The URL can be used to link to this page

Item C24 BOARD OF COUNTY COMMISSIONERS AGENDA ITEM SUMMARY Meeting Date: December 10, 2014 Division: . . Public Works/Engineering Bulk Item: Yes X No — Department: Project Management Staff Contact Person/Phone#- Kevin Wilson X8797 AGENDA ITEM WORDING: Approval of a Second Amendment to contract with William P. Horn Architect, P.A. for the extension of the continuing contract in order to complete currently active projects. ITEM BACKGROUND: The continuing contract with William P. Horn Architect, P.A. will expire on December 15,2014. There were projects awarded to William P. Horn Architect,P.A. that fall under the conditions of the expiring continuing contract that will still be active after December 15, 2014. This second amendment extends expiration of the continuing contract for only the active projects. The projects that fall under this second amendment are: Senior Center Concrete Spalling Repair; Higgs Beach Fitness Trail; Crawl Key Fire Training Facility, Structural Evaluation of the Sugarloaf Fire Station, and Public Works Building at Rockland Key. PREVIOUS RELEVANT BOCC ACTION: On December 16, 2009 the BOCC approved a continuing contract for projects in which the estimated construction costs of each individual project under the contract does not exceed $2,000,000.00, or for study activity if the fee for professional services for each individual study under the contract does not exceed $200,000.00. On November 20, 2013 the BOCC approved a one-year renewal of the continuing contract effective December 16, 2013 and terminating on December 15,2014. CONTRACT/AGREEMENT CHANGES: Extending the expiration of the continuing contract to effect only the projects listed above. STAFF RECOMMENDATIONS: Approval as stated above. TOTAL COST: N/A INDIRECT COST: N/A BUDGETED: Yes _X_No DIFFERENTIAL OF LOCAL PREFERENCE: COST TO COUNTY: N/A SOURCE OF FUNDS:— N/A REVENUE PRODUCING: Yes_ No_X AMOUNT PER MONTH Year APPROVED BY: County Atty-iL OMB/Purenasing Risk Management DOCUMENTATION: Included - X Not Required DISPOSITION: AGENDA ITEM# Revised 7/09 MONROE COUNTY BOARD OF COUNTY COMMISSIONERS CONTRACT SUIT RY Contract with: Williams P. Horn Contract# Effective Date: December 10,2014 Expiration Date: Contract Purpose/Description: To amend the Continuimp,Contract,which is scheduled to ex ire on December 1 ,2014, to extend the termination d to for the ro'ects that will still be active after the Dgg=b_er 15 2014_date. Contract Manager: Ann Ri er X4439 Pro°ect M mt/Sto #1 (Name) (Ext.) (Department/Stop#) for BOCC meeting on 12/10/14 A-enda Deadline: 11/21/14 CONTRACT COSTS Total Dollar Value of Contract: $ N/A Current Year Portion: $ N/A Budgeted? Yes® No C] Account Codes: Grant: $ N/A County Match: $ ADDITIONAL COSTS Estimated Ongoing Costs: $ /yr For: (Not included in dollar value above Leg.,maintenance,utilities,janitorial,salaries,etc.) CONTRACT REVIEW Changes :DateutDate In Needede Division Director Yes❑No[3 Risk Management Yes Nor �. ti O .B,.tTurch=g 114- - Yes[]No V County Attorney //-��. X/Yes NoAll E]"' ;j, o , Comments: ONM Forth Revised 2/27/01 MAP 72 SECOND AMENDMENT TO EXTEND THE CONTINUING CONTRACT FOR PROFESSIONAL SERVICES IN ORDER TO COMPLETE OUTSTANDING PROJECTS THIS SECOND AMENDMENT made and entered this I 01h day of December,2014, between William P.Horn Architect,P.A., ("Architect"or"Consultant") whose address is 915 Eaton Street,Key West,Florida, and Monroe County ("County"or"Owner"), a political subdivision of the State of Florida whose address is 1100 Simonton Street, Key West, Florida. WITNESSETH WHEREAS, on the 16th day of December 2009, the parties entered into a Continuing Contract for projects in which the estimated construction costs of each individual project under the contract does not exceed Two Million Dollars ($2,000,000.00), or for study activity if the fee for professional services for each individual study under the contract does not exceed Two Hundred Thousand Dollars ($200,000.00); and WHEREAS, on the 20'h day of November 2013,the parties entered into a First Amendment to Contract renewing the Continuing Contract for a one-year period effective December 16, 201,and terminating December 15, 2014; and WHEREAS, the Architect continues to provide professional services projects that fall under the Continuing Contract, which will not be completed at the time of termination and therefore the Continuing contract needs to be continued beyond the termination date of December 15, 2014; and WHEREAS,the Architect and the County desire that these active projects be finalized by the Architect within the guidelines of the Continuing Contract of December 16 1h 2009 and as renewed on November 20th 2013; NOW THEREFORE, in consideration of the mutual promises, covenants, and agreements stated herein, and for other good and valuable consideration, the sufficiency of which is hereby acknowledged,the County and Architect agree as follows: 1. County and Architect agree that the projects listed in paragraph 2 below are in the process of being completed and will still be in process at the termination date of the Renewed Continuing Contract on December 15, 2014. 2. County and Architect agree and acknowledge that the Continuing Contract shall be extended and will serve exclusively for the projects listed below and specifically for the completion of those projects, and will terminate upon completion of those projects: • Senior Center Concrete Spalling Repair—BOCC approved August 15, 2012 and as Amended on April 16, 2014. • Higgs Beach Fitness Trail—BOCC approved May 15, 2013. • Crawl Key Fire Training Facility—BOCC May 21, 2014 Page I of 2 • Structural Evaluation of the Sugarloaf Fire Station—BOCC approved September 17,2014. • Public Works Building at Rockland Key—BOCC approved October 19, 2014 3. County and Architect agree that payment for the completion on the projects listed above shall be paid under the terms of the original Continuing Contract,dated the 16'l'day of December 2009 and as renewed,,and extended under this Amendment without interruption. 4. In all other respects,the original Continuing Contract dated December 16,2009 and as renewed on November 20,2013 shall remain in full force and effect. IN WITNESS WHEREOF,each party caused this Agreement to be executed by its duly authoried representative on the day and year first above written. (SEAL) BOARD OF COUNTY COMMISSIONERS Attest:AMY HEAVILIN,CPA, Clerk OF MONROE COUNTY,FLORIDA y W --Deputy Clerk u By. Mayor/Chairman Witnesses for A hit Engineer. A CHITECT/EN EER � . Witness 1. CHITECT,P.A. D o ur a Print Name:' Q 0 iLLIAM P. AR U Date: 1114 By. w Ir Print Na e: " ¢ Ica Title: z �. o Date: ' STATE OF FLORID COUNTY OF , On this day o 2014, before me, the undersigned notary public, personally appeared kWwfl 191 ie is subscribed he/she is the produced n who execs ed as identification, and acknowledged that !x the above Contract with Monroe County for the purposes therein contained. NO ANY PUBLIC ANN M.HIGEH Notary Pu60c•thou of Florida My Conan.EaPIrM Jul 24,201e My Commission expires: C°""'d'ab"ill EE 21a11� Hatlend Nerar Alga, Page 2 of 2 2014 / 2015 MONROE COUNTY (BUSINESS TAX RECEIPT EXPIRES SEPTEMBER 30, 2015 RECEIPT9 46110-61429 Business Name: WILLIAM P HORN ARCHITECT Owner Name: WILLIAM P HORN Business Location: 915 EATON ST Mailing Address: KEY WEST,FL 33040 915 EATON ST Business Phone: 305-296-8302 KEY WEST, FL 33040 Business Type: PROFESSIONAL(PROFESSIONAL ARCHITECT) 0 STATE LICENSE: AR 0013537 Total Paid„ Prior Years iu Tax Amount Fee 30.00 0.00 30.00 0.00 0.( 0A 30.00 .......... ................ Paid 1015-13-100005D60 09 08/2014 30.00 THIS BECOMES A TAX RECEIPT Daniiise D. Henriquez, CIFC, Tax Collector THIS IS ONLY A TAX, WHEN VALIDATED PO Box 1129, Key West, FL 33041 YOU MUST MEET ALL COUNTY AND/OR MUNICIPALITY PLANNING AND ZONING REQUIREMENTS, MONROE COUNTY BUSINESS TAX RECEIPT P.O. Box 1129, Key West, FL 33041-1129 EXPIRES SEPTEMBER 30, 2015 lBusiness Name: WILLIAM P HORN ARCHITECT RECEIIPIT# 46110-614219 Business Location: giS EATON ST Owner Name: WILLIAM P HORN KEY WEST, FL 33040 Mailing Address: Business Phone: 305-296-8302 915 EATON ST Business Type: PROFESSIONAL(PROFESSIONAL ARCHITECT) KEY WEST, FL 33040 0 STATE LICENSE, AR 0013537 ars�`COIIeC�ii Tax Amount Transfer Fee Penally (Prior '�Wco`st FT01 1 P �0�. .T-E-- 30.00 0.00 30.00 0.00 0.00 0.00 10.00 Paid 105-13-000051060 09/0812014 30.00 41, �NIINVII�VII�VIIIIII� � "� ^^ P, toLO M w IVI 41 O n1 OO 0 m N ✓ ' : W.� GO c 04 0 r a y to H w �IVIIV01�1� V a QJ " rd ,"a 4 p O U Ui2 0 fn Cd O ro I Ulm; v m R m CI a P A 0 o Rq04 >1 P4 d � rd 4 H o ji � 41 x 0 E < o � A 4 c Z W o � a, o o m W i o C p H ul v ri o 0 M W IW � 0 b N S4 Ul M r-1 O 5 ,L7 U] U] [-4 x W rZ 4 r� N N to w Uri 0 w A N �+ H ul -rl PQ UI U 41 FC W r c0 2 O N cd cd -A W UI U U 01 U F+ 4.) 0 Ln 0 0 UI N O U O ,-I W W a a H a a w H `.i C x v � ------ � � � � OP 113.IIIF CERTIFICATE OF LIABILITY INSURANCE D"nt� 123114 THIS CERTIFICATE 1111 ISSUEID AS A MATTER OF INFORMATION ONLY AND CONFERS NO R10HT8 UPON TH!CERTIFICATE HOLDER,THIS CERTIFICATE 'DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTOD OR ALTER THE COVGRAGE AFFORDED BY THE POLICIES snow. T111S CERTIFICATE OF INSURANCE (DOES NOT CONSTRI)T'E A CONTRACT BETWEEN THE ISSUING INSURER(Sh AUTHORMED PtEPREYIENTATIV'E OR PRODUCER,AND THE CERTIFICATE HOLDER. IMPORTANT: It the cortifteft holder In an ADDITIONAL INSURED,the pollay(lee)must be WWOresd. If SURRMATION IS WANED,subPmt'to tfu trams and condlilone of the poilcy.certeln policies mar require an andoreeme aL A elsbrrnl+t on thlE m if aft dace not aonNr rights to the c*rtllicrts holder In lieu of ouch endo a. PROD11 err 305-214-S677 The Fullm.Inc 306.287-4041 1432 Kennedy Drive Key West,FL 33040 HORN - NonTun Fuller APFORnBrO cone Aoa NArC• LNauRM William P Ham Architect PA I Flrrrt Communft IneuraTIGG Co. 13990 Bill Morn wwalnMara; Sig Eaton St, RNKWARC; Key Wask FL 33040 rlwrRerD: ua E. C CERTIFICATE NUMBER., MMSION 'T`HIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOIL THE POLICY PERIOD INDICATED, NOTWITHSTANDING ANY RECIUIREMENT„'TERM DR CONDITION CF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED (HEREIN IS SUBJECT TO ALL THE TERMS. "CLU'SIONS AND CONDITIONS OF SUCH POLICIES.LIMITS SHOD,MAY HAVE BEEN REDUCED BY PAID CLAIMS, AWL Well P%26 TYPE OF WURANCE LlMlre GENERAL LIABILITY EACH OCCURRENCE .000.M. A COMMERCIALWNERALLIAr1ILITY X 900049ST999S10 061211114 QD12i115 EMW 112 2=MMMI II df0, CLANA34WE C OCCUrt " S Bill X IdusInasOwrom PEReONALaADVINJIMY * 1.000.6 p 2,b00�0 GGN®L AOMOATE LIMIT APFLIE$PER: PRODUCT$•CFOMPtOP AGO s 1100010 T POLICY Lac $ AUTOMrigLELIAe1LITY COMBINEVOINOLELIMIT a (EN Dodd"*) MYALITO BODILY INAINY(Per posm i ALL OWNED AUTOS SCWEDULEOAlATB$ IJ� ) BODILYINJURY(PDraNWOMI r HIRED AUTOS NG A� PROPERTY Al MIS B NON-OWNED AIJTDB NAN s F UMM IDAAL OCCUR EACHOCCURNENCEH, r EUCCEer LJAa CLAIM6 A WE AGGREGATE OEOUCTINLE • woRKra1COMPENIIAT10N AND ENPLOY&W UAMM.ITY ANY PRCPRIEICRIPARTNERIFXECUnI E NIA £L,EACH ACGIOR-IT r MPICERA"BEm do In NI j EXGLUDEOT L 41 EL DIBEABE-EAaMPLOYE r, M El-DI -POL Y LIMIT D@i!"a6PTION Or OpIrMTIONa I LOCATIII W I VENKi=IAMseh AOORO iOI.AddIMM IMmeoft rsbduY,N MM§Ws Ir DpuYsd) anahibct CUBT-1501-1 HOLpyR CANCELT MONRCON MOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED"FORE Monme County Board of County ACCORDANNCE wArT►IDTHE POLICY PROVISIONS. OTICE wlu. BE DeLnA ED B+ Comm Neelonehr 1100 Simonton Suet AurNORa7;ED.. 