Loading...
06/19/2019 Agreement cGJ.t COURT0�. Ao1 i," '";.. Kevin Madok, CPA • A V'. •" Clerk of the Circuit Court& Comptroller—Monroe County, Florida DATE: August 6, 2019 TO: Breanne Erickson Budget/Contract Administrator Steven Sanders Project Manager Tammy Sweeting Executive Assistant FROM: Pamela G. Hancoc , SUBJECT: June 19th BOCC Meeting Attached is an electronic copy of each of the following items for your handling: D3 Contract with A-1 Property Services Group, Inc. in the amount of$91,174.14 for a new roof and roof repairs of the Sheriffs Marathon Substation. Funded by Hurricane Irma fund sources. D4 Contract with A-1 Property Services Group, Inc. in the amount of$62,255.00 for a new roof and roof repairs at the Marathon Library. Funded by Hurricane Irma fund sources. Should you have any questions, please feel free to contact me at (305) 292-3550. cc: County Attorney Finance File KEY WEST MARATHON PLANTATION KEY PK/ROTH BUILDING 500 Whitehead Street 3117 Overseas Highway 88820 Overseas Highway 50 High Point Road Key West,Florida 33040 Marathon,Florida 33050 Plantation Key,Florida 33070 Plantation Key,Florida 33070 305-294-4641 305-289-6027 305-852-7145 305-852-7145 Agreement Between Owner and Contractor Where the basis of payment is a STIPULATED SUM AGREEMENT Made as of June 19, 2019 BETWEEN the Owner: Monroe County Board of County Commissioners 500 Whitehead Street Key West, Florida 33040 And the Contractor: A-1 Property Services Group Inc. 890 S.W. 69th Avenue Miami, FL 33144 For the following Project: MARATHON LIBRARY BUILDING NEW ROOF AND REPAIRS Scope of the Work The Scope of Work shall include, but not be limited to, all work shown and listed in the Project Documents and Specifications. The Contractor is required to provide a complete job as contemplated by the documents and specifications, which are a part of this bid package. The Contractor shall furnish all labor, supervision, materials, power, tools, equipment, supplies, permits and any other means of construction necessary or proper for performing and completing the Scope of Work, unless otherwise specifically stated. Marathon Library Clay Tile Roof and TPO coating and repairs: • Repair all the clay tile to match the existing clay tiles on the roof caulk and seal the entire roof and all the openings with Advanced Sealant Caulk Polymer sealant. • Provide engineering necessary to permit the work. Permit fees are included in the bid. Repair any damages to the ARTICLE 1 The Contract Documents The Contract Documents consist of this Agreement, Conditions of the Contract (General, Supplementary and other Conditions), Documents, Specifications, Proposal Documents, Addenda issued prior to execution of this Agreement, together with the response to Request for Proposals (RFP) and all required insurance documentation, and Modifications issued after execution of this Agreement. The Contract represents the entire and integrated agreement between the parties hereto and supersedes prior negotiations, representations or agreements, either written or oral. An enumeration of the Contract Documents, other than Modifications, appears in Article 9. In the event of a discrepancy between the documents, precedence shall be determined by the order of the documents as just listed. AGREEMENT 00500-Page 1 of 23 ARTICLE 2 The Work of this Contract The Contractor shall execute the entire Work described in the Contract Documents, except to the extent specifically indicated in the Contract Documents to be the responsibility of others, or as follows: N/A ARTICLE 3 Date of Commencement and Substantial Completion 3.1 The date of commencement is the date to be fixed in a notice to proceed issued by the Owner. The Contractor shall achieve Substantial Completion of the entire Work not later than Forty Five (45) calendar days after the date of commencement or issuance of a Notice to Proceed. The time or times stipulated in the contract for completion of the work of the contract or of specified phases of the contract shall be the calendar date or dates listed in the milestone schedule. Liquidated damages will be based on the Substantial Completion Date for all work, modified by all approved extensions in time as set forth by the Director of Project Management's signature of approval on the Certificate of Substantial Completion. The liquidated damages table below shall be utilized to determine the amount of liquidated damages. FIRST SECOND 31 ST DAY & CONTRACT AMOUNT 15 DAYS 15 DAYS THEREAFTER Under$50,000.00 $50.00/Day $100.00/Day $250.00/Day $50,000.00-99,999.00 100.00/Day 200.00/Day 750.00/Day $100,000.00-499,999.00 200.00/Day 500.00/Day 2,000.00/Day $500,000.00 and Up 500.00/Day 1,000.00/Day 3,500.00/Day The Contractor's recovery of damages and sole remedy for any delay caused by the Owner shall be an extension of time on the Contract. ARTICLE 4 Contract Sum 4.1 The owner shall pay the Contractor in current funds for the Contractor's performance of the Contract the Contract Sum of Sixty Two Thousand Two Hundred Fifty Five Dollars. ($62,255.00) subject to additions and deductions as provided in the Contract Documents. 4.2 The Contract Sum is based upon the following alternates, if any, which are described in the Contract Documents and are hereby accepted by the Owner: Alternate# 1: No Alternates Specified 4.3 Unit prices, if any, are as follows: N/A. ARTICLE 5 Progress Payments AGREEMENT 00500-Page 2 of 23 5.1 Based upon Applications for Payment submitted by the Contractor to the Director of Project Management, and upon approval for payment issued by the Director of Project Management and Architect, the Ownershall make progress paymentson account of the -- -- Contract Sum to the contractor as provided below and elsewhere in the Contract Documents. 5.2 The period covered by each Application for payment shall be one (1) calendar month ending on the last day of the month, or as follows: 5.3 Payment will be made by the Owner in accordance with the Florida Local Government Prompt Payment Act, Section 218.735, Florida Statutes. 5.4 Each Application for Payment shall be based upon the Schedule of Values submitted by the Contractor in accordance with the Contract Documents. The Schedule of Values shall allocate the entire Contract Sum among the various portions of the Work and be prepared in such form and supported by such data to substantiate its accuracy as the Director of Project Management may require. This schedule, unless objected to by the Director of Project Management, shall be used as a basis for reviewing the Contractor's Applications for Payment. 5.5 Applications for Payment shall indicate the percentage of completion of each portion of the Work as of the end of the period covered by the Application for Payment. 5.6 Subject to the provisions of the Contract Documents, the amount of each progress payment shall be computed as follows: 5.6.1 Take that portion of the Contract Sum properly allocable to completed Work as determined by multiplying the percentage completion of each portion of the Work by the share of the total Contract Sum allocated to that portion of the Work in the Schedule of Values, less retainage of ten percent 10%. Pending final determination of cost to the • Owner of changes in the Work, amounts not in dispute may be included in Applications for Payment. The amount of credit to be allowed by the Contractor to the Owner for a deletion or change which results in a net decrease in the Contract Sum shall be the net cost to the Owner, less Overhead, Profit and Documented Costs incurred prior to the change Request, as indicated in the corresponding line item in the Approved Schedule of Values for that line item as confirmed by the Director of Project Management. When both additions and credits covering related Work or substitutions are involved in a change, the allowance for overhead and profit shall be figured on the basis of net increase, if any, with respect to that change. 5.6.2 Add that portion of the Contract Sum properly allocable to materials and equipment delivered and suitably stored at the site for subsequent incorporation in the completed construction (or, if approved in advance by the Owner, suitably stored off the site at a location agreed upon in writing), less retainage; 5.6.3 Subtract the aggregate of previous payments made by the Owner; and 5.6.4 Subtract amounts, if any, for which the Director of Project Management has withheld or nullified a Certificate for Payment as provided in Paragraph 9.5 of the General Conditions. AGREEMENT 00500-Page 3 of 23 5.7 Retainage of ten percent (10%) will be withheld in accordance with Section 218.735 (8)(b), Florida Statutes.. 5.8 Reduction or limitation of retainage, if any, shall be as follows: Monroe County is exempt from and not subject to Florida Statutes, Section 255.078, "Public Construction Retainage". Reduction or limitation of retainage, if any, shall be reduced incrementally at the discretion of and upon the approval of the Director of Project Management. ARTICLE 6 Final Payment Final payment, constituting the entire unpaid balance of the Contract Sum, shall be made by the Owner to the Contractor when (1) the Contract has been fully performed by the Contractor except for the Contractor's responsibility to correct nonconforming Work as provided in Subparagraph 12.2.2 of the General Conditions and to satisfy other requirements, if any, which necessarily survive final payment, and (2) a final approval for payment has been issued by the Director of Project Management. Such final payment shall be made by the Owner not more than twenty (20) days after the issuance of the final approval for payment. The following documents (samples in section 01027, Application for Payment) are required for Final Payment: (1)Application and Certificate for Payment (2) Continuation Sheet • (3) Certificate of Substantial Completion (4) Contractor's Affidavit of Debts and Claims (5) Contractor's Affidavit of Release of Liens (6) Final Release of Lien (7) Contractor shall provide two (2) hard copies in tabulated divided binders and one (1) saved electronically tabbed and indexed in Adobe Acrobat file (.PDF) format delivered on a common form (i.e. flash drive) of all the following, but not limited to: A. Project Record Documents (As Built Documents). B. Operating and maintenance data, instructions to the Owner's personnel. C. Warranties, bond and guarantees. D. Keys and keying schedule. E. Spare parts and maintenance materials. F. Electronic copies of approved submittals. G. Evidence of payment and final release of liens and consent of surety to final release(includes final release from all utilities and utility companies). ARTICLE 7 Miscellaneous Provisions AGREEMENT 00500-Page 4 of 23 7.1 Where reference is made in this Agreement to a provision of the General Conditions or another Contract Document,- the.reference refers--to- that provision as amended or supplemented by other provisions of the Contract Documents. 7.2 Payment shall be made according to the Florida Local Government Prompt Payment Act and Monroe County Code. 7.3 Temporary facilities and services: As described in Section 01500, Temporary Facilities, of the General Conditions. 7.4 Monroe County's performance and obligation to pay under this contract is contingent upon an annual appropriation by the Board of County Commissioners. 