Item C15C ounty of M onroe
{f `° "
rel
BOARD OF COUNTY COMMISSIONERS
n
Mayor David Rice, District 4
The FlOnda Key
y
m ��
1
Mayor Pro Tem Sylvia J. Murphy, District 5
Danny L. Kolhage, District 1
George Neugent, District 2
Heather Carruthers, District 3
County Commission Meeting
September 19, 2018
Agenda Item Number: C.15
Agenda Item Summary #4674
BULK ITEM: Yes DEPARTMENT: Airports
TIME APPROXIMATE: STAFF CONTACT: T.J Henderson (305) 289 -6302
none
AGENDA ITEM WORDING: Approval to award bid and contract to Charley Toppino & Sons in
the amount of $397,440.00 for the Key West International Airport Faraldo Circle Realignment &
Curbside Improvements project. Total cost to be funded by the FAA Grant 37 -56 (90 %) and pending
Passenger Facility Charge (PFC) Application 418 (10 %).
ITEM BACKGROUND: Two bids were received at the bid opening held on June 13, 2018. Per
attached bid recap and the Airport consultant's recommendation, staff recommends the lowest bidder
Charley Toppino & Sons for this project.
During the Master Plan process it was determined that the amount of curbside available and the road
layout is inadequate which results in congestion during peak times at the Airport. The objective of
this project is to realign Faraldo Circle and modify the existing curbside to provide two full lanes for
through traffic and one additional lane for commercial, taxi, public bus and private vehicles (ride -
share) of various sizes and locations along the curbside.
PREVIOUS RELEVANT BOCC ACTION:
On February 21, 2018, the BOCC granted approval to advertise the bid solicitation. On August 15,
2018, the BOCC ratified FAA Grant 37 -56 that included funding for this project.
CONTRACT /AGREEMENT CHANGES:
N/A
STAFF RECOMMENDATION: Approval.
DOCUMENTATION:
Toppino Faraldo Circle Improvements
FINANCIAL IMPACT:
Effective Date: Upon Notice to Proceed (NTP)
Expiration Date: 125 days after NTP
Total Dollar Value of Contract: $397,440.00
Total Cost to County: 0.00
Current Year Portion:
Budgeted: Yes
Source of Funds: 90% FAA Grant # 37- 56/10% PFC #18 (pending)
CPI:
Indirect Costs:
Estimated Ongoing Costs Not Included in above dollar amounts:
Revenue Producing: No If yes, amount:
Grant:
County Match:
Insurance Required:
Additional Details:
REVIEWED BY:
Beth Leto
Completed
08/30/2018 2:42 PM
T.J Henderson
Completed
08/30/2018 3:13 PM
Pedro Mercado
Skipped
09/04/2018 7:44 PM
Christine Limbert
Completed
09/04/2018 7:51 PM
Budget and Finance
Completed
09/05/2018 9:02 AM
Maria Slavik
Completed
09/05/2018 9:18 AM
Kathy Peters
Completed
09/05/2018 9:23 AM
Board of County Commissioners
Pending
09/19/2018 9:00 AM
r
200 W. Forsyth Street
Suite 1520
Jacksonville, Florida 32202
1.904.636.5432 Fax 1.904.636.5433
Donald DeGraw
Airport Director
Monroe County Airports
Key West International Airport
3491 South Roosevelt Blvd.
Key West, FL 33040
Re: Key West International Airport
Faraldo Circle Realignment and Curbside Improvements
FAA AIP No. 3 -12- 0037 - 057 -2018
Dear Don,
June 15, 2018
A public bid opening was held on June 13, 2018 for the above subject project. From the submitted
proposals Jacobs has compiled the unit prices and bid amounts in the attached Bid Tabulation Matrix.
After our review it is our opinion that the unit prices appear to be fair and reasonable.
From the values represented in the attached bid tabulation the following is a summary of the bid results.
Proposer
Bid Amount
Charley T oppino & Sons, Inc.
$397,440.00
Douglas N. Higgins, Inc.
