Loading...
12/28/2020 Agreement FWC Agreement No. 20192 STATE OF FLORIDA FLORIDA FISH AND WILDLIFE CONSERVATION COMMISSION AGREEMENT No.20192 CFDA Title(s): Bipartisan Budget Act of 2018 CFDA No(s).: 11.022 Name of Federal Agency(s): NOAA Federal Award No(s): 19NOS0220007 Federal Award Year(s): 19 Federal Award Name(s): Post Hurricane Irma Marine Debris Removal and Mapping in Florida CSFA Title(s).: Derelict Vessel Removal Grant CSFA No(s).: 77.005 State Award No(s).: 20192 State Award Year(s): 2019-2020 State Award Name(s): Monroe County(Irma Grant) Derelict Vessel Removal Project This Agreement is entered into by and between the Florida Fish and Wildlife Conservation Commission, whose address is 620 South Meridian Street, Tallahassee, Florida 32399-1600, hereafter "Commission," and Monroe County BOCC, FEID 4 59-6000749, whose address is 2798 Overseas Highway, Suite 420, Marathon, Florida 33050,hereinafter"Grantee." WHEREAS,the Commission and Grantee have partnered together to remove derelict vessels from the waters of the state; and, WHEREAS, Grantee has been awarded Bulk Derelict Vessel Removal Grant 20192; and, WHEREAS,such benefits are for the ultimate good of the State of Florida,its resources,wildlife,and public welfare. NOW THEREFORE, the Commission and the Grantee, for the considerations hereafter set forth, agree as follows: 1. PROJECT DESCRIPTION. The Grantee shall provide the services and perform the specific responsibilities and obligations,as set forth in the Scope of Work, attached hereto as Attachment A and made a part hereof(hereafter, Scope of Work). The Scope of Work specifically identifies project tasks and accompanying deliverables. These deliverables must be submitted and approved by the Commission prior to any payment. The Commission will not accept any deliverable that does not comply with the specified required minimum level of service to be performed and the criteria for evaluating the successful completion of each deliverable. If this agreement is the result of Grantee responses to the Commission's request for competitive or other grant proposals, the Grantee's response is hereby incorporated by reference. GRANT- GOVERNMENTAL ENTITY Ver. January, 2018 Page 1 of 20 FWC Agreement No. 20192 2. PERFORMANCE. The Grantee shall perform the activities described in the Scope of Work in a proper and satisfactory manner. Unless otherwise provided for in the Scope of Work,any and all equipment,products or materials necessary or appropriate to perform under this Agreement shall be supplied by the Grantee. Grantee shall obtain all necessary local, state, and federal authorizations necessary to complete this project, and the Grantee shall be licensed as necessary to perform under this Agreement as may be required by law, rule, or regulation; the Grantee shall provide evidence of such compliance to the Commission upon request. The Grantee shall procure all supplies and pay all charges,fees,taxes and incidentals that may be required for the completion of this Agreement. By acceptance of this Agreement, the Grantee warrants that it has the capability in all respects to fully perform the requirements and the integrity and reliability that will assure good-faith performance as a responsible Grantee. Grantee shall immediately notify the Commission's Grant Manager in writing if its ability to perform under the Agreement is compromised in any manner during the term of the Agreement. The Commission shall take appropriate action, including potential termination of this Agreement pursuant to Paragraph nine (9) below, in the event the Grantee's ability to perform under this Agreement becomes compromised. 3. AGREEMENT PERIOD. A. Agreement Period and Commission's Limited Obligation to Pay. This Agreement is made pursuant to a grant award and shall be effective upon execution by the last Parry to sign, and shall remain in effect through 05/07/2021. However,as authorized by Rule 68-1.003,F.A.C.,referenced grant programs may execute Agreements with a retroactive start date of no more than sixty (60) days,provided that approval is granted from the Executive Director or his/her designee and that it is in the best interest of the Commission and State to do so. For this agreement,the retroactive start date was not approved. The Commission's Grant Manager shall confirm the specific start date of the Agreement by written notice to the Grantee. The Grantee shall not be eligible for reimbursement or compensation for grant activities performed prior to the start date of this Agreement nor after the end date of the Agreement. For this agreement, preaward costs are not eligible for reimbursement. If necessary,by mutual agreement as evidenced in writing and lawfully executed by the Parties, an Amendment to this Agreement may be executed to lengthen the Agreement period. 4. COMPENSATION AND PAYMENTS. A. Compensation. As consideration for the services rendered by the Grantee under the terms of this Agreement,the Commission shall pay the Grantee on a cost reimbursement basis in an amount not to exceed$83,980.00. B. Payments. The Commission shall pay the Grantee for satisfactory performance of the tasks identified in Attachment A, Scope of Work, as evidenced by the completed deliverables, upon submission of invoices, accompanied by supporting documentation sufficient to justify invoiced expenses or fees,and after acceptance of services and deliverables in writing by the Commission's Grant Manager identified in Paragraph ten(10),below. Unless otherwise specified in the Scope of Work,invoices shall be due monthly, commencing from the start date of this Agreement. Invoices must be legible and must clearly reflect the Deliverables that were provided in accordance with the terms of the Agreement for the invoice period. Unless otherwise specified in the Scope of Work, a final invoice shall be submitted to the Commission no later than forty-five (45) days following the expiration date of this Agreement to assure the availability of funds for payment. Further, pursuant to Section 215.971(l)(d), F.S., the Commission may only reimburse the Grantee for allowable costs resulting from obligations incurred during the agreement period specified in Paragraph three (3). GRANT- GOVERNMENTAL ENTITY Ver. January, 2018 Page 2 of 20 FWC Agreement No. 20192 C. Invoices. Each invoice shall include the Commission Agreement Number and the Grantee's Federal Employer Identification (FEID) Number. Invoices, with supporting documentation, may be submitted electronically to the attention of the Commission's Grant Manager identified in Paragraph ten(10),below. If submitting hard copies, an original and two(2)copies of the invoice, plus all supporting documentation, shall be submitted. All bills for amounts due under this Agreement shall be submitted in detail sufficient for a proper pre-audit and post-audit thereof. Grantee acknowledges that the Commission's Grant Manager shall reject invoices lacking documentation necessary to justify invoiced expenses. D. Match. Pursuant to grant program guidelines,the Grantee is not required to contribute non-federal match towards this Agreement. If applicable, details regarding specific match requirements are included in Attachment A, Scope of Work. E. Travel Expenses. If authorized in Attachment A, Scope of Work, travel expenses shall be reimbursed in accordance with Section 112.061, F.S. F. State Obligation to Pay. The State of Florida's performance and obligation to pay under this Agreement is contingent upon an annual appropriation and authorization to spend by the Legislature. The Parties hereto understand that this Agreement is not a commitment to future appropriations, but is subject to appropriation and authority to spend provided by the Legislature. The Commission shall be the final authority as to the availability of funds for this Agreement, and as to what constitutes an"annual appropriation"of funds to complete this Agreement. If such funds are not appropriated or available for the Agreement purpose,such event will not constitute a default on behalf of the Commission or the State. The Commission's Grant Manager shall notify the Grantee in writing at the earliest possible time if funds are not appropriated or available. G. Non-Competitive Procurement and Rate of Payment. Section 216.3475, F.S., requires that under non-competitive procurements, a Grantee may not receive a rate of payment in excess of the competitive