Item E04 � E.4
� � �, BOARD OF COUNTY COMMISSIONERS
County of Monroe � ��r�i
�r � s�� Mayor Heather Carruthers,District 3
The Florida.Keys Mayor Pro Tem Michelle Coldiron,District 2
Craig Cates,District 1
David Rice,District 4
Sylvia J.Murphy,District 5
County Commission Meeting
July 15, 2020
Agenda Item Number: E.4
Agenda Item Summary #7022
BULK ITEM: Yes DEPARTMENT: Tourist Development Council
TIME APPROXIMATE: STAFF CONTACT: Ammie Machan (305) 296-1552
N/A
AGENDA ITEM WORDING: Approval of an Amendment to extend Agreement with the Mel
Fisher Maritime Heritage Society, Inc. for the Mel Fisher Masonry and Electric Project to September
30, 2021.
ITEM BACKGROUND: See attached request from the Mel Fisher Maritime Heritage Society, Inc.
requesting to extend the completion date of the project to September 30, 2021.
DAC I approved same at their meeting of May 13, 2020
TDC approved same at their meeting of June 10, 2020
PREVIOUS RELEVANT BOCC ACTION: BOCC approved original Agreement at their meeting
of October 16, 2019
CONTRACT/AGREEMENT CHANGES:
Amendment to Extend Agreement
STAFF RECOMMENDATION: Approval
DOCUMENTATION:
Mel Fisher Masonry & Electric - Request, Amendment and Original Agreement
FINANCIAL IMPACT:
Effective Date: October 16, 2019
Expiration Date: September 30, 2021
Total Dollar Value of Contract: $281,250
Total Cost to County: No Cost to County
Current Year Portion: $281,250
Packet Pg. 1991
E.4
Budgeted: Yes
Source of Funds: TDC
CPI:
Indirect Costs:
Estimated Ongoing Costs Not Included in above dollar amounts:
Revenue Producing: No If yes, amount:
Grant:
County Match:
Insurance Required: Yes
Additional Details:
07/15/20 117-77040 - TDC BRICKS & MORTAR 117 $281,250.00
REVIEWED BY:
Maxine Pacini Completed 06/08/2020 2:57 PM
Christine Limbert Completed 06/09/2020 1:32 PM
Purchasing Completed 06/09/2020 1:41 PM
Budget and Finance Completed 06/09/2020 2:19 PM
Maria Slavik Completed 06/09/2020 3:20 PM
Kathy Peters Completed 06/09/2020 4:33 PM
Board of County Commissioners Pending 07/15/2020 9:00 AM
Packet Pg. 1992
E.4.a
� �1AR
1 LL
t8
�aII 4 ii �
t8
LU
U
U
March 23, 2020
Maxine Pacini, Office Manager
Tourist Development Council of Monroe County
1200 White Street
Key West, FL 33040
RE: TDC DAC I Capital Project Line Item#117 77040 530460 T2071383X 530460
Masonry and Electrical Improvements Project Contract ID: 2316 $281,500
Request for extension
Dear Ms. Pacini,
We would like to request an extension for this project completion date to
9/30/2021. We understand that the length of this virus related shutdown is
unknown to all. We had the contractor team scheduled to begin work on 4/4/20,
but due to the City and County closures the workers could not travel to Key West.
Work will be initiated as soon as plausible.
We request that you roll forward all funds awarded under this agreement to the
2020-2021 FY budget. Cr
Thank you for your assistance,
06
i'
Melissa Kendrick
President/CEO -
mkendrick@melfisher.org
The Mel Fisher Maritirnne Heritage Society is an independent not-for-profit 501(c)3 organiza.tjoa 1 derlict.ted to
exhil')iCicn.education, archaeology, preservation and research of maritime history in the New World,
Packet Pg. 1993
E.4.a
AMENDMENT (Ist AMENDMENT) TO AGREEMENT
0
THIS AMENDMENT to Agreement dated this day of 2020, is entered into by and
between the Board of County Commissioners for Monroe County, on behalf of the Tourist
Development Council, and Mel Fisher Maritime Heritage Society, Inc. a not for profit organized and
operating under the laws of the state of Florida (Grantee).
WHEREAS, there was an Agreement entered into on October 16, 2019 between the parties,
0)
awarding $281,250 to Grantee for the Mel Fisher Masonry and Electric Project ("Agreement"); 9
and
WHEREAS, it has became necessary to revise the termination date of the agreement to
September 30, 2021 due to delays resulting from the COVID-19 pandemic, and
NOW, THEREFORE, in consideration of the mutual covenants contained herein the parties E
agree to the amend Agreement as follows:
1. Paragraph 1 of the agreement shall be revised to read as follows: This Agreement is for E
the period of October 16, 2019 to September 30, 2021. This Agreement shall remain in effect for
the stated period unless one party gives to the other written notification of termination pursuant to and
in compliance with paragraphs 7, 12 or 13 of the original Agreement dated October 16, 2019,
2. Any references to termination date and submission of invoices shall be revised to read
September 30, 2021.
3. The remaining provisions of the agreement dated October 16, 2019 shall remain in full
force and effect.
REMAINDER OF THIS PAGE IS INTENTIONALLY LEFT BLANK
Cr
06
U
Amendment#1
Mel Fisher—Masonry and Electric
ID9 2316
Packet Pg. 1994
IN WITNESS WHEREOF, the parties have set their hands and seal can the day and year first
above written,
(SEAL) Board of County Commissioners
Attest;: Kevin Madok, Clerk of Monroe County
As Deputy Clerk _ Mayor/Chairman
Met Fisher Maritime Heritage Society, Inc.