$583,000.00
Engineer's Estimate
$418,397.50
Based on our review of the bid prices and contingent upon Monroe County's legal review of the
proposer's bid documents and funding availability, Jacobs recommends award to Charley Toppino &
Sons, Inc. If you have any questions or require any additional information, please do not hesitate to
contact us.
Sincerely,
Encl: Monroe County Purchasing Office Bid Tabulation.
Jacobs Bid Tabulation Matrix
cc:
Jacobs 'Gn 4ieerin Group inc.
BUDGET AND FINANCE
PURCHASING DEPARTMENT
TABULATION SHEET
OPEN DATE: JUNE 13, 2018 AT 3:00 PM
TITLE: KEY WEST INTERNATIONAL AIRPORT FARALDO CIRCLE
REALIGNMENT & CURBSIDE IMPROVEMENTS, MONROE COUNTY, FLORIDA
RESPONDENT
BID BOND
BID AMOUNT
Douglas N. Higgins, Inc.
5%
$583,000.00
Charley Toppino & Sons
5%
$397,440.00
Bid Committee Present N/A
Members of the Public Present Paul Waters(DN Higgins), Patrick Ortega, Michael Labrada(Toppinos)
I hereby certify that this is a true and correct copy of said bid opening and that all bidders listed above have been checked against the
State of Florida Convicted & Suspended Vendor listings. All bids listed above were received by the date and time specific
Bid Opened By: Lisa Abreu, OMB
C.15.a
BID TABULATION
Faraldo Circle Realignment and Curbside Improvements
Key West International Airport
3 -12- 0037 - 057 -2018
10
5
RELOCATION
6
P -110 -5
RELOCATE EXISTING TRAFFIC SIGNAGE STEEL POST
LS
1
' rrr rr
P -110 -6
RENTAL CAR SIGN RELOCATION INCLUDING
EA
' rrr
7
' rrr rr
CONCRETE SIGN BASE (LIGHTED, STEEL POST
' rr rr
1
' rrr rr
MOUNTED, GREATER THAN 10 SF
P -110 -7
GUIDANCE SIGN RELOCATION INCLUDING CONCRETE
EA
BACKFILL AND /OR CONCRETE SIGN BASE
8
(UNLIGHTED, WOOD OR STEEL POST MOUNTED,
1
TOTAL BASE BID AMOUN
Kyle B. Holley, P.E.
Prepared by:
Bid Opening Date: June 13, 2018
INSTALLED EARTH /ROCK /SIDEWALK, COMPLETE.
43
INCLUDES HAND EXCAVATION, SAW CUTTING OF
30
' rrr rr
' rrr rr
ROCK, LABOR, CONDUIT, DUCT MARKERS, WARNING
' rrr
' rrr
' rr rr
' rrr rr
TAPE, PULL STRING, SOD RESTORATION, CONCRETE,
' rr rr
' rr rr
' rrr rr
LABOR, AND BACKFILL COMPLETE IN PLACE.
16001 -2
#10, XHHW, 600V CONDUCTOR INSTALLED IN NEW
LF
AND EXISTING CONDUIT SYSTEM, COMPLETE.
44
INCLUDES INSTALLATION, ALL LABOR, SPLICE KITS,
125
PULLING COMPOUND, PULL STRING, TESTING,
' rr rr
' rr rr
CIRCUIT IDENTIFICATION, ETC. COMPLETE IN PLACE
' rr rr
' rr rr
' rr rr
16001 -3
ELECTRICAL CONNECTION TO OVERHEAD
EA
RELOCATED LIGHT POLE, COMPLETE IN PLACE.
' rr rr
' rr rr
' rr rr
' rr rr
INCLUDES LABOR, COORDINATION, CONDUITS WITHIN
' rrr rr
' rrr rr
' rr rr
'
FOUNDATION, LIQU IDTIGHT FLEXIBLE CONDUIT,
' .rrr rr
' .rrr rr
' rrr
' rrr rrr
XHHW CONDUCTORS WITHIN FOUNDATION, 4/0 BARE
'
rr rr
45
rr
TINNED COPPER GROUNDING CABLE, SPLICE KITS,
rr rr
1
IDENTIFICATION, GROUNDING, GROUND RODS, ,
EXCAVATION IN ROCK, TESTING, BACKFILL, LABOR,
ETC. FOR A COMPLETE WORKING SYSTEM IN PLACE
16001 -4
ELECTRICAL CONNECTION TO ELECTRICAL SIGN,
EA
COMPLETE IN PLACE. INCLUDES LABOR,
COORDINATION, CABLE OF CONDUITS WITHIN
46
FOUNDATION, LIQUIDTIGHT FLEXIBLE CONDUIT,
1
' rr rr
' rr rr
SPLICE KITS, IDENTIFICATION, GROUNDING
'.
rr rr
' r rrr rr
' r rrr rr
EXCAVATION, TESTING, BACKFILL, LABOR FOR A
COMPLETE WORKING SYSTEM
16001 -5
RELOCATE PULLBOX 17 "W X 30 "D X 36 "H WITH COVER
EA
INSTALLED IN EARTH /ROCK, COMPLETE. INCLUDES
INSTALLATION, EXCAVATION IN EARTH /ROCK,
PULLBOX, GROUND ROD, EXOTHERMIC WELD,
' r rrr rr
' r rrr rr
47
'. rr rr
TRAFFIC RATED COVER, ROCK, SPLICE KITS,
' rrr rr
1
INTERCEPT ION OF EXISTING CONDUIT AND CABLING
SYSTEM, TESTING, IDENTIFICATION, BACKFILL, SOD
RESTORATION, AND ELECTRICAL RE- CONNECTIONS
ETC. COMPLETE IN PLACE
TOTAL BASE BID AMOUN
Kyle B. Holley, P.E.
Prepared by:
Bid Opening Date: June 13, 2018
Packet Pg. 550
' rrr rr
' rrr rr
' rrr rr
' rrr rr
' rrr
' rrr
' rr rr
' rrr rr
' rrr
' rr rr
' rr rr
' rrr rr
' rr rr
' rr rr
' rr rr
' rr rr
' rr rr
' rr rr
' rr rr
' rr rr
' rr rr
' rr rr
' rr rr
' rr rr
' rrr rr
' rrr rr
' rr rr
'
rr rr
' .rrr rr
' .rrr rr
' rrr
' rrr rrr
'
rr rr
'
rr
'
rr rr
' rr rr
' rr rr
'. rr rr
'.
rr rr
' r rrr rr
' r rrr rr
' r rrr rr
' r rrr rr
'. rr rr
'. rr rr
' rrr rr
' rrr rr
' rr
' rrr rr
' rr
' rrr rr
' rrr
' rrr rr
' rrr rr
' rrr rr
' :rrr rr
' .rrr rr
' rrr rr
' rrr rr
' rrr
' rrr rr
'. rr
' rrr rr
' rrr
' rr rr
' rr
'
rrr rrr
'.rr rr
' rr
'
rr rr
MENNEN
NEEMEN
Iloilo
000000
Iloilo
' r rrr rr
' .rrr rr
' .rrr rr
' rrr rr
' rrr rr
Packet Pg. 550
BUDGET AND FINANCE
PURCHASING DEPARTMENT
TABULATION SHEET
OPEN DATE: JUNE 13, 2018 AT 3:00 PM
TITLE: KEY WEST INTERNATIONAL AIRPORT FARALDO CIRCLE
REALIGNMENT & CURBSIDE IMPROVEMENTS, MONROE COUNTY, FLORIDA
RESPONDENT
BID BOND
BID AMOUNT
Douglas N. Higgins, Inc.
