The URL can be used to link to this page

Item C21 BOARD OF COUNTY COMMISSIONERS AGENDA ITEM SUMMARY Meeting Date: i�16, 2014 Division: Engineering & Public Works Bulk Item: Yes X No — Department: Pro'ect ManaRement ,Staff Contact Person/Phone#:Wilson (453-8797) AGENDA ITEM WORDING: Ratification of a professional services contract (Task Order)under an existing Continuing Professional Services Contract with Currie, Sowards, Aguila Architects to develop several site plan options for a new library on a School Board property in Marathon. Funding is from infrastructure sales taxes. ITEM BACKGROUND: Replacement of the Marathon library is one of the debt funded projects identified in the approved capital plan. After review of several sites, the property next to the Switlik school is staff's and the community's first choice. The School Board staff has asked for examples of site plans that might result in order to make a recommendation to their board. This contract will provide a conceptual site plan to secure approval to develop an interlocal agreement leading to full design and construction. PREVIOUS RELEVANT BOCC ACTION: Approval of the capital Improvement Plan in September 2013. CONTRACT/AGREEMENT CHANGES: N/A STAFF RECOMMENDATIONS: Approval TOTAL COST: NTE$6,500 INDIRECT COST: Staff Time BUDGETED: Yes X No DIFFERENTIAL OF LOCAL PREFERENCE: N/A COST TO COUNTY:-NTE$6,500 SOURCE OF FUNDS: 304 REVENUE PRODUCING: Yes No X AMOUNT PER MONTH Year APPROVED BY: County Atty_tk�V ' &MB/Purc1fas(i-n`g, Risk Management DOCUMENTATION: Included X Not Required_ DISPOSITION: AGENDA ITEM Revised 7/09 MONROE COUNTY BOARD OF COUNTY COMMISSIONERS CONTRACT SUMMARY Contract with: Currie Sowards Aguila Contract# Effective Date: 06/11/14 Expiration Date: Contract Purpose/Description: Develop site plan options for a new Lib!Lag in the City of Marathon Contract Manager: Ann Riger_ X4439 Project M t/Sto #1 (Name) (Ext.) (Department/Stop#) for BOCC meet n on 07/16/14 Agenda Deadline: CONTRACT COSTS Total Dollar Value of Contract: $ 6,500.00 Current Year Portion: $ 6,500.00 Budgeted? Yes® No ❑ Account Codes: 304-22004-530340- - Grant: $ - - County Match: $ - _ - - ADDITIONAL COSTS Estimated Ongoing Costs: $ /yr For: )Not included in dollar value above) (el.,maintenance,utilities,janitorial,salaries,etc.) CONTRACT REVIEW Changes Date Out Date In Needed evi er Division Director Yes N . o Risk Management Yes[]No j O.M.B./Purchasing L.2—�/t/ Yes No[L] AO County Attorney ' L' Yes❑No Comments: OUS1 FoInn Revised 2/27/01 MCP 7 CONTRACT FOR PROFESSIONAL SERVICES BETWEEN OWNER AND ARCHITECT/ENGINEER Marathon Library Site Options, Marathon, Florida THIS CONTRACT made as of the d _1C day of June,2014 FOR PROFESSIONAL SERVICES BETWEEN OWNER AND ARCHITECT/ENGINEER(the"Contract"or"Agreement")is made and entered into by MONROE COUNTY, BOARD OF COUNTY COMMISSIONERS ("Owner"or"County"),a political subdivision of the State of Florida,whose address is 1100 Simonton Street,Key West,Florida 33040,its successors and assigns through the Monroe County Board of County Commissioners("BOCC"),and CURRIE SOWARDS AGUILA ARCHITECTS, the("Architect")., whose address is 185 NE 4"Avenue, Suite 101,Delray Beach,FL 33483,its successors and assigns. WITNESSETH WHEREAS,on the 20'h day of January 2010,the parties entered into a Continuing Contract for projects in which the estimated construction costs of each individual project under the contract does not exceed Two Million Dollars($2,000,000.00),or for study activity if the fee for professional services for each individual study under the contract does not exceed Two Hundred Thousand Dollars($200,000.00); and WHEREAS,on the 20"'day of November 2013,the parties entered into a First Amendment to Contract renewing the Continuing Contract for the first of two one-year periods effective January 20, 2014 and terminating January 19,20 15;and WHEREAS,the County is considering alternate sites for the location of a new public library in the City of Marathon; and WHEREAS,the County has discussed a particular School Board site for the location of that new public library in the City of Marathon pending presentation of site layout options; and WHEREAS,the Board of County Commissioners have directed staff to determine if the School Board property would be an appropriate location for the new library;now therefore, IN CONSIDERATION of the mutual promises, covenants and agreements stated herein,and for other good and valuable consideration,the sufficiency of which hereby acknowledged,the Owner and Architect agree: I PROJECT DESCRIPTION& SCOPE OF WORK A. Architect shall provide several site plan proposals for presentation to the School Board and BOCC for a new public library on the land owned by the Monroe County School Board next to Stanley Switlik School. B. The Scope of Work includes: 1) Review applicable Land Development Regulations to determine any code constraints, Page I 1 Professional Services Marathon Library Site 2) Prepare a general understanding of program spaces required to house the intended facilities, including Adult Education Classes,public library space,and other meeting spaces. 3) Prepare several site planning options for review and discussion. 4) Prepare an initial opinion of cost for the selected site plan option. 5) Attend on-site meetings, if necessary,to discuss plan with stake holders. C. Architect shall complete his services within forty-five(45)days after a written notice to proceed. Additional time may be given the architect,in writing,in such cases that presentation of a final conceptual site plan falls beyond the forty-five(45)days. 2 FEES Fees for services described above will be based on the firm's hourly rates per the current Continuing Contract Agreement between the BOCC and the Architect with a not to exceed amount of Six Thousand Five Hundred Dollars($6,500.00)and No Cents, including reimbursable expenses for printing and reproduction. 3. ADDITIONAL SERVICES Any Additional Services that may be required shall be approved by the County only after receiving an Amendment to the Agreement and a Notice to Proceed from the County. Additional Services may be provided by the Architect by a proposed lump sum fee,or at the hourly rates attached to Exhibit A. 4. PUBLIC RECORDS "Pursuant to F.S. 119.070 1,Contractor and its subcontractors shall comply with all public records laws of the State of Florida,including but not limited to: A. Keep and maintain public records that ordinarily and necessarily would be required by Monroe County in order to perform the service. B. Provide the public with access to public records on the terms and conditions that Monroe County would provide the records and at a cost that does not exceed the cost provided in Florida Statutes, Chapter 119 or as otherwise provided by law. C. Ensure that public records that are exempt or confidential and exempt from public records disclosure requirements are not disclosed except as authorized by law. D. Meet all requirements for retaining public records and transfer,at no cost,to Monroe County all public records in possession of the contractor upon termination of the contract and destroy any duplicate public records that are exempt or confidential and exempt from public records disclosure requirements.All records stored electronically must be provided to Monroe County in a format that is compatible with the information technology systems of Monroe County. Page 2 Professional Services Marathon Library Site 5, All other terms and conditions of this Contract shall comply with the Continuing Contract dated January 20,2010, and as renewed on November 20,2013,which shall be made a part of this contract as if written herein in its entirety. IN WITNESS WHEREOF, each party caused this Agreement to be executed by its duty authorized representative on the day and year first above written. BOARD OF COUNTY COMMISSIONERS OF MONROE COUNTY,FLORIDA By: County Administrator (SEAL) BOARD OF COUNTY COMMISSIONERS Attest: AMY HEAVILIN, CPA,Clerk OF MONROE COUNTY, FLORIDA By: mmm. By: Deputy Clerk Mayor/Chairman ARCHITECT/ENGINEER CURRIE SOWARDS AGUILA ARCHITECTS MONROE COUNTY ATTORNEY AVII rj()VEE) AS TY)y6'Aw By: A� 40e E itEE CA Print Ni AT� �77' 1§SE-L Title', ��SS�STANT COUNTY AT 1`09NEY Date: _ INC 6 STATE OF FLORIDA COUNTY OF PALm 6EW.Ai ,On this day of_JO.N .__E,... 2014, before me, the undersigned notary public, personally appeared jj. known to me to be the person whose name is k�E� —, — �subscribe,d above,or who produced . ......... —. as identification, and acknowledged that he/she is the person who executed the above Contract with Monroe County for Professional Serv* es for the Marathon Library Site Options for the purposes therein contained. OT. PUBLIC. mission expires: Ij Professional ery es for, miss�ion e) LEY!on#Eli 032 97 ove�t r 0 0 C C()o V�l Expires N 2 2 1419 'N'77`1� J.WHITLEY orrimission#EE 032097 Q Expires November 20,2014 Page 13 Professional Services Marathon Library Site' EXHIBIT A List of hourly rates FF1 URRIE SOAID AGUILA architects ARCHITECTURAL HOURLY SERVICES CALENDAR YEAR 2014 ARCHITECTURE: Principal $175.00 Project Architect $150.00 Project Manager $125.00 TECHNICIANS: Cadd Tech 1 $85.00 Cadd Tech II $65.00 OFFICE SUPPORT: Office Support Staff $45.00 Architecture, Planning, Interiors,Sustainable Design 185 NE 4th Avenue,Suite 101,Delray Beach,F133483 T 561-276-4951 F 561-243-8184 www.csa-architects.com Amwaism STATE OF FLORIDA p DEPART NTOF BUS"AND PROFESSIONAL REGULATION r�°" �d V/ BOARD OF AR 'URE A INTERIOR DL�SIKIP4 L J FLORIDA DEPARTMENT O F sllsw tI l I EOM I CE TIM NIr� l ��, T�FIEI� ,.: �w I U wLd�I lhrotm �i 4 Oh W d41 461 F'S BUSINESS Eapd dale: FFO,24,20ts AND PROFESSIONAL REGULATION R�w vcz lea ��w W, LICENSES �w AR RICK SCOTT 1555lE0 =W.-,7013 SE00 03WC'WW1619 KEN LAWSON CSC VE7NOR OISPLAYAS REQUIRED BY LAW SECRETARY STATE OF FLORIDA DEPAR"IMENY OF BUSINESS AND PROFESSIONAL REOULAT04 BOARD OF Ak CATECTURE A IN'MMR DESIGN u I� STIutUNSEO IBI EKpIkrTlRpar, FSYL'kk� DldF.. � rtt W f � 1 mP" INICKSCOrT kSSUED 17CA=2013 SE48 0:0060pIAft K.ENLAWSOIN ' GOVERNOR DISP LAY AS RECUR ED DY LAW SECRETARY STATE OF FLORIDA OEPARTMENT OF BUSINESS AND PROFESSIONAL REGULATION DOARD OF ARCHITECTURE A INTERIOR DESIGNPAW ? f The, Cll—601 gay Non'Y,5'i knsaw VS LICT-0I Ld Undw am of IfI1sPdnv4P 1 FS 6v$ft q SO'MWR,R J S I ,+✓ �PM F l� �p ^ � , H CdBV'I<rk:;C1TT 75iWl,D 021tpJXY93 JEOO L130.21 MM05; KEN LAWSON f GOV£"PNOR DISR.RrAS REQUIRED HY^ AW 3ECF0.E ARY l ,,,o.el' ''iN ,,.,�,IWll" m,.,,.. !0 ,,.,,, i STATE OF FLORIDA DEPARTMENT OF SUSIN S AN PROFESSIONAL R`GULA IN. � BOARD OFA9Rd"fMCIE&INTEMOR rSI ^1 O9 eLNSED 4R^A m do � �04wpW 4011FS ' Eat E,�raa.FEI� S� IE %� 3 rpp1 I S I4 ��,� 8fry ✓ 4 II I4 7 RICK SCOrT SUE n2 ns2 e3 1111.11 ILIIIXI 66 11r 1 KEN i.AWSON GOVERNOR DISPLAY AS R UIREG'RYtAW91 SEC7RW'rARY Client* 111049. --o CIURRISOW ACORD. CERTIFICATE OF LIABILITY INSURANCE THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER.THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND,EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW.THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSUREIR(S),AUTHORIZED REPRESENTATIVE OR PRODUCER,AND THE CERTIFICATE HOLDER. .............. '' ...a.n..... ........................ _'1kP6RT_A4 -if the certificate holder Is ADDITIONAL INSURED,the pollcy(les)must be endorsed.If SUBROGATION IS WAIVED,subject to the terms and conditions of the policy,certain policies may require an endorsement.A statement on this certificate does not confer rights to the certificate holder in lieu of such eindorsement(s). PRODUCER N ME USI Insurance Services,LLC, 1 " ' 813 321-75 O — 525 1715 N.Westshore Blvd.Suite 700 MAIL .................... -------------- INSURERIS)AFFORDING COVERAGE NAIL It ................. ------.............. ............. ...--l" Tampa,FL 33,6107 INSURER A�MSA Insurance Company 11066 _1............ ....... INSURED INSURER a:Travelers Casualty &Surety Co 31194 Currie Sowards Aguila Architects Inc INSURER C!XL Specialty Insurance Company 37885 185 NE 4th Ave INSURER 6 Suite 101 I Delray Beach, FL 33483 INSURER E .................. ...................... INSURER F COVERAGES CERTIFICATE NUMBER. REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED, N07VVITHSTANDIING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACTOR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE 'POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. .................. A6b1suBR------ TYPE OF IN POLICY NUMBER LIMITS ........................ ....... LA (Rmmm�iyy� A GE INBR .NE I RAIL LIABILITY BPG98835 0811712013 08/1712,014 EACH OCCURRENCE ......... E TED X COMMERCIAL GENERAL LIABILITY Ea =Airijacel I . ............"""'" - .......... ...... CLAIMS-MADE DX OCCUR MED EX ne PERSONAL&ADV NJIJ!��_ $11,000,1000 ................ GFNERALAGGRFG ................... ............. GEN'L AGGREGATE LIMIT APPLIES PER: PRODUCTS-COMP/OP AC( �$2,000,qp,q_ ................. ...... PRO. f I L2C, $ . ............ ................. ............... INC L�E A AUTOMOBILE LIABILITY BPG98835 08/1712013 0811712011 ............. _$11,000,100.10 ANYAUTO BODILY INJURY(Per person) A HEDULFD BODILY INJURY(Per accidenQ $ A AUTOS .......... ------------- _X x NOW-OWNED HIRED AUTOS AUTOS ........... ..... UM"BRELLA_L IAB 222uRR'ENCE-_ $ OCCUR EXCESS LIAG .................. .......... u"A ............................... ............ _QP 1 E12 B WORKERS COMPENSATION X UB5436Y349 01/0112013 011011201 x ............... I I - ............. -C- 0'Ill,AIU AND EMPLOYER SLIABILi TY Y!,N ANY OFFICCrUMENISER EXf NIA (Mandatory in NH) E.L.YISEASE-IEh,N M I�Oy E-E.5. under E L DISEASE 'YL, _10�000_1' �D IlW11'ON OFOPEFATI0,1JS 4ntaw ----------- ------------- qqq ........... C Professional OPS9711454 0812,4/2013 0,8/241201 $2,0010,000 per claim Liability $2,0100,000 arml aggr. DESCRIPTION OF OPERATIONS/LOCATIONS I VEHICLES(Attach ACCORD 101,Additional Remarks Schedule,if more space is required) Al PR_ Professional Liability coverage is written on a clai�ms-made basis, T_ Monroe County is an additional insured with respect tio,General Liability and Auto Liability,. MI CERTIFICATE HOLDER CANCELLATION SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE Monroe County THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN 1100 Simonton St. ACCORDANCE WITH THE POLICY PROVISIONS. Room 2-216 Key West, FL 33040 AUTHORIZED REPRESENTATIVE q Cam.-Ire,al CQ 1988-21010 ACORD CORPORATION.All rights reserved. ACORD 25(20110105) 1 of The ACORD name and logo are registered marks of ACORD #SJ08198321M1081982i KEBEW Client#: 1049229 CURRISOW DATE(MMiDDfYYYY) CERTIFICATE OF LIABILITY INSURANCE ACORDT. 1102/2014 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NORIGHTS UPON THE CERTIFICATE HOLDER.THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND,EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW.THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S),AUTHORIZED REPRESENTATIVE OR PRODUCER,AND THE CERTIFICATE HOLDER. ....................... ----------- T. .if the certificate holder is an ADDITIONAL INSURED,the 1policy(ies)must be endorsed,If SUBROGATION IS WAIVED,subject to the terms and conditions of the policy,certain policies may require an endorsement.A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s), gON'.AC PRODUCER . .......— FAA .. ............. ...... USI Insurance Services,LLC, -PHONE k �.813 3,21-7500 813 321-7525 �NC,NqAyq ......................."I'll"......... 1715 N.Wests1hore Blvd.Suite 700 E MAIL .......................... Tampa,FL 33607 INSURER A:IVISA Insurance Company 11066___ INSURED INSURER B:Travelers Casualty&Surety Co �11194 Currie Sowards Aguila Architects Inc INSLRERC!XL Specialty Insurance Company 7885 185 NE 4th Ave INSDRIE ---------- .................. ......... INSURE R� Suite 101 INSURER E: Delray Beach, FL33483 COVERAGES CERTIFICATE NUMBER: REVISION NUMBER:: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACTOR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEE N REDUCE D BY PAID CLAIMS ................. --------------- ----------------- ............. 111111____'_ 61110 _... ADDLSUSR POLICY id EXP NSR TYPE OF INSU POLICY NUMBER LIMITS 1tTg___ _ R�CE. I'M-9-k W-V.P ---------------- ——---- A GENERAL LIABILITY x BPG98835 D8117120113 0811712014 EACH OCCURRENCE ----------- JMMENTED X COMMERCIAL GENERAL LIABILITY 0r:Furrena 11_1§00,000 -— --------I CLAIMS-MADE I—XI OCCUR PSONAL&ADV INJURY $1 000000 ER .............. ----------........... . ..... ..... GENERAL ---—_--........ s2000000 GEN'L AGGREGATE LIMIT APPLIES PER: _P_R0_DyC.TS-1; E2t�219 :IfOLC ,Ro $ —Y P .............. .............. COMBINED SINGLEUMIT 1,000,000 A AUTOMOBILE LIABILITY BPG98835 D8/1712013 08/171201 ANY AUTO BODILY INJURY(Per person) $ ........ ............ ALL OWNED SCHEDULED BODILY INJURY(Per accident) $ AUTOS AUTOS .................. X NON-OWNED X HIRED AUTOS AUTOS ....... ------ - .............. ....... .... --- ACH OCCURRENCE OCCUR ------ .: ,r - .... T., EXCESS LIAB AIMS MADE, ... .......... —------ .............. _1 -fi� $ ................... I IJI. B WORKERS COMPENSATION X UB5436Y3,49 01- ................. AND EMPLOYERS'LIABILITY Y/N E.L,EACH ACCIDENr 0 000 0:010 ANY PROPRIETOR/PARTNER/EXECUTIVE ----I OFFICER/MEMBER EXCLUDED? L_J NiA EL.DISEASE-EA EM 1. EE $1000 000 (Mandatory in NH) 2y describe EL DISEASE-POLICY LIMIT $1,000,000 scribe under RIPTION OF OPERA'n0NS bel ............. ........ .............................. --------- .......... ........... .................. C Professional DPS9711454 8/24/2013 0812412014 $2,000,000 per claim Liability $2,000,000 anal aggr. DESCRIPTION OF OPERATIONS/LOCATIONS/VEWCLES(Attach ACORD 1011,Additional Remarks Schedule,it more space is required) Professional Liability coverage is written on a claims-made basis. CERTIFICATE HOLDER CANCELLATION SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE For Proposal Purposes THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. AUTHORIZED,REPRESENTATIVE Aa— (0 1988-2!010 ACORD CORPORATION.All rights reserved. ACORD 25(2010105) 1 of I The AGORD name and logo are registered marks of ACORD #S11520428IM11422873 KEBEW , � 1'T AMENDMENT TO CONTRACT FOR PROFESSIONAL SERVICES BETWEEN OWNER AND ARCHT|ECT/EmG8mEER FOR THE EXTENSION OF THE CONTINUING CONTRACT This First Amendment tu contract (herein after"Annendment°) between Owner and Arch itect/En8ineer for the Continuing Contract for Professional Services("Contract"), entered into between Monroe County ("Owner"or"County")and Currie Sowards Aguila Architects("Arch itect/E ngi n eer )is made and entered into this 20'h day of November, 2013,in order to amend the Contract as follows: VV|TNESSETH WHEREAS,on January 20,2010,the parties entered into a continuing contract for Professional Services, pursuant to Florida Statute 287.055 (2) (g)where services are to be rendered for projects in which the estimated construction costs of each individual project under the contract does not exceed Two Million Dollars($2,000,000,00),or for study activity if the fee for Professional Services for each individual study underthecontractdmesnotexceedT\xoHundredThousandDo||ars($200,OOO.DO);au6 WHEREAS,the Continuing Contract stipulates that a separate contract for each project awarded tothe Architect by the owner be provided each with specific scopes of work,time schedules,charges and payment conditions, and additional terms and conditions applicable to that specific contract;and WHEREAS,in accordance to the Continuing Contract the Professional Services will be for a period of four years commencing on the date of the contract,with options for the Owner to renew onan annual basis for two additional one year periods; NOW THEREFORE,in consideration of the mutual promises,covenants and agreements stated herein, and for other good and valuable consideration,the sufficiency of which hereby acknowledged,the Owner and the Architect agree osfollows: 1. The Continuing Contract for Professional Services dated January 20,2010 and terminating on January 19,2014,shall The renewed for the first of two one-year periods effective on January 20, 2014 and terminating January 19, 2O15. 2. The following shall be added to Article XVI] of the original Continuing Contract dated January 20, 2010: m) Architect shall not disclose publish, or authorize others to disclose or publish, design data, drawings,specifications,reports,or other information pertaining to the services performed by the Architect or other information to which the Architect has had access during the Term of this Master Agreement without the prior written approval of the County,during the Term 1 MP 1 II I! Master Agreement. Nevertheless,the parties agree that the Architect may use and publish the County's name and give a general description of the work provided by the Architect for the purpose of informing other clients and potential clients of the Architect's work experience and qualifications. b) Should the County receive a request for documents pursuant to Chapter 11.9, Florida Statutes,Architect shall cooperate with the County to facilitate the County's compliance with Chapter 119,Florida Statutes. Should the Architect assert any exemptions to the requirements of Chapter 119 and related statutes,the burden of establishing such exemption, by way of injunctive or other relief as provided by law, shall be upon the Architect. Failure by the Architect to cooperate with the County in connection with a Public Records request shall be grounds for immediate unilateral cancellation of this Masterb Agreement by the County." 