3rd Change Order 07/14/2020 MONROE o G T MMAGMENT
CONTRACT CHANGE ORDER
PROJECT TITLE:
West Martello Ammo Bunker Repairs INITIATION DATE:05111/2020
CHANGE ORDER NO:03
TO CONTRACTOR:
Innovative Masonry Restoration,LLC(IMR)
CONTRACT DATE:0911812019
(NTP: 1211812019)
The Contract is changed as follows:
The original(Contract Sum) (Guaranteed Maximum Price}.................................. .s....... $ 223,000.00
Net change by previously authorized Change Orders ..............---...............--------------,.... 6,482.47
The(Contract Sum)(Guaranteed Maximum Price)prior to this Change order was.... .....e.,. $ 229,482.47
The(Contract Sum)(Guaranteed Maximum Price)will be(increased) (decreased) $ -,
(unchanged)by this Change Order...................
The new(Contract Sum) Guaranteed Maximum Price)including this Change Order is....... $ 229,482.47
The Contract Time will be(increased)(decreased)(unchanged)by.. . ............................. 46 days
The date of Substantial Completion as of the date of this Change Order is... .................. 416/2020
Detailed description of change order and justification;
This change rsrder is re ulred toad ast the contract days to the actual time ex eared. IMR proceeded with the work
immediatelZ and continued without un-necessa dela - The work was finally corn feted and met the conditions of the
contract. A certificate of substantial com l titrrr was a rtrvad b the Architect and the Court( on rt16 2020. The
delay results in a NO—COST contract time extension of 46 days,
This change order is 0.0%of the original contract price-
Not valid until sl ned by Owner Arclrltect lif a llcabl and Contractor
ARCHITECT:
Data
CONTRACTOR:
ate
Cary Knight Digitallysigned by Cary Knight
DIRECTOR PROJECT MANAGEMENT Date:2020.07.1410:32:03''��-04'00'
Digitally signed PWA.W ikon,P.E.
( DN KevnG WI PE o Monroe County FL(the Florida
i� �+ mal wls k in@monroeco—yflgovc=US
COUNTY/ASSISTANT ADMINISTRATOR Dat 2020.0].14121830 0400
1JYJ F T4h70.7 ADMINISTRATOR:4.i[� Roman Gastesi - gate.....
Nevin Wilson
Christine Hurley
Change Order Aftachment per Ordinance No, 004-1999
Change Order was not included in the original contract specifications. Yes E] No Z
If Yes, explanation-
49 Change Order was included in the original specifications. Yes C]No Z
If Yes, explanation of increase in price:
s Change Order exceeds$50,000 or 5%of contract price(whichever is greater)- Yes F1 No Z
If Yes,explanation as to why it is not subject for a calling for bids:
• Project architect approves the change order. Yes M No El
If no, explanation of why: -
• Change Order is correcting an error or omission in design document. Yes E]No N
Should a claim under the applicable professional liability policy be made? Yes[I No
Explain: