Item C0711 1 1k I I A
�Wltci 010 cffilla 13
Meeting Date: June 11, 2014 Division: PubHc Works/Enp-ineerine
Bulk Item: Yes X No Department: Engineering Services Department
Staff Contact Person/Phone #: Judy Clarke X4329
AGENDA ITEM WORDING: Approval of a contract with Parsons Brinckerhoff, Inc. for
Construction Engineering and Inspection (CEI) services for the No Name Key Bridge Repair Project.
This project is funded by Florida Department of Transportation (FDOT) through a Local Agency
Program (LAP) Agreement.
. I I
NONNI WS,
M11 Iffs"I MR "I. I Rein gg orm &Mkoxmill $IVA$)* up.61J41,0741ANINAM 111140 QWA -1112
and Construction Engineering and Inspection (CEI) phases to the bridge at the October 2013 BOCC
meeting. BOCC approved advertising an RFQ for CEI services in November 2013. BOCC approved
negotiating a contract with Parsons Brinckerhoff, Inc., the highest ranked respondent at the April 2014
meeting.
CONTRACT/AGREEMENT CHANGES: Contract attached. I
TOTAL COST: $363,702.90 INDIRECT COST: BUDGETED: Yes X No
DIFFERENTIAL OF LOCAL PREFERENCE: _not applicable
COST TO COUNTY:_ $90,925.73 SOURCE OF FUNDS: FDOT LAP
REVENUE PRODUCING: Yes —No X AMOUNT PER MONTH Year
APPROVED BY: CountyAt�t OMB/Puria-sing— Risk Managemen6l'
DOCUMENTATION: Included x Not Required
DISPOSITION: AGENDAITEM[n
Revised 7109
CONTRACT SUMMARY
Contract with: Parsons Brinckerhoff, Contract #
Inc. Effective Date: June 11, 2014
Expiration Date:
Contract Purpose/Description:
Construction Engineering and Inspection (CEI) services for the No Name Key Bridge
Repair-Pro*t
Contract Manager: JRd Clarke 4329 Engineeringt#I
(Name) (Ext.) (Department/Stop #)
for BOCC meeting on 6/11/14 Agenda Deadline: 5/27/14
Total Dollar Value of Contract: $ 363,702.90 Current Year Portion: $ 120,021.66
Budgeted? Yes X No AccountCodes: 12-,5
Grant: $ 272.777.17
County Match: $ 90,925.73
I - -
ADDITIONAL COSTS
Estimated Ongoing Costs: $-/yr For:
(Not included in dollar value above) (eg. maintenance. utilities,
Changes
Date In Needed
D"'Ye [:] No[2
ivision Do irectr s
Risk Management j �( " Yes E] NoET
O.M.B./Ac sing i� YesEl No®
County Attorney � 4-� H YesE] No®
Reviewer,
Salaries, etc.)
5-d
This Agreement ("Agreement") made and entered into this 11th day of June, 2014 by
?nd between Monroe County, a political subdivision of the State of Florida, whose address is
1100 Simonton Street, Key West, Florida, 33040, its successors and assigns, hereinafter
referred to as "COUNTY," through the Monroe County Board of County Commissioners
AND
Parsons Brinckerhoff, Inc., a Corporation of the State of New York, whose address is
Ine Penn Plaza, New York NY 10119 its successors and assigns, hereinafter referred to as
"CONSULTANT",
WITNESSETH:
WHEREAS, COUNTY desires to employ the professional services of CONSULTANT
construction engineering and inspection (CEI) services for the No Name Key Bridge Repair
Project; and
WHEREAS, CONSULTANT has agreed to provide professional services which shall
include but not be limited to providing construction engineering and inspection (CEI) services for
the No Name Key Bridge Repair Project, which services shall collectively be referred to as the
"Project";
NOW, THEREFORE, in consideration of the mutual promises, covenants and
agreements stated herein, and for other good and valuable consideration, the sufficiency of
which is hereby acknowledged, COUNTY and CONSULTANT agree as follows:
1;[qJ;JJTJKq1VAT L I :J
By executing this Agreement, CONSULTANT makes the following express representations an."it'
warranties to the COUNTY:
1.1.1 The CONSULTANT shall maintain all necessary licenses, permits or other authorizations
necessary to act as CONSULTANT for the Project until the CONSULTANT'S duties
hereunder have been fully satisfied;
1.1.2 The CONSULTANT has become familiar with the Project site and the local conditions
under which the Work is to be completed.
�W Ell r. I III IQ War., I a 4 a 12VAM I g I IN or-4arn 0 0 oil Lei
completed and shall be in conformity and comply with all applicable law, codes and
regulations. The CONSULTANT warrants that the documents prepared as a part of this
Agreement will be adequate and sufficient to document costs in a manner that is
acceptable for reimbursement by government agencies, therefore eliminating any
additional cost due to missing or incorrect information;
1.1.4 The CONSULTANT assumes full responsibility to the extent allowed by law with regards
to his performance and those directly under his employ.
1.1.5 The CONSULTANT'S services shall be performed as expeditiously as is consistent with
professional skill and care and the orderly progress of the Project. In providing all
services pursuant to this agreement, the CONSULTANT shall abide by all statutes,
ordinances, rules and regulations pertaining to, or regulating the provisions of such
services, including those now in effect and hereinafter adopted. Any violation of said
statutes, ordinances, rules and regulations shall constitute a material breach of this
agreement and shall entitle the Board to terminate this contract immediately upon
delivery of written notice of termination to the CONSULTANT.
1.1.6 At all times and for all purposes under this agreement the CONSULTANT is an
independent contractor and not an employee of the Board of County Commissioners for
Monroe County. No statement contained in this agreement shall be construed so as to
find the CONSULTANT or any of his/her employees, contractors, servants, or agents to
be employees of the Board of County Commissioners for Monroe County.
1.1.7 The CONSULTANT shall not discriminate against any person on the basis of race,
creed, color, national origin, sex, age, or any other characteristic or aspect which is not
job related, in its recruiting, hiring, promoting, terminating, or any other area affecting
employment under this agreement or with the provision of services or goods under this
agreement.
1.1.8 The CONSULTANT shall complete the scope of services no later than 30 days after
Final Completion of the No Name Key Bridge Repair Project by the construction
contractor.
CONSULTANT'S Scope of Basic Services consists of those described in Attachment A. The
CONSULTANT shall commence work on the services provided for in this Agreement promptly
upon his receipt of a written notice to proceed from the COUNTY.
The CONSULTANT shall, without additional compensation, promptly correct any errors,
omissions, deficiencies, or conflicts in the work product of the CONSULTANT or its
subconsultants, or both.
All written correspondence to the COUNTY shall be dated and signed by an authorized
representative of the CONSULTANT. Any notice required or permitted under this agreement
shall be in writing and hand delivered or mailed, postage pre -paid, to the COUNTY by certified
mail, return receipt requested, to the following:
Ms. Judith Clarke, P.E.
Director of Engineering Services
Monroe County
1100 Simonton Street, Room 2-216
Key West, Florida 33040
And: Mr. Roman Gastesi, Jr.
Monroe County Administrator
1100 Simonton Street, Room 2-205
Key West, Florida 33040
For the Consultant:
ARTICLE III
F-11 11111119 [0161 FIX
3.1 Additional services are services not included in the Scope of Basic Services. Should t
COUNTY require additional services they shall be paid for by the COUNTY at rates or
fees negotiated at the time when services are required, but only if approved by the
COUNTY before commencement. I
3.2 If Additional Services are required the COUNTY shall issue a letter requesting and
describing the requested services to the CONSULTANT. The CONSULTANT shall
respond with a fee proposal to perform the requested services. Only after receiving an
amendment to the Agreement and a notice to proceed from the COUNTY, shall the
CONSULTANT proceed with the Additional Services.
ARTICLE IV
4.1 The COUNTY shall provide full information regarding requirements for the Project
including physical location of work, county maintained roads, maps.
4.2 The COUNTY shall designate a representative to act on the COUNTY's behalf with
respect to the Project. The COUNTY or its representative shall render decisions in a
timely manner pertaining to documents submitted by the CONSULTANT in order to
2void unreasonable delay in the orderly and sequential progress of the CONSULTANT'S
zervices.
,�.3 Prompt written notice shall be given by the COUNTY and its representative to the
CONSULTANT if they become aware of any fault or defect in the Project or non-
conformance with the Agreement Documents. Written notice shall be deemed to have
been duly served if sent pursuant to paragraph 2.3.
4.4 The COUNTY shall furnish the required information and services and shall render
approvals and decisions as expeditiously as necessary for the orderly progress of thti
CONSULTANT'S services and if • the contractors.
4.5 The C09:V%TY's review of any documents prepared by the CONSULTANT or its
subconsultants shall be solely for the purpose of determining whether such documents
are generally • with the COUNTY's criteria, as, and if, modified. No review •
such documents shall relieve the CONSULTANT of responsibility for the accuracy,
adequacy, fitness, suitability or coordination of its work product.
4.6 The COUNTY shall provide copies of necessary documents required to complete the
•
4.7 Any information that may • of assistance to the CONSULTANT that the COUNTY h
-• access to will •' provided as requested. I
ARTICLE V
INDEMNIFICATION AND HOLD HAl2,11LESS
5.1 The CONSULTANT covenants and agrees to indemnify and hold harmless
COUNTY/Monroe • and Monroe • Board • • Commissioners, its
officers and employees from liabilities, damages, losses and costs, including • no5
limited to, reasonable attorneys' fees, to the extent caused by the negligence,
recklessness, or intentional wrongful conduct of the CONSULTANT, subcontractor(s)
and other persons employed or utilized by the CONSULTANT in the performance of the
•
5.2 The first ten dollars ($10.00) of remuneration paid to the CONSULTANT is for the
indemnification provided for above. The extent of liability is in no way limited to,
reduced, or lessened by the insurance requirements contained elsewhere within this
agreement. Subject to Florida Statute 725.08, should any claims be asserted againsAl
the COUNTY by virtue of any deficiency or ambiguity in the plans and specifications
provided by the CONSULTANT, the CONSULTANT • and warrants that he shall
hold the COUNTY harmless and shall indemnify him from all losses occurring thereby
• shall further defend any claim • action • the COUNTY'S behalf.
5.3 In the event the completion of the project (to include the work of others) is delayed or
suspended as a result of the CONSULTANT'S failure to purchase or maintain the
required insurance, the CONSULTANT shall indemnify COUNTY from any and all
increased expenses resulting from such delays. Subject to Florida Statute 725.08,
should any claims be asserted against COUNTY • virtue • any deficiencies or
ambiguity in the plans and specifications provide by the CONSULTANT the
CONSULTANT agrees and warrants that CONSULTANT hold the COUNTY harmless
2nd shall indemnify it from all losses occurring thereby and shall further defend any
claims or action on the COUNTY'S behalf.
5.4 The extent of liability is in no way limited to, reduced or lessened by the insuranct
requirements contained elsewhere within the Agreement.
I U =1 W*16
The CONSULTANT shall assign only qualified personnel to perform any service concerning the
project. At the time of execution of this Agreement, the parties anticipate that the following
named individuals will perform those functions as indicated:
FWFUNIIIIISR
7.1 PAYMENT SUM
7.1.1 The COUNTY shall pay the CONSULTANT monthly in current funds for the
CONSULTANT'S performance of this Agreement based on the rates outlined in
Attachment B. The Total Not to Exceed Amount of Three Hundred Sixty Three
Thousand Seven Hundred Two Dollars and Ninety Cents ($363,702.90) will apply to
this Agreement.
7.2 PAYMENTS
For its assumption and performances of the duties, obligations and responsibilities set
forth herein, the CONSULTANT shall be paid monthly. Payment will be made pursuant
to the Local Government Prompt Payment Act 218.70, Florida Statutes.
�A) If the CONSULTANT'S duties, obligations and responsibilities are materially
changed by amendment to this Agreement after execution of this Agreement,
compensation due to the CONSULTANT shall be equitably adjusted, either
upward or downward;
(B) As a condition precedent for any payment due under this Agreement, the
CONSULTANT shall submit monthly, unless otherwise agreed in writing by the
COUNTY, a proper invoice to COUNTY requesting payment for services properly
rendered and reimbursable expenses due hereunder. The CONSULTANT'S
invoice shall describe with reasonable particularity the service rendered. The
CONSULTANT'S invoice shall be accompanied by such documentation or data
in support of expenses for which payment is sought at the COUNTY may require.
7.3 REIMBURSABLE EXPENSES
7.3.1 Reimbursable expenses include expenses incurred by the CONSULTANT in the interest
of the project:
Direct Expenses (i.e. temporary living expenses, storage, and direct expenses per
FDOT allowable) submitted by the CONSULTANT, in writing, in connection with the
project authorized by the COUNTY, in writing and in accordance with expenses as
set forth in Attachment B
7.4.1 The CONSULTANT may not be entitled to receive, and the COUNTY is not obligated tit!
pay, any fees or expenses in excess of the amount budgeted for this contract in each
fiscal year (October 1 - September 30) by COUNTY's Board of County Commissioners.