B
Presid+a t
Print Name-
Date:
AND TWO WITNESSES � � � �
{�} � {2} `
Print me Print blameLU
�
Date: 'r Date:
0
MONROE COUNTY ATTORNEY
�P spnRgv�o as ro�a a �
CHRISTME LIMBERT•BARROWS
ASSISTANT COUNTY ATTORNEY
DATE...---6L4/20
ATT1L`1idment 41
Me Fisher-2 Ftaunv IA.
pais tATIdtmf rv11e1jG
cu
ITO 2289
Packet Pg. 1995
Grant Award Agreement
THIS AGREEMENT (agreement) is entered into this day of
2019 by and between MONROE COUNTY (County or Grantor), a political
subdivision of the State of Florida and The Mel Fisher Maritime Heritage Society, Inc. .2
(Grantee) a not for profit organized and operating under the laws of the State of Florida. 2
WHEREAS, the district pennies of Tourist Development Tax may be used
for the following purposes only: To acquire, construct, extend, enlarge, remodel, repair,
improve, maintain, one or more a. Publicly owned and operated convention centers, sports
stadiums, sports arenas, coliseums, or auditoriums within the boundaries of the county or
subcounty special taxing district in which the tax is levied; or b. Auditoriums that are publicly E
owned but are operated by organizations that are exempt from federal taxation pursuant to
26 U.S.C. s. 501(c)(3) and open;to the public; c. Aquariums or museums that are publicly
owned_and operated or owned and operated by not-for-profit organizations and open to the --
public, within the boundaries of the county or subcounty special taxing district in which the
tax is levied; or 5. To finance beach park facilities or beach, channel, estuary, or lagoon
improvement, maintenance, re-nourishment, restoration, and erosion control; or 6. public
facilities if needed to increase tourist related business activities and in accordance with F.S.
125.0104(5)(a)(6.) and (b) zoological parks, fishing piers or nature centers which are public
owned and operated or owned and operated by not-for-profit organizations and open to the
public; and
.WHEREAS, Grantee has applied to TDC District I for funding for the Mel
Fisher Masonry Repair and Electrical Improvements capital project; and
WHEREAS, the Grantor and Tourist Development Council (TDC) have E
determined that it is in the best interest of the County, for purposes of promoting tourism and
preserving the heritage of the community, to attract tourists, and improve the property for
use as an museum open to the public; Cr
NOW, THEREFORE, in consideration of the mutual covenants and payments
contained herein, the Grantee and the Grantor have entered into this agreement on the
terms and conditions as set forth below.
LU
06
1. GRANT AGREEMENT PERIOD. This agreement is for the period of October 16,
2019 through to September 30, 2020. This agreement shall remain in effect for the stated y
period unless one party gives to the other written notification of termination pursuant to and
in compliance with paragraphs 7, 12 or 13 below. The project work described in Exhibit
A must commence within the fiscal year funded which is October 1, 2019 to y_
September 30, 2020. Proof that the project commenced within the fiscal year funded
may be requested by the TDC administrative office.
2. SCOPE OF AGREEMENT. The representations made by the Grantee in its proposal E
submitted to the TDC are incorporated herein by reference. The Grantee shall provide the
following scope of services: Materials and Labor required to complete the above mentioned
Mel Fisher Masonry Repair and Electrical Improvements
FY 2020 Capital Project Fundipg
Contract ID#2316 Packet Pg. 1996
1
project. Segment(s) of the work is/are more particularly described in Exhibit A, detailing the _
work and the cost allocable to each segment, attached hereto, and incorporated herein by
reference. Anything not referenced within Exhibit A will not be reimbursed. All work y
for which grant funds are to be expended must be completed by the stated termination date
of September 30, 2020 and all invoices pertaining to this project shall be submitted to the
Finance Department of Monroe County no later than September 30, 2020 to be considered
for payment. Acknowledgement: Grantee shall be required to permanently display and
LU
maintain at Grantee's expense, public acknowledgement of the support of the Monroe
County Tourist Development Council in a publicly prominent area of their facility in the
following form: "This project was made possible with the financial support of the Monroe
County Tourist Development Council." If the Grantee has already complied with this
requirement through previous funding, said acknowledgement fulfills this condition. A
photograph of said acknowledgment shall be provided with the final request for
reimbursement outlined in Exhibit A of this agreement.
a.) There shall be a project manager to acknowledge receipt of goods or work <
performed. This Project Manager shall be Melissa Kendrick (Email:
mkendrick@melfisher.org; Phone: (305) 294-2633). Should there be a change in the
project manager specified in the Grantee's application, a new project manager shall
be designated, and notice with new contact information shall be provided in writing to
the TDC administrative office.
b.) If, and to the extent that, Grantee contracts for any of the work funded under 0
this agreement to be performed or completed, Grantee shall give notice to County of
the contractual relationship, provide County with a copy of any and all contracts and
shall require the contractor(s) to comply with all the terms of this contract. Should
Grantee contract the work and then decrease the scope of work to be performed by
a contractor, Grantee shall provide County with an amended contract executed by
Grantee and its contractor.
(i) A Grantee which is a governmental entity shall comply with the procurement
Cr
regulation's and policies to which it is subject, and shall provide Grantor
documentation of the procurement requirements applicable to the project and
compliance therewith.
LU
(ii) A Grantee which is a not-for-profit entity shall use procurement processes 06
for those parts of the project to be contracted (not performed by the entity's
employees) as follows. For work expected to be under $50,000, the not-for- y
profit shall document in the file three written quotes or a notarized statement
as to why such written quotes were not feasible for the goods or services. For
work expected to be $50,000 or more, a competitive bid process must be
performed following Monroe County's procurement policies and procedures,
unless the commodities or services will be provided by a "sole source" 2
provider, in which case the not-for-profit must submit a notarized statement
with its request for payment explaining why the vendor is the only source for E
the commodities or services. Refer to: https://www.monroecounty-
fl.gov/DocumentCenterNiew/l 6004/PU RCHASI NG-POLICY---Update-09-04-
18
Mel Fisher Masonry Repair and Electrical Improvements
FY 2020 Capital Project Funding
Contract ID#2316 Packet Pg. 1997
E.4.a
c.) Grantee shall exercise good internal controls to assure that the project as
described in the funding application shall be completed on a timely basis within the
proposed budget and shall provide to County any certifications, including those by
the architect, engineer, contractor or an independent consultant if necessary,
required to establish that materials which are. purported to be applied to the project
are in fact so applied. Further verification shall be required to show that equipment LU
and other fixtures and personal property covered by this agreement are delivered to
and installed in the project site. When'any permit is required by any governmental
agency, copies of plans and other documents which are submitted to the applicable
agency shall be submitted to the County Engineering Division to enable verification
that the scope of services under this agreement has been provided.