5%
$583,000.00
Charley Toppino & Sons
5%
$397,440.00
Bid Committee Present N/A
Members of the Public Present Paul Waters(DN Higgins), Patrick Ortega, Michael Labrada(Toppinos)
I hereby certify that this is a true and correct copy of said bid opening and that all bidders listed above have been checked against the
State of Florida Convicted & Suspended Vendor listings. All bids listed above were received by the date and time specific
B/d Opened By: Lisa Abreu, OMB
S E C T I O N D
C O N T R A C T
Faraldo Circle Realignment and Curbside Improvements
Key West International Airport
THIS AGREEMENT made and entered into the day of September, 2018
by and between Charley Topping & Sons, Inc __ Contractor,
and the Monroe County Board of Commissioners, Key West, Florida, Owner.
WITNESSETH:
That the Contractor, for the consideration hereinafter fully set out hereby agrees with the
Owner as follows:
That the Contractor, shall furnish all the materials, and perform all of the work in the
manner and form as provided by the following enumerated documents;
Instruction to Bidders, Form of Proposal, General Provisions, Special Provisions,
Technical Specifications, Form of Contract, Form of Bond, Drawings and Addenda,
which are attached hereto and made a part hereof, as if fully contained herein, for
the construction of:
Faraldo Circle Realignment and Curbside Improvements
Key West International Airport
Monroe County, Florida
2. That the Contractor shall commence the work to be performed under this
agreement on a date to be specified in a written order of the Owner and shall
fully complete all work hereunder within one hundred and twenty -five (125)
calendar days from the Notice -to- Proceed (Construction) as per Special Provision
No. 2.
3. The Owner hereby agrees to pay to the Contractor for the faithful performance of the
agreement, subject to additions and deductions as provided in the
specifications or proposal in lawful money of the United States as follows:
Approximately Three hundred ninety seven thousand four hundred and fortv
Dollars ( $397,440.00 ) in accordance with lump sum and unit prices set forth
in The proposal.
4. On or before the 15th day of each calendar month, the second party shall make
partial payment to the Contractor on the basis of a duly certified and approved
estimate of work performed during the preceding calendar month by the
Contractor, less ten percent (10 %) of the amount of such estimate which is to be
retained by the Owner until all work has been performed strictly in accordance
with this agreement.
Upon submission by the Contractor of evidence satisfactory to the Owner that all
payrolls, material bills and other costs incurred by the Contractor in connection
with the construction of the work have been paid in full, final payment on account of
this agreement shall be made within twenty (20) days after the completion by the
Contractor of all work covered by this agreement and the acceptance of such work
by the Owner.
S It is mutually agreed between the parties hereto that time is of the essence in this
contract and in the event the construction of the work is not completed within the
time herein specified, it is agreed that from the compensation otherwise to be
paid to the Contractor, the Owner may retain the amounts described in the
Liquidated Damages, Special Provision No. 3, per day for each day thereafter,
Sundays and holidays included, that the work remains uncompleted, which sum shall
represent the actual damages which the Owner will have sustained per day by failure
of the Contractor to complete the work within the time stipulated and this sum is
not a penalty being the stipulated damages the Owner will have sustained in
the event of such default by the Contractor.
7. It is further mutually agreed between the parties hereto that if at any time after
the execution of this agreement and the surety bond hereto attached for its
faithful performance, the Owner shall deem the surety or sureties upon such
bond to be unsatisfactory, or if, for any reason, such bond ceases to be adequate to
cover the performance of the work, the Contractor shall, at its expense within five
(5) days after the receipt of notice from the Owner so to do, furnish an
additional bond or bonds in such form and amount and with such surety or
sureties as shall be satisfactory to the Owner. In such event, no further payment to
the Contractor shall be deemed to be due under this agreement until such new or
additional security for the faithful performance of the work shall be furnished in
manner and form satisfactory to the Owner.
8. MAINTENANCE O F RE Contractor shall maintain all books, records and
documents directly pertinent to performance under this Agreement in accordance
with generally accepted accounting principles consistently applied. Each party to this
Agreement or their authorized representatives shall have reasonable and timely
access to such records of each other party to this Agreement for public records
purposes during the term of the Agreement and for four years following the
termination of this Agreement. If an auditor employed by the County or Clerk
determines that monies paid to Contractor pursuant to this Agreement were
spent for purposes not authorized by this Agreement, the Contractor shall repay the
monies together with interest calculated pursuant to Sec. 55,03, Florida
Statutes, running from the date the monies were paid to Contractor.