'TRIG IF f Key West,FL 33040 Norman FU'Ils jifs8-200rACORD CORPORATION lgllra'. All r reeanred. ACORD 2S(20M09) The ACORD name and logo are registered mark*of ACORD OF 11J.11F CERTIFICATE OF LIABILITY WSURANCE O1 THIS CERTIFFdCAT F INFOINNIJi-TION ONLY APO CONIFERS NO RIG"T1111U CERTIFICATE DOES NOT NFINIATNIIELY Y AMEND, EXTEND OR ALTM THE COVERAGE AFFORM BY THE POUCNn THIS U T COWITUTE A CONTRACT INETWEEM THE ISSUING ), PWRIESENTATIVE OR PRODUCER,AND THE CERTIFICATE NVORTANT: If holIder III an ACCITIONALIWUPJW,ft palwAim) be encloveaId. It SUSR0dATIONWAI ,�su*d to A par"aws�ofcW In mu of Such Ttw FLdkn,! 308-M44411 1432 Key W"k FL 33040 Norman Fullor cuWg=M#jH0RNW*1 + ISRAW 111 P" A. 4 n" 011 Ham M5 NOUN"D., s #ORTIFICATE M m m THIS IA TO CERTIFY THAT THIS POLICIES OF INSURANCE USTE}BELOW HAVE BEEN I84UEO TO THE INSURED I THE POLICY PERIOD INDICATED. N01"IT"STANOIIM ANY REQUIREMENT,TeRM OR CONDITION Of ANY CONTRACT OR OTHER DOCLNENT IIMVTH RESPECT TO WHIOH THIS CERTIRCATE MAY BE!ISSUED OR MAY PERTAIN, THE INSU RwANOE AFFORDED BY THE P ILV IEI3"DesCRISED HEREIN 18 a1RIRiF- r TO ALL THE TERMS, EXCLU IONB'ANO CONDITIONS OIL SUCH POLICIES.LIMITS SIHOWN VAY HAVE BEEN REDUCED BY PAID CLAIMS. ADM rim 'CIAL OelivnILIASILITY # 1AD9 OCCURit - IEW.W 1T6 # LA To"IMPER t P TW 00601111450 # ANTAUTO DILY NW! I ) # I ALL OWNED AUTOS IDDLY # 8C LED 8 HIMUM AUTOSI N # OCCUR FMHOCCUI excum UASM wDuC70M # A AwipAor��YdM 2041 IMI IA4 ��D�1116 N.L.EWbdH CID' � t,D00, OIMMy wownyhe"") lfCMtYDL5T1� ,Nl1l E.L OISFASE.CAQ p„ O ESEARM rMGiMorapt /Y"tl"Mtl li THE EXPNIAVON DATE UME(WIP ' NUL ME DELINERIND IN M nme County I ACCORDANCE Y Key West,FL 3 FidlerNonnwn 1_ O 'TIR�N�, CS 4 ) T AC and a Id CllentM:1049512 WILLIP4 DATE(M IDDIrCM ACORM CERTIFICATE OF LIABILITY INSURANCE812112014 THIS CERTIFICATE 15 ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER.THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND,EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW.THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE ACONTRACT 13ETWEEN THE ISSUING INSURER(S),AUTHORIZED REPRESENTATIVE OR PRODUCER,AND THE CERTIFICATE HOLDER. IMPORTANT If the certificate holder Is an ADDITIONAL INSURED.the polllcy(les)must be endorsed..If SUBROCA11ON'Ii WAIVED,subject to the terns and conditlons of the policy,certain policies may require an endorsement.A statement on khis certificate does not confer rights to the certificate holder In lieu of such andorsoment(s). PRODUCER garCT USI Insurance Services,LLC ,813 321.7500 N , 1715 N.Westshore Blvd.Suite 700 e I Tampa,FL 33607 INSURER(SI AFFORDING COVERAGE NAIL 0 INeuRERA Liberty Insurance Underwriters 19917 INSURER INSURER B William P.Horn,.Architect,P.A. INSUR 915 Eaton Street ER INSUR Key West,FL 3'3040 R D: INeuRER E INSURE COVERAGES CERTIFICATE NUMBER: REVISION NUMBER. THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED, NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACTOR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE(ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMIT'S SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. AVOL S TYPE OF INSURANCE IN WVD POLICY NUMBER M LIMITS 69KERALLIABILITY EyyACHp ANTEDOCCURRENCE S COMMEACIAL GENERAL:LIABIL'RY OUR S CLJWMS-MADE F]OCCUR MeoEXP(&jEnsEtia n s PERSONAL&ADV INJURY _S OEINERALAGGREGATE' S� GEN'L AGGREGATE LIMITAPPUFSPEM PRODUCTS-COMPIOP AGG E POLICY LOC $ wamw AUTOMOOILELJOILITY H lea d INEeD& ANY AUTO 12- 0 BODILY INJURY(Perperacn) $ ALL OWNED SCHEDULED I:1�A BODILY INJURY(Per accident) $ AUTOS AUTOSVV NON-OWHIRED AUTOS AUTOS PR E III 5 ....._ War s-gsW#aIL— UMBRELLA OCCUR _ EACH OCCURRENCE 'S EXCESS UAL CLAIMS-MADE AGGREGATE .9 DED RETENTION I S WORKERS COMPENSATION VVC STATU- I OTH- AND EMPLOYERS'LIABILITY ANY PRWIETOFVPARTNEWECU71VEVIN E.L.EACH ACCIDENT' OFFICES EMBiER EXCLUDEDT N I A (hhndatary In NH) E,L,DISEASE-EA EMPLOYEE s Iryyaee,describe under _ DESCRIPTION OF OPERATIONS helaw E-L»DISEASE-POUCY LIMIT S A Professional � AEA 015530002 08 1 -LLu8�20/2014 09N20i201. $2,000,000 per claim Liability $i21,000,000 anni aggr. DESCRIPTION OF OPERATIONS r LOCATIONS I VEHICLES(AWrch ACORD 101,Addreanal Remlrke Schedule,If man space to required) Professional Liability coverage Is written on a claims-made basis. Project:Stock Island Fire Station,Bernstein Park,Annual Contract for Architectural Services CERTIFICATE HO DER CANCELLATION Monroe County SHOULD ANY OF THE ABOVE OESCRISED POLICIES RE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILLBE DELIVERED IN Board of County Commissioners ACCORDANCE WITH THE POLICY PROVISIONS. Attn:Risk Management 1100 Simonton Street AUTHORIZED REPRESENTATIVE Key West,FL 33040 01—� 01986-2010 ACORD CORPORATION.All rights reserved. ACORD 25(2010105' 1 of 11 The ACORD name and logo are registered marks of ACORD #S13137849/M13122357 KEBEW OP 10:NF CERTIFICATE OF LIABILITY INSURANCE �' 01126114'"' THIS CERTIFICATE 13 ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO MOHTS UPON THE C PICATEi! MOLDER.THIS CERTWICATE DOES NOT AFFIRMATIVELY OR NEOATPWELY AMEND, EXPEND OR ALTER THE COVERAGE AFFORDED SY THE POLICU M BELOW.: THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETIIYEE N THE ISSUM INSURE141111y, AUTHORIZED REPRESENTATIVE OR PRODUCER',AND THE CERTIFICAIIIE HOLDER. IMPORTANT; I7 the 000 holder Y an ADDITIONAL INSURED,the pollaAlanel mum be andomed. It SUAHROGATION 18 WAIVED,subs d to fhe terms and conditions of the policy,Certain policies may require an entlomenanL A efahmnd an this cartilicab dam not confer rights to f6e Cw4'a htM ^In ltrrU 4� e. rrroauoaw 30d1�2 'i'"�1 The Fullers,Inc 306-2924"1 1432 Kennedy Drive Key~,FL 33040 HCiRNWl1 Norman Fuller WX E 14NNNIaG IIIIIIIIIern Ham NOXMIt A.PMGrMWVG 151 Key Herren Rd. e Key West,FL 33040 e e; P COVERAGO CEIRTIFICATE!LUMBERt, THIS 18 TO CERTIFY THAT THE PaICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE.FOR THE(POLICY PERIOD INDICATED.. NOTWtMSTANDING ANY REQUIREMENT„TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE INLAY BE ISSUED OR MAY PERTAIN,THE.INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBo ECT TO ALL THE TERMS, EXCLUSIONS AND CONDTITONS OF SUCH POLICIES,LIMITS SHOWN MAY HAVE,BEEN!REDUCED BY PAID CLAIMS. IJL TV"OF McUMNOR JIM Ulna GENERAL LWfiJrT EACH OCCUItlIENCE. i COMMi GaNIM t"11 ITN ed _ MAM4INDrt D OCCUR MEDERP ftam I PtEIWMAL A AOV INJURY GENERALAfrGREGATE i.1 GEIN'LOLdCY T" PAS IIUNTAiPPLIEIN PER�OC PROCUCT8-COAAiAM 11 E AUYOAAOo"W! eIi X C BIMEDinGAIELulrr A ANY AUTO 216631ffT OS129Y174 061ZYI1B saauLYmauRYlP.rarwl,I f ALL OV"D AUTOO BODILY INaURY(Par wwldrA11,9 t X SCHfMLEDAUTOS PROPERTY MAIN I III HIREDAUTOB (rwaalaldwd) X I40"WNEDAUTOB iIMMM"UAa OCCUR EACR OCCUMENCE S EXCESSHLIAs CLAINa AAACa Ah l AGGREGATE III 13 OAtN,1A11(;EMEW � 1,11 WORIUM C VV=AT0�47;N C ,,,,. --TA I7 ..... AND IN :ran ANY OFFINIMUMBER P & AECLFTNE Y N f A LL.REACH ACCIDErIT L . r P E.L CIB -PO Y DEeCRIP'TION OF OPeRAMMS I LOCATIONS I VENICLE4~ACM Ift Adaili Mm ulw aahWu*.N men Ww ILA r"N"in 2012 Nle"n Frontier PU 1NBADOEROCC464279 CERTIFICATE CANCELLATION MONRCON SHOULD ANY OP THE AOM DESCRIBED POLICIES BE CANCELUNf BEFORE Monroe COY Board al'Cou THE EXPIRATION DATE THEREOF, NCMCE WILL BE MBLIVIERED IN MY ACCORDANCE'WITH THE POLICY PROVISIONS. CommhlwNonam 1100 Simonton Street AMORMO TrrS Kay Weal FL 33MO Norman Fuller 0 1 e- rRD CORPORATION. All rights nrserwed. ACOR U0eI O 2e(200 The ACORD nano and logo am mgbftmd of A � 1sT AMENDMENT TO CONTRACT FOR PROFESSIONAL SERVICES BETWEEN OWNER AND/%RCHT|ECT/ENG|NEER FOR THE EXTENSION OF THE CONTINUING CONTRACT This First Amendment tn Contract(herein after°Amendrnent") between Owner and Arch ited/Engineer for the Continuing Contract for Professional Services/"Contrmct">' entered into between Monroe County ("Owner"or"County")and William P. Horn Architect, P.A.("Arch ite ct/E ngineer") is made and entered into this 20th day of November,2013, in order to amend the Contract as follows: VV|TNESSETH WHEREAS, on December 16,2009,the parties entered into a continuing contract for Professional Services, pursuant to Florida Statute 287,055(2)(g)where services are to be rendered for projects in which the estimated construction costs of each individual project under the contract does not exceed Two Million Dollars ($2,000,000.00),or for study activity if the fee for Professional Services for each individual study under the contract does not exceed Two Hundred Thousand Dollars($200,000.00);and VVHEREAS, project avvardedtothe Arch�ectby the Owner be provided each with specific scopes of work,time schedules,charges and payment conditions, and additional terms and conditions applicable to that specific contract;and WHEREAS,the parties endeavored |na few projects under this Continuing Contract including but not limited tq the Development of Higgs Beach Park Master Plan;and WHEREAS, in accordance to the Continuing Contract the Professional Services will bc for a period offour years commencing mnthe date ofthe contract, with options for the Owner to renew onen annual basis for two additional one year periods; NOW THEREFORE, in consideration of the mutual promises,covenants and agreements stated herein, and for other good and valuable consideration,the sufficiency of which hereby acknowledged,the Owner and the Architect agree asfollows: 1. The Continuing Contract for Professional Services dated December 16, 2009 and terminating on December 15, 2013, shall be renewed for the first of two one-year periods effective on December 16, 2O13 and terminating December 15, 2D14. 