Item D3 D.3
t, BOARD OF COUNTY COMMISSIONERS
County of Monroe Mayor Sylvia Murphy,District 5
The Florida Keys l'U � � Mayor Pro Tern Danny Kolhage,District 1
�pw° Michelle Coldiron,District 2
Heather Carruthers,District 3
David Rice,District 4
County Commission Meeting
June 19, 2019
Agenda Item Number: D.3
Agenda Item Summary #5608
BULK ITEM: Yes DEPARTMENT: Project Management
TIME APPROXIMATE: STAFF CONTACT: Steven Sanders (305) 295-4338
N/A
AGENDA ITEM WORDING: Approval to accept proposal and award a contract with A-1
Property Services Group, Inc. in the amount of $91,174.14 for a new roof and roof repairs of the
Sheriffs Marathon Substation. Funded by Hurricane Irma fund sources.
ITEM BACKGROUND: The Sheriff's Marathon substation sustained roof damages from
Hurricane Irma. The roof requires repairs and replacement. Project Management issued a request for
proposals (RFP) to contractors for the roof work. Three (3) proposals were received in response to
the RFP and opened on 5/22/19. Staff recommends that the BOCC award the contract for work to the
lowest responsive, responsible bidder A-1 Property Services Group, Inc. with a proposal of
$91,174.14.
PREVIOUS RELEVANT BOCC ACTION: 6/20/18 - BOCC approved advertisement of any
required solicitations or proposals for repairs, work, or services resulting from damage to County
facilities as a result of Hurricane Irma and authorization to proceed with such repairs, work, and
service.
CONTRACT/AGREEMENT CHANGES:
N/A
STAFF RECOMMENDATION: Approval as stated above.
DOCUMENTATION:
Al Property Services Group Inc. MCSO Marathon substation Contract.docx
A-1 Property Services Group, Inc. proposal Sheriff Marathon substation roof
FINAL BID TAB Marathon Sheriff substation new TPO roof and repairs
FINANCIAL IMPACT:
Effective Date: 6/19/19
Packet Pg. 831
D.3
Expiration Date:
Total Dollar Value of Contract: $91,174.14
Total Cost to County: $11,396.77
Current Year Portion: $91,174.14
Budgeted: Hurricane Irma
Source of Funds: 125 0459110 IRMONREI
CPI:
Indirect Costs:
Estimated Ongoing Costs Not Included in above dollar amounts:
Revenue Producing: No If yes, amount: N/A
Grant: Yes
County Match: 75% Federal, 12/5% State, 12.5% County
Insurance Required: Yes
Additional Details:
Yes
06/19/19 125-0459110 - HURRICANE IRMA $91,174.14
IRMONREI
REVIEWED BY:
Cary Knight Completed 05/31/2019 9:05 AM
Chris Ambrosio Completed 05/31/2019 10:24 AM
Budget and Finance Completed 06/04/2019 3:23 PM
Maria Slavik Completed 06/04/2019 3:25 PM
Kathy Peters Completed 06/04/2019 4:07 PM
Board of County Commissioners Pending 06/19/2019 9:00 AM
Packet Pg. 832
D.3.a
E
a�
Agreement
4-
0
Between Owner and Contractor
4-
0
Where the basis of payment is a STIPULATED SUM
IL
AGREEMENT Made as of June 19, 2019
BETWEEN the Owner: Monroe County Board of County Commissioners
500 Whitehead Street
Key West, Florida 33040 U'
And the Contractor: A-1 Property Services Group Inc.
890 S.W. 69th Avenue
Miami, FL 33144
x
0
For the following Project: MARATHON SHERIFF SUBSTATION NEW TPO ROOF
AND ROOF REPAIRS
Scope of the Work
The Scope of Work shall include, but not be limited to, all work shown and listed in the Project
Documents and Specifications. The Contractor is required to provide a complete job as
contemplated by the documents and specifications, which are a part of this bid package. The
Contractor shall furnish all labor, supervision, materials, power, tools, equipment, supplies, U'
permits and any other means of construction necessary or proper for performing and completing U)
the Scope of Work, unless otherwise specifically stated.
Marathon Sheriff Substation Building NEW TPO Flat Roof and Clay Tile Roof Repairs:
• Replace all new TPO roof to match existing roof.
• Replace or repair any damaged subsurface as needed in kind before installing
the new TPO roof. Caulk and seal the entire roof and openings with Advanced
Sealant Caulk Polymer sealant.
• Provide engineering necessary to permit the work. Permit fees are included in
the bid.
• Contractor shall furnish the owner a fifteen (15) year no dollar limit total system
warranty covering the cost of repairing leaks as a direct result of either defect in U)
the material or the workmanship involved in its installation for the new TPO flat 2
roof.
• Repair all damaged clay tiles to match the existing clay tiles.
ARTICLE 1
The Contract Documents
The Contract Documents consist of this Agreement, Conditions of the Contract (General,
Supplementary and other Conditions), Documents, Specifications, Proposal Documents,
Addenda issued prior to execution of this Agreement, together with the response to Request for
AGREEMENT 00500- Page 1 of 23
Packet Pg. 833
D.3.a
Proposals (RFP) and all required insurance documentation, and Modifications issued after
execution of this Agreement. The Contract represents the entire and integrated agreement
between the parties hereto and supersedes prior negotiations, representations or agreements,
either written or oral. An enumeration of the Contract Documents, other than Modifications,
appears in Article 9. In the event of a discrepancy between the documents, precedence shall be
determined by the order of the documents as just listed.
0
0
ARTICLE 2
The Work of this Contract a.
The Contractor shall execute the entire Work described in the Contract Documents, except to
the extent specifically indicated in the Contract Documents to be the responsibility of others, or
as follows: N/A
ARTICLE 3
Date of Commencement and Substantial Completion U'
3.1 The date of commencement is the date to be fixed in a notice to proceed issued by the
Owner.
The Contractor shall achieve Substantial Completion of the entire Work not later than
Forty Five (45) calendar days after the date of commencement or issuance of a Notice
to Proceed. The time or times stipulated in the contract for completion of the work of the
contract or of specified phases of the contract shall be the calendar date or dates listed
in the milestone schedule.
Liquidated damages will be based on the Substantial Completion Date for all work, 0
modified by all approved extensions in time as set forth by the Director of Project
Management's signature of approval on the Certificate of Substantial Completion. The
liquidated damages table below shall be utilized to determine the amount of liquidated
damages.
U)
FIRST SECOND 31ST DAY &
CONTRACT AMOUNT 15 DAYS 15 DAYS THEREAFTER
Under $50,000.00 $50.00/Day $100.00/Day $250.00/Day
$50,000.00-99,999.00 100.00/Day 200.00/Day 750.00/Day
$100,000.00-499,999.00 200.00/Day 500.00/Day 2,000.00/Day
$500,000.00 and Up 500.00/Day 1,000.00/Day 3,500.00/Day
The Contractor's recovery of damages and sole remedy for any delay caused by the
Owner shall be an extension of time on the Contract.
ARTICLE 4
Contract Sum
U)
0
4.1 The owner shall pay the Contractor in current funds for the Contractor's performance of
the Contract the Contract Sum of Ninety One Thousand One Hundred Seventy Four
Dollars and Fourteen Cents. ($91,174.14) subject to additions and deductions as
provided in the Contract Documents.
4.2 The Contract Sum is based upon the following alternates, if an which are described in
p g Y�
the Contract Documents and are hereby accepted by the Owner:
AGREEMENT 00500- Page 2 of 23
Packet Pg. 834
D.3.a
Alternate # 1: No Alternates Specified
4.3 Unit prices, if any, are as follows: N/A.
0
0
ARTICLE 5
Progress Payments
0
5.1 Based upon Applications for Payment submitted by the Contractor to the Director of
Project Management, and upon approval for payment issued by the Director of Project a.