PUB LIC ACCESS. Public Records Compliance. Contractor must comply with
Florida public records laws, including but not limited to Chapter 119, Florida Statutes
and Section 24 of article I of the Constitution of Florida. The County and Contractor
shall allow and permit reasonable access to, and inspection of, all documents,
records, papers, letters or other "public record" materials in its possession or under
its control subject to the provisions of Chapter 119, Florida Statutes, and made or
received by the County and Contractor in conjunction with this contract and related
to contract performance. The County shall have the right to unilaterally cancel this
contract upon violation of this provision by the Contractor. Failure of the Contracto Packet;Pg. 553
to abide by the terms of this provision shall be deemed a material breach of this
contract and the County may enforce the terms of this provision in the form of a court
proceeding and shall, as a prevailing party, be entitled to reimbursement of all
attorney's fees and costs associated with that proceeding. This provision shall
survive any termination or expiration of the contract.
The Contractor is encouraged to consult with its advisors about Florida Public
Records Law in order to comply with this provision.
Pursuant to F.S. 119.0701 and the terms and conditions of this contract, the
Contractor is required to:
(1) Keep and maintain public records that would be required by the County to
perform the service.
(2) Upon receipt from the County's custodian of records, provide the County with
a copy of the requested records or allow the records to be inspected or copied within
a reasonable time at a cost that does not exceed the cost provided in this chapter or
as otherwise provided by law.
(3) Ensure that public records that are exempt or confidential and exempt from
public records disclosure requirements are not disclosed except as authorized by law
for the duration of the contract term and following completion of the contract if the
contractor does not transfer the records to the County.
(4) Upon completion of the contract, transfer, at no cost, to the County all public
records in possession of the Contractor or keep and maintain public records that
would be required by the County to perform the service. If the Contractor transfers
all public records to the County upon completion of the contract, the Contractor shall
destroy any duplicate public records that are exempt or confidential and exempt from
public records disclosure requirements. If the Contractor keeps and maintains public
records upon completion of the contract, the Contractor shall meet all applicable
requirements for retaining public records. All records stored electronically must be
provided to the County, upon request from the County's custodian of records, in a
format that is compatible with the information technology systems of the County.
(5) A request to inspect or copy public records relating to a County contract must
be made directly to the County, but if the County does not possess the requested
records, the County shall immediately notify the Contractor of the request, and the
Contractor must provide the records to the County or allow the records to be
inspected or copied within a reasonable time.
IF THE CONTRACTOR HAS QUESTIONS REGARDING THE APPLICATION OF
CHAPTER 119, FLORIDA STATUTES, TO THE CONTRACTOR'S DUTY TO
PROVIDE PUBLIC RECORDS RELATING TO THIS CONTRACT, CONTACT THE
CUSTODIAN OF PUBLIC RECORDS, BRIAN BRADLEY, AT (305) 292 -3470.
10. H OLD HAR AND INSURANCE Notwithstanding any minimum
insurance requirements prescribed elsewhere in this agreement,
Contractor shall defend, indemnify and hold the County and the County's elected
and appointed officers and employees harmless from and against (i) any
claims, actions or causes of action, (ii) any litigation, administrative
proceedings, appellate proceedings, or other proceedings relating to any type
of injury (including death), loss, damage, fine, penalty or business
interruption, and (iii) any costs or expenses (including, without limitation,
costs of remediation and costs of additional security measures that the
Federal Aviation Administration, the Transportation Security
Administration or any other governmental agency requires by reason
of, or in connection with a violation of any federal law or regulation,
attorneys' fees and costs, court costs, fines and penalties) that may be
asserted against, initiated with respect to, or sustained by, any
indemnified party by reason of, or in connection with, (A) any activity
of Contractor or any of its employees, agents, contractors or other invitees
on the Airport during the term of this Agreement, (B) the negligence or willful
misconduct of Contractor or any of its employees, agents, contractors or
other invitees, or (C) Contractor's default in respect of any of the obligations that
it undertakes under the terms of this Agreement, except to the extent the
claims, actions, causes of action, litigation, proceedings, costs or
expenses arise from the intentional or sole negligent acts or omissions of
the County or any of its employees, agents, contractors or invitees (other than
CONTRACTOR). Insofar as the claims, actions, causes of action,
litigation, proceedings, costs or expenses relate to events or
circumstances that occur during the term of this Agreement, this section will
survive the expiration of the term of this Agreement or any earlier termination of
this Agreement.