2' The following shall be added to Article XVII of the original Continuing Contract dated December 16, 2009: o) Architect shall not disclose, publish, or authorize others to disclose or publish,design data, � drawings,specifications, reports, or other information pertaining to the services performed � � , ^ ` ` , by the Architect or other information to which the Architect has had access during the Term of this Master Agreement without the prior written approval of the County,during the Term of this Master Agreement and for a period of two(2)years after the termination of this Master Agreement. Nevertheless,the parties agree that the Architect may use and publish the Coumt/sname and give m general description of the work provided by the Architect for the purpose of informing other clients and potential clients of the Architect's work experience and qualifications. b) Should the County receive a request for documents pursuant to Chapter 119, Florida Statutes,Architect shall cooperate with the County to facilitate the County's compliance with Chapter 119, Florida Statutes. Should the Architect assert any exemptions tothe requirements of Chapter 119 and related statutes,the burden of establishing such exemption, by way of injunctive or other relief as provided by law, shall be upon the Architect. Failure by the Architect to cooperate with the County in connection with a Public Records request shall be grounds for immediate unilateral cancellation of this Master Agreement by the County.^ ]. In all other respects,the original Continuing Contract dated December 16, 2009 remains unchanged. WITNESS WHEREOF,each party caused this Agreement tobe executed by its duly authorized 4 IVIppsentafive on the day and year first written above. MY HEAVILN, CPA, Clerk BOARD OF COUNTY COMMISSIONERS OFMONRUE COUNTY, F ` --- my By: ' Deputy Clerk Mayor/Chairman WITNES WSSSignature William P. Horn Architect, P.A. WffNES Air. rtect's :atu r ARCHITE:: � Print Witness Name JE (,00NTY AFTORNEY ell 0 ate CONTRACT FOR PROFESSIONAL SERVICES BETWEEN OWNER AND ARCHITECT/ENGINEER THIS CONTRACT FOR PROFESSIONAL SERVICES BETWEEN OWNER AND ARCHITECT/ENGINEER (the "Contract" or"Agreement") is made and entered into by Monroe County("Owner"or"County"), a political subdivision of the State of Florida, whose address is 1100 Simonton Street, Key West, Florida 33040, its successors and assigns through the Monroe County Board Of County Commissioners ("BOCC"), and William P. Horn,Architect, P.A. , the("Architect")., whose address is 915 Eaton St, Key West, FL 33040, its successors and assigns. This contract shall be effective on the date of execution by the last party signatory to the contract. This contract is issued as a continuing contract pursuant to Florida Statute 287.055(2)(g). The professional services required by this Contract are to be rendered for projects in which the estimated construction costs of each individual project under the contract does not exceed Two Million Dollars ($2,000,000.00), or for study activity if the fee for professional services for each individual study under the contract does not exceed Two Hundred Thousand Dollars($200,000.00). The parties shall enter into a separate contract for each project awarded to the Architect by the Owner. The specific services to be performed under these separate contracts will be determined by the Owner and agreed to by the Architect. Each separate contract will contain specific scope of work,time schedule, charges and payment conditions, and additional terms and conditions applicable to that specific contract. Architect will be chosen pursuant to Owner policy and work will be distributed among all contractors who have signed a continuing contract. The professional services required by this contract will be for services in the form of a continuing contract, commencing on the effective date of this contract and ending four years thereafter, with options for Owner to renew on an annual basis for two additional years. The terms and conditions of this Contract shall apply to any separate contract, unless expressly modified in the provisions of the separate contract. Where the terms of this Contract differ from the terms of the separate contract, the terms of the separate contract shall take precedence. The separate contract will contain its specific scope of work and it is anticipated by this Contract that the scope of work in the separate contract will be in addition to the scope of work outlined in this Contract NOW, THEREFORE, in consideration of the mutual promises, covenants and agreements stated herein, and for other good and valuable consideration, the sufficiency of which hereby acknowledged, the Owner and the Architect agree: t FORM OF AGREEMENT ARTICLE 1 1.1 REPRESENTATIONS AND WARRANTIES By executing this Contract, Architect makes the following express representations and warranties to the Owner: 1.1.1 The Architect is a professional qualified to act as the Architect for the Project and is licensed to practice Architecture/Engineering by all public entities having jurisdiction over the Architect/Engineer and the Project; 1.1.2 The Architect shall maintain all necessary licenses, permits or other authorizations necessary to act as Architect for the Project until the Architect's duties hereunder have been fully satisfied; 1.1.3 The Architect shall become familiar with the individual Project site and the local conditions under which the Project is to be designed, constructed, and operated prior to entering a separate contract for any specific Project. 1.1.4 The Architect shall prepare all documents required by this Contract including, but not limited to, all contract plans and specifications, in such a manner that they shall be in conformity and comply with all applicable law, codes and regulations. The Architect warrants that the documents prepared as a part of this Contract will be adequate and sufficient to accomplish the purposes of the Project, therefore, eliminating any additional construction cost due to missing or incorrect design elements in the contract documents; 1.1.5 The Architect assumes full responsibility to the extent allowed by law with regards to his performance and those directly under his employ as Architect of Record. 1.1.6 The Architect's services shall be performed as expeditiously as is consistent with professional skill and care and the orderly progress of the Work. The Architect shall submit, for the Owner's and Monroe County Project Management Department's information, a schedule for the performance of the Architect's services which may be adjusted as the Project proceeds if approved by the Owner, and shall include allowances for periods of time required for the Owner's and Monroe County Project Management Department's review,and for approval of submission by authorities having jurisdiction over the Project. Time limits established by this schedule and approved by the Owner may not be exceeded by the Architect except for delay caused by events not within the control of the Architect or,foreseeable by him. 1.1.7 In providing all services pursuant to this agreement, the Architect shall abide by all statutes, ordinances, rules and regulations pertaining to, or regulating such services, including those now in effect and hereinafter adopted. Any violation of said statutes, ordinances, rules and regulations shall constitute a material breach of this agreement and 2 shall entitle the COUNTY to terminate this agreement immediately upon delivery of written notice of termination to the Architect. ARTICLE 11 SCOPE OF ARCHITECT/ENGINEER'S BASIC SERVICE 2.1 DEFINITION 2.1.1 Architect's Basic Services consist of those described in Paragraphs 2.2 through 2.8, and other services identified as part of Basic Services, and include normal, civil, structural, mechanical, and electrical engineering services. 2.1.2 The Design for Construction shall include,but shall not necessarily be limited to, plans and specifications which describe all systems, elements, details, components, materials, equipment, and other information necessary for construction. The Design for Construction shall be accurate, coordinated and in all respects adequate for construction and shall be in conformity, and comply, with all applicable law, codes, permits, and regulations. Products, equipment and materials specified for use shall be readily available unless written authorization to the contrary is given by the Owner. The Architect shall be responsible for designing the Project in accordance with the analyses and recommendations of the geotechnical information furnished by the Owner. 2.1.3 These services shall include,but not be limited to, Preparation and completion of the design program for space requirements and relationships, schematic design, design development, preparation of contract documents for bids, preparation and advertisement for Request for Bids, tabulation and review of bids, recommendation of contract awards, cost estimating during design and document preparation, administration of contract documents, consultation and on-site inspections during construction, review and recommend approval of contractor invoices, preparation and submittal of permit applications, zoning applications, public presentations and presentations to the County Commission. Architect shall arrange his schedule in order to be available to perform the listed services for one or for several projects if requested by COUNTY and with the understanding that for any individual project the construction costs will not exceed the limits under F.S. 287.055 (2)(g). 2.2 SCHEMATIC DESIGN PHASE 2.2.1 The Architect shall review the County's program, schedule and construction budget furnished by the Owner to ascertain the requirements of the Project and shall arrive at a mutual understanding of such requirements with the Owner. 