prevailing rate for those services unless expressly authorized in the General Appropriations Act. If applicable, Grantee warrants, by execution of this Agreement, that the amount of non-competitive compensation provided in this Agreement is in compliance with Section 216.3475, F.S. H. Time Limits for Payment of Invoices. Payments shall be made in accordance with Sections 215.422 and 287.0585, F.S., which govern time limits for payment of invoices. Section 215.422, F.S.provides that agencies have five (5)working days to inspect and approve Deliverables,unless the Scope of Work specifies otherwise. If payment is not available within forty(40)days,measured from the latter of the date the invoice is received or the Deliverables are received, inspected and approved, a separate interest penalty set by the Department of Financial Services pursuant to Section 55.03(l),F.S.,will be due and payable in addition to the invoice amount. Invoices returned to a Grantee due to preparation errors will result in a payment delay. Invoice payment requirements do not start until a properly completed invoice is provided to the agency. I. Electronic Funds Transfer. Grantee agrees to enroll in Electronic Funds Transfer(EFT), offered by the State's Chief Financial Officer, within thirty (30) days of the date the last Party has signed this Agreement. Copies of the Authorization form and a sample blank enrollment letter can be found on the vendor instruction page at: htip://www.fldfs.com/aadir/direct_deposit_web/Vendors.htm GRANT- GOVERNMENTAL ENTITY Ver. January, 2018 Page 3 of 20 FWC Agreement No. 20192 Questions should be directed to the State of Florida's EFT Section at (850) 413-5517. Once enrolled,invoice payments will be made by EFT. J. Vendor Ombudsman. A Vendor Ombudsman, whose duties include acting as an advocate for vendors who may be experiencing problems in obtaining timely payment(s) from a State agency, may be contacted at(850)413-5516 or by calling the Chief Financial Officer's Hotline, (800) 342- 2762. 5. RETURN OR RECOUPMENT OF FUNDS. A. Overpayment to Grantee. Pursuant to Section 215.971(l)(e)&(f), F.S., the Grantee shall return to the Commission any overpayments due to unearned funds or funds disallowed pursuant to the terms of this Agreement that were disbursed to Grantee by the Commission. In the event the Grantee or its independent auditor discovers that overpayment has been made, the Grantee shall repay said overpayment within forty (40) calendar days without prior notification from the Commission. In the event the Commission first discovers an overpayment has been made, the Commission will notify the Grantee in writing. Should repayment not be made in a timely manner, the Commission shall be entitled to charge interest at the lawful rate of interest established pursuant to Section 55.03(l), F.S., on the outstanding balance beginning forty (40) calendar days after the date of notification or discovery. Refunds should be sent to the Commission's Grant Manager,and made payable to the "The Florida Fish and Wildlife Conservation Commission." B. Additional Costs or Monetary Loss Resulting from Grantee Non-Compliance. If the Grantee's non-compliance with any provision of the Agreement results in additional cost or monetary loss to the Commission or the State of Florida to the extent allowed by Florida Law, the Commission can recoup that cost or loss from monies owed to the Grantee under this Agreement or any other agreement between Grantee and the Commission. In the event the discovery of this cost or loss arises when no monies are available under this Agreement or any other agreement between the Grantee and the Commission, the Grantee will repay such cost or loss in full to the Commission within thirty(30) days of the date of notice of the amount owed,unless the Commission agrees,in writing, to an alternative timeframe. If the Grantee is unable to repay any cost or loss to the Commission, the Commission shall notify the State of Florida, Department of Financial Services, for resolution pursuant to Section 17.0415, F.S. 6. COMMISSION EXEMPT FROM TAXES,PROPERTY EXEMPT FROM LIEN. A. Commission Exempt from Taxes. The Grantee recognizes that the State of Florida, by virtue of its sovereignty,is not required to pay any taxes on the services or goods purchased under the terms of this Agreement. Grantee is placed on notice that this exemption generally does not apply to nongovernmental entity recipients, subrecipients, contractors, or subcontractors. Any questions regarding this tax exemption should be addressed to the Commission Grant Manager. B. Property Exempt from Lien. If the Grant involves the improvement of real property titled to the State of Florida, then the following paragraph applies: The Grantee acknowledges that Property being improved is titled to the State of Florida, and is not subject to lien of any kind for any reason. The Grantee shall include notice of such exemptions in any subcontracts and purchase orders issued hereunder. GRANT- GOVERNMENTAL ENTITY Ver. January, 2018 Page 4 of 20 FWC Agreement No. 20192 7. MONITORING. The Commission's Grant Manager shall actively monitor the Grantee's performance and compliance with the terms of this Agreement. The Commission reserves the right for any Commission staff to make scheduled or unscheduled, announced or unannounced monitoring visits. Specific State and Federal monitoring terms and conditions are found in Attachment B,Audit Requirements. Additionally,monitoring terms, conditions, and schedules may be included in Attachment A, Scope of Work. 8. TERMINATION. A. Commission Termination. The Commission may unilaterally terminate this Agreement for convenience by providing the Grantee with thirty (30) calendar days of written notice of its intent to terminate. The Grantee shall not be entitled to recover any cancellation charges or lost profits. The Grantee may request termination of the Agreement for convenience. B. Termination — Fraud or Willful Misconduct. This Agreement shall terminate immediately in the event of fraud or willful misconduct. In the event of such termination, the Commission shall provide the Grantee with written notice of termination. C. Termination—Other. The Commission may terminate this Agreement if the Grantee fails to: 1.) comply with all terms and conditions of this Agreement; 2.) produce each deliverable within the time specified by the Agreement or extension; 3.) maintain adequate progress, thus endangering the performance of the Agreement; or, 4.) abide by any statutory, regulatory, or licensing requirement. Rule 60A-1.006(3),F.A.C.,governs the procedure and consequences for default. The rights and remedies of the Commission in this clause are in addition to any other rights and remedies provided by law or under the Agreement. The Grantee shall not be entitled to recover any cancellation charges or lost profits. D. Termination - Funds Unavailability. In the event funds to finance this Agreement become unavailable or if federal or state funds upon which this Agreement is dependent are withdrawn or redirected, the Commission may terminate this Agreement upon no less than twenty-four (24) hours' notice in writing to the Grantee. Said notice shall be delivered by certified mail, return receipt requested or in person with proof of delivery. The Commission shall be the final authority as to the availability of funds and will not reallocate funds appropriated for this Agreement to another program thus causing "lack of funds." In the event of termination of this Agreement under this provision,the Grantee will be compensated for any work satisfactorily completed and any non- cancellable obligations properly incurred prior to notification of termination. E. Grantee Discontinuation of Activities upon Termination Notice. Upon receipt of notice of termination, the Grantee shall, unless the notice directs otherwise, immediately discontinue all activities authorized hereunder. Upon termination of this Agreement, the Grantee shall promptly render to the Commission all property belonging to the Commission. For the purposes of this section,property belonging to the Commission shall include,but shall not be limited to, all books and records kept on behalf of the Commission. 