3. In all other respects,the original Continuing Contract dated January 20,2010 remains unchanged. J *WJNESS WHEREOF,each party caused this Agreement to be executed by its duly authorized pr �watly on the day and year first written above. l HEAVILN CPA,Clerk BOARD OF COUNTY COMMISSIONERS OF MONROE COUNTY, FLORIDA '. q. � By: c P;Chairman Deputy Clerk ' Mayo I` WITNESS to Architect's Signature: ARCHITECT ._ WITNESSS a ature Cufie jo� ar . guila Architects NIDN 10E COUNTY ATTORNEY L Print Witness ame M �'�"HOED AS TO G"QJ4�1 a Date: NATILEENE . CASSEL ASSIST NET oum"y ArroAN Y 00 ,18 Wd C,?I CURRISOW Client#,.10�49._j DAVE IMW01WYVYY) ACORD,- CERTIFICATE IOF LIABILITY INSURANCE 08119/2013 THIS CERTIFICATE IS ISSUED AS A MATTER Of INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER.THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND,EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW,THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURERI[S),AUTHORIZED REPRESENTAME OR PRODUCER,AND THE CERTIFICATE'HOLDER. i6s IVutPOFtTAt cortificate o(er Es'en' Ab6`1`T_fdi4kC INSURED,thwPollcOos), Me terms and conditions of thia pofty.certain policies May requIre an ondorsemen'L A statement on th(ij certificate does not confer rights tothe PRODUCER ceirtifIcate holder In lieu of such endorsentent(s). -PAX— USI Insurance Services,LLC, 0, 813 321-7500 I�Q� I 1111N_P�.,Npt 1715 N.Westshore Blvd.Suite 700 E�nAIJ Atc 0 11066 rt IN UREDRS Tampa,FL 33601 INSURER A�MSA Insurance Company. Travelers Casualty&Surety Co 31194 S Currie Sowards Agulla Architects Inc INSURER C �LLLSpeclaltyInsuraance CDrmparxy 3 11 7885 185 NE 4th Ave INSURE 0' .......... Suits 101 111 k REItr Delray Beach,FL 33483 INSURER F COVERAGES CERTIFICATE NUMBER: REVISION NUMBER: THIS is To cERTiry"THAT THE POLICIES OF INSURANCE LISTED BELOW H E BEEN ISSUED TO THE INSURED NAMED AfIOVE FORTHII POLICY PERIOD INDICATED. NQTV\nTHS7ANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT'TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERIIAS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES, LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS, LIMITS ,P FINSURANCE POLICY N�400 M -�2 _,_" '' _... lWKWUR mw q,MR, A GENFRAL LIABILITY BPG98835 811712013 081171201 FA(,N,OccunfpFmcF S100000 <L 0 u COMMERCIAL GENERALLIABILIFY A a xP Soo 71 CWMS-MADE Fix OCCUR KASONAL&ADV INJURY .......... ............... UCj'S-00MPX)PAGG_s2 MOD GENT.AGGREGATE LIMIT ATIM.112S PER: " A AUTOMOBILE LIAO ILITY BPG�98835 )811712013 0 1,71201 so 0 BODILY INJURY(P"r Parson) $ ANY AUTO ........... ALI.OWNED SCHEDULED BODILY INJURY AUrOS AUTOS Of , -I� NON-OWNED X HIRED AUTOS AUTOS cuuCJtLI X, kmK. ORil L LA LEAS CXCESSUAB CLAIMI-34AA0E ..... ........... ...... ........... 1 WORKER��s�uAl#IION PEtWAT X UBS43GY349 0110112013 01101123NPLITY YIN 11 OD ANY IVOPR�,1,TOR�rPAFATNEr'�JEX�.CUTIVL. rL RACHACaUtNT 0 0_ OrFIC AVIVIEMOrR r,XCLUDED? NIA E,I, rASE,EA EMP 0YE0, Is UH) I.L I oeschbe w,dva C I' 'I OF opr-,RATI �'O SEASE &,.'S RIPnq N ONS bal__ m. DPS9711454 0 2 A 46, $2,00,000 per claim C Professional Liability $2,0100,000 anni aggr. DESCR kPITION OF OPERATIONS I LOCATIONS;VIEHIG LFS(A With ADORE)101,Additicalat Remarks ftbodu ib.it mar*space isvequomd) A Professional Liability coverage is written on a cilaims-made basis. Monroe County Is an additional Insured with respect to General Liability and Auto Liability. Crt Ai J CERTIFICATE SMOLDER CANCELLATION SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE Monroe County THE EYPIRATION DATE THEREOF:, NOTICE WILL BE DELIVERED IN 1100 Simonton St. ACCORDANCE WITH THE POLICY PROVISIONS. Room 2-216 Key West,, FL 33040 AUTHORIZED RIEPRESeNTA,riviz 06—w-.Aa, +0 1988-2010 ACORD CORPORATION.Ail rights reserved. ACORD 25 0106) 'The ACORD name and logo are regIstemd marks of AC(2011 1 of I #S108198321M10819821 KEBEW FLORIDA DEPARTMENT w� OF BUSINESS M AND PROFESSIONAL REGULATION LICENSES ✓.,�,.� r ,w,' ,�.o.�e ,,, 4rr<�yw��: ,m „m � �",m.,.� r �1�w�""a"� ,!ash"w 7,�ri i��w�"�'<'n, � ,. ��,.. Vddd w� r, d4& P LAW CAVAR` SIAM, 4 trvn ' ummmmlim � i; bB tl "m Vs man �tl'a°&�Yard ��W� . IXCfa ' 7 7, aliHwww��' rv�� dry A, t '�✓ m ^' ,„ e y u,i hE "'� rod w9 1 d Ad"' 1dl;SP Ameft: amsows not 1ommoomMOKA �. W AS f d fl'k to ry � � I ar Oo�,�i . � a�„m i n „din,:.5^y ,.ww a _,� ',•-" wmrp.w ' k4 itr mm�,Idb� pj;,. d"3G:V4d 7'4W'"NMC EYkW+d.Af hdhd RiF�y'd.ddWV'0 BY 9..KA! WI m ' '�� it r.,,.. ,.'„� ,,�,�1., ,, ,,,,�✓,, �,,llid Via; ,G, ;� ,i,, �, ,/; II; c^^ 21 M :a asa fi 0 � � mod) Lu ` i. 2 ro�®o LU a LLI uj Ae m U1 c 9 w c. o yea �;, _ p. am Me —A uj €4 E ad2 � r"ma �p ask xsa I O m1 U '0 Fx ¢. � !-T uta 55 LL •�y a& DOW co ffJ� „ u� ' t1J W �rr r ° 32 DD 0 L) uw � u� r N CONTRACT FOR PROFESSIONAL SERVICES BETWEEN OWNER AND ARCHITECUENGINEER THIS CONTRACT FOR PROFESSIONAL SERVICES BETWEEN OWNER AND ARCHITECT/ENGINEER (the"Contract" or"Agreement") is made and entered into by Monroe County("Owner"or"County"), a political subdivision of the State of Florida, whose address is 1100 Simonton Street, Key West, Florida 33040,its successors and assigns through the Monroe County Board Of County Commissioners ("BOCC"), and !Lqrrie 'Sovya rds An4jlii Archite-_qJs, the("Architect")., whose address is 134 NE IST Avenue,Delray Beach,FL 33444, its successors and assigns. This contract shall be effective on the date of execution by the last party signatory to the contract. This contract is issued as a continuing contract pursuant to Florida Statute 287.055(2)(g). The professional services required by this Contract are to be rendered for projects in which the estimated construction costs of each individual project under the contract does not exceed Two Million Dollars ($2,000,000,00), or for study activity if the fee for professional services for each individual study under the contract does not exceed Two Hundred Thousand Dollars ($200,000.00). The parties shall enter into a separate contract for each project awarded to the Architect by the Owner.The specific services to be performed under these separate contracts will be determined by the Owner and agreed to by the Architect.Each separate contract will contain specific scope of work,time schedule,charges and payment conditions,and additional terms and conditions applicable to that specific contract.Architect will be chosen pursuant to Owner policy and work will be distributed among all contractors who have signed a continuing contract. The professional services required by this contract will be for services in the form of a continuing contract,commencing on the effective date of this contract and ending four years thereafter,with options for Owner to renew on an annual basis for two additional years. The terms and conditions of this Contract shall apply to any separate contract,unless expressly modified in the provisions of the separate contract. Wliere the terms of this Contract differ from the terms of the separate contract,the terms of the separate contract shall take precedence. The separate contract will contain its specific scope of work and it is anticipated by this Contract that the scope of work in the separate contract will be in addition to the scope of work outlined in this Contract NOW,THEREFORE, in consideration of the mutual promises, covenants and agreements stated herein, and for other good and valuable consideration,-the sufficiency of which hereby acknowledged, the Owner and the Architect agree- 11 FORM OF AGREEMENT ARTICLE I 1.1 REPRESENTATIONS AND WARRANTIES By executing this Contract,Architect makes the following express representations and warranties to the Owner, UA The Architect is a professional qualified to act as the Architect for the Project and is licensed to practice Architecture/Engineering by all public entities having jurisdiction over the Architect/Engineer and the Project; 1.1.2 The Architect shall maintain all necessary licenses,permits or other authorizations necessary to act as Architect for the Project until the Architect's duties hereunder have been fully satisfied; 1.1.3 The Architect shall become familiar with the individual Project site and the local conditions under which the Project is to be designed, constructed, and operated prior to entering a separate contract for any specific Project. 1.1.4 The Architect shall prepare all documents required by this Contract including,but not limited to,all contract plans and specifications, in such a manner that they shall be in conformity and comply with all applicable law, codes and regulations. The Architect warrants that the documents prepared as a part of this Contract will be adequate and sufficient to accomplish the purposes of the Project, therefore,eliminating any additional construction cost due to missing or incorrect design elements in the contract documents; 1.1.5 The Architect assumes full responsibility to the extent allowed by law with regards to his performance and those directly under his employ as Architect of Record. 1.1.6 The Architect's services shall be performed as expeditiously as is consistent with professional skill and care and the orderly progress of the Work. The Architect shall submit, for the Owner's and Monroe County Project Management Department's information,a schedule far the performance of the Architect's services which may be adjusted as the Project proceeds if approved by the Owner, and shall include allowances for periods of time required for the Owner's and Monroe County Project Management Department's review, and for approval of submission by authorities having jurisdiction over the Project. Time limits established by this schedule and approved by the Owner may not be exceeded by the Architect except for delay caused by events not within the control of the Architect or foreseeable by him. 1.1.7 In providing all services pursuant to this agreement, the Architect shall abide by all statutes,ordinances,rules and regulations pertaining to, or regulating such services, including those now in effect and hereinafter adopted. Any violation of said statutes, ordinances,rules and regulations shall constitute a material breach of this agreement and 2 .......... cement immediately upon delivery Of shall entitle the MN-fy to terminate this agr written notice of termllation to the Architect- ARIVICLE U SCOPE OF ARCHITEC-rtENGINEF-WS BASIC SERVICE 2.1 DEFINYTION 'tl`10 "Jescribed in paragraphs 2.2 through Arch,tect,s, Basic Services consist Of include normal, civil, 2.1-1, identified ills part of,Basic Services,and 2 2,6,and Other services identified ,ld electrical engineering services, structural, rueellanica n shall include, but shall not necessarily be lted to, 2.1.2 The Design fo r Constructio ,Components, ,p -scribe all systems,elements,details he:Design f0t and s Aruction. T plan., ecifleatious which de n necessary for cons materials,equip"Ient,and other information in all respects adequate for COnstruct'011 oordinatedand and Construction shall be accurate,0.oulply,,willl all applicable law,codes,pvrmit-s, and shall.be in