7.5 A person or affiliate who has been placed on the convicted vendor list following a conviction for public entity crime may not submit a bid on a contract to provide any goods or services to a public entity, may not submit a proposal on a contract with a public entity for the construction or repair of a public building or public work, may not submit proposals on leases of real property to public entity, may not be awarded or perform work as contractor, supplier, subcontractor, or consultant under a contract with any public entity, and may not transact business with any public entity in excess of the threshold amount provided in Section 287.017, for CATEGORY TWO for a period of thirty-six(36) months from the date of being placed on the convicted vendor list. By signing this Agreement, Contractor represents that the execution of this Agreement will not violate the Public Entity Crimes Act(Section 287.133, Florida Statutes). Violation of this section shall result in termination of this Agreement and recovery of all monies paid hereto, and may result in debarment from County's competitive procurement activities. In addition to the foregoing, Contractor further represents that there has been no determination, based on an audit, that it or any subcontractor has committed an act defined by Section 287.133, Florida Statutes, as a "public entity crime" and that it has not been formally charged with committing an act defined as a "public entity crime" regardless of the amount of money involved or whether Contractor has been placed on the convicted vendor list. Contractor will promptly notify the County if it or any subcontractor or Contractor is formally charged with an act defined as a "public entity crime" or has been placed on the convicted vendor list. 7.6 The following items are included in this contract: a) Maintenance of Records. Contractor shall maintain all books, records, and documents directly pertinent to performance under this Agreement in accordance with generally accepted accounting principles consistently applied. Records shall be retained for a period of five (5) years from the termination of this agreement or for a period of three (3) years from the submission of the final expenditure report as per 2 C.F.R. §200.333, whichever is greater. Each party to this Agreement or their authorized representatives shall have reasonable and timely access to such records AGREEMENT 00500-Page 5 of 23 of each other party to this Agreement for public records purposes during the term of the Agreement and for five (5) years following the termination of this Agreement. If an auditor- employed by the County- or Clerk determines--that -monies paid to Contractor pursuant to this Agreement were spent for purposes not authorized by this Agreement, or were wrongfully retained by the Contractor, the Contractor shall repay the monies together with interest calculated pursuant to Sec. 55.03, Florida Statutes, running from the date the monies were paid to Contractor. b) Governing Law, Venue, Interpretation, Costs, and Fees, This Agreement shall be governed by and construed in accordance with the laws of the State of Florida applicable to contracts made and to be performed entirely in the State. In the event that any cause of action or administrative proceeding is instituted for the enforcement or interpretation of this Agreement, the County and Contractor agree that venue shall lie in the appropriate court or before the appropriate administrative body in Monroe County, Florida. The Parties waive their rights to trial by jury. The County and Contractor agree that, in the event of conflicting interpretations of the terms or a term of this Agreement by or between any of them the issue shall be submitted to mediation prior to the institution of any other administrative or legal proceeding. c) Severability. If any term, covenant, condition or provision of this Agreement (or the application thereof to any circumstance or person) shall be declared invalid or unenforceable to any extent by a court of competent jurisdiction, the remaining terms, covenants, conditions and provisions of this Agreement, shall not be affected thereby; and each remaining term, covenant, condition and provision of this Agreement shall be valid and shall be enforceable to the fullest extent permitted by law unless the enforcement of the remaining terms, covenants, conditions and provisions of this Agreement would prevent the accomplishment of the original intent of this Agreement. The County and Contractor agree to reform the Agreement to replace any stricken provision with a valid provision that comes as close as possible to the intent of the stricken provision. d) Attorney's Fees and Costs. The County and Contractor agree that in the event any cause of action or administrative proceeding is initiated or defended by any party • relative to the enforcement or interpretation of this Agreement, the prevailing party shall be entitled to reasonable attorney's fees and court costs as an award against the non-prevailing party, and shall include attorney's fees and courts costs in appellate proceedings. e) Binding Effect. The terms, covenants, conditions, and provisions of this Agreement shall bind and inure to the benefit of the County and Contractor and their respective legal representatives, successors, and assigns. f) Authority. Each party represents and warrants to the other that the execution, delivery and performance of this Agreement have been duly authorized by all necessary County and corporate action, as required by law. Each party agrees that it has had ample opportunity to submit this Contract to legal counsel of its choice and enters into this agreement freely, voluntarily and with advice of counsel. g) Claims for Federal or State Aid. Contractor and County agree that each shall be, and is, empowered to apply for, seek, and obtain federal and state funds to further the AGREEMENT 00500- Page 6 of 23 purpose of this Agreement; provided that all applications, requests, grant proposals, and funding solicitations shall be approved by each party prior to submission. h) Adjudication of Disputes or Disagreements. County and Contractor agree that all disputes and disagreements shall be attempted to be resolved by meet and confer sessions between representatives of each of the parties. If the issue or issues are still not resolved to the satisfaction of the parties, then any party shall have the right to seek such relief or remedy as may be provided by this Agreement or by Florida law. This Agreement is not subject to arbitration. i) Cooperation. In the event any administrative or legal proceeding is instituted against either party relating to the formation, execution, performance, or breach of this Agreement, County and Contractor agree to participate, to the extent required by the other party, in all proceedings, hearings, processes, meetings, and other activities related to the substance of this Agreement or provision of the services under this Agreement. County and Contractor specifically agree that no party to this Agreement shall be required to enter into any arbitration proceedings related to this Agreement. j) Nondiscrimination. The parties agree that there will be no discrimination against any person, and it is expressly understood that upon a determination by a court of competent jurisdiction that discrimination has occurred, this Agreement automatically terminates without any further action on the part of any party, effective the date of the court order. The parties agree to comply with all Federal and Florida statutes, and all local ordinances, as applicable, relating to nondiscrimination. These include but are not limited to: 1) Title VII of the Civil Rights Act of 1964 (PL 88-352), which prohibits discrimination in employment on the basis of race, color, religion, sex, and national origin; 2) Title IX of the Education Amendment of 1972, as amended (20 USC §§ 1681-1683, and 1685-1686), which prohibits discrimination on the basis of sex; 3) Section 504 of the Rehabilitation Act of 1973, as amended (20 USC §794), which prohibits discrimination on the basis of handicaps; 4) The Age Discrimination Act of 1975, as amended (42 USC §§ 6101-6107), which prohibits discrimination on the basis of age; 5) The Drug Abuse Office and Treatment Act of 1972 (PL 92-255), as amended, relating to nondiscrimination on the basis of drug abuse; 6)The Comprehensive Alcohol Abuse and Alcoholism Prevention, Treatment and Rehabilitation Act of 1970 (PL 91-616), as amended, relating to nondiscrimination on the basis of alcohol abuse or alcoholism; 7) The Public Health Service Act of 1912, §§ 523 and 527 (42 USC §§ 690dd-3 and 290ee-3), as amended, relating to confidentiality of alcohol and drug abuse patent records; 8) Title VIII of the Civil Rights Act of 1968 (42 USC §§ 3601 et seq.), as amended, relating to nondiscrimination in the sale, rental or financing of housing; 9) The Americans with Disabilities Act of 1990 (42 USC §§ 12101), as amended from time to time, relating to nondiscrimination in employment on the basis of disability; 10) Monroe County Code Chapter 14, Article II, which prohibits discrimination on the basis of race, color, sex, religion, national origin, ancestry, sexual orientation, gender identity or expression, familial status or age; and 11) any other nondiscrimination provisions in any federal or state statutes which may apply to the parties to, or the subject matter of, this Agreement. AGREEMENT 00500-Page 7 of 23 During the performance of this Agreement, the CONTRACTOR, in accordance with Equal Employment Opportunity(30 Fed. Reg. 12319, 12935, 3 C.F.R. Part, 1964-1965 Comp., p. 339), as amended by Executive-Order 11375, Amending Executive Order 11246 Relating to Equal Employment Opportunity, and implementing regulations at 41C.F.R. Part 60 (Office of Federal Contract Compliance Programs, Equal Employment Opportunity, Department of Labor). See 2 C.F.R. Part 200, Appendix II,¶ C, agrees as follows: 1) The contractor will not discriminate against any employee or applicant for employment because of race, color, religion, sex, sexual orientation, gender identity, or national origin. The contractor will take affirmative action to ensure that applicants are employed, and that employees are treated during employment, without regard to their race, color, religion, sex, sexual orientation, gender identity, or national origin. Such action shall include, but not be limited to the following: Employment, upgrading, demotion, or transfer, recruitment or recruitment advertising; layoff or termination; rates of pay or other forms of compensation; and selection for training, including apprenticeship. The contractor agrees to post in conspicuous places, available to employees and applicants for employment, notices to be provided by the contracting officer setting forth the provisions of this nondiscrimination clause. 2) The contractor will, in all solicitations or advertisements for employees placed by or on behalf of the contractor, state that all qualified applicants will receive consideration for employment without regard to race, color, religion, sex, sexual orientation, gender identity, or national origin. 3) The contractor will not discharge or in any other manner discriminate against any employee or applicant for employment because such employee or applicant has inquired about, discussed, or disclosed the compensation of the employee or applicant or another employee or applicant. This provision shall not apply to instances in which an employee who has access to the compensation information of other employees or applicants as a part of such employee's essential job functions discloses the compensation of such other employees or applicants to individuals who do not otherwise have access to such information, unless such disclosure is in response to a formal complaint or charge, in furtherance of an investigation, proceeding, hearing, or action, including an investigation conducted by the employer, or is consistent with the contractor's legal duty to furnish information. 4) The contractor will send to each labor union or representative of workers with which it has a collective bargaining agreement or other contract or understanding, a notice to be provided by the agency contracting officer, advising the labor union or workers' representative of the contractor's commitments under section 202 of Executive Order 11246 of September 24, 1965, and shall post copies of the notice in conspicuous places available to employees and applicants for employment. AGREEMENT. 00500-Page 8 of 23 5) The contractor will comply with all provisions of Executive Order 11246 of September 24, 1965, and of the rules, regulations, and relevant orders of the - - - Secretary of Labor.-- - - - - - - 6) The contractor will furnish all information and reports required by Executive Order 11246 of September 24, 1965, and by the rules, regulations, and orders of the Secretary of Labor, or pursuant thereto, and will permit access to his books, records, and accounts by the contracting agency and the Secretary of Labor for purposes of investigation to ascertain compliance with such rules, regulations, and orders. 