3. AMOUNT OF AGREEMENT AND PAYMENT. The Grantor shall provide an amount
not to exceed$281,260(Two Hundred Eighty-One Thousand Two Hundred.and Fifty Dollars
TDC District I funding) for materials and services used to improve the
property. Reimbursement request must show that Grantee has paid in full for materials and
services relating to the segment prior to seeking the 75% (seventy five percent)
reimbursement from Grantor. Payment shall be 75% (seventy five percent) reimbursement
of the total cost of the segment, subject to the cap on expenditures for that segment as set
forth in Exhibit A. Reimbursement can be sought after each segment of the agreement is
completed and signed by the Monroe County Engineering Department as outlined in 3.a.
The Board of County Commissioners and the Tourist Development Council assume no
liability to fund this agreement for an amount in excess of this award. Monroe County's
performance and obligation to .pay under this agreement is contingent upon an annual
appropriation by the BOCC. E
a.) Payment shall be made upon the completion of a specific segment as outlined E
in.the Scope of Services and Exhibit A. Payment for expenditures permissible by
law and County policies shall be made through reimbursement to Grantee upon
presentation of Application for Payment Summary, invoices, canceled checks, before
and after pictures, County Project Manager signature of inspection and other
documentation necessary to support a claim for reimbursement. Included in said
documentation shall be proof that the Grantee has received. the property, real or
personal,for each segment of agreement as outlined in Exhibit A and paid an amount
LU
equal to or greater than the amount invoiced to the Grantor. It shall be necessary for 06
the Grantee to contact the County Engineering Division (Stephen Sanders- phone:
305-2954338 email: Sanders-Stephen@MonroeCounty-Fl..gov or Cary Knight- y
phone: 305-292-4416 email: Knight-Cary@MonroeCounty-Fl.gov) and to arrange for
inspection upon the completion of each segment. It shall be the responsibility of the
project manager to initiate the communication with the Monroe County Engineering y
Division to facilitate the inspection of the segment of the project. The application for
payment document must be certified through a statement signed by an officer of the
organization and notarized, declaring that representations in the invoice are true and
factual.
All payment requests must be submitted no later than September 30,2020. Invoices
received after,September 30, 2020 will not be considered,for payment.
Mel Fisher Masonry Repair and Electrical Improvements
FY 2020 Capital,Project Funding
Contract ID#2316 Packet Pg. 1998
b.) If in-kind services were noted within your application, and you are applying
them to this project, documentation shall be submitted to the TDC Administrative y
Office to show the receipt and application of in-kind donations of goods, professional
services, and materials. Said documentation should include invoices, bills of lading,
etc., and be verified as received and applied to the project through a notarized
statement of the project manager and said documentation submitted to the TDC
Administrative Office. All submissions shall identify the items included in Exhibit ALU
and Grantee shall complete the Application for Payment form which is provided within
the payment/reimbursement packet. This document should be signed by the project
manager.
The Project Manager shall certify delivery to the project site and installation therein
of any goods or services provided other than through an architect, engineer or
contractor. All work performed and goods received on site and incorporated into the E
project shall be verified by one of the foregoing. Submission of any documentation <
which is untrue, falsified, or otherwise misrepresents the work which has been
completed, paid, or donated shall constitute a breach of agreement, for which the E
contract may be immediately terminated at the discretion of the County, whose
decision-shall be final.
c.) At any time that the documentation requirement policies of Monroe County are
revised, such as to require annual inventory reports for equipment purchased under 0
a TDC capital project grant, Grantee shall comply thereafter with such increased
requirements, or further funding under the agreement may be terminated by County.
d.) Upon successful completion of this Grant agreement, the Grantee may retain
ownership of the real and personal property acquired and/or improved with funding
under this Grant agreement. However, the Grantee shall maintain, preserve, and
operate the property which was acquired or improved under this agreement for the
uses and purposes which qualified the Grantee for tourist development tax funding. Cr
Grantee shall complete and sign a Property Reporting Form upon request for
personal property and forward said completed form to the TDC Administrative Office.
Real property acquired or improved through funding under this agreement shall
remain dedicated for the purposes set forth herein or for other purposes which 2
LU
promote tourism and ownership of said property shall be retained by the Grantee. 06
The following terms shall apply:
0
(i) The Grantee shall have the use of the property, including both real and
personal, acquired with funding under this agreement, at the project site for so
long as the facility is operated by Grantee, open to the public, and has a y_
primary purpose of promoting tourism. At such time as any of the conditions _
in the preceding sentence shall cease to exist, the Grantee shall transfer
ownership and possession of equipment and personal property to a local
government or another not-for-profit organization which is a facility for which E
tourist development taxes may be used pursuant to Florida Statute 125.0104
with prior approval from TDC and BOCC.
Mel Fisher Masonry Repair and Electrical Improvements
FY 2020 Capital Project Funding
Contract ID#2316 Packet Pg. 1999
A
• ,. E.4.a'
(ii) At any time that the Grantee: (a) elects to stop the project or otherwise _
decide not to place into service for tourist-related purposes the facility
acquired, constructed, or renovated with tourist development tax funding, (b) y
demolishes the project facility or divests itself of ownership or possession of
the real property, or (c) ceases the use of the property with a primary purpose
of promoting tourism, Grantee shall, pursuant to the formula set forth
hereafter, refund to the County the Tourist Development funding. This
provision shall survive the termination date of all other provisions of thisLU
contract for a period of ten years. Should the demolition, transfer of ownership,
or change to a non-tourist related purpose occur, the amount of refund shall
be pro-rated based on a useful life of ten (10) years.