9. REMEDIES. A. Financial Consequences. In accordance with Sections 215.971(l)(a)&(b), F.S., Attachment A, Scope of Work, contains clearly established tasks in quantifiable units of deliverables that must be received and accepted in writing by the agency before payment. Each deliverable specifies the required minimum level of service to be performed and the criteria for evaluating the successful completion of each deliverable. If the Grantee fails to produce each deliverable within the time GRANT- GOVERNMENTAL ENTITY Ver. January, 2018 Page 5 of 20 FWC Agreement No. 20192 frame specified by the Scope of Work, the budget amount allocated for that deliverable will be deducted from the Grantee's payment. In addition, pursuant to Section 215.971(l)(c), the Commission shall apply any additional financial consequences,identified in the Scope of Work. B. Cumulative Remedies. The rights and remedies of the Commission in this paragraph are in addition to any other rights and remedies provided by law or under the Agreement. 10. NOTICES AND CORRESPONDENCE. Any and all notices shall be delivered to the individuals identified below. In the event that either Party designates a different Grant Manager after the execution of this Agreement, the Party will provide written notice of the name, address, zip code, telephone and fax numbers, and email address of the newest Grant Manager, or an individual authorized to receive notice on behalf of that Parry, to all other Parties as soon as possible, but not later than five (5) business days after the new Grant Manager has been named. A designation of a new Grant Manager shall not require a formal amendment to the Agreement. FOR THE COMMISSION: FOR THE GRANTEE: Grant Manager Grant Manager Phil Horning Celia Hitchins Derelict Vessel Program Administrator Administrator Marine Resources Fish and Wildlife Conservation Commission Monroe County BOCC 620 S. Meridian Street, Room 235I 2798 Overseas Highway, Suite 420 Tallahassee, Florida 32399 Marathon, Florida 33050 (850) 617-9540 Direct (305)289-2505 Office (850) 488-9284 Fax (305)289-2536 Fax Phil.Horning@MyFWC.com Hitchins-Celia@MonroeCounty-fl.gov 11. AMENDMENT. A. Waiver or Modification. No waiver or modification of this Agreement or of any covenant, condition, or limitation herein contained shall be valid unless in writing and lawfully executed by the Parties. B. Change Orders. The Commission may, at any time, by written order, make a change to this Agreement. Such changes are subject to the mutual agreement of both Parties as evidenced in writing. Any change which causes an increase or decrease in the Grantee's cost or time shall require an Amendment. Minor changes, such as those updating a Party's contact information, may be accomplished by a Modification. C. Renegotiation upon Change in Law or Regulation. The Parties agree to renegotiate this Agreement if federal and/or state revisions of any applicable laws or regulations make changes in the Agreement necessary. 12. PROPERTY RIGHTS. If this Agreement includes Federal funds, the provisions of Sections 200.310-200.316, OMB Uniform Guidance (2 CFR 200), and any language addressing Federal rights, apply. GRANT- GOVERNMENTAL ENTITY Ver. January, 2018 Page 6 of 20 FWC Agreement No. 20192 A. Intellectual and Other Intangible Property. I. Grantee's Preexisting Intellectual Property (Proprietary) Rights. Unless specifically addressed in the Attachment A, Scope of Work, intellectual and other intangible property rights to the Grantee's preexisting property will remain with the Grantee. ii. Proceeds Related to Intellectual Property Rights. Proceeds derived from the sale, licensing, marketing or other authorization related to any intellectual and other intangible property right created or otherwise developed by the Grantee under this Agreement for the Commission shall be handled in the manner specified by the applicable Florida State Statute and/or Federal program requirements. iii. Commission Intellectual Property Rights. Where activities supported by this Agreement produce original writing, sound recordings, pictorial reproductions, drawings or other graphic representations and works of any similar nature, the Commission and the State of Florida have the unlimited, royalty-free, nonexclusive, irrevocable right to use, duplicate and disclose such materials in whole or in part,in any manner,for any purpose whatsoever and to have others acting on behalf of the Commission to do so. If this Agreement is supported by federal funds, the federal awarding agency reserves a royalty-free, nonexclusive and irrevocable right to reproduce, publish, or otherwise use the work for federal purposes, and to authorize others to do so. B. Purchase or Improvement of Real Property This agreement is not for the purchase or improvement of real property, therefore, the following terms and conditions do not apply'. I. Federal Funds. Any Federal funds provided for the purchase of or improvements to real property are subject to the Property Standards of Sections 200.310 -200.316,and 200.329, OMB Uniform Guidance (2 CFR 200), as amended. ii. Title. If this agreement is supported by state funds,the Grantee shall comply with Section 287.05805,F.S. This section requires the Grantee to grant a security interest in the property to the State of Florida, the type and details of which are provided for in Attachment A, Scope of Work. Title to state-owned real property remains vested in the state. Title to federally-owned real property remains vested in the Federal government in accordance with the provisions of Section 200.312,OMB Uniform Guidance(2 CFR 200),as amended. iii. Use. Federally-owned real property will be used for the originally authorized purpose as long as needed for that purpose in accordance with Section 200.311, OMB Uniform Guidance (2 CFR 200). State-owned real property will be used as provided in Attachment A, Scope of Work. C. Non-Expendable Property. The following provisions apply to the extent that the grant allows the acquisition of non-expendable property. i. Non-Expendable Property Defined. For the requirements of this section of the Agreement, "non-expendable property" is the same as "property" as defined in Section 273.02, F.S. (equipment, fixtures, and other tangible personal property of a non- consumable and non-expendable nature, with a value or cost of$1,000.00 or more, and a normal expected life of one (1) year or more; hardback-covered bound books that are GRANT- GOVERNMENTAL ENTITY Ver. January, 2018 Page 7 of 20 FWC Agreement No. 20192 circulated to students or the general public, with a value or cost of$25.00 or more; and uncirculated hardback-covered bound books,with a value or cost of$250.00 or more). ii. Title to Non-Expendable Property. Title (ownership) to all non-expendable property acquired with funds from this Agreement shall be vested in the Commission and said property shall be transferred to the Commission upon completion or termination of the Agreement unless otherwise authorized in writing by the Commission or unless otherwise specifically provided for in Attachment A, Scope of Work. D. Equipment and Supplies. The following provisions apply to the extent that the grant allows the acquisition of equipment and supplies. i. Title - Equipment. Title to equipment acquired under a Federal award will vest upon acquisition in the non-Federal entity in accordance with Sections 200.313 and 200.314, OMB Uniform Guidance (2 CFR 200). ii. Title — Supplies. Title to supplies will vest in the non-Federal entity upon acquisition. Unused supplies exceeding $5,000.00 in total aggregate value upon termination or completion of the project or program are subject to Section 200.314, OMB Uniform Guidance. in. Use— Equipment. Equipment must be used by the non-Federal entity in the program or project for which it was acquired as long as needed 13. RELATIONSHIP OF THE PARTIES. A. Independent Grantee. The Grantee shall perform as an independent grantee and not as an agent, representative, or employee of the Commission. The Grantee covenants that it presently has no interest and shall not acquire any interest that would conflict in any manner or degree with the performance of services required. Each Party hereto covenants that there is no conflict of interest or any other prohibited relationship between the Grantee and the Commission. B. Grantee Training and Qualifications. Grantee agrees that all Grantee employees,subcontractors, or agents performing work under the Agreement shall be properly trained technicians who meet or exceed any specified training qualifications. Upon request, Grantee shall furnish