The budgeted amount may only be modified by an affirmative act of the COUNTY's
Board of County Commissioners.
7.4.2 The COUNTY's performance and obligation to pay under this Agreement is contingent
upon an annual appropriation by the Board of County Commissioners and the approval
of the Board members at the time of contract ination and its duration.
Z ITTI-111 I
T 1.1 The CONSULTANT shall obtain insurance as specified and maintain the required
insurance at all times that this Agreement is in effect. In the event the completion of the
project (to include the work of others) is delayed or suspended as a result of the
CONSULTANT'S failure to purchase or maintain the required insurance, the
CONSULTANT shall indemnify the COUNTY from any and all increased expenses
resulting from such delay.
8.2 The coverage provided herein shall be provided by an insurer with an A.M. Best rating of
VI or better, that is licensed to business in the State of Florida and that has an agent for
service of process within the State of Florida. The coverage shall contain an
endorsement providing sixty (60) days notice to the COUNTY prior to any
cancellation of said coverage. Said coverage shall be written by an insurer acceptable -
to the COUNTY and shall be in a form acceptable to the COUNTY.
1 111,11! 1 Pill �1111 11111111 1 1111111111 ��1111 1111111 11 111!1111 1111111 1111 111111 !!1111
N. Workers' Compensation insurance as required by the State of Florida, sufficient to
respond to Chapter 440 Florida Statutes.
B. Employers Liability Insurance with limits of $1,000,000 per Accident, $1,000,000
Disease, policy limits, $1,000,000 Disease each employee.
C. Comprehensive business automobile and vehicle liability insurance covering claims
for injuries to members of the public and/or damages to property of others arising
from use of motor vehicles, including onsite and offsite operations, and owned, hired
or non -owned vehicles, with One Million Dollars ($1,000,000.00) combined single
limit and One Million Dollars ($1,000,000.00) annual aggregate.
D. Commercial general liability, including Personal Injury Liability insurance covering
claims for injuries to members of the public or damage to property of others arising
out of any covered act or omission of the CONSULTANT or any of its employees,
agents or subcontractors or subconsultants, including Premises and/or Operations,
Products and Completed Operations, Independent Contractors; Broad Form Property
Damage and a Contractual Liability Endorsement with One Million Dollars
($1,000,000) per occurrence and annual aggregate.
,II�afaue-punc,YII ", Muns MUM Inuilue COTO Oyu 0 MOMS MUT-un or auter
the effective date of this Agreement. In addition, the period for which they may be
reported must extend for a minimum of 48 months following the termination or
expiration of this Agreement.
E. Professional liability insurance of One Million Dollars ($1,000,000.00) per claim and
Two Million Dollars ($2,000,000.00) annual aggregate. If the policy is a "claims
made" policy, CONSULTANT shall maintain coverage or purchase a "tail" to cover
claims made after completion of the project to cover the statutory time limits in
Chapter 95 of the Florida Statutes.
F. COUNTY shall be named as an additional insured with respect to CONSULTANTS
liabes hereunder in insurance coverage idented in Paragraphs C and D.
EMMEMME, �_M
required by COUNTY during the term of this Agreement. COUNTY will not pay for
increased limits of insurance for subconsultants.
H. CONSULTANT shall provide to the COUNTY certificates of insurance or a copy of all
insurance policies including those naming the COUNTY as an additional insured by
including any subsection hereunder. The COUNTY reserves the right to require a
certified copy of such policies upon request.
If the CONSULTANT participates in a self-insurance fund, a Certificate of Insurance
will be required. In addition, the CONSULTANT may be required to submit updated
financial statements from the fund upon request from the COUNTY.
Effia 94
T, rm� IN NO 0 M1511
Section headings have been inserted in this Agreement as a matter of convenience of
reference only, and it is agreed that such section headings are not a part of this
Agreement and will not be used in the interpretation of any provision of this Agreement.
The documents prepared by the CONSULTANT for this Project belong to the COLID31�0c"
and may be reproduced and copied without acknowledgement or permission of the
CONSULTANT.
9.2.1 PUBLIC ACCESS
'.6-ursuant to F.S. 119.0701, Contractor and its subcontractors shall comply with all
*ublic records laws of the State of Florida, including but not limited to:
(a) Keep and maintain public records that ordinarily and necessarily would be required
I-
.ty Monroe County in order to perform the service.
(b) Provide the public with access to public records on the terms and conditions that
Monroe County would provide the records and at a cost that does not exceed the cosl
provided in Florida Statutes, Chapter 119 or as otherwise provided by law.
(c) Ensure that public records that are exempt or confidential and exempt from publ
records disclosure requirements are not disclosed except as authorized by lz I
(d) Meet all requirements for retaining public records and transfer, at no cost, to
Monroe County all public records in possession of the contractor upon termination of
the contract and destroy any duplicate public records that are exempt or confidential
and exempt from public records disclosure requirements. All records stored
electronically rnueƒ be provided to Monroe County in o format that is cmrnpobb|e with the
information technology systems of Monroe County.
The CONSULTANT shall not assign or subcontract its obligations under this agreement,
except in writing and with the prior written approval of the Board of County
Commissioners for K8mnnme County and the CC]NSULTANT, which approval ahe|| be
subject to such conditions and provisions as the Board may deem necessary. This
paragraph shall be incorporated by reference into any assignment orsubcontract and
any assignee or subcontractor shall comply with all of the provisions of this agreement.
Subject to the provisions of the immediately preceding oentenme, each party hereto
binds itee|f, its successors, assigns and |eQo| representatives tothe other and to the
successors, assigns and legal representatives ofsuch other party.
Nothing contained herein shall create any ndaUonahip, contractual or otherwise, with or
any rights in favor of, any third party.
A.|nthe event that the CONSULTANT shall be found to benegligent inany aspect of
service, the COUNTY shall have the right toterminate this agreement after five days
written notification tothe CONSULTANT.
B. Either of the parties hereto may cancel this Agreement without cause by giving the
other party sixty (60) days written notice of its intention to do so.
This contract consists of the Request for Que|ifioadono, any addenda, the Form of
Agreement (Articles |-|XD, the CONSULTANT'S response tothe RFQ, the documents
referred to in the Form of Agreement as a part of this Agreement including attachments
Athrough E. and modifications made after execution by written amendment. In the
event of any conflict between any of the Contract doounnento, the one imposing the
greater burden on the CONSULTANT will control.
A person or affiliate who has been placed on the convicted vendor list following a
conviction for public entity crime may not submit a bid on contracts to provide any goods
or services to a public entitv, may not submit a bid on a contract with o public entity for
the construction or repair of o public building or public xxorh, may not submit bids on
leases of real property to public entity, may not be awarded or perform work as o
oontrootor, aupp|ier, auboontnactmr, or consultant under contract with any public entity,
and may not transact business with any public entity in excess of the threshold amount
provided in Section 287.D17ofthe Florida Statubae, for CATEGORY TWO for a period of
3Gmonths from the date ofbeing placed onthe convicted vendor list.
By signing this Agreement, CONSULTANT represents that the execution of this
Agreement will not violate the Public Entity Crimes Act (Section 287.133, Florida
Statutes). Violation of this section shall result in termination of this Agreement and
recovery of all monies paid hereto, and may result in debarment from COUNTY's
competitive procurement activities.
In addition to the foregoing, CONSULTANT further represents that there has been no
determination, based on an audit, that it or any subconsultant has committed an act
defined by Section 287.133, Florida Statutes, as a "public entity crime" and that it has
not been formally charged with committing an act defined as a "public entity crime"
regardless of the amount of money involved or whether CONUSULTANT has been
placed on the convicted vendor list.
CONSULTANT will promptly notify the COUNTY if it or any subcontractor or
subconsultant is formally charged with an act defined as a "public entity crime" or
has been placed on the convicted vendor list.
CONSULTANT shall maintain all books, records, and documents directly pertinent to
performance under this Agreement in accordance with generally accepted accounting
principles consistently applied. Records shall be retained for a period of five years from
the termination of this agreement. Each party to this Agreement or its authorized
representatives shall have reasonable and timely access to such records of each other
party to this Agreement for public records purposes during the term of the Agreement
and for four years following the termination of this Agreement. If an auditor employed by
the COUNTY or Clerk determines that monies paid to CONSULTANT pursuant to this
Agreement were spent for purposes not authorized by this Agreement, or werz
wrongfully retained by the CONSULTANT, the CONSULTANT shall repay the monies
together with interest calculated pursuant to Sec. 55.03, of the Florida Statutes, running
from the date the monies were paid by the COUNTY.
This Agreement shall be governed by and construed in accordance with the laws of the
State of Florida applicable to contracts made and to be performed entirely in the State.
In the event that any cause of action or administrative proceeding is instituted for the
enforcement or interpretation of this Agreement, COUNTY and CONSULTANT agree
that venue shall lie in the 16 th Judicial Circuit, Monroe County, Florida, in the appropriate
court or before the appropriate administrative body. This agreement shall not be subject
to arbitration. Mediation proceedings initiated and conducted pursuant to this
Agreement shall be in accordance with the Florida Rules of Civil Procedure and usual
and customary procedures required by the circuit court of Monroe County.
9.10 SEVERABILITY
I (SX: I AV,= I tale I I I I A gg-ml a 61--1 me I I I, W-1 2 r� I In siziffs [--Isi t; I K--lom I a kvf- I I Le E,03 al, Is 17-11 um ter-1; I In yr-M 100R� I ITAgm -
by a court of competent jurisdiction, the remaining terms, covenants, conditions and
provisions of this Agreement, shall not be affected thereby; and each remaining term,
covenant, condition and provision of this Agreement shall be valid and shall be
enforceable to the fullest extent permitted by law unless the enforcement of the
remaining terms, covenants, conditions and provisions of this Agreement would prevenl
the accomplishment of the original intent of this Agreement. The COUNTY and
CONSULTANT agree to reform the Agreement to replace any stricken provision with a
valid provision that comes as close as possible to the intent of the stricken provision.
The COIWATY and CONSULTANT agree that in the event any cause of action or
administrative proceeding is initiated or defended by any party relative to the
enforcement or interpretation of this Agreement, the prevailing party shall be entitled to
reasonable attorney's fees, court costs, investigative, and out-of-pocket expenses, as an
award against the non -prevailing party, and shall include attorney's fees, courts costs,
investigative, and out-of-pocket expenses in appellate proceedings.
9.12 BINDING EFFECT
The terms, covenants, conditions, and provisions of this Agreement shall bind and inure
to the benefit of the COUNTY and CONSULTANT and their respective legal
representatives, successors, and assigns.
MEFIEW-lift.w[*T;wj
Each party represents and warrants to the other that the execution, delivery and
2&*_rTN0tf �1-5?X-F �y CIUPO�-2.�Zi
corporate action, as required by law.
CONSULTANT and COUNTY agree that each shall be, and is, empowered to apply for,
seek, and obtain federal and state funds to further the purpose of this Agreement;
provided that all applications, requests, grant proposals, and funding solicitations shall
be approved by each party prior to submission.
PXPIM-M I I ". � 1 11,14.1
COUNTY and CONSULTANT agree that all disputes and disagreements shall be
attempted to be resolved by meet and confer sessions between representatives of each
of the parties. If no resolution can be agreed upon within 30 days after the first meet and
confer session, the issue or issues shall be discussed at a public meeting of the Board of
County Commissioners. If the issue or issues are still not resolved to the satisfaction of
the parties, then any party shall have the right to seek such relief or remedy as may be
provided by this Agreement or by Florida law. This provision does not negate or waive
the provisions of paragraph 9.5 concerning termination or cancellation.
PAIRAMOTST101:2 4 :?-1% 11 15016T,
and CONSULTANT agree to participate, to the extent required by the other party, in all
proceedings, hearings, processes, meetings, and other activities related to the
substance of this Agreement or provision of the services under this Agreement.
COUNTY and CONSULTANT specifically agree that no party to this Agreement shall be
required to enter into any arbitration proceedings related to this Agreement.
CONSULTANT and COUNTY agree that there will be no discrimination against any
person, and it is expressly understood that upon a determination by a court of competent
jurisdiction that discrimination has occurred, this Agreement automatically terminates
without any further action on the part of any party, effective the date of the court order.