Management and Architect, the Owner shall make progress payments on account of the
Contract Sum to the contractor as provided below and elsewhere in the Contract z
Documents.
5.2 The period covered by each Application for payment shall be one (1) calendar month
ending on the last day of the month, or as follows:
5.3 Payment will be made by the Owner in accordance with the Florida Local Government
Prompt Payment Act, Section 218.735, Florida Statutes.
5.4 Each Application for Payment shall be based upon the Schedule of Values submitted by
the Contractor in accordance with the Contract Documents. The Schedule of Values
shall allocate the entire Contract Sum among the various portions of the Work and be
prepared in such form and supported by such data to substantiate its accuracy as the
Director of Project Management may require. This schedule, unless objected to by the
Director of Project Management, shall be used as a basis for reviewing the Contractor's
Applications for Payment.
5.5 Applications for Payment shall indicate the percentage of completion of each portion of U)
the Work as of the end of the period covered by the Application for Payment.
r-
5.6 Subject to the provisions of the Contract Documents, the amount of each progress
payment shall be computed as follows:
5.6.1 Take that portion of the Contract Sum properly allocable to completed Work as
determined by multiplying the percentage completion of each portion of the Work by the
share of the total Contract Sum allocated to that portion of the Work in the Schedule of
Values, less retainage of ten percent 10%. Pending final determination of cost to the
Owner of changes in the Work, amounts not in dispute may be included in Applications
for Payment. The amount of credit to be allowed by the Contractor to the Owner for a
deletion or change which results in a net decrease in the Contract Sum shall be the net
cost to the Owner, less Overhead, Profit and Documented Costs incurred prior to the
change Request, as indicated in the corresponding line item in the Approved Schedule >
of Values for that line item as confirmed by the Director of Project Management. When
both additions and credits covering related Work or substitutions are involved in a
change, the allowance for overhead and profit shall be figured on the basis of net
increase, if any, with respect to that change.
a.
Ir-
5.6.2 Add that portion of the Contract Sum properly allocable to materials and equipment
delivered and suitably stored at the site for subsequent incorporation in the completed
AGREEMENT 00500- Page 3 of 23
Packet Pg. 835
D.3.a
construction (or, if approved in advance by the Owner, suitably stored off the site at a
location agreed upon in writing), less retainage;
4-
0
5.6.3 Subtract the aggregate of previous payments made by the Owner; and
5.6.4 Subtract amounts, if any, for which the Director of Project Management has withheld or
nullified a Certificate for Payment as provided in Paragraph 9.5 of the General
Conditions.
a.
5.7 Retainage of ten percent (10%) will be withheld in accordance with Section 218.735
(8)(b), Florida Statutes.
5.8 Reduction or limitation of retainage, if any, shall be as follows:
Monroe County is exempt from and not subject to Florida Statutes, Section 255.078,
"Public Construction Retainage". Reduction or limitation of retainage, if any, shall be
reduced incrementally at the discretion of and upon the approval of the Director of
Project Management.
ARTICLE 6
Final Payment
x
0
Final payment, constituting the entire unpaid balance of the Contract Sum, shall be made by the
Owner to the Contractor when (1) the Contract has been fully performed by the Contractor
except for the Contractor's responsibility to correct nonconforming Work as provided in
Subparagraph 12.2.2 of the General Conditions and to satisfy other requirements, if any, which 0
necessarily survive final payment, and (2) a final approval for payment has been issued by the
Director of Project Management. Such final payment shall be made by the Owner not more
than twenty (20) days after the issuance of the final approval for payment. The following
documents (samples in section 01027, Application for Payment) are required for Final Payment:
U)
(1) Application and Certificate for Payment
(2) Continuation Sheet
(3) Certificate of Substantial Completion
(4) Contractor's Affidavit of Debts and Claims
(5) Contractor's Affidavit of Release of Liens
(6) Final Release of Lien
(7) Contractor shall provide two (2) hard copies in tabulated divided binders and
one (1) saved electronically tabbed and indexed in Adobe Acrobat file (.PDF)
format delivered on a common form (i.e. flash drive) of all the following, but
not limited to:
U)
0
A. Project Record Documents (As Built Documents).
B. Operating and maintenance data, instructions to the Owner's personnel.
C. Warranties, bond and guarantees.
0
a.
D. Keys and keying schedule.
E. Spare parts and maintenance materials.
AGREEMENT 00500- Page 4 of 23
Packet Pg. 836
D.3.a
a�
F. Electronic copies of approved submittals.
4-
0
G. Evidence of payment and final release of liens and consent of surety to final
release (includes final release from all utilities and utility companies).
4-
ARTICLE 7
Miscellaneous Provisions
a.
7.1 Where reference is made in this Agreement to a provision of the General Conditions or
another Contract Document, the reference refers to that provision as amended or
supplemented by other provisions of the Contract Documents.
7.2 Payment shall be made according to the Florida Local Government Prompt Payment Act
and Monroe County Code.
7.3 Temporary facilities and services: As described in Section 01500, Temporary Facilities,
of the General Conditions.
7.4 Monroe County's performance and obligation to pay under this contract is contingent
upon an annual appropriation by the Board of County Commissioners.
7.5 A person or affiliate who has been placed on the convicted vendor list following a
conviction for public entity crime may not submit a bid on a contract to provide any
goods or services to a public entity, may not submit a proposal on a contract with a 0
public entity for the construction or repair of a public building or public work, may not
submit proposals on leases of real property to public entity, may not be awarded or
perform work as contractor, supplier, subcontractor, or consultant under a contract with
any public entity, and may not transact business with any public entity in excess of the
threshold amount provided in Section 287.017, for CATEGORY TWO for a period of
thirty-six (36) months from the date of being placed on the convicted vendor list.
By signing this Agreement, Contractor represents that the execution of this Agreement
will not violate the Public Entity Crimes Act (Section 287.133, Florida Statutes). Violation
of this section shall result in termination of this Agreement and recovery of all monies
paid hereto, and may result in debarment from County's competitive procurement
activities.
In addition to the foregoing, Contractor further represents that there has been no
determination, based on an audit, that it or any subcontractor has committed an act
defined by Section 287.133, Florida Statutes, as a "public entity crime" and that it has U)
not been formally charged with committing an act defined as a "public entity crime"
regardless of the amount of money involved or whether Contractor has been placed on
the convicted vendor list.
Contractor will promptly notify the County if it or any subcontractor or Contractor
0
is formally charged with an act defined as a "public entity crime" or has been a.
placed on the convicted vendor list.
