice to Sustainability /Projects Director for the Extra Work shall include a
complete description of the extra Work, the total cost and a detailed cost breakdown by labor,
material and equipment for each additional activity required to be performed. Mark -ups shall be
limited as specified elsewhere in this Article.
GENERAL CONDITIONS OF CONTRACT 00750 -Page 39 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
.2 Except as otherwise specifically provided, no claim for additional cost shall be allowed
unless the complete notice specified by this subparagraph is given by the Contractor.
7.2.7 Unless otherwise agreed in writing, the Contractor shall carry on the Work and maintain
its progress during any dispute or claim proceeding, and Owner shall continue to make payments
to the Contractor in accordance with the Contract Documents. Disputes unresolved shall be
settled in accordance with subparagraph 4.7. The Contractor shall maintain completed daily force
account forms in accordance with subparagraph 7.2.3 for any dispute or claim item.
7.3 Authority
7.3.1 AMEC /Engineer will have authority to order minor changes in the Work not involving
adjustment in the Contract sum or extension of the Contract Time and not inconsistent with the
intent of the Contract Documents. Such changes shall be effected by written order issued through
AMEC /Engineer and shall be binding on the Owner and Contractor. The Contractor shall carry
out such written order promptly.
8.0 TIME
8.1 Definitions
8.1.1 Unless otherwise provided, Contract Time is the period of time, including authorized
adjustments, allotted in the Contract Documents for Substantial Completion of the Work.
8.1.2 The date of commencement of the Work is the date established in the Agreement. The
date shall not be postponed. by the failure to act of the Contractor or of persons or entities for
which the Contractor is responsible.
8.1.3 The date of Substantial Completion is the date certified by Sustainability /Projects Director
in accordance with Paragraph 9.8.
8.1.4 The term "day" as used in the Contract Documents shall mean calendar day unless
otherwise specifically defined.
8.1.5 The Owner /Sustainability /Projects Director shall be the final judge as to whether
Substantial Completion has been achieved and certifies the date to the Contractor.
8.2 Progress and Completion
8.2.1 Time limits stated in the Contract Documents are of the essence of the Contract. By
executing the Agreement the Contractor confirms that the Contract Time is a reasonable period
for performing the Work.
8.2.2 The Contractor shall not knowingly, except by agreement or instruction of the Owner in
writing, prematurely commence operations on the site or elsewhere prior to the effective date of
insurance required by Article 11 to be furnished by the Contractor. The date of commencement
of the Work shall not be changed by the effective date of such insurance.
8.2.3 The Contractor shall proceed expeditiously with adequate forces and shall achieve
Substantial Completion within the Contract Time.
8.3 Delays and Extensions of Time
GENERAL CONDITIONS OF CONTRACT 00750 -Page 40 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
8.3.1 If the Contractor is delayed, at any time, in the progress of the Work by any act or neglect
of the Owner, Sustainability /Projects Director, or the AMEC /Engineer, or by any employee of
either, or by any separate contractor employed by the Owner, or by changes ordered in the Work,
or by fire, unusual delay in transportation, adverse weather conditions not reasonably
anticipatable, unavoidable casualties or any causes beyond the Contractor's control, or by delay
authorized by the Owner, Sustainability /Projects Director, or by any other cause which
Sustainability /Projects Director determines may justify the delay, then the Contract Time shall be
extended by no cost Change Order for such reasonable time as Sustainability /Projects Director
may determine, in accordance with subparagraph 6.2.7.
8.3.2 Any claim for extension of time shall be made in writing to Sustainability /Projects Director
not more than Seventy -two (72) hours after the commencement of the delay in accordance with
paragraph 6.2.7; otherwise it shall be waived. Any claim for extension of time shall state the
cause of the delay and the number of days of extension requested. If the cause of the delay is
continuing, only one claim is necessary, but the Contractor shall report the termination of the
cause for the delay within seventy -two (72) hours after such termination in accordance with
paragraph 6.2.7; otherwise, any claim for extension of time based upon that cause shall be
waived.
8.3.3 No claim for an increase in the Contract Sum for either acceleration or delay will be allowed
for extensions of time pursuant to this Paragraph 8.3 or for other changes in the Construction
Schedules.
8.3.4 If the Project is delayed as a result of the Contractor's refusal or failure to begin the Work
on the date of commencement as defined in Paragraph 8.1.2, or his refusal or failure to carry the
Work forward expeditiously with adequate forces, the Contractor causing the delay shall be liable
for, but not limited to, delay claims from other Contractors which are affected.
9.0 PAYMENTS AND COMPLETION
9.1 Contract Sum
9.1.1 The Contract Sum is stated in the Agreement and, including authorized adjustments, is
the total amount payable by the Owner to the Contractor for performance of the Work under the
Contract Documents.
9.2 Schedule of Values
9.2.1 Before submittal of the first Application for Payment, the Contractor shall submit to
AMEC /Engineer, a schedule of values allocated to various portions of the Work, prepared in such
form and supported by such data to substantiate its accuracy as AMEC /Engineer may require.
This schedule, unless objected to by Sustainability /Projects Director, shall be used as a basis for
reviewing the Contractor's Applications for Payment.
9.3 Applications for Payment
9.3.1 At least fifteen days before the date established for each progress payment, the Contractor
shall submit to AMEC /Engineer an itemized Application for Payment for Work completed in
accordance with the schedule of values. Such application shall be notarized and supported by
such data substantiating the Contractor's right to payment as the Owner or Sustainability /Projects
GENERAL CONDITIONS OF CONTRACT 00750 -Page 41 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
Director may require, such as copies of requisitions from Subcontractors and material suppliers,
' and reflecting retainage if provided for elsewhere in the Contract Documents.
.1 Such applications may include request for payment on account of changes in the Work
which have been properly authorized by Construction Change Directives but not yet included in
Change Orders.
.2 Such applications may not include requests for payment of amounts the Contractor
does not intend to pay to a Subcontractor or material supplier because of a dispute or other
reason.
9.3.2 Unless otherwise provided in the Contract Documents, payments shall be made on
account of materials and equipment delivered and suitably stored at the site for subsequent
incorporation in the Work. If approved in advance by the Owner, payment may similarly be made
for materials and equipment suitably stored off the site at a location agreed upon in writing.
Payment for materials and equipment stored on or off the site shall be conditioned upon
compliance by the Contractor with procedures satisfactory to the Owner to establish the Owner's
title to such materials and equipment or otherwise protect the Owner's interest, and shall include
applicable insurance, storage and transportation to the site for such materials and equipment
stored off the site.
9.3.3 The Contractor warrants that title to all Work covered by an Application for Payment will
pass to the Owner no later than the time of payment. The Contractor further warrants that upon
submittal of an Application for Payment all Work for which approval for payment have been
previously issued and payments received from the Owner shall, to the best of the Contractor's
knowledge, information and belief, be free and clear of liens, claims security interests or
encumbrances in favor of the Contractor, Subcontractors, material suppliers, or other persons or
entities making a claim by reason of having provided labor, materials and equipment relating to
the Work. All Subcontractors and Sub - subcontractors shall execute an agreement stating that
title will so pass, upon their receipt of payment from the Contractor. The warranties are for the
administrative convenience of the Owner only and do not create an obligation on the part of the
Owner to pay directly any unpaid subcontractor, laborer or materialmen. Such persons must seek
payment from the Contractor or his public construction bond surety only.
9.4 Approval for Payment
9.4.1 AMEC /Engineer will assemble a Project Application for Payment by combining the
Contractor's applications with similar applications for progress payments from other Contractors
and certify the amounts due on such applications.
9.4.2 After the AMEC /Engineer's receipt of the Project Application for Payment, AMEC /Engineer
will either recommend approval to the Sustainability /Projects Director for the Application for
Payment, with a copy to the Contractor, for such amount as AMEC /Engineer recommends to the
Sustainability /Projects Director is properly due, or notify the Contractor in writing of
AMEC /Engineer's reasons for withholding approval in whole or in part as provided in
Subparagraph 9.5.1
9.4.3 The issuance of a separate Approval for Payment will constitute representations made by
AMEC /Engineer to the Owner, based on their individual observations at the site and the data
comprising the Application for Payment submitted by the Contractor, that the Work has
progressed to the point indicated and that, to the best of AMEC /Engineer's knowledge,
information and belief, quality of the Work is in accordance with the Contract Documents. The
GENERAL CONDITIONS OF CONTRACT 00750 -Page 42 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
foregoing representations are subject to an evaluation of the Work for conformance with the
Contract Documents upon Substantial Completion, to results of subsequent tests and inspections,
to minor deviations from the Contract Documents correctable prior to completion and to specific
qualifications expressed by AMEC /Engineer. The issuance of a separate Approval for Payment
will further constitute a representation that the Contractor is entitled to payment in the amount
approved. However, the issuance of a separate Approval for Payment will not be a representation
that AMEC /Engineer has (1) made exhaustive or continuous on -site inspections to check the
quality or quantity of the Work, (2) reviewed the Contractor's construction means, methods,
techniques, sequences or procedures, (3) reviewed copies of requisitions received from
Subcontractors and material suppliers and other data requested by the Owner to substantiate the
Contractor's right to payment or (4) made examination to ascertain how or for what purpose the
Contractor has used money previously paid on account of the Contract Sum.
9.5 Decisions to Withhold Approval
9.5.1 AMEC /Engineer may decline to approve an Application for Payment if, in his opinion, the
application is not adequately supported. If the Contractor and AMEC /Engineer cannot agree on
a revised amount, AMEC /Engineer shall process the Application for the amount it deems
appropriate. AMEC /Engineer may also decline to approve any Application for Payment because
of subsequently discovered evidence or subsequent inspections. It may nullify, in whole or part,
any approval previously made to such extent as may be necessary in its opinion because of: (1)
defective Work not remedied; (2) third party claims filed or reasonable evidence indicating
probable filing of such claims; (3) failure of the Contractor to make payments properly to
Subcontractors or for labor, materials, or equipment; (4) reasonable evidence that the Work
cannot be completed for the unpaid balance of the Contract Sum; (5) damage to AMEC /Engineer,
Sustainability /Projects Director, the Owner, or another contractor working at the project; (6)
reasonable evidence that the Work will not be completed within the contract time; (7) persistent
failure to carry out the Work in accordance with the Contract Documents.
No payment shall be made to the Contractor until certificates of insurance or other evidence of
compliance by the Contractor, with all the requirements of Article 11, have been filed with the
Owner and Sustainability /Projects Director.
9.5.2 When the above reasons for withholding approval are removed, approval will be made for
amounts previously withheld.
9.6 Progress Payments
9.6.1 After AMEC /Engineer has issued an Approval for Payment, the Owner shall make
payment in the manner and within the time provided in the Contract Documents, and shall so
notify AMEC /Engineer. From the total of the amount determined to be payable on a progress
payment, a retainage in accordance with the Florida Local Government Prompt Payment Act,
Chapter 218, Florida Statutes will be deducted and retained by the Owner until the final payment
is made. The balance of the amount payable, less all previous payments, shall be approved for
payment. .1 It is understood and agreed that the Contractor shall not be entitled to demand
or receive progress payment based on quantities of Work in excess of those provided in the
proposal or covered by approved change orders, except when such excess quantities have been
determined by AMEC /Engineer and Sustainability /Projects Director to be a part of the final
quantity for the item of Work in question.
GENERAL CONDITIONS OF CONTRACT 00750 -Page 43 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
.2 No progress payment shall bind the Owner to the acceptance of any materials or Work
in place, as to quality or quantity. All progress payments are subject to correction at the time of
final payments.
9:6.2 The Contractor shall promptly pay each Subcontractor, upon receipt of payment from the
Owner, out of the amount paid to the Contractor on account of such Subcontractor's portion of
the Work, the amount to which said Subcontractor is entitled, reflecting percentages actually
retained from payments to the Contractor on account of such Subcontractor's portion of the Work.
The Contractor shall, by appropriate agreement with each Subcontractor, require each
Subcontractor to make payments to Sub - subcontractors in similar manner.
9.6.3 AMEC /Engineer will, on request, furnish to a Subcontractor, if practicable, information
regarding percentages of completion or amounts applied for by the Contractor and action taken
thereon by the Owner and Sustainability /Projects Director on account of portions of the Work done
by such Subcontractor.
9.6.4 Neither the Owner nor Sustainability /Projects Director shall have an obligation to pay, or
to see to, the payment of money to a Subcontractor except as may otherwise be required by law.
9.6.5 Payment to material suppliers shall be treated in a manner similar to that provided in
Subparagraphs 9.6.2, 9.6.3 and 9.6.4.
9.6.6 A progress payment, or partial or entire use or occupancy of the Project by the Owner
shall not constitute acceptance of Work not in accordance with the Contract Documents.
9.6.7 All material and work covered by partial payments made shall thereupon become the sole
property of the Owner, and by this provision shall not be construed as relieving the Contractor
from the sole responsibility for the materials and Work upon which payments have been made or
the restoration for any damaged material, or as a waiver of the right of the Owner or
Sustainability /Projects Director to require the fulfillment of all the terms of the Contract.
9.6.8 Except in case of bona fide disputes, or where the Contractor has some other justifiable
reason for delay, the Contractor shall pay for all transportation and utility services not later than
the end of the calendar month following that in which services are rendered and for all materials,
tools, and other expendable equipment which are delivered at the site of the Project. The
Contractor shall pay to each of his Subcontractors, not later than the end of the calendar month
in which each payment is made to the Contractor, the representative amount allowed the
Contractor on account of the Work performed by the Subcontractor. The Contractor shall, by an
appropriate agreement with each Subcontractor, also require each Subcontractor to make
payments to his suppliers and Sub - subcontractors in a similar manner.
9.7 Substantial Completion
9.7.1 Substantial Completion is the stage in the progress of the Work when the Work or
designated portion thereof is sufficiently complete in accordance with the Contract Documents so
the Owner can occupy or utilize the Work for its intended use.
9.7.2 When the Contractor considers that the Work, or a portion thereof which the Owner agrees
to accept separately, is substantially complete, the Contractor and AMEC /Engineer shall jointly
prepare a comprehensive list of items to be completed or corrected. The Contractor shall proceed
promptly to complete and correct items on the list. Failure to include an item on such list does
not alter the responsibility of the Contractor to complete all Work in accordance with the Contract
Documents. Upon receipt of the list, AMEC /Engineer will make an inspection to determine
GENERAL CONDITIONS OF CONTRACT 00750 -Page 44 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
whether the Work or designated portion thereof is substantially complete. If the inspection
discloses any item, whether or not included on the list, which is not in accordance with the
requirements of the Contract Documents, the Contractor shall, before issuance of the Certificate
of Substantial Completion, complete or correct such item upon notification by AMEC /Engineer.
The Contractor shall then submit a request for another inspection by AMEC /Engineer, to
determine Substantial Completion. When the Work or designated portion thereof is substantially
complete, AMEC /Engineer will prepare a Certificate of Substantial Completion, shall establish
responsibilities of the Owner and Contractor for security, maintenance, heat, utilities, damage to
the Work and insurance, and shall fix the time within which the Contractor shall finish all items on
the list accompanying the Certificate. Warranties required by the Contract Documents shall
commence on the date of Substantial Completion of the Work or designated portion thereof unless
otherwise provided in the Certificate of Substantial Completion. The Certificate of Substantial
Completion shall be submitted to the Owner and Contractor for their written acceptance of
responsibilities assigned to them in such Certificate.
9.7.3 Upon Substantial Completion of the Work or designated portion thereof and upon
application by the Contractor and certification by AMEC /Engineer and Sustainability /Projects
Director, the Owner shall make payment, reflecting adjustment in retainage, if any, for such Work
or portion thereof as provided in the Contract Documents.
9.8 Partial Occupancy or Use
9.8.1 The Owner may occupy or use any completed or partially completed portion of the Work
at any stage when such portion is designated by separate agreement with the Contractor,
provided such occupancy or use is consented to by the insurer as required under Subparagraph
11.3.1 and authorized by public authorities having jurisdiction over the Work. Such partial
occupancy or use may commence whether or not the portion is substantially complete, provided
the Owner and Contractor have accepted in writing the responsibilities assigned to each of them
for payments, retainage if any, security, maintenance, heat, utilities, damage to the Work and
insurance, and have agreed in writing concerning the period for correction of the Work and
commencement of warranties required by the Contract Documents. When the Contractor
considers a portion substantially complete, the Contractor and AMEC /Engineer shall jointly
prepare a list as provided under Subparagraph 9.8.2. Consent of the Contractor to partial
occupancy or use shall not be unreasonably withheld. The stage of the progress of the Work
shall be determined by written agreement between the Owner and Contractor or, if no agreement
is reached, by decision of Sustainability /Projects Director.
9.8.2 Immediately prior to such partial occupancy or use, the Owner, Sustainability /Projects
Director, AMEC /Engineer and Contractor shall jointly inspect the area to be occupied or portion
of the Work to be used in order to determine and record the condition of the Work.
9.9.3 Unless otherwise agreed upon, partial occupancy or use of a portion or portions of the
Work shall not constitute acceptance of Work not complying with the requirements of the Contract
Documents.
9.9 Final Completion and Final Payment
9.9.1 Upon completion of the Work, the Contractor shall forward to AMEC /Engineer a written
Notice that the Work is ready for final inspection and acceptance and shall also forward to
AMEC /Engineer a final Contractor's Application for Payment. Upon receipt, AMEC /Engineer will
promptly make such inspection. When AMEC /Engineer finds the Work acceptable under the
GENERAL CONDITIONS OF CONTRACT 00750 -Page 45 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
Contract Documents and the Contract fully performed, AMEC /Engineer will promptly issue a final
Approval for Payment stating that to the best of their knowledge, information and belief, and on
the basis of their observations and inspections, the Work has been completed in accordance with
terms and conditions of the Contract Documents and that the entire balance found to be due the
Contractor and noted in said final Approval is due and payable. AMEC /Engineer's final Approval
for Payment will constitute a further representation that conditions listed in Subparagraph 9.10.2
as precedent to the Contractor's being entitled to final payment have been fulfilled.
9.9.2 Neither final payment nor any remaining retained percentage shall become due until the
Contractor submits to AMEC /Engineer and Sustainability /Projects Director (1) an affidavit that
payrolls, bills for materials and equipment, and other indebtedness connected with the Work for
which the Owner or the Owner's property might be responsible or encumbered (less amounts
withheld by Owner) have been paid or otherwise satisfied, (2) a certificate evidencing that
insurance required by the Contract Documents to remain in force after final payment is made, is
currently in effect and will not be canceled or allowed to expire until at least 30 days' prior written
notice has been given to the Owner, (3) a written statement that the Contractor knows of no
substantial reason that the insurance will not be renewable to cover the period required by the
Contract Documents, (4) consent of surety, if any, to.final payment and (5), if required by the
Owner, other data establishing payment or satisfaction of obligations, such as receipts, releases
and waivers of liens, claims, security interests or encumbrances arising out of the Contract. The
following documents ( samples included in section 1027 are required for Final Payment:
(1) Application and Certificate for Payment
- (2) Continuation Sheet
L (3) Certificate of Substantial Completion
(4) Contractor's Affidavit of Debts and Claims
(5) Contractor's Affidavit of Release of Liens
(6) Final Release of Lien
(7) Contractor shall provide two (2) hard copies in tabulated divided binders and
one (1) saved electronically tabbed and indexed in Adobe Acrobat file (.PDF)
format delivered on a downloadable CD /DVD of all the following but not limited to:
A .Project Record Documents (As Built Documents).
B. Operating and maintenance data, instructions to the Owner's personnel.
C. Warranties, bond and guarantees.
D. Keys and keying schedule.
E. Spare parts and maintenance materials.
F. Electronic copies of approved submittals
G. Evidence of payment and final release of liens and consent of surety to final release
(includes final release from all utilities and utility companies).
GENERAL CONDITIONS OF CONTRACT 00750 -Page 46 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
9.9.3 Acceptance of final payment by the Contractor, a Subcontractor or material supplier shall
constitute a waiver of claims by that payee except those previously made in writing and identified
by that payee as unsettled at the time of final Application for Payment. Such waivers shall be in
addition to the waiver described Subparagraph 4.7.5.
9.10 Payment of Subcontractors
9.10.1 Any requirement of this Article 9 that the Contractor furnish proof to the Owner or
Sustainability /Projects Director that the subcontractors and materialmen have been paid is for the
protection and convenience of the Owner only. Unpaid subcontractors and materialmen may only
seek payment from the Contractor and the surety that provided the Contractor's Public
Construction Bond. The Contractor must insert this paragraph 9.10 in all its contracts with
subcontractors and materialmen.
10.0 PROTECTION OF PERSONS AND PROPERTY
10.1 Safety Precautions and Programs
10.1.1 The Contractor shall be responsible for initiating, maintaining and supervising all safety
precautions and programs in connection with the performance of the Contract. The Contractor
shall submit the Contractor's safety program to AMEC /Engineer for review, approval and
coordination with the safety programs of other Contractors.
10.1.2 In the event the Contractor encounters on the site material reasonably believed to be
asbestos or polychlorinated biphenyl (PCB) which has not been rendered harmless, the
Contractor shall immediately stop Work in the area affected and report the condition to the Owner,
Sustainability /Projects Director and AMEC /Engineer in writing. The Work in the affected area
shall not thereafter be resumed except by written agreement of the Owner and Contractor if in
fact the material is asbestos or polychlorinated biphenyl (PCB) and has not been rendered
harmless. The Work in the affected area shall be resumed in the absence of asbestos or
polychlorinated biphenyl (PCB), or when it has been rendered harmless, by written agreement of
the Owner and Contractor.
10.1.3 The Contractor shall not be required pursuant to Article 7 to perform without consent any
Work relating to asbestos or polychlorinated biphenyl (PCB).
10.1.5 If reasonable precautions will be inadequate to prevent foreseeable bodily injury or death
to persons resulting from a material or substance encountered on the site by the Contractor, the
Contractor shall, upon recognizing the condition, immediately stop Work in the affected area and
report the condition to AMEC /Engineer and Sustainability /Projects Director in writing. The Owner,
Contractor and Sustainability /Projects Director shall then proceed in the same manner described
in Subparagraph 10.1.2.
10. 1.6 The Owner shall be responsible for obtaining the services of a licensed laboratory to verify
a presence or absence of the material or substance reported by the Contractor and, in the event
such material or substance is found to be present, to verify that it has been rendered harmless.
Unless otherwise required by the Contract Documents, the Owner shall furnish in writing to the
Contractor, AMEC /Engineer and Sustainability /Projects Director the names and qualifications of
persons or entities who are to perform tests verifying the presence or absence of such material
or substance or who are to perform the task of removal or safe containment of such material or
substance. The Contractor, AMEC /Engineer and Sustainability /Projects Director will promptly
GENERAL CONDITIONS OF CONTRACT 00750 -Page 47 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
reply to the Owner in writing stating whether or not any of them has reasonable objection to the
persons or entities proposed by the Owner. If the Contractor, AMEC /Engineer or
Sustainability /Projects Director has an objection to a person or entity proposed by the Owner, the
Owner shall propose another to whom the Contractor, AMEC /Engineer and
Sustainability /Projects Director have no reasonable objection.