7) In the event of the contractor's non-compliance with the nondiscrimination clauses of this contract or with any of such rules, regulations, or orders, this contract may be canceled, terminated or suspended in whole or in part and the contractor may be declared ineligible for further Government contracts or federally assisted construction contracts in accordance with procedures authorized in Executive Order 11246 of September 24, 1965, and such other sanctions may be imposed and remedies invoked as provided in Executive Order 11246 of September 24, 1965, or by rule, regulation, or order of the Secretary of Labor, or as otherwise provided by law. 8) The Contractor will include the portion of the sentence immediately preceding paragraph (1) and the provisions of paragraphs (1) through (8) in every subcontract or purchase order unless exempted by rules, regulations, or orders of the Secretary of Labor issued pursuant to section 204 of Executive Order 11246 of September 24, 1965, so that such provisions will be binding upon each subcontractor or vendor. The Contractor will take such action with respect to any subcontract or purchase order as the administering agency may direct as a means of enforcing such provisions, including sanctions for non-compliance; provided, however, that in the event a contractor becomes involved in, or is threatened with, litigation with a subcontractor or vendor as a result of such direction by the administering agency the contractor may request the United States to enter into such litigation to protect the interests of the United States. k) Covenant of No Interest. County and Contractor covenant that neither presently has any interest, and shall not acquire any interest, which would conflict in any manner or degree with its performance under this Agreement, and that only interest of each is to perform and receive benefits as recited in this Agreement. I) Code of Ethics. County agrees that officers and employees of the County recognize and will be required to comply with the standards of conduct for public officers and employees as delineated in Section 112.313, Florida Statutes, regarding, but not limited to, solicitation or acceptance of gifts; doing business with one's agency; unauthorized compensation; misuse of public position, conflicting employment or contractual relationship; and disclosure or use of certain information. m) No Solicitation/Payment. The County and Contractor warrant that, in respect to itself, it has neither employed nor retained any company or person, other than a AGREEMENT 00500-Page 9 of 23 bona fide employee working solely for it, to solicit or secure this Agreement and that it has not paid or agreed to pay any person, company, corporation, individual, or firm, other than -a--bona- fide employee working- solely -for it, any fee,--commission, percentage, gift, or other consideration contingent upon or resulting from the award or making of this Agreement. For the breach or violation of the provision, the Contractor agrees that the County shall have the right to terminate this Agreement without liability and, at its discretion, to offset from monies owed, or otherwise recover, the full amount of such fee, commission, percentage, gift, or consideration. n) Public Access. Public Records Compliance. Contractor must comply with Florida public records laws, including but not limited to Chapter 119, Florida Statutes and Section 24 of article I of the Constitution of Florida. The County and Contractor shall allow and permit reasonable access to, and inspection of, all documents, records, papers, letters or other"public record" materials in its possession or under its control subject to the provisions of Chapter 119, Florida Statutes, and made or received by the County and Contractor in conjunction with this contract and related to contract performance. The County shall have the right to unilaterally cancel this contract upon violation of this provision by the Contractor. Failure of the Contractor to abide by the terms of this provision shall be deemed a material breach of this contract and the County may enforce the terms of this provision in the form of a court proceeding and shall, as a prevailing party, be entitled to reimbursement of all attorney's fees and costs associated with that proceeding. This provision shall survive any termination or expiration of the contract. The Contractor is encouraged to consult with its advisors about Florida Public Records Law in order to comply with this provision. Pursuant to Fla. Stat., Sec. 119.0701 and the terms and conditions of this contract, the Contractor is required to: (1) Keep and maintain public records that would be required by the County to perform the service. (2) Upon receipt from the County's custodian of records, provide the County with a copy of the requested records or allow the records to be inspected or copied within a reasonable time at a cost that does not exceed the cost provided in this chapter or as otherwise provided by law. (3) Ensure that public records that are exempt or confidential and exempt from public records disclosure requirements are not disclosed except as authorized by law for the duration of the contract term and following completion of the contract if the contractor does not transfer the records to the County. (4) Upon completion of the contract, transfer, at no cost, to the County all public records in possession of the Contractor or keep and maintain public records that would be required by the County to perform the service. If the Contractor transfers all public records to the County upon completion of the contract, the Contractor shall destroy any duplicate public records that are exempt or confidential and exempt from public records disclosure AGREEMENT 00500-Page 10 of 23 requirements. If the Contractor keeps and maintains public records upon completion of the contract, the Contractor shall meet all applicable - - - requirements for retaining -public records. All records stored electronically- must be provided to the County, upon request from the County's custodian of records, in a format that is compatible with the information technology systems of the County. (5) A request to inspect or copy public records relating to a County contract must be made directly to the County, but if the County does not possess the requested records, the County shall immediately notify the Contractor of the request, and the Contractor must provide the records to the County or allow the records to be inspected or copied within a reasonable time. If the Contractor does not comply with the County's request for records, the County shall enforce the public records contract provisions in accordance with the contract, notwithstanding the County's option and right to unilaterally cancel this contract upon violation of this provision by the Contractor. A Contractor who fails to provide the public records to the County or pursuant to a valid public records request within a reasonable time may be subject to penalties under Section 119.10, Florida Statutes. The Contractor shall not transfer custody, release, alter, destroy or otherwise dispose of any public records unless or otherwise provided in this provision or as otherwise provided by law. IF THE CONTRACTOR HAS QUESTIONS REGARDING THE APPLICATION OF CHAPTER 119, FLORIDA STATUTES, TO THE CONTRACTOR'S DUTY TO PROVIDE PUBLIC RECORDS RELATING TO THIS CONTRACT, CONTACT THE CUSTODIAN OF PUBLIC RECORDS, BRIAN BRADLEY AT PHONE# 305-292-3470 BRADLEY- BRIAN@MONROECOUNTY-FL.GOV, MONROE COUNTY ATTORNEY'S OFFICE 1111 12TH Street, SUITE 408, KEY WEST, FL 33040. o) Non-Waiver of Immunity. Notwithstanding the provisions of Sec. 768.28, Florida Statutes, the participation of the Contractor and the County in this Agreement and the acquisition of any commercial liability insurance coverage, self-insurance coverage, or local government liability insurance pool coverage shall not be deemed a waiver of immunity to the extent of liability coverage, nor shall any contract entered into by the County be required to contain any provision for waiver. p) Privileges and Immunities. All of the privileges and immunities from liability, exemptions from laws, ordinances, and rules and pensions and relief, disability, workers' compensation, and other benefits which apply to the activity of officers, agents, or employees of any public agents or employees of the County, when performing their respective functions under this Agreement within the territorial limits of the County shall apply to the same degree and extent to the performance of such functions and duties of such officers, agents, volunteers, or employees outside the territorial limits of the County. AGREEMENT 00500-Page 11 of 23 q) Legal Obligations and Responsibilities: Non-Delegation of Constitutional or Statutory Duties. This Agreement is not intended to, nor shall it be construed as, relieving any - - - participating entity from.any obligation or responsibility imposed upon the entity by law except to the extent of actual and timely performance thereof by any participating entity, in which case the performance may be offered in satisfaction of the obligation or responsibility. Further, this Agreement is not intended to, nor shall it be construed as, authorizing the delegation of the constitutional or statutory duties of the County, except to the extent permitted by the Florida constitution, state statute, and case law. r) Non-Reliance by Non-Parties. No person or entity shall be entitled to rely upon the terms, or any of them, of this Agreement to enforce or attempt to enforce any third- party claim or entitlement to or benefit of any service or program contemplated hereunder, and the County and the Contractor agree that neither the County nor the Contractor or any agent, officer, or employee of either shall have the authority to inform, counsel, or otherwise indicate that any particular individual or group of individuals, entity or entities, have entitlements or benefits under this Agreement separate and apart, inferior to, or superior to the community in general or for the purposes contemplated in this Agreement. s) Attestations. Contractor agrees to execute such documents as the County may reasonably require, to include a Public Entity Crime Statement, an Ethics Statement, and a Drug-Free Workplace Statement. • t) No Personal Liability. No covenant or agreement contained herein shall be deemed to be a covenant or agreement of any member, officer, agent or employee of Monroe County in his or her individual capacity, and no member, officer, agent or employee of Monroe County shall be liable personally on this Agreement or be subject to any personal liability or accountability by reason of the execution of this Agreement. u) Execution in Counterparts. This Agreement may be executed in any number of counterparts, each of which shall be regarded as an original, all of which taken together shall constitute one and the same instrument and any of the parties hereto may execute this Agreement by signing any such counterpart. v) Hold Harmless and Indemnification. Notwithstanding any minimum insurance requirements prescribed elsewhere in this agreement, Contractor shall defend, indemnify and hold the COUNTY and the COUNTY's elected and appointed officers and employees harmless from and against (i) any claims, actions or causes of action, (ii) any litigation, administrative proceedings, appellate proceedings, or other proceedings relating to any type of injury (including death), loss, damage, fine, penalty or business interruption, and (iii) any costs or expenses that may be asserted against, initiated with respect to, or sustained by, any indemnified party by reason of, or in connection with, (A) any activity of Contractor or any of its employees, agents, contractors or other invitees during the term of this Agreement, (B)the negligence or recklessness, intentional wrongful misconduct, errors or other wrongful act or omission of Contractor or any of its employees, agents, sub-contractors or other invitees, or (C) Contractor's default in respect of any of the obligations that it undertakes under the terms of this Agreement, except to the extent the claims, actions, causes of action, litigation, proceedings, costs or expenses arise from the intentional or sole negligent acts or omissions of the COUNTY or any of its AGREEMENT 00500-Page 12 of 23 employees, agents, contractors or invitees (other than Contractor). The monetary limitation of liability under this contract shall be not less than $1 million per occurrence pursuant to F. S. 725.06.-Insofar as the claims, actions,_causes of action, -- -_- - _ litigation, proceedings, costs or expenses relate to events or circumstances that occur during the term of this Agreement, this section will survive the expiration of the term of this Agreement or any earlier termination of this Agreement. In the event that the completion of the project (to include the work of others) is delayed or suspended as a result of the Contractor s failure to purchase or maintain the required insurance, the Contractor shall indemnify the County from any and all increased expenses resulting from such delay. Should any claims be asserted against the County by virtue of any deficiency or ambiguity in the plans and specifications provided by the Contractor, the Contractor agrees and warrants that the Contractor shall hold the County harmless and shall indemnify it from all losses occurring thereby and shall further defend any claim or action on the County's behalf. The first ten dollars ($10.00) of remuneration paid to the Contractor is for the indemnification provided for the above. FDEM Indemnification To the fullest extent permitted by law, the Contractor shall indemnify and hold harmless the Agency, the State of Florida, Department of Emergency Management, and its officers and employees, from liabilities, damages, losses and costs, including, but not limited to, reasonable attorney's fees, to the extent caused by the negligence, recklessness or intentional wrongful misconduct of the Contractor and persons employed or utilized by the Contractor in the performance of this Contract. This indemnification shall survive the termination of this Contract. Nothing contained in this paragraph is intended to nor shall it constitute a waiver of the State of Florida and the(County)Agency's sovereign immunity. w) Section Headings. Section headings have been inserted in this Agreement as a matter of convenience of reference only, and it is agreed that such section headings are not a part of this Agreement and will not be used in the interpretation of any provision of this Agreement. • x) Disadvantaged Business Enterprise (DBE) Policy and Obligation. It is the policy of the County that DBE's, as defined in C.F.R. Part 26, as amended, shall have the opportunity to participate in the performance of contracts financed in whole or in part with County funds under this agreement. The DBE requirements of applicable federal and state laws and regulations apply to this Agreement. The