In the event the completion of the project (including the work of others) is delayed or
suspended as a result of the Contractor's failure to purchase or maintain the
required insurance, the Contractor shall indemnify the County from any
and all increased expenses resulting from such delay.
The first ten ($10.00) of remuneration paid to the Contractor is for the
indemnification provided for above.
The extent of liability is in no way limited to, reduced, or lessened by the
insurance requirements contained elsewhere within this agreement.
CERTIFICATES OF INSURANCE. Original Certificates of Insurance shall be
provided to the COUNTY at the time of execution of this Agreement and certified
copies provided if requested. Each policy certificate shall be endorsed with a
provision that not less than thirty (30) calendar days' written notice shall be
provided to the COUNTY before any policy or coverage is canceled or restricted. The
underwriter of such insurance shall be qualified to do business in the State of
Florida. If requested by the County Administrator, the insurance coverage shall be
primary insurance with respect to the COUNTY, its officials, employees,
agents and volunteers. Failure of CONTRACTOR to comply with the
requirements of this section shall be cause for immediate termination of this
agreement.
10. NON - WAIVER OF IMMUNITY: Notwithstanding the provisions of Sec. 768.28,
Florida Statutes, the participation of COUNTY and CONTRACTOR in this
Agreement and the acquisition of any commercial liability insurance coverage, self -
insurance coverage, or local government liability insurance pool coverage shall
not be deemed a waiver of immunity to the extent of liability coverage, nor shall
any Agreement entered into by the COUNTY be required to contain any provision for
waiver.
11. NO PLEDG OF CREDIT CONTRACTOR shall not pledge the COUNTY'S
credit or make it a guarantor of payment or surety for any contract, debt,
obligation, judgment, lien, or any form of indebtedness. CONTRACTOR further
warrants and represents that it has no obligation or indebtedness that would
impair its ability to fulfill the terms of this contract.
12. NO TICE REQUIREMENT Any notice required or permitted under this
agreement shall be in writing and hand delivered or mailed, postage prepaid, to
the other party by certified mail, returned receipt requested, to the following:
FOR COUNTY:
Pedro Mercado
Assistant County Attorney
1111 12th Street, Suite 408
Key West, FL 33040
T. J. Henderson, Acting Director of Airports
Key West International Airport
3491 S. Roosevelt Blvd.
Key West, Florida 33040
F CONT RACTOR:
Frank Toppino P resident
Charlev Tog i & Sons, Inc.
125 ino In dustrial Driv
Ke West 4 Flo rida 33040
13. GOVERNIN LAW, VE NUE A INTE RPRET A TION : This Agreement shall be
governed by and construed in accordance with the laws of the State of Florida
applicable to Agreements made and to be performed entirely in the State. In the
event that any cause of action or administrative proceeding is instituted for the
enforcement or interpretation of this Agreement, the COUNTY and
CONTRACTOR agree that venue will lie in the appropriate court or before the
appropriate administrative body in Monroe COUNTY, Florida.
14. MEDIATION The COUNTY and CONTRACTOR agree that, in the event of
conflicting interpretations of the terms or a term of this Agreement by or between any
of them the issue shall be submitted to mediation prior to the institution of any
other administrative or legal proceeding. Mediation proceedings initiated and
conducted pursuant to this Agreement shall be in accordance with the Florida
Rules of Civil Procedure and usual and customary procedures required by the
circuit court of Monroe County.
