Item C13BOARD OF COUNTY COMMISSIONERS
AGENDA ITEM SUMMARY
Meeting Date: June 15, 2011 Division: CountU Administration
Bulk Item: Yes X No _ Department: Project Management
Staff Contact Person/Phone #: Jeny Barnett X4416
AGENDA ITEM WORDING: Approval of a Fourth Amendment to Contract with William P. Horn
Architect, P.A. for design and construction documents for the beachside playground in Phase 1 of
Higgs Beach redesign.
ITEM BACKGROUND: This Amendment will approve the design of the beachside playground, the
scope of the work shall include the creation of a site plan, design plan and details, development of the
construction drawings and specifications including demolition of cabanas, a design for fencing,
playground equipment, additional sand, sidewalk renovations, and relocation of recycle areas, and
includes oversight of the construction by the architect.
PREVIOUS RELEVANT BOCC ACTION: On December 16, 2009 the BOCC approved a
Continuing Contract with William P. Horn Architect, P.A. for Architectural/Engineering Services. On
March 17, 2010 the BOCC approved a contract with William P. Horn to develop a Master Plan for the
Higgs Beach Park. On December 15, 2010 the BOCC approved a First Amendment to Contract with
to extend the contract time by 90 days. On January 19, 2011 the BOCC approved Phase I of the
Master Plan including revisions and approved to proceed to Phase II, and on February 16, 2011, the
BOCC approved of a Second Amendment to Contract extending the contract time to proceed to Phase
H by 180 days, from March 12, 2011 to September 8, 2011. On May 18, 2011 the BOCC approved The
Third Amendment to the March 17, 2010 agreement, which provided for payment of $3,382.50 for
additional services under Phase I Master Plan which was required due to the revisions approved by the
BOCC on January 19, 2011.
CONTRACT/AGREEMENT CHANGES: Addition to the scope of work of the March 17, 2010
agreement to allow for construction drawings, bid review and construction administration for
beachside playground site plan, design plan and details, development of the construction drawings and
specifications including demolition of cabanas, a design for fencing, playground equipment, additional
sand, sidewalk renovations, and relocation of recycle areas, and other related items.
STAFF RECOMMENDATIONS: Approval as stated above
TOTAL COST: $11,000.00 INDIRECT COST: BUDGETED: Yes X No AIS for
DIFFERENTIAL OF LOCAL PREFERENCE: N/A
COST TO COUNTY: $11,000.00 SOURCE OF FUNDS: TDC
REVENUE PRODUCING: Yes X AMOUNT PER MONTH Year
APPROVED BY: County Atty /Purchasing Risk Managements
DOCUMENTATION: Included X Not Required
DISPOSITION: AGENDA ITEM #
Revised 7/09
MONROE COUNTY BOARD OF COUNTY COMMISSIONERS
CONTRACT SUMMARY
Contract with: William P. Horn
Contract #
Effective Date: 06/15/11
Expiration Date:
Contract Purpose/Description:
Professional Services from Design through Construction Administration for new
Playground Equipment as part of the Higgs
Beach Park Master Plan
Contract Manager: Ann Riger
X4439 Facilities Devel/Stop #1
(Name)
(Ext.) (Department/Stop #)
for BOCC meeting on 06/16/11
Agenda Deadline: 05/31/11
CONTRACT COSTS
Total Dollar Value of Contract: $ 146,382.50 Current Year Portion: $ 102,132.50
Budgeted? Yes® No ❑ Account Codes: 117-77040-530340-TM17735X-530340
Grant: $ N/A - - - -
County Match: $ N/A - - - -
ADDITIONAL COSTS
Estimated Ongoing Costs: $ /yr For:
(Not included in dollar value above) (eg. maintenance:
CONTRACT REVIEW
Changes Date Out
D to Needed - eview r ,
Division Director 4Q/// Yes❑ NoL
Risk Manage ent ? b Yes❑ Noa 14
O.M.B./Purc asing Yes❑ No[
County Attorney / Yes[:]No S
Comments:
(AMR Form Revised 2/27/01 MCP #2
FOURTH AMENDMENT TO
CONTRACT BETWEEN OWNER AND ARCHITECTIENGINEER
THIS FOURTH AMENDMENT (herein after "AMENDMENT") to the CONTRACT
BETWEEN OWNER AND ARCHITECT/ENGINEER ("CONTRACT") for the Higgs Beach
Park Master Plan, entered into between MONROE COUNTY (the "Owner" or "County'), and
WILLIAM P. HORN ARCHITECT, P.A. ("Architect/Engineer") is made and entered into this
15" day of June, 2011, in order to amend the CONTRACT, as follows:
WHEREAS, on the le day of December, 2009, the parties entered into a continuing contract for
projects in which the estimated construction costs of each individual project under the contract
does not exceed Two Million Dollars ($2,000,000.00), or for study activity if the fee for
professional services for each individual study under the contract does not exceed Two Hundred
Thousand Dollars ($200,000.00); and
WHEREAS, on the 17" day of March, 2010, the parties entered into a contract for an individual
study for the purpose of developing a Higg's Beach Park Master Plan; and
WHEREAS, on the 15s` day of December, 2010, parties entered into a First Amendment to
Contract extending the contract time by ninety days (90 days), from December 12, 2010 to
March 12, 2011; and
WHEREAS, the Owner approved Phase I of the Master Plan at its public meeting on January 19,
2011, and approved to proceed to Phase H of the Master Plan; and
WHEREAS, on the 16'h day of February, 2011, the parties agreed to a Second Amendment to
Contract Extending the Contract time to proceed with Phase H by One Hundred and Eighty Days
(180 days) from March 12, 2011 to September 8, 2011; and
WHEREAS, on the le day of May, 2011, the parties agreed to Additional Services in the
amount of $3,382.50; and
WHEREAS, the County wishes to have the "Architect/Engineer" design a playground area for
Phase One on the beach side of Higgs Beach, which will include demolition of presently existing
structures on the site of the playground, as well as playground equipment, and other items as part
of the Higgs Beach Park Master Plan design; and
WHEREAS, it is in the best interest of the public to have the design and related matters for the
beachside playground to be done by the Architect/Engineer who drafted the recently approved
Master Plan; now therefore
IN CONSIDERATION of the mutual promises contained herein, the parties hereby agree as
follows:
1. The original Agreement dated March 17, 2010, stated at Article 2.1.1 that, "The Architect is
not responsible for the development of construction documents". This paragraph was intended to
1 jPabe
limit the Agreement to the development and approval of the Master Plan so that the construction
could be done in segments as funding becomes available.
2. The original Agreement dated March 17, 2010 must be amended in order to allow the
Architect/Engineer to provide a design for the phase one playground area of the Higgs Beach
project, which requires development of constriction documents. It is the intent of the County to
amend the original agreement for this limited and specific purpose only.
Article II Scope of Architect/EngineWs Basic Services in the March 17, 2010 Agreement is
amended to add paragraph 2.1.4 to read as follows:
"2.1A Additional Basics services under Phase One shall include the design of a
new playground area beachside of the present road which bisects the site. This new
playground design will coordinate with the future location of the playground area
Per the master plan and still be completely usable as built. The scope of the work
shall include the creation of a site plan, design plan and details, development of the
constriction drawings and specifications including demolition of cabanas, a design
for fencing, playground equipment, additional sand, sidewalk renovations, and
relocation of recycle area and other related items. The design and specifications
shall be done in a manner which will enable the County to have the project
Permitted, and redesigned if necessary until a permittable design is attained The
Iump sum amount for this portion shall be Eight Thousand Dollars ($8,000.00).
The Architect/Engineer shall also assist in the bidding phase by at the pre -
bid meeting attendance to answer questions, and to assist in the response to any
bidding questions during bidding process, and to assist in the bid review. The lump
sum amount for this portion shall be One Thousand Dollars ($1,000.00).
In addition, during the construction administration phase, the Architect shall assist
by providing the construction administration on the new playground area by
providing administration of the Owner/Contractor contract which shall include site
visits, review of shop drawings and schedule of values, and timely responses to
Requests for Information from the contractor or the County. The ArchitecUEngineer
shall review any as -built drawings furnished by the Contractor and shall certify to
the Owner that same are adequate and complete. The Architect/Engineer shall,
without additional compensation, promptly correct any errors, omissions,
deficiencies, or conflicts in the work product of the ArchiteatEngineer or its
consultants, or both.
Upon receipt, the Architect/Engineer shall carefully review and examine
the Contractor's Schedule of Values, together with any supporting documentation or
data which the Owner or the Architect/Engineer may require from the Contractor.
