Loading...
07/17/2019 Agreement c .. .•! 1 ° °``•. Ao�, Kevin Madok, CPA O: n��wu Clerk of the Circuit Court&Comptroller— Monroe County, Florida DATE: September 13, 2019 TO: Breanne Erickson Budget/Contract Administrator Tammy Sweeting Executive Assistant �I FROM: Pamela G. Hanc.T.1,'��i).C. SUBJECT: July 17' BOCC Meeting Attached is an electronic copy of the following item for your handling: S5 Contract with the highest ranked respondent,Advanced Construction Technologies, LLC., to build a 1,012 square foot(three bedroom, two bathroom) "Tiny Home" on a County owned parcel at First Avenue West, Cudjoe Key for a lump sum fee $207,199.00 paid for by One Cent Infrastructure Sales Tax Funds. Should you have any questions, please feel free to contact me at(305) 292-3550. cc: County Attorney Finance File KEY WEST MARATHON PLANTATION KEY PK/ROTH BUILDING 500 Whitehead Street 3117 Overseas Highway 88820 Overseas Highway 50 High Point Road Key West,Florida 33040 Marathon,Florida 33050 Plantation Key,Florida 33070 Plantation Key,Florida 33070 305-294-4641 305-289-6027 305-852-7145 305-852-7145 "TINY HOUSE" CONSTRUCTION AND DEMONSTRATION Agreement Between Owner and Contractor Where the basis of payment is a STIPULATED SUM AGREEMENT Made as of the 1 day of 3-1/4i(y 2019 BETWEEN the Owner: Monroe County Board of County Commissioners 500 Whitehead Street Key West, Florida 33040 And the Contractor: Advanced Construction Technologies, LLC 3706 N. Roosevelt Blvd, Suite 708 Key West, Florida 33040 For the following Project: "TINY HOUSE" CONSTRUCTION AND DEMONSTRATION Scope of the Work The Scope of Work shall include installation of a 1,012 square foot (SF) single family home with three (3) bedrooms and two (2) bathrooms per the proposal submitted on September 25, 2018. The home is to be constructed on the County owned parcel on 1st Avenue West, Cudjoe Key, Florida. The Scope of Work includes all tasks required for the design/build of this structure including all aspects of design (including any geotechnical or material testing required), the acquisition of all permits, all site preparation work required by those permits, and all major appliances(including range/oven, dishwasher, refrigerator, and washer/dryer)with corresponding warranties for an occupancy ready"tiny house". The County has chosen to expand the scope of work to also include the relocation of one (1) power pole and site fill. ARTICLE 1 The Contract Documents The Contract Documents consist of this Agreement, Conditions of the Contract (General, Supplementary and other Conditions as contained in the Request for Proposals as posted on Demandstar on August 4, 2018), Drawings, Specifications, Proposal Documents (including written responses to clarifying questions and any and all Declaration of Restrictions applicable to AGREEMENT Page 1 of 23 "TINY HOUSE" CONSTRUCTION AND DEMONSTRATION the Cudjoe Gardens Subdivision ),Addenda issued prior to execution of this Agreement,together with the response to the RFP and all required insurance documentation, and Modifications issued after execution of this Agreement. The Contract represents the entire and integrated agreement between the parties hereto and supersedes prior negotiations, representations or agreements, either written or oral. An enumeration of the Contract Documents, other than Modifications, appears in Article 9. In the event of a discrepancy between the documents, precedence shall be determined by the order of the documents as just listed. • ARTICLE 2 The Work of this Contract The Contractor shall execute the entire Work described in the Contract Documents, except to the extent specifically indicated in the Contract Documents to be the responsibility of others, or as follows: N/A ARTICLE 3 Date of Commencement and Substantial Completion 3.1 The date of commencement is the date to be fixed in a notice to proceed issued by the Owner. The Contractor shall achieve Substantial Completion of the entire Work not later than ninety (90) calendar days after the date of commencement or issuance of a Notice to Proceed. The time or times stipulated in the contract for completion of the work of the contract or of specified phases of the contract shall be the calendar date or dates listed in the milestone schedule. Liquidated damages will be based on the Substantial Completion Date for all work, modified by all approved extensions in time as set forth by the Director of Project Management's signature of approval on the Certificate of Substantial Completion. The liquidated damages table below shall be utilized to determine the amount of liquidated damages. FIRST SECOND 31 ST DAY & CONTRACT AMOUNT 15 DAYS 15 DAYS THEREAFTER Under$50,000.00 $50.00/Day $100.00/Day $250.00/Day $50,000.00-99,999.00 100.00/Day 200.00/Day 750.00/Day $100,000.00-499,999.00 200.00/Day 500.00/Day 2,000.00/Day $500,000.00 and Up 500.00/Day 1,000.00/Day 3,500.00/Day The Contractor's recovery of damages and sole remedy for any delay caused by the Owner shall be an extension of time on the Contract. 3.2 UNCONTROLLABLE CIRCUMSTANCE Any delay or failure of either Party to perform its obligations under this Agreement will be excused to the extent that the delay or failure was caused directly by an event beyond such Party's control, without such Party's fault or negligence and that by its nature could not have been foreseen by such Party or, if it could have been foreseen, was unavoidable: (a) acts of God; (b) flood, fire, earthquake, explosion, tropical storm, hurricane, or other declared emergency in the geographic area of the Project; (c) war, invasion, hostilities (whether war is declared or not), terrorist threats AGREEMENT Page 2 of 23 11 , "TINY HOUSE" CONSTRUCTION AND DEMONSTRATION or acts, riot, or other civil unrest in the geographic area of the Project; (d) government order or law in the geographic area of the Project; (e) actions, embargoes, or blockades in effect on or after the date of this Agreement; (f) action by any governmental authority prohibiting work in the geographic area of the Project; (each, an"Uncontrollable Circumstance"). Contractor's financial inability to perform, changes in cost, or availability of materials, components, or services, market conditions, or supplier actions, or contract disputes will not excuse performance by Contractor under this Section. Contractor shall give County written notice within seven (7)days of any event or circumstance that is reasonably likely to result in an Uncontrollable Circumstance, and the anticipated duration of such Uncontrollable Circumstance. Contractor shall use all diligent efforts to end the Uncontrollable Circumstance, ensure that the effects of any Uncontrollable Circumstance are minimized and resume full performance under this Agreement. The County will not pay additional cost as a result of an Uncontrollable Circumstance. The Contractor may only seek a no cost Change Order for such reasonable time as the Owner's Representative may determine. ARTICLE 4 Contract Sum 4.1 The owner shall pay the Contractor in current funds for the Contractor's performance of the Contract the Contract Sum of Two Hundred Seven Thousand One Hundred Ninety- nine Dollars and no cents ($207,199.00), which includes relocation of one (1) utility pole and site fill, subject to additions and deductions as provided in the Contract Documents. 4.2 The Contract Sum is based upon the following alternates, if any, which are described in the Contract Documents and are hereby accepted by the Owner: N/A 4.3 Unit prices, if any, are as follows: N/A ARTICLE 5 Progress Payments 5.1 Based upon Applications for Payment submitted by the Contractor to the Director of Project Management, and upon approval for payment issued by the Director of Project Management and Architect, the Owner shall make progress payments on account of the Contract Sum to the contractor as provided below and elsewhere in the Contract Documents. 5.2 The period covered by each Application for payment shall be one (1) calendar month ending on the last day of the month. 5.3 Payment will be made by the Owner in accordance with the Florida Local Government Prompt Payment Act, Section 218.735, Florida Statutes. 5.4 Each Application for Payment shall be based upon the Schedule of Values submitted by the Contractor in accordance with the Contract Documents.The Schedule of Values shall allocate the entire Contract Sum among the various portions of the Work and be prepared AGREEMENT Page 3 of 23 "TINY HOUSE" CONSTRUCTION AND DEMONSTRATION in such form and supported by such data to substantiate its accuracy as the Director of • Project Management may require. This schedule, unless objected to by the Director of Project Management, shall be used as a basis for reviewing the Contractor's Applications for Payment. 5.5 Applications for Payment shall indicate the percentage of completion of each portion of the Work as of the end of the period covered by the Application for Payment. 5.6 Subject to the provisions of the Contract Documents, the amount of each progress payment shall be computed as follows: 5.6.1 Take that portion of the Contract Sum properly allocable to completed Work as determined by multiplying the percentage completion of each portion of the Work by the share of the total Contract Sum allocated to that portion of the Work in the Schedule of Values, less retainage of ten percent 10%. Pending final determination of cost to the Owner of changes in the Work, amounts not in dispute may be included in Applications for Payment. The amount of credit to be allowed by the Contractor to the Owner for a deletion or change which results in a net decrease in the Contract Sum shall be the net cost to the Owner, less Overhead, Profit and Documented Costs incurred prior to the change Request, as indicated in the corresponding line item in the Approved Schedule of Values for that line item as confirmed by the Director of Project Management.When both additions and credits covering related Work or substitutions are involved in a change, the allowance for overhead and profit shall be figured on the basis of net increase, if any, with respect to that change. 5.6.2 Add that portion of the Contract Sum properly allocable to materials and equipment delivered and suitably stored at the site for subsequent incorporation in the completed construction (or, if approved in advance by the Owner, suitably stored off the site at a location agreed upon in writing), less retainage; 5.6.3 Subtract the aggregate of previous payments made by the Owner; and 5.6.4 Subtract amounts, if any, for which the Director of Project Management has withheld or nullified a Certificate for Payment as provided in Paragraph 9.5 of the General Conditions. 5.7 Retainage of ten percent(10%)will be withheld in accordance with Section 218.735(8)(b), Florida Statutes. 5.8 Reduction or limitation of retainage, if any, shall be as follows: Monroe County is exempt from and not subject to Florida Statutes, Section 255.078, "Public Construction Retainage". Reduction or limitation of retainage, if any, shall be reduced incrementally at the discretion of and upon the approval of the Director of Project, Management. ARTICLE 6 Final Payment Final payment, constituting the entire unpaid balance of the Contract Sum, shall be made by the Owner to the Contractor when (1)the Contract has been fully performed by the Contractor except for the Contractor's responsibility to correct nonconforming Work as provided in Subparagraph 12.2.2 of the General Conditions and to satisfy other requirements, if any, which necessarily AGREEMENT J Page 4 of 23 "TINY HOUSE" CONSTRUCTION AND DEMONSTRATION survive final payment, and (2) a final approval for payment has been issued by the Director of Project Management. Such final payment shall be made by the Owner not more than twenty (20) days after the issuance of the final approval for payment. The following documents (samples in section 01027, Application for Payment) are required for Final Payment: (1)Application and Certificate for Payment (2) Continuation Sheet (3) Certificate of Substantial Completion (4) Contractor's Affidavit of Debts and Claims (5) Contractor's Affidavit of Release of Liens (6) Final Release of Lien (7) Contractor shall provide two (2) hard copies in tabulated divided binders and one (1) saved electronically tabbed and indexed in Adobe Acrobat file (.PDF) format delivered on a common form (i.e. flash drive) of all the following, but not limited to: A. Project Record Documents (As Built Documents). B. Operating and maintenance data, instructions to the Owner's personnel. C. Warranties, bond and guarantees. D. Keys and keying schedule. E. Spare parts and maintenance materials. F. Electronic copies of approved submittals. G. Evidence of payment and final release of liens and consent of surety to final release (includes final release from all utilities and utility companies). ARTICLE 7 Miscellaneous Provisions 7.1 Where reference is made in this Agreement to a provision of the General Conditions or another Contract Document, the reference refers to that provision as amended or supplemented by other provisions of the Contract Documents. 7.2 Payment shall be made according to the Florida Local Government Prompt Payment Act and Monroe County Code. 7.3 Temporary facilities and services:As described in Section 01500,Temporary Facilities, of the General Conditions. 7.4 Monroe County's performance and obligation to pay under this contract is contingent upon an annual appropriation by the Board of County Commissioners. 