2.2.2 The Architect shall review with the Owner and Monroe County Project Management Department's proposed site use and improvements, required permits, zoning, selection of materials,building systems and equipment; and method of Project delivery. 3 2.2.3 The Architect shall review with the Owner and Monroe County Project Management Department's alternative approaches to design and construction of the Project. 2.2.4 Based on the mutually agreed-upon program, schedule and construction budget requirements, the Architect shall prepare, for approval by the Owner, Schematic Design Documents consisting of drawings and other documents illustrating the scale and relationship of Project components. 2.2.5 Upon completion of the Schematic Design Phase, the Architect shall provide drawings, outline specifications, estimate of anticipated cost in accordance with the schematic designs,and other documents for the Owner's approval and the Monroe County Project Management Department's information. 2.2.6 The Schematic Design must be approved in writing,by the Owner prior to Architect continuing to the Design Development Phase. 2.3 DESIGN DEVELOPMENT/DOCUMENT PHASE 2.3.1 Upon completion of the Design Development Phase, the Architect shall provide drawings, outline specifications and other documents for the Owner's approval and the Monroe County Project Management Department's information. The Architect shall provide an estimate of anticipated costs in accordance with the design development phase. 2.3.2 The Design Development Documents must be approved in writing,by the Owner prior to Architect continuing to the Construction Documents Phase. 2.4 CONSTRUCTION DOCUMENTS PHASE 2.4.1 The Architect shall provide Drawings and Specifications for the Owner's and the Monroe County Project Management Department's review. 2.4.2 The Architect shall assist the Owner and Monroe County Project Management Department in the preparation of the necessary bidding information, bidding forms, the Conditions of Contracts, and the forms of Agreement between the Owner and the Contractors. 2.4.3 The Architect's construction documents (plans, specifications, etc.)will conform to all written codes and regulations of the federal government, county, state, municipalities, agencies and state departments, in effect at the date of this Agreement, and shall be of such completion as to receive all permits when applied for. If permits are 4 denied, then the Architect will conform the construction documents in such manner to receive permits upon such plans. Work required from the Architect to conform the documents to federal, state, city, county, or agency specifications and permit requirements to allow them to be approved shall be completed at no charge or cost to the Owner. 2.5 BIDDING OR NEGOTIATION PHASE 2.5.1 The Architect, following the Owner's approval of the Construction Documents and the Architect's latest estimate of Construction Cost, shall assist the Monroe County Project Management Department in obtaining bids or negotiated proposals and assist in preparing contracts for construction. 2.5.2 The Architect shall assist the Monroe County Project Management Department in issuing bidding documents to bidders and conducting pre-bid conferences with prospective bidders. The Architect, with the assistance of the Monroe County Project Management Department, shall respond to questions from bidders, and shall issue addenda. 2.6 CONSTRUCTION PHASE -ADMINISTRATION OF THE CONSTRUCTION CONTRACT 2.6.1. The Architect's responsibility to provide Basic Services for the Construction Phase under this Agreement commences with the award of the Contract for construction and terminates with the issuance to the Owner of the final Project Certificate for Payment including the submission of all project close-out documents by the Architect and Contractor. The Architect will administer the Owner's contract as provided for in that document. The Architect agrees to perform a project check prior to the end of the warranty period as a part of the contract. The check shall not exceed one working day unless additional time is approved by the Owner. 2.6.2 The Architect shall at all times have access to the Work whenever it is in preparation or progress. 2.6.3 The Architect shall, as contemplated herein and in the Construction Contract, but not otherwise, act on behalf, and be the agent,of the Owner throughout construction of the Project. Instructions, directions, and other appropriate communications from the Owner to the Contractor shall be given to the Contractor by the Architect or Monroe County Project Management Department. 2.6.4 The Architect shall have authority, after notification to the Monroe County Project Management Department to reject Work, which does not conform to the Contract Documents. 2.6.5 The Architect shall review and sign or take other appropriate action on Change Orders and Construction Change Directives prepared by the Monroe County Project 5 Management Department for the Owner's approval and execution in accordance with the Contract Documents. 2.6.6 The Architect shall promptly provide appropriate interpretations as necessary for the proper execution of the work as long as there is no change in Contract price. 2.6.7 The Architect shall require inspection or re-inspection and testing or retesting of the work, to include architectural/engineering, structural, mechanical and electrical engineering portions of the work, in accordance with the provisions of the Construction Contract whenever appropriate. 2.6.8 The Architect, assisted by the Monroe County Project Management Department, shall conduct inspections to determine the dates of Substantial Completion and the date of Final Completion. 2.6.9 The Architect shall interpret and decide matters concerning performance of the Contractor under the requirements of the Contract Documents upon written request. 2.6.10 Interpretations and decisions of the Architects shall be consistent with the intent of and reasonably inferable from the Contract Documents and shall be in writing or in the form of drawings and submitted on proper Construction Change Directives. 2.6.11 The Architect shall render written decisions within a reasonable time on all claims, disputes or other matters in question between Owner and Contractors relating to the execution or progress of the Work as provided in the Contract Documents. 2.6.12 Duties, responsibilities and limitations of authority of the Architect shall not be restricted, modified or extended without written agreement of the Owner and Architect. 2.6.13 The Architect shall be a representative of and shall advise and consult with the Owner(1)during construction until final payment to the Contractor is due and(2)as a Basic Service at the Owner's direction from time to time during the correction period described in the Contract for Construction. 2.6.14 The Architect shall transmit to the Owner all manuals, operating instructions, as- built plans, warranties, guarantees and other documents and things required by the Construction Contract and submitted by the Contractor. 2.6.15 The Architect shall not have control over or charge of and shall not be responsible for construction means, methods, techniques, sequences or procedures,or for safety precautions and programs in connection with the Work, since these are solely the Contractor's responsibility under the Contract for Construction. The Architect shall not be responsible for the Contractor's schedules or failure to carry out the work in accordance with the contract documents. The Architect shall not have control over or charge of acts or omissions of the Contractor, Subcontractors, or their agents or employees,or of any other persons performing portions of the work. 6 2.6.16 The Architect shall make available to the Owner any personnel or consultants employed or retained by the Architect for the purpose of reviewing, studying, analyzing or investigating any claims, contentions, allegations, or legal actions relating to, or arising out of, the design or construction of the project. 2.6.17 The Architect shall review any as-built drawings furnished by the Contractor and shall certify to the Owner that same are adequate and complete. 2.6.18 The Architect shall,without additional compensation, promptly correct any errors, omissions, deficiencies, or conflicts in the work product of the Architect or its consultants, or both. 2.6.19 The Architect must reimburse the Owner for any added costs paid by the Owner during construction that were incurred as the result of any omission,deficiency, or conflict in the work product of the Architect, its consultants,or both. This added expense is defined as the difference in cost from that which the Owner would have paid if the work was included in the bid,and the actual cost presented by the Contractor. ARTICLE Ill ADDITIONAL SERVICES 3.1 GENERAL 3.1.1 The services described in this Article Ill are not included in Basic Services. They shall be paid for by the Owner as provided in this agreement as an addition to the compensation paid for the Basic Services but only if approved by the Owner before commencement, and as follows: A. Providing services of Architect for other than the previously listed consulting scope of Project provided as a part of Basic Services. B. Providing any other services not otherwise included in this Agreement or not customarily furnished in accordance with generally accepted consulting practice. C. Providing representation before public bodies in connection with the Project, upon approval by the Owner. 3.2 If Additional Services are required,such as those listed above, the Owner shall issue a letter requesting and describing the requested services to the Architect. The Architect shall respond with fee proposal to perform the requested services. Only after receiving an amendment to the Agreement and a notice to proceed from the Owner proceed with the Additional Services. 7 ARTICLE IV OWNER'S RESPONSIBILITIES 4.1 The Owner shall designate Monroe County Project Management Department to act on the Owner's behalf with respects to the Project. The Owner or Monroe County Project Management Department shall render decisions in a timely manner pertaining to documents submitted by the Architect in order to avoid unreasonable delay in the orderly and sequential progress of the Architect's services. However, the parties acknowledge that due to Monroe County Policy, Ordinances or State or Federal 'Statute there may be times when a decision must be made by the BOCC, in which case any delay shall not be attributed to Monroe County or its representative. 