CONSULTANT or COUNTY agrees to comply with all Federal and Florida statutes, and
all local ordinances, as applicable, relating to nondiscrimination. These include but are
not limited to: 1) Title VI of the Civil Rights Act of 1964 (PL 88-352) which prohibits
discrimination on the basis of race, color or national origin; 2) Title IX of the Education
Amendment of 1972, as amended (20 USC ss. 1681-1683, and 1685-1686), which
prohibits discrimination on the basis of sex; 3) Section 504 of the Rehabilitation Act of
1973, as amended (20 USC s. 794), which prohibits discrimination on the basis of
handicaps; 4) The Age Discrimination Act of 1975, as amended (42 USC ss. 6101-6107)
which prohibits discrimination on the basis of age; 5) The Drug Abuse Office and
Treatment Act of 1972 (PL 92-255), as amended, relating to nondiscrimination on the
basis of drug abuse; 6) The Comprehensive Alcohol Abuse and Alcoholism Prevention,
Treatment and Rehabilitation Act of 1970 (PL 91-616), as amended, relating to
nondiscrimination on the basis of alcohol abuse or alcoholism; 7) The Public Health
Service Act of 1912, ss. 523 and 527 (42 USC ss. 690dd-3 and 290ee-3), as amended,
relating to confidentiality of alcohol and drug abuse patient records; 8) Title Vill of the
Civil Rights Act of 1968 (42 USC s. et seq.), as amended, relating to nondiscrimination in
the sale, rental or financing of housing; 9) The Americans with Disabilities Act of 1990
(42 USC s. 1201 Note), as may be amended from time to time, relating to
nondiscrimination on the basis of disability; 10) Monroe County Code Chapter 13,
Article V1, which -trohibits discrimination on the basis of race color sex, relirrrr - ion national
origin, ancestry, sexual orientation, gender identity or expression, familial atus or age;
11) Any other nondiscrimination provisions in any Federal or state statutes which may
apply to the parties to, or the subject matter of, this Agreement.
CONSULTANT and COUNTY covenant that neither presently has any interest, and shall
not acquire any interest, which would conflict in any manner or degree with its
performance under this Agreement, and that only interest of each is to perform and
receive benefits as recited in this Agreement.
COUNTY agrees that officers and employees of the COUNTY recognize and will be
required to comply with the standards of conduct for public officers and employees as
delineated in Section 112.313, Florida Statutes, regarding, but not limited to, solicitation
or acceptance of gifts; doing business with one's agency; unauthorized compensation;
misuse of public position, conflicting employment or contractual relationship; and
disclosure or use of certain information.
The • and • warrant that, in respect to itself, it has neither
employed nor retained any company or person, other than a bona fide employee
working solely for it, to solicit or secure this Agreement and that it has not paid or agreed
• •. any person, company, corporation, individual, • firm, other than a r• fide
employee working solely for it, any fee, commission, percentage, gift, or other
consideration contingent upon or resulting • the award • making • this Agreement.
For the breach or violation of the provision, the CONSULTANT agrees that the COUNTY
shall have the right to terminate this Agreement without liability and, at its discretion, to
offset from monies owed, • otherwise recover, the full amount • such fee, commission,
percentage, gift, or consideration.
9.21 PUBLIC ACCESS.
The CONSULTANT and COUNTY shall allow and permit reasonable access to, and
inspection of, all documents, papers, letters or other materials in its possession or under
its control subject to the provisions of Chapter 119, Florida Statutes, and made or
received by the CONSULTANT and COUNTY in connection with this Agreement; and
the COUNTY shall have the right to unilaterally cancel this Agreement upon violation of
this provision by •
Notwithstanding the provisions of Sec. 768.28, Florida Statutes, the participation of the
CONSULTANT and the COUNTY in this Agreement and the acquisition of any
commercial _• insurance coverage, self-insurance coverage, • • ••
liability insurance pool coverage shall not be deemed a waiver of immunity to the extent
•r liability coverage, • shall any contract entered into • the • • required to
• any provision for waiver.
All of the privileges and immunities from liability, exemptions from laws, ordinances, and
rules and pensions and relief, disability, workers' compensation, and other benefits
which apply to the activity of officers, agents, or employees of any public agents or
employees of the '• when performing their respective • under this
or statutory duties of the COUNTY, except to the extent permitted by the Florida
constitution, state statute, and case law.
No person or entity shall be entitled to rely upon the terms, or any of them, of this
Agreement to enforce or attempt to enforce any third -party claim or entitlement to or
benefit of any service or program contemplated hereunder, and the CONSULTANT and
the COUNTY agree that neither the CONSULTANT nor the COUNTY or any agent,
officer, or employee of either shall have the authority to inform, counsel, or otherwise
indicate that any particular individual or group of individuals, entity or entities, have
entitlements or benefits under this Agreement separate and apart, inferior to, or superior
to the community in general or for the purposes contemplated in this Agreement.
CONSULTANT agrees to execute such documents as COUNTY may reasonably
require, including a Public Entity Crime Statement, an Ethics Statement, and a Drug -
Free Workplace Statement. Signature of this Agreement by CONSULTANT shall act as
the execution of a truth in negotiation certificate stating that wage rates and other factual
unit costs supporting the compensation pursuant to the Agreement are accurate,
complete, and current at the time of contracting. The original contract price and any
additions thereto shall be adjusted to exclude any significant sums by which the agency
determines the contract price was increased due to inaccurate, incomplete, or
concurrent wage rates and other factual unit costs. All such adjustments must be made
within one year following the end of the Agreement.
No covenant or agreement contained herein shall be deemed to be a covenant or
?.greement of any member, officer, agent or employee of Monroe County in his or her
individual capacity, and no member, officer, agent or employee of Monroe County shall
be liable personally on this Agreement or be subject to any personal liability or
?ccountability by reason of the execution of this Agreement.
This Agreement may be executed in any number of counterparts, each of which shall be
regarded as an original, all of which taken together shall constitute one and the same
instrument and any of the parties hereto may execute this Agreement by signing any
such counterpart.
It is the policy of the COUNTY that DBE's, as defined in 49 C.F.R. Part 26, as
amended, shall have the opportunity to participate in the performance of contract
financed in whole or in part with COUNTY funds under this Agreement. The DBE
requirements of applicable federal and state laws and regulations apply to this
Agreement. The COUNTY and its CONSULTANT agree to ensure that DBE's ha
the opportunity to participate in the performance of this Agreement. In this regard]
all recipients and contractors shall take all necessary and reasonable steps in
accordance with applicable federal and state laws and regulations to ensure that
the DBE's have the opportunity to compete for and perform contracts. The
COUNTY and the CONSULTANT and subcontractors shall not discriminate on the
basis of race, color, national origin or sex in the award and performance of
contracts, entered pursuant to this Agreement.
9.30 FEDERAL HIGHWAY ADMINISTRATION REQUIREMENTS
The following forms and provisions are incorporated in and made a part of this contract.
a). Appendix I of the FDOT Standard Professional Services Agreement is included as
Attachment C.
b). The CONSULTANT and any sub -consultants shall not discriminate on the basis of race,
color, national origin or sex in the performance of this contract. The CONSULTANT shall carry
out applicable requirements of 49 C.F.R. Part 26 in the award and administration of DOT -
assisted contracts. Failure by the CONSULTANT to carry out these requirements is a material
breach of this contract, which may result in the termination of this contract or such other
remedy as the COUNTY deems appropriate.
c). CONSULTANT will comply, and ensure its sub -consultants will comply, with the
Certification Regarding Debarment, Suspension, Ineligibility and Voluntary Exclusion — Lower
Tier Covered Transactions in 49 C. F. R. Part 29, when applicable.
d). Equal Employment Opportunity: In connection with the carrying out of any project, the
CONSULTANT shall not discriminate against any employee or applicant for employment
because of race, age, religion, color, sex national origin, disability or marital status. The
CONSULTANT will take affirmative action to ensure that applicants are employed and that
employees are treated during employment without regard to their race, age, religion color,
gender, national origin, disability or marital status. Such action shall include, but not be limited
to, the following: employment upgrading, demotion or transfer; recruitment or recruitment
advertising; layoff or termination; rates of pay or other forms of compensation; and selection
for training, including apprenticeship.
e). The CONSULTANT and all sub -consultants agree to utilize the U.S Department of
_J
, rtme4W4 o6Wnha
hired by the CONSULTANT or sub -consultants during the term of the contract.
f). The CONSULTANT will complete and submit the FDOT Anticipated DBE Participation
Statement Form No. 275-030-1 1A to identify DBE participation as outlined in Paragraph 9.29,
Disadvantaged Business Enterprise (DBE) Policy and Obligations, of the Contract for
Professional Services. FDOT has a race neutral program with an 8.6% goal.
g). The CONSULTANT will adhere to all applicable requirements outlined in the Local Agency
Program (LAP) Agreement between FDOT and Monroe County for this project. A copy of the
Agreement is included as Attachment D.
h). The CONSULTANT will complete and submit the Certification of Disclosure of
Lobbying Activities on Federal Aid Contracts and the Certification Regarding Debarment,
Suspension, Ineligibility and Voluntary Exclusion for Federal Aid Contracts included as
Attachment E.
IN WITNESS WHEREOF, each party has caused this Agreement to be executed by its duly
authorized representative on the day and year first above written.
(SEAL)
Attest: AMY HEAVILIN, Clerk
By:
Deputy Clerk
Mn
insmen was acnowh;dgeld befo
ho is
icen tificatio
I
i1J1
191&11101,11
,409-
ne this jj d.y 0' _20,d, by
0
onally kn n t2 or produced a driver's
A -
NOTARY PUBLIC, STATE OF FLORIDA
Print, type of stamp commissioned name of
notary
MO ROE COUNY-1Y ATTORNEY
APPR(?VED AS TO FORM:
CHRISTINE M. LIMBERT-BARROWS
ASSISTANT G OUN T Y ATTORNEY
Date Lqc�pq
1.0 The Consultant shall provide Construction Engineering and Inspection Services
for the No Name Key Bridge Repair project.
The Consultant shall exercise their independent professional judgment in performing
their obligations and responsibilities under this Task Order. Pursuant to Section 4.1.4 of
the FDOT's Construction Project Administration Manual (CPAM), the authority of the
Consultant's lead person, such as the Senior Project Engineer, and the Consultant's
Project Administrator shall be identical to the Department's Resident Engineer and
Project Administrator respectively and shall be interpreted as such.
The Consultant shall utilize the U.S. Department of Homeland Security's E-Verify
system to verify the employment eligibility of all new employees hired by the Consultant
during the term of the Contract and shall expressly require any subconsultants
performing work or providing services pursuant to the Contract to likewise utilize the U.S.
Department of Homeland Security's E-Verify system to verify the employment eligibility
of all new employees hired by the subconsultant during the Contract term.
NP]IIIIIIIIIIII 4 40 1019: to] 96-11 =1
The Consultant services for the Construction Contract shall begin upon written
notification to proceed by County.
The Consultant Senior Project Engineer will track the execution of the Construction
Contract such that the Consultant is given timely authorization to begin work. While no
personnel shall be assigned until written notification by the County has been issued, the
Consultant shall be ready to assign personnel within two weeks of notification. For tht
duration of the project, the Consultant shall coordinate closely with the County and
Contractor to minimize rescheduling of Consultant activities due to construction delays
or changes in scheduling of Contractor activities.
For estimating purposes the Consultant will be allowed a maximum of thirty working
days to perform preliminary administrative services prior to the issuance of the
Contractor's notice to proceed and a maximum thirty calendar days to demobilize after
final acceptance of the Construction Contract.
I * k
A. Resident Engineer: The Engineer assigned to a particular Project or area to administer
Construction Contracts for the County.
i. Construction Prooect Manage : The County employee assigned to manage the
Construction Engineering and Inspection Contract and represent the County
during the performance of the services covered under this Agreement.
C. En-gineer of Record: The Engineer noted on the Construction plans as the
responsible person for the design and preparation of the plans.
III, Consultant: The Consulting firm under contract to the County for administration of
Construction Engineering and Inspection services.
E. Agreement: The Professional Services Agreement between the County and the
Consultant setting forth the obligations of the parties thereto, including but not
limited to the performance of the work, furnishing of services, and the basis of
payment.
F. Consultant Senior Promect Engineer: The Engineer assigned by the Consultant to
be in charge of providing Construction Contract administration for one or more
Construction Projects. This person may supervise other Consultant employees
and act as the lead Engineer for the Consultant.
G, Consultant Proiect Administrator: The employee assigned by the Consultant to
be in charge of providing Construction Contract administration services one or
more Construction Projects.
H. Contractor: The individual, firm, or company contracting with the County for
performance of work or furnishing of materials.
1. Construction Contract: The written agreement between the County and the
Contractor setting forth the obligations of the parties thereto, including but no)
limited to the performance of the work, furnishing of labor and materials, and tht
basis of payment.
J. CPAM: Florida Department of Transportation, Construction Projecl
Administration manual; latest.
gmy-3=
4.1 General:
the Construction Contract such that the project is constructed in reasonablIA
conformity with the plans, specifications, and special provisions for tft
Construction •
The Consultant shall observe the Contractor's work to determine the progress
and quality of work, identify discrepancies, report significant discrepancies to the
County, and direct the Contractor to correct such observed discrepancies.
The Consultant is hereby designated by the County to negotiate Supplement
Agreements. However, the Consultant must seek input from the Constructi
t
Project Manager. The Consultant shall prepare the Supplemental Agreement
a recommendation to the County, which the County may accept, modify or reje
upon review. The Consultant shall consult with the Construction Proje
Manager, as it deems necessary and shall direct all issues, which exceed
delegated authority to the Construction Project Manager for County action
direction.
The Consultant shall advise the Construction Project Manager of any significant
omissions, substitutions, defects, and deficiencies noted in the work of the
Contractor and the corrective action that has been directed to be performed by
the Contractor. Work provided by the Consultant shall not relieve the Contractor
of responsibility for the satisfactory performance of the Construction Contract.