7.5 A person or affiliate who has been placed on the convicted vendor list following a conviction for public entity crime may not submit a bid on a contract to provide any goods or services to a public entity, may not submit a proposal on a contract with a public entity for the construction or repair of a public building or public work, may not submit proposals AGREEMENT Page 5 of 23 "TINY HOUSE" CONSTRUCTION AND DEMONSTRATION on leases of real property to public entity, may not be awarded or perform work as contractor, supplier, subcontractor, or consultant under a contract with any public entity, and may not transact business with any public entity in excess of the threshold amount provided in Section 287.017, for CATEGORY TWO for a period of thirty-six (36) months from the date of being placed on the convicted vendor list. By signing this Agreement, Contractor represents that the execution of this Agreement will not violate the Public Entity Crimes Act (Section 287.133, Florida Statutes). Violation of this section shall result in termination of this Agreement and recovery of all monies paid hereto, and may result in debarment from County's competitive procurement activities. In addition to the foregoing, Contractor further represents that there has been no determination, based on an audit, that it or any subcontractor has committed an act defined by Section 287.133, Florida Statutes, as a"public entity crime"and that it has not been formally charged with committing an act defined as a"public entity crime" regardless of the amount of money involved or whether Contractor has been placed on the convicted vendor list. Contractor will promptly notify the County if it or any subcontractor or Contractor is formally charged with an act defined as a"public entity crime"or has been placed on the convicted vendor list. 7.6 The following items are included in this contract: a) Maintenance of Records. Contractor shall maintain all books, records, and documents directly pertinent to performance under this Agreement in accordance with generally accepted accounting principles consistently applied. Records shall be retained for a period of five (5) years from the termination of this agreement or for a period of three (3)years from the submission of the final expenditure report as per 2 C.F.R. §200.333, whichever is greater. Each party to this Agreement or their authorized representatives shall have reasonable and timely access to such records of each other party to this Agreement for public records purposes during the term of the Agreement and for five (5) years following the termination of this Agreement. If an auditor employed by the County or Clerk determines that monies paid to Contractor pursuant to this Agreement were spent for purposes not authorized by this Agreement, or were wrongfully retained by the Contractor, the Contractor shall repay the monies together with interest calculated pursuant to Sec. 55.03, Florida Statutes, running from the date the monies were paid to Contractor. Right to Audit. Availability of Records. The records of the parties to this Agreement relating to the Project, which shall include but not be limited to accounting records (hard copy, as well as computer readable data if it can be made available; subcontract files(including proposals of successful and unsuccessful bidders, bid recaps, bidding instructions, bidders list, etc.); original estimates; estimating work sheets; correspondence; change order files (including documentation covering negotiated settlements); backcharge logs and supporting documentation; general ledger entries detailing cash and trade discounts earned, insurance rebates and dividends; any other supporting evidence deemed necessary by Owner or the Monroe County Office of the Clerk of Court and Comptroller(hereinafter referred as"County Clerk") to substantiate charges related to AGREEMENT Page 6 of 23 "TINY HOUSE" CONSTRUCTION AND DEMONSTRATION this agreement, and all other agreements, sources of information and matters that may in Owner's or the County Clerk's reasonable judgment have any bearing on or pertain • to any matters, rights, duties, or obligations under or covered by any contract document (all foregoing hereinafter referred to as "Records") shall be open to inspection and subject to audit and/or reproduction by Owner's representative and/or agents of Owner or the County Clerk. Owner or County Clerk may also conduct verifications such as, but not limited to, counting employees at the job site, witnessing the distribution of payroll, verifying payroll computations, overhead computations, observing vendor and supplier payments, miscellaneous allocations, special charges, verifying information and amounts through interviews and written confirmations with employees, subcontractors, suppliers, and contractors' representatives. All records shall be kept for seven (7) years after Final Completion. The County Clerk possesses the independent authority to conduct an audit of records, assets, and activities relating to this Project. If any auditor employed by Monroe County or the County Clerk determines that monies paid to Contractor pursuant to this Agreement were spend for purposes not authorized by this Agreement, the Contractor shall repay the monies together with interest calculated pursuant to Section 55.03 Fla. Stat., running from the date the monies were paid to Contractor. b) Governing Law, Venue, Interpretation, Costs, and Fees, This Agreement shall be governed by and construed in accordance with the laws of the State of Florida applicable to contracts made and to be performed entirely in the State. In the event that any cause of action or administrative proceeding is instituted for the enforcement or interpretation of this Agreement, the County and Contractor agree that venue shall lie in the appropriate court or before the appropriate administrative body in Monroe County, Florida. The Parties waive their rights to trial by jury. The County and Contractor agree that, in the event of conflicting interpretations of the terms or a term of this Agreement by or between any of them the issue shall be submitted to mediation prior to the institution of any other administrative or legal proceeding. c) Severability. If any term, covenant, condition or provision of this Agreement (or the application thereof to any circumstance or person) shall be declared invalid or unenforceable to any extent by a court of competent jurisdiction, the remaining terms, covenants, conditions and provisions of this Agreement, shall not be affected thereby; and each remaining term, covenant, condition and provision of this Agreement shall be valid and shall be enforceable to the fullest extent permitted by law unless the enforcement of the remaining terms, covenants, conditions and provisions of this Agreement would prevent the accomplishment of the original intent of this Agreement. The County and Contractor agree to reform the Agreement to replace any stricken • provision with a valid provision that comes as close as possible to the intent of the stricken provision. d) Attorney's Fees and Costs. The County and Contractor agree that in the event any cause of action or administrative proceeding is initiated or defended by any party relative to the enforcement or interpretation of this Agreement, the prevailing party shall be entitled to reasonable attorney's fees and court costs as an award against the non-prevailing party, and shall include attorney's fees and courts costs in appellate proceedings. AGREEMENT Page 7 of 23 "TINY HOUSE" CONSTRUCTION AND DEMONSTRATION e) Binding Effect. The terms, covenants, conditions, and provisions of this Agreement shall bind and inure to the benefit of the County and Contractor and their respective legal representatives, successors, and assigns. f) Authority. Each party represents and warrants to the other that the execution, delivery and performance of this Agreement have been duly authorized by all necessary County and corporate action, as required by law. Each party agrees that it has had ample opportunity to submit this Contract to legal counsel of its choice and enters into this agreement freely, voluntarily and with advice of counsel. g) Claims for Federal or State Aid. Contractor and County agree that each shall be, and is, empowered to apply for, seek, and obtain federal and state funds to further the purpose of this Agreement; provided that all applications, requests, grant proposals, and funding solicitations shall be approved by each party prior to submission. h) Adjudication of Disputes or Disagreements. County and Contractor agree that all disputes and disagreements shall be attempted to be resolved by meet and confer sessions between representatives of each of the parties. If the issue or issues are still not resolved to the satisfaction of the parties, then any party shall have the right to seek such relief or remedy as may be provided by this Agreement or by Florida law. This Agreement is not subject to arbitration. i) Cooperation. In the event any administrative or legal proceeding is instituted against either party relating to the formation, execution, performance, or breach of this Agreement, County and Contractor agree to participate, to the extent required by the other party, in all proceedings, hearings, processes, meetings, and other activities related to the substance of this Agreement or provision of the services under this Agreement. County and Contractor specifically agree that no party to this Agreement shall be required to enter into any arbitration proceedings related to this Agreement. j) Nondiscrimination. The parties agree that there will be no discrimination against any person, and it is expressly understood that upon a determination by a court of competent jurisdiction that discrimination has occurred, this Agreement automatically terminates without any further action on the part of any party, effective the date of the court order. The parties agree to comply with all Federal and Florida statutes, and all local ordinances, as applicable, relating to nondiscrimination. These include but are not limited to: 1)Title VII of the Civil Rights Act of 1964 (PL 88-352), which prohibits discrimination in employment on the basis of race, color, religion, sex, and national origin;2)Title IX of the Education Amendment of 1972, as amended(20 USC§§ 1681- 1683, and 1685-1686), which prohibits discrimination on the basis of sex; 3) Section 504 of the Rehabilitation Act of 1973, as amended (20 USC § 794), which prohibits discrimination on the basis of handicaps; 4) The Age Discrimination Act of 1975, as amended (42 USC §§6101-6107), which prohibits discrimination on the basis of age; 5) The Drug Abuse Office and Treatment Act of 1972 (PL 92-255), as amended, relating to nondiscrimination on the basis of drug abuse; 6)The Comprehensive Alcohol Abuse and Alcoholism Prevention, Treatment and Rehabilitation Act of 1970 (PL 91-616), as amended, relating to nondiscrimination on the basis of alcohol abuse or alcoholism; 7) The Public Health Service Act of 1912, §§ 523 and 527 (42 USC §§690dd-3 and 290ee-3), as amended, relating to confidentiality of alcohol and drug abuse patent records; 8)Title VIII of the Civil Rights Act of 1968 (42 USC §§ 3601 et AGREEMENT Page 8 of 23 "TINY HOUSE" CONSTRUCTION AND DEMONSTRATION seq.), as amended, relating to nondiscrimination in the sale, rental or financing of housing; 9) The Americans with Disabilities Act of 1990 (42 USC §§ 12101), as amended from time to time, relating to nondiscrimination in employment on the basis of disability; 10) Monroe County Code Chapter 14, Article II, which prohibits discrimination on the basis of race,color, sex,religion, national origin,ancestry, sexual orientation, gender identity or expression, familial status or age; and 11) any other nondiscrimination provisions in any federal or state statutes which may apply to the parties to, or the subject matter of, this Agreement. During the performance of this Agreement, the Contractor, in accordance with Equal Employment Opportunity(30 Fed. Reg. 12319, 12935, 3 C.F.R. Part, 1964-1965 Comp., p. 339), as amended by Executive Order 11375, Amending Executive Order 11246 Relating to Equal Employment Opportunity, and implementing regulations at 41 C.F.R. Part 60 (Office of Federal Contract Compliance Programs, Equal Employment Opportunity, Department of Labor). See 2 C.F.R. Part 200, Appendix II,¶C, agrees as follows: 1) The Contractor will not discriminate against any employee or applicant for employment because of race, color, religion, sex, sexual orientation, gender identity, or national origin. The Contractor will take affirmative action to ensure that applicants are employed, and that employees are treated during employment, without regard, to their race, color, religion, sex, sexual orientation,gender identity, or national origin. Such action shall include, but not be limited to the following: Employment, upgrading, demotion, or transfer, recruitment or recruitment advertising; layoff or termination; rates of pay or other forms of compensation; and selection for training, including apprenticeship.The Contractor agrees to post in conspicuous places,available to employees and applicants for employment, notices to be provided by the contracting officer setting forth the provisions of this nondiscrimination clause. 2) The Contractor will, in all solicitations or advertisements for employees placed by or on behalf of the Contractor, state that all qualified applicants will receive consideration for employment without regard to race, color, religion, sex, sexual orientation, gender identity, or national origin. 3) The Contractor will not discharge or in any other manner discriminate against any employee or applicant for employment because such employee or applicant has inquired about, discussed, or disclosed the compensation of the employee or applicant or another employee or applicant. This provision shall not apply to instances in which an employee who has access to the compensation information of other employees or applicants as a part of such employee's essential job functions discloses the compensation of such other employees or applicants to individuals who do not otherwise have access to such information, unless such disclosure is in response to a formal complaint or charge, in furtherance of an investigation, proceeding, hearing, or action, including an investigation conducted by the employer, or is consistent with the contractor's legal duty to furnish information. AGREEMENT Page 9 of 23 "TINY HOUSE" CONSTRUCTION AND DEMONSTRATION 4) The Contractor will send to each labor union or representative of workers with which it has a collective bargaining agreement or other contract or understanding, a notice to be provided by the agency contracting officer, advising the labor union or workers' representative of the contractor's commitments under section 202 of Executive Order 11246 of September 24, 1965, and shall post copies of the notice in conspicuous places available to employees and applicants for employment. 