4.2 Prompt written notice shall be given by the Owner and Monroe County Project Management Department to the Architect if they become aware of any fault or defect in the Project or non-conformance with the Contract Documents. 4.3 The Owner shall furnish the required information and services and shall render approvals and decisions as expeditiously as necessary for the orderly progress of the Architect's services and work of the contractors. 4.4 The Owner's review of any documents prepared by the Architect or its consultants shall be solely for the purpose of determining whether such documents are generally consistent with the Owner's criteria,as and if, modified. No review of such documents shall relieve the Architect of responsibility for the accuracy, adequacy, fitness, suitability or coordination of its work product. ARTICLE V CONSTRUCTION COST 5.1 The Construction Cost, if applicable, shall be defined in a contract for the specific Project. ARTICLE VI INDEMNIFICATION AND HOLD HARMLESS 6.1 The Architect covenants and agrees to indemnify and hold harmless Owner/Monroe County and Monroe County Board of County Commissioners from any and all claims for bodily injury, including death, personal injury, and property damage, including property owned by Monroe County, and any other losses,damages, and expenses, including attorney's fees, court costs and expenses, which arise out of, in connection with, or by reason of services provided by the Architect or its Subcontractor(s), occasioned by the negligence, errors, or other wrongful act or omission of the Architect, their employees,or agents. 6.2 The first ten dollars ($10.00)of remuneration paid to the Architect is for the indemnification provided for above. Should any claims be asserted against the County by g virtue of any deficiency or ambiguity in the plans and specifications provided by the Architect, the Architect agrees and warrants that he shall hold the County harmless and shall indemnify him from all losses occurring thereby and shall further defend any claim or action on the County's behalf 6.3 In the event the completion of the project(to include the work of others) is delayed or suspended as a result of the Architect's failure to purchase or maintain the required insurance, the Architect shall indemnify County from any and all increased expenses resulting from such delays. Should any claims be asserted against County by virtue of any deficiencies or ambiguity in the plans and specifications provide by the Architect the Architect agrees and warrants that Architect hold the County harmless and shall indemnify it from all losses occurring thereby and shall further defend any claims or action on the County's behalf. 6.4 The extent of liability is in no way limited to, reduced or lessened by the insurance requirements contained elsewhere within the Agreement. 6.5 This indemnification shall survive the expiration or early termination of the Agreement. ARTICLE VII 7.1 PERSONNEL The Architect shall assign only qualified personnel to perform any service concerning the project. ARTICLE VIII 8.1 PAYMENT Terms of payment will be governed by state guidelines and/or hourly rates to be approved by the County. Hourly rates are provided in Exhibit A and are subject to annual affirmation. Details of payment will be set out in the specific separate contract. 8.2 REIMBURSABLE EXPENSES Shall be negotiated and agreed to prior to award of the separate contract,but only to the extent and the amounts authorized by Section 112.061, Florida Statutes; however prior to incurring any expense written approval for any reimbursable expense must be obtained from the County. 8.3 BUDGET 8.3.1 The Architect may not be entitled to receive, and the County is not obligated to pay, any fees or expenses in excess of the amount budgeted for this Agreement in each fiscal year(October 1- September 30)by County's Board of County Commissioners. The budgeted amount may only be modified by an affirmative act of the County's Board of County Commissioners. 9 8.3.2 AVAILABILITY OF FUNDS. If funding cannot be obtained or cannot be continued at a level sufficient to allow for continued reimbursement of expenditures for services specified in this Contract or in the separate contracts for individual projects, the agreement may be terminated immediately at the option of the County by written notice of termination delivered to the Architect. The County shall not be obligated to pay for any services provided by the Architect after the Architect has received written notice of termination,unless otherwise required by law. 8.3.3 The County does not guarantee Architect any specific amount of work or contracts under this agreement. The parties shall enter into a separate contract for each project awarded to the Architect by the County. The specific services to be performed under these separate contracts will be determined by the County and agreed to by the Architect. Each separate contract will contain specific scope of work, time schedule, charges and payment conditions, and additional terms and conditions applicable to that specific contract.Architect will be chosen pursuant to County policy and work will be distributed among all contractors who have signed a continuing contract. 8.3.4 Monroe County's performance and obligation to pay under this contract is contingent upon an annual appropriation by the Board of County Commissioners and the approval of the Board members at the time of contract initiation and its duration. ARTICLE IX 9.1 APPLICABLE LAW This contract is governed by and construed in accordance with the laws of the State of Florida applicable to contracts made and performed entirely in the State. Venue for any mediation, dispute conferences or litigation arising under this contract must be in Monroe County, Florida. The Parties waive their rights to a trial by jury. ARTICLE X 10.1 OWNERSHIP OF THE PRELIMINARY DESIGN AND THE DESIGN FOR CONSTRUCTION 10.1 The Drawings, Specifications and other documents prepared by the Architect for this project are instruments of the Architect's service for use solely with respect to this project, and the Architect shall be deemed the author of these documents and shall retain all common law, statutory and other reserved rights, including reproducible copies, of the Architect's Drawings, Specifications and other documents shall not be used by the Owner or others on other projects except by agreement in writing and with appropriate compensation to the Architect. 10.1.2 Submission or distribution of documents to meet official regulatory requirements or for similar purposes in connection with the project is not to be construed as publication in derogation of the Architect's reserved rights. 10 10.1.3 The As-Built drawings and specifications may be furnished by the Architect to the Owner in electronic format in addition to the original As-Built documents. 10.1.4 The Owner may utilize the construction documents,As-Built documents, etc. as required for reference on any necessary future work on the site, and for constructing, using and maintaining the Project. ARTICLE X1 11.1 SUCCESSORS AND ASSIGNS The Architect shall not assign its right hereunder, excepting its right to payment, nor shall it delegate any of its duties hereunder without the written consent of the Owner. The Owner and Architect, respectively,bind themselves, their partners, successors, assigns and legal representatives to the other party to this Agreement and to the partners, successors, assigns and legal representatives of such other party with respect to all covenants of this Agreement. I ARTICLE XII NO THIRD PARTY BENEFICIARIES AND INDEPENDENT CONTRACTOR RELATIONSHIP 12.1 NO THIRD PARTY BENEFICIARIES Nothing contained herein shall create any relationship, contractual or otherwise,between the parties which creates or gives rise to any rights in favor of, any third party. 12.2 INDEPENDENT CONTRACTOR RELATIONSHIP The Architect is and shall be an independent contractor in the performance of all work, services, and activities under this Agreement and is not an employee, agent or servant of the County. The Architect shall exercise control over the means and manner in which it and its employees perform the work and in all respects the Architect's relationship and the relationship of its employees to the County shall be that of an independent contractor and not as employees or agents of the County. The Architect does not have the power or authority to bind the County in any promise, agreement or representation other than such power and authority that is specifically provided for in this Agreement. ARTICLE XIII 13.1 INSURANCE 13.1.1 The Architect shall obtain insurance as specified and maintain the required insurance at all times that this Agreement is in effect, Professional Liability Insurance shall also be maintained as specified. In the event the completion of the project (to include the work of others) is delayed or suspended as a result of the Architect's failure to I I purchase or maintain the required insurance, the Architect shall indemnify the County from any and all increased expenses resulting from such delay. 13.1.2 The coverage provided herein shall be provided by an insurer with an A.M. Best Rating of VI or better, that is licensed to do business in the State of Florida and that has an agent for service of process within the State of Florida. The insurance certificate shall contain an endorsement providing thirty (30) days notice to the County prior to any cancellation of said coverage. Said coverage shall be written by an insurer acceptable to the County and shall be in a form acceptable to the County. 