confortility, and c specified shall be readily regulations, Products,equipment and rnaterii,11'; ec'fied for use ,rittell.aUth0riZltion to the contrary is given by the Ovvner des,L availab[c unless Y Architect shall be responsible for 'ning the project in accordance w,ith the analyses and reccunmendations of the ileotechn"cal illformation furnished by the owner. preparation and completion of Tbese service-, shall include,but not be lirnited t( 2.1.3 and relationships, schematic design, design the design program for space requirements advertisement ritract doctiments for bids preparation and parat'lon of C( 111,1-nendation Of contract awards, devel()pment, pre review of bids, recO for R�cqucsA Car tabulation and Aration of contract, during design and document prcPar3u", adininis revieperrnrdt cOst estirliating pecti(,gs, tconsultation and on-site ins, prearation and submiltal of documents, actor i,rtvOic Is to tile: County recommend approval of contr entations and presentatiot the i,,, pplications, public pres tipplications, zol icdule in order to be available t0perform is- "inge "is sel nested by ('0LJ'N'l'Y and with the _,iorl. Architect shall art, Comm 'everal pr s Kojects if req fiat one or for s not, exceed the arliction costs will listed service i Q e understa19 that for any individual Pr ct the Coll 1,11nits tinder F,S,287-055(2)(g)- 2.2 SCHEMATIC DESIGN PHASE 'r3t",schedule and construction 2.2.I flic Architect hall review the Cot nty's Prot nts; of tile proiect and shall requiretne budget furnished by the, Owner to ascellaill the ,pith the ownen arrive at a m utual understlit"ding Of such.requirements W, y project 12.2 The Architect shall review with the()wner and MollrOe Crill"t - eand in1provenients,required permits, Nianageti'l,selecti011 0ent Deparlillent's proposed site us r triaterial-41 buildilig systems and equipment; and method of Projec g t zonin dclivery. 3 o 2.2.3 The Architect shall review with the Owner and Monroe County Project Management Department's alternative approaches to design and construction of the Project. 2.2.4 Based on the mutually agreed-upon program, schedule and construction budget requirements,the Architect shall prepare, for approval by the Owner, Schematic Design Documents consisting of drawings and other documents illustrating the scale and relationship of Project components. 2.2,5 Upon completion of the Schematic Design Phase, the Architect shall provide drawings,outline specifications,estimate of anticipated cost in accordance with the schematic designs, and other documents for the Owner's approval and the Monroe County Project Management Department's information. 2.2.6 The Schematic Design must be approved in writing,by the Owner prior to Architect continuing to the Design Development Phase. 2.3 DESIGN DEVELOPMENTIDOCUMENT PHASE 2.3.1 Upon completion of the Design Development Phase, the Architect shall provide drawings,outline specifications and other documents for the Owner's approval and the Monroe County Project Management Department's information. The Architect shall provide an estimate of anticipated costs in accordance with the design development phase. 2.3.2 The Design Development Documents must be approved in writing, by the Owner prior to.A.rchitect continuing to the Construction Documents Phase. 2.4 CONSTRUCTION DOCUMENTS PHASE 2.4.1 Ile Architect shall provide Drawings and Specifications for the Owner's and the Monroe County Project Management Department's review. 2.4.2 The Architect shall assist the Owner and Monroe County Project Management Department in the preparation of the necessary bidding information,bidding forms,the Conditions of Contracts, and the farms of Agreement between the Owner and the Contractors. 2.4.3 The Architect's construction documents plans, specifications,etc.) will conform to all written codes and regulations of the federal government, county,state, municipalities,agencies and state departments, in effect at the date of this Agreement, and shall be of such completion as to receive all permits when applied for. If permits are 4 denied,then the Architect will conform the construction documents in such manner to receive permits upon such plans. Work required from the Architect to conform the documents to federal, state,city, county,or agency specifications and permit requirements to allow them to be approved shall be completed at no charge or cost to the Owner. 2.5 BIDDING OR NEGOTIATION PHASE 2.5.1 The Architect,following the Owner's approval of the Construction Documents and the Architect's latest estimate of Construction Cost,shall assist the Monroe County Project Management Department in obtaining bids or negotiated proposals and assist in preparing con-tracts for construction. 2.5.2 The Architect shall assist the Monroe County Project Management Department in issuing bidding documents to bidders and conducting pre-bid conferences with prospective bidders. The Architect,with the assistance of the Monroe County Project Management Department, shall respond to questions from bidders,and shall issue addenda. 2.6 CONSTRUCTION PHASE-ADMINISTRATION OF THE CONSTRUCTION CONTRACT 2.6.1. The Architect's responsibility to provide Basic Services for the Construction Phase under this Agreement commences with the award of the Contract for construction and terminates with the issuance to the Owner of the final Project Certificate for Payment including the submission of all project close-out documents by the Architect and Contractor. The Architect will adnunister the Owner's contract as provided for in that doctinicaL The Architect agrees to perform a project check prior to the end of the warranty period as a part of the contract. The check shall not exceed one working day unless additional time is approved by the Owner, 2.6.2 1'he Architect shall at all times have access to the Work whenever it is in preparation or progress. 2.6.3 'Me Architect shall, as contemplated herein and in the Construction Contract, but not otherwise,act on behalf, and be the agent,of the Owner throughout construction of the Project. Instructions,directions, and other appropriate communications from the Owner to the Contractor shall be given to the Contractor by the Architect or Monroe County Project Management Department. 2.6.4 The Architect shall have authority, after notification to the Monroe County Project Management Department to reject Work, which does not conform to the Contract Documents. 2.6.5 The Architect shall review and sign or take other appropriate action on Change Orders and Construction Change Directives prepared by the Monroe County Project Management Department for the Owner's approval and execution in accordance with the Contract Documents. 2.6.6 The Architect shall promptly provide appropriate interpretations as necessary for the proper execution of the work as long as there is no change in Contract price. 2.6.7 The Architect shall require inspection or re-inspection and testing or retesting of the work,to include architectural/engineering, structural, mechanical and electrical engineering portions of the work, in accordance with the provisions of the Construction Contract whenever appropriate. 2.6.8 The Architect,assisted by the Monroe County Project Management Department, shall conduct inspections to determine the dates of Substantial Completion and the date of Final Completion. 2.6.9 The Architect shall interpret and decide matters concerning performance of the Contractor under the requirements of the Contract Documents upon written request. 2.6.10 Interpretations and decisions of the Architects shall be consistent with the intent of and reasonably inferable from the Contract Documents and shall be in writing or in the form of drawings and submitted on proper Construction Change Directives. 2.6,11 The Architect shall render written decisions within a reasonable time on all claims,disputes or other matters in question between Owner and Contractors relating to the execution or progress of the Work as provided in the Contract Documents, 2.6.12 Duties, responsibilities and limitations of authority of the Architect shall not be restricted,modified or extended without written agreement of the Owner and Architect. 2.6.13 The Architect shall be a representative of and shall advise and consult with the Owner(1)during construction until final payment to the Contractor is due and(2)as a Basic Service at the Owner's direction from time to time during the correction period described in the Contract for Construction. 2.6.14 The Architect shall transmit to the Owner all manuals, operating instructions, as- built plans,warranties, guarantees and other documents and things required by the Construction Contract and submitted by the Contractor. 2.6.15 The Architect shall not have control over or charge of and shall not be responsible for construction means, methods, techniques,sequences or procedures, or for safety precautions and programs in connection.with the Work,since these are solely the Contractor's responsibility under the Contract for Construction. The Architect shall not be responsible for the Contractor's schedules or failure to carry out the work in accordance with the contract documents. The Architect shall not have control over or charge of acts or omissions of the Contractor, Subcontractors, or their agents or employees,or of any other persons performing portions of the work, 6 2.6.16 The Architect shall make available to the Owner any personnel or consultants employed or retained by the Architect for the purpose of reviewing,studying,analyzing or investigating any claims,contentions,allegations,or legal actions relating to,or arising out of, the design or construction of the project. 2.6.17 The Architect shall review any as-built drawings furnished by the Contractor and shall certify to the Owner that same are adequate and complete. 2,6.18 The Architect shall,without additional compensation,promptly correct any errors, omissions, deficiencies,or conflicts in the work product of the Architect or its consultants, or both, 2.6.19 The Architect must reimburse the Owner for any added costs paid by the Owner during construction that were incurred as the result of any omission,deficiency, or conflict in the work product of the Architect,its consultants,or both, This added expense is defined as the difference in cost from that which the Owner would have paid if the work was included in the bid,and the actual cost presented by the Contractor. ARTICLE III ADDITIONAL SERVICES 3.1 GENERAL 3.1.1 The services described in this Article III are not included in Basic Services. They shall be paid for by the Owner as provided in this agreement as an addition to the compensation paid for the Basic Services but only if approved by the Owner before commencement, and as follows: A. Providing services of Architect for other than the previously listed consulting scope of Project provided as a part of Basic Services. B. Providing any other services not otherwise included in this Agreement of not customarily furnished in accordance with generally accepted consulting practice. C. Providing representation before public bodies in connection with the Project, upon approval by the Owner. 3.2 If Additional Services are required, such as those listed above, the Owner shall issue a letter requesting and describing the requested services to the Architect. The Architect shall respond with fee proposal to perform the requested services. Only after receiving an amendment to the Agreement and a notice to proceed from the Owner proceed with the Additional Services. ARTICLE IV OWNER'S RESPONSIBILITIES 4.1 The Owner shall designate Monroe County Project Management Department to act on the Owner's behalf with respects to the Project. The Owner or Monroe County Project Management Department shall tender decisions in a timely manner pertaining to documents submitted by the Architect in order to avoid unreasonable delay in the orderly and sequential progress of the Architect's services, However,the parties acknowledge that due to Monroe County Policy, Ordinances or State or Federal Statute there may be times when a decision must be made by the BOCC, in which case any delay shall not be attributed to Monroe County or its representative. 4.2 Prompt written notice shall be given by the Owner and Monroe County Project Management Department to the Architect if they become aware of any fault or defect.in the Project or non-conformance with the Contract Documents. 4.3 The Owner shall ftirnish the required information and services and shall render approvals and decisions as expeditiously as necessary for the orderly progress of the Architect's services and work of the contractors. 4.4 The Owner's review of any documents prepared by the Architect or its consultants shall be solely for the purpose of determining whether such documents are generally consistent with the ownees criteria,as and if,modified. No review of such documents shall relieve the Architect of responsibility for the accuracy,adequacy,fitness, suitability or coordination of its work product. ARTICLE V CONSTRUCTION COST 5.1 The Construction Cost, if applicable, shall be defined in a contract for the specific Project. ARTICLE VI INDEMNIFICATION AND HOLD HARMLESS 6.1 The Architect covenants and agrees to indemnify and hold harmless Ow-nerfMouroe County and Monroe County Board of County Commissioners from ally and all claims for bodily injury,including death,personal injury, and property damage, including property owned by Monroe County, and any other losses, damages,and expenses,including attorney's fees,court costs and expenses, which arise out of, in connection with,or by reason of services provided by the Architect or its Subcontractor(s), occasioned by the negligence, errors, or other wrongful act or omission of the Architect,their employees, or agents. 6.2 The first ten dollars($10.00)of remunaration paid to the Architect is for the indemnification provided for above. Should any claims be asserted against the County by virtue of any deficiency or ambiguity in the plans and specifications provided by the Architect,the Architect agrees and warrants that he shall hold the County harmless and shall indemnify him from all losses occurring thereby and shall further defend any claim. or action on the County's behalf. 6.3 In the event the completion of the project(to include the work of others)is delayed or suspended as a result of the Architect's failure to purchase or maintain the required insurance,the Architect shall indeninify County from any and all increased expenses resulting from such delays. Should any claims be asserted against County by virtue of any deficiencies or ambiguity in the plans and specifications provide by the Architect the Architect agrees and warrants that Architect hold the County harmless and shalt indemnify it from all losses occurring thereby and shall further defend any claims or action on the,County's behalf. 6.4 The extent of liability is in no way limited to,reduced or lessened by the insurance requirements contained elsewhere within the Agreement. 6.5 This indemnification shall survive the expiration or early termination of the Agreement. ARTICLE VII 7.1 PERSONNEL The Architect shall assign only qualified personnel to perform any service concerning the ARTICLE VIII 8.1 PAYMENT Terms of payment will be governed by state guidelines mid/or hourly rates to be approved by the County. Hourly rates are provided in Exhibit A and subject to annual affirmation, Details ref payment will be set out in the specific separate contract. 8.2 REIMBURSABLF,EXPENSES Shall be negotiated and agreed to prior to award of the separate contract, but only to the extent and the amounts authorized by Section 112.061, Florida Statutes;however prior to incurring any expense written approval for any reimbursable expense must be obtained from the County. 83 BUDGET 83.1 The Architect may not be entitled to receive, and the County is not obligated to pay, any fees or expenses in excess of the amount budgeted for this Agreement in each fiscal year(October I-September 3 0)by County's Board of County Commissioners, The budgeted amount may only be modified by an affirmative act of the County's Board of County Commissioners. 8.3.2 AVAILABILITY OF FUNDS. If funding cannot be obtained or cannot be continued at a level sufficient to allow for continued reimbursement of expenditures for services specified in this Contract or in the separate;contracts for individual projects, the agreement may be terminated immediately at the option of the County by written notice of termination delivered to the Architect, The County shall not be obligated to pay for any services provided by the Architect after the Architect has received written.notice of termination, unless otherwise required by law. 8.3.3 The County does not guarantee Architect any specific amount of work or contracts under this agreement. The parties shall enter into a separate contract for each project awarded to the Architect by the,County. The specific services to be performed under these separate contracts will be determined by the County.and agreed to by the Architect. Each separate contract will contain specific scope of work,tirueschedule, charges and payment conditions,and additional terms and conditions applicable to that specific contract. Architect will be chosen pursuant to County policy and work will be distributed among all contractors who have signed a continuing contract. 8.3.4 Mon-roe County's performance and obligation to pay under this contract is contingent upon an annual appropriation by the Board of County Commissioners and the approval of the Board members at the time of contract initiation and its duration. ARTICLE IX 9.1 APPLICABLE LAW This contract is governed by and construed in accordance with the laws of the State of Florida applicable to contracts made and performed entirely in the State. Venue for any mediation,dispute conferences or litigation arising under this contract must be in Monroe County, Florida. The Parties waive their rights to a trial by jury. ARTICLE X 10.1 OWNERSHIP OF THE PRELIMINARY DESIGN AND THE DESIGN FOR CONSTRUCTION 10.1 The Drawings, Specifications and other documents prepared by the Architect for this project are instruments of the Architect's service for use solely with respect to this project,and the Architect shalt be deemed the author of these documents and shall retain all common law, statutory and other reserved rights, including reproducible copies, of the Architect's Drawings, Specifications and other documents shall not be used by the Owner or others on other projects except by agreement in writing and with appropriate compensation to the Architect. 10.1.2 Submission or distribution of documents to meet official regulatory requirements or for similar purposes in connection with the project is not to be construed as publication in derogation of the Architect's reserved rights. 10 10.1.3 The As-Built drawings and specifications may be furnished by the Architect to the Owner in electronic format in addition to the original As-Built documents. 10.1.4 The Owner may utilize the construction documents, As-Built documents,etc. as required for reference on any necessary future work on the site,and for constructing, using and maintaining the Project. ARTICLE X1 11.1 SUCCESSORS AND ASSIGNS The Architect shall not assign its right hereunder,excepting its right to payment,nor shall it delegate any of its duties hereunder without the written consent of the Owner. The Owner and Architect, respectively, bind themselves,their partners, successors,assigns and legal representatives to the other party to this Agreement and to the partners, successors, assigns and legal representatives of such other party with respect to all covenants of this Agreement. ARTICLE XII NO THIRD PARTY BENEFICIARIES AND INDEPENDENT CONTRACTOR RELATIONSHIP 12.1 NO THIRD PARTY BENEFICIARIES Nothing contained herein shall create any relationship, contractual or otherwise,between the parties which creates or gives rise to any rights in favor of, any third party. 12.2 INDEPENDENT CONTRACTOR RELATIONSHIP The Architect is and shall be an independent contractor in the performance of all work, services, and activities wider this Agreement and is not an employee,agent or servant of the County.The Architect shall exercise control over the means and manner in which it and its employees perform the work and in all respects the Architect's relationship and the relationship of its employees to the County shall be that of an independent contractor and not as employees or agents of the County. The Architect does not have the power or authority to bind the County in any promise, agreement or representation other than such power and authority that is specifically provided for in this Agreement. ARTICLE XIII 13.1 INSU-RANCE 13.1.1 The Architect shall obtain insurance as specified and maintain the required insurance at all times that this Agreement is in effect, Professional Liability Insurance shall also be maintained as specified. In the event the completion of the project (to include the work.of others) is delayed or suspended as a result of the Architect's failure to 11 purchase or maintain the required insurance, the Architect shall indemnify the County from any and all increased expenses resulting from such delay. 13.1.2 The coverage provided herein shall be provided by an insurer with an A.M. Best Rating of VI or better, that is licensed to do business in the State of Florida and that has an agent for service of process within the State of Florida. The insurance certificate shall contain an endorsement providing thirty (30) days notice to the County prior to any cancellation of said coverage. Said coverage shall be written by an insurer acceptable to the County and shall be in a form acceptable to the County. 