7.6 The following items are included in this contract:
AGREEMENT 00500- Page 5 of 23
Packet Pg. 837
D.3.a
a�
a) Maintenance of Records. Contractor shall maintain all books, records, and
documents directly pertinent to performance under this Agreement in accordance
with generally accepted accounting principles consistently applied. Records shall be
retained for a period of five (5) years from the termination of this agreement or for a
period of three (3) years from the submission of the final expenditure report as per 2
C.F.R. §200.333, whichever is greater. Each party to this Agreement or their
authorized representatives shall have reasonable and timely access to such records
of each other party to this Agreement for public records purposes during the term of a.
the Agreement and for five (5) years following the termination of this Agreement. If
an auditor employed by the County or Clerk determines that monies paid to
Contractor pursuant to this Agreement were spent for purposes not authorized by
this Agreement, or were wrongfully retained by the Contractor, the Contractor shall
repay the monies together with interest calculated pursuant to Sec. 55.03, Florida
Statutes, running from the date the monies were paid to Contractor.
b) Governing Law, Venue, Interpretation, Costs, and Fees, This Agreement shall be
governed by and construed in accordance with the laws of the State of Florida
applicable to contracts made and to be performed entirely in the State. In the event
that any cause of action or administrative proceeding is instituted for the enforcement
or interpretation of this Agreement, the County and Contractor agree that venue shall
lie in the appropriate court or before the appropriate administrative body in Monroe
County, Florida. The Parties waive their rights to trial by jury. The County and
Contractor agree that, in the event of conflicting interpretations of the terms or a term
of this Agreement by or between any of them the issue shall be submitted to 0
mediation prior to the institution of any other administrative or legal proceeding.
c) Severability. If any term, covenant, condition or provision of this Agreement (or the
application thereof to any circumstance or person) shall be declared invalid or
unenforceable to any extent by a court of competent jurisdiction, the remaining
terms, covenants, conditions and provisions of this Agreement, shall not be affected
thereby; and each remaining term, covenant, condition and provision of this
Agreement shall be valid and shall be enforceable to the fullest extent permitted by
law unless the enforcement of the remaining terms, covenants, conditions and
provisions of this Agreement would prevent the accomplishment of the original intent
of this Agreement. The County and Contractor agree to reform the Agreement to
replace any stricken provision with a valid provision that comes as close as possible
to the intent of the stricken provision.
0
d) Attorney's Fees and Costs. The County and Contractor agree that in the event any
cause of action or administrative proceeding is initiated or defended by any party U)
relative to the enforcement or interpretation of this Agreement, the prevailing party
shall be entitled to reasonable attorney's fees and court costs as an award against
the non-prevailing party, and shall include attorney's fees and courts costs in
appellate proceedings.
0
e) Binding Effect. The terms, covenants, conditions, and provisions of this Agreement a.
shall bind and inure to the benefit of the County and Contractor and their respective
legal representatives, successors, and assigns.
AGREEMENT 00500- Page 6 of 23
Packet Pg. 838
D.3.a
f) Authority. Each party represents and warrants to the other that the execution,
delivery and performance of this Agreement have been duly authorized by all
necessary County and corporate action, as required by law. Each party agrees that it
has had ample opportunity to submit this Contract to legal counsel of its choice and
enters into this agreement freely, voluntarily and with advice of counsel.
4-
g) Claims for Federal or State Aid. Contractor and County agree that each shall be, and
is, empowered to apply for, seek, and obtain federal and state funds to further the
purpose of this Agreement; provided that all applications, requests, grant proposals, a.
and funding solicitations shall be approved by each party prior to submission.
h) Adjudication of Disputes or Disagreements. County and Contractor agree that all
disputes and disagreements shall be attempted to be resolved by meet and confer 2
sessions between representatives of each of the parties. If the issue or issues are
still not resolved to the satisfaction of the parties, then any party shall have the right
to seek such relief or remedy as may be provided by this Agreement or by Florida
law. This Agreement is not subject to arbitration.
i) Cooperation. In the event any administrative or legal proceeding is instituted against
either party relating to the formation, execution, performance, or breach of this
Agreement, County and Contractor agree to participate, to the extent required by the
other party, in all proceedings, hearings, processes, meetings, and other activities
related to the substance of this Agreement or provision of the services under this
Agreement. County and Contractor specifically agree that no party to this
Agreement shall be required to enter into any arbitration proceedings related to this 0
Agreement.
j) Nondiscrimination. The parties agree that there will be no discrimination against any
person, and it is expressly understood that upon a determination by a court of
competent jurisdiction that discrimination has occurred, this Agreement automatically
terminates without any further action on the part of any party, effective the date of the
court order. The parties agree to comply with all Federal and Florida statutes, and all
local ordinances, as applicable, relating to nondiscrimination. These include but are
not limited to: 1) Title VII of the Civil Rights Act of 1964 (PL 88-352), which prohibits
discrimination in employment on the basis of race, color, religion, sex, and national
origin; 2) Title IX of the Education Amendment of 1972, as amended (20 USC
§§ 1681-1683, and 1685-1686), which prohibits discrimination on the basis of sex;
3) Section 504 of the Rehabilitation Act of 1973, as amended (20 USC § 794), which
prohibits discrimination on the basis of handicaps; 4) The Age Discrimination Act of
1975, as amended (42 USC §§ 6101-6107), which prohibits discrimination on the
basis of age; 5) The Drug Abuse Office and Treatment Act of 1972 (PL 92-255), as U)
amended, relating to nondiscrimination on the basis of drug abuse; 6) The
Comprehensive Alcohol Abuse and Alcoholism Prevention, Treatment and
Rehabilitation Act of 1970 (PL 91-616), as amended, relating to nondiscrimination on
the basis of alcohol abuse or alcoholism; 7) The Public Health Service Act of 1912,
§§ 523 and 527 (42 USC §§ 690dd-3 and 290ee-3), as amended, relating to
0
confidentiality of alcohol and drug abuse patent records; 8) Title VIII of the Civil a.
Rights Act of 1968 (42 USC §§ 3601 et seq.), as amended, relating to
nondiscrimination in the sale, rental or financing of housing; 9) The Americans with
Disabilities Act of 1990 (42 USC §§ 12101), as amended from time to time, relating
AGREEMENT 00500- Page 7 of 23
Packet Pg. 839
D.3.a
to nondiscrimination in employment on the basis of disability; 10) Monroe County
Code Chapter 14, Article II, which prohibits discrimination on the basis of race, color,
sex, religion, national origin, ancestry, sexual orientation, gender identity or
expression, familial status or age; and 11) any other nondiscrimination provisions in
any federal or state statutes which may apply to the parties to, or the subject matter
of, this Agreement.
0
0
During the performance of this Agreement, the CONTRACTOR, in accordance with
Equal Employment Opportunity(30 Fed. Reg. 12319, 12935, 3 C.F.R. Part, 1964-1965 a.
Comp., p. 339), as amended by Executive Order 11375, Amending Executive Order
11246 Relating to Equal Employment Opportunity, and implementing regulations at
41C.F.R. Part 60 (Office of Federal Contract Compliance Programs, Equal
Employment Opportunity, Department of Labor). See 2 C.F.R. Part 200, Appendix II, ¶
C, agrees as follows: U)
1) The contractor will not discriminate against any employee or applicant for
employment because of race, color, religion, sex, sexual orientation, gender
identity, or national origin. The contractor will take affirmative action to ensure
that applicants are employed, and that employees are treated during
employment, without regard to their race, color, religion, sex, sexual
orientation, gender identity, or national origin. Such action shall include, but
0
not be limited to the following: Employment, upgrading, demotion, or transfer,
recruitment or recruitment advertising; layoff or termination; rates of pay or
other forms of compensation; and selection for training, including
apprenticeship. The contractor agrees to post in conspicuous places,
available to employees and applicants for employment, notices to be
provided by the contracting officer setting forth the provisions of this
nondiscrimination clause. U)
U)
2) The contractor will, in all solicitations or advertisements for employees placed
by or on behalf of the contractor, state that all qualified applicants will receive
consideration for employment without regard to race, color, religion, sex,
sexual orientation, gender identity, or national origin.
3) The contractor will not discharge or in any other manner discriminate against
any employee or applicant for employment because such employee or
applicant has inquired about, discussed, or disclosed the compensation of the
employee or applicant or another employee or applicant. This provision shall
not apply to instances in which an employee who has access to the
compensation information of other employees or applicants as a part of such 0
employee's essential job functions discloses the compensation of such other
employees or applicants to individuals who do not otherwise have access to
such information, unless such disclosure is in response to a formal complaint
or charge, in furtherance of an investigation, proceeding, hearing, or action,
including an investigation conducted by the employer, or is consistent with
the contractor's legal duty to furnish information. a.