5) The Contractor will comply with all provisions of Executive Order 11246 of September 24, 1965, and of the rules, regulations, and relevant orders of the Secretary of Labor. 6) The Contractor will furnish all information and reports required by Executive Order 11246 of September 24, 1965, and by the rules, regulations, and orders of the Secretary of Labor, or pursuant thereto, and will permit access to his books, records, and accounts by the contracting agency and the Secretary of Labor for purposes of investigation to ascertain compliance with such rules, regulations, and orders. 7) In the event of the Contractor's non-compliance with the nondiscrimination clauses of this contract or with any of such rules, regulations, or orders, this contract may be canceled,terminated or suspended in whole or in part and the contractor may be declared ineligible for further Government contracts or federally assisted construction contracts in accordance with procedures authorized in Executive Order 11246 of September 24, 1965, and such other sanctions may be imposed and remedies invoked as provided in Executive Order 11246 of September 24, 1965, or by rule, regulation, or order of the Secretary of Labor, or as otherwise provided by law. 8) The Contractor will include the portion of the sentence immediately preceding paragraph (1) and the provisions of paragraphs (1) through (8) in every subcontract or purchase order unless exempted by rules, regulations,or orders of the Secretary of Labor issued pursuant to section 204 of Executive Order 11246 of September 24, 1965, so that such provisions will be binding upon each subcontractor or vendor. The Contractor will take such action with respect to any subcontract or purchase order as the administering agency may direct as a means of enforcing such provisions, including sanctions for non- compliance; provided, however, that in the event a contractor becomes involved in, or is threatened with, litigation with a subcontractor or vendor as a result of such direction by the administering agency the contractor may request the United States to enter into such litigation to protect the interests of the United States. k) Covenant of No Interest. County and Contractor covenant that neither presently has any interest, and shall not acquire any interest, which would conflict in any manner or degree with its performance under this Agreement, and that only interest of each is to perform and receive benefits as recited in this Agreement. AGREEMENT Page 10 of 23 "TINY HOUSE" CONSTRUCTION AND DEMONSTRATION I) Code of Ethics. County agrees that officers and employees of the County recognize and will be required to comply with the standards of conduct for public officers and employees as delineated in Section 112.313, Florida Statutes, regarding, but not limited to, solicitation or acceptance of gifts; doing business with one's agency; unauthorized compensation; misuse of public position, conflicting employment or contractual relationship; and disclosure or use of certain information. m) No Solicitation/Payment. The County and Contractor warrant that, in respect to itself, it has neither employed nor retained any company or person, other than a bona fide employee working solely for it, to solicit or secure this Agreement and that it has not paid or agreed to pay any person, company, corporation, individual, or firm, other than a bona fide employee working solely for it, any fee, commission, percentage, gift, or other consideration contingent upon or resulting from the award or making of this Agreement. For the breach or violation of the provision, the Contractor agrees that the County shall have the right to terminate this Agreement without liability and, at its discretion, to offset from monies owed, or otherwise recover, the full amount of such fee, commission, percentage, gift, or consideration. n) Public Access. Public Records Compliance. Contractor must comply with Florida public records laws, including but not limited to Chapter 119, Florida Statutes and Section 24 of article I of the Constitution of Florida. The County and Contractor shall allow and permit reasonable access to, and inspection of, all documents, records, papers, letters or other "public record" materials in its possession or under its control subject to the provisions of Chapter 119, Florida Statutes, and made or received by the County and Contractor in conjunction with this contract and related to contract performance. The County shall have the right to unilaterally cancel this contract upon violation of this provision by the Contractor. Failure of the Contractor to abide by the terms of this provision shall be deemed a material breach of this contract and the County may enforce the terms of this provision in the form of a court proceeding and shall, as a prevailing party, be entitled to reimbursement of all attorney's fees and costs associated with that proceeding. This provision shall survive any termination or expiration of the contract. The Contractor is encouraged to consult with its advisors about Florida Public Records Law in order to comply with this provision. Pursuant to Fla. Stat. Sec. 119.0701 and the terms and conditions of this contract, the Contractor is required to: (1) Keep and maintain public records that would be required by the County to perform the service. (2) Upon receipt from the County's custodian of records, provide the County with a copy of the requested records or allow the records to be inspected or copied within a reasonable time at a cost that does not exceed the cost provided in this chapter or as otherwise provided by law. (2) Ensure that public records that are exempt or confidential and exempt from public records disclosure requirements are not disclosed except as authorized by law for the duration of the contract term and following AGREEMENT Page 11 of 23 "TINY HOUSE" CONSTRUCTION AND DEMONSTRATION completion of the contract if the contractor does not transfer the records to the County. (4) Upon completion of the contract, transfer, at no cost, to the County all public records in possession of the Contractor or keep and maintain public records that would be required by the County to perform the service. If the Contractor • transfers all public records to the County upon completion of the contract,the Contractor shall destroy any duplicate public records that are exempt or confidential and exempt from public records disclosure requirements. If the Contractor keeps and maintains public records upon completion of the contract, the Contractor shall meet all applicable requirements for retaining public records. All records stored electronically must be provided to the County, upon request from the County's custodian of records, in a format that is compatible with the information technology systems of the County. (5) A request to inspect or copy public records relating to a County contract must • be made directly to the County, but if the County does not possess the requested records, the County shall immediately notify the Contractor of the request, and the Contractor must provide the records to the County or allow the records to be inspected or copied within a reasonable time. If the Contractor does not comply with the County's request for records, the County shall enforce the public records contract provisions in accordance with the contract, notwithstanding the County's option and right to unilaterally cancel this contract upon violation of this provision by the Contractor. A Contractor who fails to provide the public records to the County or pursuant to a valid public records request within a reasonable time may be subject to penalties under Section 119.10, Florida Statutes. The Contractor shall not transfer custody, release,alter, destroy or otherwise dispose of any public records unless or otherwise provided in this provision or as otherwise provided by law. IF THE CONTRACTOR HAS QUESTIONS REGARDING THE APPLICATION OF CHAPTER 119, FLORIDA STATUTES, TO THE CONTRACTOR'S DUTY TO PROVIDE PUBLIC RECORDS RELATING TO THIS CONTRACT, CONTACT THE CUSTODIAN OF PUBLIC RECORDS, BRIAN BRADLEY AT PHONE# 305-292-3470 BRADLEY- BRIAN@MONROECOUNTY-FL.GOV, MONROE COUNTY ATTORNEY'S OFFICE 1111 12TH Street, SUITE 408, KEY WEST, FL 33040. o) Non-Waiver of Immunity. Notwithstanding the provisions of Sec. 768.28, Florida Statutes, the participation of the Contractor and the County in this Agreement and the acquisition of any commercial liability insurance coverage,self-insurance coverage, or local government liability insurance pool coverage shall not be deemed a waiver of immunity to the extent of liability coverage, nor shall any contract entered into by the County be required to contain any provision for waiver. p) Privileges and Immunities.All of the privileges and immunities from liability, exemptions from laws, ordinances, and rules and pensions and relief, disability, workers' compensation, and other benefits which apply to the activity of officers, agents, or AGREEMENT Page 12 of 23 "TINY HOUSE" CONSTRUCTION AND DEMONSTRATION employees of any public agents or employees of the County, when performing their respective functions under this Agreement within the territorial limits of the County shall apply to the same degree and extent to the performance of such functions and duties of such officers, agents, volunteers, or employees outside the territorial limits of the County. q) Legal Obligations and Responsibilities: Non-Delegation of Constitutional or Statutory Duties. This Agreement is not intended to, nor shall it be construed as, relieving any participating entity from any obligation or responsibility imposed upon the entity by law except to the extent of actual and timely performance thereof by any participating entity, in which case the performance may be offered in satisfaction of the obligation or responsibility. Further, this Agreement is not intended to, nor shall it be construed as, authorizing the delegation,of the constitutional or statutory duties of the County, except to the extent permitted by the Florida constitution, state statute, and case law. r) Non-Reliance by Non-Parties. No person or entity shall be entitled to rely upon the terms, or any of them, of this Agreement to enforce or attempt to enforce any third- party claim or entitlement to or benefit of any service or program contemplated hereunder, and the County and the Contractor agree that neither the County nor the Contractor or any agent, officer, or employee of either shall have the authority to inform, counsel, or otherwise indicate that any particular individual or group of individuals, entity or entities, have entitlements or benefits under this Agreement separate and apart, inferior to, or superior to the community in general or for the purposes contemplated in this Agreement. s) Attestations. Contractor agrees to execute such documents as the County may reasonably require, to include a Public Entity Crime Statement, an Ethics Statement, and a Drug-Free Workplace Statement. t) No Personal Liability. No covenant or.agreement contained herein shall be deemed to be a covenant or agreement of any member, officer, agent or employee of Monroe County in his or her individual capacity, and no member, officer, agent or employee of Monroe County shall be liable personally on this Agreement or be subject to any personal liability or accountability by reason of the execution of this Agreement. u) Execution in Counterparts. This Agreement may be executed in any number of counterparts, each of which shall be regarded as an original, all of which taken together shall constitute one and the same instrument and any of the parties hereto may execute this Agreement by signing any such counterpart. v) Hold Harmless and Indemnification. Notwithstanding any minimum insurance requirements prescribed elsewhere in this agreement, Contractor shall defend, indemnify and hold the COUNTY and the COUNTY's elected and appointed officers and employees harmless from and against(i) any claims, actions or causes of action, (ii) any litigation, administrative proceedings, appellate proceedings, or other proceedings relating to any type of injury(including death), loss, damage, fine, penalty or business interruption, and (iii) any costs or expenses that may be asserted against, initiated with respect to, or sustained by, any indemnified party by reason of, or in connection with, (A) any activity of Contractor or any of its employees, agents, contractors or other invitees during the term of this Agreement, (B) the negligence or recklessness, intentional wrongful misconduct, errors or other wrongful act or omission AGREEMENT Page 13 of 23 "TINY HOUSE" CONSTRUCTION AND DEMONSTRATION of Contractor or any of its employees, agents, sub-contractors or other invitees, or(C) Contractor's default in respect of any of the obligations that it undertakes under the terms of this Agreement, except to the extent the claims, actions, causes of action, litigation, proceedings, costs or expenses arise from the intentional or sole negligent acts or omissions of the COUNTY or any of its employees, agents, contractors or invitees (other than Contractor). The monetary limitation of liability under this contract shall be.not less than $1 million per occurrence pursuant to F. S. 725.06. Insofar as the claims, actions, causes of action, litigation, proceedings, costs or expenses relate to events or circumstances that occur during the term of this Agreement, this section will survive the expiration of the term of this Agreement or any earlier termination of this Agreement. In the event that the completion of the project(to include the work of others) is delayed or suspended as a result of the Contractor s failure to purchase or maintain the required insurance, the Contractor shall indemnify the County from any and all increased expenses resulting from such delay. Should any claims be asserted against the County by virtue of any deficiency or ambiguity in the plans and specifications provided by the Contractor, the Contractor agrees and warrants that the Contractor shall hold the County harmless and shall indemnify it from all losses occurring thereby and shall further defend any claim or action on the County's behalf. The first ten dollars ($10.00) of remuneration paid to' the Contractor is for the indemnification provided for the above. FDEM Indemnification To the fullest extent permitted by law,the Contractor shall indemnify and hold harmless the Agency, the State of Florida, Department of Emergency Management, and its officers and employees, from liabilities, damages, losses and costs, including, but not limited to, reasonable attorney's fees, to the extent caused by the negligence, recklessness or intentional wrongful misconduct of the Contractor and persons employed or utilized by the Contractor in the performance of this Contract. This indemnification shall survive the termination of this Contract. Nothing contained in this paragraph is intended to nor shall it constitute a waiver of the State of Florida and the (County)Agency's sovereign immunity. w) Section Headings. Section headings have been inserted in this Agreement as a matter of convenience of reference only, and it is agreed that such section headings are not a part of this Agreement and will not be used in the interpretation of any provision of this Agreement. x) Agreements with Subcontractors. In the event that the Contractor subcontracts any or all of the work in this project to any third party, the Contractor specifically agrees to identify the COUNTY as an additional insured on all insurance policies required by the County. In addition, the Contractor specifically agrees that all agreements or contracts of any nature with his subcontractors shall include the COUNTY as additional insured. y) Florida Green Building Coalition Standards. Monroe County requires its buildings to conform to Florida Green Building Coalition standards. AGREEMENT Page 14 of 23 "TINY HOUSE" CONSTRUCTION AND DEMONSTRATION Special Conditions, if any are detailed in Section 00100 of the Project Manual for this Project. 