The Consultant shall check • establish the survey control baseline(s) along witill
sufficient baseline control points and bench marks at appropriate intervals alo
the project in order to: (1) make and record such measurements as a
necessary to calculate and document quantities for pay items; (2) make a
record pre -construction and final cross section surveys of the project site in tho
areas where earthwork (i.e., embankment, excavation, subsoil excavation, et
is part of the construction project; and (3) perform incidental engineering survey
The Senior ter• Engineer will establish the specific survey requirements f
each project prior to construction.
Any questions or requests for "Waiver of Survey" should be directed to the Senior
Project Engineer.
The Consultant shall monitor the Contractor's on -site construction activities a
inspect materials entering into the • in accordance with the •
specifications, and special provisions for the Construction Contract to determi
that the projects are constructed in reasonable conformity with such document
The County will monitor all off -site activities and fabrication. The Consultant sh
keep detailed accurate records of the Contractor's daily operations and
signcant events that affect the • I
Consultant shall be responsible for monitoring and inspection of Contractor's
Work Zone traffic control plan and review of modifications to the Work Zone
Traffic Control Plan, including alternate Work Zone Traffic Control Plan, in
accordance with F.D.O.T. procedures. Consultant employees performing such
services shall be qualified in accordance with F.D.O.T. department procedure.
4.4 Sampling and Testing:
The Consultant shall perform sampling and testing of component materials and
completed work in accordance with the Construction Contract documents and
Local Agency Program requirements for Federal Aid Projects. The minimum
sampling frequencies set out in the Department's Materials Sampling, Testing
and Reporting Guide shall be met. In complying with the aforementioned guide,
the Consultant shall provide daily surveillance of the Contractor's Quality Control
activities at the project site and perform the sampling and testing of materials and
completed work items that are normally done in the vicinity of the project for
verification and acceptance.
The Consultant shall be specifically responsible for job control samples
determining the acceptability of all materials and completed work items on the
basis of either test results or verification of a certification, certified mill analysis,
DOT label, DOT stamp, etc.
Sampling, testing and laboratory methods shall be as required by the
Department's Standard Specifications, Supplemental Specifications or as
modified by the special provisions of the Construction Contract.
Documentation reports on sampling and testing shall be submitted to responsible
parties during the same week that the construction work is done.
If required, the Consultant will transport samples to be tested in a Department
laboratory to the appropriate laboratory or appropriate local FDOT facility.
The Consultant will review and approve contractor samples in FDOT's LIMS
system.
The Consultant will input verification testing information and data into the
Department's LIMS system database using written instructions provided by the
Department.
The Consultant shall coordinate the Construction Contract administration
activities of all parties other than the Contractor involved in completing the
construction project. Notwithstanding the above, the Consultant is not liable to
the County for failure of such parties to follow written direction issued by the
Consultant.
Services include maintaining the required level of surveillance of Contractor
activities, interpreting plans, specificati ' ons, and special provisions for the
Construction Contract, maintaining complete, accurate records of all activities
and events relating to the project, and properly documenting all significant project
changes. The Consultant shall perform the following services:
Schedule and attend, within ten days after the Notice to Proceed, a pre -
construction conference for the project in accordance with County and
FDOT LAP procedures. The Consultant shall provide appropriate staff to
attend and participate in the pre -construction meeting.
(2) The Consultant shall record a complete and concise record of the
proceedings of the pre -construction meeting and distribute copies of this
summary to the participants and other interested parties within seven
days.
(3) Analyze the Contractor's schedule(s) (i.e. baseline(s), revised baseline(s),
updates, as -built, etc.) for compliance with the contract documents.
Elements including, but not limited to, completeness, logic, durations,
activity, flow, milestone dates, concurrency, resource allotment, and
delays will be reviewed. Verify the schedule conforms with the
construction phasing and MOT sequences, including all contracl
modifications. Provide a written review of the schedule identifying
significant omissions, improbable or unreasonable activity durations,
errors in logic, and any other concerns as detailed in CPAM.
(4) Verify that the Contractor is conducting inspections, preparing reports and
monitoring all storm water pollution prevention measures associated with
the project.
(5) Analyze problems that arise on a project and proposals submitted by the
Contractor, endeavor to resolve such issues, and process the necessary
paperwork.
(6) Produce reports, verify quantity calculations, field measure for payment
purposes as needed to prevent delays in Contractor operations and
ensure prompt processing of such information in order for the County to
make timely payment to the Contractor. .
(7) Provide Public Information services as required to manage inquiries from
the public, public officials, and the news media. Prepare newsletters for
distribution to adjacent property owners. The County Construction Project
Manager shall approve all notices, brochures, responses to news media,
etc., prior to release.
(8) Prepare and submit to the Construction Project Manager monthly, a
Construction Status Reporting System (CSRS) report.
(9) Schedule and conduct a meeting with the County Engineering Office at
least 45 calendar days prior to project final acceptance. The purpose o-1
this meeting is to discuss the required documentation, including as-builts,
necessary to close out the permit(s).
(10) Video tape the pre -construction conditions throughout the project limits.
Provide a digital photo log or video of project activities, with heavy
emphasis on potential claim items/issues and on areas of real/potential
public controversy.
The Consultant shall have a digital camera for photographic
documentation of noteworthy incidents or events to cover the following
areas:
(a). Pre -construction photographs
(b). Normal and exceptional progress of work
(c). Critical path activities
(d). Accidents showing damage
(e). Unsafe working conditions
(f). Unusual construction techniques
(g). Damaged equipment or materials
(h). Any activity, which may result in claims
These photographs will be filed and maintained on the Consultant's
computer. Copies of photographs will be electronically transferred to the
• at an interval determined by the Senior • • and the
Construction Project Manager.
The taking of the photographs shall begin the day prior to the start of
construction and continue regularly throughout this project. Photographs
shall be taken the days of Conditional, Partial and/or Final Acceptance.
(12) Monitor each Contractor and Subcontractor's compliance with
specifications and special provisions of the Construction Contract in
regard to payment of predetermined wage rates in accordance with FDOT
LAP Department procedures.
(13) Provide a Resident Compliance Specialist for surveillance of the
Contractor's compliance with Construction Contract requirements. The
Resident Compliance Specialist is responsible for reviewing, monitoring,
evaluating and acting upon documentation required for Construction
Contract compliance, and maintaining the appropriate files thereof.
Typical areas of compliance responsibility include EEO Affirmative
Actions for the prime contractor and subcontractor, DBE Affirmative
Action, Contractor Formal Training, Payroll, and Subcontracts. The
•- Compliance • must keep all related documents and
correspondence accurate and up to date; attend all compliance reviews
and furnish the complete project files • review; and assist the District
Contract Compliance Manager as requested.
(14) As needed, prepare and make presentation before the Dispute Review
Boards in connection with the project covered by this Agreement
A. The County, on as needed basis, will furnish the following Construction Contract
documents for this project. These documents may be provided in either paper or
• •
1 Construction ♦ (drawings, specification
2 Special Provisions
3 Copy of the executed Construction Contract.
All applicable documents referenced herein shall be a condition of this
Agreement.
62 Vehicles:
Vehicles will be equipped with appropriate safety equipment and must be able
to effectively carry out requirements of this Agreement. Vehicles shall have the
name and phone number of the consulting firm visibly displayed on both sides
• the vehicle.
lm�g M-r. IT.Mr.=
W
0550117151 in 1.77712-ifurF, Inuer
includes those non -consumable and non -expendable items, which are normally
•-• • a CEI project and are essential in order to carry • the • under
this Agreement.
M M N M Mg rIMTOM -me
Equipment described herein and expendable materials under this Agreemeril
will remain the property ♦ the • and shall be removed at completion
• the •
The Consultant's handling of nuclear density gauges shall be in compliance
with their license.
The Consultant shall retain responsibility for risk of loss or damage to said
equipment during performance of this Agreement. Field office equipment shall
be maintained and in operational condition at all times.
i��1111
114
The Consultant will be responsible for obtaining proper licenses for equipment
and personnel operating equipment when licenses are required. The
Consultant shall make the license and supporting documents available to the
The Consultant shall keep the Construction Project Manager informed of all significant
activities, decisions, correspondence, reports, and other communications related to its
responsibilities under this Agreement, and seek input from the Construction Project
Manager in order for the Construction Project Manager to oversee the Consultant's
performance.
Agreement administrative duties relating to Invoice Approval Requests, Personnel
Approval Requests, User ID Requests, Time Extension Requests, and Amendment and
Supplemental Amendment Requests shall be reviewed and approved by th,Z
• Project Manager.
8.1 General Requirements:
Unless otherwise agreed by the County, the County will not compensate straight
overtime • premium overtime '• the positions of • Project •
Project Administrator, Contract Support Specialist, and Associate Contract
Support Specialist.
The Consultant shall utilize only competent personnel, qualified by experience,
and education. The Consultant shall submit in writing to the Construction Project
.•- the names • personnel proposed for assignment to the project,
including a detailed resume for each containing at a minimum salary, education,
and experience. The Consultant Action Request form for personnel approval
shall be submitted to the Construction Project Manager at least two weeks prior
to the date an individual is to report to work.
Personnel identified in the Consultant technical proposal are to be assigned as
proposed and are committed to performing services under this Agreement.
Personnel changes will require written approval from County. Previously
approved staff, whose performance is unsatisfactory, shall be replaced by the
Consultant within one week of County notification.
project staff is highly recommended to ensure a knowledgeable and versatile
project inspection team but shall not be at any additional cost to the County and
?,hould occur as workload permits. Visit the training page on the State
1`
Construction Office website • training dates.
Minimum qualifications for the Consultant personnel are set forth as follows.
Exceptions to these minimum qualifications will be considered on an individual
basis. The County Engineer or designee will have the final approval authority.
CEI SENIOR PROJECT ENGINEER - A Civil Engineer degree and be
registered in the State of Florida as a Professional Engineer (or if registered in
another state, the ability to obtain registration in the State of Florida within six
months) and six years of engineering experience (two years of which are in
major road and bridge construction), or for non-degreed personnel the
aforementioned registration and ten years of engineering experience (two years
of which are in major road or bridge construction). Qualifications include the
ability to communicate effectively in English (verbally and in writing); direct highly
program; plans and organizes the work of subordinate and staff members;
develops and/or reviews policies, methods, practices, and procedures; and
reviews programs for conformance with County standards. Also must have the
following:
•
FDOT Advanced MOT
Pass the CTQP examination covering the training video "Grouting of Bridge Post -
tensioning Tendons" (If applicable)
Attend the CTQP Quality Control Manager course and pass the examination.
Certifications: •
A Master's Degree in Engineering may be substituted for one (1) year
engineering experience.
CEI PROJECT ADMINISTRATOR -A Civil Engineering degree plus two (2) years
of engineering experience in construction of major road or bridge structures, or
eight (8) years of responsible and related engineering experience, two (2) years
of which involved construction of major road and bridge structures.
Receives general instructions regarding assignments and is expected to exercise
initiative and independent judgment in the solution of work problems. Directs and
assigns specific tasks to inspectors and assists in all phases of the construction
project. Will be responsible for the progress and final estimates throughout the
construction project duration. Must have the following:
Qualifications: FDOT Intermediate MOT Pass the CTQP examination covering
the training video "Grouting of Bridge Post -tensioning Tendons" (if applicable)
CTQP Final Estimates Level 11
Certifications: None
A Master's Degree in Engineering may be substituted for one (1) year of
engineering experience
CEI CONTRACT SUPPORT SPECIALIST - A Civil Engineering Degree or High
School diploma or equivalent and four years of road & bridge construction
engineering inspection (CEI) experience having performed/assisted in project
related duties (i.e., progress and final estimates, EEO compliance, processing
Construction Contract changes, etc.) or a Civil Engineering degree. Should
exercise independent judgment in planning work details and making technical
decisions related to the office aspects of the project. Should be familiar with the
County's Procedures covering the project related duties as stated above and be
proficient in the computer programs necessary to perform these duties. Shall
become trained in CTQP Final Estimates Level 11 course and maintain a current
quacation.
CEI SENIOR INSPECTOR/ CEI SENIOR ENGINEER INTERN — High school
graduate or equivalent plus four years of experience in construction inspection,
two years of which shall have been in bridge and/or roadway construction
inspection.
L=��=
Qualifications:
CTQP Concrete Field Inspector Level I
CTQP Concrete Transportation Construction Inspector (CTCI) Level 11 (all
bridges) CTQP Asphalt Roadway Level I (if applicable)
CTQP Asphalt Roadway Level 11 (if applicable)
CTQP Earthwork Construction Inspection Level I
CTQP Earthwork Construction Inspection Level 11
CTQP Pile Driving Inspection (if applicable) CTQP Drilled Shaft Inspection (if
applicable)
CTQP Grouting Technician Level I (if applicable)
CTQP Post -Tensioning Technician Level I (If applicable)
FDOT Intermediate MOT
CTQP Final Estimates Level I
Certifications:
4 Woe-41610TVkz•W I L
Or a Civil Engineering degree and one year of road & bridge CEI experience wi
the ability to earn additional required qualifications within one year. (Note: Senii
Engineer Intern classification requires one year experience as an Engine
Intern.) I
Responsible for performing highly complex technical assignments in field
gurveying and construction layout, making, and checking engineering
computations, inspecting construction work, and conducting field tests and is
responsible for coordinating and managing the lower level inspectors. Work is
performed under the general supervision of the Project Administrator.
8.3 Staffing:
Once authorized, the Consultant shall establish and maintain an appropriate staff
through the duration of construction and completion of the final estimate.
Responsible personnel, thoroughly familiar with all aspects of construction and
final measurements of the various pay items, shall be available to resolve
disputed final pay quantities until the appropriate Construction Contract has been
paid off.
Construction engineering and inspection forces will be required of the Consultant
at all times while the Contractor is working. If Contractor operations are
substantially reduced or suspended, the Consultant will reduce its staff
appropriately.
In the event that the suspension of Contractor operations requires the removal of
Consultant forces from the project, the Consultant will be allowed ten (10) days
maximum to demobilize, relocate, or terminate such forces.
. 1 -0 Z
The Consultant shall conduct semi-annual reviews to make certain his own
organization is in compliance with the requirements cited in the Scope of
Services. Quality Reviews shall be conducted to evaluate the adequacy of
materials, processes, documentation, procedures, training, guidance, and
staffing included in the execution of this Agreement. Quality Reviews shall also
be developed and performed to achieve compliance with specific QA provisions
contained in this Agreement. The semi-annual reviews shall be submitted to the
Construction Project Manager in written form no later than one month after th,�
review.
11 W 0 — is -
T110 KOTTY 1-71FAV-1114MIEST412M 0 ffil
9900W=
Within thirty days after receiving award of an Agreement, the Consultant shall
furnish a QA Plan to the Construction Project Manager. The QA Plan shall detail
the procedures, evaluation criteria, and instructions of the Consultant's
organization to assure conformance with the Agreement. Unless specifically
waived, no payment shall be made until the County approves the Consultant Q.
Pl_n.
gignificant changes to the work requirements may require the Consultant tp-,
-evise the QA Plan. It shall be the responsibility of the Consultant to keep the
Alan current with the work requirements. The Plan shall include, but not be
limited to, the following areas:
of personnel in the quality control organization.
The Consultant QA shall detail the methods used to monitor and achie,
organization compliance with Agreement requirements for services a
products. I
The Consultant will outline the types of records, which will be generat
and maintained during the execution of his QA program. i
MI, me I on &M
The Consultant will detail the methods used to control sub -consultants
• vendor quality.
TMICTIM
An officer of the Consultant firm shall certify that the ins�ection a
documentation was done in accordance with FDOT specifications, plan
standard indexes, and County procedures. I
The • shall maintain adequate records • the • assurance actio
performed by his organization (including subcontractors and vendors) i
providing services and products under this Agreement. All records shall indica
the nature and number of observations made, the number and type
deficiencies found, and the corrective • taken. These records shall
available to the County, upon request, during the Agreement term. All recor
shall be kept at the primary job site and shall be subject to audit review. •
Prepare documentation and records in compliance with the Agreement,
Consultant's approved QC Plan and the County's Procedures.
Submit the Final Estimate(s) and three sets of final as built plans documenting
Contractor's work (one record set with two copies) as follows:
(a) Within thirty calendar days of final acceptance; or
b• Where all items of • are complete and conditional/=*
A memorandum with documentation will be transmitted to the
Director of Engineering Services at final acceptance detailing any
necessary revisions to the pay items covered under tht
conditional/partial acceptance.
The Consultant shall be responsible for making any revisions to the Certified
Final Estimate.
922099MM•�-
Consultant personnel preparing the Certified Final Estimate Package shall bt
CTQP Final Estimates Level 11 qualified.
Duly authorized representative of the Consultant firm will provide a notarized
certification on a form pursuant to Department procedures.
91111111111111;ill :14fol 0 &ill 91 r-11
1170710-WOWUM approval o., 61- -511-1-IMIUMP-TTLrMITianager anU7fM7U=T, ana prior Yo
performance of work, the Consultant may subcontract for engineering surveys, materials
testing, or specialized professional services.
Upon written authorization by the Director of Engineering Services or designee, the
Consultant will perform additional services in connection with the project not otherwise
identified in this Agreement. The following items are not included as part of this
Agreement, but may be required by the County to supplement the Consultant services
under this Agreement.
X Assist in preparing for arbitration hearings or litigation that occurs during the
Agreement time in connection with the construction project covered by this
Agreement.
B. Provide qualified engineering witnesses and exhibits for any litigation or hearings
in connection with the Agreement.
C. Provide on- and off -site inspection services in addition to those provided for in
this Agreement.
li bRIJEW413KPOI 0 6"19 N I M I Lei 0 IM lu 16 6IJ a4nrwa
the Consultant has completed this Agreement, the Consultant shall, at the written
request from the County, analyze the claim, engage in negotiations leading to settlement
of the claim, and prepare and process the required documentation to close out the claim.
Compensation for such services will be negotiated and effected through a Supplement to
this Agreement.
In the event • a contradiction between the provisions • this Scope of Services and the
Consultant's proposal as made a part of their Agreement, the provisions of the Scope of
Services shall apply.
The • shall • the final authority in considering • modification • the
Contractor for time, money • any other consideration except matters agreed to • the
Contractor through contract changes negotiated by the Consultant.
i �
1 i. a , � �
U') Cf) C)
It m C)
00
V)
co CY)
M T
PI-
U')
I
04 m N - OO C) 0 w CD C)
r-- CN a M T 'T a - (0 M 0
0
Im
0
m
o I-- "r
00 (D 00
cV
V)
CN
M 0
I--
M
m m I--
M 0 1'- N 0 P.- M T d N r-
cNi
Q
C14 C)
M M
I,-
LO M LO M - C) I,- M (3) P.- 0)
1,-
r- 00r
00
(D
(0 CY)
(0
"t 04 "t r 0) OD V-
LO M NLO
Cl)
w
0)
A=
C14 V) V) m
Cl)
a
-0 4 -00-
C)
C\j (N 0 Cf)
CY) r-
O
6
CN ci -
(14 CD
N� CR I?
LO w
Im (D
(D
(D co
CL
6p� 69,609
0
x
w 4)
CD C) C) C) C) C)
0
V)
U)
4'
U)
> 0
0o
04
0 (14
0
0 -
0
m
0
0 CL t0 U_
(D
00 IIR
z m E '0-
4a
W
C) �—
'm (o q-
w c') N
U) CL
C\j
E
ro
"
Im
UY ell 61->
cn
U-
La
C> CD CD
n CD CD
0 >
0
06
-0 M Q. CL
x
IL
U)
,q.
0
cc x x E
0 0 0 w w w 0
0 o
C'4
cf) 04
m
F- - 1.-
1 0 0
La-) m w rn ro
0
w
=)
> =) CL =) =)
0 0 oo CL as
U)
c!)
U)
(n
0) U) U- U)
cl
�2
w
�c
LU
U)
z
z
2)
0
Z
0
U-
IL
w
0
LL:
U-
U)
<
<
U-
CO
0
w
-j
W
a.
1 0)
LL
(D
w
z
W
0
z
w
U)
0
w
z
z
z
(D 0
LLI :3
w a
Z �- Cr
U)
0
W Oo
W
W
UU)CL C)
ro
>
Z
LLJ
LLI Z w
1) IL
0
0
ui
U)
w
w
o z
cc I% z
CL
0
<
CL
0
0- 2
1
IU) C) C)
11
m
I
1�-
iw
W,
MI
PARSONS BRINCKERHOFF, INC.
PROJECT: CEI SERVICES FOR NO NAME KEY BRIDGE
i MONROE COUNTY, FIL
Description
METT"Mr. M
1.1m, Ifir:ia:
Months are from Staffing Chart
Total Estimated Temporary Livin �Cos
PARSONS BRINCKERHOFF, INC.
PROJECT: CEI SERVICES FOR NO NAME KEY BRIDGE
MONROE COUNTY, FL
ITEM QUANTITY UNIT SUBTOTAL Tax FINAL
I COST 7% COST I
PROJECT SUPPORT
Monthly Equipment Land Record Storage 2, 00 MTt ? 5 1,19 00 $ 1.768.W s 125 IS 5 1,9i3 16
FOTAt PROJECT SUPPORT EXPENSES s 1,913A6
TOTAt CONSIUMASLES $ -
[EXPENSES PBA thl s s?i ect s 1,913.16
mm�
ul
n
v
0
uj
LL
Lu
z
0
CL
U)
z
D
LU
(a
y
LLI
z
0
z
Z
LI: 0
LL LL
0 .0
tu
cl
w > ul 0
0
z
z
z
0
z U)
E
0 LLJ
> r.
Z Lu
CJ 0
o w
z
U)i
0
w 0
a. a.
ATTACHMENT C
APPENDIX I OF FDOT STANDARD PROFESSIONAL SERVICES AGREEMENT
i5111111111151101 �, 'Illiil
F
The following terms apply to all contracts in which it is indicated in Section 6.13 of the Standard
Professional Services Agreement that the services involve the expenditure of federal funds:
A It is understood and agreed that all rights of the Department relating to inspection,
review, approval, patents, copyrights, and audit of the work, tracing, plans,
specifications, maps, data, and cost records relating to this Agreement shall also be
reserved and held by authorized representatives of the United States of America.
13It is understood and agreed that, in order to permit federal participation, no supplemental
agreement of any nature may be entered into by the parties hereto with regard to the
work to be performed hereunder without the approval of the U.S. Department of
Transportation, anything to the contrary in this Agreement not withstanding.
C. Compliance with Regulations- The Consultant shall comply with the Regulations of the
U.S. Department of Transportation Title 49, Code of Federal Regulations, Part 21, as
they may be amended from time to time, (hereinafter referred to as the Regulations),
which are herein incorporated by reference and made a part of this Agreement.
D. Nondiscrimination- The Consultant, with regard to the work performed during the
contract, shall not discriminate on the basis of race, color, national origin, sex, age,
disability, religion or family status in the selection and retention of subcontractors,
including procurements of material and leases of equipment. The Consultant will not
participate either directly or indirectly in the discrimination prohibited by Section 21.5 of
the Regulations, including employment practices when the contract covers a program
set forth in Appendix B of the Regulations.
E. Solicitations for Subcontracts, Including Procurements of Materials and Equipment- In all
solicitations made by the Consultant, either by competitive bidding or negotiation for
work to be performed under a subcontract, including procurements of materials and
leases of equipment, each potential subcontractor or supplier shall be notified by the
Consultant of the Consultant's obligations under this contract and the Regulations
relative to nondiscrimination on the basis of race, color, national origin, sex, age,
disability, religion or family status.
F, Information and Reports: The Consultant will provide all information and reports required
by the Regulations, or directives issued pursuant thereto, and will permit access to its
books, records, accounts, other sources of information, and its facilities as may be
determined by the Florida Department of Transportation, Federal Highway
Administration, Federal Transit Administration, Federal Aviation Administration, and/or
Federal Motor Carrier Safety Administration to be pertinent to ascertain compliance with
such Regulations, orders and instructions. Where any information required of the
Consultant is in the exclusive possession of another who fails or refuses to furnish this
information, the Consultant shall so certify to the Florida Department of Transportation,
Federal Highway Administration, Federal Transit Administration, Federal Aviation
Administration, and/or the Federal Motor Carrier Safety Administration as appropriate,
and shall set forth what efforts it has made to obtain the information.
I Orqj Loin 0 0 so •Iml 16-Maiel
shall impose such contract sanctions as it or the Federal Highway Administration,
Federal Transit Administration, Federal Aviation Administration, and/or Federal Motor
Carrier Safety Administration may determine to be appropriate, including, but not limited
to,
1 Withholding of payments to the Consultant under the contract until the Consultanl
complies and/or
2. Cancellation, termination or suspension of the contract, in whole or in part.
H. Incorporation or Provisions- The Consultant will include the provisions of Paragraph C
through H in every subcontract, including procurements of materials and leases of
equipment unless exempt by the Regulations, order, or instructions issued pursuant
thereto. The Consultant will take such action with respect to any subcontract or
procurement as the Florida Department of Transportation, Federal Highway
Administration, Federal Transit Administration, Federal Aviation Administration, and/or
the Federal Motor Carrier Safety Administration may direct as a means of enforcing such
provisions, including sanctions for noncompliance. In the event a Consultant becomes
involved in, or is threatened with, litigation with a subcontractor or supplier as a result of
such direction, the Consultant may request the Florida Department of Transportation to
enter into such litigation to protect the interests of the Florida Department of
Transportation, and, in addition, the Consultant may request the United States to enter
into such litigation to protect the interests of the United States.
Interest of Members of Congress: No member of or delegate to the Congress of the
United States will be admitted to any share or part of this contract or to any benefit
arising therefrom.
J. Interest of Public Officials- No member, officer, or employee of the public body or of a
local public body during his tenure or for one year thereafter shall have any interest,
direct or indirect, in this contract or the proceeds thereof. For purposes of this provision,
public body shall include municipalities and other political subdivisions of States-, and
public corporations, boards, and commissions established under the laws of any State.