15, SEVERABILITY If any term, covenant, condition or provision of this Agreement
(or the application thereof to any circumstance or person) shall be declared
invalid or unenforceable to any extent by a court of competent jurisdiction, the
remaining terms, covenants, conditions and provisions of this Agreement, shall
not be affected thereby; and each remaining term, covenant, condition and
provision of this Agreement shall be valid and shall be enforceable to the fullest
extent permitted by law unless the enforcement of the remaining terms,
covenants, conditions and provisions of this Agreement would prevent the
accomplishment of the original intent of this Agreement. The COUNTY and
CONTRACTOR agree to reform the Agreement to replace any stricken provision with
a valid provision that comes as close as possible to the intent of the stricken
provision.
16. ATTO RNEY'S FEES AND COSTS COUNTY and CONTRACTOR agree that in
the event any cause of action or administrative proceeding is initiated or
defended by any party relative to the enforcement or interpretation of this
Agreement, the prevailing party shall be entitled to reasonable attorney's fees and
attorney's fees, in appellate proceedings. Each party agrees to pay its own court
costs, investigative, and out -of- pocket expenses whether it is the prevailing party or
not, through all levels of the court system.
17. ADJU OF DISPUTES OR DISAGREEMENTS COUNTY and
CONTRACTOR agree that all disputes and disagreements shall be attempted to be
resolved by meet and confer sessions between representatives of each of COUNTY
and CONTRACTOR. If no resolution can be agreed upon within 30 days after
the first meet and confer session, the issue or issues shall be discussed at
a public meeting of the Board of County Commissioners. If the issue or issues
are still not resolved to the satisfaction of COUNTY and CONTRACTOR,
then any party shall have the right to seek such relief or remedy as may be provided
by this Agreement or by Florida law.
18. COOPERATION In the event any administrative or legal proceeding is instituted
against either party relating to the formation, execution, performance, or breach of
this Agreement, COUNTY and CONTRACTOR agree to participate, to the
extent required by the other party, in all proceedings, hearings, processes,
meetings, and other activities related to the substance of this Agreement or
provision of the services under this Agreement. COUNTY and CONTRACTOR
specifically agree that no party to this Agreement shall be required to enter into
any arbitration proceedings related to this Agreement.
19. BINDING EFFECT: The terms, covenants, conditions, and provisions of this
Agreement shall bind and inure to the benefit of COUNTY and CONTRACTOR
and their respective legal representatives, successors, and assigns.
20, AUT HORITY: Each party represents and warrants to the other that the
execution, delivery and performance of this Agreement have been duly
authorized by all necessary County and corporate action, as required by law.
21. PRIVIL AND IMMUNI TIES: All of the privileges and immunities from
liability, exemptions from laws, ordinances, and rules and pensions and relief,
disability, workers' compensation, and other benefits which apply to the activity of
officers, agents, or employees of any public agents or employees of the
COUNTY, when performing their respective functions under this Agreement
within the territorial limits of the COUNTY shall apply to the same degree and
extent to the performance of such functions and duties of such officers, agents,
volunteers, or employees outside the territorial limits of the COUNTY.
22 LEGAL OBLIGATIONS AND RESPONSIBILITIES: This Agreement is not
intended to, nor shall it be construed as, relieving any participating entity from
any obligation or responsibility imposed upon the entity by law except to the
extent of actual and timely performance thereof by any participating entity, in
which case the performance may be offered in satisfaction of the obligation or
responsibility. Further, this Agreement is not intended to, nor shall it be
construed as, authorizing the delegation of the constitutional or statutory duties of Packet;Pg. 557
the COUNTY, except to the extent permitted by the Florida constitution, state
statute, and case law.
23. N RELIANCE BY NON-P ARTIES: No person or entity shall be entitled to rely
upon the terms, or any of them, of this Agreement to enforce or attempt to
enforce any third -party claim or entitlement to or benefit of any service or
program contemplated hereunder, and the COUNTY and the CONTRACTOR
agree that neither the COUNTY nor the CONTRACTOR or any agent, officer, or
employee of either shall have the authority to inform, counsel, or otherwise
indicate that any particular individual or group of individuals, entity or entities,
have entitlements or benefits under this Agreement separate and apart, inferior to,
or superior to the community in general or for the purposes contemplated in this
Agreement.