The purpose of such review and examination shall be to protect the Owner from an
unbalanced Schedule of Values which allocates greater value to certain elements of
the Work than is indicated by such supporting documentation or data, or than is
reasonable under the circumstances. The site visits Architect/Engineer shall
carefully inspect the work of the Contractor and shall, at a minimum, inspect work
at the Project site during the constriction and at the end of the construction. The
purpose of such inspections shall be to determine the quality and quantity of the
21Page
work in comparison with the requirements of the Construction Contract. In malting
such inspections, the Architect/Engineer shall protect the Owner from continuing
deficient or defective work, from continuing unexcused delays in the schedule and
from overpayment to the Contractor. Following each inspection, the
Architect/Engmeer shall submit a written report of such inspection, together with
any appropriate comments or recommendations to the Owner. Due to the small size
of the project this report may be made via email and is not expected to be as
intensive and formal as expected on large projects. The Architect/Engineer shall
review any as -built drawings furnished by the Contractor and shall certify to the
Owner that same are adequate and complete. The Architect/Engineer shall, without
additional compensation, promptly correct any errors, omissions, deficiencies, or
conflicts in the work product of the Architect/Engineer or its consultants, or both.
The lump sum amount for this portion shall be Two Thousand Dollars ($2,000.00).
The Owner and the Architect/Engineer agree that cost of this specific
scope of work, inclusive of any subcontractors of the Architect/Engineer, for this
playground design and related items shall not exceed the total lump sum amount of
Eleven Thousand Dollars ($11,000.00), and no additional services shall be awarded
for this scope of work. '
1. In addition, Article VIII shall be amended to change the fee schedule at 8.1.1.A of the
March 17, 2010 Agreement, to read as follows:
"8.I.1.A - Phase One Fees
Architectural, Planner, Civil, etc . .......................................... $45,000.00
Surveyor............ .......................................................... $10,500.00
Revisions to Master Plan Phase I ...........................................$ 3,382.50
(pursuant to Third Amendment dated May 18, 2011)
Design for Phase One Playground Total... $11000 00
-Design, Construction Documents and Specifications Fee.. $8,000
-Bidding Phase Fee .............................................. $1,000
-Construction Administration Fee..............................$2,000
(pursuant to Fourth Amendment)
Phase One
Total...........................................................................$69,882.50
8.1.1. B - Phase Two Fees
Architectural, Planner, Landscape Design,
Civil Engineering, Lighting Engineering,
Studies and assessments. etc ............ ..................................... $76.500.00
Phase Two Total ............... .............................................. $76,500.00
8.1. LC — Total Contract Sum
PhaseOne ......... .......................................................... $69,882.50
PhaseTwo ............................................. .. $76 500 00
Total Contract Sum ....................................... .............$146,38250
3f Page
At this time the number of buildings (now and/or to be nmovated) is ud nown.
Therefore the above costs are based on desiga work for four (4) buildings.
Additional buildings will be billed as stated below.
Any additional work far Phase One or Phase Two can be completed at a fixed fee,
which will be stated in Amendment form or at the standard hourly rates listed in
Exhibit A of the Agreement dated March 17, 2010. All Amendments or agreements
for use of standard rates shall be in writing and executed in the same formalities as
this Amendment and die Agreement dded Mare 17, 2010
The Tote! Contract Sum is $146,382.50 (one h®dred forty-six thousand three
hundred and eighty-two dollars and fliiy tents)."
2. The remaining terms of the CONTRACT, not inconsistent herewith, shall remain in full
force and effect.
IN WTTNESS VIBMEOF, the parties hereto have exectftd this Fourth Amendment on the date
stated above. Execution by the Ard*ed/Fngu m must be by a person with authority to bind
the entity.
Attest: DANNY L_ KOLHAGE, CLERK
By:
Deputy Clerk
Date:
(SEAL)
Witnesses ft
Witness 1:
Print Name:
Witness 2: _
Print Name.
BOARD OF COUNTY COAT MMSIONERS
OF MONROE
COUNTY, FLORIDA
By:
Mayor
ARCHPPECT���[tC�EER
WUIJAM P. ARCHTFECT, P.A.
By. %----
Print Name• 4L a Aa
Title:._ IvL1�p
Dam
STATE OFFLORMA
COUNTY OF� _
On this Z. -t day of a 2011, before me, the xmdetsww notary Public, Personally apparedl�/ �ls�
known to me bo Person whose name is subscribed above or who produced
as man, and axlmowiedged tint she is the person who executed the above Fourth Amendment
with Monroe Comity for itect/ agineering for the ITw Beach Park for the purposes therein
'red.
s
NOTARY PUBLICSTATE OB FLORIDAh
David w. Gangwi
�zz o . �a ••� u My commission expires:; �adssioa # EE032991
Print Name Expires: ° OCT. 0812014
''•.,,,,, 0 CO. 1NC.
BMED
ggRU ATLAh'T1C BO:IDIN
MON E COUNTY ATTORNEY 4�Page
A ROVED AS TO F
ATI EENE C SSEL
ASSISTANT COl1NTY ATTORNEY
ate— 2.:--,Q
I' 1 AAffaUffNT TO
THIS THIRD AMENDMENT (herein after "AMENDMENT") to the
CONTRACT BETWEEN OWNER AND ARCHiTECT/ENGINEER
("CONTRACT") for the Higgs Beach Park Master Plan, entered into between
MONROE COUNTY (the "Owner" or "County"), and WILLIAM P. HORN
ARCHITECT, P.A. ("Architect/Engineer") is made and entered into this 180` day of
May, 2011, in order to amend the CONTRACT, as follows:
WITNESSETH
WHEREAS, on the 16a' day of December, 2009, the parties entered into a continuing
contract for projects in which the estimated construction costs of each individual
project under the contract does not exceed Two Million Dollars ($2,000,000.00), or
for study activity if the fee for professional services for each individual study under
the contract does not exceed Two Hundred Thousand Dollars ($200,000.00); and
WHEREAS, on the 17* day of March, 2010, the parties entered into a contract for an
individual study for the purpose of developing a Higg's Beach Park Master Plan; and
WHEREAS, on the I P day of December 2010, the parties agreed to a First
Amendment to Contract extending the contract time by ninety days (90 days), from
.December 12, 2010 to March 12, 2011; and
WHEREAS, the Owner approved Phase I of the Master Plan at its public meeting on
January 19, 2011 and approved to proceed to Phase H of the Master Plan; and
WHEREAS, on the I e day of February, 2011, the parties agreed to a Second
Amendment to Contract Extending the Contract time to proceed with Phase If by One
Hundred and Eighty Days (I So days) from March 12, 2011 to September 8, 2011; and
WHEREAS, in accordance to the Contract of March 17, 2010, Additional Services
may be performed by the Architect only after receiving an Amendment to the
Agreement and a Notice to Proceed from the Owner; now therefore
IN CONSIDERATION of the mutual promises contained herein, the parties hereby
agree as follows:
1. Revisions to the Master Plan phase I, approved by the Board of County
Commissioners on January 19, 2011 required additional fees incurred by the
Architect/Engineer in the amount of $3,382.50, which will be paid by the Owner as
Additional Services.
Page 1 of 2 Amendment 3 to the Horn/Higg's Beach Corawt
s
2. The remaining terms of the CONTRACT, not inconsistent herewith, shall
remain in full force and effect.
IN WITNESS WHEREOF, the parties hereto have executed this Amendment on the date
stated above.
the Architect/Engineer must be by a person with authority to bind the entity.
L. KOLHAGE, CLERK
Dati:
(SEAL)
Attest:
By:
Print Name:
Title:
Date:
Or:
Witness 1:
Print Na
Witness 2:
Print Name:
BOARD OF COUNTY
COMMIISSIO OF MONROE
COUNTY, FL
O
By:
May r/C '
ARCHITECT GINEER
WILLIAM P. RN ARCHITECT, P.A.
By:
Print ame: 4A1Y► pt 13A
Title:
Date:
MONROE COUNTY ATTORNEY
,APROVED AS TO FjgAM:
/ NATILEENE W. CASSEL
ASSISTA T C-WNTY ATTORNEY
STATE OF FLORIDA Date- -
3 --//
COUNTY OF 749Aad 4,
On this +' day of_,j?aV . 2011, before me, the undersigned notary public, personally appeared _
known to me. (o be -the person whose name is subscribed above or who produced —
as identification, and acknowledged that he/she is the person who executed the
above4 fm di rment with Monroe County for Architect/Engineering services for the Higgs Beach Park
Masts for the pupoM therein contained
Notary Public
Print Name
My commission expires: 7NNKNNIW--
9► iNdr~
v, cmMunbowidii..,
s� commWo f 00 iriiM
Page 2 of 2 Amendment 3 to the Hornhiigg's Beach Contract
WILUAR P. MORNARCHITECT, P.A.
