Item C31 C.31
t, BOARD OF COUNTY COMMISSIONERS
County of Monroe Mayor Sylvia Murphy,District 5
The Florida Keys l'U � � Mayor Pro Tern Danny Kolhage,District 1
�pw° Michelle Coldiron,District 2
Heather Carruthers,District 3
David Rice,District 4
County Commission Meeting
March 21, 2019
Agenda Item Number: C.31
Agenda Item Summary #5340
BULK ITEM: Yes DEPARTMENT: Airports
TIME APPROXIMATE: STAFF CONTACT: Richard Strickland (305) 809-5200
no
AGENDA ITEM WORDING: Approval to award bid and execute contract with D.L. Porter
Constructors, Inc., in the amount of $1,176,743 for the construction of a new four-bay Car Wash
Facility at the Florida Keys Marathon International Airport to be paid with FDOT Grant GOG88
(80%) and Fleet Management Fund 504 (20%).
ITEM BACKGROUND: On October 31, 2018, the County Purchasing Department received and
opened two bids for the above-referenced project. Both bids were over $1.3 million; DL Porter in
the amount of $1,318,000 and Pedro Falcon Contractors in the amount of $1,384,106. Per County
policy, the Director of Airports along with Project Engineer from McFarland-Johnson, negotiated
with the low bidder, D.L. Porter, to value engineer the project in an attempt to bring project costs
down. With various items reworked or removed from the original scope of work, the final
negotiated price is $1,176,743.
PREVIOUS RELEVANT BOCC ACTION:
On December 14, 2016, the BOCC approved the original FDOT Joint Participation Agreement
GOG88 for this project. On August 15, 2018, the BOCC granted approval to advertise the bid
solicitation. On October 17, 2018, the BOCC approved FDOT supplemental joint participation
agreement Number One providing increased funding, and on March 21, 2019, the BOCC will
consider approval of FDOT supplement joint participation agreement Number Two providing the
additional funding needed to completely fund the project and construction administration.
CONTRACT/AGREEMENT CHANGES:
new construction agreement for MTH Car Wash Facility
STAFF RECOMMENDATION: Approval.
DOCUMENTATION:
DL Porter Constructors, Inc. MTH Car Wash Facility
Packet Pg. 760
C.31
FINANCIAL IMPACT:
Effective Date:
Expiration Date:
Total Dollar Value of Contract: Final negotiated price is $1,176,743
Total Cost to County:
Current Year Portion:
Budgeted:
Source of Funds: To be paid with FDOT Grant GOG88 (80%) and Fleet Management Fund 504
(20%).
CPI:
Indirect Costs:
Estimated Ongoing Costs Not Included in above dollar amounts:
Revenue Producing: If yes, amount:
Grant:
County Match:
Insurance Required:
Additional Details:
REVIEWED BY:
Beth Leto Completed 03/05/2019 5:33 PM
Richard Strickland Completed 03/05/2019 5:35 PM
Pedro Mercado Completed 03/05/2019 5:37 PM
Budget and Finance Completed 03/06/2019 9:10 AM
Maria Slavik Completed 03/06/2019 9:42 AM
Kathy Peters Completed 03/06/2019 11:07 AM
Board of County Commissioners Pending 03/21/2019 9:00 AM
Packet Pg. 761
C.31.a
j
McFarland,,
a 49 Court`7t.,Metrocenter
roe-PO Of ox 1980-C�3ir7gp�7<�mton,NY 1"3902
c 1 -Fax:607-723-4979
Innc>v�ally€>4�rrld.ttir,�rps/,5ustarrarat�le:Results Phone:
February 26, 2019
Mr. Thomas J. Henderson,Assistant Director of Airports E
Key West International Airport and The Florida Keys Marathon International Airport
3491 S. Roosevelt Blvd.
Key West, FL 33040
0
�s
Re: The Florida Keys Marathon International Airport
Rental Car Wash Facility
a.