4) The contractor will send to each labor union or representative of workers with
AGREEMENT 00500- Page 8 of 23
Packet Pg. 840
D.3.a
which it has a collective bargaining agreement or other contract or
understanding, a notice to be provided by the agency contracting officer,
advising the labor union or workers' representative of the contractor's
commitments under section 202 of Executive Order 11246 of September 24,
1965, and shall post copies of the notice in conspicuous places available to
employees and applicants for employment.
0
0
5) The contractor will comply with all provisions of Executive Order 11246 of
a.
September 24, 1965, and of the rules, regulations, and relevant orders of the
Secretary of Labor.
6) The contractor will furnish all information and reports required by Executive
Order 11246 of September 24, 1965, and by the rules, regulations, and
orders of the Secretary of Labor, or pursuant thereto, and will permit access
to his books, records, and accounts by the contracting agency and the
Secretary of Labor for purposes of investigation to ascertain compliance with
such rules, regulations, and orders.
7) In the event of the contractor's non-compliance with the nondiscrimination 0
clauses of this contract or with any of such rules, regulations, or orders, this
contract may be canceled, terminated or suspended in whole or in part and
the contractor may be declared ineligible for further Government contracts or
federally assisted construction contracts in accordance with procedures 0
authorized in Executive Order 11246 of September 24, 1965, and such other
sanctions may be imposed and remedies invoked as provided in Executive
Order 11246 of September 24, 1965, or by rule, regulation, or order of the
Secretary of Labor, or as otherwise provided by law.
U)
8) The Contractor will include the portion of the sentence immediately preceding
paragraph (1) and the provisions of paragraphs (1) through (8) in every
subcontract or purchase order unless exempted by rules, regulations, or
orders of the Secretary of Labor issued pursuant to section 204 of Executive
Order 11246 of September 24, 1965, so that such provisions will be binding
upon each subcontractor or vendor. The Contractor will take such action with
respect to any subcontract or purchase order as the administering agency
may direct as a means of enforcing such provisions, including sanctions for
non-compliance; provided, however, that in the event a contractor becomes
involved in, or is threatened with, litigation with a subcontractor or vendor as
a result of such direction by the administering agency the contractor may U)
request the United States to enter into such litigation to protect the interests
of the United States.
k) Covenant of No Interest. County and Contractor covenant that neither presently has
any interest, and shall not acquire any interest, which would conflict in any manner or
degree with its performance under this Agreement, and that only interest of each is a.
to perform and receive benefits as recited in this Agreement.
AGREEMENT 00500- Page 9 of 23
Packet Pg. 841
D.3.a
1) Code of Ethics. County agrees that officers and employees of the County recognize
and will be required to comply with the standards of conduct for public officers and
employees as delineated in Section 112.313, Florida Statutes, regarding, but not
limited to, solicitation or acceptance of gifts; doing business with one's agency;
unauthorized compensation; misuse of public position, conflicting employment or
contractual relationship; and disclosure or use of certain information.
0
0
m) No Solicitation/Payment. The County and Contractor warrant that, in respect to
itself, it has neither employed nor retained any company or person, other than a a.
bona fide employee working solely for it, to solicit or secure this Agreement and that
it has not paid or agreed to pay any person, company, corporation, individual, or firm,
other than a bona fide employee working solely for it, any fee, commission,
percentage, gift, or other consideration contingent upon or resulting from the award
or making of this Agreement. For the breach or violation of the provision, the
Contractor agrees that the County shall have the right to terminate this Agreement
without liability and, at its discretion, to offset from monies owed, or otherwise
recover, the full amount of such fee, commission, percentage, gift, or consideration.
n) Public Access.
Public Records Compliance. Contractor must comply with Florida public records
laws, including but not limited to Chapter 119, Florida Statutes and Section 24 of
article I of the Constitution of Florida. The County and Contractor shall allow and
permit reasonable access to, and inspection of, all documents, records, papers,
letters or other "public record" materials in its possession or under its control subject
to the provisions of Chapter 119, Florida Statutes, and made or received by the 0
County and Contractor in conjunction with this contract and related to contract
performance. The County shall have the right to unilaterally cancel this contract
upon violation of this provision by the Contractor. Failure of the Contractor to abide
by the terms of this provision shall be deemed a material breach of this contract and
the County may enforce the terms of this provision in the form of a court proceeding
and shall, as a prevailing party, be entitled to reimbursement of all attorney's fees
and costs associated with that proceeding. This provision shall survive any
termination or expiration of the contract.
The Contractor is encouraged to consult with its advisors about Florida Public Records
Law in order to comply with this provision.
Pursuant to Fla. Stat., Sec. 119.0701 and the terms and conditions of this contract, the
Contractor is required to:
0
(1) Keep and maintain public records that would be required by the County to
perform the service. U)
(2) Upon receipt from the County's custodian of records, provide the County
with a copy of the requested records or allow the records to be inspected or
copied within a reasonable time at a cost that does not exceed the cost
provided in this chapter or as otherwise provided by law.
a.
(3) Ensure that public records that are exempt or confidential and exempt from
public records disclosure requirements are not disclosed except as
authorized by law for the duration of the contract term and following
AGREEMENT 00500- Page 10 of 23
Packet Pg. 842
D.3.a
completion of the contract if the contractor does not transfer the records to
the County.
4-
0
(4) Upon completion of the contract, transfer, at no cost, to the County all public
records in possession of the Contractor or keep and maintain public records
that would be required by the County to perform the service. If the
Contractor transfers all public records to the County upon completion of the
contract, the Contractor shall destroy any duplicate public records that are
exempt or confidential and exempt from public records disclosure a.
requirements. If the Contractor keeps and maintains public records upon
completion of the contract, the Contractor shall meet all applicable
requirements for retaining public records. All records stored electronically
must be provided to the County, upon request from the County's custodian 2
of records, in a format that is compatible with the information technology
systems of the County.
(5) A request to inspect or copy public records relating to a County contract
must be made directly to the County, but if the County does not possess
the requested records, the County shall immediately notify the Contractor of
the request, and the Contractor must provide the records to the County or
allow the records to be inspected or copied within a reasonable time.
If the Contractor does not comply with the County's request for records, the
County shall enforce the public records contract provisions in accordance
with the contract, notwithstanding the County's option and right to 0
unilaterally cancel this contract upon violation of this provision by the
Contractor. A Contractor who fails to provide the public records to the
County or pursuant to a valid public records request within a reasonable
time may be subject to penalties under Section 119.10, Florida Statutes.
U)
The Contractor shall not transfer custody, release, alter, destroy or
otherwise dispose of any public records unless or otherwise provided in this
provision or as otherwise provided by law.
IF THE CONTRACTOR HAS QUESTIONS REGARDING THE
APPLICATION OF CHAPTER 119, FLORIDA STATUTES, TO THE
CONTRACTOR'S DUTY TO PROVIDE PUBLIC RECORDS RELATING
TO THIS CONTRACT, CONTACT THE CUSTODIAN OF PUBLIC
RECORDS, BRIAN BRADLEY AT PHONE# 305-292-3470 BRADLEY-
BRIAN@MONROECOUNTY-FL.GOV, MONROE COUNTY ATTORNEY'S
OFFICE 1111 12TH Street, SUITE 408, KEY WEST, FL 33040. U)
o) Non-Waiver of Immunity. Notwithstanding the provisions of Sec. 768.28, Florida
Statutes, the participation of the Contractor and the County in this Agreement and
the acquisition of any commercial liability insurance coverage, self-insurance
coverage, or local government liability insurance pool coverage shall not be deemed
a waiver of immunity to the extent of liability coverage, nor shall any contract entered a.
into by the County be required to contain any provision for waiver.
AGREEMENT 00500- Page 11 of 23
Packet Pg. 843
D.3.a
E
cu
p) Privileges and Immunities. All of the privileges and immunities from liability,
exemptions from laws, ordinances, and rules and pensions and relief, disability,
workers' compensation, and other benefits which apply to the activity of officers,
agents, or employees of any public agents or employees of the County, when
performing their respective functions under this Agreement within the territorial limits
of the County shall apply to the same degree and extent to the performance of such
functions and duties of such officers, agents, volunteers, or employees outside the
territorial limits of the County.
a.
q) Legal Obligations and Responsibilities: Non-Delegation of Constitutional or Statutory
Duties. This Agreement is not intended to, nor shall it be construed as, relieving any
participating entity from any obligation or responsibility imposed upon the entity by
law except to the extent of actual and timely performance thereof by any participating
entity, in which case the performance may be offered in satisfaction of the obligation
or responsibility. Further, this Agreement is not intended to, nor shall it be construed
as, authorizing the delegation of the constitutional or statutory duties of the County,
except to the extent permitted by the Florida constitution, state statute, and case law.
r) Non-Reliance by Non-Parties. No person or entity shall be entitled to rely upon the
terms, or any of them, of this Agreement to enforce or attempt to enforce any third-
party claim or entitlement to or benefit of any service or program contemplated
hereunder, and the County and the Contractor agree that neither the County nor the
Contractor or any agent, officer, or employee of either shall have the authority to
inform, counsel, or otherwise indicate that any particular individual or group of
individuals, entity or entities, have entitlements or benefits under this Agreement 0
separate and apart, inferior to, or superior to the community in general or for the
purposes contemplated in this Agreement.
U)
s) Attestations. Contractor agrees to execute such documents as the County may
reasonably require, to include a Public Entity Crime Statement, an Ethics Statement,
and a Drug-Free Workplace Statement.
t) No Personal Liability. No covenant or agreement contained herein shall be deemed
to be a covenant or agreement of any member, officer, agent or employee of Monroe
County in his or her individual capacity, and no member, officer, agent or employee
of Monroe County shall be liable personally on this Agreement or be subject to any
personal liability or accountability by reason of the execution of this Agreement.
u) Execution in Counterparts. This Agreement may be executed in any number of
counterparts, each of which shall be regarded as an original, all of which taken
together shall constitute one and the same instrument and any of the parties hereto U)
may execute this Agreement by signing any such counterpart.
v) Hold Harmless and Indemnification. Notwithstanding any minimum insurance
requirements prescribed elsewhere in this agreement, Contractor shall defend,
indemnify and hold the COUNTY and the COUNTY's elected and appointed officers
0
and employees harmless from and against (i) any claims, actions or causes of a.
action, (ii) any litigation, administrative proceedings, appellate proceedings, or other
proceedings relating to any type of injury (including death), loss, damage, fine,
penalty or business interruption, and (iii) any costs or expenses that may be asserted
AGREEMENT 00500- Page 12 of 23
Packet Pg. 844
D.3.a
against, initiated with respect to, or sustained by, any indemnified party by reason of,
or in connection with, (A) any activity of Contractor or any of its employees, agents,
contractors or other invitees during the term of this Agreement, (B) the negligence or
recklessness, intentional wrongful misconduct, errors or other wrongful act or
omission of Contractor or any of its employees, agents, sub-contractors or other
invitees, or (C) Contractor's default in respect of any of the obligations that it
undertakes under the terms of this Agreement, except to the extent the claims,
actions, causes of action, litigation, proceedings, costs or expenses arise from the
intentional or sole negligent acts or omissions of the COUNTY or any of its a.
employees, agents, contractors or invitees (other than Contractor). The monetary
limitation of liability under this contract shall be not less than $1 million per
occurrence pursuant to F. S. 725.06. Insofar as the claims, actions, causes of action,
litigation, proceedings, costs or expenses relate to events or circumstances that
occur during the term of this Agreement, this section will survive the expiration of the
term of this Agreement or any earlier termination of this Agreement.
In the event that the completion of the project (to include the work of others) is
delayed or suspended as a result of the Contractor s failure to purchase or maintain
the required insurance, the Contractor shall indemnify the County from any and all
increased expenses resulting from such delay. Should any claims be asserted
against the County by virtue of any deficiency or ambiguity in the plans and
specifications provided by the Contractor, the Contractor agrees and warrants that
the Contractor shall hold the County harmless and shall indemnify it from all losses
occurring thereby and shall further defend any claim or action on the County's behalf.
0
The first ten dollars ($10.00) of remuneration paid to the Contractor is for the
indemnification provided for the above.
U)
FDEM Indemnification
To the fullest extent permitted by law, the Contractor shall indemnify and hold
harmless the Agency, the State of Florida, Department of Emergency Management,
and its officers and employees, from liabilities, damages, losses and costs, including,
but not limited to, reasonable attorney's fees, to the extent caused by the negligence,
recklessness or intentional wrongful misconduct of the Contractor and persons
employed or utilized by the Contractor in the performance of this Contract.
This indemnification shall survive the termination of this Contract. Nothing contained
in this paragraph is intended to nor shall it constitute a waiver of the State of Florida
and the (County) Agency's sovereign immunity.
0
w) Section Headings. Section headings have been inserted in this Agreement as a U)
matter of convenience of reference only, and it is agreed that such section headings
are not a part of this Agreement and will not be used in the interpretation of any
provision of this Agreement.
x) Disadvantaged Business Enterprise (DBE) Policy and Obligation. It is the policy of
0
the County that DBE's, as defined in C.F.R. Part 26, as amended, shall have the a.
opportunity to participate in the performance of contracts financed in whole or in part
with County funds under this agreement. The DBE requirements of applicable federal
and state laws and regulations apply to this Agreement. The County and its
AGREEMENT 00500- Page 13 of 23
Packet Pg. 845
D.3.a
Contractor agree to ensure that DBE's have the opportunity to participate in the
performance of the Agreement. In this regard, all recipients and contractors shall
take all necessary and reasonable steps in accordance with applicable federal and
state laws and regulations to ensure that DBE's have the opportunity to compete and
perform contracts. The County and Contractor and subcontractors shall not
discriminate on the basis of race, color, national origin or sex in award and
performance of contracts, entered pursuant to this Agreement.
y) Agreements with Subcontractors. In the event that the Contractor subcontracts any a.
or all of the work in this project to any third party, the Contractor specifically agrees
to identify the COUNTY as an additional insured on all insurance policies required by
the County. In addition, the Contractor specifically agrees that all agreements or
contracts of any nature with his subcontractors shall include the COUNTY as 2
additional insured.
z) Florida Green Building Coalition Standards. Monroe County requires its buildings to
conform to Florida Green Building Coalition standards.
Special Conditions, if any are detailed in Section 00100 of the Project Manual for this
Project.
Right to Audit 0
Availability of Records. The records of the parties to this Agreement relating to the Project,
which shall include but not be limited to accounting records (hard copy, as well as computer
readable data if it can be made available; subcontract files (including proposals of successful
and unsuccessful bidders, bid recaps, bidding instructions, bidders list, etc); original estimates;
estimating work sheets; correspondence; change order files (including documentation covering
negotiated settlements); backcharge logs and supporting documentation; general ledger entries
detailing cash and trade discounts earned, insurance rebates and dividends; any other U)
supporting evidence deemed necessary by Owner or the Monroe County Office of the Clerk of U)
Court and Comptroller (hereinafter referred to as "County Clerk") to substantiate charges related
to this agreement, and all other agreements, sources of information and matters that may in
Owner's or the County Clerk's reasonable judgment have any bearing on or pertain to any
matters, rights, duties or obligations under or covered by any contract document (all foregoing
hereinafter referred to as "Records") shall be open to inspection and subject to audit and/or
reproduction by Owner's representative and/or agents or the County Clerk. Owner or County
Clerk may also conduct verifications such as, but not limited to, counting employees at the job
site, witnessing the distribution of payroll, verifying payroll computations, overhead
computations, observing vendor and supplier payments, miscellaneous allocations, special
charges, verifying information and amounts through interviews and written confirmations with
employees, Subcontractors, suppliers, and contractors representatives. All records shall be kept 0
for ten (10) years after Final Completion. The County Clerk possesses the independent
authority to conduct an audit of Records, assets, and activities relating to this Project. If any
auditor employed by the Monroe County or County Clerk determines that monies paid to
Contractor pursuant to this Agreement were spent for purposes not authorized by this
Agreement, the Contractor shall repay the monies together with interest calculated pursuant to
Section 55.03, F.S., running form the date the monies were paid to Contractor.