015 EATON Sr.
KEY WEST, FL. 33W
TEL (305J29"W2
FAX No. (3W n&1033
TO: mvmww OOt/1 ff#ztaROl11
11M &WDI rION STMEET, RE2-216
A7TN.JERRYBARNETT
3fiwA6Ell/
IZY VMWT, JFL 23M
PROJECT_
CLARENCEHIGGS BEACH
ADDITIONAL SERVIM
(RE"ING PLAN A FINAL REPORT TO
INCLUDE OPTNON'P)
INVOICE
PROJECT' CLARENCEHIGGS BEACH
I DATE--' FEBRUARY 11I 2011
PROJECTMm 1004
IDATESTARM. JANIIARY7 2011
INVOICE No. 1004MMMISANLEW
InATECOMPLETISMANUARY21, 2011
TIME
SERVICEJAES
OESCWPTION
RATF*MR
TOTAL
3.50
PRINCIPALNG
PLANE' TO PLAN T', COORDINATING
$195.00
5682.50
ONS TO PLAN AND FINAL REPORT, DEUVER
TS.
4.5
KrERN ARCH
REVISIONS TO PLAN, INSERT REVISED
$100.00
$450.00
IN REPORT 12 BOOKS
7.5
LANDSCAPE
GRAPHICS OF REPORT. COORDINATE
S150.00
$1125M
ARCHITECTNTING.
7.5
PLANNERNG
TEXT OF REPORT RE -CALCULATE SITE
$150.00
$1 125.00
TOTAL
$3.382.50
'
CREDITS
CK. No.
DESCRIPTION
RATEMOUR
TOTAL
TOTAL
$3,382.50
TOP NHOH d NQVVI17IA OUT M 20C YV3 BT : tT TT/ZO/SO
Mitchell Planning and Design, Inc.
Mitchell Planning & Design Inc.
15450 SE 103rd Place Road
Ocklawaha, Florida 32179
Phone: 352.288.0401
Cell: 305.509.0966
January 25, 2011 Email: mitchellplanningdesign@gmail.com
Mr. Bill Horn
915 Eaton Street
Key West, Florida 33040
Project: Higgs - Phase 1
Additional Tasks
INVOICE
Date Description Amount Due
01.10.11 Revise Higgs Beach Final Report per Mayor Carruthers
Request
1.5 hrs $150.00 $225.00
01.12.11 Research and provide Planning Reports for Park
Redevelopment & vagrants, start recalculation of use
areas based on Option F
2.5 hrs $150.00 $375.00
01.12.11 Complete analysis of use areas, forward to Commissioner
Carruthers office
3.5 hrs $150.00 $525.00
Due Upon Receipt: TOTAL: $1,125.00
Please Remit to Above Address
THANK YOUR
Invoice
Date Invoice #
2/11/2011 233
I Bill To I
William Horn Architect, PA
William Horn
915 Eaton Street
Key West, FL 33040
LANDWISE
D E S 1 G N
4073 San Juan Avenue
Jacksonville, FL 32210
Item
Description
4ty
Rate
Amount
Design Service
Additional Services for Staff Requested Revisions
7.5
150.00
1,125.00
to Master Plan Report
Thank You.
Total $1,125.00
MONROE COUNTY PROJECT MANAGEMENT
DEPARTMENT
M E M O R A N D U M
DATE: 4/20/11
TO: MCBOCC
FROM: Jerry A. Barnett, Director)
M.C. Project Management Dept.
RE: Contract Amendment for William P. Horn Architect. Higgs Beach Master Plan
In early Jan. 2011 changes were requested by Mayor Carruthers to the Higgs Beach Master
Plan. The plan had been completed and had been printed and bound for presentation to the
BOCC at the Jan. 191h, 2011 monthly meeting.
The requested changes required additional services to be provided by the architect and his
consultants incurring additional cost. These changes were made, printed and placed in the
report for distribution.
An agreement was made with the architect to allow the additional services and a verbal Notice
to Proceed was issued by the Director of Project Management for approval of and
commencement of the additional services. The use of a verbal Notice to Proceed was due to a
very limited time frame to complete the work before the scheduled BOCC meeting. An email
was issued to the architect with this information but is no longer retrievable.
The invoice from William P. Horn Architect dated Feb. 181h, 2011 for $3,382.50 is for the
requested additional services.
THIS SECOND AMENDMENT (herein after "AMENDMENT") to the
CONTRACT BETWEEN OWNER AND ARCHITECT/ENGINEER ("CONTRACT")
for the Higgs Beach Park Master Plan, entered into between MONROE COUNTY (the
"Owner" or "County"), and WILLIAM P. HORN ARCHITECT, P.A.
("Architect/Engineer") is made and entered into this 16th day of February, 2011, in order
to amend the CONTRACT, as follows:
WITNESSETH
WHEREAS, on the 16th day of December, 2009, the parties entered into a continuing
contract for projects in which the estimated construction costs of each individual project
under the contract does not exceed Two Million Dollars ($2,000,000.00), or for study
activity if the fee for professional services for each individual study under the contract
does not exceed Two Hundred Thousand Dollars ($200,000.00); and
WHEREAS, on the 17a` day of March, 2010, the parties entered into a contract for an
individual study for the purpose of developing a Higg's Beach Park Master Plan; and
WHEREAS, on the 15`h day of December 2010, the parties agreed to a First Amendment
to Contract extending the contract time by ninety days (90 days), from December 12,
2010 to March 12, 2011; and
WHEREAS, the Owner approved Phase I of the Master Plan at its public meeting on
January 19, 2011 and approved to proceed to Phase II of the Master Plan; and
WHEREAS, in accordance to the Contract of March 17, 2010, an extension of time at no
additional cost to the county may be granted in the form of an Amendment to the
Contract; now therefore
IN CONSIDERATION of the mutual promises contained herein, the parties hereby agree
as follows:
1. The contract time shall be extended to proceed to Phase II by One Hundred and
Eighty Days (180 days) from March 12, 2011 to September 8, 2011
2. The remaining terms of the CONTRACT, not inconsistent herewith, shall remain
in full force and effect.
IN WITNESS WHEREOF, the parties hereto have executed this Amendment on the date
stated above.
BALANCE OF PAGE INTENTIONALLY LEFT BLANK
SIGNATURE PAGE TO FOLLOW
Page 1 of 2 Amendment 2 to the Horn/Higg's Beach Contract
7
Execution by the Architect/Engineer must be by a person with authority to bind the entity.
SIGNATURE OF THE PERSON EXECUTING THE DOCUMENT MUST BE
N,Q_9,4.IRIZED AND WITNESSED BY ANOTHER OFFICER OF THE ENTITY.
t;ltttiNNY L. KOLHAGE, CLERK
� B�
lerk
(SEAL)
Attest:
By:
Print Name:
Title:
Date:
Or:
Witness l: 1
Print Name:
Witness 2: ` >�
Print Name:
STATE OF FLORIDA
COUNTY OF M,
BOARD OF COUNTY
COMMISSIONERS OF MONROE
COUNTY, FLORI A
By:
Mayovilailw
ARCHITECT/ENGINERR-
WILLIAM P. HORN AR TECT, P.A.
By:
Print Name: W,'GL%n, A�
Title:
Date:
MONROE COUNTY ATTORNEY
A ROV AS To F)
� - ,
NATILEENE W. CAS EL
SSISTANT QOUNTY ATTORNEY
®ate
On this I s' day of%, 2011, before me, the undersigned notary public, personally appeared
known to me to be the person whose name is subscribed above or who produced
ks� as identification, and acknowledged that he/she is the person who executed the
above Amendment with Monroe County for Architect/Engineering services for the Higgs Beach Park
Master P or the purposes them contained.
NATrPublic
Print Name
My commission expires:
I9tt11t
�lPgd le NN6 - �d �+RoN
._. Y301Y'11MIV
Page 2 of 2 Amendment 2 to the Horn/Higg's Beach Contract
Y =
FIRST AMENDMENT TO
CONTRACT BETWEEN OWNER AND ARCHITECT/ENGINEER
THIS FIRST AMENDMENT (herein after "AMENDMENT") to the
CONTRACT BETWEEN OWNER AND ARCHITECT/ENGINEER ("CONTRACT')
for the Higgs Beach Park Master Plan, entered into between MONROE COUNTY (the
"Owner" or "County"), and WILLIAM P. HORN ARCHITECT, P.A.