Project Bid Tabulation/Recommendation of Award
LO
Dear Mr. Henderson,
Project bids for the Marathon Airport Car Wash Facility were opened on October 31,°2018 at 3 pm in the
Monroe County Purchasing Department office located in the Gato Government Building, Key West,
Florida. Two bids were received from D.L. Porter Constructors, Inc. and Pedro Falcon Contractors, Inc.
D.L. Porter Constructors, Inc. was the lowest responsive bidder at a total project cost of$1,318,000 per U)
the attached bid tab. During coordination to award the project, the Airport and Airport's engineer 3 1
(McFarland Johnson) conducted a series of Value Engineering (VE) discussions and reviews of the
project with the low bid contractor(D.L. Porter Constructors)in an effort to reduce project costs to better
align with available grant funding for the project. Subsequent to this coordination and resulting VE
revisions, it is our recommendation that the project be awarded to the low bid contractor, D.L. Porter (3
Constructors, Inc., 6574 Palmer Park Circle, Sarasota, FL 34238, at a reduced VE project cost of
$1,176,743.
0
c�
In accordance with the project specification, bids can be retained for up to 120 days, during which the U)
VE effort was conducted. r
0
Should you have any questions regarding the above, please do not hesitate to contact the undersigned.
IL
Sincerely,
McFarland-Johnson, Inc.
Michael A. Eckhardt, P.E.
Project Engineer
meckhardt@miir7c.com
Enclosures
ummuuum imp uumuo mmimm umm um mmmmmmummummp�uimrmm�i uuuuu immm uuuu � iu min
100%Employee Owned(.,orrip any Packet Pg. 762
(sio;onj suoo aO -iag MAM '1'3 4seM a D HJLW 'Oral 6siopm suoD aO -ia wewtioeuv
co
to
T ti
CM
ci a
m
d
a
s
}
r }
� N
N c
L 4
m O
D O O $ �W
O O 0 � u w=
C) 0 s s 'u
Q 0 u ¢
cl
co L. �
t
. I r-i d >
o�
r
H
O �T„ m
}
� z m x � L. 4) >
Z �
i a � z o
CL o � a
Z IR
WON V p U) � ti 3
f•• " a `" a z
W N J W d c t
= Q m 0 U N
O
OLU
CL
-�
�y N
W H Q v d
aU c 0
G tA
i L
t
Z O u
�
o d
L L L C
C W Z U w },m o °u v
O J m
m Z to O (A) o el N
H ap o U ti } rL
n g
Ln U c 2 c O
v LU
°u
t
O 4
} U Q
OL 0 d S O H
v 0-
0-
4-
4- Co
w o o
O U U- 41
LL A V- C
u E O
no v N m
C.31.a
Florida Keys Marathon International Airport 08/18
Monroe County
Rental Car Wash Facility
Florida DOT Project Number GOG88 -Monroe County Project: GAMD78
0
U
0
0
IL
LO
a� A
U
0
0
0
IL
4i
ca
�E
3
CONTRACT II-1
Packet Pg. 764
C.31.a
Florida Keys Marathon International Airport 08/18
Monroe County
Rental Car Wash Facility
Florida DOT Project Number GOG88 -Monroe County Project: GAMD78
C T I
ACKNOWLEDGMENT CHANGE ORDERS
TO: Monroe County Board of Commissioners
Key West, Florida
U
r
0
�s
E : Rental Car Wash Facility
0
Florida Keys Marathon International Airport
Gentlemen: `O
In order to avoid the necessity of extensive amendments to the referred contract, the
undersigned acknowledges hereby that the following conditions are those for which
change orders are allowed under the Bid Law:
1 . Unusual and difficult circumstances which arose during the course of the
execution of the contract which could not have been reasonably foreseen.
2. Where competitive bidding for the new work for new money will work to the
serious detriment of the awarding authority.