AGREEMENT 00500- Page 14 of 23
Packet Pg. 846
D.3.a
7.7 Any written notices or correspondence given pursuant to this contract shall be sent by
United States Mail, certified, return receipt requested, or by courier with proof of delivery.
Notice shall be sent to the following persons:
For Contractor: Yosvany Madruga, CEO
890 S.W. 69th Ave.
Miami, FL 33144
a.
For Owner: Director of Project Management Assistant County Administrator, PW& E
1100 Simonton St., Room 2-216 1100 Simonton St.
Key West, FL 33040 Key West, FL 33040
7.8 FEDERAL CONTRACT REQUIREMENTS
The CONTRACTOR and its subcontractors must follow the provisions, as
applicable, as set forth in 2 C.F.R. §200.326 Contract provisions and Appendix II to
2 C.F.R. Part 200, as amended, including but not limited to:
7.8.1 Clean Air Act and the Federal Water Pollution Control Act. CONTRACTOR agrees to
comply with all applicable standards, orders, or regulations issued pursuant to the Clean
Air Act (42 U.S.C. 7401-7671 q) and the Federal Water Pollution Control Act as amended X
(33 U.S.C. 1251-1387) and will report violations to FEMA and the Regional Office of the
Environmental Protection Agency (EPA).
7.8.2 Davis-Bacon Act, as amended (40 U.S.C. 3141-3148). When required by Federal
program legislation, which includes emergency Management Preparedness Grant
Program, Homeland Security Grant Program, Nonprofit Security Grant Program, Tribal
Homeland Security Grant Program, Port Security Grant Program and Transit Security
Grant Program, all prime construction contracts in excess of $2,000 awarded by non- U)
Federal entities must comply with the Davis-Bacon Act (40 U.S.C. 31413144 and 3146-
3148) as supplemented by Department of Labor regulations (29 CFR Part 5, "Labor
Standards Provisions Applicable to Contracts Covering Federally Financed and Assisted
Construction"). In accordance with the statute, CONTRACTORS must be required to pay
wages to laborers and mechanics at a rate not less than the prevailing wages specified
in a wage determination made by the Secretary of Labor. In addition, CONTRACTORS
must be required to pay wages not less than once a week. If applicable, the COUNTY
must place a copy of the current prevailing wage determination issued by the
Department of Labor in each solicitation attached hereto as Exhibit "A".
The decision to award a contract or subcontract must be conditioned upon the
acceptance of the wage determination. The COUNTY must report all suspected or
reported violations to the Federal awarding agency. When required by Federal program
legislation, which includes emergency Management Preparedness Grant Program, 0
Homeland Security Grant Program, Nonprofit Security Grant Program, Tribal Homeland .2
Security Grant Program, Port Security Grant Program and Transit Security Grant
Program (it does not apply to other FEMA grant and cooperative agreement programs,
including the Public Assistance Program), the CONTRACTORS must also comply with
the Copeland "Anti-Kickback" Act (40 U.S.C. 3145), as supplemented by Department of
Labor regulations (29 CFR Part 3, "Contractors and Subcontractors on Public Building or a.
Public Work Financed in Whole or in Part by Loans or Grants from the United States").
As required by the Act, each CONTRACTOR or subrecipient is prohibited from inducing,
by any means, any person employed in the construction, completion, or repair of public
AGREEMENT 00500- Page 15 of 23
Packet Pg. 847
D.3.a
work, to give up any part of the compensation to which he or she is otherwise entitled.
The COUNTY must report all suspected or reported violations to the Federal awarding
4-
agency.
1) The CONTRACTOR shall comply with 18 U.S.C. § 874, 40 U.S.C. §
3145, and the requirements of 29 C.F.R. pt. 3 as may be applicable, which are
incorporated by reference into this contract.
2) Subcontracts. The CONTRACTOR or subcontractor shall insert in any
subcontracts the clause above and such other clauses as the FEMA may by appropriate
a.
instructions require, and also a clause requiring the subcontractors to include these
clauses in any lower tier subcontracts. The prime CONTRACTOR shall be responsible
for the compliance by any subcontractor or lower tier subcontractor with all of these
contract clauses.
3) Breach. A breach of the contract clauses above may be grounds for
termination of the contract, and for debarment as a contractor and subcontractor as U'
provided in 29 C.F.R. § 5.12.
0
7.8.3 Contract Work Hours and Safety Standards Act (40 U.S.C. 3701-3708). Where
applicable, which includes all FEMA grant and cooperative agreement programs, all
contracts awarded by the COUNTY in excess of $100,000 that involve the employment
of mechanics or laborers must comply with 40 U.S.C. 3702 and 3704, as supplemented
by Department of Labor regulations (29 CFR Part 5). Under 40 U.S.C. 3702 of the Act,
each CONTRACTOR must compute the wages of every mechanic and laborer on the
basis of a standard work week of forty (40) hours. Work in excess of the standard work
week is permissible provided that the worker is compensated at a rate of not less than
one and a half times the basic rate of pay for all hours worked in excess of forty (40)
hours in the work week. The requirements of 40 U.S.C. 3704 are applicable to
construction work and provide that no laborer or mechanic must be required to work in U)
surroundings or under working conditions which are unsanitary, hazardous, or
dangerous. These requirements do not apply to the purchases of supplies or materials
or articles ordinarily available on the open market, or contracts for transportation or
transmission of intelligence.
7.8.4 Rights to Inventions Made Under a Contract or Agreement. If the Federal award meets
the definition of "funding agreement" under 37 CFR §401.2 (a) and the recipient or
subrecipient wishes to enter into a contract with a small business firm or nonprofit
organization regarding the substitution of parties, assignment or performance of
experimental, developmental, or research work under that "funding agreement," the
recipient or subrecipient must comply with the requirements of 37 CFR Part 401, "Rights
to Inventions Made by Nonprofit Organizations and Small Business Firms Under
Government Grants, Contracts and Cooperative Agreements," and any implementing U)
regulations issued by the awarding agency.
a�
7.8.5 Clean Air Act (42 U.S.C. 7401-7671 g.), Water Pollution Control Act (33 U.S.C. 1251-
1387) as amended. Contracts and subgrants of amounts in excess of $150,000 must
comply with all applicable standards, orders, or regulations issued pursuant to the Clean
Air Act (42 U.S.C. 7401-7671 q) and the Federal Water Pollution Control Act as amended
a.
(33 U.S.C. 1251-1387). Violations must be reported to the Federal awarding agency and
the Regional Office of the Environmental Protection Agency (EPA).
AGREEMENT 00500- Page 16 of 23
Packet Pg. 848
D.3.a
7.8.6 Debarment and Suspension (Executive Orders 12549 and 12689). A contract award
(see 2 CFR 180.220) must not be made to parties listed on the government wide
exclusions in the System for Award Management (SAM), in accordance with the OMB
guidelines at 2 CFR 180 that implement Executive Orders 12549 (3 CFR part 1986
Comp., p. 189) and 12689 (3 CFR part 1989 Comp., p. 235), "Debarment and
Suspension." SAM Exclusions contains the names of parties debarred, suspended, or
otherwise excluded by agencies, as well as parties declared ineligible under statutory or
regulatory authority other than Executive Order 12549.
a.