7.7 Any written notices or correspondence given pursuant to this contract shall be sent by United States Mail, certified, return receipt requested, or by courier with proof of delivery. Notice shall be sent to the following persons: For Contractor: Advanced Construction Technologies, LLC Pete Masalin, Executive Vice President,Administration 3706 N. Roosevelt Blvd., Suite 708 Key West, Florida 33040 For Owner: Director of Project Management County Attorney 1100 Simonton St., Room 2-216 1111 12th Street, Suite 408 Key West, Florida 33040 Key West, Florida 33040 7.8 FEDERAL CONTRACT REQUIREMENTS The CONTRACTOR and its subcontractors must follow the provisions, as applicable, as set forth in 2 C.F.R. §200.326 Contract provisions and Appendix II to 2 C.F.R. Part 200, as amended, including but not limited to: 7.8.1 Clean Air Act and the Federal Water Pollution Control Act. CONTRACTOR agrees to comply with all applicable standards, orders, or regulations issued pursuant to the Clean Air Act(42 U.S.C. 7401-7671q) and the Federal Water Pollution Control Act as amended (33 U.S.C. 1251-1387). 7.8.2 Davis-Bacon Act,as amended (40 U.S.C. 3141-3148).When required by Federal program legislation, which includes emergency Management Preparedness Grant Program, Homeland Security Grant Program, Nonprofit Security Grant Program, Tribal Homeland Security Grant Program, Port Security Grant Program and Transit Security Grant Program, all prime construction contracts in excess of$2,000 awarded by non-Federal entities must comply with the Davis-Bacon Act(40 U.S.C. 31413144 and 3146-3148)as supplemented by Department of Labor regulations (29 CFR Part 5, "Labor Standards Provisions Applicable to Contracts Covering Federally Financed and Assisted Construction"). In accordance with the statute, CONTRACTORS must be required to pay wages to laborers and mechanics at a rate not less than the prevailing wages specified in a wage determination made by the Secretary of Labor. In addition, CONTRACTORS must be required to pay wages not less than once a week. If applicable, the COUNTY must place a copy of the current prevailing wage determination issued by the Department of Labor in each solicitation (attached hereto as Exhibit A). The decision to award a contract or subcontract must be conditioned upon the acceptance of the wage determination. The COUNTY must report all suspected or reported violations to the Federal awarding agency. When required by Federal program legislation,which includes emergency Management Preparedness Grant Program, Homeland Security Grant Program, Nonprofit Security Grant Program, Tribal Homeland Security Grant Program, Port Security Grant Program and Transit Security AGREEMENT Page 15 of 23 "TINY HOUSE" CONSTRUCTION AND DEMONSTRATION Grant Program (it does not apply to other FEMA grant and cooperative agreement programs, including the Public Assistance Program), the CONTRACTORS must also comply with the Copeland "Anti-Kickback" Act (40 U.S.C. 3145), as supplemented by Department of Labor regulations (29 CFR Part 3, "Contractors and Subcontractors on Public Building or Public Work Financed in Whole or in Part by Loans or Grants from the United States").As required by the Act, each CONTRACTOR or subrecipient is prohibited from inducing, by any means, any person employed in the construction, completion, or repair of public work, to give up any part of the compensation to which he or she is otherwise entitled. The COUNTY must report all suspected or reported violations to the Federal awarding agency. 1) The CONTRACTOR shall comply with 18 U.S.C. § 874, 40 U.S.C. § 3145, and the requirements of 29 C.F.R. pt. 3 as may be applicable, which are incorporated by reference into this contract. 2) Subcontracts. The CONTRACTOR or subcontractor shall insert in any subcontracts the clause above and such other clauses as the FEMA may by appropriate instructions require, and also a clause requiring the subcontractors to include these clauses in any lower tier subcontracts.The prime CONTRACTOR shall be responsible for the compliance by any subcontractor or lower tier subcontractor with all of these contract clauses. 3) Breach. A breach of the contract clauses above may be grounds for termination of the contract, and for debarment as a contractor and subcontractor as provided in 29 C.F.R. § 5.12. 7.8.3 Contract Work Hours and Safety Standards Act(40 U.S.C.3701-3708).Where applicable, which includes all FEMA grant and cooperative agreement programs, all contracts awarded by the COUNTY in excess of $100,000 that involve the employment of mechanics or laborers must comply with 40 U.S.C. 3702 and 3704, as supplemented by Department of Labor regulations (29 CFR Part 5). Under 40 U.S.C. 3702 of the Act, each CONTRACTOR must compute the wages of every mechanic and laborer on the basis of a standard work week of forty (40) hours. Work in excess of the standard work week is permissible provided that the worker is compensated at a rate of not less than one and a half times the basic rate of pay for all hours worked in excess of forty (40) hours in the work week. The requirements of 40 U.S.C. 3704 are applicable to construction work and provide that no laborer or mechanic must be required to work in surroundings or under working conditions which are unsanitary, hazardous, or dangerous. These requirements do not apply to the purchases of supplies or materials or articles ordinarily available on the open market, or contracts for transportation or transmission of intelligence. 7.8.4 Rights to Inventions Made Under a Contract or Agreement. If the Federal award meets the definition of "funding agreement" under 37 CFR §401.2 (a) and the recipient or subrecipient wishes to enter into a contract with a small business firm or nonprofit organization regarding the substitution of parties, assignment or performance of experimental, developmental, or research work under that "funding agreement," the recipient or subrecipient must comply with the requirements of 37 CFR Part 401, "Rights to Inventions Made by Nonprofit Organizations and Small Business Firms Under Government Grants, Contracts and Cooperative Agreements," and any implementing regulations issued by the awarding agency. AGREEMENT Page 16 of 23 "TINY HOUSE" CONSTRUCTION AND DEMONSTRATION 7.8.5 Clean Air Act(42 U.S.C. 7401-7671o.),Water Pollution Control Act(33 U.S.C. 1251-1387) as amended. Contracts and subgrants of amounts in excess of $150,000 must comply with all applicable standards, orders, or regulations issued pursuant to the Clean Air Act (42 U.S.C. 7401-7671q) and the Federal Water Pollution Control Act as amended (33 U.S.C. 1251-1387). Violations must be reported to the Federal awarding agency and the Regional Office of the Environmental Protection Agency (EPA). 7.8.6 Debarment and Suspension (Executive Orders 12549 and 12689).A contract award (see 2 CFR 180.220) must not be made to parties listed on the government wide exclusions in the System for Award Management (SAM), in accordance with the OMB guidelines at 2 CFR 180 that implement Executive Orders 12549 (3 CFR part 1986 Comp., p. 189) and 12689 (3 CFR part 1989 Comp., p. 235), "Debarment and Suspension." SAM Exclusions contains the names of parties debarred, suspended, or otherwise excluded by agencies, as well as parties declared ineligible under statutory or regulatory authority other than Executive Order 12549. 7.8.7 Byrd Anti-Lobbvina Amendment (31 U.S.C. 1352). CONTRACTORS that apply or bid for an award exceeding $100,000 must file the required certification. Each tier certifies to the tier above that it will not and has not used Federal appropriated funds to pay any person or organization for influencing or attempting to influence an officer or employee of any agency, a member of Congress, officer or employee of Congress, or an employee of a member of Congress in connection with obtaining any Federal contract,grant or any other award covered by 31 U.S.C. 1352. Each tier must also disclose any lobbying with non- Federal funds that takes place in connection with obtaining any Federal award. Such disclosures are forwarded from tier to tier up to the non-Federal award. 7.8.8 Compliance with Procurement of recovered materials as set forth in 2 CFR § 200.322. CONTRACTOR must comply with section 6002 of the Solid Waste Disposal Act, as amendment by the Resource Conservation and Recovery Act. The requirements of Section 6002 include procuring only items designed in guidelines of the Environmental Protection Agency (EPA at 40 CPR part 247 that contain the highest percentage of recovered materials practicable, consistent with maintaining a satisfactory level of competition, where the purchase price of the item exceeds $10,000 or the value of the quantity acquired during the preceding fiscal year exceeded $10,000; procuring solid waste management services in a manner that maximizes energy and resource recovery; and establishing an affirmative procurement program for procurement of recovered materials identified in the EPA guidelines. (1) In the performance of this contract, the CONTRACTOR shall make maximum use of products containing recovered materials that are EPA-designated items unless the product cannot be acquired (i) Competitively within a timeframe providing for compliance with the contract performance schedule; (ii) Meeting contract performance requirements; or (iii) At a reasonable price. (2) Information about this requirement, along with the list of EPA-designated items, is available at EPA's Comprehensive Procurement Guidelines web site, https://www.epa.o ov/smm/comprehensive-procurement-guideline-cpq-progra m. Other Federal Requirements (as applicable): AGREEMENT Page 17 of 23 "TINY HOUSE" CONSTRUCTION AND DEMONSTRATION 7.8.9 Americans with Disabilities Act of 1990, as amended, (ADA). The CONTRACTOR will comply with all the requirements as imposed by the ADA, the regulations of the Federal government issued thereunder, and the assurance by the CONTRACTOR pursuant thereto. 7.8.10 Disadvantaaed Business Enterprise (DBE) Policy and Obligation. It is the policy of the COUNTY that DBE's, as defined in 49 C.F.R. Part 26, as amended, shall have the opportunity to participate in the performance of contracts financed in whole or in part with COUNTY funds under this Agreement. The DBE requirements of applicable federal and state laws and regulations apply to this Agreement.The COUNTY and its CONTRACTOR agree to ensure that DBE's have the opportunity to participate in the performance of this Agreement. In this regard, all recipients and contractors shall take all necessary and reasonable steps in accordance with 2 C.F.R. § 200.321(as set forth in detail below), applicable federal and state laws and regulations to ensure that the DBE's have the opportunity to compete for and perform contracts. The COUNTY and the CONTRACTOR and subcontractors shall not discriminate on the basis of race, color, national origin or sex in the award and performance of contracts, entered pursuant to this Agreement. 2 C.F.R. § 200.321 CONTRACTING WITH SMALL AND MINORITY BUSINESSES, WOMEN'S BUSINESS ENTERPRISES, AND LABOR SURPLUS AREA FIRMS a. If the CONTRACTOR,with the funds authorized by this Agreement, seeks to subcontract goods or services, then, in accordance with 2 C.F.R. §200.321, the CONTRACTOR shall take the following affirmative steps to assure that minority businesses, women's business enterprises, and labor surplus area firms are used whenever possible. b. Affirmative steps must include: 1. Placing qualified small and minority businesses and women's business enterprises on solicitation lists; 2. Assuring that small and minority businesses, and women's business enterprises are solicited whenever they are potential sources; 3. Dividing total requirements, when economically feasible, into smaller tasks or quantities to permit maximum participation by small and minority businesses, and women's business enterprises; 4. Establishing delivery schedules, where the requirement permits, which encourage participation by small and minority businesses, and women's business enterprises; 5. Using the services and assistance, as appropriate, of such organizations as the Small Business Administration and the Minority Business Development Agency of the Department of Commerce. 6. Requiring'the Prime contractor, if subcontractor are to be let, to take the affirmative steps listed in paragraph (1)through (5) of this section. 7.8.11 The CONTRACTOR shall utilize the U.S. Department of Homeland Security's E-Verify system to verify the employment eligibility of all new employees hired by the CONTRACTOR during the term of the Contract and shall expressly require any subcontractors performing work or providing services pursuant to the Contract to likewise utilize the U.S. Department of Homeland Security's E-Verify system to verify the AGREEMENT Page 18 of 23 "TINY HOUSE" CONSTRUCTION AND DEMONSTRATION employment eligibility of all new employees hired by the subcontractor during the Contract term. 7.8.12 Fraud and False or Fraudulent or Related Acts. The CONTRACTOR acknowledges that 31 U.S.C. Chap. 38 (Administrative Remedies for False Claims and Statements) applies to the CONTRACTOR'S actions pertaining to this contract. 7.8.13 Access to Records.The following access to records requirements apply to this contract: (1) The CONTRACTOR agrees to provide MONROE COUNTY, the FEMA Administrator, the Comptroller General of the United States, or any of their authorized representatives access to any books, documents, papers, and records of the CONTRACTOR which are directly pertinent to this contract for the purposes of making audits, examinations, excerpts, and transcriptions. (2) The CONTRACTOR agrees to permit any of the foregoing parties to reproduce by any means whatsoever or to copy excerpts and transcriptions as reasonably needed. (3) The CONTRACTOR agrees to provide the FEMA Administrator or his authorized representatives access to construction or other work sites pertaining to the work being completed under the contract. 7.9 The Contractor is bound by all applicable local, County, State, and Federal laws and regulations. 7.10 The CONTRACTOR shall hold the Division and County harmless against all claims of whatever nature arising out of the CONTRACTOR'S performance of work under this Agreement, to the extent allowed and required by law. ARTICLE 8 Termination or Suspension 8.1 The Contract may be terminated by the Owner as provided in Article 14 of the General Conditions. A. In the event that the CONTRACTOR shall be found to be negligent in any aspect of service, the COUNTY shall have the right to terminate this agreement after five (5) days' written notification to the CONTRACTOR. B. Either of the parties hereto may cancel this Agreement without cause by giving the other party sixty (60) days'written notice of its intention to do so. C. Termination for Cause and Remedies: In the event of breach of any contract terms, the COUNTY retains the right to terminate this Agreement. The COUNTY may also terminate this agreement for cause with CONTRACTOR should CONTRACTOR fail to perform the covenants herein contained at the time and in the manner herein provided. In the event of such termination, prior to termination, the COUNTY shall provide CONTRACTOR with seventy-two (72) hours' notice and provide the AGREEMENT Page 19 of 23 • "TINY HOUSE" CONSTRUCTION AND DEMONSTRATION CONTRACTOR with an opportunity to cure the breach that has occurred. If the breach is not cured, the Agreement will be terminated for cause. If the COUNTY terminates this agreement with the CONTRACTOR, COUNTY shall pay CONTRACTOR the sum due the CONTRACTOR under this agreement prior to termination, unless the cost of completion to the COUNTY exceeds the funds remaining in the contract; however, the COUNTY reserves the right to assert and seek an offset for damages caused by the breach. The maximum amount due to CONTRACTOR shall not in any event exceed the spending cap in this Agreement. In addition, the COUNTY reserves all rights available to recoup monies paid under this Agreement, including the right to sue for breach of contract and including the right to pursue a claim for violation of the COUNTY's False Claims Ordinance, located at Section 2-721 et al. of the Monroe County Code. D. Termination for Convenience: The COUNTY may terminate this Agreement for convenience, at any time, upon sixty (60) days' notice to CONTRACTOR. If the COUNTY terminates this agreement with the CONTRACTOR, COUNTY shall pay CONTRACTOR the sum due the CONTRACTOR under this agreement prior to termination, unless the cost of completion to the COUNTY exceeds the funds remaining in the contract. The maximum amount due to CONTRACTOR shall not exceed the spending cap in this Agreement. In addition, the COUNTY reserves all rights available to recoup monies paid under this Agreement, including the right to sue for breach of contract and including the right to pursue a claim for violation of the COUNTY's False Claims Ordinance, located at Section 2-721 et al. of the Monroe County Code. E. Scrutinized Companies. For Contracts of any amount, if the County determines that the Contractor/Consultant has submitted a false certification under Section 287.135(5), Florida Statutes or has been placed on the Scrutinized Companies that Boycott Israel List,or is engaged in a boycott of Israel,the County shall have the option of (1) terminating the Agreement after it has given the Contractor/Consultant written notice and an opportunity to demonstrate the agency's determination of false certification was in error pursuant to Section 287.135(5)(a), Florida Statutes, or (2) maintaining the Agreement if the conditions of Section 287.135(4), Florida Statutes, are met. ARTICLE 9 Enumeration of Contract Documents 9.1 The Contract Documents, except for Modifications issued after execution of this Agreement, are enumerated as follows: a) Drawings: None b) Project Manual: None c) Detailed Site Specific Information: See Appendix I of the RFP for the specific site AGREEMENT Page 20 of 23 "TINY HOUSE" CONSTRUCTION AND DEMONSTRATION 9.1.1 The Agreement is this executed Standard Form of Agreement Between Owner and Contractor. 9.1.2 The General Conditions are the General Conditions of the Contract for Construction. 9.1.3 The Supplementary and other Conditions of the Contract are those contained in the Project Manual dated: None 9.1.4 The Addenda, if any, are as follows: Number Date Pages 1 August 21, 2018 10 2 September 12, 2018 1 This Agreement is entered into as of the day and year first written above and is executed in at least three (3) original copies of which one (1) is to be delivered to the Contractor. BALANCE OF PAGE INTENTIONALLY LEFT BLANK SIGNATURE PAGE TO FOLLOW • AGREEMENT Page 21 of 23 "TINY HOUSE" CONSTRUCTION AND DEMONSTRATION " `rcl E by the Contractor must be by a person with authority to bind the entity. , ' ' ` eT`4° .'?= OF THE PERSON EXECUTING THE DOCUMENT MUST BE NOTARIZED. `.,, BOARD OF COUNTY COMMISSIONERS <}" - r- Madok, Clerk OF MONROE COUNTY, FLORIDA :.43„-,.::* ,,,, i litospefr„, By: putt' Clerk yor/Chairma Date 17 1,o' - (SEAL) CONTRACTOR'S Witnesses Attest: CONTRACTOR: ADVANCED Contractor must provide two witnesses CONSTRU 0 T H L IES, LLC signatures ,L. Signatu Signatu0C) " r`� Y r� Print Name: FC-4 ee II ct sel 1 i h Print Name: Jtit Ra:,/auta►-\ Title: CO O Title: Date: ` 1/3 i/7vp 11 Date: 01.1 3 t I n • and Signature: MONROE COUNTY ATTORNEY' OFFICE n PRQVED AS TO O� Print a \ PATRICIA-a'� [ FABLES ASSISTANT COUNTY ATTORNEY Title: I DATE: . t rZ-I 1 Date: \ \C\ ' c-. f,4 : ..11 " , STATE OF FLORIDA, COUNTY OF t'--4 O v-+ r0-L-- r)::"-` I -rt (---;: ca el On this 'cfi day of 1 t ) 1 , 201 q before me, the undersigned notary publico personally appeared pcA-..c_ -,•.l i rN known to me to be the person whas4-iame TS subscribed above or who produced as identification, and achnowledg6d 2 _k, that he/she is the person who executed the above contract with Monroe County for "TV/ c HOUSE" CONSTRUCTION AND DEMONSTRATION for the purposes therein contained. Notary Public: ��t'��P°� ELVEGA Print Nam ,,.. P� l �0 a Cs (/\ N1). `I' g WIRES:March 2�0C221 J 4'OF FLOP Bonded nu Navy sentes My commission expires:hlot✓c- ' -. 2� 20 - I (Seal) AGREEMENT Page 22 of 23 "TINY HOUSE" CONSTRUCTION AND DEMONSTRATION EXHIBIT "A" Davis-Bacon Wage Determination AGREEMENT Page 23 of 23 beta.SAM.gov Page 1 of 7 "General Decision Number: FL20190045 01/04/2019 Superseded General Decision Number: FL20180088 State: Florida Construction Type: Residential County: Monroe County in Florida. RESIDENTIAL CONSTRUCTION PROJECTS (consisting of single family homes and apartments up to and including 4 stories) . Note: Under Executive Order (EO) 13658, an hourly minimum wage of $10.60 for calendar year 2019 applies to all contracts subject to the Davis-Bacon Act for which the contract is awarded (and any solicitation was issued) on or after January 1, 2015. • If this contract is covered by the E0, the contractor must pay all workers in any classification listed on this wage determination at least $10.60 per hour (or the applicable wage rate listed on this wage determination, if it is higher) for all hours spent performing on the contract in calendar year 2019. If this contract is covered by the EO and a classification considered necessary for performance of work on the contract does not appear on this wage determination, the contractor must pay workers in that classification at least the wage rate determined through the conformance process set forth in 29 CFR 5.5(a) (1) (ii) (or the EO minimum wage rate, if it is higher than the conformed wage rate) . The EO minimum wage rate will be adjusted annually. Please note that this EO applies to the above-mentioned types of contracts entered into by the federal government that are subject https://beta.sam.gov/wage-determination/FL20190045/0/document 7/2/2019 beta.SAM.gov Page 2 of 7 to the Davis-Bacon Act itself, but it does not apply to contracts subject only to the Davis-Bacon Related Acts, including those set forth at 29 CFR 5.1(a) (2)-(60) . Additional information on contractor requirements and worker protections under the EO is available at www.dol.gov/whd/govcontracts. Modification Number Publication Date 0 01/04/2019 " SUFL2009-084 06/08/2009 Rates , Fringes CARPENTER $ 15.83 0.00 CEMENT MASON/CONCRETE FINISHER $ 12.81 0.00 ELECTRICIAN $ 10.80 0.00 HVAC MECEHANIC (HVAC System Installation Only) $ 13.96 0.00 LABORER: Common or General $ 7.25 0.00 LABORER: Mason Tender - Cement/Concrete $ 9.00 0.00 LABORER: Pipelayer $ 9.71 0.00 OPERATOR: Backhoe $ 13.92 0.00 OPERATOR: Loader $ 12.00 0.00 PLUMBER $ 13.23 0.0r https://beta.sam.gov/wage-determination/FL20190045/0/document 7/2/2019 beta.SAM.gov Page 3 of 7 ROOFER, Including Built Up and Shake and Shingle $ 12.70 0.00 TRUCK DRIVER, Dump and Lowboy $ 11.40 0.00 WELDERS - Receive rate prescribed for craft performing operation to which welding is incidental. Note: Executive Order CEO) 13706, Establishing Paid Sick Leave for Federal Contractors applies to all contracts subject to the Davis-Bacon Act for which the contract is awarded (and any solicitation was issued) on or after January 1, 2017. If this contract is covered by the E0, the contractor must provide employees with 1 hour of paid sick leave for every 30 hours they work, up to 56 hours of paid sick leave each year. Employees must be permitted to use paid sick leave for their own illness, injury or other health-related needs, including preventive care; to assist a family member (or person who is like family to the employee) who is ill, injured, or has other health-related needs, including preventive care; or for reasons resulting from, or to assist a family member (or person who is like family to the employee) who is a victim of, domestic violence, sexual assault, or stalking. Additional information on contractor requirements and worker protections under the EO is available at www.dol.gov/whd/govcontracts. Unlisted classifications needed for work not included within the scope of the classifications listed may be added after award only as provided in the labor standards contract clauses (29CFR 5.5 (a) (1) (ii) ) . https://beta.sam.gov/wage-determination/FL20190045/0/document 7/2/2019 beta.SAM.gov Page 4 of 7 The body of each wage determination lists the classification and wage rates that have been found to be prevailing for the cited type(s) of •construction in the area covered by the wage determination. The classifications are listed in alphabetical order of ""identifiers"" that indicate whether the particular rate is a union rate (current union negotiated rate for local) , a survey rate (weighted average rate) or a union average rate (weighted union average rate) . Union Rate' Identifiers A four letter classification abbreviation identifier enclosed in dotted lines beginning with characters other than ""SU"" or ""UAVG"" denotes that the union classification and rate were prevailing for that classification in the survey. Example: PLUM0198-005 07/01/2014. PLUM is an abbreviation identifier of the union which prevailed in the survey for this classification, which in this example would be Plumbers. 0198 indicates the local union number or district council number where applicable, i.e., Plumbers Local 0198. The next number, 005 in the example, is an internal number used in processing the wage determination. 07/01/2014 is the effective date of the most current negotiated rate, which in this example is July 1, 2014. Union prevailing wage rates are updated to reflect all rate changes in the collective bargaining agreement (CBA) governing this classification and rate. Survey Rate Identifiers Classifications listed under the "SU"" identifier indicate that no one rate prevailed for this classification in the survey and the published rate is derived by computing a weighted average rate based on all the rates reported in the survey for that https://beta.sam.gov/wage-determination/FL20190045/0/document 7/2/2019 beta.SAM.gov Page 5 of 7 classification. As this weighted average rate includes all rates reported in the survey, it may include both union and non-union rates. Example: SULA2012-007 5/13/2014. SU indicates the rates are survey rates based on a weighted average calculation of rates and are not majority rates. LA indicates the State of Louisiana. 2012 is the year of survey on which these classifications and rates are based. The next number, 007 in the example, is an internal number used in producing the wage determination. 