3. Emergencies arising during the course of the work.
0
4. Changes or alterations provided for in the original bid and originals contract
0
�s
0
D. L. Porter Constructors,Inc.
Contractor
o een castagna
Title: Corporate Secretary
CONTRACT II-2
Packet Pg. 765
C.31.a
Florida Keys Marathon International Airport 08/18
Monroe County
Rental Car Wash Facility
Florida DOT Project Number GOG88 -Monroe County Project: GAMD78
0
r
0
0
eO
INTENTIONALLY LEFT BLANK
a�
�i
t
0
x
k
CONTRACT II-3
Packet Pg. 766
C.31.a
Florida Keys Marathon International Airport 08/18
Monroe County
Rental Car Wash Facility
Florida DOT Project Number GOG88 -Monroe County Project: GAMD78
S E C T I O N D
CONTRACT
Rental Car Wash Facility
0
Florida Keys Marathon International Airport
U)
0
THIS AGREEMENT made and entered into the day of
by and between D.L. Porter Constructors, Inc., Contractor, and the Monroe County Board of
Commissioners, Key West, Florida, Owner.
WITNESSETH: LO
That the Contractor, for the consideration hereinafter fully set out hereby agrees with the _
Owner as follows:
1. That the Contractor, shall furnish all the materials, and perform all of the work in
the manner and form as provided by the following enumerated documents;
Instruction to Bidders, Form of Proposal, General Provisions, Special Provisions,
Technical Specifications, Form of Contract, Form of Bond, Drawings and
Addenda, which are made a part hereof, as if fully contained herein, for the i
construction of:
Rental Car Wash Facility
Florida Keys Marathon International Airport
Monroe County, Florida
2. That the Contractor shall commence the work to be performed under this
agreement on a date to be specified in a written order of the Owner and shall
fully complete all work hereunder within two hundred seventy(270) calendar days
from the Notice-to-Proceed (Construction) as per Special Provision No. 2.
3. The Owner hereby agrees to pay to the Contractor for the faithful performance of
the agreement, subject to additions and deductions as provided in the
specifications or proposal in lawful money of the United States as follows: Ey
Approximately One Million One Hundred Seventy-Six Thousand Seven
Hundred Forty-Three Dollars ($1,176,743.00) in accordance with lump sum and
unit prices set forth in the proposal.
4. On or before the 15th day of each calendar month, the second party shall make
partial payment to the Contractor on the basis of a duly certified and approved
estimate of work performed during the preceding calendar month by the
Contractor, less ten percent (10%) of the amount of such estimate which is to be
CONTRACT II-4
Packet Pg. 767
C.31.a
Florida Keys Marathon International Airport 08/18
Monroe County
Rental Car Wash Facility
Florida DOT Project Number GOG88 -Monroe County Project: GAMD78
retained by the Owner until all work has been performed strictly in accordance
with this agreement.
5. Upon submission by the Contractor of evidence satisfactory to the Owner that all
payrolls, material bills and other costs incurred by the Contractor in connection
with the construction of the work have been paid in full, final payment on account of
this agreement shall be made within twenty (20) days after the completion by the
Contractor of all work covered by this agreement and the acceptance of such work
by the Owner. 0
6. It is mutually agreed between the parties hereto that time is of the essence in this
contract and in the event the construction of the work is not completed within the
time herein specified, it is agreed that from the compensation otherwise to be
paid to the Contractor, the Owner may retain the amounts described in the LO
Liquidated Damages, Special Provision No. 3, per day for each day thereafter,
Sundays and holidays included, that the work remains uncompleted, which sum
shall represent the actual damages which the Owner will have sustained per day by
failure of the Contractor to complete the work within the time stipulated and this
sum is not a penalty being the stipulated damages the Owner will have
sustained in the event of such default by the Contractor.