7.8.7 Byrd Anti-Lobbying Amendment (31 U.S.C. 1352). CONTRACTORS that apply or bid for
an award exceeding $100,000 must file the required certification. Each tier certifies to
the tier above that it will not and has not used Federal appropriated funds to pay any
person or organization for influencing or attempting to influence an officer or employee of
any agency, a member of Congress, officer or employee of Congress, or an employee of
a member of Congress in connection with obtaining any Federal contract, grant or any U'
other award covered by 31 U.S.C. 1352. Each tier must also disclose any lobbying with
non-Federal funds that takes place in connection with obtaining any Federal award.
Such disclosures are forwarded from tier to tier up to the non-Federal award.
7.8.8 Compliance with Procurement of recovered materials as set forth in 2 CFR � 200.322.
CONTRACTOR must comply with section 6002 of the Solid Waste disposal Act, as
amendment by the Resource Conservation and Recovery Act. The requirements of
Section 6002 include procuring only items designed in guidelines of the Environmental
Protection Agency (EPA at 40 CPR part 247 that contain the highest percentage of
recovered materials practicable, consistent with maintaining a satisfactory level of
competition, where the purchase price of the item exceeds $10,000 or the value of the
quantity acquired during the preceding fiscal year exceeded $10,000; procuring solid
waste management services in a manner that maximizes energy and resource recovery;
and establishing an affirmative procurement program for procurement of recovered U)
materials identified in the EPA guidelines. (1) In the performance of this contract, the
CONTRACTOR shall make maximum use of products containing recovered materials
that are EPA-designated items unless the product cannot be acquired (i) Competitively
within a timeframe providing for compliance with the contract performance schedule; (ii)
Meeting contract performance requirements; or (iii) At a reasonable price. (2) Information
about this requirement, along with the list of EPA-designated items, is available at EPA's
Comprehensive Procurement Guidelines web site,
https://www.epa.gov/smm/comprehensive-procurement-quideline-cpq-program.
Other Federal Requirements (as applicable):
7.8.9 Americans with Disabilities Act of 1990, as amended, (ADA). The CONTRACTOR will
comply with all the requirements as imposed by the ADA, the regulations of the Federal a
government issued thereunder, and the assurance by the CONTRACTOR pursuant 0
thereto.
7.8.10 Disadvantaged Business Enterprise (DBE) Policy and Obligation. It is the policy of the
COUNTY that DBE's, as defined in 49 C.F.R. Part 26, as amended, shall have the
opportunity to participate in the performance of contracts financed in whole or in part
with COUNTY funds under this Agreement. The DBE requirements of applicable federal a.
and state laws and regulations apply to this Agreement. The COUNTY and its
CONTRACTOR agree to ensure that DBE's have the opportunity to participate in the
performance of this Agreement. In this regard, all recipients and contractors shall take all
AGREEMENT 00500- Page 17 of 23
Packet Pg. 849
D.3.a
necessary and reasonable steps in accordance with 2 C.F.R. § 200.321( as set forth in
detail below), applicable federal and state laws and regulations to ensure that the DBE's
have the opportunity to compete for and perform contracts. The COUNTY and the
CONTRACTOR and subcontractors shall not discriminate on the basis of race, color,
national origin or sex in the award and performance of contracts, entered pursuant to
this Agreement.
0
2 C.F.R. § 200.321 CONTRACTING WITH SMALL AND MINORITY
BUSINESSES, WOMEN'S BUSINESS ENTERPRISES, AND LABOR SURPLUS AREA
a.
FIRMS
3
a. If the CONTRACTOR, with the funds authorized by this Z
Agreement, seeks to subcontract goods or services, then, in accordance with 2 C.F.R.
§200.321, the CONTRACTOR shall take the following affirmative steps to assure that
minority businesses, women's business enterprises, and labor surplus area firms are U)
used whenever possible.
b. Affirmative steps must include:
1. Placing qualified small and minority businesses and women's business
enterprises on solicitation lists;
2. Assuring that small and minority businesses, and women's business
enterprises are solicited whenever they are potential sources;
3. Dividing total requirements, when economically feasible, into smaller tasks or
quantities to permit maximum participation by small and minority businesses,
and women's business enterprises;
4. Establishing delivery schedules, where the requirement permits, which
encourage participation by small and minority businesses, and women's
business enterprises;
5. Using the services and assistance, as appropriate, of such organizations as
the Small Business Administration and the Minority Business Development U)
Agency of the Department of Commerce.
6. Requiring the Prime contractor, if subcontractor are to be let, to take the
affirmative steps listed in paragraph (1) through (5) of this section.
7.8.11 The CONTRACTOR shall utilize the U.S. Department of Homeland Security's E-Verify
system to verify the employment eligibility of all new employees hired by the
CONTRACTOR during the term of the Contract and shall expressly require any
subcontractors performing work or providing services pursuant to the Contract to
likewise utilize the U.S. Department of Homeland Security's E-Verify system to verify the
employment eligibility of all new employees hired by the subcontractor during the
Contract term.
7.8.12 Fraud and False or Fraudulent or Related Acts. The CONTRACTOR acknowledges that 0
31 U.S.C. Chap. 38 (Administrative Remedies for False Claims and Statements) applies
to the CONTRACTOR'S actions pertaining to this contract.
7.8.13 Access to Records. The following access to records requirements apply to this contract:
(1) The CONTRACTOR agrees to provide MONROE COUNTY, the FEMA
Administrator, the Comptroller General of the United States, or any of their authorized
representatives access to any books, documents, papers, and records of the
AGREEMENT 00500- Page 18 of 23
Packet Pg. 850
D.3.a
CONTRACTOR which are directly pertinent to this contract for the purposes of making
audits, examinations, excerpts, and transcriptions.
(2) The CONTRACTOR agrees to permit any of the foregoing parties to reproduce
by any means whatsoever or to copy excerpts and transcriptions as reasonably needed.
(3) The CONTRACTOR agrees to provide the FEMA Administrator or his authorized
representatives access to construction or other work sites pertaining to the work being
completed under the contract.
7.9 The CONTRACTOR is bound by the terms and conditions of the Federally-Funded
a.
Subaward and Grant Agreement between County and the Florida Division of Emergency
Management (Division) and attached hereto as Exhibit "B".
7.10 The Contractor is bound by all applicable local, County, State, and Federal laws and
regulations.
U)
7.11 The CONTRACTOR shall hold the Division and County harmless against all claims of
whatever nature arising out of the CONTRACTOR'S performance of work under this
Agreement, to the extend allow and required by law.
ARTICLE 8
Termination or Suspension
x
0
0
8.1 The Contract may be terminated by the Owner as provided in Article 14 of the General
Conditions.
A. In the event that the CONTRACTOR shall be found to be negligent in any aspect of
service, the COUNTY shall have the right to terminate this agreement after five days
written notification to the CONTRACTOR.
U)
B. Either of the parties hereto may cancel this Agreement without cause by giving the U)
other party sixty (60) days written notice of its intention to do so.