(iii) The Grantee is responsible for the implementation of adequate
maintenance procedures to keep the real and personal property in good
operating condition.
(iv) The Grantee is responsible for any loss, damage, or theft of, and any
loss, damage or injury caused by the use of, real or personal property or CD
equipment purchased through funding under this agreement.
4. RECORDS AND REPORTS. The Grantee shall keep such records as are necessary
to document the performance of the agreement and expenses as incurred, and give access
to these records at the request of the TDC, the County, the State of Florida or authorized 0
agents and representatives of said government bodies. The Grantee shall also provide
such access to the personal Property and equipment purchased under this agreement. It is
the responsibility of the Grantee to maintain appropriate records in accordance with
generally accepted accounting principles consistently applied to insure a proper accounting
of all funds and expenditures. The Grantee understands that it shall be responsible for
repayment of any and all audit exceptions which are identified by the Auditor General for the
State of Florida, the Clerk of Court for Monroe County, the Board of County Commissioners
for Monroe County, or their agents and representatives. If an audit determines that monies
Cr
paid to the Grantee pursuant to this agreement were spent for purposes not authorized by
this agreement, the Grantee shall repay the monies together with interest calculated
pursuant to Sec. 55.03, F.S. running from the date the monies were paid to Grantee. In the
event of an audit exception, the current fiscal year grant award or subsequent grant awards 2
LU
will be offset by the amount of the audit exception. In the event the grant is not renewed or 06
supplemented in future years, the Grantee will be billed by the Grantor for the amount of the LN
audit exception and shall promptly repay any audit exception. y
a.) Public Access. The County and Grantee shall allow and permit reasonable
access to, and inspection of, all documents, papers, letters or other materials in its
possession or under its control subject to the provisions of Chapter 119, Florida
Statutes, and made or received by the County and Grantee in conjunction with this 2
agreement; and the County shall have the right to unilaterally cancel this agreement
upon violation of this provision by Grantee.
5. MODIFICATIONS AND AMENDMENTS. Any and all modifications of the terms of
this agreement shall be only amended in writing and approved by the Board of County
Mel Fisher Masonry Repair and Electrical Improvements
FY 2020 Capital Project Funding
Contract ID#2316 Packet Pg. 2000
Commissioners for Monroe County. The terms, covenants, conditions, and provisions of
this agreement shall bind and inure to the benefit of the County and Grantee and their
respective legal representatives, successors, and assigns. y
6. INDEPENDENT CONTRACTOR. At all times and for all purposes hereunder, the
Grantee is an independent contractor and not an employee of the Board of County
Commissioners of Monroe County. No statement contained in this agreement shall be
construed as to find the Grantee or any of its employees, contractors, servants or agents to
the employees of the Board of County Commissioners of Monroe County, and they shall be
entitled to none of the rights, privileges or benefits of employees of Monroe County.
a.) No Personal Liability. No covenant or agreement contained herein shall be
deemed to be a covenant or agreement of any member, officer, agent or employee
of Monroe County in his or her individual capacity, and no member, officer, agent or
employee of Monroe County shall be liable personally on this agreement or be subject E
to any personal liability or accountability by reason of the execution of this agreement.
7. COMPLIANCE WITH LAW. In carrying out its obligations under this agreement, the E
Grantee shall abide by all statutes, ordinances, rules and regulations pertaining to or
regulating the provisions of this agreement, including those now in effect and hereafter
adopted. Any violation of said statutes, ordinances, rules or regulations shall constitute a
material breach of this agreement and shall entitle the Grantor to terminate this agreement
immediately upon delivery of written notice of termination to the Grantee. 0
8. RESTRICTIONS ON AGREEMENTS ENTERED PURSUANT TO THIS
AGREEMENT. The Grantee shall include in all agreements funded under this agreement
the following terms:
a.) Anti-discrimination. Contractor agrees that it will not discriminate against any
employees or applicants for employment or against persons for any other benefit or
service under this agreement because of their race, color, religion, sex, national
Cr
origin, or physical or mental handicap where the handicap does not affect the ability
of an individual to perform in a position of employment, and to abide by all federal
and state laws regarding non-discrimination.
Lu
b.) Anti-kickback. Contractor warrants that no person has been employed or 06
retained to solicit or secure this agreement upon an agreement or understanding for LN
a commission, percentage, brokerage or contingent fee, and that no employee or y
officer of the Contractor has any interest, financially or otherwise, in the County. For
breach or violation of this warranty, the County shall have the right to annul this
agreement without liability or, in its discretion, to deduct from the agreement price or y_
consideration, the full amount of such commission, percentage, brokerage or _
contingent fee. Contractor acknowledges that it is aware that funding for this.
agreement is available at least in part through the County and that violation of this
paragraph may result in the County withdrawing funding for the project.
c.) Hold harmless/indemnification. Contractor acknowledges that this agreement
is funded at least in part by the County and agrees to indemnify and hold harmless
Mel Fisher Masonry Repair and Electrical Improvements
FY 2020 Capital Project Funding
Contract ID#2316 Packet Pg. 2001
F
the County and any of its officers and employees from and against any and all claims, _
liabilities, litigation, causes of action, damages, costs, expenses (including but not
limited to fees and expenses arising from any factual investigation, discovery or y
preparation for litigation), and the payment of any and all of the foregoing or any
demands, settlements or judgments (collectively claims) arising directly or indirectly
from any negligence, wrongful acts or omissions or criminal conduct on the part of
contractor in the performance of the terms of this agreement. The contractor shall
LU
immediately give notice to the County of any suit, claim or action made against the
contractor that is related to the activity under this agreement, and will cooperate with
the County in the investigation arising as a result of any suit, action or claim related _
to this agreement.
d.) Insurance. Contractor agrees that it maintains in force at its own expense a
liability insurance policy which will insure and indemnify the contractor and the County
from any suits, claims or actions brought by any person or persons and from all costs E
and expenses of litigation brought against the contractor for such injuries to persons S
or damage to property occurring during the agreement or thereafter that results from
performance by contractor of the obligations set forth in this agreement. The E
following coverage's shall be provided:
1. Workers' Compensation insurance as required by Florida Statutes.
2. Commercial General Liability Insurance with minimum limits of $500,000 0
per occurrence for bodily injury, personal injury and property damage.