U)
7. It is further mutually agreed between the parties hereto that if at any time after
the execution of this agreement and the surety bond hereto attached for its
faithful performance, the Owner shall deem the surety or sureties upon such
bond to be unsatisfactory, or if, for any reason, such bond ceases to be adequate R
to cover the performance of the work, the Contractor shall, at its expense within
five (5) days after the receipt of notice from the Owner so to do, furnish an
additional bond or bonds in such form and amount and with such surety or }
sureties as shall be satisfactory to the Owner. In such event, no further payment
to the Contractor shall be deemed to be due under this agreement until such new
or additional security for the faithful performance of the work shall be furnished in
manner and form satisfactory to the Owner.
8. MAINTENANCE OF RECORDS: Contractor shall maintain all books, records and
documents directly pertinent to performance under this Agreement in accordance
with generally accepted accounting principles consistently applied. Each party to
this Agreement or their authorized representatives shall have reasonable and
timely access to such records of each other party to this Agreement for public
records purposes during the term of the Agreement and for four years following
the termination of this Agreement. If an auditor employed by the County or Clerk
determines that monies paid to Contractor pursuant to this Agreement were
spent for purposes not authorized by this Agreement, the Contractor shall repay
the monies together with interest calculated pursuant to Sec. 55,03, Florida
Statutes, running from the date the monies were paid to Contractor.
9. PUBLIC ACCESS. Public Records Compliance. Contractor must comply with
Florida public records laws, including but not limited to Chapter 119, Florida
Statutes and Section 24 of article I of the Constitution of Florida. The County and
CONTRACT II-5 1
Packet Pg. i 8
C.31.a
Florida Keys Marathon International Airport 08/18
Monroe County
Rental Car Wash Facility
Florida DOT Project Number GOG88 -Monroe County Project: GAMD78
Contractor shall allow and permit reasonable access to, and inspection of, all
documents, records, papers, letters or other "public record" materials in its
possession or under its control subject to the provisions of Chapter 119, Florida
Statutes, and made or received by the County and Contractor in conjunction with
this contract and related to contract performance. The County shall have the right
to unilaterally cancel this contract upon violation of this provision by the Contractor.
Failure of the Contractor to abide by the terms of this provision shall be deemed a
material breach of this contract and the County may enforce the terms of this
provision in the form of a court proceeding and shall, as a prevailing party, be U
entitled to reimbursement of all attorney's fees and costs associated with that 0
proceeding. This provision shall survive any termination or expiration of the
contract.
0
a.
The Contractor is encouraged to consult with its advisors about Florida Public
Records Law in order to comply with this provision. LO
Pursuant to F.S. 119.0701 and the terms and conditions of this contract, the
Contractor is required to:
(1) Keep and maintain public records that would be required by the County to
perform the service.
U
(2) Upon receipt from the County's custodian of records, provide the County with
a copy of the requested records or allow the records to be inspected or copied
within a reasonable time at a cost that does not exceed the cost provided in this
chapter or as otherwise provided by law.
� R
(3) Ensure that public records that are exempt or confidential and exempt from
public records disclosure requirements are not disclosed except as authorized by
law for the duration of the contract term and following completion of the contract if
0
the contractor does not transfer the records to the County.
U
r
(4) Upon completion of the contract, transfer, at no cost, to the County all public
records in possession of the Contractor or keep and maintain public records that
would be required by the County to perform the service. If the Contractor transfers
all public records to the County upon completion of the contract, the Contractor a.
shall destroy any duplicate public records that are exempt or confidential and
exempt from public records disclosure requirements. If the Contractor keeps and
maintains public records upon completion of the contract, the Contractor shall meet
all applicable requirements for retaining public records. All records stored
electronically must be provided to the County, upon request from the County's
custodian of records, in a format that is compatible with the information technology
systems of the County.
(5) A request to inspect or copy public records relating to a County contract must
be made directly to the County, but if the County does not possess the requested
records, the County shall immediately notify the Contractor of the request, and the
Contractor must provide the records to the County or allow the records to be
inspected or copied within a reasonable time.