a copy of technical certification or other proof of qualification. C. Commission Security. All employees, subcontractors, or agents performing work under the Agreement must comply with all security and administrative requirements of the Commission. The Commission may conduct, and the Grantee shall cooperate in, a security background check or otherwise assess any employee,subcontractor,or agent furnished by the Grantee. The Commission may refuse access to,or require replacement of, any personnel for cause,including,but not limited to,technical or training qualifications,quality of work,change in security status,or non-compliance with the Commission's other requirements. Such refusal shall not relieve Grantee of its obligation to perform all work in compliance with the Agreement. The Commission,in coordination with the Grantee,may reject and bar from any facility for cause any of Grantee's employees,subcontractors, or agents. D. Commission Rights to Assign or Transfer. The Grantee agrees that the State of Florida shall at all times be entitled to assign or transfer its rights, duties, or obligations under this Agreement to GRANT- GOVERNMENTAL ENTITY Ver. January, 2018 Page 8 of 20 FWC Agreement No. 20192 another governmental agency in the State of Florida, upon giving prior written notice to the Grantee. E. Commission Rights to Undertake and Award Supplemental Agreements. Grantee agrees that the Commission may undertake or award supplemental agreements for work related to the Agreement. The Grantee and its subcontractors shall cooperate with such other Grantees and the Commission in all such cases. 14. SUBCONTRACTS. A. Authority. Grantee is permitted to subcontract work under this Agreement, therefore, the following terms and conditions apply. The Grantee shall ensure, and provide assurances to the Commission upon request, that any subcontractor selected for work under this Agreement has the necessary qualifications and abilities to perform in accordance with the terms and conditions of this Agreement. The Grantee must provide the Commission with the names of any subcontractor considered for work under this Agreement; the Commission in coordination with the Grantee reserves the right to reject any subcontractor. The Grantee agrees to be responsible for all work performed and all expenses incurred with the project. Any subcontract arrangements must be evidenced by a written document available to the Commission upon request. The Grantee further agrees that the Commission shall not be liable to the extent allowed by law,to any subcontractor for any expenses or liabilities incurred under the subcontract and the Grantee shall be solely liable to the subcontractor for all expenses and liabilities incurred under the subcontract. B. Grantee Payments to Subcontractor. If subcontracting is permitted pursuant to Paragraph A, above, Grantee agrees to make payments to the subcontractor upon completion of work and submitted invoice in accordance with the contract between the Grantee and subcontractor. Failure to make payment pursuant to any subcontract will result in a penalty charged against Grantee and paid to the subcontractor in the amount of one-half of one percent(0.50%) of the amount due per day from the expiration of the period allowed herein for payment. Such penalty shall be in addition to actual payments owed and shall not exceed fifteen percent(15%) of the outstanding balance due." C. Commission Right to Reject Subcontractor Employees. The Commission in coordination with Grantee shall retain the right to reject any of the Grantee's or subcontractor's employees whose qualifications or performance,in the Commission's judgment, are insufficient. D. Subcontractor as Independent Contractor. If subcontracting is permitted pursuant to Paragraph A above, the Grantee agrees to take such actions as may be necessary to ensure that each subcontractor will be deemed to be an independent contractor and will not be considered or permitted to be an agent, servant,joint venturer, or partner of the State of Florida. 15. MANDATORY DISCLOSURE. These disclosures are required by State law, as indicated, and apply when this Agreement includes State funding; and by Federal law, as indicated, and apply when the Agreement includes a Federal award. A. Disclosure of Interested State Employees and Conflict of Interest. This Agreement is subject to Chapter 112, F.S. Grantee shall provide the name of any officer, director, employee, or other agent who is affiliated with this project and an employee of the State of Florida. If the Agreement includes a Federal award, then the Agreement is also subject to Section 200.112, OMB Uniform Guidance (2 CFR 200). Grantee must disclose,in writing, any potential conflict of interest to the Commission in accordance with applicable Federal awarding agency policy. GRANT- GOVERNMENTAL ENTITY Ver. January, 2018 Page 9 of 20 FWC Agreement No. 20192 B. Convicted Vendors. Grantee hereby certifies that neither it,nor any person or affiliate of Grantee, has been convicted of a Public Entity Crime as defined in section 287.133, F.S.,nor placed on the convicted vendor list. Grantee shall have a continuing obligation to disclose, to the Commission, in writing, if it, its principals, recipient, subrecipient, contractor, or subcontractor, are on the convicted vendors list maintained by the Florida Department of Management Services pursuant to Section 287.133(3)(d), F.S. i. Convicted Vendor List. Pursuant to Subsection 287.133(2)(a), F.S., a person or affiliate who has been placed on the convicted vendor list following a conviction for a public entity crime may not be awarded or perform work as a Grantee, supplier, subcontractor or consultant under a contract with any public entity and may not transact business with any public entity in excess of the threshold amount provided in Section 287.017, F.S., for Category Two for a period of thirty-six (36) months from the date of being placed on the convicted vendor list. The State of Florida,Department of Management Services,Division of State Purchasing provides listings for convicted, suspended, discriminatory and federal excluded parties, as well as the vendor complaint list at: htlp://www.dms.myflon*da.com/business_operations/state purchasing/vendor_information/co nvicted_suspended_discriminatory complaints_vendor lists ii. Notice of Conviction of Public Entity Crime. Any person must notify the Department of Management Services and the Commission, in writing, within thirty (30) days after conviction of a public entity crime applicable to that person or an affiliate of that person as defined in Section 287.133, F.S. C. Vendors on Scrutinized Companies List. i. Scrutinized Companies. Grantee certifies that it and any of its affiliates are not scrutinized companies as identified in Section 287.135,F.S. In addition, Grantee agrees to observe the requirements of Section 287.135, F.S., for applicable sub-agreements entered into for the performance of work under this Agreement. Pursuant to Section 287.135, F.S.,the Commission may immediately terminate this Agreement for cause if the Grantee,its affiliates, or its subcontractors are found to have submitted a false certification; or if the Grantee,its affiliates, or its subcontractors are placed on any applicable scrutinized companies list or engaged in prohibited contracting activity during the term of the Agreement. As provided in Subsection 287.135(8), F.S.,if federal law ceases to authorize these contracting prohibitions then they shall become inoperative. D. Discriminatory Vendors. Grantee shall disclose to the Commission, in writing, if they, their subrecipient,contractor,or subcontractor,are on the Discriminatory Vendor List maintained by the Florida Department of Management Services pursuant to Section 287.134(3)(d),F.S. "An entity or affiliate who has been placed on the discriminatory vendor list may not submit a bid,proposal, or reply on a contract to provide any goods or services to a public entity; may not submit a bid, proposal,or reply on a contract with a public entity for the construction or repair of a public building or public work; may not submit bids, proposals, or replies on leases of real property to a public entity; may not be awarded or perform work as a contractor, supplier, subcontractor, or consultant under a contract with any public entity; and may not transact business with any public entity." Section 