10.2 Safety of Persons and Property
10.2.1 The Contractor shall take reasonable precautions for safety of, and shall provide
reasonable protection to prevent damage, injury or loss to:
1 employees on the Work and other persons who may be affected thereby;
.2 the Work and materials and equipment to be incorporated therein, whether in storage
on or off the site, under care, custody or control of the Contractor or the Contractor's
Subcontractors or Sub - subcontractors;
.3 other property at the site or adjacent thereto, such as trees, shrubs, lawns, walks,
pavements, roadways, structures and utilities not designated for removal, relocation or
replacement in the course of construction; and
.4 construction or operations by the Owner or other Contractors.
10.2.2 The Contractor shall give notices and comply with applicable laws, ordinances, rules,
regulations and lawful orders of public authorities bearing on safety of persons or property or their
protection from damage, injury or loss.
10.2.3 The Contractor shall erect and maintain, as required by existing conditions and
performance of the Contract, reasonable safeguards for safety and protection, including posting
danger signs and other warnings against hazards, promulgating safety regulations and notifying
owners and users of adjacent sites and utilities.
10.2.4 When use or storage of explosives or other hazardous materials or equipment or unusual
methods are necessary for execution of the Work, the Contractor shall exercise utmost care and
carry on such activities under supervision of properly qualified personnel.
10.2.5 The Contractor shall promptly remedy damage and loss to property referred to in Clauses
10.2.1.2, 10.2.1.3, 10.2.1.4 caused in whole or in part by the Contractor, a Subcontractor, a Sub -
subcontractor, or anyone directly or indirectly employed by any of them, or by anyone for whose
acts they may be liable and for which the Contractor is responsible under Clauses 10.2.1.2,
10.2.1.3 and 10.2.1.4, except damage or loss attributable to acts or omissions of the Owner,
Sustainability /Projects Director or AMEC /Engineer or anyone directly or indirectly employed by
any of them, or by anyone for whose acts any of them may be liable, and not attributable to the
fault or negligence of the Contractor. The foregoing obligations of the Contractor are in addition
to the Contractor's obligations under Paragraph 3.18.
10.2.6 The Contractor shall designate a responsible member of the Contractor's organization at
the site whose duty shall be the prevention of accidents. This person shall be the Contractor's
superintendent unless otherwise designated by the Contractor in writing to the Owner,
AMEC /Engineer or Sustainability /Projects Director.
10.2.7 The Contractor shall not load or permit any part of the construction or site to be loaded so
as to endanger its safety.
GENERAL CONDITIONS OF CONTRACT 00750 -Page 48 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
10.3 Emergencies
10.3.1 In an emergency affecting safety of persons or property, the Contractor shall act, at the
Contractor's discretion, to prevent threatened damage, injury or loss. Additional compensation
or extension of time claimed by the Contractor on account of an emergency shall be determined
as provided in Paragraph 4.7 and Article 7.
10.4 Site Specific Safety Plan
See Section 00970 for minimum requirements of job site safety plan.
11.0 INSURANCE AND BONDS
11.1.1 Prior to commencement of Work governed by this contract (including the pre- staging of
personnel and material), the Contractor shall obtain, at its own expense, insurance as specified
in the schedule set forth in Section 00110 Bid Form which are made part of this Agreement. The
Contractor will ensure that the insurance obtained will extend protection to all subcontractors
engaged by the Contractor. As an alternative the Contractor may require all subcontractors to
obtain insurance consistent with the attached schedules.
11.1.2 The Contractor will not be permitted to commence Work governed by the Agreement
(including pre- staging of personnel and material) until satisfactory evidence of the required
insurance has been furnished to the County as specified below. Delays in the commencement of
Work resulting from the failure of the Contractor to provide satisfactory evidence of the required
insurance shall not extend deadlines specified in this Agreement and any penalties and failure to
perform assessments shall be imposed as if the Work commenced on the specified date and time,
except for the Contractor's failure to provide satisfactory evidence of insurance.
11.1.3 The Contractor. shall maintain the required insurance throughout the entire term of this
contract and any extensions specified in any attached schedules. Failure to comply with this
provision may result in the immediate suspension of all Work until the required insurance has
been reinstated or replaced. Delays in the completion of Work resulting from the failure of the
Contractor to maintain the required insurance shall not extend deadlines specified in this
Agreement and any penalties and failure to perform assessments shall be imposed as if the Work
commenced on the specified date and time, except for the Contractor's failure to provide
satisfactory evidence of insurance.
11.1.4 The Contractor shall provide, to the County in care of Sustainability /Projects Director as
satisfactory evidence of the required insurance, either:
Certificate of Insurance
Or
A certified copy of the actual insurance policy
11.1.5 The County, at its sole option, has the right to request a certified copy of any or all
insurance policies required by this Contract.
GENERAL CONDITIONS OF CONTRACT 00750 -Page 49 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
11.1.6 All insurance policies must specify that they are not subject to cancellation, nonrenewal,
material change, or reduction in coverage unless a minimum of thirty (30) days prior notification
is given to the County by the insurer.
11.1.7 The acceptance and /or approval of the Contractor's insurance shall not be construed as
relieving the Contractor from any liability or obligation assumed under this contract or imposed by
law.
11.1.8 The Monroe County Board of County Commissioners, its employees and officials will be
included as "Additional Insured" on all policies, except for Worker's Compensation.
11.1.9 In addition, the County will be named as an additional insured and loss payee on all
policies covering County -owned property.
11.1.10 Any deviations from these General Insurance Requirements must be requested in writing
on the County prepared form entitled "Request for Waiver of Insurance Requirements" and
approved by the Monroe County's Risk Manager.
11.2 Builder's Risk Insurance: Not Required
11.3 Public Construction Bond
11.3.1 The Owner shall require the Contractor to furnish a Public Construction Bond in the form
provided by the Owner as a guarantee for the faithful performance of the Contract (including
guarantee and maintenance provisions) and the payment of all obligations arising
thereunder. The Public Construction Bond shall be in an amount at least equal to the contract
price. This contract is subject to the provisions of Section 255.05, Florida Statutes, which are
incorporated herein.
12.0 UNCOVERING AND CORRECTION OF WORK
12.1 Uncovering of Work
12.1.1 If a portion of the Work is covered contrary to AMEC /Engineer's request or to requirements
specifically expressed in the Contract Documents, it must, if required in writing by
AMEC /Engineer, be uncovered for their observation and be replaced at the Contractor's expense
without change in the Contract Time.
12.1.2 If a portion of the Work has been covered which AMEC /Engineer has not specifically
requested to observe prior to its being covered, AMEC /Engineer may request to see such Work
and it shall be uncovered by the Contractor, if such Work is in accordance with the Contract
Documents, costs of uncovering and replacement shall, by appropriate Change Order, be
charged to the Owner, if such Work is not in accordance with the Contract Documents, the
Contractor shall pay such costs unless the condition was caused by the Owner or one of the other
Contractors in which event the Owner shall be responsible for payment of such costs.
12.2 Correction of Work
12.2.1 The Contractor shall promptly correct Work rejected by AMEC /Engineer or failing to
conform to the requirements of the Contract Documents, whether observed before or after
Substantial Completion and whether or not fabricated, installed or completed. The Contractor
shall bear costs of correcting such rejected Work, including additional testing and inspections and
compensation for AMEC /Engineer's services and expenses made necessary thereby.
GENERAL CONDITIONS OF CONTRACT 00750 -Page 50 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
12.2.2 If, within one year after the date of Substantial Completion of the Work or designated
portion thereof, or after the date for commencement of warranties established under
Subparagraph 9.9, or by terms of an applicable special warranty required by the Contract
Documents, any of the Work is found to be not in accordance with the requirements of the
Contract Documents, the Contractor shall correct it promptly after receipt of written notice from
the Owner to do so unless the Owner has previously given the Contractor a written acceptance
of such condition. This period of one year shall be extended with respect to portions of Work first
performed after Substantial Completion by the period of time between Substantial Completion
and the actual performance of the Work. This obligation under this Subparagraph 12.2.2 shall
survive acceptance of the Work under the Contract and termination of the Contract. The Owner
shall give such notice promptly after discovery of the condition.
12.2.3 The Contractor shall remove from the site portions of the Work which are not in
accordance with the requirements of the Contract Documents and are neither corrected by the
Contractor nor accepted by the Owner.
12.2.4 If the Contractor fails to correct nonconforming Work within a reasonable time, the Owner
may correct it in accordance with Paragraph 2.4. If the Contractor does not proceed with
correction of such nonconforming Work within a reasonable time fixed by written notice from
AMEC /Engineer, the Owner may remove it and store the salvageable materials or equipment at
the Contractor's expense. If the Contractor does not pay costs of such removal and storage within
ten days after written notice, the Owner may upon ten additional days' written notice sell such
materials and equipment at auction or at private sale and shall account for the proceeds thereof,
after deducting costs and damages that should have been borne by the Contractor, including
- compensation for AMEC /Engineer's services and expenses made necessary thereby. If such
proceeds of sale do not cover costs which the Contractor should have borne, the Contract Sum
shall be reduced by the deficiency. If payments then or thereafter due the Contractor are not
sufficient to cover such amount, the Contractor shall pay the difference to the Owner.
12.2.5 The Contractor shall bear the cost of correcting destroyed or damaged construction,
whether completed or partially completed, of the Owner or other Contractors caused by the
Contractor's correction or removal of Work which is not in accordance with the requirements of
the Contract Documents.
12.2.6 Nothing contained in this Paragraph 12.2 shall be construed to establish a period of
limitation with respect to other obligations which the Contractor might have under the Contract
Documents. Establishment of the time period of one year as described in Subparagraph 12.2.2,
relates only to the specific obligation of the Contractor to correct the Work, and has no relationship
to the time within which the obligation to comply with the Contract Documents may be sought to
be enforced, nor to the time within which proceedings may be commenced to establish the
Contractor's liability with respect to the Contractor's obligations other than specifically to correct
the Work.
12.3 Acceptance of Nonconforming Work
12.3.1 If the Owner prefers to accept Work which is not in accordance with the requirements of
the Contract Documents, the Owner may do so instead of requiring its removal and correction, in
which case the Contract Sum will be reduced as appropriate and equitable. Such adjustment
shall be effected whether or not final payment has been made.
13.0 MISCELLANEOUS PROVISIONS
GENERAL CONDITIONS OF CONTRACT 00750 -Page 51 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
13.1 Governing Law
13.1.1 The contract shall be governed by the laws of the State of Florida. Venue for any claims
or disputes arising under this contract shall be in the Circuit Court of the 16th Judicial Circuit of
the State of Florida.
13.2 Successors and Assigns
13.2.1 The Owner or Sustainability /Projects Director (as the case may be) and the Contractor
each binds himself, his partners, successors, assigns, and legal representatives of such other
party in respect to all covenants, agreements, and obligations contained in the Contract
Documents. Neither party to the Contract shall assign the Contract or sublet it as a whole without
the written consent of the other.
13.2.2 The Contractor shall not assign any monies due or to become due under this Contract
without prior written consent of the Owner or Sustainability /Projects Director.
13.3 Written Notice
13.3.1 Any written notices or correspondence given pursuant to this contract shall be sent by
United States Mail, certified, return receipt requested, or by courier with proof of delivery. Notice
shall be sent to the following persons:
For Contractor: Adventure Environmental Inc.
Attn: Greg Tolpin
12895 Southwest 87th Avenue
Miami, Florida 33176
For Owner: Sustainability /Projects Director
Rhonda Haag
102050 Overseas Highway, Ste. 246
Key Largo, FL 33037
13.4 Rights and Remedies
County Administrator
Roman Gastesi
1100 Simonton St., Ste. 2 -205
Key West, FL 33040
13.4.1 Duties and obligations imposed by the Contract Documents and rights and remedies
available there under shall be in addition to and not a limitation of duties, obligations, rights and
remedies otherwise imposed or available by law.
13.4.2 No action or failure to act by the Owner, Sustainability /Projects Director, AMEC /Engineer
or Contractor shall constitute a waiver of a right or duty afforded them under the contract, nor shall
such action or failure to act constitute approval of or acquiescence in a breach there under, except
as may be specifically agreed in writing.
13.5 Tests and Inspections
13.5.1 Tests, inspections and approvals of portions of the Work required by the Contract
Documents or by laws, ordinances, rules, regulations or orders of public authorities having
jurisdiction shall be made at an appropriate time. Unless otherwise provided, the Contractor shall
make arrangements for such tests, inspections and approvals with an independent testing
laboratory or entity acceptable to the Owner, or with the appropriate public authority, and shall
bear all related costs of tests, inspections and approvals. The Contractor shall give
AMEC /Engineer timely notice of when and where tests and inspections are to be made so
GENERAL CONDITIONS OF CONTRACT 00750 -Page 52 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
AMEC /Engineer may observe such procedures. The Owner shall bear costs of test, inspections
or approvals which do not become requirements until after bids are received or negotiations
concluded.
13.5.2 If AMEC /Engineer, Sustainability /Projects Director, Owner or public authorities having
jurisdiction determine that portions of the Work require additional testing, inspection or approval
not included under Subparagraph 13.5.1, AMEC /Engineer will, upon written authorization from
the Sustainability /Projects Director or Owner, instruct the Contractor to make arrangements for
such additional testing, inspection or approval by an entity acceptable to the Owner, and the
Contractor shall give timely notice to AMEC /Engineer of when and where tests and inspections
are to be made so AMEC /Engineer may observe such procedures. The Owner shall bear such
costs except as provided in Subparagraph 13.5.3.
13.5.3 If such procedures for testing, inspection or approval under Subparagraphs 13.5.1 and
13.5.2 reveal failure of the portions of the Work to comply with requirements established by the
Contract Documents, the Contractor shall bear all costs made necessary by such failure including
those of repeated procedures and compensation for AMEC /Engineer's services and expenses.
13.5.4 Required certificates of testing, inspection or approval shall, unless otherwise required by
the Contract Documents, be secured by . the Contractor and promptly delivered to
AMEC /Engineer.
13.5.5 If AMEC /Engineer is to observe tests, inspections or approvals required by the Contract
Documents, AMEC /Engineer will do so promptly and, where practicable, at the normal place of
testing.
-- 13.5.6 Test or inspections conducted pursuant to the Contract Documents shall be made
promptly to avoid unreasonable delay in the Work.
13.7 Commencement of Statutory Limitation Period
13.7.1 The statute of limitations applicable to this contact are as provided in Section 95.11 (3)
(C), Florida Statutes.
14.0 TERMINATION OR SUSPENSION OF THE CONTRACT
14.1 Termination by the Owner for Cause
14.1.1 The Owner may terminate the Contract if the Contractor:
.1 persistently or repeatedly refuses or fails to supply enough properly skilled workers or
proper materials;
.2 fails to make payment to Subcontractors for materials or labor in accordance with the
respective agreements between the Contractor and the Subcontractors;
.3 persistently disregards laws, ordinances, or rules, regulations or orders of a public
authority having jurisdiction;
or
.4 Otherwise is guilty of substantial breach of a provision of the Contract Documents.
GENERAL CONDITIONS OF CONTRACT 00750 -Page 53 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
14.1.2 When any of the above reasons exist, the Owner, after consultation with AMEC /Engineer„
` and upon certification by Sustainability /Projects Director that sufficient cause exists to justify such
action, may without prejudice to any other rights or remedies of the Owner and after giving the
Contractor and the Contractor's surety, if any, 72 hours written notice, terminate employment of
the Contractor and may, subject to any prior rights of the surety:
.1 take possession of the site and of all materials, equipment, tools, and construction
equipment and machinery thereon owned by the Contractor;
.2 accept assignment of subcontracts pursuant to Paragraph 5.4; and
.3 finish the Work by whatever reasonable method the Owner may deem expedient.
14.1.3 When the Owner terminates the Contract for one of the reasons stated in Subparagraph
14.1.1, the Contractor shall not be entitled to receive further payment until the Work is finished.
14.2 Suspension or Termination by the Owner for Convenience
14.2.1 The Owner may, without cause, order the Contractor in writing to terminate; suspend,
delay or interrupt the Work in whole or in part for such period of time as the Owner may determine.
14.2.2 In the event of Termination. the Owner shall pay for work completed to date of Termination.
GENERAL CONDITIONS OF CONTRACT 00750 -Page 54 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
SECTION 00970 - PROJECT SAFETY AND HEALTH PLAN
REGULATIONS AND POLICIES
A. Every Contractor and Subcontractor employed on the Project shall comply with all
applicable local, State, and Federal safety and health regulations and with Monroe County safety
and health policies as described herein.
The Contractor shall comply with OSHA (Occupational Safety and Health Administration) Parts
1910 and 1926, Construction Industry Standards and Interpretations, and with this supplement.
Requests for variances or waiver from this supplement are to be made to the Contracting Officer
in writing supported by evidence that every reasonable effort has been made to comply with the
contractual requirements. A written request for a waiver or a variance shall include- -
(1) Specific reference to the provision or standard in question;
(2) An explanation as to why the waiver is considered justified; and
(3) The Contractor's proposed alternative, including technical drawings, materials, or equipment
specifications needed to enable the Contracting Officer to render a decision.
No waiver or variance will be approved if it endangers any person. The Contractor shall not
proceed under any requested revision of provision until the Contracting Officer has given written
approval. The Contractor is to hold and save harmless Monroe county Florida free from any claims
or causes of action whatsoever resulting from the Contractor or subcontractors proceeding under
a waiver or approved variance.
Copies of OSHA Parts 1910 and 1926, Construction Industry Standards and Interpretations, may
be obtained from:
U.S. Government Printing Office Bookstore
710 North Capitol Street N.W.
Washington, DC
http: / /www.gpo.gov /about/bookstore.htm
GENERAL CONTRACTOR REQUIREMENTS
SAFETY PROGRAM
Each Contractor and sub - contractor is to demonstrate that he or she has facilities for conducting
a safety program commensurate with the work under contract. The Contractor is to submit in
writing a proposed comprehensive site specific safety program for approval to the Contracting
Officer for Monroe County before the start of construction operations.
The program is to specifically state what provisions the Contractor proposes to take for the health
and safety of all employees, including subcontractors and rental equipment operators. The
PROJECT SAFETY AND HEALTH PLAN 00970 -Page 55 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
program shall be site specific and provide details relevant to the work to be done, the hazards
associated with the work, and the actions that will be necessary to minimize the identified hazards.
The Safety Program will also be required to provide emergency contact person, emergency
planning and a personnel evacuation plan for any hurricane evacuation event.
1.2 PRECONSTRUCTION SAFETY MEETING
Representatives for the Contractor are to meet with the Contracting Officer (CO) or the CO's
representative before the start of construction to discuss the safety program and the
implementation of all health and safety standards pertinent to the work under this contract.
1.3 JOINT SAFETY POLICY COMMITTEE
The Contractor or designated on -site representative is to participate in monthly meetings of a joint
Safety Policy Committee with AMEC /Engineer and Contractor supervisory personnel. At these
meetings the Contractor's project manager and the Contracting Officer will review the
effectiveness of the Contractor's safety effort, resolve current health and safety problems, and
coordinate safety activities for upcoming work.
1.4 SAFETY PERSONNEL
Each Contractor is to designate a competent supervisory employee satisfactory to the Contracting
Officer to administer the safety program.
The Mandatory Safety and Health Rules shall be posted in a conspicuous location along with the
OSHA and Emergency Phone Number posters.
1.5 SAFETY MEETINGS
A minimum of one "on- the -job" or "toolbox" safety meeting is to be conducted each week by all
field supervisors or foremen and attended by mechanics and all construction personnel at the
jobsite.
The Contractor is to also conduct regularly scheduled supervisory safety meetings at least
monthly for all levels of job supervision.
Each Contractor and Subcontractor shall be expected to indoctrinate his employees as to the
safety and health requirements of this project and to enforce adherence to safe work procedures.
Each Contractor and Subcontractor shall cooperate fully with all other contractors in their
respective safety and health programs.
1.6 SAFETY INSPECTION
The Contractor shall perform frequent and regular safety inspections of the jobsite, materials, and
equipment, and shall correct deficiencies.
PROJECT SAFETY AND HEALTH PLAN 00970 -Page 56 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
Good housekeeping shall be observed at all times. Waste, debris, and garbage shall be removed
daily or placed in appropriate waste containers. All materials, tools, and equipment shall be stored
in a safe and orderly fashion. Each contractor shall donate 10% of their staff to a crew that will
convene every Friday at 1:00 pm for a joint site clean -up effort not to exceed duration of three
hours.
In summary, there will be a three -part clean -up plan.
1. The first part consists of the contractor cleaning up on a daily basis, his workstations, and his
trade work.
2. The second part consists of the general clean -up, the concerted effort by all trade contractors
working on the project. A minimum of one (1) crew is to be utilized by each contractor, or
10 %, whichever is more.
3. The third part consists of the Owner cleaning up for a particular trade contractor should
adequate notice not compel him to clean up his work. In this case, the appropriate contractors
will be back charged.
Shortly after the award of the contract and prior to the beginning of work, an Activity Hazard
Analysis (phase plan) shall be prepared by the contractor and submitted to Monroe County for
approval. The analysis will address the hazards for each activity to be performed in that phase
and will present the procedures and safeguards necessary to eliminate the hazards or reduce the
risk to an acceptable level. A phase is defined as an operation involving a type of work presenting
hazards not experienced in previous operations or where a new subcontractor or work crew is to
perform work. The analysis will be discussed by the contractor and Monroe County on -site
representatives at the Preparatory Inspection Meeting. Work will not proceed on that phase until
the Activity Hazard Analysis (phase plan) has been accepted by Monroe County.
If Monroe County notifies any Contractor of any noncompliance with the provisions of this
program, the Contractor shall make all reasonable efforts to immediately correct the unsafe
conditions or acts. Satisfactory corrective action shall be taken within the specified time. If the
Contractor or Subcontractor refuses to correct unsafe or unhealthy conditions or acts, Monroe
County shall take one or more of the following steps:
a. Cease the operation or a portion thereof.
b. Stop payment for the work being performed.
c. Correct the situation using other forces and back charge the Contractor expenses
incurred.
d. Increase withholding in proportional increments for that given pay period.
1.7 FIRST AID TRAINING
Every Contractor foreman's work crew must include an employee who has a current first aid
certificate from the, American Red Cross, or other Monroe County- approved organization.
PROJECT SAFETY AND HEALTH PLAN 00970 -Page 57 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
1.8 REPORTS
Each Contractor is to maintain an accurate record of all job - related deaths, diseases, or disabling
injuries. The records shall be maintained in a manner approved by the Contracting Officer. A copy
of all reports is to be provided to the Contracting Officer.
All fatal or serious injuries are to be reported immediately to the Contracting Officer, and every
assistance is to be given in the investigation of the incident, including submission of a
comprehensive narrative report to the Contracting Officer. Other occurrences with serious
accident potential, such as equipment failures, slides, and cave -ins, must also be reported
immediately.
The Contractor is to assist and cooperate fully with the Contracting Officer in conducting accident
investigations. The Contracting Officer is to be furnished all information and data pertinent to
investigation of an accident.
1.9 CERTIFICATION OF INSURANCE
Contractors are to provide the Contracting Officer or his or her authorized representative with
certificates of insurance before the start of operations indicating full compliance with State
Worker's Compensation statutes, as well as other certificates of insurance required under the
contract.
2.0 FIRST AID AND MEDICAL FACILITIES
2.1 FIRST AID KITS
A 16 -unit first aid kit approved by the American Red Cross is to be provided at accessible, well -
identified, locations at the ratio of at least 1 kit for each 25 employees. The first aid kits are to be
moisture proof and dust tight, and the contents of the kits are to be replenished as used or as
they become ineffective or outdated.