3. Comprehensive Auto Liability Insurance with minimum limits of $300,000
combined single limit per occurrence.
The contractor, the County and the TDC shall be named as additional insured on
insurance policies, except workers' compensation. The policies shall provide no less
than 30 days' notice of cancellation, non-renewal or reduction of coverage.
At all times during the term of this agreement and for one year after acceptance of
the project, contractor shall maintain on file with the County a certificate of insurance
showing that the aforesaid insurance coverage are in effect. 2
06
e.) Licensing and Permits. Contractor warrants that it shall have, .prior to
commencement of work under this agreement and at all times during said work, all y
required licenses and permits whether federal, state, county or city.
f.) Right to Audit. The contractor shall keep such records as are necessary to T
document the performance of the agreement and expenses as incurred, and give
access to these records at the request of the TDC, the County, the State of Florida 2
or authorized agents and representatives of said government bodies.
9. HOLD HARMLESS/INDEMNIFICATION. The Grantee hereby agrees to indemnify
and hold harmless the BOCC/TDC and the 3406 North Roosevelt Blvd. Corporation or any
of its officers and employees from and against any and all claims, liabilities, litigation, causes
Mel Fisher Masonry Repair and Electrical Improvements
FY 2020 Capital Project Funding Packet P 2002
Contract ID#2316 9
7
of action, damages, costs, expenses (including but not limited to fees and expenses arising
from any factual investigation, discovery or preparation for litigation), and the payment of LN
any and all of the foregoing or any demands, settlements or judgments arising directly or y
indirectly under this agreement. The Grantee shall immediately give notice to the Grantor
of any suit, claim or action made against the Grantor that is related to the activity under this
agreement, and will cooperate with the Grantor,in the investigation arising as a result of any
suit, action or claim related to this agreement.
a.) Non-Waiver of Immunity. Notwithstanding the provisions of Sec. 768.28,
Florida Statutes, the participation of the County and the Grantee in this agreement iz
and the acquisition of any commercial liability insurance coverage, self-insurance
coverage, or local government liability insurance pool coverage shall not be deemed
a waiver of immunity to the extent of liability coverage, nor shall any contract entered
into by the County be required to contain any provision for waiver.
b.) Privileges and Immunities. All of the privileges and immunities from liability,
exemptions from laws, ordinances, and rules and pensions and relief, disability,
workers' compensation, and other benefits which apply to the activity of officers, E
agents, or employees of any public agents or employees of the County, when
performing their respective functions under this agreement within the territorial limits
of the County shall apply to the same,degree and extent to the performance of such
functions and duties of such officers, agents, volunteers, or employees outside the
territorial limits of the County. 0
10. NONDISCRIMINATION. County and Grantee agree that there will be no
discrimination against any person, and it is expressly understood that upon a determination
by a court of competent jurisdiction that discrimination has occurred, this Agreement
automatically terminates without any further action on the part of any party, effective the date
of the court order. County or Grantee agree to comply with all Federal and Florida statutes,
and all local ordinances, as applicable, relating to nondiscrimination. These include but are
not limited to: 1) Title VII of the Civil Rights Act of 1964 (PL 88-352) which prohibits
Cr
discrimination on the basis of race, color or national origin; 2) Title IX of the Education
Amendment of 1972, as amended (20 USC ss. 1681-1683, and 1685-1686), which prohibits
discrimination on the basis of sex; 3) Section 504 of the Rehabilitation Act of 1973, as
amended (20 USC s. 794), which prohibits discrimination on the basis of handicaps; 4) The
Age Discrimination Act of 1975, as amended (42 USC ss. 6101-6107) which prohibits
discrimination on the basis,of age; 5) The Drug Abuse Office and Treatment Act of 1972 (PL LN
92-255), as amended, relating to nondiscrimination on the basis of drug abuse; 6) The y
Comprehensive Alcohol Abuse and Alcoholism Prevention, Treatment and Rehabilitation
Act of 1970 (PL 91-616), as amended, relating to nondiscrimination on the basis of alcohol
abuse or alcoholism; 7) The Public Health Service Act of 1912, ss. 523 and 527 (42 USC y_
ss. 690dd-3 and 290ee-3), as amended, relating to confidentiality of alcohol and drug abuse _
patient records; 8) Title VIII of the Civil Rights Act of 1968 (42 USC s. et seq.), as amended, 2
relating to nondiscrimination in the sale, rental or financing of housing; 9) The Americans
with Disabilities Act of 1990 (42 USC s. 12101 Note), as maybe amended from time to time, E
relating to nondiscrimination on the basis of disability; 1.0) Monroe County Code Chapter 14,
Article II, which prohibits discrimination on the basis of race, color, sex, religion, national
origin, ancestry, sexual orientation, gender identity or expression, familial status or age; 11)
Mel Fisher Masonry Repair and Electrical Improvements
FY 2020 Capital Project Funding
Contract ID#2316 Packet Pg. 2003
u
any other nondiscrimination provisions in any Federal or state statutes which may apply to
the parties to, or the subject matter of, this Agreement.
0
11. ANTI-KICKBACK. The Grantee warrants that no person has been employed or
retained to solicit or secure this agreement upon an agreement or understanding for a
commission, percentage, brokerage or contingent fee, and that no employee or officer of the
County or TDC has any interest, financially or otherwise, in the said funded project, except
for general membership. For breach or violation of this warranty, the Grantor shall have theLU
right to annul this agreement without liability or, in its discretion, to deduct from the
agreement price or consideration, the full amount of such commission, percentage, -
brokerage or contingent fee.