("Architect/Engineer') is made and entered into this 1 P day of December 2010, in order
to amend the CONTRACT, as follows:
WITNESSETH
WHEREAS, on the 16'h day of December, 2009, the parties entered into a continuing
contract for projects in which the estimated construction costs of each individual project
under the contract does not exceed Two Million Dollars ($2,000,000.00), or for study
activity if the fee for professional services for each individual study under the contract
does not exceed Two Hundred Thousand Dollars ($200,000.00); and
WHEREAS, on the 171h day of March, 2010, the parties entered into a contract for an
individual study for the purpose of developing a Higg's Beach Park Master Plan, and
WHEREAS, in accordance to the contract of March 17, 2010 the contract expiration is
two hundred and seventy days (270 days) from the contract date or December 12, 2010;
now therefore
IN CONSIDERATION of the mutual promises contained herein, the parties hereby agree
as follows:
1. The contract time shall be extended by ninety days (90 days), from December 12,
2010 to March 12, 2011.
2. The remaining terms of the CONTRACT, not inconsistent herewith, shall remain
in full force and effect.
IN WITNESS WHEREOF, the parties hereto have executed this Amendment on the date
stated above.
BALANCE OF PAGE INTENTIONALLY LEFT BLANK
SIGNATURE PAGE TO FOLLOW
Amend #1
by the Architect/Engineer must be by a person with authority to bind the entity.
JRE OF THE PERSON EXECUTING THE DOCUMENT MUST BE
ED AND WITNESSED BY ANOTHER OFFICER OF THE ENTITY.
L. KOLHAGE, CLERK
Deputy
Date: DEC 1 r 2010
(SEAL)
Attest:
By:
Print Name:
Title:
Date:
Or:
Witne
Print I
Witne:
Print Name: Z1. `R; &(2
BOARD OF COUNTY
COMMISSIONERS OF MONROE
COUNTY, FLORIDA
By:
Mdyor/Chffirinan
ARCHITECT/ENG - ER
WILLIAM P. HORN CHITECT, P.A.
By:
Print Name: Wf "Ile l ;,a , 6f l/Ij
Title: L
Date: v d
STATE OF FLORIDA
COUNTY OF . _ fly/ t1 �-
On this �ayofTnj.� ., 20i0, before me, the undersigned notary public, personally appeared
%1 / fkr A,l known to me to be the person whose name is subscribed above or who produced
as identification, and acknowledged that he/she is the person who executed tl e
above Amendment with Monroe County for Architect/Engineering services for the Higgs Beach Park
Master an 'or the purposes therein contained.
No Public
Print Name
My commission expires: /�-
2 Amend #1
I
f
CONTRACT FOR
PROFESSIONAL SERVICES
BETWEEN OWNER AND ARCHITECUENGINEER
THIS CONTRACT FOR PROFESSIONAL SERVICES BETWEEN OWNER AND
ARCHITECT/ENGINEER (the "Contract" or "Agreement") is made and entered into by
Monroe County ("Owner" or "County'l, a political subdivision of the State of Florida,
whose address is 1100 Simonton Street, Key West, Florida 33040, its successors and
assigns through the Monroe County Board Of County Commissioners ("BOCC'j, and
William P. Horn, Architect. P.Athe ( "Architect')., whose address is 915 Eaton St.
Key West, FL 33040, its successors and assigns.
This contract shall be effective on the date of execution by the last party signatory to the
contract.
This contract is issued under a continuing contract awarded to William P. Hom Architect.
P.A. by Monroe County pursuant to Florida Statute 287.055(2) ().
The professional services required by this Contract are to be rendered for a project for
study activity that the fee for professional services for each individual study under the
contract does not exceed Two Hundred Thousand Dollars ($200,000.00).
The professional services required by this contract will be for services in the form of
developing a Higg's Beach Park Master Plan, commencing on the effective date of this
contract and ending 270 days from the commencement date. An extension of time at no
additional cost to the County, in the form of an amendment to this contract, may be
granted only by BOCC approval.
The terms and conditions of the Continuing Contract shall apply to this contract, unless
expressly modified in the provisions of this contract Where the terms of the Continuing
Contract differ from the terms of this contract, the terns of this contract shall take
precedence. This contract will contain a specific scope of wort
NOW, THEREFORE, in consideration of the mutual promises, covenants and
agreements stated herein, and for other good and valuable consideration, the sufficiency
of which hereby acknowledged, the Owner and the Architect agree:
ARTICLE 1
1.1 REPRESENTATIONS AND WARRANTIES
By executing this Contract, Architect makes the following express representations and
warranties to the Owner:
1.1.1 The Architect is a professional qualified to act as the Architect for the Project and
is licensed to practice Architecture Engineering by all public entities having jurisdiction
over the Architect/Engineer and the Project,
1.1.2 The Architect shall maintain all necessary licenses, permits or other
authorizations necessary to act as Architect for the Project until the Architect's duties
hereunder have been fully satisfied;
1.1.3 The Architect shall become familiar with the individual Project site and the local
conditions under which the Project is to be designed
1.1.4 The Architect shall prepare all documents required by this Contract including„ but
not limited to, all contract Master Plans and Specifications, in such a manner that they
shall be in conformity and comply with all applicable law, codes and regulations. The
Architect warrants that the documents prepared as a part of this Contract will be adequate
and sufficient to accomplish the purposes of the Project, therefore, eliminating any
additional design costs due to missing or incorrect design elements in the contract
documents;
1.1.5 The Architect assumes full responsibility to the extent allowed bylaw with
regards to his performance and those directly under his employ as Architect of Record
1.1.6 The Architect's services shall be performed as expeditiously as is consistent with
professional skill and care and the orderly progress of the Work. The Architect shall
submit, for the Owner's and Monroe County Project Management Department's
information, a schedule for the performance of the Architect's services which may be
adjusted as the Project proceeds if approved by the Owner, and shall include allowances
for periods of time required for the Owner's and Monroe County Project Management
Department's review, and for approval of submission by authorities having jurisdiction
over the Project. Time limits established by this schedule and approved by the Owner
may not be exceeded by the Architect except for delay caused by events not within the
control of the Architect or foreseeable by him.
1.1.E In providing all services pursuant to this agreement, the Architect shall abide by
all statutes, ordinances, rules and regulations pertaining to, or regulating such services,
including those now in effect and hereinafter adopted. Any violation of said statutes,
ordinances, rules and regulations shall constitute a material breach of this agreement and
shall entitle the COUNTY to terminate this agreement immediately upon delivery of
written notice of termination to the Architect.
ARTICLE II
SCOPE OF ARCHITECT/ENGINEER'S BASIC SERVICE
2.1 DEFINITION
2.1.1 Architect's Basic Services consist of those described in Paragraphs 2.2 through
2.3 and other services identified as part of Basic Services, and include normal, civil,
structural, mechanical, and electrical engineering services as required for this project.
2.1.2 The Master Plan shall include, but shall not necessarily be limited to, plans and
specifications that describe all systems, elements, details, components, materials,
equipment, and other information necessary for the development and approval of the
Master Plan. The Master Plan shall be accurate, coordinated and in all respects adequate
for approval of the Development Plan and shall be in conformity, and comply, with all
applicable law, codes, permits, and regulations. Products, equipment and materials
specified for use shall be readily available unless written authorization to the contrary is
given by the Owner. The Architect is not responsible for the development of
Construction Drawings.
2.1.3 These services shall include, but not be limited to: Preparation and completion of
the design program for space requirements and relationships, schematic design, design
development, cost estimating during design and document preparation, preparation and
submittal of approval applications, zoning applications, public presentations and
Presentations to the County Commission. Architect shall arrange his schedule in order to
be available to perform the listed services for the project as requested by COUNTY and
with the understanding that for any individual project the costs will not exceed the limits
under F.S. 287.055 (2)(g).
2.2 PHASE ONE, SCHEMATIC DESIGN
2.2.1 The Architect shall review the County's program, schedule and budget furnished
by the Owner to ascertain the requirements of the Project and shall arrive at a mutual
understanding of such requirements with the Owner.
2.2.2 The Architect shall review with the Owner and Monroe County Project
Management Department's proposed site use and improvements, required approvals,
zoning; selection of materials, building systems and equipment; and method of Project
delivery.
2.2.3 The Architect shall review with the Owner and Monroe County Project
Management Department's alternative approaches to design of the Project
2.2.4 Based on the mutually agreed -upon program, schedule and budget requirements,
the Architect shall prepare, for approval by the Owner, Schematic Design Documents
consisting of drawings and other documents illustrating the scale and relationship of
Project components.
2.2.5 Upon completion of the Schematic Design Phase, the Architect shall provide
drawings, outline specifications, estimate of anticipated cost in accordance with the
schematic designs, and other documents for the Owner's approval and the Monroe
County project Management Department's information.
2.2.6 The Schematic Design must be approved in writing, by the Owner prior to
Architect continuing to Phase Two of the Master Plan.
2.2.7 During the development of the Master Plan the Architect will plan, arrange and
conduct Public Meetings and all other meetings as indicated in his proposal that is
attached to and is part of this contract. Upon agreement between the County and the
Architect (the total number of meetings shall remain the same) the number of meetings
with individual committees, boards, staff, and etc. can be modified and scheduled as
needed. The Architect shall provide for recording and distributing meeting minutes. The
County will provide the space for the Public Meetings and meetings with county staff and
committees. Advertising for Public Meetings will be the County's responsibility.
2.2.8 The Architect shall take into consideration, for the development of the Master
Plan, information acquired through meetings identified in 2.2.7 and shall review other
Master Plans generated in the past regarding Higgs Beach Park.
2.2.9 The County, at its discretion, reserves the option to and the project with the
completion of Phase One and not proceed to Phase Two. 'If the County chooses this
option the Architect shall be paid for work completed on .Phase One but will not receive
any additional funds unless instructed in writing to proceed with Phase Two.
2.3 PHASE TWO, DESIGN DEVELOPMENT DOCUMENTS
AND APPROVALS
2.3.1 Upon completion of Phase One, and with written approval from the County, the
Architect shall proceed to Phase Two and provide drawings, outline specifications and
other documents for the Owner's approval and the Monroe County Project Management
Department's information for submittal by the Architect to the City of Key West for
development review and approval. The Architect shall provide an estimate of anticipated
costs in accordance with Phase Two design documents.
2.3.2 The Phase One Documents must be approved in writing, by the Owner prior to
Architect continuing to Phase Two.
2.3.3 The Architect shall provide all Drawings and Specifications required by the City
of Key West's development Review Board for Development Approval and for the
Owner's and the Monroe County Project Management Department's review.
4
2.3.4 The Architect shall submit to the City of Key West the above mentioned
documents and information for obtaining Development Approval from the City of Key
West.
2.3.5 The Architect's Development Approval documents (plans, specifications, etc.)
will conform to all written codes and regulations of the federal government, county, state,
municipalities, agencies and state departments, in effect at the date of this Agreement,
and shall be of such completion as to receive all approvals when applied for. If approvals
are denied, then the Architect will conform the documents in such manner to receive
approvals upon such plans. Work required from the Architect to conform the documents
to federal, state, city, county, or agency specifications and approval requirements to allow
thew to be approved shall be completed at no additional cost to the Owner.
2.3.6 Duties, responsibilities and limitations of authority of the Architect shall not be
restricted, modified or extended without written agreement of the Owner and Architect.
2.3.7 The Architect shall make available to the Owner any personnel or consultants
employed or retained by the Architectfor the purpose of reviewing, studying, analyzing
or investigating any claims, contentions, allegations, or legal actions relating to, or arising
out of, the design of the project.
2.3.8 The Architect shall without additional compensation, promptly correct any errors,
omissions, deficiencies, or conflicts in the work product of the Architect or its
consultants, or both.
ARTICLE III
ADDITIONAL SERVICES
3.1 GENERAL
3.1.1 The services described in this Article III are not included in Basic Services. They
shall be paid for by the Owner as provided in this agreement as an addition to the
compensation paid for the Basic Services but only if approved by the Owner before
commencement, and as follows:
A. Providing services of Architect for other than the previously listed consulting
scope of Project provided as a part of Basic Services.
B. Providing any other services not otherwise included in this Agreement or not
customarily furnished in accordance with generally accepted consulting
practice.
3.2 If Additional Services are required, such as those listed above, the Owner
shall issue a letter requesting and describing the requested services to the Architect. The
Architect shall respond with fee proposal based on hourly fees listed on Exhibit A to
5
perform the requested services. Only after receiving an amendment to the Agreement and
a notice to proceed from the Owner proceed with the Additional Services.
ARTICLE IV
OWNER'S RESPONSIBILITIES
4.1 The Owner shall designate Monroe County Project Management Department to
act on the Owner's behalf with respect to the Project. The Owner or Monroe County
Project Management Department shall render decisions in a timely manner pertaining to
documents submitted by the Architect in order to avoid unreasonable delay in the orderly
and sequential progress of the .Architect's services. However, the parties acknowledge
that due to Monroe County Policy, Ordinances or State or Federal Statute there may be
times when a decision must be made by the BOCC, in which case any delay shall not be
attributed to Monroe County or its representative.
4.2 Prompt written notice shall be given by the Owner and Monroe County Project
Management Department to the Architect if they become aware of any fault or defect in
the Project or non-conformance with the Contract Documents.
4.3 The Owner shall furnish the required information and services and shall render
approvals and decisions as expeditiously as necessary for the orderly progress of the
Architect's services.
4.4 The Owner's review of any documents prepared by the Architect or its consultants
shall be solely for the purpose of determining whether such documents are generally
consistent with the Owner's criteria, as and i4 modified. No review of such documents
shall relieve the Architect of responsibility for the accuracy, adequacy, fitness, suitability
or coordination of its work product.
ARTICLE
CONSTRUCTION COSH
5.1 The Architect shall provide an Estimated Construction Cost for the total project.
6.1 The Architect covenants and agrees to indemnify and hold harmless
Owner/Monroe County and Monroe County Board of County Commissioners from any
and all claims for bodily injury, including death, personal injury, and property damage,
including property owned by Monroe County, and any other losses, damages, and
expenses, including attorneys fees, court costs and expenses, which arise out of, in
connection with, or by reason of services provided by the Architect or its
Subcontractor(s), occasioned by the negligence, errors, or other wrongful act or omission
of the Architect, their employees, or agents.
6.2 The first ten dollars ($10.00) of remuneration paid to the Architect is for the
indemnification provided for above. Should any claims be asserted against the County by
virtue of any deficiency or ambiguity in the plans and specifications provided by the
Architect, the Architect agrees and warrants that he shall hold the County harmless and
shall indemnify him from all losses occurring thereby and shall further defend any claim
or action on the County's behalf.
6.3 • In the event the completion of the project (to include the work of others) is delayed
or suspended as a result of the Architect's failure to purchase or maintain the required
insurance, the Architect shall indemnify County from any and all increased expenses
resulting from such delays. Should any claims be asserted against County by virtue of
any deficieneies'or ambiguity in the plans and specifications provide by the Architect the
Architect agrees and warrants that Architect hold the County harmless and shall
indemnify it from all losses occurring thereby and shall further defend any claims or
action on the County's behalf.
6.4 The extent of liability is in no way limited to, reduced or lessened. by the insurance
requirements contained elsewhere within the Agreement.
6.S This indemnification shall survive the expiration or early termination of the
Agreement.
ARTICLE VII
7.1 PERSONNEL
The Architect shall assign only qualified personnel to perform any service concerning the
project.
ARTICLE VIII
8.1 PAYMENT
Payment shall be the agreed to lump sum and will be distributed on a monthly basis as
described below. Additional services will be based on hourly rates to be approved by the
County. Hourly rates are provided in Exhibit A and are subject to annual affirmation.
Details ofpayment are as specified below.
&1.1 The Architect shall submit monthly, unless otherwise agreed in writing by the
Owner, an invoice to the Owner requesting payment for services properly rendered and
reimbursable expenses due hereunder. The Architect's invoice shall describe with
reasonable particularly the services rendered For billing purposes, the project shall be
divided into two portions, known as the Beach side and the Land side. The Architect
shall identify that portion of work completed for the Beach side of the park and that
portion of work completed for the Land side of the park separately. The boundary line
between the two shall be the centerline of Atlantic Boulevard passing through the Park.
The Architect's invoice shall be accompanied by such documentation or data, as required
by the Owner, in support of expenses for which payment is sought.
7
8.1.1.A - Phase One Fees
Architectural, Planner, Civil, etc .................................. $45,000.00
Surveyor $ 10 500 00
Phase One Total.........................................................$55,500.00
8.1.1.B - Phase Two Fees
Architectural, Planner, Landscape Design,
Civil Engineering, Lighting Engineering,
Studies and assessments. etc. $76 500 00
Phase Two Total ............................................... .... $76,500.00
8.1.1.0 - Total Contract Sum
PhaseOne .......................................................... .$55,500.00
Phase Two $76 500 00
Tot2l Contract Sum..............................................$132,000.00
At this time the number of buildings (new and/or to be renovated) is unknown. Therefore
the above costs are based on design work for 4 (four) buildings. Additional buildings
will be billed as stated below.
Any additional work for Phase I or Phase H can be completed at a fixed fee (to be
determined) or at the standard hourly rates listed in Exhibit A.
The Total Contract Sum is ......... S132,000.00 (one hundred thirty-two thousand
dollars and no cents)
8.2 REIMBURSABLE EXPENSES
All reimbursable expenses are included in the Total Contract Sum, however prior to
incurring any additional expense written approval for that expense must be obtained in
writing from the County.
8.3 BUDGET
8.3.1 The Architect may not be entitled to receive, and the County is not obligated to
pay, any fees or expenses in excess of the amount budgeted for this Agreement in each
fiscal year (October I- September 30) by County's Board of County Commissioners.
The budgeted amount may only be modified by an affirmative act of the County's Board
of County Commissioners.
8.3.2 AVAILABILITY OF FUNDS. If funding cannot be obtained or cannot be
continued at a level sufficient to allow for continued reimbursement of expenditures for
services specified in this Contract the agreement may be terminated immediately at the
option of the County by written notice of termination delivered to the Architect. The
County shall not be obligated to pay for any services provided by the Architect after the
Architect has received written notice of termination, unless otherwise required by law.
8.3.3 Monroe County's performance and obligation to pay under this contract is
contingent upon an annual appropriation by the Board of County Commissioners and the
approval of the Board members at the time of contract initiation and its duration.
ARTICLE IX
9.1 APPLICABLE LAW
This contract is governed by and construed in accordance with the laws of the State of
Florida applicable to contracts made and performed entirely in the State. Venue for any
mediation, dispute conferences or litigation arising under this contract must be in Monroe
County, Florida. The Parties waive their rights to a trial by jury.
10.1 OWNERSHIP OF THE PRELIMINARY DESIGN AND THE DESIGN
DOCUMENTS
10.1 The Drawings, Specifications and other documents prepared by the Architect for
this project are instruments of the Architect's service for use solely with respect to this
project, and the Architect shall be deemed the author of these documents and shall retain
all common law, statutory and other reserved rights, including reproducible copies, of the
Architect's Drawings, Specifications and other documents shall not be used by the Owner
on other projects except by agreement in writing and with appropriate compensation to
the Architect.
10.1.2 Submission or distribution of documents to meet official regulatory requirements
or for similar purposes in connection with the project is not to be construed as publication
in derogation of the Architect's reserved rights.
10.1.3 The Owner may utilize the documents as required for reference on any necessary
future work on the site, and for constructin& using and maintaining the Project:
11.1 SUCCESSORS AND ASSIGNS
The Architect shall not assign its right hereunder, excepting its right to payment, nor shall
it delegate any of its duties hereunder without the written consent of the Owner. The
Owner and Architect, respectively, bind themselves, their partners, successors, assigns
and legal representatives to the other party to this Agreement and to the partners,
successors, assigns and legal representatives of such other party with respect to all
covenants of this Agreement.
9
ARTICLE XII
NO THIRD PARTY BENEFICIARIES
AND INDEPENDENT CONTRACTOR RELATIONSHIP
12.1 NO THIRD PARTY BENEFICIARIES
Nothing contained herein shall create any relationship, contractual or otherwise, between
the parties which creates or gives rise to any rights in favor of, any third party.
12.2 INDEPENDENT CONTRACTOR RELATIONSHIP
The Architect is and shall he an independent contractor in the performance of all work,
services, and activities under this Agreement and is not an employee, agent or servant of
the County. The Architect shall exercise control over the means and manner in which it
and its employees perform the work and in all respects the Architect's relationship and
the relationship of its employees to the County shall be that of an independent contractor
and not as employees or agents of the County. The Architect does not have the power or
authority to bind the County in any promise, agreement or representation other than such
power and authority that is specifically provided for in this Agreement.
ARTICLE XJH
13.1 INSURANCE
13.1.1 The Architect shall obtain insurance as specified and maintain the required
insurance at all times that this Agreement is in effect. Professional Liability Insurance
shall also be maintained as specified. In the event the completion of the project (to
include the work of others) is delayed or suspended as a result of the Architect's failure to
purchase or maintain the required insurance, the Architect shall indemnify the County
from any and all increased expenses resulting from such delay.
13.1.2 ' The coverage provided herein shall be provided by an insurer with an A.M. Best
Rating of VI or better, that is licensed to do business in the State of Florida and that has
an agent for service of process within the State of Florida. The insurance certificate shall
contain an endorsement providing thirty (30) days notice to the County prior to any
cancellation of said coverage. Said coverage shall be written by an insurer acceptable to
the County and shall be in a form acceptable to the County.
13.1.3 Architect shall obtain and maintain the following policies:
A. Workers' Compensation insurance as required by the State of Florida.
B. Employers Liability Insurance with limits of $100,000 per Accident, $500,000
Disease, policy limits, $100,000 Disease each employee.
C. Comprehensive business automobile and vehicle liability insurance covering
claims for injuries to members of the public and/or damages to property of
others arising from use of motor vehicles, including onsite and offsite
operations, and owned, hired or non -owned vehicles, with One Hundred
10
Thousand Dollars ($100,000.00) combined single limit and One Million
Dollars ($1,000,000.00) annual aggregate.
D. Commercial general liability covering claims for injuries to members of the
public or damage to property of others arising out of any covered act or
omission of the Architect or any of its employees, agents or subcontractors or
subconsultants, including Premises and/or Operations, Independent
Contractors; Broad Form Property Damage and a Contractual Liability
Endorsement with Five Hundred Thousand Dollars ($500,000.00) per
occurrence and annual aggregate.
E. Professional liability insurance of Five Hundred Thousand Dollars
($500,000.00) per claim and One Million Dollars ($1,000,000.00) annual
aggregate If the policy is a "claims made" policy, Architect shall maintain
coverage or purchase a "tail" to cover claims made after completion of the
project to cover the statutory time limits in Chapter 95 of the Florida Statutes.
F. County shall be named as an additional insured with respect to Architect's
liabilities hereunder in insurance coverage identified in Paragraphs C and D.
G. Architect shall require its subconsultants to be adequately insured at least to
the limits prescribed above, and to any increased limits of Architect if so
required by County during the tern of this Agreement; and subconsultants
shall be required by contract to provide copies of insurance policies to the
Architect. County will not pay for increased limits of insurance for
subconsultants.
H. Architect shall provide to the County certificates. of insurance or a copy of all
insurance policies including those naming the County as an additional insured
by including any subsection thereunder. The County reserves the right to
require a certified copy of such policies upon request. County reserves the
right to require copies of insurance policies of subconsultants.
ARTICLE XIV
TERMIlYATIOIY
14.1 Either party hereto may terminate this contract prior to expiration upon giving
seven (7) days written notice to the other in the event that such other party negligently or
for any reason substantially fails to perform its material obligations set forth herein. No
termination expenses shall be paid by the Owner after the date of notice of termination.
14.2 The Owner may terminate this Contract without cause by giving the other party
sixty (60) days written notice of its intention to do so. Termination expenses shall include
expenses available under the contract through the date on the notice of termination and
shall not include any additional services required in order to stop performance of
services, unless agreed to in writing by the County and subject to audit for the purpose of
verification.
ARTICLE XV .
ENTIRE AGREEMENT
15.1 This contract constitutes of the form of agreement, the exhibits that are attached
and made a part of the contract, and the documents referred to in the form of agreement
as a part of this contract. in the event any conflict between any of those contract
documents, the one imposing the greater burden on the Architect will control.
15.2 A person or affiliate who has been placed on the convicted vendor list following a
conviction for public entity crime may not submit a bid on contract to provide any goods
or services to a public entity, may not submit a bid on a contract with a public entity for
the property to public entity, may not be awarded or perform work as a
contractor, supplier, subcontractor, or consultant under a contract with any public entity,
and may not transact business with any public entity in excess of the threshold amount
provided in Section 287.017 of the Florida Statutes, for CATEGORY TWO for a period
of 36 months from the date of being placed on the convicted vendor list.
ARTICLE XVI
DISPUTE RESOLUTION .
16.1 County and Architect agree that all disputes and disagreements shall first be
attempted to be resolved by meet and confer sessions between representatives of each of
the parties. If no resolution can be agreed upon within 30 days after the first meet and
confer session, the issue or issues shall be submitted to mediation before a mediator
mutually agreed to by the parties. The cost of mediation shall be shared equally. The
parties agree that mediation is a condition precedent to the institution of legal or equitable
proceedings by either party. Request for mediation shall be in writing and sent to the
other party. The parties shall agree on a mediator to hear the dispute
16.2 Mediation shall be held in Monroe County Florida in a location in Key West; the
location may be moved only by mutual agreement of the parties.
16.3 Agreements reached in mediation shall be reduced to writing and signed by the
representative of each party; however, agreements must be approved by the Board of
County Commissioners to be enforceable Agreements reached in mediation shall be
enforceable as settlement agreements in any court having jurisdiction in Monroe County.
16.4 Nothing in this Agreement shall be construed to interfere with a subsequent order
from any court of competent jurisdiction ordering the parties to enter into mediation after
institution of legal or equitable proceedings.
12
16.5 Arbitration is specifically rejected by the parties as a method of settling disputes
which arise under this agreement; neither of the parties shall be compelled by the other to
arbitrate a dispute which may arise under this Agreement.
ARTICLE XV1I
Additional Reauirements
17.1 The following items are part of this contract:
a) Architect shall maintain all books, records, and documents directly pertinent to
performance under this Agreement in accordance with generally accepted accounting
principles consistently applied. Each party to this Agreement or their authorized
representatives shall have reasonable and timely access to such records of each other
party to this Agreement for public records purposes during the terra of the Agreement and
for four years following the termination of this Agreement. If an auditor employed by the
County or Clerk determines that monies paid to Architect pursuant to this Agreement
were spent for purposes not authorized by this Agreement, the Architect shall repay the
monies together with interest calculated pursuant to F.S. Sec 55.03, naming from the
date the monies were paid to County.
b) Governing Law, Venue, Interpretation, Costs, and Fees: This Agreement
shall be governed by and construed in accordance with the laws of the State of Florida
applicable to contracts made and to be performed entirely in the State In the event that
any cause of action or administrative proceeding is instituted for the enforcement or
interpretation of this Agreement; the County and Architect agree that venue will lie in the
appropriate court or before the appropriate administrative body in Monroe County,
Florida. The Parties waive their rights to a trial by jury. The County and Architect agree
that, in the event of conflicting interpretations of the terms or a term of this Agreement by
or between any of them the issue shall be submitted to mediation prior to the institution
of any other administrative or legal proceeding; pursuant -to Section XVI of this
agreement.
c) Severability. If any two, covenant, condition or provision of this
Agreement (or the application thereof to any circumstance or person) shall be declared
invalid or unenforceable to any extent by a court of competent jurisdiction, the remaining
terms, covenants, conditions and provisions of this Agreement, shall not be affected
thereby; and each remaining term, covenant, condition and provision of this Agreement
shall be valid and shall be enforceable to the fullest extent permitted by law unless the
enforcement of the remaining terns, covenants, conditions and provisions of this
Agreement would prevent the accomplishment of the original intent of this Agreement.
The County and Architect agree to reform the Agreement to replace any stricken
provision with a valid provision that comes as close as possible to the intent of the
stricken provision.
d) Attorney's Fees and Costs. The County and Architect agree that in the
event any cause of action or administrative proceeding is initiated or defended by any
party relative to the enforcement or interpretation of this Agreement, the prevailing party
13
shall be entitled to reasonable attorney's fees and court costs expenses, as an award
against the non -prevailing party, and shall include attorney's fees and courts costs
expenses in appellate proceedings.
e) Binding Effect. The terns, covenants, conditions, and provisions of this
Agreement shall bind and inure to the benefit of the County and Architect and their
respective legal representatives, successors, and assigns.
t) Authority. Each party represents and warrants to the other that the
execution, delivery and performance of this Agreement have been duly authorized by all
necessary County and corporate action, as required by law. Each party agrees that it has
had ample opportunity to submit this Contract to legal counsel of its choice and enters
into this agreement freely, voluntarily and with advise of counsel.
g) Claims for Federal or State Aid. Architect and County agree that each
shall bey and is, empowered to apply for, seep and obtain federal and state funds to
further the purpose of this Agreement; provided that all applications, requests, grant
proposals, and funding solicitations shall be approved by each party prior to submission.
h) Adjudication of Disputes or Disagreements. County and Architect agree
that all disputes and disagreements shall be attempted to be resolved under Section XVl
of this agreement. If no resolution can be agreed upon within 30 days after mediation,
then any party shall have the right to seek such relief or remedy as may be provided by
this Agreement or by Florida law.
i) Cooperation. In the event any administrative or legal proceeding is
instituted against either party relating to the formation, execution, performance, or breach
of this Agreement, County and Architect agree to participate, to the extent required by the
other party, in all proceedings, hearings, processes, meetings, and other activities related
to the substance of this Agreement or provision of the services under this Agreement.
County and Architect specifically agree that no party to this Agreement shall be required
to enter into any arbitration proceedings related to this Agreement.
j) Nondiscrimination. Architect and County agree that there will be no
discrimination against any person, and it is expressly understood that upon a
determination by a court of competent jurisdiction that discrimination has occurred, this
Agreement automatically terminates without any further action on the part of any party,
effective the date of the court order. Architect or County agree to comply with all
Federal and Florida statutes, and all local ordinances, as applicable, relating to
nondiscrimination. These include but are not limited to: 1) Title VI of the Civil Rights
Act of 1964 (PL 88-352) which prohibits discrimination on the basis of race, color or
national origin; 2) Title IX of the Education Amendment of 1972, as amended (20 USC
ss. 1681-1683, and 1685-1686), which prohibits discrimination on the basis of sex; 3)
Section 504 of the Rehabilitation Act of 1973, as amended (20 USC s. 794), which
prohibits discrimination on the basis of handicaps; 4) The Age Discrimination Act of
1975, as amended (42 USC ss. 6101-6107) which prohibits discrimination on the basis of
14
age; 5) The Drug Abuse Office and Treatment Act of 1972 (PL 92-255), as amended,
relating to nondiscrimination on the basis of drug abuse; 6) The Comprehensive Alcohol
Abuse and Alcoholism Prevention, Treatment and Rehabilitation Act of 1970 (PL 91-
616), as amended, relating to nondiscrimination on the basis of alcohol abuse or
alcoholism; 7) The Public Health Service Act of 1912, ss. 523 and 527 (42 USC sq.
690dd-3 and 290ee-3), as amended, relating to confidentiality of alcohol and drug abuse
patent records; 8) Title VIII of the Civil Rights Act of 1968 (42 USC s. et seq.), as
amended, relating to nondiscrimination in the sale, rental or financing of housing; 9) The
Americans with Disabilities Act of 1990 (42 USC s. 1201 Note), as maybe amended from
time to time, relating to nondiscrimination on the basis of disability, 10) Any other
nondiscrimination provisions in any Federal or state statutes which may apply to the
parties to, or the subject matter of, this Agreement.
k) Covenant of No Interest. Architect and County covenant that neither
presently has any interest, and shall not acquire any interest, which would conflict in any
manner or degree with its performance under this Agreement; and that only interest of
each is to perform and receive benefits as recited in this Agreement.
1) Code of Ethics. County agrees that officers and employees of the County
recognize and will be required to comply with the standards of conduct for public officers
and employees as delineated in Section 112.313, Florida Statutes, and the Monroe
County Code of Ordinances, regarding, but not limited to, solicitation or acceptance of
gifts; doing business with one's agency; unauthorized compensation; misuse of public
position, conflicting employment or contractual relationship; and disclosure or use of
certain information.
m) No Solicitation/Payment. The Architect and County warrant that, in
respect to itself, it has neither employed nor retained any company or person, other than a
bona fide employee working solely for it, to solicit or secure this Agreement and that it
has not paid or agreed to pay any person, company, corporation, individual, or firm, other
than a bona fide employee working solely for it, any fee, commission, percentage, gift, or
other consideration contingent upon or resulting from the award or making of this
Agreement. For the breach or violation of the provision, the Architect agrees that the
County shall have the right to terminate this Agreement without liability and, at its
discretion, to offset from monies owed, or otherwise recover, the full amount of such fee,
commission, percentage, gift, or consideration.
n) Public Access. The Architect and County shall allow and permit
reasonable access to, and inspection of, all documents, papers, letters or other materials in
its possession or under its control subject to the provisions of Chapter 119, Florida
Statutes, and made or received by the Architect and County in conjunction with this
Agreement; and the Architect shall have the right to unilaterally cancel this Agreement
upon violation of this provision by County.
o) Non -Waiver of Immunity. Notwithstanding the provisions of Sec. 286.28,
Florida Statutes, the participation of the Architect and the County in this Agreement and
15
}
the acquisition of any commercial liability insurance. coverage, self-insurance coverage,
or local government liability insurance pool coverage shall not be deemed a waiver of
immunity to the extent of liability coverage, nor shall any contract entered into by the
County be required to contain. -any provision for waiver.