5/13/2014 indicates the survey completion date for the classifications and rates under that identifier. Survey wage rates are not updated and remain in effect until a new survey is conducted. Union Average Rate Identifiers Classification(s)' listed under the UAVG identifier indicate that no single majority rate prevailed for those classifications; however, 100% of the data reported for the classifications was union data. EXAMPLE: UAVG-OH-0010 08/29/2014. UAVG indicates that the rate is a weighted union average rate. OH indicates the state. The next number, 0010 in the example, is an internal number used in producing the wage determination. 08/29/2014 indicates the survey completion date for the classifications and rates under that identifier. A UAVG rate will be updated once a year, usually in January of each year, to reflect a weighted average of the current negotiated/CBA rate of the union locals from which the rate is based. WAGE DETERMINATION APPEALS PROCESS https://beta.sam.gov/wage-determination/FL20190045/0/document 7/2/2019 beta.SAM.gov Page 6 of 7 1.) Has there been an initial decision in the matter? This can be: • • an existing published wage determination • a survey underlying a wage determination * a Wage and Hour Division letter setting forth a position on a wage determination matter ♦ a conformance (additional classification and rate) ruling On survey related matters, initial contact, including requests for summaries of surveys, should be with the Wage and Hour Regional Office for the area in which the survey was conducted because those Regional Offices have responsibility for the Davis-Bacon survey program. If the response from this initial contact is not satisfactory, then the process described in 2.) and 3.) should be followed. With regard to any other matter not yet ripe for the formal process described here, initial contact should be with the Branch of Construction Wage Determinations. Write to: Branch of Construction Wage Determinations Wage and Hour Division U.S. Department of Labor 200 Constitution Avenue, N.W. Washington, DC 20210 2.) If the answer to the question in 1.) is yes, then an interested party (those affected by the action) can request review and reconsideration from the Wage and Hour Administrator (See 29 CFR Part 1.6 and 29 CFR Part 7) . Write to: Wage and Hour Administrator U.S. Department of Labor 200 Constitution Avenue, N.W. Washington, DC 20210 https://beta.sam.gov/wage-determination/FL20190045/0/document 7/2/2019 beta.SAM.gov Page 7 of 7 The request should be accompanied by a full statement of the interested party's position and by any information (wage payment data, project description, area practice material, etc. ) that the requestor considers relevant to the issue. 3. ) If the decision of the Administrator is not favorable, an interested party may appeal directly to the Administrative Review Board (formerly the Wage Appeals Board) . Write to: Administrative Review Board U.S. Department of Labor 200 Constitution Avenue, N.W. Washington, DC 20210 4. ) All decisions by the Administrative Review Board are final. END OF GENERAL DECISION https:!/beta.sam.gov/wage-determination/FL20190045/0/document 7/2/2019 S.5.b "TINY HOUSE" CONSTRUCTION AND DEMONSTRATION 0 L U) 0 PROPOSER'S INSURANCE AND INDEMNIFICATION STATEMENT INSURANCE REQUIREMENTS c co Worker's Compensation Statutory Limits a Employers Liability $1,000,000 Bodily Injury by Accident $1,000,000 Bodily Injury by Disease Policy.Limits $1,000,000 Bodily Injury by Disease, each employee ,o • General Liability, including $1,000,000 Combined Single Limit Premises Operations o Products and Completed Operations Blanket Contractual Liability Personal injury Liability >, c ca Vehicle Liability(Owned, non-owned, and hired vehicles) $300,000 Combined Single Limit If split limits are preferred: co $200,000 per Person $300,000 per Occurrence 8 $200,000 Property Damage 46 To The contract shall require a Public Construction bond equal to the contract cost. The bond must 2 be issued by an A rated surety company doing business in the State of Florida. a Hold Harmless and Indemnification. Notwithstanding any minimum insurance requirements o prescribed elsewhere in this agreement, Contractor shall defend, indemnify and hold the COUNTY and the COUNTY's elected and appointed officers and employees harmless from and against(1) any claims, actions or causes of action, (ii) any litigation, administrative proceedings, appellate proceedings, or other proceedings relating to any type of injury(including death), loss, damage, fine, penalty or business interruption, and (iii) any costs or expenses that may be asserted against, initiated with respect to, or sustained by, any indemnified party by reason of, a or in connection with, (A) any activity of Contractor or any of its employees, agents, contractors c or other invitees during the term of this Agreement, (B) the negligence or recklessness, intentional wrongful misconduct, errors or other wrongful act or omission of Contractor or any of N its employees, agents, sub-contractors or other invitees, or(C) Contractor's default in respect of E any of the obligations that it undertakes under the terms of this Agreement, except to the extent the claims, actions, causes of action, litigation, proceedings, costs or expenses arise from the <; intentional or sole negligent acts or omissions of the COUNTY or any of its employees, agents, contractors or invitees (other than Contractor). The monetary limitation of liability under this contract shall be not less than $1 million per occurrence pursuant to F. S. 725.06. Insofar as the claims, actions, causes of action, litigation, proceedings, costs or expenses relate to events or circumstances that occur during the term of this Agreement, this section will survive the E expiration of the term of this Agreement or any earlier termination of this Agreement. ea INSURANCE REQUIREMENTS AND FORMS 00130-Page 38 of 261 Packet Pg. 3363 S.5.b "TINY HOUSE" CONSTRUCTION AND DEMONSTRATION 0 L. In the event that the completion of the project (to include the work of others) is delayed or suspended as a result of the Contractor s failure to purchase or maintain the required insurance, 0 the Contractor shall indemnify the County from any and all increased expenses resulting from .0 such delay. Should any claims be asserted against the County by virtue of any deficiency or ambiguity in the plans and specifications provided by the Contractor, the Contractor agrees and warrants that the Contractor shall hold the County harmless and shall indemnify it from all > losses occurring thereby and shall further defend any claim or action on the County's behalf. a The first ten dollars ($10.00) of remuneration paid to the Contractor is for the indemnification provided for the above. as The extent of liability is in no way limited to, reduced, or lessened by the insurance requirements 0 contained elsewhere within this AGREEMENT. FDEM Indemnification 0 To the fullest extent permitted by law, the Contractor shall indemnify and hold harmless the E Agency, the State of Florida, Department of Emergency Management, and its officers and employees, from liabilities, damages, losses and costs, including, but not limited to, reasonable attorney's fees, to the extent caused by the negligence, recklessness or intentional wrongful misconduct of the Contractor and persons employed or utilized by the Contractor in the. performance of this Contract. ,o This indemnification shall survive the termination of this Contract. Nothing contained in this paragraph is intended to nor shall it constitute a waiver of the State of Florida and the (County) o Agency's sovereign immunity. 0 PROPOSER'S STATEMENT a I understand the insurance that will be mandatory if awarded the contract and will comply in full c with all of the requirements herein. I fully accept the indemnification and hol• harmless and duty to defend as set out in this proposal. o a A 1 r,, Advync; (okr. rst. io,l I Cr-vnol}fa k5, *gip PROPOSER Signature I • N C v > Q r 47 E C.) r-. INSURANCE REQUIREMENTS AND FORMS 00130-Page 39 of 261 Packet Pg. 3364 AL? CERTIFICATE OF LIABILITY INSURANCE DATE YYY) E/9/2019 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER,AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED,the policy(ies) must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER CONTACT NAME: King Insurance King Ins Agency of Gainesville, Inc PHONE FAX 2321 NW 41st Street (A/c,No,Ext):352-377-0420 (A/C,No):352-415-8030 Gainesville FL 32606 ADDRESS: Certificates@king-insurance.com INSURER(S)AFFORDING COVERAGE NAIC# INSURERA:American Builders Insurance Company 11240 INSURED ADVACON-03 Advanced Construction Technologies LLC • INSURER e: 3706 North Roosevelt Boulevard, Suite 208 INSURER C: Key West FL 33040 INSURER D: INSURER E: INSURER F: COVERAGES CERTIFICATE NUMBER:334822121 REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES.LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR ADDL S POLICY EFF POLICY EXP LTR TYPE OF INSURANCE INSD IWVD POLICY NUMBER LIMITS (MMIDD/YYYY) (MMIDD/YYYY) COMMERCIALGENERALLIABILITY EACH OCCURRENCE $ DAMAGE TO RENTED CLAIMS-MADE OCCUR PREMISES(Ea occurrence) $ MED EXP(Any one person) $ PERSONAL 8 ADV INJURY $ GEN'L AGGREGATE LIMIT APPLIES PER: GENERAL AGGREGATE S POLICY PRO- JECT LOC PRODUCTS-COMP/OP AGG $ OTHER: $ AUTOMOBILE LIABILITY COMBINED SINGLE LIMIT S (Ea accident) ANY AUTO BODILY INJURY(Per person) $ OWNED SCHEDULED AUTOS ONLY AUTOS BODILY INJURY(Per accident) S HIRED NON-OWNED PROPERTY DAMAGE S AUTOS ONLY AUTOS ONLY (Per accident) S UMBRELLA LIAR OCCUR EACH OCCURRENCE $ EXCESS LIAB CLAIMS-MADE AGGREGATE $ DED RETENTIONS S A WORKERS COMPENSATION WCV029123700 8/19/2019 8/19/2020 X PER OTH- AND EMPLOYERS'LIABILITY Y/N STATUTE ER ANYPROPRIETOR/PARTNER/EXECUTIVE E.L.EACH ACCIDENT S 1,000,000 OFFICER/MEMBER EXCLUDED? Y N/A (Mandatory in NH) E.L.DISEASE-EA EMPLOYEE $1,000,000 If yes,describe under - - - --- DESCRIPTION OF OPERATIONS below E.L.DISEASE-POLICY LIMIT $1,000,000 DESCRIPTION OF OPERATIONS/LOCATIONS/VEHICLES (ACORD 101,Additional Remarks Schedule,may be attached if more space is required) A fl 8`TF1st;MA GEMENT SY DATE WAIVER WA ES_ CERTIFICATE HOLDER CANCELLATION SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. Monroe County Board of County Commissioners 1100 Simonton Street, Suite 2-216 Key West FL 33040 AUTHORIZED REPRESENTATIVE I ©1988-2015 ACORD CORPORATION. All rights reserved. ACORD 25(2016/03) The ACORD name and logo are registered marks of ACORD A ® CERTIFICATE OF LIABILITY INSURANCE DATE(MM/DDIYYYI� 9/9/2019 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER,AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED,the policy(ies) must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED,subject to the terms and conditions of the policy, certain policies may require an endorsement A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER CONTACT NAME: The Horton Group PHONE FAX 10320 Orland Parkway (a No.Ext):708-845-3000 (NC,No): Orland Park IL 60467 ADDRESS: mailroom@thehortongroup.com INSURER(S)AFFORDING COVERAGE NAIC# INSURERA:CM Vantage Specialty Insurance Company 15872 INSURED ADVACON-02 INSURER B Advanced Construction Technologies, LLC 3706 N. Roosevelt Blvd. Suite 208 INSURER C: Key West FL 33040 INSURER D: INSURER E: INSURER F: COVERAGES CERTIFICATE NUMBER:1204019293 REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT,TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES.LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR TYPE OF INSURANCE ADDL SUBR' POLICY EFF POLICY EXP LIMITS LTR INSD.WVD. POLICY NUMBER (MM/DDIYYYY) (MMIDDIYYYY) A X COMMERCIAL GENERAL LIABILITY CMV PLI 0015484 01 8/30/2019 8/30/2020 EACH OCCURRENCE $1,000,000 DAMAGE TRENTED CLAIMS-MADE r X OCCUR PREMISES(Ea occurrence) $100,000 MED EXP(Any one person) $5,000 i PERSONAL 8 ADV INJURY $1,000,000 GEN'L AGGREGATE LIMIT APPLIES PER: GENERAL AGGREGATE $2,000,000 POLICY X JECT LOC PRODUCTS-COMP/OP AGG $2,000,000 OTHER: $ A AUTOMOBILE LIABILITY CMV PLI 001548 01 8/30/2019 8/30/2020 COMBINED SINGLE LIMIT $1,000,000 �.,n� (Ea accident) ANY AUTO si Y f1t17 lvf'v�`- T BODILY INJURY(Per person) $ OWNED SCHEDULED AP BODILY INJURY(Per accident) $ AUTOS ONLY AUTOS L x HIRED y NON-OWNED AUTOS ONLY X AUTOS ONLY DY ; '� (Per accident) $ . _ / $ UMBRELLA LIAB OCCUR �� WRl' Sr EACH OCCURRENCE $ EXCESS LIAB CLAIMS-MADE \ AGGREGATE $ DED RETENTION$ $ WORKERS COMPENSATION PER OTH- AND EMPLOYERS'LIABILITY Y/N STATUTE ER_ ANYPROPRIETOR/PARTNER/EXECUTIVE E.L.EACH ACCIDENT $ OFFICER/MEMBER EXCLUDED? N/A (Mandatory In NH) E.L.DISEASE-EA EMPLOYEE $ If yes,describe under DESCRIPTION OF OPERATIONS below E.L.DISEASE-POLICY LIMIT $ DESCRIPTION OF OPERATIONS/LOCATIONS/VEHICLES(ACORD 101,Additional Remarks Schedule,may be attached If more space Is required) Additional insured on a primary and non-contributory basis with respect to general liability and auto liability only when required by written contract:Monroe County Board of County Commissioners CERTIFICATE HOLDER CANCELLATION SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. Monroe County Board of County Commissioners 1100 Simonton Street; Suite 2-216 AUTHORIZED REPRESENTATIVE Key West FL 33040 - --) ©1988-2015 ACORD CORPORATION. All rights reserved. ACORD 25(2016/03) The ACORD name and logo are registered marks of ACORD Acc•REP® EVIDENCE OF PROPERTY INSURANCE DATE TE(M2/2oi9 THIS EVIDENCE OF PROPERTY INSURANCE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE ADDITIONAL INTEREST NAMED BELOW.THIS EVIDENCE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND,EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS EVIDENCE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S),AUTHORIZED REPRESENTATIVE OR PRODUCER,AND THE ADDITIONAL INTEREST. AGENCY PHONE (678)424-6500 COMPANY (A/C.No,Ext): Sterling Seacrest Partners, Inc American Zurich Insurance Company P 0 Box 724137 P 0 Box 10197 Atlanta GA 31139 Jacksonville FL 32247 FAX E (A/C,No):(678)424-65n AD RIESS: CODE: SUB CODE: AGENCY 00036413 CUSTOMER ID#: INSURED LOAN NUMBER POLICY NUMBER Advanced Construction Technologies, LLC BR13972072 3706 North Roosevelt Blvd EFFECTIVE DATE EXPIRATION DATE CONTINUED UNTIL Ste 208 8/1/2019 8/1/2020 TERMINATED IF CHECKED Key West FL 33040 THIS REPLACES PRIOR EVIDENCE DATED: PROPERTY INFORMATION LOCATION/DESCRIPTION • Loc# 00001 20950 Overseas Highway Cudjoe Key, FL 33042 THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT,TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS EVIDENCE OF PROPERTY INSURANCE MAY BE ISSUED OR MAY PERTAIN,THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS,EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. COVERAGE INFORMATION COVERAGE/PERILS/FORMS AMOUNT OF INSURANCE DEDUCTIBLE Job Specific Builders Risk New 207,199 $5,000 REMARKS(Including Special Conditions) CANCELLATION SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF,NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. ADDITIONAL INTEREST NAME AND ADDRESS MORTGAGEE X ADDITIONAL INSURED LOSS PAYEE Monroe County LOAN# 1100 Simonton Street Suite 2-216 Key West, FL 33040 AUTHORIZED REPRESENTATIVE ,I/�� Wesley Hamilton/TGRAHA 1 F ACORD 27(2009/12) ©1993-2009 ACORD CORPORATION. All rights reserved. INS027 (200912).02 The ACORD name and logo are registered marks of ACORD ADDITIONAL COVERAGES Ref# Description Coverage Code Form No. Edition Date Builders Risk New BRNEW Limit 1 Limit 2 Limit 3 Deductible Amount Deductible Type Premium 207,199 5,000 Dollars Ref# Description Coverage Code Form No. Edition Date Limit 1 Limit 2 Limit 3 Deductible Amount Deductible Type Premium Ref# Description Coverage Code Form No. Edition Date Limit 1 Limit 2 Limit 3 Deductible Amount Deductible Type Premium Ref# Description Coverage Code Form No. Edition Date Limit 1 Limit 2 Limit 3 Deductible Amount Deductible Type Premium Ref# Description Coverage Code Form No. Edition Date Limit 1 Limit 2 Limit 3 Deductible Amount Deductible Type Premium Ref# Description - Coverage Code Form No. Edition Date Limit 1 Limit 2 Limit 3 Deductible Amount Deductible Type Premium Ref# Description Coverage Code Form No. Edition Date Limit 1 Limit 2 Limit 3 Deductible Amount Deductible Type Premium Ref# Description Coverage Code Form No. Edition Date Limit 1 Limit 2 Limit 3 Deductible Amount Deductible Type Premium Ref# Description Coverage Code Form No. Edition Date Limit 1 Limit 2 Limit 3 Deductible Amount Deductible Type Premium Ref# Description Coverage Code Form No. Edition Date Limit 1 Limit 2 Limit 3 Deductible Amount Deductible Type Premium Ref# Description Coverage Code Form No. Edition Date Limit 1 Limit 2 Limit 3 Deductible Amount Deductible Type Premium OFADTLCV Copyright 2001,AMS Services,Inc. - _ usted THE MAIN STREET AMERICA GROUP cr PERFORMANCE BOND Bond No.: 321531 CONTRACTOR: SURETY: (Name, legal status and address) (Name, legal status and principal place of business) Advanced Construction Technologies, LLC NGM Insurance Company 3706 North Roosevelt Boulevard, Suite 208 4601 Touchton Rd East Ste 3400 Key West, Florida 33040 Jacksonville, FL 32246-4486 OWNER: (Name, legal status and address) Monroe County Board of County Commissioners 500 Whitehead Street Key West, Florida 33040 CONSTRUCTION CONTRACT Date: July 17th, 2019 Amount: $207,199 Description(Name and Location): "Tiny House"Construction and Demonstration Key West, Florida BOND Date: July 17th, 2019 (Not earlier than Construction Contract Date) Amount: $207,199 Modifications to this Bond: None X See Section 16 `'\ CONTRACTOR ASPRINCIPA SURETY '- �`- Company: (Corporate Seal) Company: _,,,i ` ate Seal) Advanced Co .fucti.n, .. .•'_ - NGM Insurance Company . !� "'�; Signature: ,',''!/ Signature: 9fg4 %�,,,/e Name and itle: Dean Porter,General Counsel Name and Title: Matthew Clarke,Attorney in Fact (Any additional signatures appear on the last page of this Performance Bond.) (FOR INFORMATION ONLY—Name, address and telephone) AGENT or BROKER: OWNER'S REPRESENTATIVE: Carolina Indemnity Group Ltd Co (Architect, Engineer or other party:) PO Box 815 Charleston, South Carolina 29402 Florida License No L105585 §1 The Contractor and Surety,jointly and severally, bind themselves, their heirs, executors, administrators, successors and assigns to the Owner for the performance of the Construction Contract,which is incorporated herein by reference. §2 If the Contractor performs the Construction Contract, the Surety and the Contractor shall have no obligation under this Bond,except when applicable to participate in a conference as provided in Section 3. §3 If there is no Owner Default under the Construction Contract,the Surety's obligation under this Bond shall arise after .1 the Owner first provides notice to the Contractor and the Surety that the Owner is considering declaring a Contractor Default. Such notice shall indicate whether the Owner is requesting a conference among the Owner, Contractor and Surety to discuss the Contractor's performance. If the Owner does not request a conference,the Surety may,within five(5) business days after receipt of the Owner's notice,request such a conference.If the Surety timely requests a conference,the Owner shall attend.Unless the Owner agrees otherwise,any conference requested under this Section 3.1 shall be held within ten (10) business days of the Surety's receipt of the The Company executing this bond vouches that this document conforms to American Institute of Architects Document A312,2010 edition 1 68-9010 03/15 Owner's notice. If the Owner,the Contractor and the Surety agree,the Contractor shall be allowed a reasonable time to perform the Construction Contract, but such an agreement shall not waive the Owner's right, if any, subsequently to declare a Contractor Default; .2 the Owner declares a Contractor Default,terminates the Construction Contract and notifies the Surety;and .3 the Owner has agreed to pay the Balance of the Contract Price in accordance with the terms of the Construction Contract to the Surety or to a contractor selected to perform the Construction Contract. §4 Failure on the part of the Owner to comply with the notice requirement in Section 3.1 shall not constitute a failure to comply with a condition precedent to the Surety's obligations, or release the Surety from its obligations, except to the extent the Surety demonstrates actual prejudice. §5 When the Owner has satisfied the conditions of Section 3,the Surety shall promptly and at the Surety's expense take one of the following actions: §5.1 Arrange for the Contractor,with the consent of the Owner,to perform and complete the Construction Contract; §5.2 Undertake to perform and complete the Construction Contract itself,through its agents or independent contractors; §5.3 Obtain bids or negotiated proposals from qualified contractors acceptable to the Owner for a contract for performance and completion of the Construction Contract, arrange for a contract to be prepared for execution by the Owner and a contractor selected with the Owner's concurrence, to be secured with performance and payment bonds executed by a qualified surety equivalent to the bonds issued on the Construction Contract, and pay to the Owner the amount of damages as described in Section 7 in excess of the Balance of the Contract Price incurred by the Owner as a result of the Contractor Default;or §5.4 Waive its right to perform and complete, arrange for completion, or obtain a new contractor and with reasonable promptness under the circumstances: .1 After investigation, determine the amount for which it may be liable to the Owner and, as soon as practicable after the amount is determined,make payment to the Owner;or .2 Deny liability in whole or in part and notify the Owner,citing the reasons for denial. §6 If the Surety does not proceed as provided in Section 5 with reasonable promptness, the Surety shall be deemed to be in default on this Bond seven days after receipt of an additional written notice from the Owner to the Surety demanding that the Surety perform its obligations under this Bond, and the Owner shall be entitled to enforce any remedy available to the Owner. If the Surety proceeds as provided in Section 5.4, and the Owner refuses the payment or the Surety has denied liability, in whole or in part,without further notice the Owner shall be entitled to enforce any remedy available to the Owner. §7 If the Surety elects to act under Section 5.1, 5.2 or 5.3, then the responsibilities of the Surety to the Owner shall not be greater than those of the Contractor under the Construction Contract, and the responsibilities of the Owner to the Surety shall not be greater than those of the Owner under the Construction Contract. Subject to the commitment by the Owner to pay the Balance of the Contract Price,the Surety is obligated,without duplication,for .1 the responsibilities of the Contractor for correction of defective work and completion of the Construction Contract; .2 additional legal, design professional and delay costs resulting from the Contractor's Default, and resulting from the actions or failure to act of the Surety under Section 5;and .3 liquidated damages, or if no liquidated damages are specified in the Construction Contract, actual damages caused by delayed performance or non-performance of the Contractor. §8 If the Surety elects to act under Section 5.1,5.3 or 5.4,the Surety's liability is limited to the amount of this Bond. §9 The Surety shall not be liable to the Owner or others for obligations of the Contractor that are unrelated to the Construction Contract,and the Balance of the Contract Price shall not be reduced or set off on account of any such unrelated obligations.No right of action shall accrue on this Bond to any person or entity other than the Owner or its heirs, executors, administrators, successors and assigns. §10 The Surety hereby waives notice of any change, including changes of time, to the Construction Contract or to related subcontracts,purchase orders and other obligations. §11 Any proceeding, legal or equitable, under this Bond may be instituted in any court of competent jurisdiction in the location in which the work or part of the work is located and shall be instituted within two years after a declaration of Contractor Default or within two years after the Contractor ceased working or within two years after the Surety refuses or fails The Company executing this bond vouches that this document conforms to American Institute of Architects Document A312,2010 edition 2 68-9010 03/15 , to perform its obligations under this Bond,whichever occurs first.If the provisions of this Paragraph are void or prohibited by law,the minimum period of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable. §12 Notice to the Surety,the Owner or the Contractor shall be mailed or delivered to the address shown on the page on which their signature appears. §13 When this Bond has been furnished to comply with a statutory or other legal requirement in the location where the construction was to be performed, any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefrom and provisions conforming to such statutory or other legal requirement shall be deemed incorporated herein.When so furnished,the intent is that this Bond shall be construed as a statutory bond and not as a common law bond. §14 Definitions §14.1 Balance of the Contract Price.The total amount payable by the Owner to the Contractor under the Construction Contract after all proper adjustments have been made, including allowance to the Contractor of any amounts received or to be received by the Owner in settlement of insurance or other claims for damages to which the Contractor is entitled, reduced by all valid and proper payments made to or on behalf of the Contractor under the Construction Contract. §14.2 Construction Contract. The agreement between the Owner and Contractor identified on the cover page, including all Contract Documents and changes made to the agreement and the Contract Documents. §14.3 Contractor Default.Failure of the Contractor,which has not been remedied or waived,to perform or otherwise to comply with a material term of the Construction Contract. §14.4 Owner Default Failure of the Owner,which has not been remedied or waived,to pay the Contractor as required under the Construction Contract or to perform and complete or comply with the other material terms of the Construction Contract. §14.5 Contract Documents.All the documents that comprise the agreement between the Owner and Contractor. §15 If this Bond is issued for an agreement between a Contractor and subcontractor,the term Contractor in this Bond shall be deemed to be Subcontractor and the term Owner shall be deemed to be Contractor. §16 Modifications to this bond are as follows: <<n/a>> (Space is provided below for additional signatures of added parties, other than those appearing on the cover page.) CONTRACTOR AS PRINCIPAL SURETY Company: (Corporate Seal) Company: (Corporate Seal) NGM Insurance Company Signature: Signature: Name and Title: Name and Title: Address: Address: The Company executing this bond vouches that this document conforms to American Institute of Architects Document A312,2010 edition 3 68-9010 03/15 ' V J NGM INSURANCE COMPANY POWER OF ATTORNEY A member of The Man Street America Group S-321531 KNOW ALL MEN BY THESE PRESENTS: That the NGM Insurance Company,a Florida corporation having its principal office in the City of Jacksonville,State of Florida,pursuant to Article IV,Section 2 of the By-Laws of said Company,to wit: "SECTION 2.The board of directors,the president,any vice president,secretary,or the treasurer shall have the power and authority to appoint attorneys-in-fact and to authorize them to execute on behalf of the company and affix the seal of the company thereto,bonds,recognizances,contracts of indemnity or writings obligatory in the nature of a bond, recognizance or conditional undertaking and to remove any such attorneys-in-fact at any time and revoke the power and authority given to them." does hereby make,constitute and appoint Matthew Clarke its true and lawful Attorney-in-fact,to make, execute,seal and deliver for and on its behalf,and as its act and deed bond number S-321531 dated July 17,2019, on behalf of ***Advanced Construction Technologies, LLC*** in favor of ***Monroe County Board of County Commissioners*** for Two Hundred Seven Thousand One Hundred Ninety-Nine Dollars and 00/100 Dollars($207,199) and to bind NGM Insurance Company thereby as fully and to the same extent as if such instrument was signed by the duly authorized officers of the NGM Insurance Company;this act of said Attorney is hereby ratified and confirmed. This power of attorney is signed and sealed by facsimile under and by the authority of the following resolution adopted by the Directors of NGM Insurance Company at a meeting duly called and held on the 2nd day of December 1977. Voted:That the signature of any officer authorized by the By-Laws and the company seal may be affixed by facsimile to any power of attorney or special power of attorney or certification of either given for the execution of any bond,undertaking, recognizance or other written obligation in the nature thereof; such signature and seal,when so used being hereby adopted by the company as the original signature of such officer and the original seal of the company,to be valid and binding upon the company with the same force and effect as though manually affixed. IN WITNESS WHEREOF,NGM Insurance Company has caused these presents to be signed by its Assistant Vice President, General Counsel and Secretary and its corporate seal to be hereto affixed this 4th day of October,2015. 1111N11NNN+ms uNoNN NGM INSURANCE COMPANY By: •g zi 1923 l r Bruce R Fox Vice President, General Counsel and Secretary State of Florida, County of Duval On this 4th day of October,2015 before the subscriber a Notary Public of State of Florida in and for the County of Duval duly commissioned and qualified,came Bruce Fox of the NGM Insurance Company,to me personally known to be the officer described herein,and who executed the preceding instrument,and he acknowledged the execution of same,and being by me fully sworn,deposed and said that he is an officer of said Company,aforesaid:that the seal affixed to the preceding instrument is the corporate seal of said Company,and the said corporate seal and his signature as officer were duly affixed and subscribed to the said instrument by the authority and direction of the said Company;that Article IV,Section 2 of the By-Laws of said Company is now in force. IN WITNESS WHEREOF,I have hereunto set my hand and affixed by official seal at Jacksonville,Florida this 4th day of October, 2015. TasheAm P tipat trorNtvPustic L4:.STATE FF F1 117 �1'�-y Canm#�FF916117 Expires 10/3/2019 I,Nancy Giordano-Ramos,Vice President of the NGM Insurance Company,do hereby certify that the above and foregoing is a true and correct copy of a Power of Attorney executed by said Company which is still in force and effect. IN WITNESS WHEREOF,I have hereunto set my hand and affixed the seal of said Company at Jacksonville,Florida this 19th day of August , 2019 • u ~z 1923 4ry"Hrsa�mMiS WARNING: Any unauthorized reproduction or alteration of this document is prohibited. TO CONFIRM VALIDITY of the attached bond please call 1-603-358-1343. TO SUBMIT A CLAIM: Send all correspondence to 55 West Street, Keene, NH 03431 Attn: Bond Claim Dept. or call our Bond Claim Dept. at 1-603-358-1229. Vir � 7Yu-s.t-e�d. THE MAIN STREET AIVIERIGA GROUP PAYMENT BOND Bond No.: 321531 CONTRACTOR: SURETY: (Name, legal status and address) (Name, legal status and principal place of business) Advanced Construction Technologies, LLC NGM Insurance Company 3706 North Roosevelt Boulevard, Suite 208 4601 Touchton Rd East Ste 3400 Key West, Florida 33040 Jacksonville, FL 32246-4486 OWNER: (Name, legal status and address) Monroe County Board of County Commissioners 500 Whitehead Street Key West, Florida 33040 CONSTRUCTION CONTRACT Date: July 17th,2019 Amount: $207,199 Description(Name and Location): "Tiny House"Construction and Demonstration Key West, Florida • BOND Date: July 17th,2019 (Not earlier than Construction Contract Date) ._--_• Amount $207,199 f ,,:-._-.._:.:;�- • Modifications to this Bond: None X See Section 18 rvf. . CONTRACTOR AS PRINCIPAL SURETY „ Company: (Corporate Seal) Company: Advanced Constr do T gies, LLC NGM Insurance Company Signature: Signature: a`/,, -5 Name and T. le: ea Porter,General Counsel Name and Title: Matthew Clarke,Attorney in Fact (Any additional signatures appear on the last page of this Payment Bond.) (FOR INFORMATION ONLY—Name, address and telephone) AGENT or BROKER: OWNER'S REPRESENTATIVE: Carolina Indemnity Group Ltd Co (Architect,Engineer or other party:) PO Box 815 Charleston, South Carolina 29402 Florida License No L105585 §1 The Contractor and Surety,jointly and severally, bind themselves, their heirs, executors, administrators, successors and assigns to the Owner to pay for labor, materials and equipment furnished for use in the performance of the Construction Contract,which is incorporated herein by reference,subject to the following terms. §2 If the Contractor promptly makes payment of all sums due to Claimants, and defends, indemnifies and holds harmless the Owner from claims, demands, liens or suits by any person or entity seeking payment for labor, materials or equipment The Company executing this bond vouches that this document conforms to American Institute of Architects Document A312,2010 edition 1 68-9009 03/2015 furnished for use in the performance of the Construction Contract,then the Surety and the Contractor shall have no obligation under this Bond. §3 If there is no Owner Default under the Construction Contract,the Surety's obligation to the Owner under this Bond shall arise after the Owner has promptly notified the Contractor and the Surety (at the address described in Section 13) of claims, demands,liens or suits against the Owner or the Owner's property by any person or entity seeking payment for labor,materials or equipment furnished for use in the performance of the Construction Contract and tendered defense of such claims,demands, liens or suits to the Contractor and the Surety. §4 When the Owner has satisfied the conditions in Section 3, the Surety shall promptly and at the Surety's expense defend, indemnify and hold harmless the Owner against a duly tendered claim,demand,lien or suit. §5 The Surety's obligations to a Claimant under this Bond shall arise after the following: §5.1 Claimants,who do not have a direct contract with the Contractor, .1 have furnished a written notice of non-payment to the Contractor, stating with substantial accuracy the amount claimed and the name of the party to whom the materials were, or equipment was, furnished or supplied or for whom the labor was done or performed, within ninety (90) days after having last performed labor or last furnished materials or equipment included in the Claim;and .2 have sent a Claim to the Surety(at the address described in Section 13). §5.2 Claimants, who are employed by or have a direct contract with the Contractor, have sent a Claim to the Surety (at the address described in Section 13). §6 If a notice of non-payment required by Section 5.1.1 is given by the Owner to the Contractor,that is sufficient to satisfy a Claimant's obligation to furnish a written notice of non-payment under Section 5.1.1. §7 When a Claimant has satisfied the conditions of Sections 5.1 or 5.2,whichever is applicable,the Surety shall promptly and at the Surety's expense take the following actions: §7.1 Send an answer to the Claimant,with a copy to the Owner, within sixty (60) days after receipt of the Claim, stating the amounts that are undisputed and the basis for challenging any amounts that are disputed;and §7.2 Pay or arrange for payment of any undisputed amounts. §7.3 The Surety's failure to discharge its obligations under Section 7.1 or Section 7.2 shall not be deemed to constitute a waiver of defenses the Surety or Contractor may have or acquire as to a Claim,except as to undisputed amounts for which the Surety and Claimant have reached agreement. If, however, the Surety fails to discharge its obligations under Section 7.1 or Section 7.2,the Surety shall indemnify the Claimant for the reasonable attorney's fees the Claimant incurs thereafter to recover any sums found to be due and owing to the Claimant. §8 The Surety's total obligation shall not exceed the amount of this Bond, plus the amount of reasonable attorney's fees provided under Section 7.3,and the amount of this Bond shall be credited for any payments made in good faith by the Surety. §9 Amounts owed by the Owner to the Contractor under the Construction Contract shall be used for the performance of the Construction Contract and to satisfy claims, if any, under any construction performance bond. By the Contractor furnishing and the Owner accepting this Bond,they agree that all funds earned by the Contractor in the performance of the Construction Contract are dedicated to satisfy obligations of the Contractor and Surety under this Bond, subject to the Owner's priority to use the funds for the completion of the work. §10 The Surety shall not be liable to the Owner, Claimants or others for obligations of the Contractor that are unrelated to the Construction Contract. The Owner shall not be liable for the payment of any costs or expenses of any Claimant under this Bond, and shall have under this Bond no obligation to make payments to, or give notice on behalf of,Claimants or otherwise have any obligations to Claimants under this Bond. §11 The Surety hereby waives notice of any change, including changes of time, to the Construction Contract or to related subcontracts,purchase orders and other obligations. The Company executing this bond vouches that this document conforms to American Institute of Architects Document A312,2010 edition 2 68-9009 03/2015 • §12 No suit or action shall be commenced by a Claimant under this Bond other than in a court of competent jurisdiction in the state in which the project that is the subject of the Construction Contract is located or after the expiration of one year from the date(1) on which the Claimant sent a Claim to the Surety pursuant to Section 5.1.2 or 5.2, or(2) on which the last labor or service was performed by anyone or the last materials or equipment were furnished by anyone under the Construction Contract,whichever of(1) or(2) first occurs. If the provisions of this Paragraph are void or prohibited by law,the minimum period of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable. §13 Notice and Claims to the Surety, the Owner or the Contractor shall be mailed or delivered to the address shown on the page on which their signature appears. Actual receipt of notice or Claims, however accomplished, shall be sufficient compliance as of the date received. §14 When this Bond has been furnished to comply with a statutory or other legal requirement in the location where the construction was to be performed, any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefrom and provisions conforming to such statutory or other legal requirement shall be deemed incorporated herein.When so furnished,the intent is that this Bond shall be construed as a statutory bond and not as a common law bond. §15 Upon request by any person or entity appearing to be a potential beneficiary of this Bond,the Contractor and Owner shall promptly furnish a copy of this Bond or shall permit a copy to be made. §16 Definitions §16.1 Claim.A written statement by the Claimant including at a minimum: .1 the name of the Claimant; .2 the name of the person for whom the labor was done,or materials or equipment furnished; .3 a copy of the agreement or purchase order pursuant to which labor, materials or equipment was furnished for use in the performance of the Construction Contract; .4 a brief description of the labor,materials or equipment furnished; .5 the date on which the Claimant last performed labor or last furnished materials or equipment for use in the performance of the Construction Contract; .6 the total amount earned by the Claimant for labor,materials or equipment furnished as of the date of the Claim; .7 the total amount of previous payments received by the Claimant;and .8 the total amount due and unpaid to the Claimant for labor,materials or equipment furnished as of the date of the Claim. §16.2 Claimant.An individual or entity having a direct contract with the Contractor or with a subcontractor of the Contractor to furnish labor,materials or equipment for use in the performance of the Construction Contract.The term Claimant also includes any individual or entity that has rightfully asserted a claim under an applicable mechanic's lien or similar statute against the real property upon which the Project is located. The intent of this Bond shall be to include without limitation in the terms "labor, materials or equipment"that part of water, gas, power, light, heat, oil, gasoline,telephone service or rental equipment used in the Construction Contract, architectural and engineering services required for performance of the work of the Contractor and the Contractor's subcontractors, and all other items for which a mechanic's lien may be asserted in the jurisdiction where the labor,materials or equipment were furnished. §16.3 Construction Contract. The agreement between the Owner and Contractor identified on the cover page, including all Contract Documents and all changes made to the agreement and the Contract Documents. §16.4 Owner Default Failure of the Owner,which has not been remedied or waived,to pay the Contractor as required under the Construction Contract or to perform and complete or comply with the other material terms of the Construction Contract. §16.5 Contract Documents.All the documents that comprise the agreement between the Owner and Contractor. §17 If this Bond is issued for an agreement between a Contractor and subcontractor,the term Contractor in this Bond shall be deemed to be Subcontractor and the term Owner shall be deemed to be Contractor. The Company executing this bond vouches that this document conforms to American Institute of Architects Document A312,2010 edition 3 68-9009 03/2015 §18 Modifications to this bond are as follows: <<n/a>> (Space is provided below for additional signatures of added parties, other than those appearing on the cover page.) CONTRACTOR AS PRINCIPAL SURETY Company: (Corporate Seal) Company: (Corporate Seal) NGM Insurance Company Signature: Signature: Name and Title: Name and Title: Address: Address: The Company executing this bond vouches that this document conforms to American Institute of Architects Document A312,2010 edition 4 68-9009 03/2015