County and its Contractor agree to ensure that DBE's have the opportunity to participate in the performance of the Agreement. In this regard, all recipients and contractors shall take all necessary and reasonable steps in accordance with applicable federal and state laws and regulations to ensure that DBE's have the opportunity to compete and perform contracts. The County and Contractor and subcontractors shall not discriminate on the basis of race, color, national origin or sex in award and performance of contracts, entered pursuant to this Agreement. AGREEMENT 00500-Page 13 of 23 y) Agreements with Subcontractors. In the event that the Contractor subcontracts any or all of the work in this project to any third party, the Contractor specifically agrees - - - - to identify the COUNTY as an additional insured on all insurance policies required by the County. In addition, the Contractor specifically agrees that all agreements or contracts of any nature with his subcontractors shall include the COUNTY as additional insured. z) Florida Green Building Coalition Standards. Monroe County requires its buildings to conform to Florida Green Building Coalition standards. Special Conditions, if any are detailed in Section 00100 of the Project Manual for this Project. Right to Audit Availability of Records. The records of the parties to this Agreement relating to the Project, which shall include but not be limited to accounting records (hard copy, as well as computer readable data if it can be made available; subcontract files (including proposals of successful and unsuccessful bidders, bid recaps, bidding instructions, bidders list, etc); original estimates; estimating work sheets; correspondence; change order files (including documentation covering negotiated settlements); backcharge logs and supporting documentation; general ledger entries detailing cash and trade discounts earned, insurance rebates and dividends; any other supporting evidence deemed necessary by Owner or the Monroe County Office of the Clerk of Court and Comptroller(hereinafter referred to as"County Clerk") to substantiate charges related to this agreement, and all other agreements, sources of information and matters that may in Owner's or the County Clerk's reasonable judgment have any bearing on or pertain to any matters, rights, duties or obligations under or covered by any contract document (all foregoing hereinafter referred to as "Records") shall be open to inspection and subject to audit and/or reproduction by Owner's representative and/or agents or the County Clerk. Owner or County Clerk may also conduct verifications such as, but not limited to, counting employees at the job site, witnessing the distribution of payroll, verifying payroll computations, overhead computations, observing vendor and supplier payments, miscellaneous allocations, special charges, verifying information and amounts through interviews and written confirmations with employees, Subcontractors, suppliers, and contractors representatives. All records shall be kept for ten (10) years after Final Completion. The County Clerk possesses the independent authority to conduct an audit of Records, assets, and activities relating to this Project. If any auditor employed by the Monroe County or County Clerk determines that monies paid to Contractor pursuant to this Agreement were spent for purposes not authorized by this Agreement, the Contractor shall repay the monies together with interest calculated pursuant to Section 55.03, F.S., running form the date the monies were paid to Contractor. 7.7 Any written notices or correspondence given pursuant to this contract shall be sent by United States Mail, certified, return receipt requested, or by courier with proof of delivery. Notice shall be sent to the following persons: For Contractor: Yosvany Madruga, CEO 890 S.W. 69th Ave. Miami, FL 33144 AGREEMENT 00500-Page 14 of 23 For Owner: Director of Protect Management Assistant County Administrator, PW& E 1100 Simonton St., Room 2-216 1100 Simonton St. Key West,-FL 33040 - - - Key West, FL 33040-- 7.8 FEDERAL CONTRACT REQUIREMENTS The CONTRACTOR and its subcontractors must follow the provisions, as applicable, as set forth in 2 C.F.R. §200.326 Contract provisions and Appendix II to 2 C.F.R. Part 200, as amended, including but not limited to: 7.8.1 Clean Air Act and the Federal Water Pollution Control Act. CONTRACTOR agrees to comply with all applicable standards, orders, or regulations issued pursuant to the Clean Air Act(42 U.S.C. 7401-7671q) and the Federal Water Pollution Control Act as amended (33 U.S.C. 1251-1387) and will report violations to FEMA and the Regional Office of the Environmental Protection Agency (EPA). 7.8.2 Davis-Bacon Act, as amended (40 U.S.C. 3141-3148). When required by Federal program legislation, which includes emergency Management Preparedness Grant Program, Homeland Security Grant Program, Nonprofit Security Grant Program, Tribal Homeland Security Grant Program, Port Security Grant Program and Transit Security Grant Program, all prime construction contracts in excess of $2,000 awarded by non- Federal entities must comply with the Davis-Bacon Act (40 U.S.C. 31413144 and 3146- 3148) as supplemented by Department of Labor regulations (29 CFR Part 5, "Labor Standards Provisions Applicable to Contracts Covering Federally Financed and Assisted Construction"). In accordance with the statute, CONTRACTORS must be required to pay wages to laborers and mechanics at a rate not less than the prevailing wages specified in a wage determination made by the Secretary of Labor. In addition, CONTRACTORS must be required to pay wages not less than once a week. If applicable, the COUNTY must place a copy of the current prevailing wage determination issued by the Department of Labor in each solicitation attached hereto as Exhibit "A". The decision to award a contract or subcontract must be conditioned upon the acceptance of the wage determination. The COUNTY must report all suspected or reported violations to the Federal awarding agency. When required by Federal program legislation, which includes emergency Management Preparedness Grant Program, Homeland Security Grant Program, Nonprofit Security Grant Program, Tribal Homeland Security Grant Program, Port Security Grant Program and Transit Security Grant Program (it does not apply to other FEMA grant and cooperative agreement programs, including the Public Assistance Program), the CONTRACTORS must also comply with the Copeland "Anti-Kickback" Act (40 U.S.C. 3145), as supplemented by Department of Labor regulations (29 CFR Part 3, "Contractors and Subcontractors on Public Building or Public Work Financed in Whole or in Part by Loans or Grants from the United States"). As required by the Act, each CONTRACTOR or subrecipient is prohibited from inducing, by any means, any person employed in the construction, completion, or repair of public work, to give up any part of the compensation to which he or she is otherwise entitled. The COUNTY must report all suspected or reported violations to the Federal awarding agency. 1) The CONTRACTOR shall comply with 18 U.S.C. § 874, 40 U.S.C. § 3145, and the requirements of 29 C.F.R. pt. 3 as may be applicable, which are incorporated by reference into this contract. 2) Subcontracts. The CONTRACTOR or subcontractor shall insert in any subcontracts the clause above and such other clauses as the FEMA may by appropriate AGREEMENT 00500-Page 15 of 23 instructions require, and also a clause requiring the subcontractors to include these clauses in any lower tier subcontracts. The prime CONTRACTOR shall be responsible for the compliance by any--subcontractor or lower tier--subcontractor with all of--these - contract clauses. 3) Breach. A breach of the contract clauses above may be grounds for termination of the contract, and for debarment as a contractor and subcontractor as provided in 29 C.F.R. § 5.12. 7.8.3 Contract Work Hours and Safety Standards Act (40 U.S.C. 3701-3708). Where applicable, which includes all FEMA grant and cooperative agreement programs, all contracts awarded by the COUNTY in excess of $100,000 that involve the employment of mechanics or laborers must comply with 40 U.S.C. 3702 and 3704, as supplemented by Department of Labor regulations (29 CFR Part 5). Under 40 U.S.C. 3702 of the Act, each CONTRACTOR must compute the wages of every mechanic and laborer on the basis of a standard work week of forty (40) hours. Work in excess of the standard work week is permissible provided that the worker is compensated at a rate of not less than one and a half times the basic rate of pay for all hours worked in excess of forty (40) hours in the work week. The requirements of 40 U.S.C. 3704 are applicable to construction work and provide that no laborer or mechanic must be required to work in surroundings or under working conditions which are unsanitary, hazardous, or dangerous. These requirements do not apply to the purchases of supplies or materials or articles ordinarily available on the open market, or contracts for transportation or transmission of intelligence. 7.8.4 Rights to Inventions Made Under a Contract or Agreement. If the Federal award meets the definition of "funding agreement" under 37 CFR §401.2 (a) and the recipient or subrecipient wishes to enter into a contract with a small business firm or nonprofit organization regarding the substitution of parties, assignment or performance of experimental, developmental, or research work under that "funding agreement," the recipient or subrecipient must comply with the requirements of 37 CFR Part 401, "Rights to Inventions Made by Nonprofit Organizations and Small Business Firms Under Government Grants, Contracts and Cooperative Agreements," and any implementing regulations issued by the awarding agency. 7.8.5 Clean Air Act (42 U.S.C. 7401-7671g.), Water Pollution Control Act (33 U.S.C. 1251- 1387) as amended. Contracts and subgrants of amounts in excess of $150,000 must comply with all applicable standards, orders, or regulations issued pursuant to the Clean Air Act(42 U.S.C. 7401-7671q) and the Federal Water Pollution Control Act as amended (33 U.S.C. 1251-1387). Violations must be reported to the Federal awarding agency and the Regional Office of the Environmental Protection Agency (EPA). 7.8.6 Debarment and Suspension (Executive Orders 12549 and 12689). A contract award (see 2 CFR 180.220) must not be made to parties listed on the government wide exclusions in the System for Award Management (SAM), in accordance with the OMB guidelines at 2 CFR 180 that implement Executive Orders 12549 (3 CFR part 1986 Comp., p. 189) and 12689 (3 CFR part 1989 Comp., p. 235), "Debarment and Suspension." SAM Exclusions contains the names of parties debarred, suspended, or otherwise excluded by agencies, as well as parties declared ineligible under statutory or regulatory authority other than Executive Order 12549. AGREEMENT 00500- Page 16 of 23 7.8.7 Byrd Anti-Lobbying Amendment (31 U.S.C. 1352). CONTRACTORS that apply or bid for an award exceeding $100,000 must file the required certification. Each tier certifies to the tier above that- it will not and has not used Federal appropriated-funds to pay any _ person or organization for influencing or attempting to influence an officer or employee of any agency, a member of Congress, officer or employee of Congress, or an employee of a member of Congress in connection with obtaining any Federal contract, grant or any other award covered by 31 U.S.C. 1352. Each tier must also disclose any lobbying with non-Federal funds that takes place in connection with obtaining any Federal award. Such disclosures are forwarded from tier to tier up to the non-Federal award. 7.8.8 Compliance with Procurement of recovered materials as set forth in 2 CFR § 200.322. CONTRACTOR must comply with section 6002 of the Solid Waste disposal Act, as amendment by the Resource Conservation and Recovery Act. The requirements of Section 6002 include procuring only items designed in guidelines of the Environmental Protection Agency (EPA at 40 CPR part 247 that contain the highest percentage of recovered materials practicable, consistent with maintaining a satisfactory level of competition, where the purchase price of the item exceeds $10,000 or the value of the quantity acquired during the preceding fiscal year exceeded $10,000; procuring solid waste management services in a manner that maximizes energy and resource recovery; and establishing an affirmative procurement program for procurement of recovered materials identified in the EPA guidelines. (1) In the performance of this contract, the CONTRACTOR shall make maximum use of products containing recovered materials that are EPA-designated items unless the product cannot be acquired (i) Competitively within a timeframe providing for compliance with the contract performance schedule; (ii) Meeting contract performance requirements; or(iii) At a reasonable price. (2) Information about this requirement, along with the list of EPA-designated items, is available at EPA's Comprehensive Procurement Guidelines web site, https://www.epa.gov/smm/comprehensive-procurement-guideline-cpq-proq ram. Other Federal Requirements (as applicable): 7.8.9 Americans with Disabilities Act of 1990, as amended, (ADA). The CONTRACTOR will comply with all the requirements as imposed by the ADA, the regulations of the Federal government issued thereunder, and the assurance by the CONTRACTOR pursuant thereto. • 7.8.10 Disadvantaged Business Enterprise (DBE) Policy and Obligation. It is the policy of the COUNTY that DBE's, as defined in 49 C.F.R. Part 26, as amended, shall have the opportunity to participate in the performance of contracts financed in whole or in part with COUNTY funds under this Agreement. The DBE requirements of applicable federal and state laws and regulations apply to this Agreement. The COUNTY and its CONTRACTOR agree to ensure that DBE's have the opportunity to participate in the performance of this Agreement. In this regard, all recipients and contractors shall take all necessary and reasonable steps in accordance with 2 C.F.R. § 200.321( as set forth in detail below), applicable federal and state laws and regulations to ensure that the DBE's have the opportunity to compete for and perform contracts. The COUNTY and the CONTRACTOR and subcontractors shall not discriminate on the basis of race, color, national origin or sex in the award and performance of contracts, entered pursuant to this Agreement. AGREEMENT 00500-Page 17 of 23 2 C.F.R. § 200.321 CONTRACTING WITH SMALL AND MINORITY BUSINESSES, WOMEN'S BUSINESS ENTERPRISES, AND LABOR SURPLUS AREA FIRMS - -- -- - a. If the CONTRACTOR, with the funds authorized by this Agreement, seeks to subcontract goods or services, then, in accordance with 2 C.F.R. §200.321, the CONTRACTOR shall take the following affirmative steps to assure that minority businesses, women's business enterprises, and labor surplus area firms are used whenever possible. b. Affirmative steps must include: 1. Placing qualified small and minority businesses and women's business enterprises on solicitation lists; 2. Assuring that small and minority businesses, and women's business enterprises are solicited whenever they are potential sources; 3. Dividing total requirements, when economically feasible, into smaller tasks or quantities to permit maximum participation by small and minority businesses, and women's business enterprises; 4. Establishing delivery schedules, where the requirement permits, which encourage participation by small and minority businesses, and women's business enterprises; 5. Using the services and assistance, as appropriate, of such organizations as the Small Business Administration and the Minority Business Development Agency of the Department of Commerce. 6. Requiring the Prime contractor, if subcontractor are to be let, to take the affirmative steps listed in paragraph (1)through (5) of this section. 7.8.11 The CONTRACTOR shall utilize the U.S. Department of Homeland Security's E-Verify system to verify the employment eligibility of all new employees hired by the CONTRACTOR during the term of the Contract and shall expressly require any subcontractors performing work or providing services pursuant to the Contract to likewise utilize the U.S. Department of Homeland Security's E-Verify system to verify the employment eligibility of all new employees hired by the subcontractor during the Contract term. 7.8.12 Fraud and False or Fraudulent or Related Acts. The CONTRACTOR acknowledges that 31 U.S.C. Chap. 38 (Administrative Remedies for False Claims and Statements) applies to the CONTRACTOR'S actions pertaining to this contract. 7.8.13 Access to Records. The following access to records requirements apply to this contract: (1) The CONTRACTOR agrees to provide MONROE COUNTY, the FEMA Administrator, the Comptroller General of the United States, or any of their authorized representatives access to any books, documents, papers, and records of the CONTRACTOR which are directly pertinent to this contract for the purposes of making audits, examinations, excerpts, and transcriptions. (2) The CONTRACTOR agrees to permit any of the foregoing parties to reproduce by any means whatsoever or to copy excerpts and transcriptions as reasonably needed. (3) The CONTRACTOR agrees to provide the FEMA Administrator or his authorized representatives access to construction or other work sites pertaining to the work being completed under the contract. AGREEMENT 00500-Page 18 of 23 7.9 The CONTRACTOR is bound by the terms and conditions of the Federally-Funded Subaward and Grant Agreement between County and the Florida Division of Emergency Management(Division) and attached hereto as Exhibit"B": 7.10 The Contractor is bound by all applicable local, County, State, and Federal laws and regulations. 7.11 The CONTRACTOR shall hold the Division and County harmless against all claims of whatever nature arising out of the CONTRACTOR'S performance of work under this Agreement, to the extend allow and required by law. ARTICLE 8 Termination or Suspension 8.1 The Contract may be terminated by the Owner as provided in Article 14 of the General Conditions. A. In the event that the CONTRACTOR shall be found to be negligent in any aspect of service, the COUNTY shall have the right to terminate this agreement after five days written notification to the CONTRACTOR. B. Either of the parties hereto may cancel this Agreement without cause by giving the other party sixty (60) days written notice of its intention to do so. C. Termination for Cause and Remedies: In the event of breach of any contract terms, the COUNTY retains the right to terminate this Agreement. The COUNTY may also terminate this agreement for cause with CONTRACTOR should CONTRACTOR fail to perform the covenants herein contained at the time and in the manner herein provided. In the event of such termination, prior to termination, the COUNTY shall provide CONTRACTOR with seventy-two (72) hours' notice and provide the CONTRACTOR with an opportunity to cure the breach that has occurred. If the breach is not cured, the Agreement will be terminated for cause. If the COUNTY terminates this agreement with the CONTRACTOR, COUNTY shall pay CONTRACTOR the sum due the CONTRACTOR under this agreement prior to termination, unless the cost of completion to the COUNTY exceeds the funds remaining in the contract; however, the COUNTY reserves the right to assert and seek an offset for damages caused by the breach. The maximum amount due to CONTRACTOR shall not in any event exceed the spending cap in this Agreement. In addition, the COUNTY reserves all rights available to recoup monies paid under this Agreement, including the right to sue for breach of contract and including the right to pursue a claim for violation of the COUNTY's False Claims Ordinance, located at Section 2-721 et al. of the Monroe County Code. D. Termination for Convenience: The COUNTY may terminate this Agreement for convenience, at any time, upon sixty (60) days' notice to CONTRACTOR. If the COUNTY terminates this agreement with the CONTRACTOR, COUNTY shall pay CONTRACTOR the sum due the CONTRACTOR under this agreement prior to termination, unless the cost of completion to the COUNTY exceeds the funds remaining in the contract. The maximum amount due to CONTRACTOR shall not AGREEMENT 00500-Page 19 of 23 exceed the spending cap in this Agreement. In addition, the COUNTY reserves all rights available to recoup monies paid under this Agreement, including the right to sue for breach of contract and including the right to pursue_a claim for violation of the COUNTY's False Claims Ordinance, located at Section 2-721 et al. of the Monroe County Code. 8.2 For Contracts of any amount, if the County determines that the Contractor/Consultant has submitted a false certification under Section 287.135(5), Florida Statutes or has been placed on the Scrutinized Companies that Boycott Israel List, or is engaged in a boycott of Israel, the County shall have the option of(1) terminating the Agreement after it has given the Contractor/Consultant written notice and an opportunity to demonstrate the agency's determination of false certification was in error pursuant to Section 287.135(5)(a), Florida Statutes, or (2) maintaining the Agreement if the conditions of Section 287.135(4), Florida Statutes, are met. For Contracts of $1,000,000 or more, if the County determines that the Contractor/Consultant submitted a false certification under Section 287.135(5), Florida Statutes, or if the Contractor/Consultant has been placed on the Scrutinized Companies with Activities in the Sudan List, the Scrutinized Companies with Activities in the Iran Petroleum Energy Sector List or been engaged in business operations in Cuba or Syria, the County shall have the option of (1) terminating the Agreement after it has given the Contractor/Consultant written notice and an opportunity to demonstrate the agency's determination of false certification was in error pursuant to Section 287.135(5)(a), Florida Statutes, or (2) maintaining the Agreement if the conditions of Section 287.135(4), Florida Statutes, are met. ARTICLE 9 Enumeration of Contract Documents 9.1 The Contract Documents, except for Modifications issued after execution of this Agreement, are enumerated as follows: a) Drawings: None b) Project Manual: None c) Documents: None 9.1.1 The Agreement is this executed Standard Form of Agreement Between Owner and Contractor. 9.1.2 The General Conditions are the General Conditions of the Contract for Construction. 9.1.3 The Supplementary and other Conditions of the Contract are those contained in the Project Manual dated: None 9.1.4 The Addenda, if any, are as follows: Number Date Page 1 4/19/19 1 AGREEMENT 00500-Page 20 of 23 This Agreement is entered into as of the day and year first written above and is executed in at least one(1) original copy. A copy will be delivered to the Contractor. SIGNATURE PAGE TO FOLLOW AGREEMENT 00500-Page 21 of 23 Execution by the Contractor must be by a person with authority to bind the entity. SIGNATURE OF THE PERSON EXECUTING THE DOCUMENT MUST BE NOTARIZED. (SEAL) BOARD OF COUNTY COMMISSIONERS Attest: Kevin Madok, Clerk OF MONRO.v OUN LORIDA 4' . l / • By:c-7 / -� �: `3 =-puty Clerk Mayor/Chairman Y:? cy rf�` `y N.„.......,'. - s RACTOR'S Witnesses Attest: CONTRACT R:�r I SeN4A‘a-S I�Uf� ontractor must provide witnesses 1 signatures Signature: c Signature: Print Nam : D Mil, AO(tit ' ' O=o Print Name: �t°H rift?' Title: y-ef/d"h xc- `fl ,. -,-•, / ,rt. 7 c� Title: & -C-6()( MC9/7 j7/K Date: 0/ 2/// DJ r; r -,, Date: / 2 l�I ✓ • } and C MONROE COUNTY ArFdRNEY 2 ` PP'•VED AS F RM us c - - Q Signature: (j1' /Print Name: / g i N a� CH IR S A ROSIO Title: (I' t p 9i/)A//r ASSISTAN COIN A ORNEY Date: v/® 1 / Date: ( /� 2 f f q I STATE OF f ORIDA, COUNTY OF /14 I Hy/I -I�(� 1 On this 2/ day of J V-I h e , 201 , before me, the undersigned notary public, ,pers ti lly.appearedi: known to me to be the person whose name is subscribed above or who produced /S L_ as identification, and acknowledged that he/she is the person who executed the above contract with Monroe County for MARATHON LIBRARY ILDING NEW ROOF AND REPAIRS for the purposes therein contained. Notary Public / &gr/30e� HECTORANTHONYGONZALEZ /� /, Commission#GG 311235 Print Name %�t°C (�" �i/ �///(7 a—e., Commission Expires 03-13-2023 7 ..„-¢ Bonded Through-Cynanotary My commission expires: l� J --/✓? 