2.2 EMERGENCY FIRST AID
At least one employee certified to administer emergency first aid must be available on each shift
and duly designated by the Contractor to care for injured employees. The names of the certified
employees shall be posted at the jobsite.
2.1 COMMUNICATION AND TRANSPORTATION
Prior to the start of work, the Contractor is to make necessary arrangements for prompt and
dependable communications, transportation, and medical care for injured employees.
2.2 FIRST AID AND MEDICAL REPORTS
The Contractor is to maintain a record system for first aid and medical treatment on the jobsite.
Such records are to be readily available to the Contracting Officer and are to include --
PROJECT SAFETY AND HEALTH PLAN 00970 -Page 58 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
(a) A daily treatment log listing chronologically all persons treated for occupational injuries and
illnesses;
(b) Cumulative record of injury for each individual;
(c) Monthly statistical records of occupational injuries, classified by type and nature of injury; and
(d) Required records for worker's compensation.
2.5 SIGNS AND DIRECTIONAL MARKINGS
Adequate identification and directional markers are to be provided to readily denote the location
of all first aid stations.
2.3 EMERGENCY LISTING
A listing of telephone numbers and addresses of doctor, rescue squad, hospital, police, and fire
departments is to be provided at all first aid locations.
3.0 PHYSICAL QUALIFICATIONS OF EMPLOYEES:
3.1 GENERAL REQUIREMENTS
Persons employed throughout the contract are to be physically qualified to perform their assigned
f . -- duties. Employees must, not knowingly be permitted or required to work while their ability or
alertness is impaired by fatigue, illness, or any other reason that may jeopardize themselves or
others.
No personal radios or stereos will be allowed on the job -site.
3.2 HOIST OPERATORS
Operators of cranes, cableways, and other hoisting equipment shall be examined annually by a
physician and provided with a certification stating that they are physically qualified to safely
operate hoisting equipment. The Contractor is to submit a copy of each certification to the
Contracting Officer.
3.3 HEAVY EQUIPMENT OPERATORS
It is recommended that operators of trucks and heavy construction equipment be given physical
examinations to determine if they are physically qualified to perform their assigned work without
endangering themselves or others.
3.4 MOTOR VEHICLE OPERATORS
Operators of motor vehicles engaged primarily in the transportation of personnel are to be 18
years of age or older and have a valid state operator's permit or license for the equipment being
operated. The operators must have passed a physical examination administered by a licensed
physician within the past year showing that they are physically qualified to operate vehicles safely.
PROJECT SAFETY AND HEALTH PLAN 00970 -Page 59 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
4.0 PERSONAL PROTECTIVE EQUIPMENT:
4.1 HARDHAT AREAS
The entire jobsite, with the exception of offices, shall be considered a hardhat area. All persons
entering the area are, without exception, required to wear hardhats. The Contractor shall provide
hardhats for visitors entering hardhat areas.
4.1.1 LABELS
Hardhats shall bear a manufacturer's label indicating design compliance with the appropriate
ANSI (American National Standards Institute) standard.
4.2 POSTING
Signs at least 3 by 4 feet worded as follows with red letters (minimum 6 inches high) and white
background shall be erected at access points to designated hardhat areas:
CONSTRUCTION AREA - HARDHATS REQUIRED BEYOND THIS POINT
These signs are to be furnished and installed by the Contractor at entries to shops, construction
yards, and job access points.
4.3 SAFETY GOGGLES (DRILLERS)
4.3.1 DRILLERS AND HELPERS.
Drillers and helpers operating pneumatic rock drills /concrete saws must wear protective safety
goggles.
5.0 MACHINERY AND MECHANIZED EQUIPMENT:
5.1 SAFE CONDITION
Before any machinery or mechanized equipment is initially used on the job, it must be inspected
and tested by qualified personnel and determined to be in safe operating condition and
appropriate for the intended use. Operators shall inspect their equipment prior to the beginning of
each shift. Any deficiencies or defects shall be corrected prior to using the equipment. Safety
equipment, such as seatbelts, installed on machinery is to be used by equipment operators.
5.2 TAGGING AND LOCKING
The controls of power- driven equipment under repair are to be locked. An effective lockout and
tagging procedure is to be established, prescribing specific responsibilities and safety procedures
to be followed by the person or persons performing repair work. Mixer barrels are to be securely
locked out before permitting employees to enter them for cleaning or repair.
PROJECT SAFETY AND HEALTH PLAN 00970 -Page 60 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
5.3 HAUL ROADS FOR EQUIPMENT
5.3.1 ROAD MAINTENANCE
The Contractor shall maintain all roadways, including haul roads and access roads, in a safe
condition so as to eliminate or control dust and ice hazards. Wherever dust is a hazard, adequate
dust - laying equipment shall be available at the jobsite and utilized to control the dust.
5.3.2 SINGLE -LANE HAUL ROADS
Single -lane haul roads with two -way traffic shall have adequate turnouts. Where turnouts are not
practical, a traffic control system shall be provided to prevent accidents.
5.3.3 TWO -WAY HAUL ROADS
On two -way haul roads, arrangements are to be such that vehicles travel on the right side
wherever possible. Signs and traffic control devices are to be employed to indicate clearly any
variations from a right -hand traffic pattern. The road shall be wide enough to permit safe passage
of opposing traffic, considering the type of hauling equipment used.
5.3.4 DESIGN AND CONSTRUCTION OF HAUL ROADS
Haul road design criteria and drawings, if requested by the Contracting Officer, are to be submitted
for approval prior to road construction. Sustained grades shall not exceed 12 percent and all
curves shall have open -sight line with as great a radius as practical. All roads shall be posted with
" curve signs and maximum speed limits that will permit the equipment to be stopped within one -
half the minimum sight distance.
5.3.5 OPERATORS.
Machinery and mechanized equipment shall be operated only by authorized qualified persons.
5.3.6 RIDING ON EQUIPMENT
Riding on equipment by unauthorized personnel is prohibited. Seating and safety belts shall be
provided for the operator and all passengers.
5.3.7 GETTING ON OR OFF EQUIPMENT
Getting on or off equipment while the equipment is in motion is prohibited.
5.3.8 HOURS OF OPERATION.
Except in emergencies, an equipment operator shall not operate any mobile or hoisting equipment
for more than 12 hours without an 8 -hour rest interval away from the job.
5.4 POWER CRANES AND HOISTS (TRUCK CRANES, CRAWLER CRANES, TOWER
- . CRANES, GANTRY CRANES, HAMMERHEAD CRANES, DERRICKS, CABLEWAYS, AND
HOISTS)
PROJECT SAFETY AND HEALTH PLAN 00970 -Page 61 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
( 5.4.1 PERFORMANCE TEST
Before initial onsite operation, at 12 -month intervals, and after major repairs or modification,
power cranes, derricks, cableways, and hoists must satisfactorily complete a performance test to
demonstrate the equipment's ability to safely handle and maneuver the rated loads. The tests
shall be conducted in the presence of a representative of the Contracting Officer. Test data shall
be recorded and a copy furnished the Contracting Officer.
5.4.2 PERFORMANCE TEST —POWER CRANES (Crawler mounted, truck mounted and wheel
mounted)
The performance test is to be carried out as per ANSI requirements. The test is to consist of
raising, lowering, and braking the load and rotating the test load through 360 degrees at the
specified boom angle or radius. Cranes equipped with jibs or boom -tip extensions are to be tested
using both the main boom and the jib, with an appropriate test load in each case.
5.4.3 PERFORMANCE TEST — DERRICKS, GANTRY CRANES, TOWER CRANES,
CABLEWAYS, AND HOISTS, INCLUDING OVERHEAD CRANES
This equipment is to be performance tested as per ANSI requirements.
5.4.4 BOOM ANGLE INDICATOR
Power cranes (includes draglines) with booms capable of moving in the vertical plane shall be
provided with a boom angle indicator in good working order.
5.4.5 CRANE TEST CERTIFICATION.
The performance test required by 5.4.2 and 5.4.3- is fulfilled if the Contractor provides the
Contracting Officer a copy of a certificate of inspection made within the past 12 months by a
qualified person or by a government or private agency satisfactory to the Contracting Officer.
5.4.6 POSTING FOR HIGH VOLTAGE LINES
A notice of the 10 -foot (or greater) clearance required by OSHA 1926.550, Subpart N, shall be
posted in the operator's cab of cranes, shovels, boom -type concrete pumps, backhoes, and
related equipment.
5.4.7 BOOM STOPS
Cranes or derricks with cable- supported booms, except draglines, shall have a device attached
between the gantry of the A -frame and the boom chords to limit the elevation of the boom. The
device shall control the vertical motions of the boom with increasing resistance from 83 or less,
until completely stopping the boom at not over 87 above horizontal.
5.4.8 SAFETY HOOKS
PROJECT SAFETY AND HEALTH PLAN 00970 -Page 62 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
Hooks used in hoisting personnel or hoisting loads over construction personnel or in the
immediate vicinity of construction personnel shall be forged steel equipped with safety keepers.
When shackles are used under these conditions, they shall be of the locking type or have the pin
secured to prohibit turning.
5.5.1 ROLLOVER PROTECTIVE STRUCTURES
OSHA 1926, Subpart W, Overhead Protection, Sections 1001 and 1002 are applicable regardless
of the year in which the equipment was manufactured and regardless of the struck capacity of the
equipment.
5.5.2 EQUIPMENT REQUIRING ROPS
The requirement for ROPS meeting 5.5.1 above applies to crawler and rubber -tired tractors such
as dozers, push- and -pull tractors, winch tractors, tractors with backhoes, and mowers; off-
highway, self - propelled, pneumatic -tired earthmovers, including scrapers, motor graders and
loaders; and rollers, compactors, water tankers (excluding trucks with cabs). These requirements
shall also apply to agricultural and industrial tractors and similar equipment.
5.5.3 EQUIPMENT REQUIRING SEATBELTS
The requirements for seatbelts as specified in OSHA Subpart 0, Motor Vehicles, Mechanized
Equipment, and Marine Operations, Section 1926.602 shall also apply to self - propelled
compactors and rollers, and rubber -tired skid -steer equipment.
5.6 LIFT PLAN
A Crane Lift or concrete boom truck Plan is required for any crane lift on a Monroe County project.
Lifts exceeding 75% of the cranes stability / structural capacity chart, requiring movement of a
crane carriage with the load, personnel platforms, sensitive loads (long lead time, cost), loads
requiring two (or more) hooks, work over occupied facilities or work involving encroachment on
public rights of way are considered critical. These lifts must be authorized in advance.
Critical crane lift plans, if authorized, may have to be reviewed by a professional engineer
(the contractor shall budget the PE review within project budget). Additionally, a critical lift
JHA shall be submitted with the crane lift plan.
Crane Lift Plans must be submitted at least 48 hours (2 business days) prior to mobilization — 5
days for critical and helicopter lifts.
Crane Lift Plans must be based on "worst case" combination of load weight with chart deductions
and lift radius for a specific crane configuration in a specific location.
The Crane Lift Plan may be valid for more than one day, as long as the configuration, location,
maximum expected load, and maximum expected radius does not change. Use multiple lift plans
for multiple locations.
PROJECT SAFETY AND HEALTH PLAN 00970 -Page 63 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
The Crane Lift Plan must be COMPLETE along with attachments — see Section 5 for the required
Attachments.
All rigging devices MUST bear the name of the manufacturer and be certified as to their capacity.
Custom - fabricated devices (lifting beams, spreader bars, etc.) may be acceptable with proper PE
stamp or proof testing as required by applicable standards. Capacities shall be marked and legible
on all such devices.
Work that is not anticipated in the Crane Lift Plan, but may arise due to site conditions (moving
equipment, loading materials onto floors, etc.) must be reviewed with Monroe County prior to
hoisting. Changes affecting crane configuration and / or location may require the Crane Lift Plan
to be amended.
The contractor is responsible to visit the site prior to the lift date to review documentary information
pertaining to the site, which is maintained by Monroe County.
The contractor is responsible (determining adequacy, supplying and installing) for all supporting
material (as defined within 29 CFR 1926.1402) necessary for the crane lift.
The contractor is responsible to obtain all information that is necessary to develop a power line
safety plan.
The contractor is responsible to train all personnel involved in the Assembly / Disassembly and
or Crane Lift.
The contractor must provide the following information along with the Crane Lift Plan:
• Competent / Qualified Person Designation Forms for A/D Director, Operator, Rigger,
Signal Person
• Load Chart (complete with notes)
• Range Chart
• Dimension Illustration and Specifications for Crane
• Lightning and Wind Restrictions (from operators manual)
• Area (Quadrant) of Operation Diagram
• Operators License, Operators Training Information, USDOT Medical Certification, OSHA
10/30 Hour Course Completion Cards, as may be required by the project.
• Jurisdictional Registration, if required
• JHA for Assembly / Disassembly of Crane, Severe Weather, Truck Load / Unload, Etc.
• JHA for Power Line Encroachment
• 3rd Party Inspection Certification and Report — see Crane Lift Plan for requirements (Note:
The inspector shall be certified with the CCAA).
• Weights of Materials
• Rigging Plan
• Logistics Plan
PROJECT SAFETY AND HEALTH PLAN 00970 -Page 64 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
The contractor shall comply with the Site Specific Safety Plan.
The contractor / Crane Company / Rigging Company is responsible for the accuracy of plan and
inspections. This planning process has been established to help ensure proper coordination
between Contractor, subcontractors and Monroe County.
No warranty or certification of the suitability of this plan is accepted by Monroe County. It is the
responsibility of the Contractor /Subcontractor and the Crane Operator to ensure that they and
their employees are qualified, competent, properly equipped and properly trained to perform the
activities outlined in this plan.
6.0 LADDERS AND SCAFFOLDING:
6.1 LADDERS.
OSHA 1926, Subpart L - Section 450. Ladders shall be used as work platforms only when use of
small hand tools or handling of light material is involved. No work requiring lifting of heavy
materials or substantial exertion shall be done from ladders.
6.2 SCAFFOLDING. OSHA 1926, Subpart L - Section 451
Scaffolds, platforms or temporary floors shall be provided for all work except that which can be
done safely from the ground or similar footing.
-- 6.3 SAFETY BELTS, LIFELINE, AND LANYARDS. OSHA 1926, Subpart E, Section 104
Lifelines, safety belts and lanyards independently attached or attended, shall be used when
performing such work as the following when the requirements of 6.1 or 6.2 above cannot be met.
(a) Work on stored material in hoppers, bins, silos, tanks, or other confined spaces.
(b) Work on hazardous slopes, structural steel, or poles; erection or dismantling of safety nets,
tying reinforcing bars; and work from Boatswain's chairs, swinging scaffolds, or other unguarded
locations at elevations greater than 6 feet.
(c) Work on skips and platforms used in shafts by crews when the skip or cage does not block
the opening to within 1 foot of the sides of the shaft, unless cages are provided.
7.0 FIRE PROTECTION
A.. Every Contractor and Subcontractor employed on the Project shall exercise good
construction practices to prevent fire. It shall be the responsibility of the Contractor to insure that
general fire protection facilities are adequate for his work and to provide additional fire protection
facilities and devices, including fire extinguishers as required by their scope of work.
8.0 WORK NEAR ENERGIZED ELECTRICAL LINES OR OTHER UTILITIES
A. It shall be the Contractor's sole and exclusive responsibility:
PROJECT SAFETY AND HEALTH PLAN 00970 -Page 65 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
(a) To provide personnel capable of working adjacent to energized electrical lines or other utilities
(b) To provide adequate, safe and properly maintained equipment
(c) To conduct all of his work in accordance with the safety rules and regulations prescribed by
the National Electric Code, National Electric Safety Code, H30, and Safety Rules for Installation
and Maintenance of Electrical Supply and Communication Lines Hand Book 81, Occupational
Safety and Health Act of 1970, as well as other safety codes in effect at the site of construction
and as specified elsewhere herein, or as are generally applicable to the type of work being
performed
(d) To continuously supervise and inspect the work being performed to assure that the
requirements of (a), (b), and (c) above are complied with, and nothing in these Contract
Documents shall be held to mean that any such responsibility is the obligation of the Owner or
AMEC /Engineer or Sustainability /Projects Director.
9.0 BARRICADES, WARNING DEVICES AND LIGHTING
A. The Contractor shall be solely responsible for providing temporary ladders, guard rails,
warning signs, barricades, night guard lights, and deck or floor closures required in connection
with his work to comply with Federal, State and local safety requirements. The Contractor shall
be solely and exclusively responsible for the design, construction, inspection and maintenance of
such facilities at all times.
B. It shall be the responsibility of the Contractor to provide additional temporary lighting, if
needed to maintain safe conditions.
C. It shall be the sole and exclusive responsibility of the Contractor to provide a safe place to
work for all laborers and mechanics and other persons employed on or in connection with the
project, and nothing in these Contract Documents shall be construed to give any of such
responsibility to the Owner, AMEC /Engineer, or Sustainability /Projects Director.
D. The Contractor shall provide a security fence around the area of the Work so as to prevent
entry into the Work area by unauthorized personnel and the general public. The fence shall have
fence post bases that eliminate the need to penetrate the ground for support.
10.0 HAZARDOUS MATERIALS
10.1 In the event the Contractor encounters on the site material reasonably believed to be
asbestos or polychlorinated biphenyl (PCB) which has not been rendered harmless, the
Contractor shall immediately stop Work in the area affected and report the condition to the Owner,
Sustainability /Projects Director, and AMEC /Engineer in writing. The Work in the affected area
shall not thereafter be resumed except by written agreement of the Owner and Contractor if in
fact the material is asbestos or polychlorinated biphenyl (PCB) and has not been rendered
harmless. The Work in the affected area shall be resumed in the absence of asbestos or
polychlorinated biphenyl (PCB), or when it has been rendered harmless, by written, agreement of
the Owner and Contractor.
PROJECT SAFETY AND HEALTH PLAN 00970 -Page 66 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
(/ 10.1.1 The Contractor shall not be required pursuant to Article 7 to perform without
consent any Work relating to asbestos or polychlorinated biphenyl (PCB).
10.1.2 If reasonable precautions will be inadequate to prevent foreseeable bodily injury
or death to persons resulting from a material or substance encountered on the site by the
Contractor, the Contractor shall,, upon recognizing the condition, immediately stop Work in the
affected area and report the condition to AMEC /Engineer and Sustainability /Projects Director in
writing. The Owner, Contractor and Sustainability /Projects Director shall then proceed in the
same manner described in Subparagraph 10.1
10.1.3 The Owner shall be responsible for obtaining the services of a licensed laboratory
to verify a presence or absence of the material or substance reported by the Contractor and, in
the event such material or substance is found to be present, to verify that it has been rendered
harmless. Unless otherwise required by the Contract Documents, the Owner shall furnish in
writing to the Contractor, AMEC /Engineer and Sustainability /Projects Director the names and
qualifications of persons or entities who are to perform tests verifying the presence or absence of
such material or substance or who are to perform the task of removal or safe containment of such
material or substance. The Contractor, AMEC /Engineer and Sustainability /Projects Director will
promptly reply to the Owner in writing stating whether or not any of them has reasonable objection
to the persons or entities proposed by the Owner. If the Contractor, AMEC /Engineer or
Sustainability /Projects Director has an objection to a person or entity proposed by the Owner, the
Owner shall propose another to whom the Contractor, AMEC /Engineer and
Sustainability /Projects Director have no reasonable objection.
10.2 Safety of Persons and Property
10.2.1 The Contractor shall take reasonable precautions for safety of, and shall provide
reasonable protection to prevent damage, injury or loss to:
.1 employees on the Work and other persons who may be affected thereby;
.2 The Work and materials and equipment to be incorporated therein, whether in storage
on or off the site, under care, custody or control of the Contractor or the Contractor's
Subcontractors or Sub - subcontractors;
.3 other property at the site or adjacent thereto, such as trees, shrubs, lawns, walks,
pavements, roadways, structures and utilities not designated for removal, relocation or
replacement in the course of construction; and
.4 construction or operations by the Owner or other Contractors
10.2.2 The Contractor shall give notices and comply with applicable laws, ordinances, rules,
regulations and lawful orders of public authorities bearing on safety of persons or property or their
protection from damage, injury or loss.
10.2.3 The Contractor shall erect and maintain, as required by existing conditions and
performance of the Contract, reasonable safeguards for safety and protection, including posting
danger signs and other warnings against hazards, promulgating safety regulations and notifying
owners and users of adjacent sites and utilities.
10.2.4 When use or storage of explosives or other hazardous materials or equipment or unusual
methods are necessary for execution of the Work, the Contractor shall exercise utmost care and
carry on such activities under supervision of properly qualified personnel.
PROJECT SAFETY AND HEALTH PLAN 00970 -Page 67 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
10.2.5 The Contractor shall promptly remedy damage and loss to property referred to in Clauses
10:2.1.2, 10.2.1.3, 10.2.1.4 caused in whole or in part by the Contractor, a Subcontractor, a Sub -
subcontractor, or anyone directly or indirectly employed by any of them, or by anyone for whose
acts they may be liable and for which the Contractor is responsible under Clauses 10.2.1.2,
10.2.1.3 and 10.2.1.4, except damage or loss attributable to acts or omissions of the Owner,
Sustainability /Projects Director or AMEC /Engineer or anyone directly or indirectly employed by
any of them, or by anyone for whose acts any of them may be liable, and not attributable to the
fault or negligence of the Contractor. The foregoing obligations of the Contractor are in addition
to the Contractor's obligations under Paragraph 3.18.
10.2.6 The Contractor shall designate a responsible member of the Contractor's organization at
the site whose duty shall be the prevention of accidents. This person shall be the Contractor's
superintendent unless otherwise designated by the Contractor in writing to the Owner or
Sustainability /Projects Director.
10.2.7 The Contractor shall not load or permit any part of the construction or site to be loaded so
as to endanger its safety.
11.0 EMERGENCIES
11.1 In an emergency affecting safety of persons or property, the Contractor shall act, at the
Contractor's discretion, to prevent threatened damage, injury or loss. Additional compensation
or extension of time claimed by the Contractor on account of an emergency shall be determined
as provided in Paragraph 4.7 and Article 7
END SECTION 00970
PROJECT SAFETY AND HEALTH PLAN 00970 -Page 68 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
SECTION 00980 - CONTRACTOR QUALITY CONTROL PLAN
1.1 AMEC /Engineer DUTIES AND RESPONSIBILITIES
A. AMEC /Engineer will monitor all work performed by the Contractor and assist the
Contractor with his conformance of the work to the Contract Drawings and
Specifications.
1.2 CONTRACTOR'S DUTIES AND RESPONSIBILITIES
A. The Contractor is responsible for the quality of the work performed by his work
force on this project as well as the quality of the material, equipment and supplies
furnished by him to be incorporated into the work.
B. The Contractor will provide a Quality Control Plan for approval and designate a
Quality Control Representative who will be on site at all times while the respective
Contractor's work is in progress and will have the authority and responsibility to
accept or reject items of work. The Contractor's Quality Control Representative
may delegate his duties but the primary responsibility and authority will rest on him.