K. Participation by Disadvantaged Business Enterprises: The Consultant shall agree to
abide by the following statement from 49 CFR 26.13(b). This statements shall be
included in all subsequent agreements between the Consultant and any subconsultant
or contractor.
It is mutually understood and agreed that the willful falsification, distortion or
misrepresentation with respect to any facts related to the project(s) described in this
Agreement is a violation of the Federal Law. Accordingly, United States Code, Title 18,
Section 1020, is hereby incorporated by reference and made a part of this Agreement.
M. It is understood and agreed that if the Consultant at any time learns that the certification
it provided the Department in compliance with 49 CFR, Section 26.51, was erroneous
when submitted or has become erroneous by reason of changed circumstances, the
• shall provide immediate written notice to the Department. It is further agreed
that the clause titled "Certification Regarding Debarment, Suspension, Ineligibility and
Voluntary Exclusion - Lower Tier Covered Transaction" as set forth in 49 CFR, Section
29.510, shall be included by the Consultant in all lower tier covered transactions and in
all aforementioned federal regulation.
N. The Department hereby certifies that neither the consultant nor the consultant's
representative has been required by the Department, directly or indirectly as an express
or implied condition in connection with obtaining • carrying out this contract, to
1 . Employ or retain, or agree to employ or retain, any firm or person, or
2. Pay, or agree to pay, to any firm, person, or organization, any fee, contribution,
donation, • consideration • any kind;
O. The Consultant hereby certifies that it has not:
1 Employed • retained • a commission, percentage, brokerage, contingent fee,
or other consideration, any firm or person (other than a bona fide employee
working solely for the above Consultant) to solicit or secure this contract;
2. Agreed, as an express or implied condition for obtaining this contract, to employ
or retain the services of any firm or person in connection with carrying out this
•: •o'.
1 Paid, or agreed to pay, to any firm, organization or person (other than a bona fide
employee working solely for the above Consultant) any fee contribution,
donation, or consideration of any kind for, or in connection with, procuring or
carrying • the contract.
I ne cons uffa—n-t-Yuff ffe--raCKnowiea ge nis agreement WA i
Department of Transportation and a federal agency in connection with this contract involving
participation of Federal -Aid funds, and is subject to applicable State and Federal Laws, both
criminal • civil.
STATE OF FLORIDA DEPARTMENT OF TRANSPORTATION 525-W a
LOCAL AGENCY PROGRAM AGREEMENT PRODUCTION
♦. 1:
Pag
• , 1
If all funds are removed from the project, Including amounts previously billed to the Department and reimbursed to the
Agency, and the project is off the state highway system, then the department will have to request repayment for the
previously billed amounts from the Local Agency. No state funds can he used on off -system projects,
2.02 Expiration of Agreement: They Agency agrees to complete the project on or before rune 30, 2015. if the Agency
does not complete the project within this time period, this Agreement will expire on the last day of the scheduled
completion as provided in this paragraph unless an extension of the time period is requested by the Agency and granted
in writing by the Department prior to the expiration of this Agreement Expiration of this Agreement will be considered
termination of the project. The cost of any work performed after the expiration date of this Agreement will not be
reimbursed by the Department.
2.03 Pursuant to Federal, State, and Local Laws: In the event that any election, referendum, approval, permit, notice
or other proceeding or authorization Is requisite under applicable law to enable the Agency to enter into this Agreement or
to undertake the project hereunder or to observe, assume or carry out any of the provisions of the Agreement, the Agency
will Initiate and consummate:, as provided by law, all actions necessary with respect to any such matters so requisite.
2.04 Agency Funds: The Agency shall initiate and prosecute to completion all proceedings necessary, Including
federal -aid requirements, to enable the Agency to provide the necessary funds for completion of the project.
2,05 Submission of Proceedings, Contracts, and Other Documents: The Agency shall submit to the Department
such data, reports, records, contracts, and other documents relating to the project as the Department and the Federal
Highway AdmInisiration (FHWA) may require. The Agency shall use the Department's Local Agency Program Information
Tool and applicable Information systems as required.
3.00 Project Cost: 5, RYA
3.01 Total Cost: The total cost of the project is $-6rM.15.60 This amount is based upon the schedule of funding in
Exhibit "B." The Agency agrees to bear all expenses in excess of the total cost of the project and any deficits involved.
The schedule of funding may be modified by mutual agreement as provided for in paragraph 4,00.
3.02 Department Participation: The Department agrees to participate in the project cost to the extent provided in Exhibit
amount includes federal -aid funds which are limited
a) Legislative approval of the Departmenfis appropriation request in the work program year that the project is
scheduled to be • "_Ii.
b) Availability of funds as stated in paragraphs 3.04 and 3.05 of this Agreement;
c) Approval of all plans, specifications, contracts or other obligating documents and all other terms of this
A ♦ and
d) Department approval of the project scope and budget at the time appropriation authority becomes available,
3.04 Appropriation of Funds: The Department's performance and obligation to pay under this Agreement is contingent
upon an annual appropriation by the Legislature, If the Department's funding for this project is In multiple fiscal years,
funds approval from the Department's Comptroller must be received each fiscal year prior to costs being incurred, See
Exhibit "B" for funding levels by fiscal year. Project costs utilizing these fiscal year funds are not eiigible for
reimbursement if incurred prior to funds approval being received. The Department will notify the Agency, In wrlting, when
funds are available.
• \ �� _ • • .
+ . • : ♦ ♦ • : ! ■ • f . - - ; •. ; • \ ♦ : is
srAFF01 TON �2_010 410
PRODUCI 10111 SUN 0I
LOCAL AGENCY PROGRAM AGREEMENT OGG— i (W11 2
I
The administration of resources awarded by the Department to the Agency may be subject to audits and/or monitoring by
the Department, as described in this section.
Monitoring: In addition to reviews of audits conducted in accordance with OMB Circular A-133 and Section 215.97,
Florida Statutes, as revised (see "Audits" below), monitoring procedures may include, but not be limited to, on -site visits
by Department staff, limited scope audits as defined by OMB Circular A-133, as revised, and/or other procedures. By
entering into this Agreement, the recipient agrees to comply and cooperate fully with any monitoring
procedures/processes deemed appropriate by the Department. In the event the Department determines that a limited
scope audit of the recipient is appropriate, the recipient agrees to comply with any additional instructions provided by the
Department staff to the Agency regarding such audit. The Agency further agrees to comply and cooperate with any
inspections, reviews, investigations or audits deemed necessary by the Department's Office of Inspector General (OIG),
and the Chief Financial Officer (CFO) or Auditor General.
Audits
Part I - Federally Funded: Recipients of federal funds (i.e., state, local government or non-profit organizations as
defined in OMB Circular A-133, as revised) are to have audits done annually using the following criteria:
In the event that the recipient expends $500,000 or more in federal awards in its fiscal year, the recipient must
have a single or program -specific audit conducted in accordance with the provisions of OMB Circular A-133, as
revised. Exhibit "T' of this Agreement indicates federal resources awarded through the Department by this
Agreement. In determining the federal awards expended in its fiscal year, the recipient shall consider all sources
of federal awards, including federal resources received from the Department. The determination of amounts of
federal awards expended should be in accordance with the guidelines established by OMB Circular A-133, as
revised. An audit of the recipient conducted by the Auditor General in accordance with the provisions OMB
Circular A-1 33, as revised, will meet the requirements of this part
91-10191101111-16 1 &IN IMM I Mr-AWK11[m I I I tell if gle El I W,610 I Olen I A ILWAS I ELVA Il I -ELVIINMEW-1,11ii 0
3. If the recipient expends less than $500,000 in federal awards in its fiscal year, an audit conducted in accordance
with the provisions of OMB Circular A-133, as revised, is not required. However, if the recipient elects to have an
audit conducted in accordance with the provisions of OMB Circular A-133, as revised, the cost of the audit must
be paid from non-federal resources (Le., the cost of such an audit must be paid from recipient resources obtained
from other than federal entities).
4. Federal awards arL-ta-b-e-ld-entffled-uslfTg-t"-C-a alog ol
award number and year, and name of the awarding federal agency,
Part 11 - State Funded: Recipients of state funds (i.e., a non -state entity as defined by Section 215.97(2) (1), Flori
Statutes) are to have audits done annually using the following criteria: I
In the event that the recipient expends a total amount of state financial assistance equal to or in excess of
$500,000 in any fiscal year of such recipient, the recipient must have a state single or project -specific audit for
such fiscal year in accordance with Section 215.97, Florida Statutes, applicable rules of the Executive Office of
the Governor and the CFO, and Chapters 10.550 (local governmental entities) or 10.650 (nonprofit and for -profit
organizations), Rules of the Auditor General. Exhibit "'I" to this Agreement indicates state financial assistance
awarded through the Department by this Agreement. In determining the state financial assistance expended in its
fiscal year, the recipient shall consider all sources of state financial assistance, including state financial assistance
received from the Department, other state agencies, and other non -state entities. State financial assistance does
not include federal direct or pass -through awards and resources received by a non -state entity for federal
program matching requirements.
connection with the audit requirements addressed in Part 11, paragraph 1, the recipient shall ensure that th-,
audit complies with the requirements of Section 215.97(7), Florida Statutes. This includes submission of 9
financial reporting package as defined by Section 215,97(2) (d), Florida Statutes, and Chapters 10.550 (local
governmental entities) or 10.650 (nonprofit and for -profit organizations), Rules of the Auditor General.
STATE OF FLORIDA DEPARTMENT OF TRANSPORTATION 525-010-40
LOCAL AGENCY PPRODUCTION SUPPORTROGRAM AGREEMENT OGC— 1/14
Page 5
3. If the recipient expends less than $500,000 in state financial assistance in its fiscal year, an audit conducted in
accordance with the provisions of Section 215.97, Florida Statutes, is not required. However, if the recipient
elects to have audit conducted in accordance with the provisions of Section 215.97, Florida Statutes, the cost of
the audit must be paid from the non -state entity's resources (i.e., the cost of such an audit must be paid from the
recipient's resources obtained from other than State entities).
4. State awards are to be identified using the Catalog of State Financial Assistance (CSFA) title and number, award
number and year, and name of the state agency awarding it.
Part III - Other Audit Requirements: The recipient shall follow up and take corrective action on audit findings.
Preparation of a Summary Schedule of Prior Year Audit Findings, including corrective action and current status of the
audit findings is required. Current year audit findings require corrective action and status of findings.
Records related to unresolved audit findings, appeals or litigation shall be retained until the action is completed or the
*ispute is resolved. Access to Project records and audit work papers shall be given to the Department, the Department of
Financial 8ervices, and the Auditor General. This section does not limit the authority of the Department to conduct or
,?.rrange for the conduct of additional audits or evaluations of state financial assistance or limit the authority of any other
state official.
:Fr111kVA2z1V =I. I&IIII147""IT-7 =.
Copies of financial reporting packages for audits conducted in accordance with OMB Circular A-1 33, as revised,
and required by Part I of this Agreement shall be submitted, when required by Section .320 (d), OMB Circular A�
133, as revised, by or on behalf of the recipient directly to each of the following:
Florida Department of Transportation
Office of Comptroller, MS 24
605 Suwannee Street
Tallahassee, Florida 32399-0405
b) The Federal Audit Clearinghouse designated in CIMB Circular A-133, as revised (the number of copies
required by Sections .320 (d)(1) and (2), OMB Circular A-1 33, as revised), at the following address:
Bureau of the Census
1201 East 1 oth Street
Jeffersonville, IN 47132
c) Other federal agencies and pass -through entities in accordance with Sections .320 (e) and (f), OMB Circular
A-1 33, as revised.
2. In the event that a copy of the financial reporting package required by Part I of this Agreement and conducted in
accordance with OMB Circular A-133, as revised, is not required to be submitted to the Department for reasons
pursuant to Section .320 (e)(2), OMB Circular A-133, as revised, the recipient shall submit the required written
notification pursuant to Section .320 (e)(2) and a copy of the recipient's audited Schedule of Expenditures of
Federal Awards directl to each of the following:
Florida Department of Transportation
Office of Comptroller, MS 24
1 ,ZO5 Suwannee Street
Tallahassee, Florida 32399-0405
STATE OF FLORIDA DEPARTMENT OF TRANSPORTATION PRODUCTION 525-0101
LOCAL AGENCY PROGRAM AGREEMENT
Florida Department of Transportation
Office of Comptroller, MS 24
605 Suwannee Street
Tallahassee, Florida 32399-0405
Fiaia.265J k I z 1 4
3. Copies of the financial reporting package required by Part 11 of this Agreement shall be submitted by or on behalf
of the recipient directl to each of the following:
Florida Department of Transportation
Office of Comptroller, MS 24
605 Suwannee Street
Tallahassee, Florida 32399-0405
.IF4 I aliQ's Azsjd �J-Z& 4 #
Auditor General's Office
Room 401, Pepper Building
111 West Madison Street
Tallahassee, Florida 32399-14]1
4. Copies of reports or the Management Letter required by Part III of this Agreement shall be submitted by or on
behalf of the recipient directl to:
a) The Department at each of the following address(es):
Florida Department of Transportation
Office of Comptroller, MS 24
605 Suwannee Street
Tallahassee, Florida 32399-0405
Email: FDOTSingleAud it@dot state JI us
5. Any reports, Management Letters, or other information required to be submitted to the Department pursuant to
this Agreement shall be submitted in a timely manner in accordance with OMB Circular A-133, as revised, Florida
Statutes, and Chapters 10.550 (local governmental entities) or 10.650 (nonprofit and for -profit organizations),
Rules of the Auditor General, as applicable.