13.1.3 Architect shall obtain and maintain the following policies: A. Workers' Compensation insurance as required by the State of Florida. B. Employers Liability Insurance with limits of V 00,000 per Accident, $500,000 Disease, policy limits, $100,000 Disease each employee. C. Comprehensive business automobile and vehicle liability insurance covering claims for injuries to members of the public and/or damages to property of others arising from use of motor vehicles, including onsite and offsite operations, and owned, hired or non-owned vehicles, with One Hundred Thousand Dollars ($100,000.00) combined single limit and One Hundred Thousand Dollars($100,000.00)annual aggregate, D. Commercial general liability covering claims for injuries to members of the public or damage to property of others arising out of any covered act or omission of the Architect or any of its employees, agents or subcontractors or subconsultants, including Premises and/or Operations, Independent Contractors; Broad Form Property Damage and a Contractual Liability Endorsement with Five Hundred Thousand Dollars ($500,000.00) per occurrence and annual aggregate. E. Professional liability insurance of Five Hundred Thousand Dollars ($500,000.00) per claim and One Million Dollars ($1,000,000.00) annual aggregate. If the policy is a "claims made" policy, Architect shall maintain coverage or purchase a "tail" to cover claims made after completion of the project to cover the statutory time limits in Chapter 95 of the Florida Statutes. F. County shall be named as an additional insured with respect to Architect's liabilities hereunder in insurance coverage identified in Paragraphs C and D. G. Architect shall require its subconsultants to be adequately insured at least to the limits prescribed above, and to any increased limits of Architect if so required by County during the term of this Agreement. County will not pay for increased limits of insurance for subconsultants. 12 H. Architect shall provide to the County certificates of insurance or a copy of all insurance policies including those naming the County as an additional insured by including any subsection thereunder. The County reserves the right to require a certified copy of such policies upon request. ARTICLE XIV TERMINATION 14.1 Either party hereto may terminate this contract prior to expiration upon giving seven(7)days written notice to the other in the event that such other party negligently or for any reason substantially fails to perform its material obligations set forth herein. No termination expenses shall be paid by the Owner after the date of notice of termination. 14.2 The Owner may terminate this Contract without cause by giving the other party sixty(60)days written notice of its intention to do so. Termination expenses shall include expenses available under the contract through the date on the notice of termination and shall not include any additional services required in order to stop performance of services,unless agreed to in writing by the County and subject to audit for the purpose of verification. ARTICLE XV ENTIRE AGREEMENT 15.1 This contract constitutes of the form of agreement, the exhibits that are attached and made a part of the contract, and the documents referred to in the form of agreement as a part of this contract. In the event any conflict between any of those contract documents, the one imposing the greater burden on the Architect will control. 15.2 A person or affiliate who has been place on the convicted vendor list following a conviction for public entity crime may not submit a bid on contract to provide any goods or services to a public entity,may not submit a bid on a contract with a public entity for the property to public entity, may not be awarded or perform work as a contractor, supplier, subcontractor,or consultant under a contract with any public entity, and may not transact business with any public entity in excess of the threshold amount provided in Section 287.017 of the Florida Statutes, for CATEGORY TWO for a period of 36 months from the date of being placed on the convicted vendor list, ARTICLE XVI DISPUTE RESOLUTION 16.1 County and Architect agree that all disputes and disagreements shall first be attempted to be resolved by meet and confer sessions between representatives of each of the parties. ff no resolution can be agreed upon within 30 days after the first meet and confer session, the issue or issues shall be submitted to mediation before a mediator 13 mutually agreed to by the parties. The cost of mediation shall be shared equally. The parties agree that mediation is a condition precedent to the institution of legal or equitable proceedings by either party. Request for mediation shall be in writing and sent to the other party. The parties shall agree on a mediator to hear the dispute. 16.2 Mediation shall be held in Monroe County Florida in a location in Key West; the location may be moved only by mutual agreement of the parties. 16.3 Agreements reached in mediation shall be reduced to writing and signed by the representative of each party; however agreements must be approved by the Board of County Commissioners to be enforceable. Agreements reached in mediation shall be enforceable as settlement agreements in any court having jurisdiction in Monroe County. 16.4 Nothing in this Agreement shall be construed to interfere with a subsequent order from any court of competent jurisdiction ordering the parties to enter into mediation after institution of legal or equitable proceedings. 16.5 Arbitration is,specifically rejected by the parties as a method of settling disputes which arise under this agreement; neither of the parties shall be compelled by the other to arbitrate a dispute which may arise under this Agreement. ARTICLE XV11 Additional Requirements 17.1 The following items are part of this contract: a) Architect shall maintain all books, records, and documents directly pertinent to performance under this Agreement in accordance with generally accepted accounting principles consistently applied. Each party to this Agreement or their authorized representatives shall have reasonable and timely access to such records of each other party to this Agreement for public records purposes during the term of the Agreement and for four years following the termination of this Agreement. If an auditor employed by the County or Clerk determines that monies paid to Architect pursuant to this Agreement were spent for purposes not authorized by this Agreement, the Architect shall repay the monies together with interest calculated pursuant to F.S. Sec. 55.03, running from the date the monies were paid to County. b) Governing Law, Venue, Interpretation, Costs, and Fees: This Agreement shall be governed by and construed in accordance with the laws of the State of Florida applicable to contracts made and to be performed entirely in the State. In the event that any cause of action or administrative proceeding is instituted for the enforcement or interpretation of this Agreement, the County and Architect agree that venue will lie in the appropriate court or before the appropriate administrative body in Monroe County, Florida. The Parties waive their rights to a trial by jury. The County and Architect agree that, in the event of conflicting interpretations of the terms or a term of this Agreement by or between any of them the issue shall be submitted to mediation prior to the institution 14 of any other administrative or legal proceeding, pursuant to Section XVI of this agreement. C) Severability. If any term, covenant, condition or provision of this Agreement (or the application thereof to any circumstance or person) shall be declared invalid or unenforceable to any extent by a court of competent jurisdiction, the remaining terms, covenants, conditions and provisions of this Agreement, shall not be affected thereby; and each remaining term, covenant, condition and provision of this Agreement shall be valid and shall be enforceable to the fullest extent permitted by law unless the enforcement of the remaining terms, covenants, conditions and provisions of this Agreement would prevent the accomplishment of the original intent of this Agreement. The County and Architect agree to reform the Agreement to replace any stricken provision with a valid provision that comes as close as possible to the intent of the stricken provision. d) Attorney's Fees and Costs. The County and Architect agree that in the event any cause of action or administrative proceeding is initiated or defended by any party relative to the enforcement or interpretation of this Agreement, the prevailing party shall be entitled to reasonable attorney's fees and court costs expenses, as an award against the non-prevailing party, and shall include attorney's fees and courts costs expenses in appellate proceedings. e) Binding Effect, The terms, covenants, conditions, and provisions of this Agreement shall bind and inure to the benefit of the County and Architect and their respective legal representatives, successors, and assigns. f) Authority. Each party represents and warrants to the other that the execution, delivery and performance of this Agreement have been duly authorized by all necessary County and corporate action, as required by law. Each party agrees that it has had ample opportunity to submit this Contract to legal counsel of its choice and enters into this agreement freely, voluntarily and with advise of counsel. g) Claims for Federal or State Aid. Architect and County agree that each shall be, and is, empowered to apply for, seek, and obtain federal and state funds to further the purpose of this Agreement; provided that all applications, requests, grant proposals, and funding solicitations shall be approved by each party prior to submission. h) Adjudication of Disputes or Disagreements. County and Architect agree that all disputes and disagreements shall be attempted to be resolved under Section XVI of this agreement. If no resolution can be agreed upon within 30 days after mediation, then any party shall have the right to seek such relief or remedy as may be provided by this Agreement or by Florida law. i) Cooperation. In the event any administrative or legal proceeding is instituted against either party relating to the formation, execution, performance, or breach of this Agreement, County and Architect agree to participate, to the extent required by the 15 other party, in all proceedings, hearings, processes, meetings, and other activities related to the substance of this Agreement or provision of the services under this Agreement. County and Architect specifically agree that no party to this Agreement shall be required to enter into any arbitration proceedings related to this Agreement. j) Nondiscrimination. Architect