C. The Contractor's Quality Control Representative will coordinate the submittal of all
shop drawings, product data and samples to AMEC /Engineer. Any submittal that
is at variance to the contract requirements must be identified as such and
transmitted to AMEC /Engineer for submittal and approval by the Owner. No work
requiring submittal of a shop drawing, product data or sample shall commence until
the submittal has been reviewed and approved by AMEC /Engineer.
D. The Contractor will bear the responsibility of scheduling all required testing and
inspections by the designated material- testing laboratory, in a timely fashion, to
prevent needless cancellations and delays of work activities. Any costs caused by
untimely notification shall be borne by the Contractor.
E. The Contractor's Quality Control Representative will review his drawings,
procurement documents and contracts to insure that the technical information
provided and all work performed is in accordance with the latest revisions of the
Contract Drawings and Specifications.
F. The Contractor's Quality Control Representative will perform an inspection upon
receipt at the site of the work of all materials, equipment and supplies including
those furnished to him by the Owner. Notes from this inspection will be filled out
on the appropriate form and included with the Contractor Daily Quality Control
Report. Items which are damaged or not in conformance with the respective
submittals, quality standards, contract drawings and specifications shall be
brought to the attention of Monroe County representative AMEC /Engineer on site
and then will be identified and segregated from accepted items. Items thus
identified will not be incorporated into the work until corrective action acceptable
to AMEC /Engineer is completed. Items determined unsalvageable will be removed
from the job site. These items shall be noted as deficient in the applicable section
of the Contractor Daily Quality Control Report.
CONTRACTOR QUALITY CONTROL PLAN 00980 -Page 69 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
1.3 INSPECTION AND TESTING
A. INSPECTION PLAN
Sustainability /Projects Director utilizes a multi -point inspection plan for each
separate feature of work to be performed under this Contract, i.e., work described
by each division of the technical provision section of the contract specifications.
This plan consists of the following:
1. Preparatory Inspection —Prior to commencing the work, the Contractor's
Quality Control Representative will meet with Sustainability /Projects
Director's representative AMEC /Engineer and check the following items at
a minimum for conformance:
(a)
(b)
(c)
(d)
(e)
(f)
(g)
(h)
Approval of shop drawings and submittals.
Approval of inspection and test reports of materials and equipment
to be utilized.
Completion of previous operations of preliminary work.
Availability of materials and equipment required.
Potential utility outages.
Any other preparatory steps dependent upon the particular
operation.
Quality standards.
Safety or environmental precautions to be observed. (Phase
Hazard)
Note: AMEC /Engineer will record the minutes to this inspection meeting and
distribute accordingly.
2. Initial Inspection —Upon completion of a representative sample of a given
feature of the work, the Contractor's Quality Control Representative will
meet with Sustainability/Projects Director's representative AMEC /Engineer
and check the following items at a minimum for conformance:
(a) Workmanship to established quality standards.
(b) Conformance to contract drawings and specifications.
(c) Construction methods, equipment and tools utilized.
(d) Materials and articles utilized.
(e) Adequacy of testing methods.
(f) Adequacy of shop drawings.
(g) Adequacy of safety or environmental precautions.
Note: AMEC /Engineer will record the minutes to this inspection meeting and
distribute accordingly.
3. Follow -up Inspections —The Contractor's Quality Control Representative
will inspect the work daily to assure the continuing conformance of the work
to the workmanship standards established during the preparatory and initial
inspections.
CONTRACTOR QUALITY CONTROL PLAN 00980 -Page 70 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
Additionally, as a part of the follow -up inspection, sign -off sheets will be
utilized as often as possible. The intent of these sheets is to achieve
concurrence from other trade contractors and responsible parties that
ensuing work can indeed commence over underlying work. This will
prevent oversights and omissions which could elevate costs. Sign -off
sheets shall be used for, but not be limited to, concrete, drywall, ceilings,
painting, roofing substrates and flooring. These reports are to be
generated by the Contractor and submitted to AMEC /Engineer
Superintendent for approval prior to the start-up of work.
Failure to generate a sign -off sheet or to attain proper signatures prior to
covering up underlying work may affect payment for that piece of work if
ensuing problems are detected or not. This disciplinary action shall be
carried out via the Nonconformance Report. (See Section 1.4.13 of this
plan.)
Note: The Contractor shall be responsible to record these inspections and all
other project related activities encountered throughout the day on the
Contractor Daily Quality Control Report.
4. Completion Inspections —Upon completion of a given feature of the work,
the Contractor's Quality Control Representative will meet with the
Sustainability /Projects Director representative AMEC /Engineer, if he so
desires to attend, to perform an inspection of the completed work.
Nonconforming items will be identified and corrected prior to
commencement of the next operation.
Note: The Contractor shall conduct and report corrections of this inspection which
shall be a required submittal.
5. Follow -On Inspections —Upon execution of the contractor's completion
inspection in elements of the work which result in concealment; such as,
ceiling and drywall installations, the Contractor shall schedule and conduct
multi -trade or singular inspections prior to covering installation.
Note: AMEC /Engineer will record the minutes to this inspection meeting.
6. Pre -Final Inspection —Upon substantial completion of the project work
AMEC /Engineer shall coordinate and conduct a universal inspection of all
areas and elements of the work. The Sustainability /Projects Director may
be represented if she so desires. This inspection shall be completed at
least (15) days prior to the final substantial completion inspection which
shall be conducted by AMEC /Engineer. All deficiencies and incomplete
work should be completed prior to the final substantial completion
inspection.
B. OPERATION AND CHECK OUT TESTING
CONTRACTOR QUALITY CONTROL PLAN 00980 -Page 71 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
The Contractor will provide personnel and equipment to perform the operational
tests and check -out of the equipment, facilities or equipment constructed,
fabricated or installed under this Contract. The Sustainability /Projects Director
representative AMEC /Engineer will coordinate and witness all such tests.
Notification should be given at least ten (10) days in advance of the scheduled
tests.
C. FINAL INSPECTION
AMEC /Engineer will coordinate and attend all final inspections of the work. The
Sustainability /Projects Director may be represented if she so desires. Prior to
requesting a final inspection, all tests for the equipment and systems must be
completed.
See Section 01700 for contract closeout.
1.4 REPORTING
Maintaining accurate and retrievable records is extremely important in the Quality
Assurance Program. These records will act as a main source of information in the present
and in the future for the entire Sustainability /Projects Director team. The main report that
will be utilized to provide this information is the Daily Quality Control Report.
Nonconformance Reports may also be issued.
A. DAILY QUALITY CONTROL REPORT
The Daily Quality Control Report shall be used to document the summary of daily
inspection activities performed by the Contractor's designated Quality Control
Representative. It shall include any of the steps of inspection that are performed
that day, all test monitoring and any rework of nonconforming items. The daily
Quality Control Report section of the Daily Superintendent's Report will be
routinely used for daily reporting requirements. When the magnitude or complexity
necessitates such, a more separate and comprehensive form will be used.
Reference Contractor's Daily Report, and as needed Contractor Daily Quality
Control Report, Section 01385.
B. NONCONFORMANCE REPORT
Nonconformance Reports will be issued for work that is found to be in
nonconformance with the contract documents or the referenced quality standards.
The report will be issued by Sustainability /Projects Director.
It is not the intent to routinely and repeatedly issue nonconformance reports, but
to issue them only after normal enforcement standards have been exhausted, or if
the work performed is a detriment to the project.
A copy of the Nonconformance Report will be forwarded to the Site Project
Manager for his information and /or action. It should also be included in the
Contractor's Daily Quality Report package for general review.
CONTRACTOR QUALITY CONTROL PLAN 00980 -Page 72 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
Nonconformance Reports will be signed off once the deficient item or items have
adequately been corrected. This will be done by the issuing Superintendent and
Project Manager. These sign -offs will be included with a corresponding corrective
action taken. Significant nonconformance needs to be addressed to prevent
recurrence. The signed -off report will also be submitted for review.
Work activities affected by a Nonconformance Report will proportionally counter -
affect payments. Whether that be partial or full retainage will be left up to the
discretion of Sustainability /Projects Director.
1.5 AUDITS
A. Sustainability /Projects Director may choose at its option to perform Contractor
audits of their Contractor Quality Control Plan at any time. Reports of these audit
results will be forwarded to the Project Manager for his action. Any action items
noted during an audit for the Contractor will be followed up and documented to
insure compliance and avoid recurrence.
1.6 SUMMARY
The intention of this plan is to create a system of checks and balances that will minimize
delays caused by rework and a lack of planning and maximize production and insure that
the finished product is one that the entire construction team can pride themselves in.
These goals can be achieved by giving the Owner exactly what he has bought. The Owner
will expect no more and through Quality Assurance, the construction team will provide no
less.
END SECTION 00980
CONTRACTOR QUALITY CONTROL PLAN 00980 -Page 73 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
SECTION 00990 - SPECIAL CONDITIONS
Construction shall be conducted in such a manner as to cause the least possible
interruption to normal County business. Necessary access to and from adjacent
buildings and the parking area shall be provided at all times.
2. Contractor shall take all means necessary to contain dust and debris as an integral
part of the work.
3. Weather intrusion and unauthorized access to the Project Site due to construction
activities shall be prevented by the Contractor's careful scheduling of work, or other
means satisfactory to the Owner.
4. Contractor shall coordinate construction activities as necessary to avoid security
or safety concerns at the Project Site.
5. Information shown on the Drawings is assembled from numerous record
information sources and may be inaccurate or incomplete. Contractor shall make
such field visits or investigations as are necessary to prepare an accurate and
complete bid. Claims for extra work or expense after bid closing which are due to
reasonably foreseeable circumstances shall be denied and shall remain the sole
risk and expense of the Contractor. Field measured dimensions shall be obtained
by the Contractor prior to placing orders for fabrications or prefabricated materials.
Adjustments, delays, re- fabrications, or replacement materials due to inaccurate
information are the sole responsibility of the Contractor.
6. SITE SURVEY
A. The Plat of Survey or other survey data, are available in the Office of the
Sustainability /Projects Director for review, and are for the general information of
the contractor. The data contained was prepared by AMEC /Engineer for the
design of the project, and neither the Owner nor AMEC /Engineer, nor
Sustainability /Projects Director make any representation, guarantee of warranty as
to the accuracy or completeness of data indicated, expressed or implied.
B. Proposers shall visit the site; make their own investigations, assumptions
and conclusions as to the nature and extent of existing surface and overhead
conditions affecting the work. Neither the Owner nor AMEC /Engineer, nor
Sustainability /Projects Director will be responsible for additional type or extent of
work required to be performed under the Contract due to any assumptions or
conclusions by the successful proposer based upon the survey information
provided.
END SECTION 00990
SPECIAL CONDITIONS 00990 -Page 74 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
SECTION 01010 - SUMMARY OF THE WORK
Project Overview
The Scope of Work for Canal #75 located between Ocean Drive and Coral Way in Rock Harbor
on Key Largo, Florida consists of backfilling within the canal. Due to excessive depths, the water
column is stratified, with anoxia (depleted oxygen) present in the lower portion of the water column
which prevents the inhabitance of fish or other marine organisms.
The backfilling shall be completed using the proposed staging areas identified in the design
drawings (Exhibit A), or an approved alternate. The backfilling will raise the canal bottom to -7.9
ft. NAVD88, which is approximately 6 feet below the Mean Sea Level for the canal (a depth that
is typically suitable to allow for sufficient light and oxygen to permeate the water column to support
a healthy ecological habitat).
The backfilling shall be done in such a way to prevent impact to the nearshore waters.
2 General Project Intent and Scope
Provide all labor, supervision, engineering, materials, supplies, equipment, tools, transportation,
surveying, layout, and protection for the proper execution and completion of all the work in
accordance with the Contract Documents. The Work shall include but not be limited to that shown
on the Drawings and detailed in the Technical Specifications if any included in this Contract.
SPECIAL PROVISIONS
The following Special Provisions are intended to clarify the scope of work, or highlight features of
the work, or modify, change, add to, or delete from the General Scope of this Proposal Package.
All licenses required in order to perform the scope of work in the specified location,
shall be procured and maintained by the contractor and his subcontractors.
Contractor shall submit copies to Sustainability /Projects Director prior to notice to
proceed. Contractor's license shall accompany proposal.
2.. Contractor is to review General Requirements for additional responsibilities
required in order to perform this Work.
3.. If in the event of conflicting, or overlapping requirements in any area of the proposal
documents, technical specifications, or drawings, the most stringent condition shall
be proposed and constructed Notify Sustainability /Projects Director in any event,
in order to not compromise the Owner's right to make appropriate decisions.
4. Contractor shall maintain As -Built Drawings (Record Drawings per Section
01720), of his work progression.
6. The Contractor shall not store materials, tools or debris in areas of the project site
without written permission. Contractor shall provide suitable storage container,
and be responsible for disposal off -site of all debris and trash.
7. The Contractor shall coordinate with Owner's representative on available hours for
Job Site access. Job site will have limited 8AM -6PM work hours. Contractor will
SUMMARY OF THE WORK 01010 -Page 75 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
need to schedule work shifts typically from 8AM- 6PM weekly. Any change to
agreed upon schedule must be obtained in writing with a minimum of 72 hr
advanced notice.
8. Coordination of each days works shall be done in advance with approval from
County.
1.2 PROTECTION:
A. The Contractor shall use every available precaution to provide for the safety of property
owner, visitors to the site, and all connected with the work under the Contract.
B. All existing facilities both above and below ground shall be protected and maintained free
of damage. Existing facilities shall remain operating during the period of construction
unless otherwise permitted. All access roadways must remain open to traffic unless
otherwise permitted.
C. Barricades shall be erected to fence off all construction areas from operations personnel
and the general public. Fence posts shall have bases that eliminate the need to penetrate
the ground for support.
D. Safety Requirements
1. All application, material handling, and associated equipment shall conform to and be
operated in conformance with OSHA safety requirements.
2. Comply with federal, state and local and owner fire and safety requirements.
3. Advise owner whenever work is expected to be hazardous to owner employees and /or
operations.
4. Maintain proper fire extinguisher within easy access whenever power tools, roofing kettles,
and torches are being used.
1.3 HOUSEKEEPING:
1. Keep materials neat and orderly.
2. Remove scrap, waste and debris from project area daily.
3. Maintenance of clean conditions while work is in progress and cleanup when work is
completed shall be in strict accordance with the "General Conditions" of this contract.
4. Maintain Fire protection during construction
5. Housekeeping required on a daily basis
END SECTION 01010
SUMMARY OF THE WORK 01010 -Page 76 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
SECTION 01015 - CONTRACTOR'S USE OF PREMISES
PART 1 — GENERAL
1.1 DESCRIPTION
A. Work included:
This Section applies to situations in which the Contractor or his representatives including, but not
necessarily limited to, suppliers, subcontractors, employees, and field engineers, enter upon
Owner's property.
Related work:
Documents affecting work of this Section include, but are not limited to, General Conditions,
Supplementary Conditions, and Sections in Division 1 of these Specifications.
1.2 QUALITY ASSURANCE
A. Promptly upon award of the Contract, notify all pertinent personnel regarding requirements
of this Section.
Require all personnel who will enter upon the Owner's property certify their awareness of and
familiarity with requirements of this Section.
1.3 SUBMITTALS
Maintain an accurate record of names and identification of all persons entering upon Owner's
property in connection with Work of this Contract, including times of entering and times of leaving,
and submit a copy of the record to Owner daily.
1.4 TRANSPORTATION FACILITIES
A. Provide adequate protection for curbs and sidewalks over which trucks and equipment
pass to reach job site.
Contractor's vehicles:
Require Contractor's vehicles, vehicles belonging to employees of Contractor, and all
other vehicles entering upon Owner's property in performance of Work of Contract, to use
only the Access Route approved in advance by Owner.
Do not permit such vehicles to park on any street or other area of Owner's property except in the
area approved by Owner as "Contractor's Parking Area."
1.5 SECURITY
A. Restrict access of all persons entering upon the Owner's property in connection with work
to the Access Route and to actual site of the work.
END SECTION 01015
CONTRACTOR'S USE OF PREMISES 01015 -Page 77 of 154
Mi
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
SECTION 01027 - APPLICATION FOR PAYMENT
SUMMARY
This section provides procedures for preparation and submittal of Applications for Payment.
2. FORMAT
The Application for Payment including the Continuation Sheet is the required format for submitting
invoices. A copy of these forms is included in this section. The Owner reserves the right to modify
the format to better suit his internal accounting system.
3. SUBMITTAL PROCEDURES
A. The initial Application for Payment will not be processed until the Contractor's
Construction Schedule, Schedule of Values, and the initial Submittal Schedule have
been received, reviewed and approved by Sustainability /Projects Director.
B. Submit an updated Construction Schedule and Submittal Schedule and a Partial Release
of Lien with each Application for Payment.
C. Payment shall be made according to the Local Government Prompt Payment Act, Sec.
218.70 et seq. Florida Statutes.
D. Monroe County makes every effort to meet the payment schedule. It is requested that the
contractor not make any calls to any County office inquiring about payment until the
twentieth (20th) day after submission of the pay request.
4. MONTHLY PAY REQUEST PROCEDURE
A. AMEC /Engineer to review as- builts as to current additions, corrections, etc., prior to
monthly approval to ensure as- builts are current.
5. FINAL PAY PROCEDURE
A. To help expedite the final payment, it is necessary for AMEC /Engineer to have a correct
and complete package of documents 20 days in advance of requested pay date.
B. A minimum of ten (10) working days is required from receipt of correct documents for
Sustainability /Projects Director to obtain necessary signatures and submit project for Final
Payment. Contractor shall submit all required forms and releases to AMEC /Engineer.
The following documents ( samples attached are required for Final Payment:
(1) Application and Certificate for Payment
(2) Continuation Sheet
(3) Certificate of Substantial Completion
(4) Contractor's Affidavit of Debts and Claims
APPLICATION FOR PAYMENT 01027 -Page 78 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
(5) Contractor's Affidavit of Release of Liens
(6) Final Release of Lien
Also, all warranties and guarantees required by Contract, "As- Built" drawings, including
red -lined site plan, submittal documents, certification that all utility bills (i.e., electric, local
water) have been paid, and a complete list of subcontractors with addresses and phone
numbers must be submitted prior to final payment in both bound paper and electronic PDF
form on CD /DVD.
C. It is the Contractor's responsibility to ensure the completeness of the Final Pay
Package. Incompleteness will result in delay of Final Pay. Final Pay Requests will
not be processed until all the required documents are received by Monroe County
Sustainability /Projects Director. Final Pay Request must be submitted no later than
30 days after final project completion and acceptance.
6. SUBSTANTIATING DATA
A. When the Owner's Representative requires substantiating information, submit data
justifying dollar amounts in question.
B. Provide one copy of data with cover letter for each copy of submittal. Indicate Application
number, date, line item by number and description.
APPLICATION FOR PAYMENT 01027 -Page 79 of 154
BACKFILLING WATER QUAL; , , IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
APPLICATION FOR PAYMENT ENGINEER'S CERTIFICATE FOR PAYMENT
SUMMARY In accordance with the Contract Documents, based on on -site observations and the data
comprising the above application, the Engineer certifies to the Owner that to the best of the
Application No: Engineer's knowledge, information and belief, the Work has progressed as indicated, the
quality of the Work is in accordance with the Contract Documents, and the Contractor is
To: Monroe County, Florida entitled to payment of the Amount Certified.
From:
Contractor
Project:
Contract For:
Period: From: To:
Contract Date:
Original Contract Sum: $
Net Change By Approved Change Order:
Contract Sum To Date:
Total Completed & Stored To Date:
Retainage
% of Completed Work:
Total Earned Less Retainage:
Less Previous Payments:
Current Payment Due:
Balance to Finish:
Reviewed for Payment
Sustainability /Projects Director
Date:
Approved for Payment
This Certificate is not negotiable. The Amount Certified is payable only to the Contractor
named herein. Issuance, payment and acceptance of payment are without any prejudice to
any rights of the Owner or Contractor under this Contract.
Amount Certified:
(Attach an explanation if the amount certified differs from the amount applied for)
ENGINEER:
By:
Date:
The undersigned Contractor certifies that to the best of the Contractor's knowledge,
information and belief, the Work covered by this Application for Payment has been
completed in accordance with the Contract Documents, that all amounts have been paid by
the Contractor for Work for which previous Applications for Payment were issued and
payments received from the Owner, and that current payment shown herein is now due.
By:
State of:
Subscribed and sworn to before me this
Notary Public:
Date:
County of:
day of , 200
My Commission Expires:
Approved for Payment
Sustainability /Projects Director
Date:
Monroe County, Owner
Roman Gastesi, County Administrator
Date:
APPLICATION FOR PAYMENT 01027 -Page 80 of 154
BACKFILLING WATER QUA[ IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, K_ , -ARGO, MONROE COUNTY, FL
CONTINUATION SHEET
PAGES
APPLICATION AND CERTIFICATE FOR PAYMENT APPLICATION NO.:
Containing Contractor's signed Certification is attached. APPLICATION DATE:
In tabulations below, amounts are stated to the nearest dollar. PERIOD TO:
Use Column I on Contracts where variable retainage for line items may apply.
Change Orders added at the end of sheet.
PAGE OF
A
B
C
D I E
F
G
H
I
ITEM
NO.
DESCRIPTION OF WORK
SCHEDULED
VALUE
WORK COMPLETED
MATERIALS
PRESENTLY
STORED
NOT INDORE
TOTAL
COMPLETED AND
STORED TO DATE
D +E +F
%
(G + C)
BALANCE
TO
FINISH
C - G
RETAINAGE
(IF VARIABLE
RATE)
FROM PREVIOUS
APPLICATION
(D + E)
THIS PERIOD
APPLICATION FOR PAYMENT 01027 -Page 81 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
PROJECT TITLE:
CONTRACT CHANGE ORDER
TO CONTRACTOR:
INITIATION DATE:
The Contract is changed as follows:
CHANGE ORDER NO:
CONTRACT DATE:
The original (Contract Sum) (Guaranteed Maximum Price) .............. ..............................$
Net change by previously authorized Change Orders ..................... ..............................$
The (Contract Sum) (Guaranteed Maximum Price) prior to this Change order was .............$
The (Contract Sum) (Guaranteed Maximum Price) will be (increased) (decreased)
(unchanged) by this Change Order ....... $
The new (Contract Sum) (Guaranteed Maximum Price) including this Change Order is ...... $
The Contract Time will be (increased) (decreased) (unchanged) by ... ...............................
The date of Substantial Completion as of the date of this Change Order is .........................