24. NO PERSONAL LIA BILITY: No covenant or agreement contained herein shall
be deemed to be a covenant or agreement of any member, officer, agent or
employee of Monroe County in his or her individual capacity, and no member, officer,
agent or employee of Monroe County shall be liable personally on this Agreement or
be subject to any personal liability or accountability by reason of the execution of this
Agreement.
25. E XECUTION IN C OUNTERPARTS: This Agreement may be executed in any
number of counterparts, each of which shall be regarded as an original, all of which
taken together shall constitute one and the same instrument and COUNTY and
CONTRACTOR hereto may execute this Agreement by signing any such
counterpart.
26. N N- DISCRIMINATION: Contractor agrees that there will be no discrimination against
any person, and it is expressly understood that upon a determination by a court of
competent jurisdiction that discrimination has occurred, this Agreement automatically
terminates without any further action on the part of any party, effective the date of
the court order. Contractor agrees to comply with all Federal and Florida statutes,
and all local ordinances, as applicable, relating to nondiscrimination. These include
but are not limited to: 1) Title VI of the Civil Rights Act of 1964 (PL 88 -352) which
prohibits discrimination on the basis of race, color or national origin; 2) Title IX of the
Education Amendment of 1972, as amended (20 USC ss. 1681 -1683, and 1685-
1686), which prohibits discrimination on the basis of sex; 3) Section 504 of the
Rehabilitation Act of 1973, as amended (20 USC s. 794), which prohibits
discrimination on the basis of handicaps; 4) The Age Discrimination Act of 1975, as
amended (42 USC ss. 6101 -6107) which prohibits discrimination on the basis of age;
5) The Drug Abuse Office and Treatment Act of 1972 (PL 92 -255), as amended,
relating to nondiscrimination on the basis of drug abuse; 6) The Comprehensive
Alcohol Abuse and Alcoholism Prevention, Treatment and Rehabilitation Act of 1970
(PL 91 -616), as amended, relating to nondiscrimination on the basis of alcohol abuse
or alcoholism; 7) The Public Health Service Act of 1912, ss. 523 and 527 (42 USC
ss. 690dd -3 and 290ee -3), as amended, relating to confidentiality of alcohol and drug
abuse patient records; 8) Title VIII of the Civil Rights Act of 1968 (42 USC s. et seq.),
as amended, relating to nondiscrimination in the sale, rental or financing of housing;
9) The Americans with Disabilities Act of 1990 (42 USC s. 1201 Note), as maybe
amended from time to time, relating to nondiscrimination on the basis of disability;
10) Monroe County Code Chapter 14, Article Il, which prohibits discrimination on the
basis of race, color, sex, religion, national origin, ancestry, sexual orientation, gender
identity or expression, familial status or age; and 11) Any other nondiscrimination
provisions in any Federal or state statutes which may apply to the parties to, or the
subject matter of, this Agreement. I
(Contractor) (Monroe County Board of Commissioners)
By: Frank Topping By:
Title: Preside !Lt
WITNESS
STATE OF FLORIDA
COUNTY OF MONROE
Title:
WITNESS:
I, the undersigned authority, a Notary Public, in and for said County and State, hereby certify that
Frank P Topino * whose name as President of Charley Topping & Sons,
Inc signed the foregoing instrument and who is known to me, acknowledged before me
on this day that being informed of the contents of the within instrument, he, in his capacity as
such, executed the same voluntarily on the date the same bears date.
Given under my hand and seal this 2.1-- day of Au u, 2018.
MICHAEL LABRADA
^ State of Florida- Notary Public
•_
Commission # GG 116317
My Commission Expires
June 19, 2021
*Who is authorized by the corporation to execute this contract.
CONTRACT 11 -8