13.1.3 Architect shall obtain and maintain the following policies: A. Workers' Compensation insurance as required by the State of Florida. B. Employers Liability Insurance with limits of $100,000.00 per Accident, $5 00,000,00 Disease, policy limits, $100,000.00 Disease each employee. C. Comprehensive business automobile and vehicle liability insurance covering claims for injuries to members of the public and/or damages to property of others arising from use of motor vehicles, including onsite and offsite operations, and owned, hired or non-owned vehicles, with One Hundred Thousand Dollars ($100,000.00) combined single limit and One Million Dollars($1,000,000.00) annual aggregate. D. Commercial general liability covering claims for injuries to members of the public or damage to property of others arising out of any covered act or omission of the Architect or any of its employees, agents or subcontractors or subconsultants, including Premises and/or Operations, Independent Contractors; Broad Form Property Damage and a Contractual Liability Endorsement with One Hundred Thousand Dollars ($100,000-00) per occurrence and annual aggregate. E. Professional liability insurance of Five Hundred Thousand Dollars ($500,000,00) per claim and One Million Dollars ($1,000,000.00) annual aggregate. If the policy is a "claims made" policy, Architect shall maintain coverage or purchase a "tail" to cover claims made after completion of the project to cover the statutory time limits in Chapter 95 of the Florida Statutes. F. County shall be named as an additional insured with respect to Architect's liabilities hereunder in insurance coverage identified in Paragraphs C and D. G. Architect shall require its subconsultants to be adequately insured at least to the limits prescribed above, and to any increased limits of Architect if so required by County during the term of this Agreement. County will not pay for increased limits of insurance for subconsultants. 12 t H. Architect shall provide to the County certificates of insurance or a copy of all insurance policies including those naming the County as an additional insured by including any subsection thereunder. The County reserves the right to require a certified copy of such policies upon request. ARTICLE XIV TERMINATION 14.1 Either party hereto may terminate this contract prior to expiration upon giving seven(7)days written notice to the other in the event that such other party negligently or for any reason substantially fails to perform its material obligations set forth herein. No termination expenses shall be paid by the Owner after the date of notice of termination. 14.2 The Owner may terminate this Contract without cause by giving the other party sixty(60) days written notice of its intention to do so. Termination expenses shall include expenses available under the contract through the date on the notice of termination and shall not include any additional services required in order to stop performance of services,unless agreed to in writing by the County and subject to audit for the purpose of verification. ARTICLE XV ENTIRE AGREEMENT 15.1 This contract constitutes of the form of agreement,the exhibits that are attached and made a part of the contract,and the documents referred to in the form of agreement as a part of this contract. In the event any conflict between any of those contract documents,the one imposing the greater burden on the Architect will control. 15.2 A person or affiliate who has been place on the convicted vendor list following a conviction for public entity crime may not submit a bid on contract to provide any goods or services to a public entity,may not submit a bid on a contract with a public entity for the property to public entity,may not be awarded or perform work as a contractor, supplier, subcontractor, or consultant under a contract with any public entity, and may not transact business with any public entity in excess of the threshold amount provided in Section 287.017 of the Florida Statutes, for CATEGORY TWO for a period of 36 months from the date of being placed on the convicted vendor list. ARTICLE XVI DISPUTE RESOLUTION 16.1 County and Architect agree that all disputes and disagreements shall first be attempted to be resolved by meet and confer sessions between representatives of each of the parties. If no resolution can be agreed upon within 30 days after the first meet and confer session,the issue or issues shall be submitted to mediation before a mediator 13 IP mutually agreed to by the parties.The cost of mediation shall be shared equally.'The parties agree that mediation is a condition precedent to the institution of legal or equitable proceedings by either party. Request for mediation shall be in writing and sent to the other party. The parties shall agree on a mediator to hear the dispute. 16.2 Mediation shall be held in Monroe County Florida in a location in Key West; the location may be moved only by mutual agreement of the parties. 16.3 Agreements reached in mediation shall be reduced to writing and signed by the representative of each party; however agreements must be approved by the Board of County Commissioners to be enforceable.Agreements reached in mediation shall be enforceable as settlement agreements in any cotirt having jurisdiction in Monroe County. 16.4 Nothing in this Agreement shall be construed to interfere with a subsequent order from any court of competent jurisdiction ordering the parties to enter into mediation after institution of legal or equitable proceedings. 16.5 Arbitration is specifically rejected by the parties as a method of settling disputes which arise under this agreement; neither of the parties shalt be compelled by the other to arbitrate a dispute which may arise under this Agreement. ARTICLE XV11 Additional Requirements 17.1 The following items are part of this contract: a)Architect shall maintain all books,records, and documents directly pertinent to performance under this Agreement in accordance with generally accepted accounting principles consistently applied. Each party to this Agreement or their authorized representatives shall have reasonable and timely access to such records of each other party to this Agreement for public records purposes during the term of the Agreement and -nation of this Agreement. If an auditor employed by the for four years following the termination ursuant to this Agreement County or Clerk determines that monies paid to .Architect p Architect shall repay the were spent for purposes not authorized by this Agreement, the c running monies together with c an alculated pursut to F.,9 S. Sec. 55,03, , n ing from the date the monies were paid to County. b) Governing Law, Venue, Interpretation, Costs, and Fees: This Agreerne t shall be governed by and construed in accordance with the taws of the State of Florida applicable to contracts made and to be performed entirely in the State. In the event that any cause of action or administrative proceeding is instituted for the enforcement or interpretation of this Agreement,the County'and Architect agree that venue will lie in the appropriate court or before the appropriate administrative body in Monroe County, Florida. The Parties waive their rights to-a trial by jury. The County and Architect agree that,in the event of conflicting interpretations of the terms or a term of this Agreement by or between any of them the issue shall be submitted to mediation prior to the institution 14 of any other admirdstrative or legal proceeding, pursuant to Section XV[ of this agreement. c) Severability. If any term, covenant, condition or provision of this Agreement (or the application thereof to any circumstance or person) shall be declared invalid or unenforceable to any extent by a court of competent jurisdiction, the retraining terms, covenants, conditions and provisions of this Agreement, shall not be affected thereby; and each remaining term, covenant, condition and provision of this Agreement shall be valid and shall be enforceable to the fullest extent permitted by law unless the enforcement of the retraining terms, covenants, conditions and provisions of this Agreement would prevent the accomplishment of the original intent of this Agreement. "flhe County and Architect agree to reform the Agreement to replace any stricken provision with a valid prevision that comes as close as passible to the intent of the stricken provision. d) Attorney's Fees and Costs. The County and Architect agree that in the event any cause of action or administrative proceeding is initiated or defended by any party relative to the entbreement or interpretation of this Agreement, the prevailing party shall be entitled to reasonable attorney's fees and court costs expenses, as an award against the non-prevailing party, and shall include attorneys fees and courts costs expenses in appellate proceedings. e) Binding Effect. The terms, covenants, conditions, and provisions of this Agreement .shall bind and inure to the bereft of the County and Architect acrid their respective legal representatives, successors, and assigns, f) Authority. Each party represents and warrants to the other that the execution, delivery and performance of this Agreement have been duty authorized by all J necessary County and corporate action, as required by law. Each party agrees that it has had ample opportunity to submit this Contract to legal counsel of its choice and enters into this agreement freely, voluntarily and with advise of counsel. g) Claims for Federal or State Aid. Architect and County agree that each shall be, and is, empowered to apply for, seek., and obtain federal and state funds to further the purpose of this Agreement; provided that all applications, requests, grant proposals, and funding solicitations shall be approved by each party prior to submission. h) Adjudication of Disputes or Disagreements. County and Architect agree that all disputes and disagreements shall be attempted to be resolved under Section XVl of this agreement. if no resolution can be a-greed upon within 30 days after mediation, r then any party shall have the right to seek such relief or remedy as may be provided by this Agreement or by Florida law. i) Cooperation, In the event any administrative or legal proceeding is instituted against either party relating to the formation, execution,performance, or breach of this Agreement, County and Architect agree to participate,to the extent required by the 15 other party, in all proceedings,hearings, processes, meetings, and other activities related to the substance of this Agreement or provision of the services under this Agreement. County and Architect specifically agree that no patty to this