287.134(2)(a),F.S.. Grantee has a continuing duty to disclose to the Commission whether they appear on the discriminatory vendor list. E. Prompt Disclosure of Litigation,Investigations,Arbitration, or Administrative Proceedings. Throughout the term of the Agreement, the Grantee has a continuing duty to promptly disclose to GRANT- GOVERNMENTAL ENTITY Ver. January, 2018 Page 10 of 20 FWC Agreement No. 20192 the Commission's Grant Manager, in writing, upon occurrence, all civil or criminal litigation, investigations, arbitration, or administrative proceedings (Proceedings)relating to or affecting the Grantee's ability to perform under this agreement. If the existence of such Proceeding causes the Commission concern that the Grantee's ability or willingness to perform the Agreement is jeopardized, the Grantee may be required to provide the Commission with reasonable assurances to demonstrate that: a.) the Grantee will be able to perform the Agreement in accordance with its terms and conditions; and,b.) Grantee and/or its employees or agents have not and will not engage in conduct in performing services for the Commission which is similar in nature to the conduct alleged in such Proceeding. F. Certain Violations of Federal Criminal Law.If this agreement includes a Federal award,then in accordance with Section 200.113, OMB Uniform Guidance (2 CFR 200), Grantee must disclose, in a timely manner, in writing to the Commission all violations of Federal criminal law involving fraud,bribery, or gratuity violations potentially affecting the Federal award. 16. INSURANCE. The Grantee warrants and represents that it is insured, or self-insured for liability insurance, in accordance with applicable state law and that such insurance or self-insurance offers protection applicable to the Grantee's officers, employees, servants and agents while acting within the scope of their employment with the Grantee. 17. SPONSORSHIP. As required by Section 286.25, F.S., if any recipient, subrecipient, contractor or subcontractor under this grant is a nongovernmental organization which sponsors a program financed wholly or in part by state funds, including any funds obtained through this Agreement, it shall, in publicizing, advertising, or describing the sponsorship of the program, state: "Sponsored by(Grantee's name)and the State of Florida, Fish and Wildlife Conservation Commission." If the sponsorship reference is in written material,the words "State of Florida,Fish and Wildlife Conservation Commission"shall appear in the same size letters or type as the name of the Grantee's organization. Additional sponsorship requirements may be specified in Attachment A, Scope of Work. 18. PUBLIC RECORDS. A. This Agreement may be unilaterally canceled by the Commission for refusal by the Grantee to allow public access to all documents,papers, letters, or other material subject to the provisions of Chapter 119,F.S., and made or received by the Grantee in conjunction with this Agreement,unless exemption for such records is allowable under Florida law. B. If the Grantee meets the definition of"Contractor"in Section 119.070l(1)(a)F.S.,the Grantee shall comply with the following: i. IF THE CONTRACTOR HAS QUESTIONS REGARDING THE APPLICATION OF THE CHAPTER 119, FLORIDA STATUES, TO THE CONTRACTOR'S DUTY TO PROVIDE PUBLIC RECORDS RELATING TO THIS CONTRACT, CONTACT THE CUSTODIAN OF PUBLIC RECORDS AT: 850-488-6553, RecordsCustodian(amyfwc.com, and 620 South Meridian Street, Tallahassee FL 32399 GRANT- GOVERNMENTAL ENTITY Ver. January, 2018 Page 11 of 20 FWC Agreement No. 20192 ii. Keep and maintain public records required by the Commission to perform the service. iii. Upon request from the Commission's custodian of public records, provide the Commission with a copy of the requested records or allow the records to be inspected or copied within a reasonable time at a cost that does not exceed the cost provided in Chapter 119,F.S. or as otherwise provided by law. iv. Ensure that public records that are exempt or confidential and exempt from public records disclosure requirements are not disclosed except as authorized by law for the duration of the contract term and following completion of the contract if the Contractor does not transfer the records to the Commission. V. Upon completion of the contract transfer, at no cost, to the Commission all public records in possession of the Contractor or keep and maintain public records required by the Commission to perform the service. If the Contractor transfers all public records to the Commission upon completion of the contract, the Contractor shall destroy any duplicate public records that are exempt or confidential and exempt from public records disclosure requirements. If the Contractor keeps and maintains public records upon completion of the contract,the Contractor shall meet all applicable requirements for retaining public records. All records stored electronically must be provided to the Commission, upon request from the Commission's custodian of public records, in a format that is compatible with the information technology systems of the Commission. 19. COOPERATION WITH INSPECTOR GENERAL. Pursuant to subsection 20.055(5),F.S., Grantee,and any subcontractor to the Grantee,understand and will comply with their duty to cooperate with the Inspector General in any investigation, audit, inspection, review, or hearing. Upon request of the Inspector General or any other authorized State official, the Grantee shall provide any type of information the Inspector General deems relevant to the Grantee's integrity or responsibility.Such information may include,but shall not be limited to,the Grantee's business or financial records, documents, or files of any type or form that refer to or relate to the Agreement. The Grantee agrees to reimburse the State for the reasonable costs of investigation incurred by the Inspector General or other authorized State official for investigations of the Grantee's compliance with the terms of this or any other agreement between the Grantee and the State which results in the suspension or debarment of the Grantee. Such costs shall include, but shall not be limited to: salaries of investigators, including overtime; travel and lodging expenses; and expert witness and documentary fees. 20. SECURITY AND CONFIDENTIALITY. The Grantee shall not divulge to third parties any clearly marked confidential information obtained by the Grantee or its agents, distributors, resellers, subcontractors, officers or employees in the course of performing Grant work. To ensure confidentiality, the Grantee shall take appropriate steps regarding its personnel, agents, and subcontractors. The warranties of this paragraph shall survive the Grant. 21. RECORD KEEPING REQUIREMENTS. A. Grantee Responsibilities. The Grantee shall maintain accurate books,records, documents and other evidence that sufficiently and properly reflect all direct and indirect costs of any nature expended in the performance of this Agreement,in accordance with generally accepted accounting principles. B. State Access to Grantee Books, Documents, Papers, and Records. The Grantee shall allow the Commission, the Chief Financial Officer of the State of Florida, the Auditor General of the State of Florida,the Florida Office of Program Policy Analysis and Government Accountability or authorized representatives of the state or federal government to have access to any of the Grantee's books, documents, papers, and records, including electronic storage media, as they may relate to this GRANT- GOVERNMENTAL ENTITY Ver. January, 2018 Page 12 of 20 FWC Agreement No. 20192 Agreement, for the purposes of conducting audits or examinations or making excerpts or transcriptions. C. Grantee Records Retention. Unless otherwise specified in the Scope of Work, these records shall be maintained for five (5) fiscal years following the close of this Agreement, or the period required for this particular type of project by the General Records Schedules maintained by the Florida Department of State (available at: http://dos.myflorida.com/library-archives/records- management/general-records-schedules/), whichever is longer. Grantee shall cooperate with the Commission to facilitate the duplication and transfer of such records upon the Commission's request. D. Grantee Responsibility to Include Records Requirements—Subcontractors. In the event any work is subcontracted under this Agreement, the Grantee shall include the aforementioned audit and record keeping requirements in all subsequent contracts. E. Compliance with Federal Funding Accountability and Transparency. Any federal funds awarded under this Agreement must comply with the Federal Funding Accountability and Transparency Act (FFATA)of 2006. The intent of the FFATA is to empower every American with the ability to hold the government accountable for each spending decision. The result is to reduce wasteful spending in the government. The FFATA legislation requires that information on federal awards (federal financial assistance and expenditures) be made available to the public via a single, searchable website: htip://www.USASpending.gov. Grant recipients awarded a new Federal grant greater than or equal to $25,000.00 awarded on or after October 1, 2010 are subject to the FFATA. The Grantee agrees to provide the information necessary,over the life of this Agreement,for the Commission to comply with this requirement. 22. FEDERAL AND FLORIDA SINGLE AUDIT ACT REQUIREMENTS. Pursuant to the FSAA (or Federal) Vendor / Recipient Determination Checklist, the Grantee has been determined to be a recipient of state financial assistance and/or a subrecipient of a federal award. Therefore, pursuant to Section 215.97,F.S. and/or OMB Uniform Guidance (2 CFR 200), the Grantee may be subject to the audit requirements of the Florida and/or Federal Single Audit Acts. If applicable, the Grantee shall comply with the audit requirements outlined in Attachment B, "Requirements of the Federal and Florida Single Audit Acts,"attached hereto and made a part of the Agreement, as applicable. 23. FEDERAL COMPLIANCE. As applicable, Grantee shall comply with all federal laws, rules, and regulations,including but not limited to: i. Clean Air Act and Water Pollution Control Act. All applicable standards, orders, or requirements issued under the Clean Air Act (42 U.S.C. 7401-7671q), and the Water Pollution Control Act(33 U.S.C. 1251-1387, as amended). ii. Lacey Act, 16 U.S.0 3371-3378. This Act prohibits trade in wildlife, fish and plants have been illegally taken,possessed, transported or sold. in. Magnuson-Stevens Fishery Conservation and Management Act, 16 U.S.C. 1801-1884. This Act governs marine fisheries in Federal waters. iv. Migratory Bird Treaty Act, 16 U.S.C. 703-712. The Act prohibits anyone, unless permitted, to pursue, hunt, take, capture, kill, attempt to take, capture or kill, possess, offer for sale, sell, offer to purchase, deliver for shipment, ship, cause to be shipped, deliver for transportation, transport, cause to be transported, carry or cause to be carried by any means GRANT- GOVERNMENTAL ENTITY Ver. January, 2018 Page 13 of 20 FWC Agreement No. 20192 whatsoever, receive for shipment, transport of carriage, or export, at any time, or in any manner, any migratory bird, or any part,nest, or egg of such bird. V. Endangered Species Act, 16 U.S.C. 1531, et seq. The Act provides a program for the conservation of threatened and endangered plants and animals and the habitat in which they are found. The Act also prohibits any action that cause a "taking" of any listed species of endangered fish or wildlife. Also generally prohibited are the import, export, interstate, and foreign commerce of listed species. 24. FEDERAL FUNDS. This;Agreement relies on federal funds, therefore, the following terms and conditions apply: A. Prior Approval to Expend Federal Funds to Federal Agency or Employee. It is understood and agreed that the Grantee is not authorized to expend any federal funds under this Contract to a federal agency or employee without the prior written approval of the awarding federal agency. B. Equal Employment Opportunity. Executive Order 11246 of September 24, 1965, entitled "Equal Employment Opportunity," as amended by Executive Order 11375 of October 13, 1967, and as supplemented in Department of Labor regulations (41 CFR Chapter 60). Applicable, except as otherwise provide under 41 CFR Part 60,to any grant,contract,loan,insurance,or guarantee involving Federal assisted construction. C. Davis-Bacon Act. The Davis-Bacon Act, 40 U.S.C. 3141-3148, as supplemented by Department of Labor regulations at 29 CFR Part 5. Applicable to contractors and subcontractors performing on federally funded or assisted contracts in excess of$2,000.00 for the construction, alteration, or repair (including painting and decorating) of public buildings or public works. Under this Act, contractors and subcontractors must pay their laborers and mechanics employed under the contract no less than the locally prevailing wages and fringe benefits for corresponding work on similar projects in the area. D. Copeland "Anti-Kickback Act. The Copeland "Anti-Kickback" Act, 40 U.S.C. 3141-3148, and 3146-3148, as supplemented by Department of Labor regulations (29 CFR Part 5). Applicable to contracts awarded by a non-Federal entity in excess of $100,000.00 that involve employment of mechanics or labors. Under this Act, contractors and subrecipients are prohibited from inducing, by any mean, any person employed in the construction, completion, or repair of public work, to give up any part of the compensation to which he or she is otherwise entitled. E. Contract Work Hours and Safety Standards Act. Sections 103 and 107 of the Agreement Work Hours and Safety Standards Act (40 U.S.C. 327-330) as supplemented by Department of Labor regulations (29 CFR part 5). Applicable to construction contracts awarded by Contractors and subcontractors in excess of$2,000.00, and in excess of$2,500.00 for other contracts which involve the employment of mechanics or laborers. Under this Act, contractors and subcontractors must compute wages of mechanics and laborers (workers) on the basis of a standard forty (40) hour work week;provide workers no less than time and a half for hours worked in excess of the forty (40) hour work week; and not require workers to work in surroundings or work conditions that are unsanitary, hazardous, or dangerous. F. Rights to Inventions Made Under a Contractor Agreement. 37 CFR Part 401.If the Federal award meets the definition of"funding agreement"under 37 CFR 401.2(a) and the recipient or Subrecipient wishes to enter into a contract with a small business firm or nonprofit organization regarding the substitution of parties, assignment or performance of experimental, developmental, or research work under the "funding agreement,"the recipient or subrecipient must comply with the requirements of 37 GRANT- GOVERNMENTAL ENTITY Ver. January, 2018 Page 14 of 20 FWC Agreement No. 20192 CFR Part 401, "Rights to Inventions Made by Nonprofit Organizations and Small Business Firms Under Government Grants, Contracts and Cooperative Agreements," and any implementing regulations issued by the awarding agency. G. Energy Efficiency. Mandatory standards and policies relating to energy efficiency which are contained in the State energy conservation plan issued in compliance with the Energy Policy and Conservation Act(Pub. L. 94-163, 89 Stat. 871). H. Debarment and Suspension Contractor Federal Certification. In accordance with Federal Executive Order 12549 and 2 CFR Part 1400 regarding Debarment and Suspension, the Grantee certifies that neither it, nor its principals, is presently debarred, suspended, proposed for debarment, declared ineligible, or voluntarily excluded from participation in this transaction by any federal department or agency; and, that the Grantee shall not knowingly enter into any lower tier contract, or other covered transaction,with a person who is similarly debarred or suspended from participating in this covered transaction. I. Prohibition against Lobbying. i. Grantee Certification — Payments to Influence. The Grantee certifies that no Federal appropriated funds have been paid or will be paid,on or after December 22, 1989,by or on behalf of the Grantee,to any person for influencing or attempting to influence an officer or employee of an agency, a Member of Congress, an officer or employee of Congress, or an employee of a Member of Congress, in connection with the awarding, renewal, amending or modifying of any Federal contract, grant, or cooperative agreement. The Grantee also certifies that they have not engaged any registrant under the Lobbying Disclosure Act of 1995 who has made lobbying contacts on behalf of the Grantee with respect to this Contract and its related federal contract,grant,loan,or