2,023 �O �° _'Florida-Notary Public End of Section 00500 AGREEMENT 00500- Page 22 of 23 GENERAL REQUIREMENTS Where Project Management is Not a Constructor Section 00750 General Conditions Section 00970 Project Safety and Health Plan Section 00980 Contractor Quality Control Plan Section 01015 Contractor's Use of the Premises Section 01027 Application for Payment Section 01030 Alternates Section 01040 Project Coordination Section 01045 Cutting and Patching Section 01050 Field Engineering Section 01200 Project Meetings Section 01301 Submittals Section 01310 Progress Schedules Section 01370 Schedule of Values Section 01385 Daily Construction Reports Section 01395 Request for Information—(RFI) Section 01410 Testing Laboratory Services Section 01421 Reference Standards and Definitions Section 01500 Temporary Facilities Section 01520 Construction Aids Section 01550 Access Roads and Parking Areas Section 01560 Temporary Controls Section 01590 Field Offices and Sheds Section 01595 Construction Cleaning Section 01600 Material and Equipment Section 01630 Post-Proposal Substitutions Section 01640 Product Handling Section 01700 Contract Closeout Section 01710 Final Cleaning Section 01720 Project Record Documents Section 01730 Operation and Maintenance Data Section 01740 Warranties MARATHON LIBRARY BUILDING NEW ROOF AND REPAIRS INSURANCE REQUIREMENTS Worker's Compensation Statutory Limits Employers Liability $500,000 Bodily Injury by Accident $500,000 Bodily Injury by Disease Policy Limits $500,000 Bodily Injury by Disease, each employee General Liability, including $500,000 Combined Single Limit Premises Operations Products and Completed Operations Blanket Contractual Liability Personal Injury Liability Vehicle Liability (Owned, non-owned, and hired vehicles) $300,000 Combined Single Limit If split limits are preferred: $200,000 per Person $300,000 per Occurrence $200,000 Property Damage The contract shall require a Public Construction bond equal to the contract cost. The bond must be issued by an A rated surety company doing business in the State of Florida. Hold Harmless and Indemnification. Notwithstanding any minimum insurance requirements prescribed elsewhere in this agreement, Contractor shall defend, indemnify and hold the COUNTY and the COUNTY's elected and appointed officers and employees harmless from and against (i) any claims, actions or causes of action, (ii) any litigation, administrative proceedings, appellate proceedings, or other proceedings relating to any type of injury (including death), loss, damage, fine, penalty or business interruption, and (iii) any costs or expenses that may be asserted against, initiated with respect to, or sustained by, any indemnified party by reason of, or in connection with, (A) any activity of Contractor or any of its employees, agents, contractors or other invitees during the term of this Agreement, (B) the negligence or recklessness, intentional wrongful misconduct, errors or other wrongful act or omission of Contractor or any of its employees, agents, sub-contractors or other invitees, or (C) Contractor's default in respect of any of the obligations that it undertakes under the terms of this Agreement, except to the extent the claims, actions, causes of action, litigation, proceedings, costs or expenses arise from the intentional or sole negligent acts or omissions of the COUNTY or any of its employees, agents, contractors or invitees (other than Contractor). The monetary limitation of liability under this contract shall be not less than $1 million per occurrence pursuant to F. S. 725.06. Insofar as the claims, actions, causes of action, litigation, proceedings, costs or expenses relate to events or circumstances that occur during the term of this Agreement, this section will survive the expiration of the term of this Agreement or any earlier termination of this Agreement. In the event that the completion of the project (to include the work of others) is delayed or suspended as a result of the Contractor s failure to purchase or maintain the required insurance, INSURANCE REQUIREMENTS AND FORMS 00130-Page 38 of 299 MARATHON LIBRARY BUILDING NEW ROOF AND REPAIRS the Contractor shall indemnify the County from any and all increased expenses resulting from such delay. Should any claims be asserted against the County by virtue of any deficiency or ambiguity in the plans and specifications provided by the Contractor, the Contractor agrees and warrants that the Contractor shall hold the County harmless and shall indemnify it from all losses occurring thereby and shall further defend any claim or action on the County's behalf. The first ten dollars ($10.00) of remuneration paid to the Contractor is for the indemnification provided for the above. The extent of liability is in no way limited to, reduced, or lessened by the insurance requirements contained elsewhere within this AGREEMENT. FDEM Indemnification To the fullest extent permitted by law, the Contractor shall indemnify and hold harmless the Agency, the State of Florida, Department of Emergency Management, and its officers and employees, from liabilities, damages, losses and costs, including, but not limited to, reasonable attorney's fees, to the extent caused by the negligence, recklessness or intentional wrongful misconduct of the Contractor and persons employed or utilized by the Contractor in the performance of this Contract. This indemnification shall survive the termination of this Contract. Nothing contained in this paragraph is intended to nor shall it constitute a waiver of the State of Florida and the (County) Agency's sovereign immunity. PROPOSER'S STATEMENT I understand the insurance that will be mandatory if awa ded the contract and will comply in full with all of the requirements herein. I fully accept the inde nification and hold armless and duty to defend as set out in this proposal. A-1 Property Services Group Inc PROPOSER Si na ure INSURANCE REQUIREMENTS AND FORMS 00130-Page 39 of 299 i r A OR ® CERTIFICATE OF LIABILITY INSURANCE DATE(MMIOD"YTY) 06/2512019 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER.THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND,EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S),AUTHORIZED REPRESENTATIVE OR PRODUCER,AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder Is an ADDITIONAL INSURED.the policy(ies)must have ADDITIONAL INSURED provisions or be_endorsed._ If SUBROGATION IS WAIVED,subject to the terms and conditions of the policy,certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER CONTACT Sandra LaRue NOVAE: Frank H.Furman,Inc. Fitt: (954)843•5050 I FAX wc.Not, (954)942-6310 1314 East Atlantic Blvd. -MAIL�A : sandra@funnaninsuranco.com P.O.Box 1927 INSURERS)AFFORDING COVERAGE HNC M Pompano Beach FL 33061 INSURER A: Lloyd's Syndicate 33(Hlscox) INSURED INSURER a. Travelers Casualty Ins Co of America 19046 A-1 Property Services Group,Inc INSURER c: Br(dgefield Casually Ins Co 10335 890 SW 69th Ave INSURER 0: INSURER E: Miami FL 33144 INSURER F: COVERAGES CERTIFICATE NUMBER: B:19 WC/18 GLAU UM REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED NOTWITHSTANDING ANY REQUIREMENT,TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN,THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS. EXCLUSIONS AND CONDITIONS OF SUCH POLICIES.LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. tNSR TYPE OF INSURANCE ADDL`SUBR POLICY EFF POLICY EXP INS° wvo POUCY NUMBER (MMIDDIYYYYI (MMIDONYYVY) UNITS X COMMERCIAL GENERAL LIABILITY EACH OCCURRENCE S 1,000,000 DAMAGE S RENTED 1000CLAIMS•MADE El OCCUR PREMISES lEa=onrencel S0 MED EXP(Any one person) S 5,000 A _ Y Y WCISCGL000209401 09/3012018 09/30/2019 PERSONAL BADVINJURY S 1,000,000 GEM-AGGREGATE LIMIT APPLIES PER: GENERAL AGGREGATE S 2,000,000 RPOLICY©JEIT PLOC PRODUCTS-COMP/OP AGG S 2,000,000 OTHER S AUTOMOBILE LIABILITY CEwOMa SINGLE LIMT S 1,000,000 f occident) X ANY AUTO BODILY INJURY(Per person) S B — OWNED SCHEDULED Y Y BA4H629064 08/17/2018 08/17/2019 BODILY INJURY(Per accident) S AUTOS OILY ` AUTOS X HIRED X NON-0WNED PROPERTY DAMAGE AUTOS ONLY AUTOS ONLY (Per pccdden0 PIP-Basic S 10,000 UMIIRELLAUAB X OCCUR EACHOCCURRENCE s 5,000,000 A X EXCESS UAB cLAIMM,LADE WCISCEL000209501 09/30/2018 09/30/2019 AGGREGATE S 5,000,000 DED I RETENTIONS S WORKERS COMPENSATION P OTI+ AND EMPLOYERS'LIABILITY XI STATUTE I I ER C ANY PROPRIETOR/PARTNER/EXECUTIVE Y� NIA 19648542 DSl01/2019 05101l2020 EL.FACHACCIDENT S 1,000,000 /W OFFICEEIMER EXCLUDED? (Mandatary In PIN) E.L.DISEASE•EA EMPLOYEE S 1,000,000 If yyees,describe under DESCRIPTION OF OPERATIONS belew E.L.DISEASE-POLE?LIMIT S 1,000,000 DESCRIPTION OF OPERATIONS!LOCATIONS!VEHICLES(ACORD 101,Additlonsl Remarks Schedule,may be attached lf more apace Is required) The Monroe County Board of County Commissioners,Its employees and officials are Included as additional Insured for General&Auto Liability as required by written contract.Waiver of Subrogation applies t c •- •Aufo l y as required by written contract it./ RBKe►1 WAPJN V • CERTIFICATE HOLDER CANCELLATION SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF,NOTICE WILL BE DELIVERED IN Monroe County BOCC ACCORDANCE WITH THE POLICY PROVISIONS. 500 Whitehead Street AUTHORIZED REPRESENTATIVE -n Key West FL 33040 442 1 C1 1988-2015 ACORD CORPORATION.All rights reserved. ACORD 25(2016103) The ACORD name and logo are registered marks of ACORD BOND NUMBER 3301801 'Men Hill DOCUMENT A312-2010 Performance Bond CONTRACTOR: SURETY: (Name,legal status and address) (Name, legal status and principal place of business) A-1 Property Services Group, Inc. FCCI Insurance Company 890 SW 69th Ave. 6300 University Parkway Miami, FL 33144 Sarasota, FL 34240 OWNER: (Name,legal status and address) Monroe County Board of County Commissioners 500 Whitehead Street Key West, FL 33144 CONSTRUCTION CONTRACT Date: Amount: $62,255.00 Description: (Name and Location) Marathon Library Building New Roof and Repairs BOND Date:July 9,2019 Amount: $62,255.00 Modifications to this Bond: ❑✓ None ❑ See Section 16 CONTR TOR AS P IN IPAL SURETY Compa,y: (Corporate Seal) Company: (Corporate Seal) A-1 Property Servi e Group, Inc. FCCI Insurance Company X: ' / _ � X: 'c'`�``-` • Na and Title:: Name and Title: Tina Man rm,Attorney-in-Fact. (An additional signatures appear on the last page of this Performance Bond.) (FOR INFORMATION ONLY—Name, Address and telephone AGENT or BROKER: OWNER'S REPRESENTATIVE: (Architect, Engineer or Other Party) Frank H. Furman, Inc 1314 East Atlantic Blvd., Pompano Beach, FL 33060 (954) 943-5050 • § 1 The Contractor and Surety,jointly and severally,bind themselves,their heirs,executors,administrators,successors and assigns to the Owner for the performance of the Construction Contract,which is incorporated herein by reference. §2 If the Contractor performs the Construction Contract,the Surety and the Contractor shall have no obligation under this Bond,except when applicable to participate in a conference as provided in Section 3. §3 If there is no Owner Default under the Construction Contract,the Surety's obligation under this Bond shall arise after .1 the Owner first provides notice to the Contractor and the Surety that the Owner is considering declaring a Contractor Default. Such notice shall indicate whether the Owner is requesting a conference among the Owner,Contractor and Surety to discuss the Contractor's performance.If the Owner does not request a conference,the Surety may,within five(5)business days after receipt of the Owner's notice,request such a conference.If the Surety timely requests a conference,the Owner shall attend.Unless the Owner agrees otherwise,any conference requested under this Section 3.1 shall be held within ten(10)business days of the Surety's receipt of the Owner's notice. If the Owner,the Contractor and the Surety agree,the Contractor shall be allowed a reasonable time to performnhe Construction Contract,but such an agreement shall not waive the Owner's right, if any,subsequently to declare a Contractor Default; .2 the Owner declares a Contractor Default,terminates the Construction Contract and notifies the Surety;and .3 the Owner has agreed to pay the Balance of the Contract Price in accordance with the terms of the Construction Contract to the Surety or to a contractor selected to perform the Construction Contract: §4 Failure on the part of the Owner to comply with the notice requirement in Section 3.1 shaIl not constitute a failure to comply with a condition precedent to the Surety's obligations,or release the Surety from its obligations,except to the extent the Surety demonstrates actual prejudice. §5 When the Owner has satisfied the conditions of Section 3,the Surety shall promptly and at the Surety's expense take one of the following actions: §5.1 Arrange for the Contractor,with the consent of the Owner,to perform and complete the Construction Contract; §5.2 Undertake to perform and complete the Construction Contract itself,through its agents or independent contractors; §5.3 Obtain bids or negotiated proposals from qualified contractors acceptable to the Owner for a contract for performance and completion of the Construction Contract,arrange for a contract to be prepared for execution by the Owner and a contractor selected with the Owner's concurrence,to be secured with performance and payment bonds executed by a qualified surety equivalent to the bonds issued on the Construction Contract,and pay to the Owner the amount of damages as described in Section 7 in excess of the Balance of the Contract Price incurred by the Owner as a result of the Contractor Default;or §5.4 Waive its right to perform and complete,arrange for completion,or obtain a new contractor and with reasonable promptness under the circumstances: .1 After investigation,determine the amount for which it may be liable to the Owner and,as soon as practicable after the amount is determined,make payment to the Owner;or .2 Deny liability in whole or in part and notify the Owner,citing the reasons for denial. §6 If the Surety does not proceed as provided in Section 5 with reasonable promptness,the Surety shall be deemed to be in default on this Bond seven days after receipt of an additional written notice from the Owner to the Surety demanding that the Surety perform its obligations under this Bond,and the Owner shall be entitled to enforce any remedy available to the Owner.If the Surety proceeds as provided in Section 5.4,and the Owner refuses the payment or the Surety has denied liability,in whole or in part,without further notice the Owner shall be entitled to enforce any remedy available to the Owner. • §7 If the Surety elects to act under Section 5.1,5.2 or 5.3,then the responsibilities of the Surety to the Owner shall not be greater than those of the Contractor under the Construction Contract,and the responsibilities of the Owner to the Surety shall not be greater than those of the Owner under the Construction Contract.Subject to the commitment by the Owner to pay the Balance of the Contract Price,the Surety is obligated,without duplication,for .1 the responsibilities of the Contractor for correction of defective work and completion of the Construction Contract; .2 additional legal,design professional and delay costs resulting from the Contractor's Default,and resulting from the actions or failure to act of the Surety under Section 5;and .3 liquidated damages,or if no liquidated damages are specified in the Construction Contract,actual damages caused by delayed performance or non-performance of the Contractor. §8 If the Surety elects to act under Section 5,1,5.3 or 5.4,the Surety's liability is limited to the amount of this Bond. §9 The Surety shall not be liable to the Owner or others for obligations of the Contractor that are unrelated to the Construction Contract,and the Balance of the Contract Price shall not be reduced or set off on account of any such unrelated obligations.No right of action shall accrue on this Bond to any person or entity other than the Owner or its heirs,executors,administrators, successors and assigns. § 10 The Surety hereby waives notice of any change,including changes of time,to the Construction Contract or to related subcontracts,purchase orders and other obligations. § 11 Any proceeding,legal or equitable,under this Bond may be instituted in any court of competent jurisdiction in the location in which the work or part of the work is located and shall be instituted within two years after a declaration of Contractor Default or within two years after the Contractor ceased working or within two years after the Surety refuses or fails to perform its obligations under this Bond,whichever occurs first.If the provisions of this Paragraph are void or prohibited by law,the minimum period of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable. § 12 Notice to the Surety,the Owner or the Contractor shall be mailed or delivered to the address shown on the page on which their signature appears. § 13 When this Bond has been furnished to comply with a statutory or other legal requirement in the location where the construction was to be performed,any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted here from and provisions conforming to such statutory or other legal requirement shall be deemed incorporated herein.When so furnished,the intent is that this Bond shall be construed as a statutory bond and not as a common law bond. § 14 Definitions §14.1 Balance of the Contract Price.The total amount payable by the Owner to the Contractor under the Construction Contract after all proper adjustments have been made,including allowance to the Contractor of any amounts received or to be received by the Owner in settlement of insurance or other claims for damages to which the Contractor is entitled,reduced by all valid and proper payments made to or on behalf of the Contractor under the Construction Contract. § 14.2 Construction Contract.The agreement between the Owner and Contractor identified on the cover page,including all Contract Documents and changes made to the agreement and the Contract Documents. § 14.3 Contractor Default.Failure of the Contractor,which has not been remedied or waived,to perform or otherwise to comply with a material term of the Construction Contract. §14.4 Owner Default.Failure of the Owner,which has not been remedied or waived,to pay the Contractor as required under the Construction Contract or to perform and complete or comply with the other material terms of the Construction Contract. § 14.5 Contract Documents.All the documents that comprise the agreement between the Owner and Contractor. §15 If this Bond is issued for an agreement between a Contractor and subcontractor,the term Contractor in this Bond shall be deemed to be Subcontractor and the term Owner shall be deemed to be Contractor. 3 §16 Modifications to this bond are as follows: (Space is provided for additional signatures of added parties, other than those appearing on the cover page.) CO1VT l JO TOR°AS PR C 'AL SURETY Compa ' (Corporate Seal) Company: (ColporateSeal) .A-1 Pr.'arty Serv(c oup, Inc. FCCI Insurance Company Nam nd Title: Name and Title: Tina Man m,Attorney-in-Fact 4 BOND NUMBER 3301801 nn DOCUMENT A312-2010 Payment Bond CONTRACTOR: SURETY: (Name, legal status and address) (Name,legal status and principal place of business) A-1 Property Services Group, Inc. FCCI Insurance Company 890 SW 69th Ave. 6300 University Parkway Miami, FL 33144 Sarasota,FL 34240 OWNER: (Name,legal status and address) Monroe County Board of County Commissioners • 500 Whitehead Street Key West, FL 33144 CONSTRUCTION CONTRACT Date: • Amount: $62,255.00 Description: (Name and Location) Marathon Library Building New Roof and Repairs BOND Date: July 9,2019 Amount: $62,255.00 Modifications to this Bond: ❑ None 17 See Section 18 CONTR, : TOR,AS PR NCI AL SURETY Compa' . (Corporate Seal) Company: (Corporate Seal) A-1 Pr erty.$ervic , r oup, Inc. FCCI Insurance Company X; X: -0,. . Nam nd Title: Name and Title: Tina M ngum,Attorhpy-irh=Face • (Any, clition.al•signatures appear on the last page of this Payment Bond) • (FOR INFORMATION ONLY—Name, Address and telephone AGENT or BROKER: OWNER'S REPRESENTATIVE: (Architect, Engineer or Other Party) Frank H. Furman, Inc 1314 East Atlantic Blvd., Pompano Beach, FL 33060 (954)943-5050 5 §1 The Contractor and Surety,jointly and severally,bind themselves,their heirs,executors,administrators,successors and assigns to the Owner to pay for labor,materials and equipment furnished for use in the performance of the Construction Contract,which is incorporated herein by reference,subject to the following terms. §2 If the Contractor promptly,makes payment of all sums due to Claimants,and defends,indemnifies and holds harmless the Owner from claims,demands,liens or suits by any person or entity seeking payment for labor,materials or equipment furnished for use in the performance of the Construction Contract,then the Surety and the Contractor shall have no obligation under this Bond. §3 If there is no Owner Default under the Construction Contract,the Surety's obligation to the Owner under this Bond shall arise after the Owner has promptly notified the Contractor and the Surety (at the address described in Section 13) of claims, demands, liens or suits against the Owner or the Owner's property by any person or entity seeking payment for labor,materials or equipment furnished for use in the performance of the Construction Contract and tendered defense of such claims,demands,liens or suits to the Contractor and the Surety. §4 When the Owner has satisfied the conditions in Section 3,the Surety shall promptly and at the Surety's expense defend, indemnify and hold harmless the Owner against a duly tendered claim,demand,lien or suit. §5 The Surety's obligations to a Claimant under this Bond shall arise after the following: §5.1 Claimants,who do not have a direct contract with the Contractor, .1 have furnished a written notice of non-payment to the Contractor,stating with substantial accuracy the amount claimed and the name of the party to whom the materials were,or equipment was,furnished or supplied or for whom the labor was done or performed,within ninety(90)days after having last performed labor or last furnished materials or equipment included in the Claim;and .2 have sent a Claim to the Surety(at the address described in Section 13). §5.2 Claimants,who are employed by or have a direct contract with the Contactor,have sent a Claim to the Surety(at the address described in Section 13). §6 If a notice of non-payment required by Section 5.1.1 is given by the Owner to the Contractor,that is sufficient to satisfy a Claimant's obligation to furnish a written notice of non-payment under Section 5.1.1. §7 When a Claimant has satisfied the conditions of Sections 5.1 or 5.2,whichever is applicable,the Surety shall promptly and at the Surety's expense take the following actions: §7.1 Send an answer to the Claimant,with a copy to the Owner,within sixty(60)days after receipt of the Claim,stating the amounts that are undisputed and the basis for challenging any amounts that are disputed; and §7.2 Pay or arrange for payment of any undisputed amounts. §7.3 The Surety's failure to discharge its obligations under Section 7.1 or Section 7.2 shall not be deemed to constitute a waiver of defenses the Surety or Contractor may have or acquire as to a Claim,except as to undisputed amounts for which the Surety and Claimant have reached agreement.If,however,the Surety fails to discharge its obligations under Section 7.1 or Section 7.2,the Surety shall indemnify the Claimant for the reasonable attorney's fees the Claimant incurs thereafter to recover any sums found to be due and owing to the Claimant. § 8 The Surety's total obligation shall not exceed the amount of this Bond, plus the amount of reasonable attorney's fees provided under Section 7.3,and the amount of this Bond shall be credited for any payments made in good faith by the Surety. §9 Amounts owed by the Owner to the Contractor under the Construction Contract shall be used for the performance of the Construction Contract and to satisfy claims,if any,under any construction perfortance bond.By the Contractor furnishing and the Owner accepting this Bond,they agree that all funds earned by the Contractor in the performance of the Construction Contract are dedicated to satisfy obligations of the Contractor and Surety under this Bond,subject to the Owner's priority to use the funds for the completion of the work. 6 § 10 The Surety shall not be liable to the Owner,Claimants or others for obligations of the Contractor that are unrelated to the Construction Contract.The Owner shall not be liable for the payment of any costs or expenses of any Claimant under this Bond,and shall have under this Bond no obligation to make payments to,or give notice on behalf of,Claimants or otherwise have any obligations to Claimants under this Bond. § 11 The Surety hereby waives notice of any change,including changes of time,to the Construction Contract or to related subcontracts,purchase orders and other obligations. §12 No suit or action shall be commenced by a Claimant under this Bond other than in a court of competent jurisdiction in the state in which the project that is the subject of the Construction Contract is located or after the expiration of one year from the date(1)on which the Claimant sent a Claim to the Surety pursuant to Section 5.1.2 or 5.2,or(2)on which the last labor or service was performed by anyone or the last materials or equipment were furnished by anyone under the Construction Contract,whichever of(1) or(2)first occurs.If the provisions of this Paragraph are void or prohibited by law,the minimum period of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable. § 13 Notice and Claims to the Surety,the Owner or the Contractor shall be mailed or delivered to the address shown on the page on which their signature appears.Actual receipt of notice or Claims,however accomplished,shall be sufficient compliance as of the date received. §14 When this Bond has been furnished to comply with a statutory or other legal requirement in the location where the construction was to be performed,any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefrom and provisions conforming to such statutory or other legal requirement shall be deemed incorporated herein.When so furnished,the intent is that this Bond shall be construed as a statutory bond and not as a common law bond. § 15 Upon request by any person or entity appearing to be a potential beneficiary of this Bond,the Contractor and Owner shall promptly furnish a copy of this Bond or shall permit a copy to be made. §16 Definitions § 16.1 Claim. A written statement by the Claimant including at a minimum: .1 the name of the Claimant; .2 the name of the person for whom the labor was done,or materials or equipment furnished; .3 a copy of the agreement or purchase order pursuant to which labor,materials or equipment was furnished for use in the performance of the Construction Contract; .4 a brief description of the labor,materials or equipment furnished; .5 the date on which the Claimant last performed labor or last furnished materials or equipment for use in the performance of the Construction Contract; .6 the total amount earned by the Claimant for labor,materials or equipment furnished as of the date of the Claim; .7 the total amount of previous payments received by the Claimant;and .8 the total amount due and unpaid to the Claimant for labor,materials or equipment furnished as of the date of the Claim. §16.2 Claimant. An individual or entity having a direct contract with the Contractor or with a subcontractor of the Contractor to Punish labor,materials or equipment for use in the performance of the Construction Contract.The term Claimant also includes any individual or entity that has rightfully asserted a claim under an applicable mechanic's lien or similar statute against the real property upon which the Project is located.The intent of this Bond shall be to include without limitation in the tenns"labor,materials or equipment"that part of water,gas,power,light,heat,oil,gasoline,telephone service or rental equipment used in the Construction Contract,architectural and engineering services required for performance of the work of the Contractor and the Contractor's subcontractors,and all other items for which a mechanic's lien may be asserted in the jurisdiction where the labor.materials or equipment were furnished. § 16.3 Construction Contract. The agreement between the Owner and Contractor identified on the cover page,including all Contract Documents and all changes made to the agreement and the Contract Documents. 7 § 16.4 Owner Default.Failure of the Owner,which has not been remedied or waived,to pay the Contractor as required under the Construction Contract or to perform and complete or comply with the other material terms of the Construction Contract. §16,5 Contract Documents,All the documents that comprise the agreement between the Owner and Contractor. §17 If this Bond is issued for an agreement between a Contractor and subcontractor,the term Contractor in this Bond shall be deemed to be Subcontractor and the term Owner shall be deemed to be Contractor. §18 Modifications to this bond are as follows: This Payment Bond is intended to, and shall be deemed to be, an unconditional statutory Payment Bond pursuant to the requirements of Section 713.23, Florida Statutes.All of the provisions of Section 713.23, Florida Statutes, and all related provisions of Chapter 713, Florida Statutes, are incorporated into this Payment Bond by this reference. Insofar as any provision of this Payment Bond is inconsistent with, or more limiting or more expansive than, the provisions of Section 713.23, Florida Statutes,or any related provisions of Chapter 713, Florida Statutes, then the statutory provisions shall control. (Space is provided for additional signatures of added parties, other than those appearing..On'the cover ' page.) CONTRACT( R AS PRINC AL SURETY Company: ,•• (Corporate Seal) Company: (Corporate Seal) A.-1 Prop= y Services ro , Inc. FCCI Insurance Company Nam= a d Title: • . Name and Title: Tina Mdngum,Attorney-in-Fact • . ••••• .,. .....,•:•.! „:...,.,..•••, .....: ..-:. ••.7:77:::;:-..7.'.7.7.7:::7,1 ..1ITT-Ti.,,IT:::...---;•;R:77.:TEli.7:77...f.r.'::::',..:7.::::7.,..y7,,;::'::ii•:'. 1:•,:!':.:*.;.-:t:',..::,..,...ji:.:E:1::' •:•.;:':',.:i .„:1:.?..'•';-‘" ..,.:;g:,•:.,.:,.j.:••,,i!,:.'••• .:.T:.:::••• :•.1:,.r.i..•:i;.,....,,......i......li,.;,:;.:,::......i.,......i,...;.........,.:•:.• ....:i•i•!::,.,.• ..,..:;:!.. •.::;;!.. :;:-....1.g ...::::: ,i,:.c.,.:,........i::::.:::::::....A th;00.097144.9., :•!';•'11,1',.'.'''-1.1.?i.::.':'•:';'::;.:1;...'qi;:-,.:::.,,i.::::•.:' •:•,...i ••::...:::i: ':.•;:::.f.i.•••••••kl,,•:;....:' E;,,:::'*'::.•:-:•:•,•. ....:?,•:•, ...,:g..::,....; ....1.,i,..„,,,i, :::::;.f,. ..,:•••• ••,:k.,::::. ...,L,...., .„.;.: ... . * ..- ..... "1"1".m"."11410,... • . • . .... •-• ....... . ... ••••••• ••• -- ••••••••••„,:....,,!:•!i!,::,.: ,.„.:.:.:.,,..• ‘!..:.,....,.; S..:.,. •••:!:•;."•: i•:::• agjiir .•• :.::]••••' •••'::!;. i?•: :'..?: :-...,•:,'-'; ,.:.., ::.,..:y.:•: .!;...!.:-..;:•..,... . y.,,:•. ,.*•:.. ...., i:,..;:.,,-•,,..,...,.:.:. ,.,.,?„.. .......„...,...:.:,.. .,..:„..:.......,.!!,....... .,.:..:....„:. .„....:,,„..,,........ ........:,. .......;..:„. ‘,,,„ :::.!.:i.:•:.2:1:::-,.. v•,••,;..i:.::-;:,!1?•••,• •i••••:. :•.:,•:• ••• •••;•..• -:•'•'• • :.•:::• -.-:.:..... . - •2 • More than a policy. A proinise. • • i . ... ..... ... .. ..... . - .... .. - . ... . ...„ .... .. . . . .::L•''ii::::1:...i1E'',• ''',!-•::.:::', .i.!',:i:':' i'.••:,.: ...i'':.:1': ' T-••::..',..:-:1•:•: i:!:::;.;:. ..::;E•:!;. ..!.:;',:,....,:?. ...' .!.,:i''': ;:.,.ii:;':: !!:: ::•!::::•.::;•••,..1•:::.:;: .: ••.:!:::::. .,.::•.•;: :;.i•., :.:;!..i:.;.;:••;'' ';:'!..::'. C '"'':":':' '...":..'ll". lJ); ". . . i...*....c""::: ' .H.:'*. ''': 11 Titi •'ig•OCI InSbranceThnipany,&Corporation arganiZed••andexisting un er - I r:.;:;•!:i: ••••,,I,:, ... :KhOw ell rneribylhesepresentS:-T a • e ' '.• .. the laws of the State of Florida (the."Corporation")does make, constitute and appoint: 1 : .. Dirk-ID DeJang; Sharan..R. Myersjine IVIapgu.71.„ ,:: ••-„.„. -:- :,-,:•.,:.•:••••.•• •••.• •::. :F:•:.;,:. ••.•:::-i::::•:•-..,-: ::-:•:".:',:•:••1 ,,,. is:.:•:,:,..•,..!5:,.,,!:•,• :: ,::.,•,:,,-:, --; , i::''.7.''''''':•;:;: '''';':..:1::':!.:F EAc....•'.:.:"..h''. ts trt::;:ri :L.. .::.:.kfuil'.:ik4o Attorney-In-Factiia:01. .sie;•:':...:.e4ctAe...:,!.'.....Sealanddeliie.„17id.f.'66.-d...E.on its behalf aSi:Sarety,•'and ..;.i.,...,:::,i•'•1 as its act and deed in all bonds and undertakings provided that no bond or undertaking or contract of suretyship executed . under this authority shall exceed the sum of(not to $10,000,000.00 This $10,000,000.00): .. .. - _ . ... 1 .... .. .: . : :, ......... .,. ....., .... .,..- ....- .... .............. ... . , - - ••;.1 i':,;...,..,..:::;•,•,.:1.:',.....:::,„•..• ,.;:•••:.,':.:::::.':,:.•;'..,:'.::::.1: ..i..3...:''OLi:e:•-::;oi.;.:i)5%:'.tigrne}f..::,;'',.i...s.'.'::•:'-'ii. ..'"61a..':.:6.:.V4?(.;',..e. i.4d.':-:.-D y autiiOi.hy,is.0:0.:1!: ..,... 01uTIcj.:.0.adoptOdby.#)0.....1.3obr Q:-Directors .That..., .-:;.......1 1re.......S.C.:11i.Aidr):a...1s6::authbrfied'a.4 fayffheractiOn-bOherOffiCers ofiheCOmpany necessary ta'effeCCsaali.tranSaetidii. ':.-...:. .:.•!' .'! .:::k.-...::•.:::::. •• The signatures below and the seal of the Corporation may be. affixed by facsimile, and any such facsimile . 1•.,:.:, -..". • • t res-or facsimile•seakshall,be,biriding upon:the:Corp,orati.on...w.::hen.....so...!affixed.andln:the....:.;future...w...„..it.h. regard to any ..:......:...:...,!:.•;•:.,.....:.:,:...] 1:',''''-.1;''':.• 1..ibicli'::..OhdOij6king or contract of surety to which:!tis.a..:ached „..T..j.... .:,..,„. .,....„...: ,.....,.. ..,..: ...„::,!:...:.,............::::„. ........'......._._ ...;....: ..,:....y., ..,,,..... _,.... ,...... ...._ , I••::; t'i,..f.;q:SE-c:.• rr.:!:,•ii'.--,...,,. ;J:'•'.•:',:,i;.':" 'A.::.m::-!..: %•:•-y"..e.:•-• ]-::',: :‘:•:•:• . --------::,•••••••' -!..•••:. •::::•:.•'...,.• - ' . . In witness whereof,the FCCI Insurance Company has caused these presents to be signed by its duly authorized officers and its corporate seal to be hereunto affixed, this 31st _.... day of January ,.,..,.. ...,. ,....:.... 2019.4:. ...:.i ..,.,. ,...: ...:: ..,,..!...:. 1 • -• •••••••••• ••-••••••. ,•,::,,,.. ,I,'.:! .::'...,!4: ••:•.',:•,; ....,,j,,irE:•,•••:,:r: 1.-cs,:. ,,::.:::::! •::.!:•,,•,: ,i.;::::,,,,,.:::,.:,,.::.i::: ••.::.,,.. :., 4:. „...,:g.,: ,;,,,.. ::::..,....r.„.:•„.,..„.., .,..„.... ,,,,,,,,.,.,,„,,,tsp;,..,:...,.:,...., .,.,::,.. •:;:::::: .......i:. -,..?..i-•::„....:•.:. .......: „...„1.,.. . ..... :.:.„ :.,.. ..,. .„1..E....: 1 . ..,-,i;:i.Erti.,.!•,!: .:-:,!;::-:::.....;:.!..:: -!::-;:l..;;;•:..••,•• •,.:.;•:! ,:;., -. -,.• ;.:.ii:c., :::ti , k::.:„?,..!:•:::!,.. ....:•-!•,;::::•i' i-j....;60.0/14;is'•?,..-,;,v:•• •••,„ :. ..--- -itt)••• • (e&c.,2•. ..- -. ••• 1 -.". ... Attest: ,z 4.-i 1-4; i : •• Crai John n, President : .., SEAL t • [994 i Cina Welch, EVP, General Counsel, i r• Secretary••-, ........„. I 1... .,.. ...:,..,,.., ..!chiet.Audit:a 0orp pliPPPe..:02ff.cc?.,: •;..,-, ••:•••'•••',:.•-••• •-•i:,•••• i, , FOCI Ins.t.Kance,Qpiqpapy ...i1' '..::i:':: ••• ::.;.'..t,•.°!.4?..•'!::I:.','"::';':".:.:. ::' rOdi'lligureide Companyi,::•• •••!...:::. ".:! •-f•i:::: 4 ,.,,,,,...,•!•„;!::, •-•-::,•:„!•:•• :.,.:::•:•, ... ::,..:.:•! •,,,::.... ,..,,,,, •••••,•••,.:,A,• ;,!i,,, !::,,:::...,,,F •::.i;!,.,:•:,. :•Li.L. ,:•;:,.::,,:•,,:•:!„...,,T.•!:::: ......f,.,ii,,,-,..,:;-,','..0,'•:;.:. :•'!:•,:: •::•:.:'.'..:i.'•'••••* •':::::''. '•••'''':•:...-1- '-',7•• :•••:1:••;•,:••••: '•:-•:',.:,-;: •*••::;:',•-•''' '..,:••.::,..-:•• -,:"-•!:,....,.. 1:‘:,,:••: !,:,;•,.." ....:::.,:i:' ,q.,.,:..:!•,K, .:...s...•!•••:: ,...,.. •,....:.;.:::,• :,..:,:iy ]„!;•,......-• ••.,;',,•,• W g.:40-,.,..F; Wp::-.,• •':'!(:',:!: :: ';:':' ,Y •-'i::: ::• *:'•':! •,:,.' •:•::::••..i..:1:‘,:':",.... •••c!:'•':, ••.!,...":''''''-•!]-.• ••:•!::: ::::' ••;•.*:.: '.::::- ••••.-:'. •:.'c:••:.• -:: ::-. - ••• •••• - ••• - • •••• ' :....; • • State of Florida County of Sarasota • .. ;•::,..•-.J :::::..',-•.;:::,.. ....i„,,...:„.„..• T‘.:.6iie.....:. ;:...i.17i;, ;:,.p .1;(. 6.::y appeared::..!;,.... :::7-........;::7 ...7....:::':..:..'personallyknown-to me arid who executed the ••.,i ,..)!...,:•:,..!,.-,. ,:.,:,,•::,!::•!!•:.. •::;•••:. „...:.. :••,.... :•.,., :.......:••••, .... ,•:,..,:.„. -::„.- •••:'•-.... , ,,, ,- :...,:••:,•:::!:. ...i.,.....L..:::.• :.:.,,... :,-,: !,..,;!•• ••:, :::•,. •,...-• ,......., ::•,. •..:•,...• •.•.• .. : - ....foregoing document for the;purposes expressed.therein. .... 1 '...•-• •• • ....' ' • •••••••. Artenc Monso 1 .. M.•. yccm.ission expires: 9/25/2Q20 . . lilt*Nougy Publ io,Stale of Hada _,, .4...-X:4 . . . - .CE09I13JO Notary Public ........., v.:.-, ,,......., 1...'i::!•,,ilE!: ''''''.",;:!:.:::.:.:1";.;',..!,::::'.:::-..:..--.::::.... ...:::.;::' '•.,;: J..±.2:'. !•:.i.j:: ::!'.:1;:..::-..::::... ..' ,..,.!:1,,: ,,.._0 iposio. „t",..,„.. „.;,:. ::;:::. .,:;:::. ....:;.:-.:.:.;',''.I.:::. :f...", ..... ...,:.....,.. .g...,,..!...:-..-,:::....„, ....:..„...:..., -.:.;-....;:-.*. - .. ...- - ' 1 1 . ...' .. ..State of Florida . ..,„ sy.,. :,. ,. ...„:„..,,, ...,.. ,:::::: ......,..,:. i •. t...„.eqqnty.pf p.p.rg§.PAP::. ::.:.. ..,::.i:.?.. !:„,.... '.:.:. .:;•,,,,] ,..;.:F.,7, .....f,,,..:. .....7:,.:,...:. .,;...,,, .:: -,--.:::.--: -.;::,...::• ;...:,,,.....3. ::.. , • ::-..:;..i........': :'.::.!..'::. - i3 f:'6. r-:"....!...rn." '':-'i.i.JiI'';'... .i'a .pi. ; ngilyz;'...4.'i::pe6$.ci!ii.-i:c).'n.:.'a W810,..:-:.-itifjp,..:11sii:,i?"-61-sori..-611y knO.V.n:31o...:;.'..M0: a..indyyhO-,,execated.the•••• •.,,..yr• .1 '''..?fOrega...inidOcan-ientfOr the purposes therein. , ...; ...: /1 _, 1 . •• it Aden magi _. ,(2/414.4cec.4c,,...z.;,„0 ,.. :::::::::::..:•. ..,..-„•:••.;',...11 L •'Nokay NUM.*of.F.Ical expires 9/25/2020„.q:',... ...,y * *, ... .1...... MWtprn-trAiOipn . ,„... ,.„.. ,•••:,., oqr..,p:tosr19, ... .u., .‘,..„. ::'..ei• z,'••'••• •••-i-,-- :•:i,•:,,,....,.• •,:.::, :,•i!;-1. ••,-,:::::::. ••-, :•:::::,!: .6-::.„i„,.:.,-3.,,,- :.-„,;;.-,•„. ti1,410.1,4";9.e.?4,.,,, ,, , :,:,.:, ::,...• .:.N.a....;:.•.•:..:f.•,:.:.:...i.f,•:::., •:.:•:.,.,.,..„..:..,..0, ....fy,..a... 1::;:...;:.:........ ;::...::;...::......:.,. ......::. ...:..... „,..,,:,l '.•,!:,:, ,:iig ir.i.,..,:,::;::,?::,..H. 1.::,::,.i,;,,:;-.....i.,..!:-•:',:.•• . . . . CERTIFICATE . ..„. - yl.?., :,;:..;:;::::.:. :::i...... ., .;:::;. ...:.:.' ...I:K. .:.....:!iis., 'l,...:.' ...;!..;( ;'../:.:! .::.;:.; :':.'.......;.':;'...'...': ....!..'", .: [;. .-,.. ...:...... .:;:.K,: .!.:',:... 'jj.',.. .. .. :..:::.!:.. `0"i!':',. '.;'.. ::...1..1;. .' : ' ..',1''.'..!1'!•'.!.:.!..' ..";..q:: .H..:, ...:'' ..'..;.*!'icloai.y. .thitih:6-....... 'Ic4',:',!;'-f,.i!',i..::.,i.,.;. .c!.:fi'::•i•Y.: .•.. gp. .t.r.ider.',.sr.,..lhe11.!' 668i..i'aaw8f.rddiiiiii.ii'grie Company,' . p.:110tida CO..0oration,pQ. 1-1. 7• 14•.::::CERTIFY .••••• ••-••• •,.•••,,.:.•:..-:•.' • fa'il.:.'g..4- ing,'.P.:o..-WYer-o-f:-A-itOrriei remainslrfaii'forc'e- .'6.a has n6tbeehievOked; and furtheirriorethatthe'February.24, 2011 I .--• - Resolution of the Board of Directors, referenced'in.said Power of Attorney, is now in force. .. ... ,.,,:::. -..".....11,:-.......i.::.„:...;:;•::::;:,,.. :.!..:!.,..:, :....-..,.• !:.•••• . , ;...; .!:::•:;,:;•,: .!•:-:,..,',•:••••:_, _:.:.. .:•• •i.-•:::.•:1:::.;!/•:., i•L',.,-;:::: :::i.:• :,...,:. e-), . ,,,,,,•4•,, „,...:1:-:.:!.."!....1 i- ..,,, .„--- ,,,,, :•,,,,,. •:••,,..,:?...:::„.. .,;4•••!•:::,,••••. .i:;.,:!•::';5::':•••,: '';':1.'2'''''' ' ' ..:,'.:: '..:•;:::: '':'''''''....;:!.'''' Dated this ....',:,4)•)\•::•:',- day of : ••...: — ,•••• . -: ._4.,:.:.. :,,::•:.1 Q . ,........ ...,..... Cina Welch EVP -- •••••••••• •,•,..., •-•.:.••::,•,,. .:::,.......,:,:t.. 1...:•:!,.":,.;':',?A ,:: ,:A!:;.•,::.:'•,,, '...,,,.:1...::•:., ..• ••..•••• •••'. .•'?'.•• ••;;:•-•!''..":',;(•, ;•,•!-,••••-',.&i: •,:Yr!....,•:;'!. • ;•.::::.:•: ••••:'&••• ri.'i..• •,•:::::•,•••••••••• 1.:•;;'•••••':.:]:•./.2./ .-•,-.0•'•., •::,-.•-•••-,.. •• • • • General Counsel, 1.!-;: .tt ':,:!!': ::::::::.4-•ii-:. 1-;.:-:*.! i:Iii.:.''.V.i."-. ..;:::,.:.;:•4!:::::.7:::."'',:',-.;.:.:v::: ...:7:::,i;.---4!:, :!:!:;.r :,.;:...,:,...,.:..:.:::z.:::',: -.;!!',4 ..::.,...`.: •`.:-.-.:.i.::-.• ...,H.:'.:' Chief Audit&cortplionce....0.fNpr,.. ecr.e...pry „T„, .::,:,,,...,......:„.,..:.-:......:...:.,.... ..1 11:i';.:,.--:'.:4!-.'A:;.1,:,.-::;,.;. g!:.!....}.:1 :,;,..•::.! '.:;.,;i: • ii:::.: :,-ii:i1-‘'...1...-:',i.:!..':i. ...iI:::.:-.‘.g....:i.:';':!::-,.. E,I:::' ,:i: :::::::.:.i,,, 1:.?,..::„...„ ..i:::;:,:,;...;-:.::;::..- ..D...„.,!:,::;::-,!.,:.:.!.::::::;,. .!....:,,: :::,-,. 0 i:§''...:.k..-.):1'..61469:Ng.04, fiipis..1••..• •••i•:::•• •:•;!!:•,:i.-'.:' ...',.: •-•,:- •••:••:-.••••, . -...••- - ,,0,m74,,,,,,, • ,: i •• •§'•r!i•• ••••.•• IIP:::•'''::':li.::;:::,•• '1•!.I.:•]...]...;;':: *:.!'•..:;::',.:•.!::1:::•::'.•:.::::;••;;•.'fii-:.4...° Gard:I;i,/6,...0nihs'1•1,'€:'!..p....4i!.!..ti/P7),•,;tograph,41itiii..,kg."•:;*....0..::••1/.61iy.ipsitke.,..t.'f.14,..::colii..;ireacq1Qq..i.Atgrfijark; ri ...0.cfoteg Pililly16!9aPPIAI!,-:::!........z.,_............,;...„.......:_:...L..,........;...,:,,, . •