Agreement shall be required to enter into any arbitration proceedings related to this Agreement. j) Nondiscrimination. Architect and County agree that there will be no discrimination against any person, and it is expressly understood that upon a determination by a court of competent jurisdiction that discrimination has occurred, this Agreement automatically terminates without any further action on the part of any party, effective the date of the court order. Architect or County agree to comply with all Federal and Florida statutes, and all local ordinances, ass applicable, relating to nondiscrimination. These include but are not limited to: 1) Title VI of the Civil Rights Act of 1964 (PL 88-352) which prohibits discrimination on the basis of race, color or national origin; 2) Title IX of the Education Amendment of 1972, as amended (20 USC ss. 1681-1683, and 1685-1686), which prohibits discrimination on the basis of sex; 3. ) Section 504 of the Rehabilitation Act of 1973, as amended (20 USC s, 794), which prohibits discrimination on the basis of handicaps; 4) The Age Discrimination Pict of 1975, as amended (42 LJSC ss, 6101-6107) which prohibits discrimination on the basis of age; 5) The Drug Abuse Office and Treatment Act of 1972 (PL 92-255), as amended, relating to nondiscrimination on the basis of drug abuse; 6) The Comprehensive Alcohol Abuse and Alcoholism Prevention, Treatment and Rehabilitation Act of 1970 (PL 91- 616), as amended, relating to nondiscrimination on the basis of alcohol abuse or alcoholism; 7) The Public Health Service Act of 1912, ss. 523 and 527 (42 LJSC ss. 690dd-3 and 290ee-3), as amended, relating to confidentiality of alcohol and drug abuse patent records; 8) Title VIII of the Civil Rights Act of 1968 (42 USC s. et seq.), as amended, relating to nondiscrimination in the sale, rental or financing of housing, 9)The Americans with Disabilities Act of 1990 (42 USC s, 1201 Note),as maybe amended from time to time, relating to nondiscrimination on the basis of disability; 10) Any other nondiscrimination provisions in any Federal or state statutes which may apply to the parties to,or the subject matter of, this Agreement. k) Covenant of No hiterest. Architect and County covenant that neither presently has any interest., and shall not acquire any interest, which would conflict in any manner or degree with its performance under this Agreement, and that only interest of each is to perform and receive benefits as recited in this Agreement. 1) Code of Ethics. County agrees that officers and employees of the County recognize and will.be required to comply with the standards of conduct for public officers and employees as delineated in Section 112.313, Florida Statutes, regarding, but not limited to, solicitation or acceptance of gifts; doing business with one's agency; unauthorized compensation; misuse of public position, conflicting employment or contractual relationship;and disclosure or use of certain information. in) No Solicitation/Payment, The Architect and County warrant that, in respect to itself, it has neither employed,nor retained any company or person, other than a bona fide employee working solely for it, to solicit or secure this Agreement and that it 16 P0, has not paid or agreed to pay any person,company, corporation, individual,or firm, other than a bona fide employee working solely for it., any fee,commission, percentage, gift,or other consideration contingent upon or resulting from the award or making of this Agreement. For the breach or violation of the provision, the Architect agrees that the County shall have the right to terminate this Agreement without liability and, at its discretion, to offset from monies owed, or otherwise recover, the full amount of such fee, commission,percentage, gift,or consideration. n) Public Access, The Architect and County shall allow and permit reasonable access to,and inspection of,all documents,papers, letters or other materials in its possession or under its control subject to the provisions of Chapter 119, Florida Statutes, and made or received by the Architect and County in conjunction with this Agreement; and the Architect shall have the right to unilaterally cancel this Agreement upon violation of this provision by County. o) Non-Waiver of Immunity. Notwithstanding he provisions of Sec. 286,28, Florida Statutes, the participation of the Architect and the County in this Agreement and the acquisition of any commercial liability insurance coverage, self-insurance coverage, or local government liability insurance pool coverage shall not be deemed a waiver of immunity to the extent of liability coverage, nor shall any contract entered into by the County be required to contain any provision for waiver. p) Privileges and Immunities. All of the privileges and immunities from, liability, exemptions from laws, ordinances, and rules and pensions and relief, disability, workers' compensation, and other benefits which apply to the activity of officers, agents, or employees of any public agents or employees of the County, when performing their respective functions wider this Agreement within the territorial limits of the County shall apply to the same degree and extent to the performance of such functions and duties of such -1 officers,agents, volunteers, or employees outside the territorial limits of the County. q) Legal Obligations and Responsibilities: Non-Delegation of Constitutional 4 or Statutory Duties. This Agreement is not intended to, nor shall it be construed as, relieving any participating entity from any obligation or responsibility imposed upon the entity by law except to the extent of actual and timely performance thereof by any participating entity, in which case the performance may be offered in satisfaction of the obligation or responsibility- Further, this Agreement is not intended to, nor shall it be construed as, authorizing the delegation of the constitutional or statutory duties of the County, except to the extent permitted by the Florida constitution, state statute, and case law. r) Non-Reliance by Non-Parties. No person or entity shall be entitled to rely upon the terms, or any of them, of this Agreement to enforce or attempt to enforce any third-party claim or entitlement to or benefit of any service or program contemplated hereunder, and the Architect and the Courity agree that neither the Architect nor the County or any agent, officer, or employee of either shall have the authority to inibrin, counsel, or otherwise indicate that any particular individual or group of individuals, entity 17 or entities, have entitlements or benefits under this Agreement separate and apart, inferior to, or superior to the community in general or for the purposes contemplated in this Agreement. s) Attestations. Architect agrees to execute such documents as the County may reasonably require including a Public Entity Crime Statement, an Ethics Statement, and a Drug-Free Workplace Statement. t) No Personal Liability. No covenant or agreement contained herein shall be deemed to be a covenant or agreement of any member, officer, agent or employee of Monroe County in his or her individual capacity, and no member, officer, agent or employee of Monroe County shall be liable personally on this Agreement of be subject to any personal liability or accountability by reason of the execution of this Agreement. u) Americans with Disabilities Act of 1990 (ADA)and Florida Accessibility Code(FAC), current edition,whichever is required for The specific project, The Architect will comply with all the requirement,-,as imposed by the ADA,the regulations of the Federal goverturient issued thereunder, and the assurance by the Architect pursuant thereto. V) Disadvimtaged Business Enterprise (DBE)Policy And Obligation. It is the policy of the County that DBEs, as defined in C.F.R. Part 26, as amended,shall have the opportunity to participate in the performance of contracts financed in whole or in part with County fonds under this Agreement. The DBE requirements of applicable federal and state laws and regulations apply to this Agreement. The County and its Architect agree to ensure that DBE's have the opportunity to participate in the performance of the Agreement. In this regard, all recipients and contractors shall take all necessary and reasonable steps in accordance with applicable federal and state laws and regulations to ensure that.DBEs have the opportunity to compete and perform contracts. The County and the Architect and subcontractors shall not discriminate on the basis of race, color, national origin or sex in the award and performance of contracts,entered pursuant to this Agreement. w) Execution in Counterparts, This Agreement may be executed in any number of counterparts, each of which shal I be regarded as an original, all of which taken together shall constitute one and the same instrument and any of the parties hereto may execute this Agreement by singing any such counterpart, 18 X) Section Headings, Section headings have been inserted in this Agreement as a matter of convenience of reference only, and it is agreed that such section headings are not a part of this Agreement and will not be used in the interpretation of any provision of this Agreement. IN WITNESS WHEREOF, each party caused this Agreement to be executed by its duly authorized representative on the day and year first above written. (SEAT.,) BOARD OF COUNTY COMMISSIONERS Attest: DANNY L. KOLHAGE, Clerk OF MONROE COU FLORIDA By: By ........... Deputy Clerk Mayor/Chairman Date- I— 2��, I c) CURRIE SOWARDS AGUILA ARCHITECTS TLEEN 7'EA7 By: N AwqSiSTANT C�,U oAs6, 4��. ,ui�la,, Alps,Principal Date: WITNESS TO Architect's Signature, Kathleen Davis Date. 09 END OF AGREEMENT 19 SECTION FIVE INSURANCE REQUIREMENTS AND INDEMNIFICATION STATEMENT Insurance Requirement Reguired Limits Worker's Compensation Statutory Limits Employer's Liability $100,0001$500,0001$100,000 General Liability $100,000 Combined Single Limit Vehicle Liability $100,000 Combined Single Limit per Occurrence/$1,000,000 Aggregate Professional Liability $500,000 per occurrence/$t,000,000 Aggregate ilk "S 0 IDENMIFICA11ON! �ANDjjo -,Q D\ f� FO�R C NSULTANTS AND L _I_L SUBCONSULTANTS The Architect/Consultant covenants and agrees to indemnify, hold harmless and defend Monroe County, its commissioners, officers, employees, agents and servants from any and all claims for bodily injury, including death, personal injury, and property damage, including property owned by Monroe County, and any other losses,, damages, and expenses of any kind, including attorney's fees,court costs and expenses,which arise out of, in connection with, or by reason of services provided by the Architect or Consultant or any of its Subcontractor(s) in any tier, occasioned by the negligence, errors, or other wrongful act or omission of the Architect/Consultant, including its Subcontractor(s) in any tier,their officers,employees, servants or agents. In the event that the completion of the project(to include the work of others) is delayed or suspended as a result of the Architect/Consultant's failure to purchase or maintain the required insurance, the Architect/Consultant shall indernrafy the County from any and all increased expenses resulting from such delay. Should any claims be asserted against the COUNTY by virtue of any deficiency or arnbiguity in the plans and specifications provided by the Architect/Consultant,the Architect/Consultant agrees and warrants that Architect/Consultant shall hold the County harmless and shall indemnify it from all losses occurring thereby and shall further defend any claim or action on the County's behalf. The first ten dollars ($10.00) of remuneration paid to the Arehitect/Consultant is consideration for the indemnification provided for above. 20 The extent of liability is in no way limited to, reduced, or lessened by the insurance requirements contained elsewhere within this agreement. This indemnification shall survive the expiration or earlier termination of the Agreement. V RESPONDENT'S STATEMENT I understand the insurance that will be mandatory if awarded the contract and will comply in full with all the requirements Currie Sowarrto A Mils Architects Despondent _ Signature INSURANCE AGENrS STATEMENT l I have reviewed the above requirements with the respondent named above. The following deductibles apply to the corresponding policy. s POLIC DEDUCTIB,LU General Liebli MSA Insuwance Gam n /Po!!r #8PG31784 om n tPalic *BPG31784 �mm Autamobi•Llabi ' tiIISA Insurance C mm Workers Comp-Travelers Casulaty&Surety/Policy iM1JB5436Y34 Professional _.. _.I nsuran y eefftli SOPR9617044 *� V$ 000 Specialty is I 1 Liability policies are^,� Occurrence �_Claims Made P�Wrtt:xo••a(Z !J Suncaast Insurance Aaeociates,Inc.,_ . Signalure��.�_.�� .�.�.�.,.— Insurance Agency i COUNTY RESPONSE FORMS RESPOND TO. MONROE COUNTY BOARD OF COUNTY COMMISSIONERS c/o PURCHASING DEPARTMENT GATO BUILDING, ROOM 1-213 1100 SIMONTON STREET KEY VILEST, FLORIDA 33040 1 acknowledge receipt of Addenda No,(s) _ w& 2 I have included: o The Submission Response Forms ✓ o Lobbying and Conflict of Interest Clause ✓ o The Non-Collusion Affidavit ✓ o Drug Free Workplace Form ✓ o Respondent's Insurance and Indemnification Statement V o Insurance Agent's Statement✓ o Professional and Occupational Licenses ✓ In addition, I have included a current copy of the following professional and occupational licenses; ProfessionalLicenses: Currie Sowards Aguila Architects, Robert G.Currie,,Jess M.Sowards,Josd N.Aguila, Occupational Ucenses: Currie Sowards Agulla Architects, Robert G. Currie,Jess M. Sowards,Josd N.A rulla a.e..� -- ..,1 _ .__ Check mark items above as a reminder that they are included, Mailing Address-, 134 N.E.1stl irenue,Delrayeach,Florida 334" Telephone, .. 561-276-4951 Fax w 561 243-8184- Date: I Signed. Josh N.Aquila,Al 4 (Name) Principal/Secretary �.. (Title) .� i FLORIDA � �41 a ..� STA-M OF DEPARTMENT OF � BUSINESS p Aux m.#w pam�.rLaa cMeL Lek a N„ w,�pY,�^�a 5, r der�wr W'tl�7 �F, 9a,LY e AND PROFESSIONAL REGULATION CMIA LICENSES 00k 019 �,«N, N..., . ,... M ..�� O .... „ .._. WNv �w ct+wpps sM .' onion � J Y VT,AMEW .a i cArnY " Cii.9 C7dEtA8 �' pMpPW,.M-A LNfdKp 0 LAIN 1 1435 a .. aar yr txd 16£ CA�%%E.R�YQ%9Y }} IqC�4NYN,� IYx Ife AK�LY'nX4�U"NIx �� aV.'"�Yb�gdS'n 1N Ml�,y M�4%, i �fi 1 OA n Jr444 n r - unueo. rnarass avpao � s� tom .. 'S,r^iq�rl a u.�m ma s�caeTlkx'x CURRIE • SOWAR.DS • AGUILA ARCnITECTS m, I PALM BEACH COUNTY OCCUPATIONAL LICENSES 20104OW STA T IA a )(01 r 1a $&J*TsarI $•. 1011 .Ab9.CNIE ,. T A0000"Orsow WAMV ANSI fs Ww9ALAA �FA,RwA9Rm9T NI�a� I�wi�� i Ib9n�h,Au?Nkr��a��wm� � i YRN�a A w w Book' lit"0004"Mm", tww TAX CI'aa.LVCrOR„HALM YIEACH COUNTY uY TAX .zLLEis f 2006.OM8 STATE OF FLORIDA pA-oT 6 PALM BEACH COUNTY v;.,4�aNn yrk v HRH LOCAL BUSINESS TAX RECEIPT EXPIRES:SEPTEMBER- 30-2010 CUHRIE SOWARDS AAU1LA LOL.ATED AT CHyY 1L.09 ARCH TCCTN CURRTE RORERT 8 114 N£ IST AVEHOE DELRAV REAAH rL 33444 TOTAL T'1,W9 .. ....,., m+�dArw�k�w.n.rm �lrw+mow yV 7�riww. i THpS IS NOT A DWLL•DO NOT PAY., 3 �nr.rx�xme. If wRCHp TCCT PAID. PI TAk a:`Di.r ECTaR 1 ARpEXpQ 4AM1 ."n..1.4U 014'b44 Op661+75'Y P}Ox 9/a UroN ANNE M.CANNON THIS DOCUMENT IS VALID ONLY WHEN RNCOP160 2005.00687 STATE OF PLORIOA PALM BEACH COUNTY z;Lr,.v^�iet�nanzr LOCAL BUSINESS TAX RECEIPT EXPIRES, SEPTEMBER-30-2010 CUHRIE SWARDS AOU10 LOCATED AT CNTY .is,YOU ARCHITECTS SWARDS JE%$H 134 RE iST AVENUE DEL PAY REACH FL 53444 TOTAL 3;.TO �w.r.nw9 uw wr'wa. +mw + -rM ryd«am.a •.• Vtl^Vo=�IC u40T' 0714�dDC 4Wu','.'bT PAY 9 ApViHM i'TT'.C,T PAID, PRC TAY.COLLECTOR AROOi3Z05 13,OD ATR 040 [ Abi9S9 w71iY/2009 ANNE M.CANNON THIS DOCUMENT IS VAUD ONLY WHEN RECEIPTED TAX COLLECTOR,PALM BEACH COUNTY BY TAX COLLECTOR j ......_..........._......_..._.._.....,....._........w...._..._...�....,,,,,,,,,,,,,,. ..�,,.,...... .......... ........mmw...... 1 i44 2flOB-00683 STATE OF FLORIDA nA n tea PALM BEACH COUNTY LOCAL BUSINESS TAX RECEIPT EXPIRES:SEPTEMBER-30-2010 CUHRIE SOWARDS AGUILA LOCATED AT CHTY 31.DO ARCD11EC15 AGUILA JU5E N 1d4 RE iST AVENUE DELRAY REACH PL 31444 TOTAL AS pD nw,. 0. 1.r bµWAA IN .w .mp.m. w«w wx 6'Ti Is NrIT A gfix-oo moT PAv A.wAwx'u.p an mww wxxm ad Aro�4rAw w.x�4�w+w+aa•;w.�r,.M1n.Y.,a`...,.r�m,�wwe«ro�, ,... _.. .., �„m ... arcccgrmErmry be ARCiH16FCT CAiD, rI TAX f'Oc I.LcTOR 53.v4 ®TN OAN 4166;mos OFfi?i;ODV AR,R0.7.2Oo9 ANNE M.BANNON THIS DOCUMENT IS VALID ONLY WHEN RQCEIPTEO TAX COLLECTOR.PALM BEACH COUNTY BY TAX COLLECTOR CURRIE . SOWARDS • AGUILA - ARCMECTS LOBBYING AND CONFLICT OF INTEREST CLAUSE SWORN STATEMENT UNDER ORDINANCE NO. 010-1990 MONROE COUNTY, FLORIDA ETHICS CLAUSE Currie Sowards A uil a A�chltects (Company) warrants that helit has not employed, retained or otherwise had act on hislits behalf any former County officer or ern loyee in violation of Section 2 of Ordinance No. 010-1990 or an�r County officer or emp oyee in violation of Section 3 of Ordinance No. 010-1990. For l reach or violation of this provision the County may, in its discretion, terminate this Agreement without liabillty and many also, In its discretion,, deduct from,the Agreement or purchase price, or of erwlse recover, the full amount of any fee, commission, percentage, Sift, or consideration paid to the former County officer or employee". _.. ....._ a Principal )Since erel Mµ_�� Date: December 22,2009 STATE OF FLORIDA COUNTY OF PALM BEACH y Subscribed and sworn to(or affirmed) before me on December 22,2009 .�pS6 NSA ulla A1A personally by _�..__�� He Is ersonall known to me. r J My commission expires:: �'t ! t iM ' T114 e to �4b of "rrtewws� DRUG-FREE WORKPLACE FORM The undersigned vendor in accordance with Florida Statute 287.087 hereby certifies that: Currie Sowards Aquila Architects 1. Publish a statement notifying employees that the unlawful manufacture, distribution, dispensing, possession, or use of a controlled substance is prohibited in the workplace and ! specifying the actions that will be taken against employees for violations of such prohibition. 2. Inform employees about the dangers of drug abuse in the workplace, the business's policy of maintaining a drug-free workplace, any available drug counseling, rehabilitation, and employee assistance programs, and the penalties that may be imposed upon employees,for drug abuse violations. 3. Give each employee engaged in providing the commodities or contractual services that are under bid a copy of the statement specified in subsection (1). 1 4. In the statement specified in subsection (1), notify the employees that, as a condition of working on the commodities or contractual services that are under bid, the employee will abide by the terms of the statement and will noti the employer of any conviction of, or plea of guilty or nolo contendere to, any violation of Chapter 893 (Florida Statutes) or of any, controlled substance law of the United States or any state, for a violation occurring in the workplace no later than five (5) days after such conviction. 5. Impose a sanction on, or require the satisfactory participation in a drug abuse assistance or 1 rehabilitation program if such is available in the employee's community, or any employee who is so convicted. 6. Make a good faith effort to continue to maintain a drug-free workplace through implementation of this section. As the person authorized to sign the statement, I certify that this firm complies fully with the above requirements. _._..... ......_... ._.�es a nt's Si.._natur _ �.... � 9 e December 22 2009 Date NON-COLLUSION AFFIDAVIT 1, Jo96 R, Agulla,AlA of the city of Delra Beach,Florida according to law on my oath,., and under penalty of perjury, depose and say that: 1. I am 5ecreta IPrinci p al of the firm of Currie Sowards Aquila Architects the bidder making the Proposal for the project described in the Request for Qualifications for, Continuing Contract for Professional services b ArchitecturalNEn ineerin Firms or lndivlduals and that I executed the said proposal with full authority t do soli 2. the prices in this bid have been arrived at independently without collusion, consultation, communication or agreement for the purpose of restricting competition, as to any matter relating to such prices with any other bidder or with any competitor; 3. unless otherwise required by law, the prices which have been quoted in this bid have not been knowingly disclosed by the bidder and will not knowingly be disclosed by the bidder prior to bid opening, directly or indirectly, to any other bidder or to any competitor: and'. 4. no attempt has been made or will be made b the bidder to induce any other person, partnership or corporation to submit, or not to submit, a bid for the purpose of restricting competition; 5. the statements contained in this affidavit are true and correct, and made with full knowledge that Monroe County relies upon the truth of the statements contained in this affidavit in awarding contracts for said project. ._ December 22, 2009 nazi gjspondent) . ._... .._ _ .. (Date) STATE OF FLORIDA COUNTY OF PALM BEACH � PERSONALLY APPEARED BEFORE ME, the undersigned authority, Josh M.Aquila,AIA who, after first being sworn by me, affixed his/her signature in the space provided above on this 22nd day of. December __.___2009 NOTARY PUBLIC r,t + �0 f; My Commission Expires: r g xs � 's R. EXHIBIT"A" m CURRIE • SOWARDS • AGUII A • ARCHITECT l' fttwA 0.CwMe,NM Jew M. ,ATA J086 M.AgUU AIA Hourly Rues: Ij Principals $ 175.00 Project Architect $150,00 Project Manager $125.00 T CARD Level t 85.00 CARD Level ii $ 65.00 Clerical $ 45.00 I i n i i; labrafin UVg our 4()th Y aSr! Uld' 1001 1341409unt 17tft,4VMW•DOOM 34=k r4Xkts 336"•36 4-2 76 4 01 r*u MI.24S41"