CONTRACT II-6
Packet Pg. 769
C.31.a
Florida Keys Marathon International Airport 08/18
Monroe County
Rental Car Wash Facility
Florida DOT Project Number GOG88 -Monroe County Project: GAMD78
IF THE CONTRACTOR HAS QUESTIONS REGARDING THE APPLICATION OF
CHAPTER 119, FLORIDA STATUTES, TO THE CONTRACTOR'S DUTY TO
PROVIDE PUBLIC RECORDS RELATING TO THIS CONTRACT, CONTACT THE
CUSTODIAN OF PUBLIC RECORDS, BRIAN BRADLEY, AT (305) 292-3470.
0
c�
10. HOLD HARMLESS AND INSURANCE: Notwithstanding any minimum
insurance requirements prescribed elsewhere in this agreement, 0
Contractor shall defend, indemnify and hold the County and the County's
elected and appointed officers and employees harmless from and against (i)
any claims, actions or causes of action, (ii) any litigation, administrative a.
proceedings, appellate proceedings, or other proceedings relating to any
type of injury (including death), loss, damage, fine, penalty or business LO
interruption, and (iii) any costs or expenses (including, without limitation,
costs of remediation and costs of additional security measures that the
Federal Aviation Administration , the Transportation
Security Administration or any other governmental agency requires
by reason of, or in connection with a violation of any federal law or
regulation, attorneys' fees and costs, court costs, fines and penalties) that
may be asserted against, initiated with respect to, or sustained by,
any indemnified party by reason of, or in connection with, (A) any
activity of Contractor or any of its employees, agents, contractors or
other invitees on the Airport during the term of this Agreement, (B) the
negligence or willful misconduct of Contractor or any of its
employees, agents, contractors or other invitees, or (C) Contractor's default in
respect of any of the obligations that it undertakes under the terms of this
Agreement, except to the extent the claims, actions, causes of action,
litigation, proceedings, costs or expenses arise from the intentional or
sole negligent acts or omissions of the County or any of its employees,
agents, contractors or invitees (other than CONTRACTOR). Insofar as the U)
claims, actions, causes of action, litigation, proceedings, costs or
expenses relate to events or circumstances that occur during the term of
this Agreement, this section will survive the expiration of the term of this
Agreement or any earlier termination of this Agreement. a.
In the event the completion of the project (including the work of others) is delayed
or suspended as a result of the Contractor's failure to purchase or maintain the
required insurance, the Contractor shall indemnify the County from
any and all increased expenses resulting from such delay.
The first ten ($10.00) of remuneration paid to the Contractor is for the
indemnification provided for above. j
3`
The extent of liability is in no way limited to, reduced, or lessened by the
insurance requirements contained elsewhere within this agreement.
CERTIFICATES OF INSURANCE. Original Certificates of Insurance shall be
CONTRACT II-7
Packet Pg. 770
C.31.a
Florida Keys Marathon International Airport 08/18
Monroe County
Rental Car Wash Facility
Florida DOT Project Number GOG88 -Monroe County Project: GAMD78
provided to the COUNTY at the time of execution of this Agreement and certified
copies provided if requested. Each policy certificate shall be endorsed with a
provision that not less than thirty (30) calendar days' written notice shall be
provided to the COUNTY before any policy or coverage is canceled or restricted.
The underwriter of such insurance shall be qualified to do business in the State
of Florida. If requested by the County Administrator, the insurance coverage shall
be primary insurance with respect to the COUNTY, its officials, employees,
agents and volunteers. Failure of CONTRACTOR to comply with the
requirements of this section shall be cause for immediate termination of this U
agreement. 0
10. NON-WAIVER OF IMMUNITY: Notwithstanding the provisions of Sec. 768.28,
Florida Statutes, the participation of COUNTY and CONTRACTOR in this
Agreement and the acquisition of any commercial liability insurance coverage, self-
insurance coverage, or local government liability insurance pool coverage shall LO
not be deemed a waiver of immunity to the extent of liability coverage, nor shall
any Agreement entered into by the COUNTY be required to contain any provision
for waiver.