12. TERMINATION. This agreement shall terminate on September 30, 2020.
Termination prior thereto shall occur whenever funds cannot be obtained or cannot be
continued at a level sufficient to allow for the continuation of this agreement pursuant to the E
terms herein. In the event that funds cannot be continued at a level sufficient to allow the <
continuation of this agreement pursuant to the terms specified herein, this agreement may
then be terminated immediately by written notice of termination delivered in person or by E
mail to Grantee. The Grantor may terminate this agreement without cause upon giving
written notice of termination to Grantee. The Grantor shall not be obligated to pay for any
services or goods provided by Grantee after Grantee has received written. notice of
termination. -
13. TERMINATION FOR BREACH. The Grantor may immediately terminate this
agreement for any breach of the terms contained herein. Such termination shall take place
immediately upon receipt of written notice of said termination. Any waiver of any breach of
covenants herein contained to be kept and performed by Grantee shall not be deemed or
considered as a continuing waiver and shall not operate to bar or prevent the Grantor from
declaring a forfeiture for any succeeding breach either of the same conditions or of any other
conditions. Failure to provide Grantor with certification of use of matching funds or matching
in-kind services at or above the rate of request for reimbursement or payment is a breach of
Cr
agreement, for which the Grantor may terminate this agreement upon giving written
notification of termination.
14. ENTIRE AGREEMENT. This agreement constitutes the entire agreement of the 2
LU
parties hereto with respect to the subject matter hereof and supersedes any and all prior 06
agreements with respect to such subject matter between the Grantee and the Grantor.
0
15. GOVERNING LAW, VENUE, INTERPRETATION, COSTS, AND FEES. This
agreement shall be governed by and construed in accordance with the laws of the State of
Florida applicable to contracts made and to be performed entirely in the state. This
agreement is not subject to arbitration. Mediation proceedings initiated and conducted
pursuant to this agreement shall be in accordance with the Florida Rules of Civil Procedure 2
and usual and customary procedures required by the circuit court of Monroe County.
a.) Venue. In the event that any cause of action or administrative proceeding is
instituted for the enforcement or interpretation of this agreement, the County and
Mel Fisher Masonry Repair and Electrical Improvements
FY 2020 Capital Project Funding
Contract ID#2316 Packet Pg. 2004
0
• E.4.a'
Grantee agree that venue shall lie in the appropriate court or before the appropriate _
administrative body in Monroe County, Florida.
0
b.) Severability. If any term, covenant, condition or provision of this agreement
(or the application thereof to any circumstance or person) shall be declared invalid or
unenforceable to any extent by a court of competent jurisdiction, the remaining terms,
covenants, conditions and provisions of this agreement, shall not be affected thereby;
and each remaining term, covenant, condition and provision of this agreement shall
be valid and shall be enforceable to the fullest extent permitted by law unless the
enforcement of the remaining terms, covenants, conditions and provisions of this
agreement would prevent the accomplishment of the original intent of this agreement.
The County and Grantee agree to reform the agreement to replace any stricken
provision with a valid provision that comes as close as possible to the intent of the
stricken provision.
c.) Attorney's Fees and Costs. The County and Grantee agree that in the event
any cause of action or administrative proceeding is initiated or defended by any party 0)
relative to the enforcement or interpretation of this agreement, the prevailing party
shall be entitled to reasonable attorney's fees, court costs, investigative, and out-of-
pocket expenses, as an award against the non-prevailing party, and shall include
attorney's fees, court costs, investigative, and out-of-pocket expenses in appellate
proceedings.
d.) Adjudication of Disputes or Disagreements. County and Grantee agree that
all disputes'and disagreements shall be attempted to be resolved by meet and confer
sessions between representatives of each of the parties. If the issue or issues are
still not resolved to the satisfaction of the parties, then any party shall have the right
to seek such relief or remedy as may be provided by this agreement or by Florida
law. This agreement shall not be subject to arbitration.
Cr
e.) Cooperation. In the event any administrative or legal proceeding is instituted
against either party relating to the formation, execution, performance, or breach of
this agreement,,County and Grantee agree to participate, to the extent required by
the other party, in all proceedings, hearings, processes, meetings, and other activities 2
Lu
related to the substance of this agreement or provision of the services under this 06
agreement. County and Grantee specifically agree that no party to this agreement
shall be required to enter into any arbitration proceedings related to this agreement. y
16. ETHICS CLAUSE: Grantee warrants that he has not employed, retained or
otherwise had act on his behalf any former County officer or employee in violation of Section y_
2 of Ordinance No. 10-1990 or any County officer or employee in violation of Section 3 of _
Ordinance No. 10-1990. For breach or violation of the provision the Grantor may, at its
discretion terminate this agreement without liability and may also, at its discretion, deduct
from the agreement or purchase price, or otherwise recover, the full amount of any fee,
commission, percentage, gift, or consideration paid to the former or present County officer
or employee. The County and Grantee warrant that, in respect to itself, it has neither
employed nor retained any company or person, other than a bona fide employee working
Mel Fisher Masonry Repair and Electrical Improvements
FY 2020 Capital Project Funding
Contract ID#2316 Packet Pg. 2005
in
• E.4.a'
solely for it, to solicit or secure this agreement and that it has not paid or agreed to pay any _
person, company, corporation, individual, or firm, other than a bona fide employee working
solely for it, any fee, commission, percentage, gift, or other consideration contingent upon y
or resulting from the award or making of this agreement. For the breach or violation of the
provision, the Grantee agrees that the County shall have the right to terminate this
agreement without liability and, at its discretion, to offset from monies owed, or otherwise
recover, the full amount of such fee, commission, percentage, gift, or consideration.