Recipients, when submitting financial reporting packages to the Department for audits done in accordance with
OMB Circular A-133, as revised, or Chapters 10.550 (local governmental entities) or 10.650 (nonprofit and for -
profit organizations), Rules of the Auditor General, should indicate the date that the financial reporting package
was delivered to the recipient in correspondence accompanying the financial reporting package.
wmiW I - I - 11 MR Is — A I
MIS KgreeFT11fd[It lUr-d-perKYO-OT-clUTeaSr-u-j,earts Min me Me ine RIM repurils�Ttuldm snan anoll ine leparlinern ur 1
designee, the state CFO or Auditor General access to such records upon request. The recipient shall ensure that t
independent audit documentation is made available to the Department, or its designee, the state CFO or Auditor Gener upon request for a period of at least 5 years from the date the audit report is issued, unless extended in writing by t
Department.
STATE OF FLORIDA DEPARTMENT OF: TRANSPORTATION 525-010-40
DUCTi ROON SUPPORT
LOCAL AGENCY PROGRAM AGREEMENT POGC— 10/12
Page 7
SI'AJ E ()7 F I DRIDA DUIARTMENI 0- I RANSPORTA90N 525-010-W
PRODUC, I KON SLIFIFICIP I
LOCAL AGENCY PROGRAM AGREEMENT 0 G-C, - 10 f 12
Page 8
8.02 Action Subsequent to Notice -of -Termination or Suspension: Upon receipt of any final termination or suspension
notice under this paragraph, the Agency shall proceed promptly to carry out the actions required therein which may
include any or all of the following: (a) necessary action to terminate or suspend, as the case may be, project activities and
contracts and such other action as may be required or desirable to keep to a minimum the costs upon the basis of which
the financing is to be computed; (b) furnish a statement of the project activities and contracts and other undertakings the
cost of which are otherwise includable as project costs. The termination or suspension shall be carried out in conformity
with the latest schedule, plan, and cost as approved by the Department or upon the basis of terms and conditions
imposed by the Department upon the failure of the Agency to furnish the schedule, plan, and estimate within a reasonable
time. The closing out of federal financial participation in the project shall not constitute a waiver of any claim which the
Department may otherwise have arising out of this Agreement.
9.00 Contracts of Agency:
9.01 Third Party Agreements: Except as otherwise authorized in writing by the Department, the Agency shall not
or construction contracts or amendments thereto, with any third party with respect to the project without the written
approval of the Department. Failure to obtain such approval shall be sufficient cause for nonpayment by the Department.
The Department specifically reserves unto itself the right to review the qualifications of any consultant or contractor and to
approve or disapprove the employment of the same.
9.02 Compliance with Consultants' Competitive Negotiation Act: It is understood and agreed by the parties hereto
that participation by the Department in a project with the Agency, where said project involves a consultant contract for
engineering, architecture or surveying services, is contingent on the Agency's complying in full with provisions of Section
287.055, Florida Statutes, Consultants' Competitive Negotiation Act. At the discretion of the Department, the Agency will
involve the Department in the consultant selection process for all projects. In all cases, the Agency's attorney shall certify
to the Department that selection has been accomplished in compliance with the Consultants' Competitive Negotiation Act.
STATE OF FLORIDA DEPARTMENT OF TRANSPORTATION 525-010-40
PRODUCTION SUPPORT
LOCAL AGENCY PROGRAM AGREEMENT OGC_ 10/12
Page 9
10.00 Disadvantaged Business Enterprise (DBE) Policy and Obligation: It is the policy of the Department that DBE's,
as defined in 49 C.F.R. Part 26, as amended, shall have the opportunity to participate in the performance of contracts
financed in whole or in part with Department funds under this Agreement. The DBE requirements of applicable federa'
and state laws and regulations apply to this Agreement.
The Agency and its contractors agree to ensure that DBE's have the opportunity to participate in the performance of this
Agreement. In this regard, all recipients and contractors shall take all necessary and reasonable steps in accordance with
applicable federal and state laws and regulations to ensure that the DBE's have the opportunity to compete for and
perform contracts. The Agency and its contractors and subcontractors shall not discriminate on the basis of race, color,
national origin or sex in the award and performance of contracts, entered pursuant to this Agreement. Furthermore, the
Agency agrees that:
(a) Each financial assistance agreement signed with a US -DOT operating administration (or a primary recipient) must
include the following assurance:
"The recipient shall not discriminate on the basis of race, color, national origin, or sex in the award and
performance of any DOT -assisted contract or in the administration of its DBE program or the requirements of
49 C.F.R, Part 26. The recipient shall take all necessary and reasonable steps under 49 C.F.R. Part 26 to
ensure nondiscrimination in the award and administration of DOT -assisted contracts. The recipient's DBE
program, as required by 49 C.F.R. Part 26 and as approved by Department, is incorporated by reference in
this Agreement. Implementation of this program is a legal obligation and failure to carry out its terms shall be
treated as a violation of this Agreement. Upon notification to the recipient of its failure to carry out its
approved program, the Department may impose sanctions as provided for under 49 C.F.R. Part 26 and may,
in appropriate cases, refer the matter for enforcement under 18 U.S.C. 1001 and/or the Program Fraud Civil
Remedies Act of 1986 (31 U.S.C. 3801 et seq.)."
(b) Each contract signed with a contractor (and each subcontract the prime contractor signs with a subcontractor) mu
include the following assurance: I
"The contractor, subrecipient or subcontractor shall not discriminate on the basis of race, color, national origin,
or sex in the performance of this contract. The contractor shall carry out applicable requirements of 49 C.F.R.
Part 26 in the award and administration of DOT -assisted contracts. Failure by the contractor to carry out these
requirements is a material breach of this contract, which may result in the termination of this contract or such
other remedy as the recipient deems appropriate."
11.00 Compliance with Conditions and Laws: The Agency shall comply and require its contractors and subcontractors
to comply with all terms and conditions of this Agreement and all federal, state, and local laws and regulations applicable
to this project. Execution of this Agreement constitutes a certification that the Agency is in compliance with, and will
require its contractors and subcontractors to comply with, all requirements imposed by applicable federal, state, and local
laws and regulations, including the "Certification Regarding Debarment, Suspension, Ineligibility and Voluntary Exclusion
— Lower Tier Covered Transactions," in 49 C.F.R. Part 29, when applicable.
12.01 Equal Employment Opportunity: In connection with the carrying out of any project, the Agency shall not
discriminate against any employee or applicant for employment because of race, age, religion, color, sex, national origin,
disability or marital status. The Agency will take affirmative action to ensure that applicants are employed and that
employees are treated during employment without regard to their race, age, religion, color, gender, national origin,
disability or marital status. Such action shall include, but not be limited to, the following: employment upgrading, demotion
or transfer; recruitment or recruitment advertising; layoff or termination; rates of pay or other forms of compensation; and
selection for training, including apprenticeship. The Agency shall insert the foregoing provision modified only to show the
particular contractual relationship in all its contracts in connection with the development of operation of the project, except
contracts for the standard commercial supplies or raw materials, and shall require all such contractors to insert a similar
provision in all subcontracts, except subcontracts for standard commercial supplies or raw materials. When the project
involves installation, construction, demolition, removal, site improvement or similar work, the Agency shall post, in
conspicuous places available to employees and applicants for employment for project work, notices to be provided by the
Department setting forth the provisions of the nondiscrimination clause.
STATE OF FLORIC DA M ARTMENT OF TRANSPORTATION 521 5 - 0110 - 4 0
LOCAL AGENCY PROGRAM AGREEMENT PRODUCTION SUPPORr
f
OGC-- 12
Pace 10
12.02 Title VI — Civil Rights Act of 1964: The Agency will comply with all the requirements imposed by Title V1 of tl
Civil Rights Act of 1964, the regulations of the U.S. Department of Transportation issued thereunder, and the assuranc
by the Agency pursuant thereto.
The Agency shall include provisions in all contracts with third parties that ensure compliance with Title VI of the Ci\
Rights Act of 1964, 49 C.F.R. Part 21, and related statutes and regulations.
12.03 Americans with Disabilities Act of 1990 (ADA): The Agency will comply with all the requirements as imposed 1:
the ADA, the regulations of the Federal government issued thereunder, and assurance by the Agency pursuant thereto.
12.04 Public Entity Crime: A person or affiliate who has been placed on the convicted vendor list following a convictio
for a public entity crime may not submit a bid on a contract to provide any goods or services to a public entity; may n4
submit a bid on a contract with a public entity for the construction or repair of a public building or public work; may n(
submit bids on leases of real property to a public entity; may not be awarded or perform work as a contractor, supplie
Kom pfe"�9-14"6 VV#' ' 2VT
excess of the threshold amount provided in Section 287.017, Florida Statutes, for CATEGORY TWO for a period of 2
months from the date of being placed on the convicted vendor list.
12.05 Discrimination: In accordance with Section 287.134, Florida Statutes, an entity or affiliate who has been place
on the Discriminatory Vendor List, kept by the Florida Department of Management Services, may not submit a bid on
contract to provide goods or services to a public entity; may not submit a bid on a contract with a public entity for th
construction or repair of a public building or public work; may not submit bids on leases of real property to a public entit.
may not be awarded or perform work as a contractor, supplier, subcontractor or consultant under a contract with ar
public entity; and may not transact business with any public entity.
12.06 Suspension, Revocation, Denial of Qualification or Determination of Contractor Non -Responsibility: A
entity or affiliate who has had its Certificate of Qualification suspended, revoked, denied or have further been determine
by the Department to be a non -responsible contractor may not submit a bid or perform work for the construction or repe
of a public building or public work on a contract with the Agency.
12.07 Prohibited Interests: Neither the Agency nor any of its contractors or their subcontractors shall enter i t ar
'n ro
contract, subcontract or arrangement in connection with the project or any property included or planned to be incluLd
the project in which any member, officer or employee of the Agency or the locality during tenure or for 2 years thereaft
has anv interest, direct or indirect. If anv such roesent or former riernher, off icer or e-jrt-ofloMee involuntarilM acouires r Kill
M snaii riot parucipate in any action Dy ine
contract, subcontract or arrangement,
The Agency shall insert in all contracts entered into in connection with the project or any property included or planned
be included in any project, and shall require its contractors to insert in each of their subcontracts, the following provision:
"No member, officer or employee of the Agency or of the locality during his tenure or for 2 years
thereafter shall have any interest, direct or indirect, in this contract or the proceeds thereof."
The provisions of this paragraph shall not be applicable to any agreement between the Agency and its fiscal depositories
or to any agreement for utility services the rates for which are fixed or controlled by a governmental agency.
12.08 Interest of Members of, or Delegates to, Congress: No member or delegate to the Congress of the United
States shall be admitted to any share or part of this Agreement or any benefit arising therefrom.
13.00 Miscellaneous Provisions:
13.01 Environmental Regulations: The Agency will be solely responsible for compliance with all the applicable
environmental regulations, for any liability arising from non-compliance with these regulations, and will reimburse th--
Department for any loss incurred in connection therewith. The Agency will be responsible for securing any applicablc
permits.
STATE orFLORIDA DEPARTMENT opTRANSPORTATION 525�0-40
PRODUCTION SUPPORT
LOCAL AGENCY PROGRAM AGREEMENT oGC-'011z
Page 11
13.12 Restrictions on Lobbying:
Federal: The Agency agrees that no federally -appropriated funds have been paid, or will be paid by or on behalf ofthe
Agency, to any mon�v influencing or attempting to influence any o�icarmr employee of any federal agency, a Member
of [�onqnaem, a' officer or employee of ConQnoae or an employee of Member of Congress in connection with the
awarding ofany federal contraut, the making ofany federal grant, the making of any federal loan, the entering into of any
cooperative agremmeni, and the axtension, conUnuaUon, renewal, ama-idmmnt or modification o[any (adm,a| contract,
grant, loan orcooperative agreement.
|fany funds other than fedmra||y-appropriated funds have been paid by the Agency to any person for influencing or
attempting to influence an officer or employee ofany federal agency. e Member of Congreem, an officer or employee of
STATE OF" FLORIDA D.-- ' PARTMENT OF TRANSPORTATION 51-15 - 0 , 0 4 C
LOCAL AGENCY PROGRAM AGREEMENT FIROEAUGTK)N SUPPORTC-G(, , 1 01M 2
Page 12
9 V 11 L I a W�d I oR I -j W1 I LWNA W1 L7-M Lviv L101 ff-- IILWLF 9
4:11M
The Agency:
1 . shall utilize the U.S. Department of Homeland Security's E-Verify system to verify the employment eligibility of all
new employees hired by Agency during the term of the contract; and
2. shall expressly require any subcontractors performing work or providing services pursuant to the state contract to
likewise utilize the U,S. Department of Homeland Security's E-Verify system to verify the employment eligibility of
all new employees hired by the subcontractor during the contract term.
STATE OF FLORIDA DEPARTMENT OF TRANSPORTATION 525-010-40
PRODUCTION SUPPORT
LOCAL AGENCY PROGRAM AGREEMENT OGC— 10112
Page 13
IN WITNESS WIJEREOF, the parties have caused these presents to be executed the day and year first above written
AGENCY Mcrhroe County, Flo STATE OF FL I A EP T OF TRANSPORTATION
k
By: Z' 17
I, t�4 -"
\Rh' Name: HAMId &
Title: Mnyor, ii A Director of
)4ame: Gear e Neugerif Title: TrUnIportabon DevalapM#nj
,7
Attest: \AA AN CA.
Titit;: blgrk Title: J0, ff
U, %
COUNTY ATTORNEY
VED AS TO FORM:
01HFINIIINE M LIMBERT-BARBnWS
ASSI!Q COUNTY ATTORNEY
See attached Encumbrance Form for date of funding approval by Comptroller,
525-010-0 SIAIE-0[ TRANS POR-TA NON
LOCAL AGENCY PROGRAM AGREEMENT PRC)DUCIION SUPPORT
0�106,
Page
AM=
Dated
IV=
0 0 •0
PROJECT DESCRIPTION: Construction and Construction Engineering and Inspection (CEI) services for the No Name
Key Bridge Repair Project. Work will include repairs to deck, beams, columns, bearings, bent caps and pile jackets and
other bridge elements. The work will include repairing concrete spalling, and rebar corrosion on the deck and sidewalks.
The remaining bridge elements will be repaired by cleaning rebar (or replacing where needed) and repairing concrete
spall and cracks, cleaning and repairing (or replacing) bearings and expansion joints.
The audit report(s) required in the Agreement shall include a Schedule of Project Assistance that will reflect t
Department's contract number, the Financial Project Number (FPN), the Federal Authorization Number (FAN), whe
applicable, the amount of state funding action (receipt and disbursement of funds), any federal or local funding action, a
the funding action from any other source with respect to the project. I
The Agency shall commence the project's activities subsequent to the execution of this Agreement and shall perform in
accordance with the following schedule:
a) Study to be completed by
b) Design to be completed by 1/30/2014
c) Right -of -Way requirements identified and provided to the Department by 1/30/2014
1) Right -of -Way to be certified by 1/30/2014
e) Construction contract to be let by 6/30/2014
f) Construction to be completed by 6/30/2015
If this schedule cannot be met, the Agency will notify the Department in writing with a revised schedule or the project is
subject to the withdrawal of federal funding.
"Ilk MAHVIIIIIIIII
STATE OF FLORIDA DEPARTMENT OFT NSPORTATION 525-010-40
PORT
LOCAL AGENCY PROGRAM AGREEMENT PRODUCTION SUP08/06
Page
EXH I BIT
PA j&5Wz
Federal Resources Awarded to the Recipient Pursuant to This Agreement Consist of the Following:
Federal Agency: Federal Highway Administration
CFDA #: 20.205 Highway Planning and Construction
Amount: $ 3,238,552
STATE OF FLORIDA DEPARTMENT OF TRANSPORTATION 525-010-40
PROD',JCTION SUPPORT
LOCAL AGENCY PROGRAM AGREEMENT 08/06
Page 5
State Resources Awarded to the Recipient Pursuant to This Agreement Consist of the Following:
Subject to Section 215.97, Florida Statutes
State Project: County Incentive Grant Program (CIGP)
State Awarding Agency: Florida Department of Transportation
Catalog of State Financial Assistance (CSFA) Number: 55.008
Grant Amount: $2,323,047.00
Compliance Requirement Applicable to State Resources Awarded Pursuant to This Agreement are as follows:
Allowed Activities: The CIGP Program is intended to provide grants to counties for improving transportation facilities,
which are located on the State Highway System or which relieve traffic congestion on the State Highway System.
Eligibility: 339.2817, Florida Statutes, establishes several minimum eligibility criteria in order to qualify for the CIGP
funds. The project must:
1. Improve a facility on the State Highway system or relieve traffic congestion on the State Highway system,
CIGP funds cannot be used for operational expenses.
2. Be consistent to the maximum extent feasible with the Florida Transportation Plan.
3. Be consistent to the maximum extent feasible, where appropriate, with the Local Metropolitan Planning
Organization.
4. Be consistent with, to the maximum extent feasible, with any local comprehensive plans.*
* If the project is not in these plans, it must be amended into them within six months of application.
Matching: The Department shall fund 50% of the cost of the project funded under this program unless the participant
qualifies and is approved for a reduction or waiver of match under the Rural Economic Development Initiative (REDI)
program. NOTE: The County has met the REDI match waiver.
NOTE: Section .400(d) of OMB Circular A-133, as revised and Section 215.97(5)(a), Florida Statutes, require that the
information about Federal Programs and State Projects included in Exhibits "I" and "2" be provided to the recipient.
STATE OF FLORIDA DEPARTMENT OF TRANSPORTATION 525-010-40
PRODUCTION SUPPORT
LOCAL AGENCY PROGRAM AGREEMENT 09/11
Page
AGENCY NAME & BILLING ADDRESS FP: 4301211-11
Name:— No Name Key Bridge Rehabilitation Length: 2230 Feeo
TYPE OF WORK By Fiscal Year
FUNDING
TOTAL
PROJECT FUNDS
(2)
AGENCY
FUNDS
(3)
STATE &
FEDERAL FUNDS
Manning FY:
FY:
FY:
Total Planning Cost
Project Development & Environment (PD&E)
FY:
FY:
FY:
Total PD&E Cost
Design FY:
FY:
FY:
Total Design Cost
Right -of -Way FY:
FY:
FY:
Total Right -of -Way Cost
Construction FY:
FY: 2014
FY: 2015
FY:
Total Construction Cost
2,574,448
643.612
1 930 �836
2,574,448
643,612
1,930.836
Construction Engineering and Inspection (CEI)
FY: 2014
FY: 2015
FY:
Total CEI Cost
Total Construction and CEI Costs
522.948
130.737
392.211
522,948
—
1 130,737
1 392,211
3,097,396
774,349
2,323,047
TOTAL COST OF THE PROJECT
3,097,396
774,349
2.323.047
STATE OF FLORIDA DEPARTIVIFN r OF TRANSPORTATION 525-010-40
PRODUCTION SUPPORT
LOCAL AGENCY PROGRAM AGREEMENT 09/11
Page
FW W04till"t
AGENCY NAME & BILLING ADDRESS FPN: 430121-2
Name: No Name Key Bridge Rehal�ilitatlon Length: 2230 Fee�
TYPE OF WORK By Fiscal Year
FUNDING
TOTAL
PROJECT FUNDS
(2)
AGENCY
FUNDS
(3)
STATE &
FEDERAL FUNDS
Planning FY:
FY:
FY:
Total Planning Cost
Project Development & Environment (PD&E)
FY:
FY:
FY:
Total PD&E Cost
Design FY:
FY:
FY:
Total Design Cost
Right -of -Way FY:
FY:
FY:
Total Right -of -Way Cost
Construction FY:
FY: 2014
FY:
FY:
Total Construction Cost
2,935,000
1935,000
2,935,000
2.935,000
Construction Engineering and Inspection (CEI)
FY
FY: 2014
FY:
Total CEI Cost
Total Construction and CEI Costs
303.552
303,552
303,552
303,552
3,238,552
3,238,552
TOTAL COST OF THE PROJECT
3,238,552
3,238,552
The Department's fiscal year begins on July 1. For this project, funds are not projected to be available until after the Ist of July of
each fiscal year. The Department will notify the Agency, in writing, when funds are available.
Voluntaryo• for • • Contracts
STATE OF FLORIDA DEPARTMENT OF TRANSPORTATION 375-030-33
CERTIFICATION FOR DISCLOSURE OF LOBBYING ACTIVITIES PROCUREMENT10/01
ON FEDERAL -AID CONTRACTS
The prospective participant certifies, by signing this certification, that to the best of his or her knowledge
and belief:
(1) No federal appropriated funds have been paid or will be paid, by or on behalf of the undersigned, to
any person for influencing or attempting to influence an officer or employee of any federal agency, a
Member of Congress, an officer or employee of Congress, or an employee of a Member of Congress in
connection with the awarding of any federal contract, the making of any federal grant, the making of any
federal loan, the entering into of any cooperative agreement, and the extension, continuation, renewal,
amendment, or modification of any federal contract, grant, loan, or cooperative agreement.
(2) If any funds other than federal appropriated funds have been paid or will be paid to any person for
influencing or attempting to influence an officer or employee of any federal agency, a Member of
Congress, an officer or employee of Congress, or an employee of a Member of Congress in connection
with this federal contract, grant, loan, or cooperative agreement, the undersigned shall complete and
submit Standard Form-LLL, "Disclosure of Lobbying Activities", in accordance with its instructions.
(Standard Form-LLL can be obtained from the Florida Department of Transportation's Professional
Services Administrator or Procurement Office.)
was made or entered into. Submission of this certification is a prerequisite for making or entering into this
transaction imposed by Section 1352, Title 31, U.S. Code. Any person who fails to file the required
certification shall be subject to a civil penalty of not less than $10,000 and not more than $100,000 for
each such failure.
I I a r. [or.11 1 W1111 L" a W19 I Q V.1" I Sir-] I I VVJ I r. I I KJW,4 It I VJL- I I It Kq I k*M L*1;!r.RZ Wkel to I I I[_! I
Name 7_Uullan Lson2sBr ckerhoff, Inc.
By: Date: 12-(1 Lf
Authorized Signature. Kenneth B. Spilleft, P.E.
Title: Senior Vice President
FLORIDASTATE OF OF • O r, 375-030-35
• - - •PROCUREMENT
0!
D VOLUNTARY EXCLUSION FOR
r: CONTRACTS
(Compliance with 49CFR,Section
(Appendix Certification]
It is certified that neither the below identified firm nor its principals are presently suspended, proposed for
debarment, declared ineligible, or voluntarily excluded from participation in this transaction by any federal
department or age
Name of n, tant: a ns Brinc erhoff, Inc.
By - Date: � 1 !j
14
Authorized SIJ re
Kenneth B. Spillett, P.E.
Title: Spninr Vice PrPcirlpnt
to s r
1 . By signing and submitting this certification with the proposal, the prospective lower tier participant is providing the certification
set out below.
2. The certification in this clause is a material representation of fact upon which reliance was placed when this transaction was
entered into. If it is later determined that the prospective lower tier participant knowingly rendered an erroneous certification, in
addition to other remedies available to the Federal Government, the Department may pursue available remedies, including
suspension and/or debarment.
3. The prospective lower tier participant shall provide immediate written notice to the person to which this proposal is submitted. If
at any time the prospective lower tier participant learns that its certification was erroneous when submitted or has become
erroneous by reason of changed circumstances.
4. The terms 'covered transaction', 'debarred', 'suspended', 'ineligible', 'lower tier covered transaction','participant', 'person', primary
covered transaction', 'principal', 'proposal', and 'voluntarily excluded', as used in this clause, have the meanings set out in the
Definitions and Coverage sections of the rules implementing Executive Order 12549. You may contact the person to which this
proposal is being submitted for assistance in obtaining a copy of those regulations.
5. The prospective lower tier participant agrees by submitting this proposal that, should the proposed covered transaction be
entered into, it shall not knowingly enter into any lower tier covered transaction with a person who is debarred, suspended, declared
ineligible, or voluntarily excluded from participation in this covered transaction, unless authorized by the Department or agency with
which this transaction originated.
6. The prospective lower tier participant further agrees by submitting this proposal that it will include this clause titled "Appendix B:
Certification Regarding Debarment, Suspension, Ineligibility and Voluntary Exclusion - Lower Tier Covered Transaction", without
modification, in all lower tier covered transactions and in all solicitations for lower tier covered transactions.
7. A participant in a covered transaction may rely upon a certification of a prospective participant in a lower tier covered transaction
that it is not debarred, suspended, ineligible, or voluntarily excluded from the covered transaction, unless it knows that the
certification is erroneous. A participant may decide the method and frequency by which it determines the eligibility of its principals.
Each participant may, but is not required to, check the Nonprocurement List.
8. Nothing contained in the foregoing shall be construed to require establishment of a system of records in order to render in good
faith the certification required by this clause. The knowledge and information of a participant are not required to exceed that which
is normally possessed by a prudent person in the ordinary course of business dealings.
9. Except for transactions authorized under paragraph 5 of these instructions, if a participant in a covered transaction knowingly
enters into a lower tier covered transaction with a person who is suspended, debarred, ineligible, or voluntarily excluded from
participation in this transaction, in addition to other remedies available to the Federal Government, the Department may pursue
available remedies, including suspension and/or debarment.