and County agree that there will be no discrimination against any person, and it is expressly understood that upon a determination by a court of competent jurisdiction that discrimination has occurred, this Agreement automatically terminates without any further action on the part of any party, effective the date of the court order. Architect or County agree to comply with all Federal and Florida statutes, and all local ordinances, as applicable, relating to nondiscrimination. These include but are not limited to: 1) Title VI of the Civil Rights Act of 1964 (PL 88-352) which prohibits discrimination on the basis of race, color or national origin; 2) Title IX of the Education Amendment of 1972, as amended (20 USC ss. 1681-1683, and 1685-1686), which prohibits discrimination on the basis of sex; 3) Section 504 of the Rehabilitation Act of 1973, as amended (20 USC s. 794), which prohibits discrimination on the basis of handicaps; 4) The Age Discrimination Act of 1975, as amended (42 USC ss. 6101-6107) which prohibits discrimination on the basis of age; 5) The Drug Abuse Office and Treatment Act of 1972 (PL 92-255), as amended, relating to nondiscrimination on the basis of drug abuse; 6) The Comprehensive Alcohol Abuse and Alcoholism Prevention, Treatment and Rehabilitation Act of 1970 (PL 91- 616), as amended, relating to nondiscrimination on the basis of alcohol abuse or alcoholism; 7) The Public Health Service Act of 1912, ss. 523 and 527 (42 USC ss. 690dd-3 and 290ee-3), as amended, relating to confidentiality of alcohol and drug abuse patent records; 8) Title VIII of the Civil Rights Act of 1968 (42 USC s. et seq.), as amended, relating to nondiscrimination in the sale, rental or financing of housing; 9) The Americans with Disabilities Act of 1990(42 USC s. 1201 Note), as maybe amended from time to time, relating to nondiscrimination on the basis of disability; 10) Any other nondiscrimination provisions in any Federal or state statutes which may apply to the parties to, or the subject matter of, this Agreement. k) Covenant of No Interest. Architect and County covenant that neither presently has any interest, and shall not acquire any interest, which would conflict in any manner or degree with its performance under this Agreement, and that only interest of each is to perform and receive benefits as recited in this Agreement. 1) Code of Ethics. County agrees that officers and employees of the County recognize and will be required to comply with the standards of conduct for public officers and employees as delineated in Section 112.313, Florida Statutes, regarding, but not limited to, solicitation or acceptance of gifts; doing business with one's agency; unauthorized compensation; misuse of public position, conflicting employment or contractual relationship; and disclosure or use of certain information. m) No -Solicitation/Payment. The Architect and County warrant that, in respect to itself, it has neither employed nor retained any company or person, other than a bona fide employee working solely for it, to solicit or secure this Agreement and that it 16 has not paid or agreed to pay any person, company, corporation, individual, or firm, other than a bona fide employee working solely for it, any fee, commission, percentage, gift, or other consideration contingent upon or resulting from the award or making of this Agreement. For the breach or violation of the provision, the Architect agrees that the County shall have the right to terminate this Agreement without liability and, at its discretion, to offset from monies owed, or otherwise recover, the fall amount of such fee, commission,percentage, gift,or consideration. n) Public Access. The Architect and County shall allow and permit reasonable access to,and inspection of, all documents,papers, letters or other materials in its possession or under its control subject to the provisions of Chapter 119, Florida Statutes, and made or received by the Architect and County in conjunction with this Agreement; and the Architect shall have the right to unilaterally cancel this Agreement upon violation of this provision by County. 0) Non-Waiver of Immunity. Notwithstanding he provisions of See. 286.28, Florida Statutes, the participation of the Architect and the County in this Agreement and the acquisition of any commercial liability insurance coverage, self-insurance coverage, or local government liability insurance pool coverage shall not be deemed a waiver of immunity to the extent of liability coverage, nor shall any contract entered into by the County be required to contain any provision for waiver. P) Privileges and Immunities. All of the privileges and immunities from liability, exemptions from laws, ordinances, and rules and pensions and relief, disability, workers' compensation, and other benefits which apply to the activity of officers, agents, or employees of any public agents or employees of the County, when performing their respective functions under this Agreement within the territorial limits of the County shall apply to the same degree and extent to the performance of such functions and duties of such officers,agents, volunteers, or employees outside the territorial limits of the County. q) Legal Obligations and Responsibilities: Non-Delegation of Constitutional or Statutory Duties. This Agreement is not intended to, nor shall it be construed as, relieving any participating entity from any obligation or responsibility imposed upon the entity by law except to the extent of actual and timely performance thereof by any participating entity, in which case the performance may be offered in satisfaction of the obligation or responsibility. Further, this Agreement is not intended to, nor shall it be construed as, authorizing the delegation of the constitutional or statutory duties of the County, except to the extent permitted by the Florida constitution, state statute, and case law. r) Non-Reliance by Non-Parties. No person or entity shall be entitled to rely upon the terms, or any of them, of this Agreement to enforce or attempt to enforce any third-party claim or entitlement to or benefit of any service or program contemplated hereunder, and the Architect and the County agree that neither the Architect nor the County or any agent, officer, or employee of either shall have the authority to inform, counsel,or otherwise indicate that any particular individual or group of individuals, entity 17 or entities, have entitlements or benefits under this Agreement separate and apart, inferior to, or superior to the community in general or for the purposes contemplated in this Agreement. S) Attestations. Architect agrees to execute such documents as the County may reasonably require including a Public Entity Crime Statement, an Ethics Statement, and a Drug-Free Workplace Statement. t) No Personal Liability. No covenant or agreement contained herein shall be deemed to be a covenant or agreement of any member, officer, agent or employee of Monroe County in his or her individual capacity, and no member, officer, agent or employee of Monroe County shall be liable personally on this Agreement or be subject to any personal liability or accountability by reason of the execution of this Agreement. U) Americans with Disabilities Act of 1990(ADA). The Architect will comply with all the requirements as imposed by the ADA, the regulations of the Federal government issued thereunder, and the assurance by the Architect pursuant thereto. V) Disadvantaged Business Enterprise(DBE) Policy And Obligation. It is the policy of the County that DBE's, as defined in C.F.R. Part 26, as amended, shall have the opportunity to participate in the performance of contracts financed in whole or in part with County funds under this Agreement.The DBE requirements of applicable federal and state laws and regulations apply to this Agreement. The County and its Architect agree to ensure that DBE's have the opportunity to participate in the performance of the Agreement. In this regard, all recipients and contractors shall take all necessary and reasonable steps in accordance with applicable federal and state laws and regulations to ensure that DBE's have the opportunity to compete and perform contracts. The County and the Architect and subcontractors shall not discriminate on the basis of race, color, national origin or sex in the award and performance of contracts,entered pursuant to this Agreement. w) Execution in Counterparts. This Agreement may be executed in any number of counterparts, each of which shall be regarded as an original, all of which taken together shall constitute one and the same instrument and any of the parties hereto may execute this Agreement by singing any such counterpart. 18 N x) Section Headings. Section headings have been inserted in this Agreement as a matter of convenience of reference only, and it is agreed that such section headings are not a part of this Agreement and will not be used in the interpretation of any provision of this Agreement. IN WITNESS WHEREOF, each party caused this Agreement to be executed by its duly authorized representative on the day and year first above written. (SEAL) BOARD OF COUNTY COMMISSIONERS Attest: DANNY L. KOLHAGE, Clerk OF MONROE COUNTY, FLORIDA, B By: Deputy Clerk Mayor/C airman Date: DEC 1 6 2009 n Ef �l (INSERT NA of Architect) By. .. .