Lu
a.) Covenant of No Interest. County and Grantee covenant that neither presently
has any interest, and shall not acquire any interest, which would conflict in any
manner or degree with its performance under this agreement, and that only interest
of each is to perform and receive benefits as recited in this agreement.
b.) Code of Ethics. County agrees that officers and employees of the County
recognize and will be required to comply with the standards of conduct for public
officers and employees as delineated in Section 112.313, Florida Statutes, regarding,
but not limited to, solicitation or acceptance of gifts; doing business with one's agency;
unauthorized compensation; misuse of public ,position; conflicting employment or
contractual relationship; and disclosure or use of certain information.
17. PUBLIC ENTITY CRIME STATEMENT: A person or affiliate who has been placed
on the convicted vendor list following a conviction for public entity crime may not submit a
bid on an agreement to provide any goods or services to a public entity, may not submit a 0
bid on an agreement with a public entity for the construction or repair of a public building or
public work, may not submit bids on leases of real property to public entity, may not be
awarded or perform work as a contractor, supplier, sub-contractor, or consultant under an
agreement with any public entity, and may not transact business with any public entity in
excess of the threshold amount provided in Section 287.017, Florida Statutes, for E
CATEGORY TWO for a period of 36 months from the date of being placed on the convicted
vendor list. By executing this document grantee warrants that it is in compliance with this
paragraph. Cr
18. AUTHORITY: Grantee warrants that it is authorized by law to engage in the
performance of the activities encompassed by the project herein described. Each of the
signatories for the Grantee below certifies and warrants that the Grantee's name in this
Lu
agreement is the full name as designated in its corporate charter (if a corporation); they are 06
empowered to act and contract for the Grantee; and this agreement has been approved by
the Board of Directors of Grantee or other appropriate authority. y
19. LICENSING AND PERMITS: Grantee warrants that it shall have, prior to
commencement of work under this agreement and at all times during said work, all required y
licenses and permits whether federal, state, county or city.
20. INSURANCE: Grantee agrees that it maintains in force at its own expense a liability
insurance policy which will insure and indemnify the Grantee and the Grantor from any suits,
claims or actions brought by any person or persons and from all costs and expenses of
litigation brought against the Grantee for such injuries to persons or damage to property
occurring during the agreement or thereafter that results from performance by Grantee of
Mel Fisher Masonry Repair and Electrical Improvements
FY 2020 Capital Project Funding Packet P 2006
Contract ID#2316 9
14
the obligations set forth in this agreement. At all times during the term of this agreement and _
for one year after acceptance of the project, Grantee shall maintain on file with the Grantor
a certificate of the insurance of the carriers showing that the aforesaid insurance policy is in y
effect. The following coverage's shall be provided:
1. Workers' Compensation insurance as required by Florida Statutes.
2. Commercial General Liability Insurance with minimum limits of $500,000
Combined Single Limit (CSL) If split limits are provided, the minimum limits
acceptable shall be $250,000 per Person $500,000 per occurrence
$50,000 property damage.
3. Comprehensive Business Auto Liability Insurance with minimum limits of
$300,000 combined single limit per occurrence.
The Grantee, the Grantor and the TDC shall be named as additional insured, except S
workers' compensation. The policies shall provide no less than 30 days' notice of
cancellation, non-renewal or reduction of coverage. Grantee shall provide to the County, as E
satisfactory evidence of the required insurance, including the insurance policy application
and either:
• Original Certificate of Insurance, OR
• Certified copy of the actual insurance policy, OR
• Certificate of Insurance e-mailed from Insurance Agent/Company to
County Risk Management - Telephone Maria Slavik at (305) 295-3178 for
details (Certificates can be e-mailed directly from the insurance agency to: E
Slavik-Maria(a_Mon roeCounty-FL.Gov — The e-mail must state that this is
a certificate for a TDC project and should be forwarded to Ammie Machan
at the TDC administrative office) Cr
An original certificate or a certified copy of any or all insurance policies required by this .2
contract shall be filed with the Clerk of the BOCC prior to the contract being executed by the
Clerk's office. The Insurance policy must state that the Monroe County BOCC and Monroe
County TDC is the Certificate Holder and additional Insured for this contract (certificate only
for workers' compensation coverage). Insurance information should be mailed to:
Monroe County Board of County Commissioners
c/o Risk Management
P.O. Box 1026
Key West, FL 33041 y
21. NOTICE. Any notice required or permitted under this agreement shall be in writing
and hand delivered or mailed, postage prepaid, to the other party by certified mail, returned
receipt requested to the following:
Mel Fisher Masonry Repair and Electrical Improvements
FY 2020 Capital Project Funding
Contract ID#2316 Packet Pg. 2007
17
For Grantee: Melissa Kendrick
The Mel Fisher Maritime Heritage Society, Inc.
200 Greene St. y
Key West, FL 33040
For Grantor: Maxine Pacini
Monroe County Tourist Development Council
1201 White Street, Suite 102
Key West, FL 33040
and
Ms. Christine Limbert-Barrows, Asst. County Attorney
P.O. Box 1026
Key West, FL 33041-1026
22. CLAIMS FOR FEDERAL OR STATE AID: Grantee and County agree that each shall
be, and is, empowered to apply for, seek, and obtain federal and state funds to further the E
purpose of this agreement. Any conditions imposed as a result of funding that effect the
Project will be provided to each party.
23.. NON-DELEGATION OF CONSTITUTIONAL OR STATUTORY DUTIES. This
agreement is not intended to, nor shall it be construed as, relieving any participating entity 0
from any obligation or responsibility imposed upon the entity by law except to the extent of
actual and timely performance thereof by any participating entity, in which case the
performance may be offered in satisfaction of the obligation or responsibility. Further, this
agreement is not intended to, nor shall it be construed as, authorizing the delegation of the
constitutional or statutory duties of the County, except to the extent permitted by the Florida
constitution, state statute, and case law.