Detailed description of change order and justification:
This change Order is % of the original contract price.
g
Not valid until sinned by Owner, Engineer (if applicable), and Contractor
ENGINEER:
Date
CONTRACTOR:
MONROE COUNTY
Date
SUSTAI NAB I LITY/PROJECTS DIRECTOR:
Date
COUNTY /DEPUTY ADMINISTRATOR
Date
APPLICATION FOR PAYMENT 01027 -Page 82 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
Change Order Attachment per Ordinance No. 004 -1999
• Change Order was not included in the original contract specifications. Yes ❑ No ❑
If Yes, explanation:
• Change Order was included in the original specifications. Yes ❑ No ❑
If Yes, explanation of increase in price:
• Change Order exceeds $25,000 or 5% of contract price (whichever is greater). Yes ❑ No ❑
If Yes, explanation as to why it is not subject for a calling for bids:
• Project engineer approves the change order. Yes ❑ No ❑
If no, explanation of why:
• Change Order is correcting an error or omission in design document. Yes ❑No ❑
Should a claim under the applicable professional liability policy be made? Yes ❑ No ❑
Explain:
APPLICATION FOR PAYMENT
01027 -Page 83 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
CERTIFICATE OF SUBSTANTIAL COMPLETION
PROJECT: CONTRACT FOR:
(Name and address) CONTRACT DATE:
TO OWNER: TO CONTRACTOR:
(Name and address) (Name and address)
DATE OF ISSUANCE:
PROJECT OR DESIGNATED PORTION SHALL INCLUDE:
The Work performed under this Contract has been reviewed and found, to the Project Managers best knowledge,
information and belief, to be substantially complete. Substantial Completion is the stage in the progress of the Work
when the Work or designated portion thereof is sufficiently complete in accordance with the Contract Documents so the
Owner can occupy or utilize the Work for its intended use. The date of Substantial Completion of the Project or portion
thereof designated above is hereby established as
which is also the date of commencement of applicable warranties required by the Contract Documents, except as stated
below:
A list of items to be completed or corrected is attached hereto. The failure to include any items on such list does not
alter the responsibility of the Contractor to complete all Work in accordance with the Contract Documents.
INSPECTOR
(if used)
BY
DATE
The Contractor will complete or correct the Work on the list of items attached hereto within the above date of
Substantial Completion.
CONTRACTOR BY DATE
The Owner accepts the Work or designated portion thereof as substantially complete and will assume full possession
thereof at (time), on
(date).
OWNER
M
DATE
The responsibilities of the Owner and the Contractor for security, maintenance, heat, utilities, damage to the Work and
insurance shall be
as follows:
Note - Owners and Contractors legal and insurance counsel should detennine and review insurance requirements and coverage.
APPLICATION FOR PAYMENT
01027 -Page 84 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
CONTRACTOR'S AFFIDAVIT OF PAYMENT OF DEBTS AND CLAIMS
TO OWNER: CONTRACT FOR:
(Name and address) CONTRACT DATE:
PROJECT:
(Name and address)
State of:
County of:
The undersigned, pursuant to Article 9 of the General Conditions of the Contract for Construction, hereby certifies that, except as listed
below, he has paid in full or has otherwise satisfied all obligations for all materials and equipment furnished, for all work, labor, and
services performed, and for all known indebtedness and claims against the Contractor for damages arising in any manner in connection
with the performance of the Contract referenced above for which the Owner or his property might in any way be held responsible.
EXCEPTIONS: (If none, write "None ". If required by the Owner, the Contractor shall furnish bond satisfactory to the Owner for each
exception).
SUPPORTING DOCUMENTS ATTACHED HERETO:
Consent of Surety to Final Payment. Whenever
Surety is involved, Consent of Surety is required.
AIA DOCUMENT G707, CONSENT OF
SURETY, may be used for this purpose. Indicate
attachment: yes ( ) no ( )
CONTRACTOR:
Address:
The following supporting documents should be attached
hereto:
Contractor's Release or Waiver of Liens,
conditional upon receipt of final payment.
Separate Releases or Waivers of Liens from
Subcontractors and material and equipment
suppliers, to the extent required by the Owner,
accompanied by a list thereof.
C
Subscribed and sworn to before me this
day of 1 20_
Notary Public:
Contractor's Affidavit or Release of Liens.
My Commission Expires:
APPLICATION FOR PAYMENT 01027 -Page 85 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
CONTRACTOR'S AFFIDAVIT OF
RELEASE OF LIENS
TO OWNER: CONTRACT FOR:
(Name and address)
CONTRACT DATED:
PROJECT:
(Name and address)
State of
County of
The undersigned hereby certifies that to the best of the undersigned's knowledge, information and belief,
except as listed below, the Releases or Waivers of Lien attached hereto include the Contractor, all
Subcontractors, all suppliers of materials and equipment, and all performers of Work, labor or services
who have or may have liens or encumbrances or the right to assert liens or encumbrances against any
Y- property of the Owner arising in any manner out of the performance of the Contract referenced above.
EXCEPTIONS:
SUPPORTING DOCUMENTS ATTACHED
HERETO:
1. Contractor's Release or Waiver of Liens,
conditional upon receipt of final payment.
CONTRACTOR:
(Name and address)
0
2. Separate Releases or Waivers of Liens from
Subcontractors and material and equipment
suppliers, to the extent required by the Owner,
accompanied by a list thereof.
(Signature of authorized representative)
(Printed Name and Title)
Subscribed and sworn to before me this date:
Notary Public:
My Commission Expires:
(SEAL)
APPLICATION FOR PAYMENT 01027 -Page 86 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
MONROE COUNTY
FINAL RELEASE OF LIEN
KNOW ALL MEN BY THESE PRESENTS, that
for and consideration of the sum of
Dollars ($
paid to
by Monroe County, Florida receipt of which is hereby acknowledged, do(es) hereby release
and quit claim to Monroe County, Florida, the Owner, its successors or assigns, all liens, lien
rights, claims or demands of any kind whatsoever which
has (have) or might have against the property, building, and /or improvements, on account of
labor performed, material furnished, and /or for any incidental expense for the construction of:
thereon or in otherwise improving said property situated as above described.
IN WITNESS WHEREOF THIS day of
Witness
Witness
Notary Public
Signature, Title
My commission expires:
,20
Name of Company
APPLICATION FOR PAYMENT 01027 -Page 87 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
MONROE COUNTY
AFFIDAVIT AND PARTIAL RELEASE OF LIEN
APPLICATION NO.: PERIOD ENDING DATE: APPLICATION DATE:
KNOW ALL MEN BY THESE PRESENTS, that the undersigned, for and in consideration of the
payment of the sum $ , to be paid to the undersigned, hereby releases,
acquits, satisfies and forever discharges, MONROE COUNTY, OWNER, their successors and
assigns from all suits, causes of action, liens, lien rights, claims or demands of any kind
whatsoever, to the extent of the payment to date on account of the furnishing of labor, material
or services for the improvement of the following described property:
As part of this PARTIAL RELEASE. THAT UNDERSIGNED HEREBY CERTIFIES the following:
THAT the contract of the undersigned, as adjusted by all increases and decreases, is in the
amount of $ , as of the date of the Partial Release and the undersigned has
received
$ as payment on the adjusted contract amount as of the date of this Partial
Release.
THAT all supplies of labor, material or services furnished 'to, or for the benefit of the undersigned
for improvement to the subject property have been paid in full. Any and all suppliers of labor,
material or services for improvement to the subject property, who have not been paid in full are
listed below with the amount owing each, claimed by each and the reason for non - payment: (If
none, write "NONE ")
CLAIMANT AMOUNT DUE AMOUNT CLAIMED REASON FOR NONPAYMENT
THAT all taxes imposed by all government agencies have been paid and discharged.
THAT all funds have been collected for FICA and withholding taxes have been properly deposited
with appropriate agencies or paid to the government as required by law.
THAT the undersigned has no other claims for money against the OWNER other than those
Subcontractors' /Suppliers' amounts remaining due and owing on the adjusted contract balance
as reflected above.
THAT the undersigned further certifies that if there is a Guarantee, Warranty or Maintenance
Agreement in connection with the labor and material furnished by it, that this payment and
PARTIAL RELEASE shall not release the undersigned from any obligations under such
Guarantee, Warranty, or Maintenance Agreement.
WITNESS MY HAND THIS day of
Witness
Witness
1 20,
Name of Company
Signature, Title
APPLICATION FOR PAYMENT 01027 -Page 88 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
SECTION 01030 - ALTERNATES
PART 1 — GENERAL
1.1 RELATED DOCUMENTS
A. Drawings and general provisions of the Contract, including General and Supplementary
Conditions and other Division -1 Specification Sections, apply to this Section.
1.2 SUMMARY
A. This Section specifies administrative and procedural requirements for Alternates.
B. Definition: An alternate is an amount proposed by Proposer and stated on the Proposal
Form for certain construction activities defined in the Proposal Requirements that may be
added to or deducted from Base Proposal amount if the Owner decides to accept a
corresponding change in either the installation or methods described in Contract
Documents.
C. Coordination: Coordinate related Work and modify or adjust adjacent Work as necessary
to ensure that Work affected by each accepted Alternate is complete and fully integrated
into the project.
D. Notification: Immediately following the award of the Contract, prepare and distribute to
each party involved, notification of the status of each Alternate. Indicate whether
Alternates have been accepted, rejected or deferred for consideration at a later date.
Include a complete description of negotiated modifications to Alternates.
Include as part of each Alternate, miscellaneous devices, accessory objects and
similar items incidental to or required for a complete installation whether or not
mentioned as part of the Alternate.
END SECTION 01030
ALTERNATES 01030 -Page 89 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
SECTION 01040 - PROJECT COORDINATION
PART I — GENERAL
1.1 RELATED DOCUMENTS
A. Drawings and general provisions of Contract, including General and
Supplementary Conditions and other Division 1 Specification Sections, apply to
this Section.
1.2 SUMMARY
A. This Section specifies administrative and supervisory requirements of the
Contractor necessary for Project coordination including, but not necessarily limited
to:
1. Coordination
2. Administrative and supervisory personnel
3. General installation provisions
4. Cleaning and protection
B. Field engineering is included in Section 01050 "Field Engineering ".
C. Progress meetings, coordination meetings and pre - installation conferences are
included in Section 01200 "Project Meetings ".
D. Requirements for the Contractor's Construction Schedule are included in Section
01301 "Submittals ".
1.3 COORDINATION
A. Coordination: Coordinate construction activities included under various Sections
of these Specifications to assure efficient and orderly installation of each part of
the Work. Coordinate construction operations included under different Sections of
the Specifications that are dependent upon each other for proper installation,
connection, and operation.
1. Where installation of one part of the Work is dependent on installation of
other components, either before or after its own installation, schedule
construction activities in the sequence required to obtain the best results.
2. Where availability of space is limited, coordinate installation of different
components to assure maximum accessibility for required maintenance,
service and repair.
3. Make adequate provisions to accommodate items scheduled for later
installation.
B. Where necessary, prepare memoranda for distribution to each party involved
(� outlining special procedures required for coordination. Include items as required
notices, reports, and attendance at meetings.
PROJECT COORDINATION 01040 -Page 90 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
1. Prepare similar memoranda for the Owner and separate Contractors
where coordination of their work is required.
C. Administrative Procedures: Coordinate scheduling and timing of required
administrative procedures with other construction activities to avoid conflicts and
ensure orderly progress of the Work. Such administrative activities include, but
are not limited to, the following:
1. Preparation of schedules
2. Installation and removal of temporary facilities
3. Delivery and processing of submittals
4. Progress meetings
5. Project Close -out activities
D. Conservation: Coordinate construction activities to ensure that operations are
carried out with consideration given to conservation of energy, water, and
materials.
1. Salvage materials and equipment involved in performance of, but not
actually incorporated in, the Work. Refer to other sections for disposition
of salvaged materials that are designated as Owner's property.
1.4 SUBMITTALS
A. Coordination Drawings: Prepare and submit coordination Drawings where close
=` and careful coordination is required for installation of products and materials
fabricated off -site by separate entities, and where limited space availability
necessitates maximum utilization of space for efficient installation of different
components.
1. Show the interrelationship of components shown on separate Shop
Drawings.
2. Indicate required installation sequences.
3. Comply with requirements contained in Section 01301 "Submittals ".
B. Staff Names: Within five (5) calendar days of Notice to Proceed, submit a list of
the Contractor's principal staff assignments, including the Superintendent and
other personnel in attendance at the site; identify individuals, their duties and
responsibilities; list their addresses and telephone numbers.
1. Post copies of the list in the Project meeting room, the temporary field
office, and at each temporary telephone.
PART 2 — PRODUCTS (Not Applicable)
PART 3 — EXECUTION
r�
3.1 GENERAL INSTALLATION PROVISIONS
1 Inspection of Conditions: Require the Installer of each major component to inspect both
the substrate and conditions under which Work is to be performed. Do not
PROJECT COORDINATION 01040 -Page 91 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
i proceed until unsatisfactory conditions have been corrected in an acceptable
manner.
Manufacturer's Instructions: Comply with manufacturer's installation instructions and
recommendations, to the extent that those instructions and recommendations
are more explicit or stringent than requirements contained in Contract
Documents.
Inspect materials or equipment immediately upon delivery and again prior to installation.
Reject damaged and defective items.
Provide attachment and connection devices and methods necessary for security Work.
Secure Work true to line and level. Allow for expansion and building movement.
Visual Effects: Provide uniform joint widths in exposed Work. Arrange joints in exposed
Work to obtain the best visual effect. Refer questionable choices to Engineer for
final decision.
Recheck measurements and dimensions, before starting each installation.
Install each component during weather conditions and Project status that will ensure the
best possible results. Isolate each part of the completed construction from
incompatible material as necessary to prevent deterioration.
Coordinate temporary enclosures with required inspections and tests, to minimize the
necessity of uncovering completed construction for that purpose.
Mounting Heights: Where mounting heights are not indicated, install individual
components at standard mounting heights recognized within the industry for the
particular application indicated. Refer questionable mounting height decisions
to Engineer for final decision.
3.1 CLEANING AND PROTECTIONS
A. During handling and installation, clean and protect construction in progress and
adjoining materials in place. Apply protective covering where required to ensure
protection from damage or deterioration at Substantial Completion.
B. Clean and maintain completed construction as frequently as necessary through
the remainder of the construction period. Adjust and lubricate operable
components to ensure operability without damaging effects.
C. Limiting Exposures: Supervise construction activities to ensure that no part of the
construction completed or in progress, is subject to harmful, dangerous, damaging,
or otherwise deleterious exposure during the construction period. Where
applicable, such exposures include, but are not limited to, the following:
PROJECT COORDINATION 01040 -Page 92 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
1.
2.
3.
4.
5.
6.
7.
8.
9.
10.
11.
12.
13.
14.
15.
16.
17.
18.
19.
20.
21.
22.
23.
24.
25.
26.
27.
28.
29.
30.
LIMITING EXPOSURES
Excessive static or dynamic loading
Excessive internal or external pressures
Excessively high or low temperatures
Thermal shock
Excessively high or low humidity
Air contamination or pollution
Water
Solvents
Chemicals
Light
Radiation
Puncture
Abrasion
Heavy traffic
Soiling, staining and corrosion
Bacteria
Rodent and insect infestation
Combustion
Electrical current
High speed operation
Improper lubrication
Unusual wear or other misuse
Contract between incompatible materials
Destructive testing
Misalignment
Excessive weathering
Unprotected storage
Improper shipping or handling
Theft
Vandalism
END SECTION 01040
PROJECT COORDINATION 01040 -Page 93 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
SECTION 01045 - CUTTING AND PATCHING
PARTS 1, 2 and 3 — Not Applicable.
END SECTION 01045
CUTTING AND PATCHING 01045 -Page 94 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
SECTION 01050 - FIELD ENGINEERING
PART 1- GENERAL
1.1 RELATED DOCUMENTS
A. Drawings and general provisions of the Contract, including General and
Supplementary Conditions and other Divisions 1 Specification Sections, apply to
this Section.
1.2 SUMMARY
A. General: This Section specifies administrative and procedural requirements of the
Contractor for field- engineering services including, but not limited to, the following:
1. Land survey work.
2. Civil- engineering services.
3. Damage surveys.
4. Geotechnical monitoring.
B. Related Sections: The following Sections contain requirements that are related to
this Section:
1. Division 1 Section "Coordination" for procedures for coordinating field
engineering with other construction activities.
2. Division 1 Section "Submittals" for submitting Project record surveys.
3. Division 1 Section "Project Closeout" for submitting final property survey
with Project Record Documents and recording of Owner - accepted
deviations from indicated lines and levels.
1.3 SUBMITTALS
A. Certificates: Submit a certificate signed by the land surveyor or professional
engineer certifying the location and elevation of improvements.
B. Project Record Documents: Submit a record of Work performed and record survey
data as required under provisions of "Submittals" and "Project Closeout" Sections.
1.4 QUALITY ASSURANCE
A. Surveyor Qualifications: Engage a land surveyor registered in the state where the
Project is located, to perform required land- surveying services.
B. Engineer Qualifications: Engage an engineer of the discipline required, licensed
in the state where the Project is located, to perform required engineering services.
PART 2 - PRODUCTS (Not Applicable)
FIELD ENGINEERING 01050 -Page 95 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
PART 3 - EXECUTION
3.1 EXAMINATION
A. Identification: The Owner will identify existing control points and property
line corner stakes.
B. Verify layout information shown on the Drawings, in relation to the property survey
and existing benchmarks, before proceeding to lay out the Work. Locate and
protect existing benchmarks and control points. Preserve permanent reference
points during construction.
1. Do not change or relocate benchmarks or control points without prior
written approval. Promptly report lost or destroyed reference points or
requirements to relocate reference points because of necessary changes
in grades or locations.
2. Promptly replace lost or destroyed Project control points. Base
replacements on the original survey control points.
C. Establish and maintain a minimum of 2 permanent benchmarks on the site,
referenced to data established by survey control points.
Record benchmark locations, with horizontal and vertical data, on Project
Record Documents.
D. Existing Utilities and Equipment: The existence and location of underground and
other utilities and construction indicated as existing are not guaranteed. Before
beginning site work, investigate and verify the existence and location of
underground utilities and other construction.
Prior to construction, verify the location and invert elevation at points of
connection of sanitary, sewer, storm sewer, and water - service piping.
3.2 PERFORMANCE
A. Work from lines and levels established by the property survey. Establish
benchmarks and markers to set lines and levels at each story of construction and
elsewhere as needed to locate each element of the Project. Calculate and
measure required dimensions within indicated or recognized tolerances. Do not
scale Drawings to determine dimensions.
1. Advise entities engaged in construction activities of marked lines and levels
provided for their use.
2. As construction proceeds, check every major element for line, level, and
plumb.
B. Surveyor's Log: Maintain a surveyor's log of control and other survey work. Make
this log available for reference.
FIELD ENGINEERING 01050 -Page 96 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
1. Record deviations from required lines and levels, and advise
AMEC /Engineer when deviations that exceed indicated or recognized
tolerances are detected. On Project Record Drawings, record deviations
that are accepted and not corrected.
2. On completion of foundation walls, major site improvements, and other
work requiring field- engineering services, prepare a certified survey
showing dimensions, locations, angles, and elevations of construction and
site work.
C. Site Improvements: Locate and lay out site improvements, including pavements,
stakes for grading, fill and topsoil placement, utility slopes, and invert elevations.
D. Building Lines and Levels: Locate and lay out batter boards for structures, building
foundations, column grids and locations, floor levels, and control lines and levels
required for mechanical electrical work.
E. Existing Utilities: Furnish information necessary to adjust, move, or relocate
existing structures, utility poles, lines, services, or other appurtenances located in
or affected by construction. Coordinate with local authorities having jurisdiction.
END SECTION 01050
FIELD ENGINEERING 01050 -Page 97 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
SECTION 01200 - PROJECT MEETINGS
PART 1 - GENERAL
SUMMARY
A. Section includes:
Project meetings
2. AMEC /ENGINEER'S RESPONSIBILITY
A. AMEC /Engineer shall schedule and administer pre- construction meeting, periodic
progress meetings, and specially called meetings throughout progress of the Work.
1. Prepare agenda for meetings.
2. Provide notice of each meeting 24 hours in advance of meeting date, or
provide as much advance notice as possible.
3. Make physical arrangements for meetings.
4. Preside at meetings.
5. Record the minutes; include significant proceedings and decisions.
6. Reproduce and distribute copies of minutes.
a. To participants in the meeting.
J b. To parties affected by decisions made at the meeting.
C. To Monroe County staff as needed.
B. Representatives of the Contractors, subcontractors and suppliers attending
meetings shall be qualified and authorized to act on behalf of the entity each
represents.
C. The Engineer and the Owner's Representative may attend meetings to ascertain
that the Work is expedited consistent with the Contract Documents and
construction schedules.
3. PRE - CONSTRUCTION MEETING
A. Location: A central site designated by AMEC /Engineer.
B. Attendance:
1. Monroe County Sustainability /Projects Director designee.
2. AMEC /Engineer and his professional consultants (as required).
3. The Contractor's Superintendent.
4. Major subcontractors.
5. Major suppliers.
6. Others as appropriate.
C. Suggested Agenda:
1. Distribution and discussion of:
_i a. List of major subcontractors and suppliers.
b. Projected Construction Schedules.
PROJECT MEETINGS 01200 -Page 98 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
2.
Critical Work sequencing.
3.
Major equipment deliveries and priorities.
4.
Project Coordination.
a. Designation of responsible personnel.
5.
Procedures and processing of:
a. Field decisions.
b. Bid requests.
C. Submittals.
d. Change Orders.
e. Applications for Payment.
6.
Adequacy of distribution of the Contract Documents.
7.
Procedures for maintaining Record Documents.
8.
Use of premises:
a. Office, work and storage areas.
b. The Owner's requirements.
9.
Construction facilities, controls and construction aids.
10.
Temporary utilities.
11.
Safety and first -aid procedures.
12.
Security procedures.
13.
Housekeeping procedures.
14.
Distribute meeting minutes within (3) days.
4. PERIODIC PROGRESS MEETINGS
A. The Contractor's Project Manager and /or Superintendent shall be required to
attend a periodic scheduled meeting.
B. Location of the meetings: A central site designated by AMEC /Engineer, typically it
will be at the project site.
C. Attendance:
1. Monroe County Sustainability /Projects Director designee
2. AMEC /Engineer and his professional consultants as needed.
3. Contractors as appropriate to the agenda.
4. Suppliers as appropriate to the agenda.
5. Others.
D. Suggested Agenda:
1. Distribute meeting minutes.
2. Approval of the minutes.
3. Review of Work progress since previous meeting.
4. Field observations, problems, conflicts, Requests for Information (RFI).
5. Problems which impede Construction Schedule.
6. Review of off -site fabrication, delivery schedules.
7. Corrective measures and procedures to regain projected schedule.
8. Revisions to Construction Schedule.
9. Progress, schedule, during succeeding Work period.
10. Coordination of schedules.
11. Review submittal schedules.
12. Maintenance of quality standards.
13. Pending changes, substitutions and Change Order Requests (COR).
PROJECT MEETINGS 01200 -Page 99 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
14. Review proposed changes for:
a. Effect on Construction Schedule and on completion date.
b. Effect on other contracts of the Project.
15. Other business.
E. Revisions to minutes:
1. Unless published minutes are challenged in writing prior to the next
regularly scheduled progress meeting, they will be accepted as properly
stating the activities and decisions of the meeting.
2. Persons challenging published minutes shall reproduce and distribute
copies of the challenge to all indicated recipients of the particular set of
minutes.
3. Challenge to minutes shall be settled as priority portion of "old business"
at the next regularly scheduled meeting.
END SECTION 01200
PROJECT MEETINGS 01200 -Page 100 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
SECTION 01301 -SUBMITTALS
PART 1 - GENERAL
1.1 SUMMARY
A. Section includes:
1. The Contractor shall submit to AMEC /Engineer, shop drawings, product
data, certifications and samples required by the technical sections.
2. The Contractor shall prepare and submit a separate schedule listing dates
for submission and dates for review.
B. Related Sections:
1. Section 00750 - GENERAL CONDITIONS
2. Individual submittals required: refer to each specific section, for
certifications, shop drawings, product data and sample requirements.
1.2 SUBMITTAL SCHEDULE
A. The Contractor shall submit within five (5) days of Notice to Proceed, and prior to
proceeding with the site work, a preliminary "Submittal Schedule" to
Sustainability /Projects Director and AMEC /Engineer for review, modification and
response. No payment applications will be processed prior to finalizing the
u . submittal schedule. The "Submittal Schedule" shall contain the following
information for all required submittals on both paper and electronic PDF.
1. Specification Section number and name.
2. Specification Section paragraph identification which describes submittal
requirement.
3. Submittal information required, (i.e., sample, test data, shop drawing, etc.).
B. The Contractor shall also supply the following dates in order to meet the project
schedule.
1. Date submittal is scheduled to be submitted.
2. Date contractor has scheduled to order material or equipment or the
submittal item.
3. Date contractor has scheduled delivery to job -site of material or equipment
or the submittal item.
4. Add any remarks or unique items that Sustainability /Projects Director and
AMEC /Engineer should be aware of.
C. The Contractor shall allow a minimum of two (2) days for review of submittal by
Sustainability /Projects Director and AMEC /Engineer (in calendar days).
D. The submittal master record will then be used to track submittals within the
process.
SUBMITTALS 01301 -Page 101 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
1.3 SHOP DRAWINGS - Not applicable
1.4 PRODUCT DATA
A. Product data such as catalog cuts, brochures or manufacturer's sheets will be
submitted and adequately identified to AMEC /Engineer. Submit four (4) copies of
product data to AMEC /Engineer.
B. Modify product data sheets to delete information which is not applicable to the
Project. Provide additional information if necessary to supplement standard
information.
C. The contractor shall submit seven (7) sets to AMEC /Engineer. AMEC /Engineer
will check and return five (5) copies to the Contractor after review.
1.5 SAMPLES
A. Provide samples to illustrate materials, equipment or workmanship, and to
establish standards by which completed work may be judged.
B. Construct mock -ups as required by the technical sections, at the Project Site in a
location designated by AMEC /Engineer. Construct mock -ups, including adjacent
work required, to demonstrate the final appearance of the Work.
C. The contractor shall submit (3) samples to AMEC /Engineer and (1) will be returned
to the contractor after review /return from AMEC /Engineer.
1.6 CERTIFICATIONS
A. Provide certifications as required by various technical sections on the Contractor's
letterhead stationery. Certifications shall be identified to this Project, dated and
bear Contractor's signature in the same format used for the Owner /Contractor
agreement.
B. Clearly identify the materials referenced and state that the material and the
intended installation methods, where applicable, are in compliance with the
Contract Documents. Attach manufacturer's affidavits where applicable.
C. The Contractor shall submit one (1) original, one (1) electronic and two (2)
hardcopies to AMEC /Engineer. AMEC /Engineer will retain two (2) sets and the
balance returned to the Contractor after review.
1.7 THE CONTRACTOR'S RESPONSIBILITIES
A. Before making submittals to AMEC /Engineer, review each submittal, make
changes or notations as necessary to conform to the Contract Documents, identify
such review with review stamp and forward reviewed submittal with comments to
AMEC /Engineer for review. Return submittals not meeting Contract requirements
' to subcontractors and do not forward such submittals to AMEC /Engineer.
l
SUBMITTALS 01301 -Page 102 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
B. Submit catalog sheets, product data, shop drawings and where specified, submit
calculations, material samples, color chips or charts, test data, warranties and
guarantees all at the same time for each submittal item.
C. Verify field measurements and product catalog numbers or similar data.
D. Clearly identify on the submittal and transmittal to AMEC /Engineer in writing of
deviations in submittals from the requirements of the Contract Documents.
E. After AMEC /Engineer's review, distribute copies with one copy to be maintained at
the Project Site for reference use and other copies distributed to suppliers and
fabricators.
F. Do not begin the Work which requires submittals until return of submittals with
AMEC /Engineer's stamp and initials indicating review.
G. The Contractor's responsibility for errors and omissions in submittals is not relieved
by AMEC /Engineer's review of submittals.
H. The Contractor's responsibility for deviations in submittals from requirements of
the Contract Documents is not relieved by AMEC /Engineer review of submittals
unless AMEC /Engineer gives written acceptance of specific deviations.
1.8 AMEC /ENGINEER'S RESPONSIBILITIES
A. AMEC /Engineer will review submittals with reasonable promptness, checking only
for conformance with the design compliance of the Project and compliance with
information given in the Contract Documents.
B. AMEC /Engineer will make changes or notations directly on the submittal, identify
such review with his review stamp, obtain and record the Record File copy and
return the submittal to the Contractor, with copies to AMEC /Engineer.
C. AMEC /Engineer will return to the Contractor, without review, all submittals not
bearing the Contractor's review stamp or not showing it has been reviewed by the
Contractor.
END SECTION 01301
SUBMITTALS 01301 -Page 103 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
SECTION 01310 - PROGRESS SCHEDULES
PART 1 - GENERAL
1.1 SUMMARY
A. Section includes:
1. Contractor submission of Progress schedules
2. Contractor submission of Revisions to schedules
B. Related sections:
1. Scope of work.
C. Description:
1. Progress Schedules: promptly after award of the Contract and prior to
proceeding with the site work, prepare and submit to Sustainability /Projects
Director and AMEC /Engineer for approval, construction progress
schedules for the work, with sub - schedules of related activities which are
essential to its progress. Also incorporate manpower loading related to
each activity on the construction schedule.
2. Revisions to Schedule: submit revised /updated progress schedules with
each payment application.
1.2 FORMAT
A. Prepare Progress Schedules, Contractor to submit format of schedule for approval
by Sustainability /Projects Director and AMEC /Engineer.
1.3 CONTENT
A. Indicate complete sequence of construction by activity, with dates for beginning
and completion of each element of construction.
B. Identify work of separate stages and other logically grouped activities.
C. Provide sub - schedules to define critical portions of the entire schedule.
1.4 REVISIONS TO SCHEDULES
A. Indicate progress of each activity to date of submittal, and projected completion
date of each activity.
B. Identify activities modified since previous submittal, major changes in scope, and
other identifiable changes.
1. Major changes in scope.
2. Activities modified since previous submission.
3. Revised projections of progress and completion.
PROGRESS SCHEDULES 01310 -Page 104 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
4. Other identifiable changes.
C. Provide a narrative report as needed to define:
1. Problem areas, anticipated delays and the impact on the schedule.
2. Corrective action recommended and its effect.
3. The effect of changes on schedules of other prime contractors.
1.5 SUBMITTALS
A. Submit initial schedules within five (5) days after receipt of the Contract Notice to
Proceed.
1. Sustainability /Projects Director and AMEC /Engineer will review schedules
and return approved copy.
2. Submit revised Progress Schedules with each Application for Payment.
1.6 DISTRIBUTION
A. Distribute copies of the reviewed schedules to:
1. Job site file.
2. Subcontractors.
3. Other concerned parties.
B. Instruct recipients to report promptly to the Contractor, in writing, any problems
anticipated by the projections shown in the schedules.
Note: It is not incumbent upon Sustainability /Projects Director or AMEC /Engineer to
notify the Contractor when to begin, to cease, or to resume work nor to give early
notice of faulty or defective work, or in any way to superintend so as to relieve the
Contractor of responsibility or of any consequence of neglect or carelessness.
END SECTION 01310
PROGRESS SCHEDULES
01310 -Page 105 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
SECTION 01370 - SCHEDULE OF VALUES
PART 1 - GENERAL.
1.1 SUMMARY
A. Section includes: Contractor submission of a Schedule of Values.
1. The Schedule of Values allocated to the various portions of the Work shall
be submitted to Sustainability /Projects Director within five (5) days after
Notice to Proceed.
2. No item in the Schedule of Values shall exceed $25,000.00 without prior
approval from Monroe County Sustainability /Projects Director.
3. Upon request of Sustainability /Projects Director, revise and /or support the
values with data which will substantiate their correctness.
4. The Schedule of Values forms the basis for the Contractor's Applications
for Payment.
5. The Schedule of Values shall be the basis for the amount of credit to be
allowed by the Contractor to the Owner as per 5.6.1 of the Contract.
1.2 FORM AND CONTENT OF SCHEDULE OF VALUES
A. Type schedule on AIA G703 Form; the Contractor's standard forms and automated
printout will be considered by Sustainability /Projects Director upon the Contractor's
request. Identify schedule with:
1. Title of Project and location
2. Architect/Engineer
3. Name and Address of the Contractor
4. Contract designation
5. Date of submission
B. List the installed value of the component parts of the Work in sufficient detail to
serve as a basis for computing values for progress payments during construction.
C. Follow the Specifications as the format for listing component items.
1. Identify each line item with the number and title of the respective major
section of the Specifications.
D. Itemize separate line item cost for each of the following general cost items:
1. Mobilization.
2. Bonds, Insurance and Permits.
3. Clean -up.
4. Submittals.
5. Safety.
E. For each major line item list sub - values of major products or operations under the
item.
F. For the various portions of the Work:
1. Include a directly proportional amount of the Contractor's overhead and
profit for each item.
SCHEDULE OF VALUES 01370 -Page 106 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
2. for items on which progress payments will be requested for stored
materials, break down the value into:
a. The cost of the materials, delivered and unloaded, with taxes paid.
b. The total installed value.
C. Attach vendor invoices.
d. No progress payments will be made for any materials stored off site.
3. Submit a sub - schedule for each separate stage of work specified
G. The sum of values listed in the schedule shall equal the total Contract Sum.
1.3 REVIEW AND SUBMITTAL
A. After review by Sustainability /Projects Director, revise and resubmit schedule (and
Schedule of Material Values) as required.
B. Resubmit revised schedule in same manner.
END SECTION 01370
}
SCHEDULE OF VALUES 01370 -Page 107 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
SECTION 01385 - DAILY CONSTRUCTION REPORTS
PART 1 - GENERAL
1.1 SUMMARY
A. Section includes:
1. Requirement for Daily Construction Reports by the General Contractor.
2. Scheduled submission times for Daily Construction Reports.
1.2 FORM AND CONTENT OF DAILY CONSTRUCTION REPORTS
A. Daily Construction Reports shall be submitted by the General Contractor
performing work on the project. We have provided a form for your use at the end
of this section. If you chose to use your own form, all the information asked for on
the Daily Construction Report form included in this section, must be included on
your form. Items to be addressed on the Report are:
1. Title of Project
2. Name of Contractor
3. Date and day of Report information. For example, you performed work on
Thursday, February 14, 2008, so you would therefore use "Thursday,
- 2/14/08." This holds true even if you did not complete filling out the Report
until Friday, 2/15/08.
4. Contract designation.
5. Note any major Shipments received on that particular day.
6. Note major equipment used that day.
7. Note manpower used, and designate what trades. For example, if you
were the mechanical .contractor, you would also list how many insulators,
pipe fitters, etc., that you were also managing, even if they were
subcontractors. In addition, list the names of the subcontractors that were
on -site that day.
8. Note any deficiencies in your work, and corrective actions taken to resolve
the deficiencies.
9. Note any safety violations discovered, whether or not caused by your
forces.
10. Provide a full description of work performed that day, by all subcontractors,
and or employees, currently working on the project. Furthermore, be sure
to include any problems or unusual conditions discovered.
11. Report is to be signed by the authorized representative of the contractor,
and should the signature not be legible, print the name of the signer next
to the signature.
1.3 SCHEDULE OF SUBMITTING DAILY REPORTS
A. Daily Reports are to be submitted to AMEC /Engineer at the regularly scheduled
Project Meetings. Contractors are to submit the original of their report, and should
keep a copy for their records. AMEC /Engineer or Sustainability Manger
photocopying facilities are not to be used in the reproduction for submission of the
reports.
DAILY CONSTRUCTION REPORTS 01385 -Page 108 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
B. Should contractor fail to comply with these instructions, the contractor's payment
application for the following month will be held in abeyance until such time the
contractor properly submits the delinquent reports.
DAILY CONSTRUCTION REPORT
PROJECT: REPORT NO:
CONTRACTOR:
DATE TIME WEATHER TEMP.RANGE
EST. % OF COMPLETION CONFORMANCE WITH SCHEDULE
WORK IN PROGRESS PRESENT AT SITE
OBSERVATIONS
ITEMS TO SATISFY
INFORMATION OR ACTION REQUIRED
ATTACHMENTS
REPORT BY:
DAILY CONSTRUCTION REPORTS 01385 -Page 109 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
SECTION 01395 - REQUEST FOR INFORMATION (RFI)
PART 1 - GENERAL
1.1 SUMMARY
A. Section includes:
1. Notification to AMEC /Engineer and Sustainability /Projects Director in the
event errors, field conflicts, and omissions are found in the Contract
Documents or clarifications are necessary.
2. Utilization of (RFI) form.
B. Related Sections:
1. General Conditions Article 2.3
2. General Conditions Article 8.3.2
3. General Conditions Article 12.3
1.2 FORM AND CONTENT OF REQUEST FOR INFORMATION
A. All errors, field conflicts, and omissions in the Contract Documents shall be brought
to the attention of AMECHEngineer and Sustainability /Projects Director
immediately. If clarifications are necessary, the request is to be conveyed to
AMEC /Engineer and Sustainability /Projects Director. AMEC /Engineer and
Sustainability /Projects Director will respond to the Contractor. The RFI is a tool
established to provide expedient clarifications of contract drawings, specifications
or field conflicts. It is not meant to be a substitute for good communication.
B. The RFI is not meant for formal notification of extra work. Reference General
Conditions paragraph 8.3.2 and 12.3 (see Supplementary General Conditions),
when formal correspondence is required for formal notification of time extensions,
and for cost change notifications.
C. The responses provided on the RFI form to the Contractor are considered by the
Owner to be clarifications and /or minor changes in the Work not involving an
adjustment in the Contract Sum or an extension of the Contract time per Paragraph
12.4 of the Contract General Conditions. Should the Contractor consider the RFI
response requires extra work, notification in accordance with Paragraph 12.3.1 of
the Supplementary General Conditions is required.
1.3 UTILIZATION OF RFI FORM
A. The RFI form to be utilized is included at the end of this section, if you wish to use a
form of your own; it must contain the same information requested on our form.
J
REQUEST FOR INFORMATION
01395 -Page 110 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
� r
REQUEST FOR INFORMATION (RFI)
DATE
RFI #
PROJECT
FROM
PHONE
TO
PHONE
DESCRIPTION
CONTRACTOR
ADDRESS
FAX CELL
ARCHITECT
ADDRESS
FAX CELL
CONTRACTOR RECOMMENDATION
COSTIMPACT
RESPONSE
NAME DATE
NAME DATE
REQUEST FOR INFORMATION 01395 -Page 111 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
i SECTION 01400 - QUALITY CONTROL
PART 1 - GENERAL
1.1 RELATED DOCUMENTS
A. Drawings and general provisions of the Contract, including General and
Supplementary Conditions, and other Division 1 Specification Sections, apply to
this Section.
1.2 SUMMARY
A. This Section includes administrative and procedural requirements for quality
control services.
B. Quality control services include inspections, tests, and related actions, including
reports performed by Contractor, by independent agencies, and by governing
authorities. They do not include contract enforcement activities performed by
Architect.
C. Inspection and testing services are required to verify compliance with
requirements specified or indicated. These services do not relieve Contractor of
responsibility for compliance with Contract Document requirements.
D. Requirements of this Section relate to ' customized fabrication and installation
procedures, not production of standard products.
1. Specific quality control requirements for individual construction activities
are specified in the Sections that specify those activities. Requirements in
those Sections may also cover production of standard products.
2. Specified inspections, tests, and related actions do not limit Contractor's
quality control procedures that facilitate compliance with Contract
Document requirements.
3. Requirements for Contractor to provide quality control services required by
Owner, or authorities having jurisdiction are not limited by provisions of this
Section.
E. Related Sections: The following Sections contain requirements that are related
to this Section:
1. Division 1 Section "Cutting and patching" specifies requirements for repair
and restoration of construction disturbed by inspection and testing
activities.
2. Division 1 Section "Submittals: specifies requirements for development of
a schedule of required tests and inspections.
1.3 RESPONSIBILITIES
A. The contractor shall be responsible to secure, provide, and pay for all inspections,
test, and other quality - control services specified and required by the contract or
governing authorities. Costs for these services are included in the Contract Sum.
QUALITY CONTROL 01400 -Page 112 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
Any reference in the Contract Documents, Drawings, Front End Documents or
Technical Specifications indicating the Owner is responsible to secure and pay for
testing shall be disregarded and rendered null and void.
Where individual Sections specifically indicate that certain inspections,
tests, and other quality - control services are the Contractor's responsibility,
the Contractor shall employ and pay a qualified independent testing agency
to perform quality - control services. Costs for these services are included
in the Contract Sum.
a. Where the Owner has engaged a testing agency for testing and
inspecting part of the Work, and the Contractor is also required to
engage an entity for the same or related element, the Contractor
shall not employ the entity engaged by the Owner, unless agreed
to in writing by the Owner.
B. Re- testing: The Contractor is responsible for re- testing where results of
inspections, tests, or other quality - control services prove unsatisfactory and
indicate noncompliance with Contract Document requirements, regardless of
whether the original test was Contractor's responsibility.
1. The cost of re- testing construction, revised or replaced by the Contractor,
is the Contractor's responsibility where required tests performed on original
construction indicated noncompliance with Contract Document
requirements.
C. Associated Services: Cooperate with agencies performing required inspections,
tests, and similar services, and provide reasonable auxiliary services as requested.
Notify the agency sufficiently in advance of operations to permit assignment of
personnel. Auxiliary services required include, but are not limited to, the following:
1. Provide access to the Work.
2. Furnish incidental labor and facilities necessary to facilitate inspections and
tests.
3. Take adequate quantities of representative samples of materials that
require testing or assist the agency in taking samples.
4. Provide facilities for storage and curing of test samples.
5. Deliver samples to testing laboratories.
6. Provide the agency with a preliminary design mix proposed for use for
materials mixes that require control by the testing agency.
7. Provide security and protection of samples and test equipment at the
Project Site.
D. Duties of the Testing Agency: The independent agency engaged to perform
inspections, sampling, and testing of materials and construction specified in
individual Sections shall cooperate, with the Architect and the Contractor in
performance of the agency's duties. The testing agency shall provide qualified
personnel to perform required inspections and tests.
QUALITY CONTROL 01400 -Page 113 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
1. The agency shall notify AMEC /Engineer, the Sustainability /Projects
Director and the Contractor promptly of irregularities or deficiencies
observed in the Work during performance of its services.
2. The agency is not authorized to release, revoke, alter, or enlarge
requirements of the Contract Documents or approve or accept any portion
of the Work.
3. The agency shall not perform any duties of the Contractor.
1.4 SUBMITTALS
A. Unless the Contractor is responsible for this service, the independent testing
agency shall submit a certified written report, in duplicate, of each inspection, test,
or similar service to AMEC /Engineer and Sustainability /Projects Director. If the
Contractor is responsible for the service, submit a certified written report, in
duplicate, of each inspection, test, or similar service through the Contractor. .
1. Submit additional copies of each written report directly to the governing
authority, when the authority so directs.
2. Report Data: Written reports of each inspection, test, or similar service
include, but are not limited to, the following:
a. Date of issue.
b. Project title and number.
C. Name, address, and telephone number of testing agency.
d. Dates and locations of samples and tests or inspections.
e. Names of individuals making the inspection or test.
f. Designation of the Work and test method.
g. Identification of product and Specification Section.
h. Complete inspection or test data.
I. Test results and an interpretation of test results.
j. Ambient conditions at the time of sample taking and testing.
k. Comments or professional opinion on whether inspected or tested
Work complies with Contract Document requirements.
I. Name and signature of laboratory inspector.
M. Recommendation on re- testing.
1.5 QUALITY ASSURANCE
A. Qualifications for Service Agencies: Engage inspection and testing service
agencies, including independent testing laboratories, that are pre - qualified as
complying with the American Council of Independent Laboratories" Recommended
Requirements for Independent Laboratory Qualification" and that specialize in the
types of inspections and tests to be performed.
1. Each independent inspection and testing agency engaged on the Project
shall be authorized by authorities having jurisdiction to operate in the state
where the Project is located.
i
PART 2 - PRODUCTS (Not Applicable)
QUALITY CONTROL 01400 -Page 114 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
PART 3 - EXECUTION
3.1 REPAIR AND PROTECTION
A. General: Upon completion of inspection, testing, sample taking and similar
services, repair damaged construction and restore substrates and finishes.
Comply with Contract Document requirements for Division 1 Section "Cutting and
Patching ".
B. Protect construction exposed by or for quality - control service activities, and protect
repaired construction.
C. Repair and protection is Contractor's responsibility, regardless of the assignment
of responsibility for inspection, testing, or similar services.
END SECTION 01400
QUALITY CONTROL
01400 -Page 115 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
SECTION 01410 -TESTING LABORATORY SERVICES
PART 1 - GENERAL
1.1 SUMMARY
A. Section Includes:
1. Selection and payment
2. The Contractor submittals
3. Testing laboratory responsibilities
4. Testing laboratory reports
5. Limits on testing laboratory authority
6. The Contractor responsibilities
7. Schedule of inspections and tests
B. Section Includes:
1. Section 00750 - GENERAL CONDITIONS
2. Section 01700 - CONTRACT CLOSEOUT
3. Section 01800 - SOIL BORING DATA
4. Individual Specification Sections: inspections and tests required, and
standards for testing.
1.2 SELECTION AND PAYMENT
A. The Contractor shall be responsible to secure and pay for all testing services of a
qualified independent testing laboratory to perform specified inspections and
testing as indicated in Technical Specification Sections and as required by the
contract or any governing authorities. Any reference in the Contract Documents,
Drawings, Front End Documents or Technical Specification indicating the Owner
is responsible to secure and pay for testing shall be disregarded and rendered null
and void.
B. Employment of testing laboratory shall in no way relieve the Contractor of obligation
to perform the Work in accordance with requirements of the Contract Documents.
1.3 QUALITY ASSURANCE
A. Testing laboratory: authorized to operate in the State of Florida.
B. Testing laboratory staff: maintain a full time registered Engineer on staff to review
services.
C. Testing Equipment: calibrated at reasonable intervals with devices of accuracy
traceable to either National Bureau of Standards (NBS) standards or accepted
values of natural physical constants.
D. Meet "Recommended Requirements for Independent Laboratory Qualification,"
L published by American Council of Independent Laboratories.
TESTING LABORATORY SERVICES 01410 -Page 116 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
1.4 TESTING LABORATORY RESPONSIBILITIES
A. Test samples of mixes.
B. Provide qualified personnel at the Site. Cooperate with AMEC /Engineer and the
Contractor in performance of services.
C. Perform specified inspection, sampling, and testing of products in accordance with
specified standards.
D. Ascertain compliance of materials and mixes with requirements of the Contract
Documents.
E. Promptly notify AMEC /Engineer and the Contractor of observed irregularities or
non - conformance of the Work or products.
F. Perform additional inspections and tests required by the AMEC /Engineer.
1.5 TESTING LABORATORY REPORTS
A. After each inspection and test, promptly submit copies of testing laboratory report
to AMEC /Engineer and Contractor.