~ " d Sign re of Corporate Agent �- IQ M Pw D Print Name of 'orp rate Agent Date: CD C CD > v r— WITNESS TO Architect's ature: sr a WITNESS Si at re V, �44, z rn " c *c7 C-) " 6 Fn ca Print Witness Name =, w Date: au _.. END OF AGREEMENT 19 SECTION FIVE INSURANCE REQUIREMENTS AND INDEMNIFICATION STATEMENT Insurance Requirement Required Limits Worker's Compensation Statutory Limits Employer's Liability $100,0001$500,0001$100,000 General Liability $100,000 Combined Single Limit Vehicle Liability $100,000 Combined Single Limit per Occuffencel$1,000,000 Aggregate Architects Errors and Omissions Liability $500,000 per occurrence/$1,000,000 Aggregate IDEMNIFICATION AND HOLD HARMLESS FOR CONSULTANTS AND SUBCONSULTANTS The Architect/Consultant covenants and agrees to indemnify, hold harmless and defend Monroe County, its commissioners, officers, employees, agents and servants from any and all claims for bodily injury, including death, personal injury, and property damage, including property owned by Monroe County, and any other losses, damages, and expenses of any kind, including attorney's fees, court costs and expenses, which arise out of, in connection with, or by reason of services provided by the Architect or Consultant or any of its Subcontractor(s) in any tier, occasioned by the negligence, errors, or other wrongful act or omission of the Architect/Consultant, including its Subcontractor(s) in any tier, their officers, employees,servants or agents. In the event that the completion of the project(to include the work of others) is delayed or suspended as a result of the Architect/Consultant's failure to purchase or maintain the required insurance, the Architect/Consultant shall indemnify the County from any and all increased expenses resulting from such delay. Should any claims be asserted against the COUNTY by virtue of any deficiency or ambiguity in the plans and specifications provided by the Architect/Consultant, the Architect/Consultant agrees and warrants that Architect/Consultant shall hold the County harmless and shall indemnify it from all losses occurring thereby and shall further defend any claim or action on the County's behalf. The first ten dollars ($10.00) of remuneration paid to the Architect/Consultant is consideration for the indemnification provided for above. 20 The extent of liability is in no way limited to, reduced, or lessened by the insurance requirements contained elsewhere within this agreement. This indemnification shall survive the expiration or earlier termination of the Agreement. RESPONDENT'S STATEMENT I understand the insurance that will be mandatory if awarded t contract and will comply in full with all the requirements. w>G40 M Respondent Sig a oars 21 INSURANCE AGENT'S STATEMENT I have reviewed the above requirements with the Architect named below. The following deductibles apply to the corresponding policy. POLICY DEDUCTIBLES Ve �afe- 1640114--1-, d Liability policies are ✓Occurrence Claims Made — "A Insurance Agency Signature Print Name: The Fullers Iris, 432 Kenn0dy Dr. Key WOO, FL 330 22 SECTION SIX COUNTY RESPONSE FORMS RESPOND TO: MONROE COUNTY BOARD OF COUNTY COMMISSIONERS c/o PURCHASING DEPARTMENT GATO BUILDING, ROOM 1-213 1100 SIMONTON STREET KEY WEST, FLORIDA 33040 I acknowledge receipt of Addenda No.(s) I have included: o The Response Form u� Q Lobbying and Conflict of Intexest Clause/ o Non-Collusion Affidavit V o Drug Free Workplace Form a Respondent's Insurance and Ind(Trification Statement o Insurance Agent's Statement / o Professional and Occupational Licenses I have included a current copy of the following professional and occupational licenses: (Check mark items above, as a reminder that they are included.) Mailing Address: Telephoner "' Fay: —A 3 Date: Signed: lVitnew (Seal) L NAY PUBLI -srP:r i l (Name) ,•.,��,�. David W.Gangwlsch " -C,Ommis'ion 322a3 owlw �braes, d ,2010 Expires, C BONDING C"U,2'IN » $oN� n��su (Title) 23 LOBBYING AND CONFLICT OF INTEREST CLAUSE SWORN STATEMENT UNDER ORDINANCE NO.010-1990 MONROE COUNTY, FLORIDA ETHICS CLAUSE (Company) "... warrants that he/it has not employed, retained or otherwise had act on his/its behalf any former County officer or employee in violation of Section 2 of Ordinance No. 010-1990 or any County officer or employee in violation of Section 3 of Ordinance No. 010-1990. For breach or violation of this provision the County ay; in its discretion, terminate this Agreement without liability and may also, in its di retion,deduct from the Agreement or purchase price, or otherwise recover, the ull amount of any fee, commission, percentage, gift, or consideration paid to t former County officer or employee". (Signa Bate: /),// STATE OF: 1C COUNTY OF: /-e-e+ Subscribed and sworn to (or affirmed)before me on.. c! c -------- (date)by C,t,1ZIa drn (name ofaffiant). He/She is personally known to me or has produced � ~ as identification. (type of identification) N°OTA PUBLI My commissio�� " 24 DRUG-FREE WORKPLACE FORM The undersigned vendor in accordance with Florida Statute 287.087 hereby certifies that: �V/ � ^ (Name of Business) 1. Publish a statement notifying employees that the unlawful manufacture, distribution, dispensing, possession, or use of a controlled substance is prohibited in the workplace and specifying the actions that will be taken against employees for violations of such prohibition. 2. Inform employees about the dangers of drug abuse in the workplace, the business's policy of maintaining a drug-free workplace, any available drug counseling, rehabilitation, and employee assistance programs, and the penalties that may be imposed upon employees for drug abuse violations. 3. Give each employee engaged in providing the commodities or contractual services that are under bid a copy of the statement specified in subsection(1). 4. In the statement specified in subsection (1), notify the employees that, as a condition of working on the commodities or contractual services that are under bid, the employee will abide by the terms of the statement and will notify the employer of any conviction of, or plea of guilty or nolo contenders to, any violation of Chapter 893 (Florida Statutes) or of any controlled substance law of the United States or any state, for a violation occurring in the workplace no later than five (5)days after such conviction. 5. Impose a sanction on, or require the satisfactory participation in a drug abuse assistance or rehabilitation program if such is available in the employee's community, or any employee who is so convicted. 6. Make a good faith effort to continue to maintain a drug-free workplace through implementation of this section. As the person authorized to sign a statement, I certify that this firm complies fully with the above requirements. I�espondernt's Signature 1111710 ate 25 NON-COLLUSION AFFIDAVIT 1, of the city of kie 666t �• according to law on my oath, and under penalty of perjury,depose and say that: 1. I am l N of the firm of We o &O-b AAabzZRA - the bidder making the Proposal for the project described in the Request for Qualifications for: V 1 l 1. eS and that I executed the said proposal with full authority to do so: 2. the prices in this bid have been arrived at independently without collusion, consultation, communication or agreement for the purpose of restricting competition, as to any matter relating to such prices with any other bidder or with any competitor; 3. unless otherwise required by law, the prices which have been quoted in this bid have not been knowingly disclosed by the bidder and will not knowingly be disclosed by the bidder prior to bid opening, directly or indirectly, to any other bidder or to any competitor; and 4. no attempt has been made or will be made by the bidder to induce any other person, partnership or corpor tion to submit, or not to submit, a bid for the purpose of restricting compion; 5. the statements contained ur this alffidavit are true and correct, and made with full knowledge that Monioe County relies upon the truth of the statements contained in this affidavit in awarding contracts for said project. (Signature of Respondent) *( a STATE OF: COUNTY OF: ✓�'rO�= PERSONALLY APPEARED BEFORE ME, the undersigned authority, 4Z,754 i, r, m/ e 4 ,l who, after first being sworn by me, (name of individual signing) affixed his/her signature in the space provided above on this . f4`t ay of 20 Of OTAR " PU Ll t -STATE ch My Commission EQ,� #art 2 3 commissiolft C1 8, 00 pt%G C'o.,INC„ t4DED 26 1DEMNIFICATION AND HOLD HARMLESS FOR CONSULTANTS AND SUBCONSULTANTS The Architect/Consultant covenants and agrees to indemnify, hold harmless and defend Monroe County, its commissioners, officers, employees, agents and servants from any and all claims for bodily injury, including death, personal injury, and property damage, including property owned by Monroe County, and any other losses, damages, and expenses of any kind, including attorney's fees, court costs and expenses, which arise out of, in connection with, or by reason of services provided by the Architect or Consultant or any of its Subcontractor(s) in any tier, occasioned by the negligence, errors, or other wrongful act or omission of the Architect/Consultant, including its Subcontractor(s) in any tier, their officers, employees, servants or agents. In the event that the completion of the project(to include the work of others)is delayed or suspended as a result of the Architect/Consultant's failure to purchase or maintain the required insurance, the Architect/Consultant shall indemnify the County from any and all increased expenses resulting from such delay. Should any claims be asserted against the COUNTY by virtue of any deficiency or ambiguity in the plans and specifications provided by the Architect/Consultant, the Architect/Consultant agrees and warrants that Architect/Consultant shall hold the County harmless and shall indemnify it from all losses occurring thereby and shall further defend any claim or action on the County's behalf. The first ten dollars ($10.00) of remuneration paid to the Architect/Consultant is consideration for the indemnification provided for above. The extent of liability is in no way limited to, reduced, or lessened by the insurance requirements contained elsewhere within this agreement. This indemnification shall survive the expiration or earlier termination of the Agreement. RESPONDENT'S STATEMENT I understand the insurance that will be mandatory if awarded the contract and will comply in full with all the requirements. Ah r AN Respondent Signature 27 EXHIBIT A Hourly Rates Monroe CC-inty � C �TV 2609 dME: _.�. WILLIAM P. HORN ARCHITECT,PARECEIVED BY:. AA 0003040 915 EATON STREET,KEY WEST,FLORIDA 33040 PHONE:305-296-8302 FAX:305-296-1033 Date: 11/20/09 To: Jerry Barnett Facilities Development Coordinator Monroe County Re: Hourly Rates Annual Contract Dear Mr. Barnett, Our standard hourly rates are as follows: Principal Architect $195.00/hr Architect $130.00/hr Intern Architect $100.00/hr Draftsperson $85.00/hr Structural Engineer $150,00/hr MEP Engineer $125.00/hr Principal Civil Engineer$150.00/hr Senior Civil Engineer $120.00/hr Civil Engineer $100.00/hr Please call if you have any questions. We are looking forward to working with you. Sincerely WILLI P. HORN ARCHITECT,P.A. William P.Horn, Principal