cooperative agreement;or,if the Grantee has engaged any registrant with respect to this Contract and its related Federal contract, grant, loan, or cooperative agreement, the Grantee shall, prior to or upon execution of this Contract,provide the Commission Contract Manager a signed declaration listing the name of any said registrant. During the term of this Contract, and at the end of each Calendar quarter in which any event occurs that materially affects the accuracy of this certification or declaration, the Grantee shall file an updated declaration with the Commission's Contract Manager. If any non-federal funds are used for lobbying activities as described above in connection with this Contract, the Grantee shall submit Standard Form-LLL, "Disclosure Form to Report Lobbying", and shall file quarterly updates of any material changes. The Grantee shall require the language of this certification to be included in all subcontracts, and all subcontractors shall certify and disclose accordingly. ii. Grantee— Refrain from Subcontracting with Certain Organizations. Pursuant to the Lobbying Disclosure Act of 1995, the Grantee agrees to refrain from entering into any subcontracts under this Contract with any organization described in Section 501(c)(4) of the Internal Revenue Code of 1986,unless such organization warrants that it does not, and will not, engage in lobbying activities prohibited by the Act as a special condition of the subcontract. J. Compliance with Office of Management and Budget Circulars. As applicable, Grantee shall comply with the following Office of Management and Budget (OMB) Uniform Guidance (2 CFR 200). GRANT- GOVERNMENTAL ENTITY Ver. January, 2018 Page 15 of 20 FWC Agreement No. 20192 K. Drug Free Workplace. Pursuant to the Drug-Free Workplace Act of 1988, the Grantee attests and certifies that the Grantee will provide a drug-free workplace compliant with 41 U.S.C. 81. 25. CONTRACT-RELATED PROCUREMENT. A. PRIDE. In accordance with Section 946.515(6), F.S., if a product or service required for the performance of this Contract is certified by or is available from Prison Rehabilitative Industries and Diversified Enterprises, Inc. (PRIDE) and has been approved in accordance with Subsection 946.515(2), F.S., the following statement applies: It is expressly understood and agreed that any articles which are the subject of,or required to carry out,this contract shall be purchased from [PRIDE] in the same manner and under the same procedures set forth in Subsections 946.515(2) and(4),F.S.; and for purposes of this contract the person,firm or other business entity carrying out the provisions of this contract shall be deemed to be substituted for this agency insofar as dealings with such corporation are concerned. The above clause is not applicable to subcontractors unless otherwise required by law. Additional information about PRIDE and the products it offers is available at htlp://www.pride-entelprises.org. B. Respect of Florida. In accordance with Subsection 413.036(3), F.S., if a product or service required for the performance of this Contract is on the procurement list established pursuant to Subsection 413.035(2), F.S., the following statement applies: It is expressly understood and agreed that any articles that are the subject of, or required to carry out, this contract shall be purchased from a nonprofit agency for the blind or for the severely handicapped that is qualified pursuant to Chapter 413,F.S.,in the same manner and under the same procedures set forth in Subsections 413.036(l) and(2),F.S.; and for purposes of this contract,the person,firm or other business entity carrying out the provisions of this contract shall be deemed to be substituted for the state agency insofar as dealings with such qualified nonprofit agency are concerned. Additional information about the designated nonprofit agency and the products it offers is available at htlp://www.respectofflorida.org. C. Procurement of Recycled Products or Materials. Grantee agrees to procure any recycled products or materials which are the subject of or are required to carry out this Contract in accordance with Section 403.7065, F.S. 26. PROFESSIONAL SERVICES. A. Architectural, Engineering, Landscape Architectural, or Survey and Mapping. If this Agreement is for the acquisition of professional architectural, engineering, landscape architectural, or registered surveying and mapping services, and is therefore subject to Section 287.055,F.S.,the following provision applies: The architect (or registered surveyor and mapper or professional engineer, as applicable) warrants that he or she has not employed or retained any company or person, other than a bona fide employee working solely for the architect (or GRANT- GOVERNMENTAL ENTITY Ver. January, 2018 Page 16 of 20 FWC Agreement No. 20192 registered surveyor and mapper, or professional engineer, as applicable) to solicit or secure this Agreement and that he or she has not paid or agreed to pay any person,company,corporation,individual,or firm,other than a bona fide employee working solely for the architect(or registered surveyor and mapper or professional engineer, as applicable) any fee, commission, percentage, gift, or other consideration contingent upon or resulting from the award or making of this contract. B. Termination for Breach. For the breach or violation of this provision,the Commission shall have the right to terminate the Agreement without liability and, at its discretion, to deduct from the Agreement price, or otherwise recover, the full amount of such fee, commission,percentage, gift, or consideration. 27. INDEMNIFICATION. If Grantee is a state agency or subdivision, as defined in Subsection 768.28(2),F.S.,pursuant to Subsection 768.28(19), F.S.,neither Party indemnifies nor insures the other Party for the other Party's negligence. If Grantee is not a state agency or subdivision as defined above, Grantee shall be fully liable for the actions of its agents, employees, partners, or subcontractors and shall fully indemnify, defend, and hold harmless the State and the Commission, and their officers, agents, and employees, from suits, actions, damages, and costs of every name and description, including attorneys' fees, arising from or relating to personal injury and damage to real or personal tangible property alleged to be caused in whole or in part by Grantee, its agents,employees,partners,or subcontractors,provided,however,that Grantee shall not indemnify for that portion of any loss or damages proximately caused by the negligent act or omission of the State or the Commission. If this is a Professional Services Agreement as defined in Subsection 725.08 F.S., then notwithstanding the provisions of Subsection 725.06 F.S., the design professional shall only be liable for, and fully indemnify, defend, and hold harmless the State, the Commission, and their officers, agents, and employees,for actions caused in whole or in part,by the negligence,recklessness,or intentionally wrongful conduct of the design professional and other persons employed or utilized by the design professional in the performance of the Agreement. 28. NON-DISCRIMINATION. No person, on the grounds of race, creed, color, national origin, age, sex, or disability, shall be excluded from participation in,be denied the proceeds or benefits of, or be otherwise subjected to discrimination in performance of this Agreement. 29. SEVERABILITY, CHOICE OF LAW,AND CHOICE OF VENUE. This Agreement has been delivered in the State of Florida and shall be construed in accordance with the laws of Florida. Wherever possible, each provision of this Agreement shall be interpreted in such manner as to be effective and valid under applicable law,but if any provision of this Agreement shall be prohibited or invalid under applicable law, such provision shall be ineffective to the extent of such prohibition or invalidity, without invalidating the remainder of such provision or the remaining provisions of this Agreement. Any action in connection herewith,in law or equity, shall be brought in Leon County,Florida, to the exclusion of all other lawful venues. GRANT- GOVERNMENTAL ENTITY Ver. January, 2018 Page 17 of 20 FWC Agreement No. 20192 30. NO THIRD PARTY RIGHTS. The Parties hereto do not intend nor shall this Agreement be construed to grant any rights, privileges or interest to any person not a parry to this Agreement. 