C. Termination for Cause and Remedies: In the event of breach of any contract terms,
the COUNTY retains the right to terminate this Agreement. The COUNTY may also
terminate this agreement for cause with CONTRACTOR should CONTRACTOR fail cas
to perform the covenants herein contained at the time and in the manner herein
provided. In the event of such termination, prior to termination, the COUNTY shall
provide CONTRACTOR with seventy-two (72) hours' notice and provide the
CONTRACTOR with an opportunity to cure the breach that has occurred. If the
breach is not cured, the Agreement will be terminated for cause. If the COUNTY
terminates this agreement with the CONTRACTOR, COUNTY shall pay U)
CONTRACTOR the sum due the CONTRACTOR under this agreement prior to 0
termination, unless the cost of completion to the COUNTY exceeds the funds
remaining in the contract; however, the COUNTY reserves the right to assert and cas
seek an offset for damages caused by the breach. The maximum amount due to
CONTRACTOR shall not in any event exceed the spending cap in this Agreement.
In addition, the COUNTY reserves all rights available to recoup monies paid under
this Agreement, including the right to sue for breach of contract and including the
right to pursue a claim for violation of the COUNTY's False Claims Ordinance,
located at Section 2-721 et al. of the Monroe County Code.
AGREEMENT 00500- Page 19 of 23
Packet Pg. 851
D.3.a
a�
D. Termination for Convenience: The COUNTY may terminate this Agreement for
convenience, at any time, upon sixty (60) days' notice to CONTRACTOR. If the
COUNTY terminates this agreement with the CONTRACTOR, COUNTY shall pay
CONTRACTOR the sum due the CONTRACTOR under this agreement prior to
termination, unless the cost of completion to the COUNTY exceeds the funds
remaining in the contract. The maximum amount due to CONTRACTOR shall not
exceed the spending cap in this Agreement. In addition, the COUNTY reserves all
a.
rights available to recoup monies paid under this Agreement, including the right to
sue for breach of contract and including the right to pursue a claim for violation of the
COUNTY's False Claims Ordinance, located at Section 2-721 et al. of the Monroe
County Code.
U)
8.2 For Contracts of any amount, if the County determines that the Contractor/Consultant
has submitted a false certification under Section 287.135(5), Florida Statutes or has
been placed on the Scrutinized Companies that Boycott Israel List, or is engaged in a
boycott of Israel, the County shall have the option of (1) terminating the Agreement after
it has given the Contractor/Consultant written notice and an opportunity to demonstrate
the agency's determination of false certification was in error pursuant to Section X
287.135(5)(a), Florida Statutes, or (2) maintaining the Agreement if the conditions of
Section 287.135(4), Florida Statutes, are met.
For Contracts of $1,000,000 or more, if the County determines that the
Contractor/Consultant submitted a false certification under Section 287.135(5), Florida
Statutes, or if the Contractor/Consultant has been placed on the Scrutinized Companies
with Activities in the Sudan List, the Scrutinized Companies with Activities in the Iran
Petroleum Energy Sector List or been engaged in business operations in Cuba or Syria,
the County shall have the option of (1) terminating the Agreement after it has given the
Contractor/Consultant written notice and an opportunity to demonstrate the agency's
determination of false certification was in error pursuant to Section 287.135(5)(a), Florida
Statutes, or (2) maintaining the Agreement if the conditions of Section 287.135(4),
Florida Statutes, are met.
ARTICLE 9
Enumeration of Contract Documents
9.1 The Contract Documents, except for Modifications issued after execution of this
Agreement, are enumerated as follows:
a) Drawings: None U)
b) Project Manual: None
c) Documents: None
9.1.1 The Agreement is this executed Standard Form of Agreement Between Owner and
Contractor.
0
a.
9.1.2 The General Conditions are the General Conditions of the Contract for Construction.
AGREEMENT 00500- Page 20 of 23
Packet Pg. 852
D.3.a
9.1.3 The Supplementary and other Conditions of the Contract are those contained in the
Project Manual dated: None
4-
0
9.1.4 The Addenda, if any, are as follows:
Number Date Page
1 4/19/19 1
0
0
This Agreement is entered into as of the day and year first written above and is executed in at
least one (1) original copy. A copy will be delivered to the Contractor. a.
SIGNATURE PAGE TO FOLLOW
0
x
0
0
0
U)
U)
r-
0
0
U)
0
a�
0
a.
AGREEMENT 00500- Page 21 of 23
Packet Pg. 853
4-
Execution by the Contractor must be by a person with authority to bind the entity. 0
SIGNATURE OF THE PERSON EXECUTING THE DOCUMENT MUST BE NOTARIZED. 0W
(SEAL) BOARD OF COUNTY COMMISSIONERS
4-
Attest: Kevin Madok, Clerk OF MONROE COUNTY, FLORIDA 0
0
W
0
IL
By: By:
Deputy Clerk May
Date z
(SEAL)
U)
CONTRA2.TOR'S Witnesses Attest CONTRACTOR: (n
r-
Contractor must provide two witnesses 0
signatures Signature:
Signature: Print Name:
X
0
Print Name: Title: 0
Title: Date:
0
Date:
and
U)
.0
MONROE COUNTY ATTORNEY
Signature: ( DROVED U)
0
Print Name: ,
Title: ti-I'FfIS A MBROSIO
ASSISTA T COUNTY ATTORNEY
Date: Date:
STATE OF FLORIDA, COUNTY OF
0
On this day of 20 before me, the undersigned notary public,
U)
personally appeared known to me to be the person whose name is 0
subscribed above or who produced- as identification, and acknowledged .2
that he/she is the person who executed the above contract with Monroe County for
MARATHON SHERIFF SUBSTATION BUILDING NEW ROOF AND REPAIRS for the
purposes therein contained.
Notary Public 0
Print Name
My commission expires: Sea[
E
End of Section 00500
AGREEMENT 00500- Page 22 of 23
I Packet Pg. 854
D.3.a
GENERAL REQUIREMENTS
Where Project Management is Not a Constructor
4-
0
0
Section 00750 General Conditions
Section 00970 Project Safety and Health Plan
Section 00980 Contractor Quality Control Plan
Section 01015 Contractor's Use of the Premises
Section 01027 Application for Payment a.
Section 01030 Alternates
Section 01040 Project Coordination z
Section 01045 Cutting and Patching
Section 01050 Field Engineering
Section 01200 Project Meetings
Section 01301 Submittals
Section 01310 Progress Schedules
Section 01370 Schedule of Values
Section 01385 Daily Construction Reports
Section 01395 Request for Information— (RFI)
Section 01410 Testing Laboratory Services
Section 01421 Reference Standards and Definitions
Section 01500 Temporary Facilities
Section 01520 Construction Aids
Section 01550 Access Roads and Parking Areas
Section 01560 Temporary Controls
Section 01590 Field Offices and Sheds
Section 01595 Construction Cleaning U)
Section 01600 Material and Equipment U)
Section 01630 Post-Proposal Substitutions
Section 01640 Product Handling
Section 01700 Contract Closeout
Section 01710 Final Cleaning
Section 01720 Project Record Documents
Section 01730 Operation and Maintenance Data
Section 01740 Warranties
0
U)
0
a�
0
a.
Packet Pg. 855
uoI; ;s n uoq;ear ) siiedej Pue JOOJ Ora uoI; ;s ns djlaeq uoq;ear -I :;�Ow4o ;; co
q LO
ci co
o �
a
`
s a
in
t
H a
N 00 0 0 u
Q o in s
a Q o
W 0 L � N
m o
LL t
p s°
0LL
c,
2 O ° }
IL p
U Z C
Z LU O
Q W
Z H W H o L
LL 3 O z °
a (1 W m o 0 o s 3
W Z *.I Z U') u') u') } >
ZQpON Z 0 o
M-0a
LU
in
a a � z Q0
LL > E-
W LV U v t o
a =
O th J ° � _ 0
Z z u L 0 0 > v
2 o a) o > a
z U o :3 S3-
:�- s
Q w inN ZS
O Uin L N N L
-0 ; "r- N
N Q L :3 t v
-a
} L Co
t
� a
m H i m