B. Include:
1. Date issued
2. Project title and number
3. Name of inspector
4. Date and time of sampling or inspection
5. Identification of product and Specifications Section
6. Location in the Project
7. Type of inspection or test
8. Date of test
9. Results of test
10. Conformance with the Contract Documents
C. When requested by AMEC /Engineer, provide interpretation of test results.
1.6 LIMITS ON TESTING LABORATORY AUTHORITY
A. The testing laboratory may not release, revoke, alter, or enlarge on requirements
of the Contract Documents.
B. The testing laboratory may not approve or accept any portion of the Work.
C. The testing laboratory may not assume any duties of the Contractor.
D. The testing laboratory has no authority to stop the Work.
TESTING LABORATORY SERVICES 01410 -Page 117 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
I �
1.7 THE CONTRACTOR RESPONSIBILITIES
A. Deliver to the testing laboratory at designated location, adequate samples of
materials proposed to be used which require testing, along with proposed mix
designs.
B. Cooperate with testing laboratory personnel, and provide access to the Work and
to the manufacturer's facilities.
C. Provide incidental labor and facilities to provide access to the Work to be tested,
to obtain and handle samples at the Site or at source of products to be tested, to
facilitate tests and inspections, storage and curing of test samples.
D. Notify AMEC /Engineer and the testing laboratory 24 hours prior to expected time
for operations requiring inspection and testing services.
E. Employ services of a separate qualified testing laboratory and pay for additional
samples and tests which are beyond the specified requirements.
1.8 RETEST RESPONSIBILITY
A. Where the results of required inspections, tests, or similar services prove
unsatisfactory and do not indicate compliance with the requirements of the Contract
Documents, the cost for any re -tests shall be the responsibility of the Contractor.
END SECTION 01410
TESTING LABORATORY SERVICES
01410 -Page 118 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
SECTION 01421 - REFERENCE STANDARDS AND DEFINITIONS
PART 1 — GENERAL
1.1 RELATED DOCUMENTS
A. Drawings and general provisions of Contract, including General and
Supplementary Conditions and other Division 1 Specifications Sections, apply to
this Section.
1.2 DEFINITIONS
A. General: Basic Contract definitions are included in the conditions of this Contract.
B. Indicated: The term "indicated" refers to graphic representations, notes or
schedules on the Drawings, or other Paragraphs or Schedules in the
Specifications, and similar requirements in the Contract Documents. Where terms
such as "shown ", "noted ", "scheduled ", and "specified" are used, it is to help the
reader locate the reference; no limitation on location is intended.
C. Directed: Terms such as "directed ", "requested ", "authorized ", "selected ",
"approved ", "required ", and "permitted" mean "directed by AMEC /Engineer",
"requested by AMEC /Engineer", and similar phrases.
D. Approve: The term "approved ", where used in conjunction with AMEC /Engineer's
action on the Contractor's submittals, applications, and requests, is limited to
AMEC /Engineer's duties and responsibilities as stated in the Conditions of the
Contract.
E. Regulation: The term "regulations" includes laws, ordinances, statutes, and lawful
orders issued by authorities having jurisdiction, as well as rules, conventions, and
agreements within the construction industry that control performance of the Work.
F. Furnish: The term "furnish" is used to mean "supply and deliver to the Project site,
ready for unloading, unpacking, assembly, installation, and similar operations."
G. Install: The term "install" is used to describe operations at project site including
the actual "unloading, unpacking, assembly, erection, placing, anchoring, applying,
working to dimension, finishing, curing, protecting, cleaning, and similar
operations."
H. Provide: The term "provide" means "to furnish and install, complete and ready for
the intended use."
I. Installer: An "Installer" is the Contractor or an entity engaged by the Contractor,
either as an employee, subcontractor, or contractor of lower tier for performance
of a particular construction activity, including installation, erection, application, and
similar operations. Installers are required to be experienced in the operations they
are engaged to perform.
1. The term "experienced ", when used with the term "Installer', means having
a minimum of five previous projects similar in size and scope to this Project,
�) being familiar with the special requirements indicated, and having complied
with requirements of the authority having jurisdiction.
REFERENCE STANDARDS AND DEFINITIONS 01421 -Page 119 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
2. Trades: Use of titles such as "carpentry" is not intended to imply that
certain construction activities must be performed by accredited or
unionized individuals of a corresponding generic name, such as
"carpenter". It also does not imply that requirements specified apply
exclusively to tradespersons of the corresponding general name.
3. Assignment of Specialists: Certain Sections of the Specifications require
that specific construction activities shall be performed by specialists who
are recognized experts in the operations to be performed. The specialists
must be engaged for those activities, and assignments are requirements
over which the Contractor has no choice or option. Nevertheless, the
ultimate responsibility for fulfilling Contract requirements remains with the
Contractor.
a. This requirement shall not be interpreted to conflict with
enforcement of building codes and similar regulations governing the
Work. It is also not intended to interfere with local trade union
jurisdictional settlements and similar conventions.
J. Project Site is the space available to the contractor for performance of construction
activities, either exclusively or in conjunction with others performing other work as
part of the Project. The extent of the Project site is shown on the Drawings and
may or may not be identical with the description of the land on which the Project is
to be built.
K. Testing Laboratories: A "testing laboratory' is an independent entity engaged to
perform specific inspections or tests, either at the Project Site or elsewhere, and
to report on and, if required, to interpret results of those inspection or tests.
1.3 SPECIFICATION FORMAT AND CONTENT EXPLANATION
A. Specification Format: These Specifications are organized into Divisions and
Sections based on the Construction Specifications Institute's 16- Division format
and MASTER FORMAT numbering system.
B. Specification Content: This specification uses certain conventions in the use of
language and the intended meaning of certain terms, words, and phrases when
used in particular situations or circumstances. These conventions are explained
as follows:
Abbreviated Language: Language used in Specifications and other
Contract Documents is the abbreviated type. Words and meanings shall
be interpreted as appropriate. Words that are implied, but not stated shall
be interpolated as the sense required. Singular words will be interpreted
as plural and plural words interpreted as singular where applicable and the
context of the Contract Documents so indicates.
2. Imperative and streamlined language is used generally in the
Specifications. Requirements expressed in the imperative mood are to be
performed by the Contractor. At certain locations in the text, for clarity,
subjective language is used to describe responsibilities that must be
fulfilled indirectly by the Contractor, or by others when so noted.
a. The words "shall be" shall be included by inference wherever a
colon () is used within a sentence or phrase.
REFERENCE STANDARDS AND DEFINITIONS 01421 -Page 120 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
1.4 INDUSTRY STANDARDS
A. Applicability of Standards: Except where the Contract Documents include more
stringent requirements, applicable construction industry standards have the same
force and effect as if bound or copied directly into the Contract Documents to the
extent referenced. Such standards are made a part of the Contract Documents by
reference.
B. Publication Dates: Comply with the standard in effect as of the date of the Contract
Documents.
C. Conflicting Requirements: Where compliance with two or more standards is
specified, and the standards may establish different or conflicting requirements for
minimum quantities or quality levels. Refer requirements that are different, but
apparently equal, and uncertainties to Sustainability /Projects Director for a
decision before proceeding.
1. Minimum Quantity or Quality Levels: The quantity or quality level shown or
specified shall be the minimum provided or performed. The actual
installation may comply exactly with the minimum quantity or quality
specified, or it may exceed the minimum within reasonable limits. In
complying with these requirements, indicated numeric values are minimum
or maximum, as appropriate for the context of the requirements. Refer
uncertainties to AMEC /Engineer for a decision before proceeding.
D. Copies of Standards: Each entity engaged in construction on the Project is
required to be familiar with industry standards applicable to that entity's
construction activity. Copies of applicable standards are not bound with the
Contract Documents.
1. Where copies of standards are needed for performance of a required
construction activity, the Contractor shall obtain copies directly from the
publications source.
E. Abbreviations and Names: Trade association names and titles of general
standards are frequently abbreviated. Where such acronyms or abbreviations are
used in the Specifications or other Contract Documents, they mean the recognized
name of the trade association, standards generating organization, authority having
jurisdiction, or other entity applicable to the context of the text provision. Refer to
the "Encyclopedia of Associations ", published by Gale Research Co., available in
most libraries.
F. Abbreviations and Names: Trade association names and titles of general
standards are frequently abbreviated. The following abbreviations and acronyms,
as referenced in the Contract Documents, mean the associated names. Names
and addresses are subject to change and are believed, but are not assured, to be
accurate and up -to -date as of the date of the Contract Documents.
REFERENCE STANDARDS AND DEFINITIONS 01421 -Page 121 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
REFERENCE STANDARDS AND DEFINITIONS 01421 -Page 122 of 154
AA
Aluminum Association
AABC
Associated Air Balance Council
AAMA
American Architectural Manufacturers
AAN
American Association of Nurserymen
(See ANLA)
AASHTO
American Association of State Highway and Transportation Officials
ACI
American Concrete Institute
ACPA
America Concrete Pipe Association
AHA
American Hardboard Association
Al
Asphalt Institute
AIA
the American Institute of Architects
AISC
American Institute of Steel Construction
AITC
American Institute of Timber Construction
ALA
American Laminators Association
ALSC
American Lumber Standards Committee
AMCA
Air Movement and Control Association International, Inc.
ANLA
American Nursery and Landscape Association
ANSI
American National Standards Institute
APA
APA -The Engineering Wood Association
(Formerly: American Plywood Association)
APA
I Architectural Precast Association
ARMA
Asphalt Roofing Manufacturers Association
ASA
Acoustical Society of America
ASC
Adhesive and Sealant Council
ASHRAE
American Society of Heating, Refrigerating and Air
Conditioning Engineers
ASME
American Society of Mechanical Engineers
REFERENCE STANDARDS AND DEFINITIONS 01421 -Page 122 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
ASPA American Sod Producers Association
(See TPI)
ASTM American Society for Testing and Materials
AWI Architectural Woodwork Institute
AWPA American Wood Preservers' Association
AWS American Welding Society
BHMA Builders Hardware Manufacturers Association
BIA Brick Institute of America
EIMA EIFS Industry Members Association
EJMA Expansion Joint Manufacturers Association
FM Factory Mutual System
GA Gypsum Association
GANA Glass Association of North America
(Formerly: Flat Glass Marketing Association)
HMA Hardwood Manufacturers Association
(Formerly: Southern Hardwood Lumber Manufacturers Association)
HPVA Hardwood Plywood and Veneer Association
MFMA Maple Flooring Manufacturers Association
NAAMM National Association of Architectural Metal Manufacturers
NECA National Electrical Contractors Associations
NEI National Elevator Industry
NELMA Northeastern Lumber Manufacturers Association
NEMA National Electrical Manufacturers Association
NFPA National Fire Protection Association
NHLA National Hardwood Lumber Association
NLGA National Lumber Grades Authority
NOFMA National Oak Flooring Manufacturers Association
REFERENCE STANDARDS AND DEFINITIONS 01421 -Page 123 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
NWWDA National Wood Window and Door Association
(Formerly: National Woodwork Manufacturers Association)
PCA . Portland Cement Association
PCI • Precast/Prestressed Concrete Institute
RFCI Resilient Floor Covering Institute
SDI Steel Door Institute
SGCC Safety Glazing Certification Council
SIGMA Sealed Insulating Glass Manufacturing Association
SMACNA Sheet Metal and Air Conditioning Contractor's National
Association, Inc.
SPIB Southern Pine Inspection Bureau
SPRI SPRI (Formerly: Single Ply Roofing Institute)
SWRI Sealant, Waterproofing and Restoration Institute
TCA Tile Council of America
UL Underwriters Laboratories, Inc.
WCLIB West Coast Lumber Inspection
WIC Woodwork Institute of California
WWPA Western Wood Products Association
G. Federal Government Agencies: Names and titles of Federal Government standards -or
specification - producing agencies are often abbreviated. The following abbreviations and
acronyms referenced in the Contract Documents indicate names of standards -or
specification - producing agencies of the Federal Government. Names and addresses are
subject to change and are believed, but are not assured, to be accurate and up -to -date as
of the date of the Contract Documents.
OSHA Occupational Safety and Health Administration
(U.S. Department of Labor)
200 Constitution Ave., NW
Washington, DC 20210
END SECTION 01421
REFERENCE STANDARDS AND DEFINITIONS 01421 -Page 124 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
�! SECTION 01500 - TEMPORARY FACILITIES
PART 1 — GENERAL
1.1 DESCRIPTION
A. Work included: Provide temporary facilities needed for the Work including, but
not necessarily limited to:
1. Temporary utilities such as water, electricity, and telephone.
2. Field office for the Contractor's personnel.
3. Sanitary facilities.
4. Enclosures such as tarpaulins, barricades, and canopies.
5. Temporary fencing of the construction site as required for public and
employee safety.
6. Project sign.
B. Related Work:
1. Documents affecting work of this Section include, but are not necessarily
limited to Supplementary Conditions, and Sections in Division 1 of these
Specifications.
1.2 PRODUCT HANDLING
A. Maintain temporary facilities and controls in proper and safe condition throughout
progress of the Work.
PART 2 - PRODUCTS
2.1 FIELD OFFICES AND SHEDS
A. Contractor's facilities:
1. Not Applicable
B. Sanitary facilities:
1. Provide temporary sanitary facilities in the quantity required for use by all
personnel.
2. Maintain in a sanitary condition at all times.
2.2 ENCLOSURES
A. Provide and maintain for the duration of construction all scaffolds, tarpaulins,
canopies, warning signs, steps, platforms, bridges, and other temporary
construction necessary for proper completion of the Work in compliance with
pertinent safety and other regulations.
B. Upon completion of the Work, remove job signs.
TEMPORARY FACILITIES 01500 -Page 125 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
C. Except as otherwise specifically approved by the Owner, do not permit other signs
or advertising on the job site.
2.3 TEMPORARY FENCING
A. Provide and maintain for the duration of construction a temporary fence or
barricade of design and type needed to prevent entry onto the Work by the public.
2.4 PROJECT SIGNS:
A. Prior to start of construction, mount a project sign on a 4'x8' sheet of plywood.
Securely fasten the sign to the building or posts set in the ground as approved by
Sustainability /Projects Director. A design provided by, or approved by
Sustainability /Projects Director will include, but not necessarily be limited to: the
project name; the Owner's name; major tenant's names; the Contractor's name,
address, and telephone number, and the Engineer's name, address, and
telephone number.
PART 3 — EXECUTION
3.1 MAINTENANCE AND REMOVAL
A. Maintain temporary facilities and controls as long as needed for safe and proper
completion of the Work.
B. Remove such temporary facilities, to include existing mobile home, and controls
as rapidly as progress of the Work will permit, or as directed by the Owner.
END SECTION 01500
i
TEMPORARY FACILITIES 01500 -Page 126 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
SECTION 01520 - CONSTRUCTION AIDS
PART 1 - GENERAL
1.1 SUMMARY
A. Section includes:
1. Construction aids
2. Temporary enclosures
1.2 REQUIREMENTS OF REGULATORY AGENCIES
B. Comply with Federal, State and local codes and regulations.
PART 2 - PRODUCTS
2.1 MATERIALS - GENERAL
A. Materials may be new or used, suitable for the intended use and shall not violate
requirements of applicable codes and standards.
2.2 CONSTRUCTION AIDS
A. The Contractor shall be responsible for furnishing, installing, maintaining, and
removing on completion of the Work all scaffolds, staging, ladders, stairs, ramps,
runways, platforms, railings, chutes, and other such facilities and equipment
required by his personnel to insure their safety and facilitate the execution of the
Work.
1. The Contractor shall comply with all Federal, State and local codes, laws
and regulations governing such construction aids.
2. The Contractor shall relocate such construction aids as required by the
progress of construction, by storage or work requirements, and to
accommodate the legitimate requirements of the Owner or AMEC /Engineer
or other separate contractors employed at the site.
3. The Contractor shall completely remove temporary scaffolds, access,
platforms, and other such materials, facilities, and equipment, at the
completion of the Work or when construction needs can be met by the use
of the permanent construction, provided AMEC /Engineer has approved
and authorized such use. The Contractor shall clean up and shall repair
any damage caused by the installation or by the use of such temporary
construction aids. The Contractor shall restore any permanent facilities
used for temporary purposes to their specified condition.
The foregoing obligations of the Contractor are in addition to his obligations under Article
10 of the General Conditions.
Tom.
h�
CONSTRUCTION AIDS
01520 -Page 127 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
�1 2.3 TEMPORARY ENCLOSURES
A. The Contractor shall be responsible for installing the permanent closure in an
opening in an exterior wall and shall be responsible for installing, maintaining, and
removing, as the Work progresses, a temporary weather -tight enclosure for that
opening as necessary to provide acceptable working conditions, to provide
weather protection for interior materials, to allow for effective temporary heating
and /or cooling, and to prevent entry of unauthorized persons.
1. The Contractor shall install such temporary enclosures as soon as is
practical after the opening is constructed or as directed by AMEC /Engineer.
2. Temporary enclosures shall be removable as necessary for the Work and
for handling of materials.
3. Temporary enclosures shall be completely removed when construction
needs can be met by the use of the permanent closures.
4. The Contractor responsible for providing, maintaining, and removing the
temporary enclosure shall clean and shall repair any damage caused by
the installation of such enclosure.
5. The Contractor shall remain responsible for insuring that his work, material,
equipment, supplies, tools, machinery, and construction equipment is
adequately protected from damage or theft and shall provide, maintain and
remove such additional temporary enclosures as may be deemed
necessary.
The foregoing obligations of the Contractor are in addition to his obligations under Article
10 of the General Conditions.
END SECTION 01520
CONSTRUCTION AIDS 01520 -Page 128 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
SECTION 01550 -ACCESS ROADS AND PARKING AREAS
A. The Contractor shall be responsible for installing and maintaining, until the
completion of his Work any temporary access roads or parking facilities required
by his Work, other than that which has been provided or required by the Owner.,
after approval from the Owner has been obtained. The Contractor shall remove
temporary access roads and parking facilities and restore the areas to original or
required grades.
B. Any Contractor excavating across an access road or parking area shall back -fill
and compact his excavation and resurface the road or parking area to match the
existing surface. The Contractor shall comply with all applicable Specifications
when so doing.
i
END SECTION 01550
ACCESS ROADS AND PARKING AREAS
01550 -Page 129 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
SECTION 01560 -TEMPORARY CONTROLS
PART 1 - GENERAL
1.1 SUMMARY OF WORK BY THE CONTRACTOR
A. Section Includes:
1. Water control
2. Dust control
3. Erosion and sediment control
4. Pollution control
B. Related sections:
1. SCOPES OF WORK
1.2 WATER CONTROL
A. Contractor shall grade site to drain.
B. Protect site from puddling or running water. Provide water barriers to protect site
from soil erosion. Maintain excavations free of water. Provide, operate, and
maintain pumping equipment.
1.3 DUST CONTROL
A. Execute the Work by methods to minimize raising dust from construction
operations.
B. Provide positive means to prevent airborne dust from dispersing into atmosphere.
1.4 EROSION AND SEDIMENT CONTROL
A. Plan and execute construction by methods to control surface drainage from cuts
and fills, from borrow and waste disposal areas. Prevent erosion and
sedimentation.
B. Minimize amount of bare soil exposed at one time.
C. Provide temporary measures such as berms, dikes, and drains, to prevent water
flow.
D. Construct fill and waste areas by selective placement to avoid erosive surface silts
or clays.
E. Inspect earthwork to detect evidence of erosion and sedimentation; promptly apply
corrective measures.
TEMPORARY CONTROLS 01560 -Page 130 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
1.5 POLLUTION CONTROL
A. Provide methods, means, and facilities to prevent contamination of soil, water, and
atmosphere from discharge of noxious, toxic substances, and pollutants produced
by construction operations.
END SECTION 01560
TEMPORARY CONTROLS 01560 -Page 131 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
SECTION 01590 - FIELD OFFICES AND SHEDS
A. The Contractor shall furnish, install, and maintain a temporary field office if required
by Sustainability /Projects Director and AMEC /Engineer for his use, the use of his
employees, and the use AMEC /Engineer during the construction period. The
location of the Field Office shall be determined by Sustainability /Projects Director
and AMEC /Engineer.
B. The Contractor shall furnish, install, and maintain temporary storage and work
sheds to adequately protect his work, materials, equipment, supplies, tools,
machinery, and construction equipment from damage and theft.
C. The Contractor shall arrange his field office and sheds so as not to interfere with
the construction. The locations of field offices and sheds shall be coordinated with
Sustainability /Projects Director and AMEC /Engineer. The type, size and location
of field offices and sheds are subject to approval by Sustainability /Projects Director
and AMEC /Engineer.
D. The Contractor shall arrange and pay for temporary electricity and telephone
service for his field office and sheds, if he should require such services.
E. The Contractor shall relocate his field office and sheds as directed by
Sustainability /Projects Director, at no additional cost to the Owner.
F. The Contractor shall remove his field office and sheds on completion of the Work
or when directed by Sustainability /Projects Director and AMEC /Engineer. The
Contractor shall remove all debris and rubbish and shall leave the area in a clean
and orderly condition.
END SECTION 01590
FIELD OFFICES AND SHEDS 01590 -Page 132 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
SECTION 01595 - CONSTRUCTION CLEANING
PART 1 - GENERAL
1.1 SUMMARY OF WORK PERFORMED BY THE CONTRACTOR
A. Section includes:
1. Cleaning during progress of work.
1.2 DISPOSAL REQUIREMENTS
A. Conduct cleaning and disposal operations to comply with codes, ordinances,
regulations, and anti - pollution laws.
1. Do not burn or bury rubbish and waste materials on Project Site.
2. Do not dispose of volatile wastes such as mineral spirits, oil or paint thinner
in storm or sanitary drains.
PART 2 - PRODUCTS
2.1 MATERIALS
A. Use only those cleaning materials which will not create hazards to health or
property and which will not damage surfaces.
B. Use only those cleaning materials and methods recommended by manufacturer of
the surface material to be cleaned.
C. Use cleaning materials only on surfaces recommended by cleaning material
manufacturer.
D. Sweeping compounds used in cleaning operations shall leave no residue on
concrete floor surfaces that may affect installation of finish flooring materials.
PART 3 - EXECUTION
3.1 DURING CONSTRUCTION
A. Execute cleaning to keep the Work, the Site and adjacent properties free from
accumulations of waste materials, rubbish and windblown debris, resulting from
construction operations.
B. Provide on -site containers for the collection of waste materials, debris, and
rubbish.
C. Dispose of waste materials, debris and rubbish off site at a state permitted disposal
site.
CONSTRUCTION CLEANING 01595 -Page 133 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
1 D. Trash containers shall be provided by Contractor and located in trash accumulation
areas designated by AMEC /Engineer. Contractor each day shall collect and
deposit in the containers all rubbish, waste materials, debris, and other trash from
his operations, including any trash generated by his employees during lunch
periods or coffee breaks. Shipping dunnage is also to be removed by the
contractor. Paper, boxes and bulk packaging shall be folded or cut into reasonable
sizes and shapes as appropriate and confined to prevent loss of trash due to wind
relocation. Full trash containers shall be disposed and replaced as necessary to
maintain above requirements and /or as directed by AMEC /Engineer. Contractor
shall use properly licensed solid waste hauling vendors, licensed to operate in
Monroe County.
END SECTION 01595
CONSTRUCTION CLEANING 01595 -Page 134 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
1 i SECTION 01600 - MATERIAL AND EQUIPMENT
PART 1 - GENERAL
1.1 SUMMARY OF WORK PERFORMED BY THE CONTRACTOR
A. Section includes:
1
2
3
4
1.2 PRODUCTS
Products
Transportation and handling
Storage and protection
Security
A. Products: means new material, machinery, components, equipment, fixtures, and
systems forming the Work. Products do not include machinery and equipment
used for preparation, fabrication, conveying and erection of the Work. Products
may also include existing materials or components required for reuse.
B. Do not use materials and equipment removed from existing premises, except as
specifically permitted by the Contract Documents.
C. Provide interchangeable components of the same manufacturer, for similar
components.
1.3 TRANSPORTATION AND HANDLING
A. The Contractor shall be responsible for the transportation of all materials and
equipment furnished under this contract. Unless otherwise noted, the Contractor
shall also be responsible for loading, receiving and off - loading at the site all
material and equipment installed under this Contract, whether furnished by the
Contractor or the Owner. The Contractor shall be responsible for coordinating the
installation within the buildings of equipment that is too large to pass through
finished openings.
B. Transport and handle products in accordance with manufacturer's instructions.
C. Promptly inspect shipments to assure that products comply with requirements,
quantities are correct, and products are undamaged.
D. Provide equipment and personnel to handle products by methods to prevent
soiling, disfigurement, or damage.
1.4 STORAGE AND PROTECTION
The Contractor shall be responsible for the proper storage of all materials,
supplies, and equipment to be installed under this Contract. Materials stored on
site but not adequately protected will not be included in estimates for payment.
Except for materials stored within designated and approved storage sheds, vans,
MATERIAL AND EQUIPMENT 01600 -Page 135 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
or trailers, the Contractor shall not bring onto nor store in any manner at the site
any materials and equipment which will not be incorporated into the permanent
Work within seven (7) days from the delivery date. The Contractor shall be
responsible for arranging and paying for the use of property off the site for storage
of materials and equipment as may be required.
1.5 SECURITY
A. The Contractor shall be totally responsible for the security of his work, materials,
equipment, supplies, tools, machinery, and construction equipment.
END SECTION 01600
MATERIAL AND EQUIPMENT 01600 -Page 136 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
SECTION 01630 - POST - CONTRACT SUBSTITUTIONS
PART 1 - GENERAL
1.1 SUMMARY
A. Section includes:
Post - proposal substitutions
1.2 SUBSTITUTIONS
A. Base Proposal shall be in accordance with the Contract Documents.
B. After the end of the proposal period, substitution requests, from the successful
Proposer, will be considered only in the case of:
1. Product unavailability.
2. Other conditions beyond the control of the Contractor.
C. Submit a separate request for each substitution. Support each request with the
following information:
1. Complete data substantiating compliance of proposed substitution with
requirements stated in Contract Documents:
a. Product identification, including manufacturer's name and address.
b. Manufacturer's literature, identifying:
1) Product description.
2) Reference standards.
3) Performance and test data.
C. Samples, as applicable.
d. Name and address of similar projects on which product has been
used and date of each installation.
2. Itemized comparison of the proposed substitution with product specified,
listing significant variations.
3. Data relating to changes in construction schedule.
4. Effects of substitution on separate contracts.
5. List of changes required in other work or products.
6. Accurate cost data comparing proposed substitution with product specified.
a. Amount of net change to Contract Sum.
7. Designation of required license fees or royalties.
8. Designation of availability of maintenance services, sources of
replacement materials.
D. Substitutions will not be considered for acceptance when:
1. A substitution is indicated or implied on shop drawings or product data
submittals without a formal request from Proposer.
2. Acceptance will require substantial revision of Contract Documents.
3. In judgment of AMEC /Engineer the substitution request does not include
adequate information necessary for a complete evaluation.
POST CONTRACT SUBSTITUTIONS 01630 -Page 137 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
4. Requested directly by a subcontractor or supplier.
E. Do not order or install substitute products without written acceptance of
AMEC /Engineer.
F. AMEC /Engineer will determine acceptability of proposed substitutions.
G. No verbal or written approvals other than by Change Order will be valid.
1.3 CONTRACTOR'S REPRESENTATION
A. In making formal request for substitution the Contractor represents that:
1. The proposed product has been investigated and it has been determined
that it is equivalent to or superior in all respects to the product specified.
2. The same warranties or bonds will be provided for the substitute product
as for the product specified.
3. Coordination and installation of the accepted substitution into the Work will
be accomplished and changes as may be required for the Work to be
complete will be accomplished.
4. Claims for additional costs caused by substitution which may subsequently
become apparent will be waived by the Contractor.
5. Complete cost data is attached and includes related costs under the
Contract, but not:
a. Costs under separate contracts.
b. Sustainability /Projects Director's costs for redesign or revision of
Contract Documents.
1.4 POST - PROPOSAL SUBSTITUTION FORM
A. The form is attached to this section.
B. Substitutions will be considered only when the attached form is completed and
included with the submittal with back -up data.
POST CONTRACT SUBSTITUTIONS 01630 -Page 138 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
POST - PROPOSAL SUBSTITUTION FORM
TO: AMEC /Engineer
We hereby submit for your consideration the following product instead of the specified item for
the above project:
DRAWING NO: DRAWING NAME:
SPEC. SEC. SPEC. NAME PARAGRAPH SPECIFIED ITEM
Proposed Substitution:
Attach complete information on changes to Drawings and /or Specifications which proposed
substitution will require for its proper installation.
Submit with request necessary samples and substantiating data to prove equal quality and
performance to that which is specified. Clearly mark manufacturer's literature to indicate equality
in performance.
The undersigned certifies that the function, appearance and quality are of equal performance and
assumes liability for equal performance, equal design and compatibility with adjacent materials.
Submitted By:
Signature
Firm
Address
Title
Telephone Date
Signature shall be by person having authority to legally bind his firm to the above terms. Failure
to provide legally binding signature will result in retraction of approval.
For use by the Architect/Engineer: For use by the Owner
Recommended Recommended as noted Approved
Not Recommended Received too late Not Approved
Insufficient data received Approved as noted
By:
Date:
0
Date:
POST CONTRACT SUBSTITUTIONS 01630 -Page 139 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
Fill in Blanks Below:
A. Does the substitution affect dimensions shown on Drawings?
Yes No If yes, clearly indicate changes:
B. Will the undersigned pay for changes to the building design, including engineering and
detailing costs caused by the requested substitution?
Yes No If no, fully explain:
C. What effect does substitution have on other Contracts or other trades?
D. What effect does substitution have on construction schedule?
E.
Manufacturer's warranties of the proposed and specified items are:
Same Different. Explain:
F. Reason for Request:
G. Itemized comparison of specified item(s) with the proposed substitution; list significant
variations:
H. This substitution will amount to a credit or extra cost to the Owner of:
dollars ($ ).
I. Designation of maintenance services and sources:
(Attach additional sheets if required.)
END SECTION 01630
POST CONTRACT SUBSTITUTIONS 01630 -Page 140 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
�1 SECTION 01640 - PRODUCT HANDLING
PART I-- GENERAL
1.1 DESCRIPTION: THE CONTRACTOR SHALL BE RESPONSIBLE FOR
A. Work included. Protect products scheduled for use in the Work by means
including, but not necessarily limited to, those described in this Section.
B. Related work:
1. Documents affecting work of this Section include, but are not
necessarily limited to, General Conditions, Supplementary
Conditions, and Sections in Division of these Technical Special
Provisions.
2. Additional procedures also may be prescribed in other Sections of
these Technical Special Provisions.
1.2 QUALITY ASSURANCE
A. Include within the Contractor's quality assurance program such procedures
as are required to assure full protection of work and materials.
1.3 MANUFACTURERS' RECOMMENDATIONS
A. Except as otherwise approved by Sustainability /Projects Director,
determine and comply with manufacturers' recommendations on product
handling, storage, and protection.
1.4 PACKAGING
A. Deliver products to the job site in their manufacturer's original container,
with labels intact and legible.
1. Maintain packaged materials with seals unbroken and labels intact
until time of use.
2. Promptly remove damaged material and unsuitable items from the
job site, and promptly replace with material meeting the specified
requirements, at no additional cost to the Owner.
B. AMEC /Engineer may reject as non - complying such material and products
that do not bear identification satisfactory to AMEC /Engineer as to
manufacturer, grade, quality, and other pertinent information.
1.5 PROTECTION
A. Protect finished surfaces through which equipment and materials are
handled.
PRODUCT HANDLING 01640 -Page 141 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
B. Provide protection for finished floor surfaces in traffic area prior to allowing
equipment or materials to be moved over such surfaces.
C. Maintain finished surfaces clean, unmarred, and suitably protected until
accepted by the Owner.
1.6 REPAIRS AND REPLACEMENTS
A. In event of damage, promptly make replacements and repairs to the
approval of AMEC /Engineer and at no additional cost to the Owner.
B. Additional time required to secure replacements and to make repairs will
not be considered by AMEC /Engineer and Sustainability /Projects Director
to justify an extension in Contract Time of Completion.
END SECTION 01640
PRODUCT HANDLING 01640 -Page 142 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
SECTION 01700 - CONTRACT CLOSEOUT
PART 1 — GENERAL
1.1 PROJECT TERMINATION
A. The Contract requirements are met when construction activities have
successfully produced, in this order, these three terminal activities:
1. Substantial Completion
2. Final Completion
3. Final Payment
1.2 NOTICE OF SUBSTANTIAL COMPLETION
A. Contractor shall submit to AMEC /Engineer when work is substantially
complete:
1. A written notice that the Work, or designated portion thereof, is
substantially complete.
2. Request Substantial Completion Observation at a mutually
agreeable date.
3. Certifications of systems and testing /balancing final reports.
4. Submit evidence of compliance with requirements of governing
- authorities:
a. Certificate of Occupancy (or Completion)
b. Certificates of Inspection as applicable:
1) Electrical systems if required by Code
B. Within a reasonable time after receipt of such notice, the Owner and the
Contractor will make an observation to determine the status of completion.
C. Should the Owner determine that the work is not substantially complete,
the following will occur:
1. The Owner will promptly notify the Contractor in writing, giving the
reasons.
2. The Contractor shall remedy the deficiencies in the Work, and send
a second written notice of substantial completion to the Owner.
3. The Owner will re- observe the Work.
D. When the Owner concurs that the Work is substantially complete, the
following will occur:
1. AMEC /Engineer will prepare a Certificate of Substantial Completion
accompanied by the Punch List of items to be completed or
corrected, as verified and amended by Sustainability /Projects
Director. Contract responsibilities are not altered by inclusion or
omission of required Work from the punch list.
2. The Owner will submit the certificate to the contractor for written
acceptance of the responsibilities assigned to them in the
certificate.
CONTRACT CLOSEOUT 01700 -Page 143 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
E. Contractor shall complete or correct items identified on the punch list and
required by the Contract requirements within time limit established by the
certificate.
1.3 FINAL COMPLETION
A. To attain final completion, the Contractor shall complete activities
pertaining to substantial completion, complete Work on punch list items and
submit written request to the Owner for final inspection within thirty (30)
calendar days of date of substantial completion.
B. When the Work is complete, the Contractor shall submit written
certification that:
1. The Contract Documents have been reviewed.
2. Work has been inspected for compliance with the Contract
Documents.
3. Work has been completed in accordance with the Contract
Documents.
4. Equipment and systems have been tested in the presence of the
Owner's representative and are operational.
5. Work is completed and ready for final observation.
C. The Owner and the Contractor will make an inspection to verify the status
of completion with reasonable promptness after receipt of such
certification.
D. Should the Owner consider that the Work is incomplete or defective:
1. The Owner will promptly notify the Contractor in writing, listing the
incomplete or defective work.
2. The Contractor shall take immediate steps to remedy the stated
deficiencies and send a second written certification to the Owner
that the Work is complete.
3. The Owner will re- inspect the Work.
E. When the Work is acceptable under the Contract Documents as
determined by the Owner, the Owner will request the Contractor to make
close -out submittals. Warranties & Guarantees for everything will begin at
Substantial Completion.
1.4 THE CONTRACTOR'S CLOSEOUT SUBMITTALS TO THE OWNER
Contractor shall provide two (2) hard copies in tabulated divided binders and one
(1) saved electronically tabbed and indexed in Adobe Acrobat file (.PDF) format
delivered on a downloadable CD /DVD or flash drive of the all the following but not
limited to:
A. Project Record Documents (As Built Documents).
CONTRACT CLOSEOUT 01700 -Page 144 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
B. Operating and maintenance data, instructions to the Owner's personnel.
C. Warranties, bond and guarantees.
D. Keys and keying schedule.
E. Spare parts and maintenance materials.
F. Electronic copies of approved submittals
G. Evidence of payment and final release of liens and consent of surety to final
release (includes final release from all utilities and utility companies).
1.5 FINAL ADJUSTMENT OF ACCOUNTS
A. Submit a final statement of accounting to the Owner.
B. Statement shall reflect adjustments to the Contract Sum:
1. The original Contract Sum
2. Additions and deductions resulting from:
a. Previous Change Orders
b. Allowances
C. Deductions for uncorrected Work
d. Deductions for Liquidated Damages
e. Deductions for Re- inspection Payments
f. Other Adjustments
C. The Owner will prepare a final Change Order, reflecting adjustments to the
Contract Sum which were not previously made by Change Orders.
1.6 FINAL APPLICATION FOR PAYMENT
A. The Contractor shall submit the final Application for Payment in accordance
with procedures and requirements stated in the Conditions of the Contract.
END SECTION 01700
CONTRACT CLOSEOUT 01700 -Page 145 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
SECTION 01710 - FINAL CLEANING
PART 1 - GENERAL
1.1 SUMMARY
A. Section includes:
1. Contractor's cleaning at completion of Work
1.2 DISPOSAL REQUIREMENTS
A. Conduct cleaning and disposal operations to comply with codes,
ordinances, regulations, and anti - pollution laws.
1. Do not burn or bury rubbish and waste materials on the Project Site.
2. Do not dispose of volatile wastes such as mineral spirits, oil or paint
thinner in storm or sanitary drains.
PART 2 - PRODUCTS
2.1 MATERIALS
A. Use only those cleaning materials which will not create hazards to health
or property and which will not damage surfaces.
B. Use only those cleaning materials and methods recommended by
manufacturer on the surface material to be cleaned.
C. Use cleaning materials only on surfaces recommended by cleaning
material manufacturer.
PART 3 - EXECUTION
3.1 DUST CONTROL
A. Handle materials in a controlled manner with as little handling as possible.
3.2 FINAL CLEANING
A. Employ skilled workmen for final cleaning.
B. Remove grease, mastic, adhesives, dust, dirt, stains, fingerprints, labels,
and other foreign materials from sight- exposed interior and exterior
surfaces.
C. Polish glossy surfaces to a clear shine.
D. Broom clean exterior paved surfaces; rake clean other surfaces of the
grounds.
FINAL CLEANING 01710 -Page 146 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
✓) E. Prior to final completion, or the Owner occupancy, conduct an inspection
of sight- exposed interior surfaces, exterior surfaces and work areas, to
verify that the entire Work is clean.
F. Clean tunnels and closed off spaces of packing boxes, wood frame
members and other waste materials used in the Construction.
G. Remove temporary labels and stickers from fixtures and equipment. Do
not remove permanent name plates, equipment model numbers and
ratings.
H. Remove from the Site all items installed or used for temporary purposes
during construction.
Restore all adjoining areas to their original or specified condition.
END SECTION 01710
FINAL CLEANING 01710 -Page 147 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
C1
1 SECTION 01720 - PROJECT RECORD DOCUMENTS
PART 1 - GENERAL
1.1 SUMMARY
A. Contractor shall:
1. Maintain at the job site one copy of:
a.
Record Contract Drawings
b.
Record Project Manual
C.
Coordination drawings
d.
Addenda
e.
Reviewed shop drawings
f.
Change Orders
g.
Other modifications to the Contract
h.
Field test records
1.2 GENERAL
A. Store documents in cabinets in temporary field office, apart from
documents used for construction.
B. Maintain documents in clean, dry, legible condition.
C. Do not use Project Record Documents for construction purposes.
D. Make documents available for inspection by AMEC /Engineer.
E. Failure to maintain documents up -to -date will be cause for withholding
payments.
F. Obtain from Sustainability /Projects Director (at no charge) two sets of the
Contract Documents for Project Record Documents including:
1. Specifications with all addenda.
2. Two complete sets of black -line prints of all Drawings.
1.3 RECORDING
A. Label each document "Project Record ".
B. Keep record documents current.
C. Do not permanently conceal any work until required information has been
recorded.
D. Contract Drawings:
PROJECT RECORD DOCUMENTS 01720 -Page 148 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
1. Required information may, as an option, be entered on a "working
set" and then at completion of Project transfer the information to
final submitted "Project Record" set.
2. Legibly mark to record actual construction:
a. Depths of various elements of foundation in relation to
survey data.
b. Horizontal and vertical location of underground utilities and
appurtenances referenced to permanent surface
improvements.
C. Location of internal utilities and appurtenances concealed in
construction referenced to visible and accessible features of
structure.
d. Field changes of dimension and detail.
e. Changes made by Change Order or Construction Change
Directive.
f. Details not on original Contract Drawings.
E. Specifications and Addenda:
1. Legibly mark up each Section to record:
a. Manufacturer, trade name, catalog number and supplier of
each product and item of equipment actually installed.
b. Changes made by Change Order or Construction Change
Directive.
C. Other items not originally specified.
F. Conversion of schematic layouts:
1. Arrangement of conduits, circuits, piping, ducts and similar items
are in most cases shown schematically on the Drawings.
2. Legibly mark to record actual construction:
a. Dimensions accurate to within 1" on the centerline of items
shown schematically.
b. Identify each item, for example, "cast iron drain" "galvanized
water ".
C. Identify location of each item, for example, "under slab ", "in
ceiling plenum ", "exposed ".
3. AMEC /Engineer may waive requirements of schematic layout
conversion, when in his opinion, it serves no beneficial purpose. Do
not, however, rely on waivers being issued except when specifically
issued by AMEC /Engineer in writing.
1.4 SUBMITTAL
A. At completion of Project, deliver, Project Record Documents to
AMEC /Engineer prior to request for final payment.
PROJECT RECORD DOCUMENTS 01720 -Page 149 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
i
B. Accompany submittal with transmittal letter, in duplicate, containing:
1. Date
2. Project title and Project number
3. The Contractor's name and address
4. Title and number of each record document
5. Certification that each document as submitted is complete and
accurate.
6. Signature of the Contractor, or his authorized representative.
END SECTION 01720
PROJECT RECORD DOCUMENTS 01720 -Page 150 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
SECTION 01730 - OPERATION AND MAINTENANCE DATA
PART 1 — GENERAL - Not Applicable
END SECTION 01730
OPERATION AND MAINTENANCE DATA 01730 -Page 151 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
SECTION 01740 -WARRANTIES
PART 1 — GENERAL
1.1 RELATED DOCUMENTS
A. Drawings and general provisions of the Contract, including General and
Supplementary Conditions and other Specification Sections, apply to this
Section.
1.2 SUMMARY
A. This Section includes administrative and procedural requirements for the
Contractor for warranties required by the Contract Documents, including
manufacturer's standard warranties on products and special warranties.
1. Refer to the General Conditions for terms of the Contractor's period for
correction of the Work.
B. Related Sections: Not Applicable
- °. C. Disclaimers and Limitations: Manufacturer's disclaimers and limitations on
j product warranties do not relieve the Contractor or the warranty on the Work that
incorporates the products. Manufacturer's disclaimers and limitations on product
warranties do not relieve suppliers, manufacturers, and subcontractors required
to countersign special warranties with the Contractor.
D. Separate Prime Contracts: Each prime contractor is responsible for warranties
related to its own contract.
1.3 DEFINITIONS
A. Standard products warranties are preprinted written warranties published by
individual manufacturers for particular products and are specifically endorsed by
the manufacturer to the Owner.
B. Special warranties are written warranties required by or incorporated in the
Contract Documents, either to extend limits provided by standard warranties or to
provide greater rights for the Owner.
1.4 WARRANTY REQUIREMENTS
A. Related Damages and Losses: When correcting failed or damaged warranted
construction, remove and replace construction that has been damaged as a
result of such failure or must be removed and replaced to provide access for
correction of warranted construction.
WARRANTIES 01740 -Page 152 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
B. Reinstatement of Warranty: When Work covered by a warranty has failed and
been corrected by replacement or rebuilding; reinstate the warranty by written
endorsement. The reinstated warranty shall be equal to the original warranty
with an equitable adjustment for depreciation.
C. Replacement Cost: Upon determination that Work covered by a warranty has
failed, replace or rebuild the Work to an acceptable condition complying with
requirements of the Contract Documents. The Contractor is responsible for the
cost of replacing or rebuilding defective Work regardless of whether the Owner
has benefited from use of the Work through a portion of its anticipated useful
service life.
D. Owner's Recourse: Expressed warranties made to the Owner are in addition to
implied warranties and shall not limit the duties, obligations, rights, and remedies
otherwise available under the law. Expressed warranty periods shall not be
interpreted as limitations on the time in which the Owner can enforce such other
duties, obligations, rights or remedies.
E. Where the Contract Documents require a special warranty, or similar
commitment on the Work or part of the Work, the Owner reserves the right to
refuse to accept the Work, until the Contractor presents evidence that entities
required to countersign such commitments are willing to do so.
-- 1.5 SUBMITTALS
l J
A. Submit written warranties to Sustainability /Projects Director prior to the date
certified for Substantial Completion. If the Sustainability /Projects Director's
Certificate of Substantial Completion designates a commencement date for
warranties other than the date of Substantial Completion for the Work, or a
designated portion of the Work, submit written warranties upon request of
Sustainability /Projects Director.
B. When the Contract Documents require the Contractor, or the Contractor and a
subcontractor or supplies manufacturer to execute a special warranty, prepare a
written document that contains appropriate terms and identification, ready for
execution by the required parties. Submit a draft to the Owner, through Project
Management, for approval prior to final execution.
C. Form of Submittal: At Final Completion compile 2 copies of each required
warranty properly executed by the Contractor, or by the Contractor,
subcontractor, supplier, or manufacturer. Organize the warranty documents into
an orderly sequence.
D. Bind warranties and bonds in heavy -duty, commercial - quality, durable 3 -ring,
vinyl- covered loose -leaf binders, thickness as necessary to accommodate
contents, and sized to receive 8'/z x 11" (115 -by- 280 -mm) paper.
1. Provide heavy paper dividers with celluloid covered tabs for each
separate warranty. Mark the tab to identify the product or installation.
Provide a typed description of the product or installation, including the
WARRANTIES 01740 -Page 153 of 154
BACKFILLING WATER QUALITY IMPROVEMENT PROJECTS,
CANAL #75 ROCK HARBOR, KEY LARGO, MONROE COUNTY, FL
name of the product, and the name, address, and telephone number of
the Installer.
2. Identify each binder on the front and spine with the typed or printed title
"WARRANTIES ", Project title or name, and name of the Contractor.
3. When warranted construction requires operation and maintenance
manuals, provide additional copies of each required warranty, as
necessary, for inclusion in each required manual.
4. Provide one complete electronic copy on CD /DVD
5. Warranties will be submitted with the final project closure package
END SECTION 01740
WARRANTIES 01740 -Page 154 of 154