24. NON-RELIANCE BY NON-PARTIES. No person or entity shall be entitled to rely
Cr
upon the'terms, or any of them, of this agreement to enforce or attempt to enforce any third-
party claim or entitlement to or benefit of any service or program contemplated hereunder,
and the County and the Grantee agree that neither the County nor the Grantee or any agent,
officer, or employee of either shall have the authority to inform, counsel, or otherwise indicate
that any particular individual or group of individuals, entity or entities, have entitlements or
benefits under this agreement separate and apart, inferior to, or superior to the community
in general or for the purposes contemplated in this agreement. y
25. ATTESTATIONS. Grantee agrees to execute such documents as the County may
reasonably require, to include a Public Entity Crime Statement, an Ethics Statement, and a
Drug-Free Workplace Statement.
26. FORCE MAJEURE. The Grantee shall not be liable for delay in performance or
failure to complete the project, in whole or in part, due to the occurrence of any contingency E
beyond its control or the control of its contractors and subcontractors, including war or act
of war whether an actual declaration thereof is made or not, act of terrorism impacting travel
in the United States, insurrection, riot or civil commotion, act of public enemy, epidemic,
Mel Fisher Masonry Repair and Electrical Improvements
FY 2020 Capital Project Funding
Contract ID#2316 Packet Pg. 2008
14
quarantine restriction, storm, flood, drought or other act of God, or act of nature (including _
presence of endangered animal species which cannot be timely removed in a safe manner)
or any act of any governmental authority which prohibits the project from proceeding as y
described in the scope of services and incorporated references and which the Grantee has
exercised reasonable care in the prevention thereof. However, lack of planning for normal
and expected weather conditions for the time of year the project is to be executed shall not
constitute an act of God excusing a delay. Any delay or failure due to the causes stated
Lu
shall not constitute a breach of the agreement; however, the Grantor shall have the right to
determine if there will be any reduction to the amount of funds due to the Grantee after
consideration of all relevant facts and circumstances surrounding the delay in performance
or failure to complete the project within the contract period. Upon demand of TDC or
Grantor, the Grantee must furnish evidence of the causes of such delay or failure. Grantor
shall not pay for any goods received or services provided after the date(s) described in E
paragraph 1 and Scope of Services.
27. EXECUTION IN COUNTERPARTS. This agreement may be executed in any number
.of counterparts, each of which shall be regarded as an original, all-of which taken together
shall constitute one and the same instrument and any of the parties hereto may execute this
agreement by signing any such counterpart.
28. SECTION-HEADINGS. Section headings have been inserted in this agreement as a
matter of convenience of reference only, and it is agreed that such section headings are not
a part of this agreement and will,not be used in the interpretation of any provision of this 0
agreement.
29. MISCELLANEOUS: As used herein, the terms "contract" and "agreement" shall be
read interchangeably.
Cr
2
06
Lu
y
Mel Fisher Masonry Repair and Electrical Improvements
FY 2020 Capital Project Funding Packet P 2009
Contract ID#2316 9
1A
y NESS WHEREOF, the parties hereto have caused this agreement to be executed
and year first above written.
Board of County Commissioners
vin Madok, Clerk of Monroe County
LU
9ryPReRT COYN7�
7
Deputy Clerk Mayor/Chair an
...........................................................................................................................
The I fisher Maritime Heritage Society, Inc.
By ..y E
President -7M 2
r, o .T--
C r�> rrI
� o
Prin Name a co
i.. L
Date: 3 ,,, +
c,
ca �
N'D�TW_O WITNESSE:7
0 &Aa (2)
(1) A46n iew &CbK (2) vtog V4
Print Name Print Name
Date: 9 3 Date: 7 '
06
0
MONROE COUNTY ATTORNEY
AP VED AS T�jFO,RM: / as
rrru7�
CMUSTINE LIMBB jE�RT-BARROWS
ASSISTA 7�T�'AEI ORNEY
DATE:
� ) ��
Mel Fisher Masonry Repair and Electrical Improvements
FY 2020 Capital Project Funding
Contract ID#2316
15
Packet Pg. 2010
4uewpueua ) 4ueweejBv IBUIBIJO PUB 4UgwP qua `4s nb - 3IJ43 ' ®s a ys' 1 :4u8ua 3 44 r
R o
ai 0)
Q IL
LO
u
N
hp N C
X C
W 4 0
` L
0
h
V 0 Q
° c C)
m
%- ----------------------------------------------------------------------------------------- --
o o
ma o
o � o
0 a_ � 3
co
L vs
U o o 0
G� t3
W
h
to U :E C (�
.0
0 O ° a U
.� E .Q a) a�i m a,
> 0 3 y
0 O � � o � 00
y 0 C
:F. p w O y 0 " � � � u ° *: Q
.L � � O X — 0 a £ rE
i.. � C •� 0 W 4-- 0 y U
U •C � } p
O$ _ CC
t LL O .Q N L £ .� t a!
-0 ._ a o
U a 1�2L 0 E Q-
W O Ec :E O U N d U y �.
y C C L 0' al E W
N
OO uiE.o 0 0- � QCA U °.dN
w o c � Ln o �
W W m V E O � u 0 .� .CO .fl s
r2 � u U •� 3w . � Q � �.yc °
ZZ ZZa c � �° Eo °
L H 0 CL
r 4uewpueua ) 4ueweejBv IBUIBIJO PUB 4UgwP 9ua `4s nb - 3IJ43 ' ®s a ys' 1 :4u8LUq3B44V 04
R o
w
a
00
IL
X CL
W c
O
4-
L
O
C
U
0
--------------------------------------------------------------------------------------------
b
0
o
0 30
N
toe) x cn
an
v 0 .o
U z
dN �
U
O
F 1 .2 a
"u
O Facia
E
L N (D ar o
�-
U d '> � ar
Cc mQoy
— O
i
O v
O O o -� �
y
� p cagy
U 0 ~
vEcEV w
Q U � 0 E
.� C5
0
W CL 0
� � o a C
� uE °'
rnc.� v
O m c E m
'sue 0
«. u
0 E •� 0
E U a c•`-' c rn
� cn ° 5E p
Q c v
� ".� yya