11. NO PLEDGE OF CREDIT: CONTRACTOR shall not pledge the COUNTY'S
credit or make it a guarantor of payment or surety for any contract, debt,
obligation, judgment, lien, or any form of indebtedness. CONTRACTOR further
warrants and represents that it has no obligation or indebtedness that would
impair its ability to fulfill the terms of this contract.
12. NOTICE REQUIREMENT: Any notice required or permitted under this
agreement shall be in writing and hand delivered or mailed, postage prepaid, to
the other party by certified mail, returned receipt requested, to the following:
0
FOR COUNTY:
Director of Airports County Attorney's Office
3491 South Roosevelt Blvd. and 1111 12th St., Suite 408
Key West, Florida 33040 Key West, FI. 33040
FOR CONTRACTOR: i
D.L. Porter Constructors, Inc
6574 Palmer Park Circle
Sarasota, FL 34238
a
13. GOVERNING LAW, VENUE, AND INTERPRETATION: This Agreement shall be
governed by and construed in accordance with the laws of the State of Florida
applicable to Agreements made and to be performed entirely in the State. In the
event that any cause of action or administrative proceeding is instituted for the
enforcement or interpretation of this Agreement, the COUNTY and
CONTRACTOR agree that venue will lie in the appropriate court or before the
CONTRACT II-8
Packet Pg. 771
C.31.a
Florida Keys Marathon International Airport 08/18
Monroe County
Rental Car Wash Facility
Florida DOT Project Number GOG88 -Monroe County Project: GAMD78
appropriate administrative body in Monroe COUNTY, Florida.
14. MEDIATION: The COUNTY and CONTRACTOR agree that, in the event of
conflicting interpretations of the terms or a term of this Agreement by or between
any of them the issue shall be submitted to mediation prior to the institution of
any other administrative or legal proceeding. Mediation proceedings initiated and
conducted pursuant to this Agreement shall be in accordance with the Florida
Rules of Civil Procedure and usual and customary procedures required by the E
circuit court of Monroe County.
0
15. SEVERABILITY: If any term, covenant, condition or provision of this Agreement
(or the application thereof to any circumstance or person) shall be declared
invalid or unenforceable to any extent by a court of competent jurisdiction, the
remaining terms, covenants, conditions and provisions of this Agreement, shall
not be affected thereby; and each remaining term, covenant, condition and LO
provision of this Agreement shall be valid and shall be enforceable to the fullest
extent permitted by law unless the enforcement of the remaining terms,
covenants, conditions and provisions of this Agreement would prevent the
accomplishment of the original intent of this Agreement. The COUNTY and
CONTRACTOR agree to reform the Agreement to replace any stricken provision
with a valid provision that comes as close as possible to the intent of the stricken
� a
provision.
16. ATTORNEY'S FEES AND COSTS: COUNTY and CONTRACTOR agree that in
the event any cause of action or administrative proceeding is initiated or
defended by any party relative to the enforcement or interpretation of this
Agreement, the prevailing party shall be entitled to reasonable attorney's fees
and attorney's fees, in appellate proceedings. Each party agrees to pay its own
court costs, investigative, and out-of-pocket expenses whether it is the prevailing
party or not, through all levels of the court system.
E
17. ADJUDICATION OF DISPUTES OR DISAGREEMENTS: COUNTY and
CONTRACTOR agree that all disputes and disagreements shall be attempted to be �s
resolved by meet and confer sessions between representatives of each of
COUNTY and CONTRACTOR. If no resolution can be agreed upon within 30
a.
days after the first meet and confer session, the issue or issues shall be
discussed at a public meeting of the Board of County Commissioners. If the
issue or issues are still not resolved to the satisfaction of COUNTY and
CONTRACTOR, then any party shall have the right to seek such relief or remedy
as may be provided by this Agreement or by Florida law.
18. COOPERATION: In the event any administrative or legal proceeding is instituted
against either party relating to the formation, execution, performance, or breach
of this Agreement, COUNTY and CONTRACTOR agree to participate, to the
extent required by the other party, in all proceedings, hearings, processes,
meetings, and other activities related to the substance of this Agreement or
provision of the services under this Agreement. COUNTY and CONTRACTOR
specifically agree that no party to this Agreement shall be required to enter into
any arbitration proceedings related to this Agreement.
CONTRACT II-9
Packet Pg. 772
C.31.a
Florida Keys Marathon International Airport 08/18
Monroe County
Rental Car Wash Facility
Florida DOT Project Number GOG88 -Monroe County Project: GAMD78
19. BINDING EFFECT: The terms, covenants, conditions, and provisions of this
Agreement shall bind and inure to the benefit of COUNTY and CONTRACTOR
and their respective legal representatives, successors, and assigns.
20. AUTHORITY: Each party represents and warrants to the other that the
execution, delivery and performance of this Agreement have been duly
authorized by all necessary County and corporate action, as required by law.
21. PRIVILEGES AND IMMUNITIES: All of the privileges and immunities from
liability, exemptions from laws, ordinances, and rules and pensions and relief,
disability, workers compensation, and other benefits which apply to the activity of
officers, agents, or employees of any public agents or employees of the
COUNTY, when performing their respective functions under this Agreement
within the territorial limits of the COUNTY shall apply to the same degree and
extent to the performance of such functions and duties of such officers, agents, LO
volunteers, or employees outside the territorial limits of the COUNTY.
22. LEGAL OBLIGATIONS AND RESPONSIBILITIES: This Agreement is not 3
intended to, nor shall it be construed as, relieving any participating entity from a
any obligation or responsibility imposed upon the entity by law except to the
extent of actual and timely performance thereof by any participating entity, in
which case the performance may be offered in satisfaction of the obligation or
responsibility. Further, this Agreement is not intended to, nor shall it be
construed as, authorizing the delegation of the constitutional or statutory duties of
the COUNTY, except to the extent permitted by the Florida constitution, state
statute, and case law.
23. NON-RELIANCE BY NON-PARTIES: No person or entity shall be entitled to rely
upon the terms, or any of them, of this Agreement to enforce or attempt to
enforce any third-party claim or entitlement to or benefit of any service or
program contemplated hereunder, and the COUNTY and the CONTRACTOR
agree that neither the COUNTY nor the CONTRACTOR or any agent, officer, or a
employee of either shall have the authority to inform, counsel, or otherwise
indicate that any particular individual or group of individuals, entity or entities, {
have entitlements or benefits under this Agreement separate and apart, inferior
to, or superior to the community in general or for the purposes contemplated in
this Agreement.
x
24. NO PERSONAL LIABILITY: No covenant or agreement contained herein shall
be deemed to be a covenant or agreement of any member, officer, agent or
employee of Monroe County in his or her individual capacity, and no member,
officer, agent or employee of Monroe County shall be liable personally on this
Agreement or be subject to any personal liability or accountability by reason of the
execution of this Agreement.
25. EXECUTION IN COUNTERPARTS: This Agreement may be executed in any i
number of counterparts, each of which shall be regarded as an original, all of which
taken together shall constitute one and the same instrument and COUNTY and
CONTRACTOR hereto may execute this Agreement by signing any such
CONTRACT 11-10
Packet Pg. 773
C.31.a
Florida Keys Marathon International Airport 08/18
Monroe County
Rental Car Wash Facility
Florida DOT Project Number GOG88 -Monroe County Project: GAMD78
counterpart.
26. NON-DISCRIMINATION: Contractor agrees that there will be no discrimination
against any person, and it is expressly understood that upon a determination by a
court of competent jurisdiction that discrimination has occurred, this Agreement
automatically terminates without any further action on the part of any party,
effective the date of the court order. Contractor agrees to comply with all Federal
and Florida statutes, and all local ordinances, as applicable, relating to
nondiscrimination. These include but are not limited to: 1) Title VI of the Civil
Rights Act of 1964 (PL 88-352) which prohibits discrimination on the basis of race, 0
color or national origin; 2) Title IX of the Education Amendment of 1972, as
amended (20 USC ss. 1681-1683, and 1685-1686), which prohibits discrimination
on the basis of sex; 3) Section 504 of the Rehabilitation Act of 1973, as amended a.