31. JURY TRIAL WAIVER. As part of the consideration for this Agreement, the Parties hereby waive trial by jury in any action or proceeding brought by any party against any other parry pertaining to any matter whatsoever arising out of or in any way connected with this Agreement, or with the products or services provided under this Agreement,including but not limited to any claim by the Grantee of quantum meruit. 32. PROHIBITION OF UNAUTHORIZED ALIENS. In accordance with Federal Executive Order 96-236,the Commission shall consider the employment by the Grantee of unauthorized aliens a violation of Section 274A(e) of the Immigration and Nationalization Act. Such violation shall be cause for unilateral cancellation of this Agreement if the Grantee knowingly employs unauthorized aliens. 33. EMPLOYMENT ELIGIBILITY VERIFICATION(E-VERIFY). A. Requirement to Use E-Verify. Executive Order 11-116, signed May 27, 2011,by the Governor of Florida, requires Commission contracts in excess of nominal value to expressly require the Grantee to: 1.) utilize the U.S. Department of Homeland Security's E-Verify system to verify the employment eligibility of all new employees hired by Grantee during the Agreement term; and,2.) include in all subcontracts under this Agreement, the requirement that subcontractors performing work or providing services pursuant to this Agreement utilize the E-Verify system to verify the employment eligibility of all new employees hired by the subcontractor during the term of the subcontract. B. E-Verify Online. E-Verify is an Internet-based system that allows an employer,using information reported on an employee's Form I-9, Employment Eligibility Verification, to determine the eligibility of all new employees hired to work in the United States after the effective date of the required Memorandum of Understanding (MOU); the responsibilities and elections of federal contractors, however, may vary, as stated in Article II.D.l.c. of the MOU. There is no charge to employers to use E-Verify. The Department of Homeland Security's E-Verify system can be found online athtlp://www.dhs.gov/files/programs/gc 1185221678150.shtm C. Enrollment in E-Verify. If Grantee does not have an E-Verify MOU in effect, the Grantee must enroll in the E-Verify system prior to hiring any new employee after the effective date of this Agreement. D. E-Verify Recordkeeping. The Grantee further agrees to maintain records of its participation and compliance with the provisions of the E-Verify program, including participation by its subcontractors as provided above, and to make such records available to the Commission or other authorized state entity consistent with the terms of the Grantee's enrollment in the program. This includes maintaining a copy of proof of the Grantee's and subcontractors' enrollment in the E- Verify Program(which can be accessed from the"Edit Company Profile"link on the left navigation menu of the E-Verify employer's homepage). GRANT- GOVERNMENTAL ENTITY Ver. January, 2018 Page 18 of 20 FWC Agreement No. 20192 E. Employment Eligibility Verification. Compliance with the terms of the Employment Eligibility Verification provision is made an express condition of this Agreement and the Commission may treat a failure to comply as a material breach of the Agreement. 34. FORCE MAJEURE AND NOTICE OF DELAY FROM FORCE MAJEURE. Neither Parry shall be liable to the other for any delay or failure to perform under this Agreement if such delay or failure is neither the fault nor the negligence of the Parry or its employees or agents and the delay is due directly to acts of God, wars, acts of public enemies, strikes, fires, floods, or other similar cause wholly beyond the Party's control, or for any of the foregoing that affects subcontractors or suppliers if no alternate source of supply is available. However,in the event of delay from the foregoing causes,the Party shall take all reasonable measures to mitigate any and all resulting delay or disruption in the Party's performance obligation under this Agreement.If the delay is excusable under this paragraph,the delay will not result in any additional charge or cost under the Agreement to either Parry. In the case of any delay Agreement believes is excusable under this paragraph, Grantee shall notify the Commission's Grant Manager in writing of the delay or potential delay and describe the cause of the delay either: (1)within ten (10)calendar days after the cause that creates or will create the delay first arose,if Grantee could reasonably foresee that a delay could occur as a result; or(2)within five (5) calendar days after the date Grantee first had reason to believe that a delay could result, if the delay is not reasonably foreseeable. THE FOREGOING SHALL CONSTITUTE GRANTEE'S SOLE REMEDY OR EXCUSE WITH RESPECT TO DELAY. Providing notice in strict accordance with this paragraph is a condition precedent to such remedy. The Commission,in its sole discretion,will determine if the delay is excusable under this paragraph and will notify Grantee of its decision in writing. No claim for damages, other than for an extension of time, shall be asserted against the Commission. Grantee shall not be entitled to an increase in the Agreement price or payment of any kind from the Commission for direct, indirect, consequential, impact,or other costs,expenses or damages,including but not limited to costs of acceleration or inefficiency arising because of delay,disruption,interference,or hindrance from any cause whatsoever. If performance is suspended or delayed,in whole or in part, due to any of the causes described in this paragraph, after the causes have ceased to exist, Grantee shall perform at no increased cost,unless the Commission determines, in its sole discretion,that the delay will significantly impair the value of the Agreement to the Commission or the State, in which case, the Commission may do any or all of the following: (1) accept allocated performance or deliveries from Grantee, provided that Grantee grants preferential treatment to the Commission with respect to products or services subjected to allocation; (2)purchase from other sources (without recourse to and by Grantee for the related costs and expenses)to replace all or part of the products or services that are the subject of the delay,which purchases may be deducted from the Agreement quantity; or(3) terminate the Agreement in whole or in part. 35. TIME IS OF THE ESSENCE. Time is of the essence regarding the performance obligations set forth in this Agreement. Any additional deadlines for performance for Grantee's obligation to timely provide deliverables under this Agreement including but not limited to timely submittal of reports, are contained in the Scope of Work,Attachment A. 36. ENTIRE AGREEMENT. This Agreement with all incorporated attachments and exhibits represents the entire Agreement of the Parties. Any alterations, variations, changes, modifications or waivers of provisions of this Agreement shall only be valid when they have been reduced to writing, and duly signed by each of the Parties hereto, unless otherwise provided herein. In the event of conflict, the following order of precedence shall prevail; GRANT- GOVERNMENTAL ENTITY Ver. January, 2018 Page 19 of 20 FWC Agreement No. 20192 this Agreement and its attachments, the terms of the solicitation and the Grantee's response to the solicitation. IN WITNESS WHEREOF, the Parties hereto have caused this Agreement to be executed through their duly authorized signatories on the day and year last written below. MONROE COUNTY BOCC FLORIDA FISH AND WILDLIFE CONSERVATION COMMISSION I Cf Digitally signed by Gregg Eason Gregg d S o n Date:2021.01.04 11:03:10-05'00' SIGNATURE SIGNATURE Name: Roman Gastesi Name: Title: County Administrator Title: Date: 12/28/2020 Date: ONROE CCUNTY ATTORNEY Approved as to form and legality by FWC Attorney: A -D kS ro ORM Date. �3 SIGNAT Attachments in this Agreement include the following: Attachment A Scope of Work Attachment B Requirements of the Federal and Florida Single Audit Acts Exhibit 1 Federal and State Funding Detail Attachment C Cost Reimbursement Contract Payment Requirements Attachment D Derelict Vessel Removal Best Management Practices Attachment E Letter of Return on Investment for the State Attachment F Sample Invoice Form Attachment G Monthly Progress Report Attachment H Certificate of Completion GRANT- GOVERNMENTAL ENTITY Ver. January, 2018 Page 20 of 20