(20 USC s. 794), which prohibits discrimination on the basis of handicaps; 4) The
Age Discrimination Act of 1975, as amended (42 USC ss. 6101-6107) which LO
prohibits discrimination on the basis of age; 5) The Drug Abuse Office and
Treatment Act of 1972 (PL 92-255), as amended, relating to nondiscrimination on
the basis of drug abuse; 6) The Comprehensive Alcohol Abuse and Alcoholism
Prevention, Treatment and Rehabilitation Act of 1970 (PL 91-616), as amended,
relating to nondiscrimination on the basis of alcohol abuse or alcoholism; 7) The
Public Health Service Act of 1912, ss. 523 and 527 (42 USC ss. 690dd-3 and
290ee-3), as amended, relating to confidentiality of alcohol and drug abuse patient
records; 8) Title VIII of the Civil Rights Act of 1968 (42 USC s. et seq.), as
amended, relating to nondiscrimination in the sale, rental or financing of housing; 9)
The Americans with Disabilities Act of 1990 (42 USC s. 1201 Note), as maybe
amended from time to time, relating to nondiscrimination on the basis of disability;
10) Monroe County Code Chapter 14, Article II, which prohibits discrimination on
the basis of race, color, sex, religion, national origin, ancestry, sexual orientation,
gender identity or expression, familial status or age; and 11) Any other
nondiscrimination provisions in any Federal or state statutes which may apply to
the parties to, or the subject matter of, this Agreement.
U
0
)
0
i
CONTRACT II-11
Packet Pg. 774
Florida Keys Marathon International Airport 08/18
Monroe County
Rental Car Wash Facility
Florida DOT Project Number GOG88 -Monroe County Project: GAMD78
IN WITNESS WHEREOF the parties hereto have executed this agreement on the day and
to first above written in two (2) counterparts, each of is shall, without proof or accounting
forte other count emed an original contract.
(SEAL) BOARD OF COUNTY COMMISSIONERS
Attest., KEVIN MADOK, Clerk OF MONROE COUNTY, FLORIDA 01
U)
By: By: r-
0
Deputy Clerk Mayor�Chalrrnan U
Date 0
(SEAL) CONTRACTOR, IL
-J
Porter Constructors,Inc. a
Attest: LO
By gigg By:
Print Name�, Kevin Groner Print Name: Colleen
U-
Title:...... Estimator Title: Cor orate Secreta
Date: March 5,2019 Date:, March 5,2019 3:
And:
By:
COUNTY AN 4
Print Name:
Title: PED1401ME ADO 0
ASSISTANT CID
Date: Date. 19
......................................... ........................ .............................................................. U)
0
STATE OF FLORIDA
COUNTY OF SARSOTA
..............................I I............A...................................................................
On this day of Marcm.....-................h 20,.19.......... before me, the undersigned notary public, 0
.............. IL
personally" appearied '�ieen Castagna. known to me to be the person
whose name is subscribed above xrvwkwcxpmrdwita&xxx XW
and acknowledged that he/she is the person who executed-the above contract
with Monroe Count,' for the-purposes herein contained.
E
qttylw
KIM MCGINNIS 1i <
No!ary Public NOTA:R:YPUBW
Kim McGinnis STATFE OF FLONDA
C
NO,GG 208455
Print Name
My commission expires: February24,2023 Seal
CONTRACT 11-12
F Packet Pg. 775
Florida Keys Marathon International Airport 08/18
Monroe County
Rental Car Wash Facility
Florida DOT Project Number GOG88 -Monroe County Project: GAMD78
0
ca
U)
0
0
(L
LO
U-
0
IT
0
INTENTIONALLY LEFT BLANK
U)
0
0
E
CONTRACT 11-13
Packet Pg. 776