. p) Privileges and Immunities. All of the privileges and immunities from
liability, exemptions from laws, ordinances, and rules and pensions and relief; disability,
workers' compensation, and other benefits which apply to the activity of officers, agents,
or employees of any public agents or employees of the County, when performing their
respective functions under this Agreement within the territorial limits of the County shall
apply to the same degree and extent to the performance of such functions and duties of
such officers, agents, volunteers, or employees outside the territorial limits of the County.
q) Legal Obligations and Responsibilities: Non -Delegation of Constitutional
or Statutory Duties. This Agreement is not intended to, nor shall it be construed as,
relieving any participating entity from any obligation or responsibility imposed upon the
entity by law except to the extent of actual and timely performance thereof by any
participating entity, in which case the performance may be offered in satisfaction of the
obligation or responsibility. Further, this Agreement is not intended to, nor shall it be
construed as, authorizing the delegation of the constitutional or statutory duties of the
County, except to the extent permitted by the Florida constitution, state statute, and case
law.
r) Non -Reliance by Non -Parties. No person or entity shall he entitled to rely
upon the terms, or any of them, of this Agreement to enforce or attempt to enforce any
third party claim or entitlement to or benefit of any service or program contemplated
hereunder, and the Architect and the County agree that neither the Architect nor the
County or any agent, officer, or employee of either shall have the authority to inform,
counsel, or otherwise indicate that any particular individual or group of individuals, entity
or entities, have entitlements or benefits under this Agreement separate and apart, inferior
to, or superior to the community in general or for the purposes contemplated in this
Agreement.
s) Attestations. Architect agrees to execute such documents as the County
may reasonably require including a Public Entity Crime Statement, an Ethics Statement,
and a Drug -Free Workplace Statement.
t) No Personal Liability. No covenant or agreement contained herein shall
be deemed to be a covenant or agreement of any member, oflcer, agent or employee of
Monroe County in his or her individual capacity, and no member, officer, agent or
employee of Monroe County shall be liable personally on this Agreement or be subject to
any personal liability or accountability by reason of the execution of this Agreement.
u) Americans with Disabilities Act of 1990 (ADA). The Architect will
comply with all the requirements as imposed by the ADA, the regulations of the Federal
government issued thereunder, and the assurance by the Architect pursuant thereto.
16
v) Disadvantaged Business Enterprise (DBE) Policy And Obligation. It is
the policy of the County that DBE's, as defined in C.F.R. Part 26, as mended, shall have
the opportunity to participate in the performance of contracts financed in whole or in part
with County funds under this Agreement. The DBE requirements of applicable federal
and state laws and regulations apply to this Agreement. The County and its Architect
agree to ensure that DBE's have the opportunity to participate in the performance of the
Agreement. In this regard, all recipients and contractors shall take all necessary and
reasonable steps in accordance with applicable federal and state laws and regulations to
ensure that DBE's have the opportunity to compete and perform contracts. The County
and the Architect and subcontractors shall not discriminate on the basis of race, color,
national origin or sex in the award and performance of contracts, entered pursuant to this
Agreement.
w) Execution in Counterparts. This Agreement may he executed in any
number of counterparts, each of which shall be regarded as an original, all of which taken
together shall constitute one and the same instrument and any of the parties hereto may
execute this Agreement by singing any such counterpart
x) Section Headings. Section headings have been inserted in this Agreement
as a matter of convenience of reference only, and it is agreed that such section headings
are riot a part of this Agreement and will not be used in the interpretation of any provision
WHEREOF, each party caused this Agreement to be executed by its duly
esentative on the day and year first above written.
Clerk
9-T'g9 COUNTY ATTORNaY
AP ROVED AS DTO0 M�
NATILEENE W. CASSEL
ASSISTANT COUNTY ATTORNEY
WITN S T Architect' atur ,
By:
1TNESS Sig re
Print Witness Name
Date: ,: , % L S� ZZO
BOARD OF COUNTY CO ISSIONERS ..>
OF MOLAR COUNWIFA
¢�� xy t:
..Br. C.)rTii
Date: MAR } 7 ZWO
v . =,—"iv
(INSERT N of Architect) -n C)
t— �
By:
Signature of Corporate A exit
L✓/L ,44 ho drtN
Print Name of rporat Agent
Date: �/ � D
END OF AGREEMENT
17
N
0
cz
w
Z
4
N
N
�'l� tAritit • titr. M t#ttt�
M►G�aYt4�11#ii1, �q
` Goa tl t#g 1f�1� j
-n
r—
rri
_q
C7
rn
Cl)
O
:V
t::7
SECTION FIVE
INSURANCE REQUIREMENTS AND INDEMNIFICATION STATEMENT
Insurance Requirement
Workers' Compensation
Employer's Liability
General Liability
Vehicle Liability
Architects Errors and Omissions Liability
Required Limits
Statutory Limits
$1001000/$500,000/$100,000
$500,000 Combined Single Limit
$100,000 Combined Single Limit per
Occurrence!$1,000,000 Aggregate
$500,000 per occurrence/ $1,000,000
Aggregate
IDEMNIFICATION AND HOLD HARMLESS FOR CONSULTANTS AND
SUBCONSULTANTS
The Architect/Consultant covenants and agrees to indemnify, hold harmless and defend
Monroe County, its commissioners, officers, employees, agents and servants from any
and all claims for bodily injury, including death, personal injury, and property damage,
including property owned by Monroe County, and any other losses, damages, and
expenses of any kind, including attorney's fees, court costs and expenses, which arise out
of, in connection with, or by reason of services provided by the Architect or Consultant
or any of its Subcontractor(s) in any tier, occasioned by the negligence, errors, or other
wrongful act or omission of the Architect/Consultant, including its Subcontractor(s) in
any tier, their officers, employees, servants or agents.
In the event that the completion of the project (to include the work of others) is delayed
or suspended as a result of the Architect/Consultant's failure to purchase or maintain the
required insurance, the Architect/Consultant shall indemnify the County from any and all
increased expenses resulting from such delay. Should any claims be asserted against the
COUNTY by virtue of any deficiency or ambiguity in the plans and specifications
provided by the Architect/Consultant; the Architect/Consultant agrees and warrants that
Architect/Consultant shall hold the County harmless and shall indemnify it from all
losses occurring thereby and shall further defend any claim or action on the County's
behalf.
The first ten dollars ($10.00) of remuneration paid to the Architect/Consultant is
consideration for the indemnification provided for above.
is
The extent of liability is in no way limited to, reduced, or lessened by the insurance
requirements contained elsewhere within this agreement.
This indemnification shall survive the expiration or earlier terminationofthe Agreement.
RESPONDENT'S STATEMENT
I understand the insurance that will be mandatory if awarded the"contract and will comply
in full with all the requirements. .f
AemZ om a, ��nN --�
Respondent Signature
19
tN$ CE ACEN7"� 5?ATEMENT
i have reviewed the above requirements with the Architect named blow. ` U following
deductibles apply to the corresponding policy.
POLICY
v�ycK�S Lome
ICA
e—Y, RIP— i(-e4. —
DEDUCTIBLES
l�
D
LiabiiitypolWas me ��ca------Claims Made
Insurance Agency Signature
Print Name•
The Fullers Ins.
1432 Kennedy Dr.
Key West, FL 33040
20
SECTION SIX
COUNTY RESPONSE FORMS
RESPOND TO: MONROE COUNTY BOARD OF COUNTY COMMISSIONERS
e10 PURCHASING DEPARTMENT
GATO BUILDING, ROOM 1-213
1100 SIMONTON STREET
KEY WEST, FLORIDA 33040
I acknowledge receipt of Addenda No.(s)
I have included:
o The Response Formy /
o Lobbying and Conflict of Int est Clause v
o Non -Collusion Affidavit
o Drug Free Workplace Form.
o Respondent's Insurance and Indenmification Statement
o Insurance Agent's Statement
o Professional and Occupational Licenses_
I have included a current copy of the following professional and occupational licenses:
4 G/fib zGiwAv*i oc�tlr9a�i'on,�
GlcrrN���
(Check mark itegn above, as s reminder that they are Included.)
Mailing Address:
Telephone..5 05'W'$"3o 2 Fax: 3a S- 29 • 033
Date:
Signed: f Witness: -
ZA41, (Seal)
(Name)
(Title)
21
LOBBYING AND CONFLICT OF INTEREST CLAUSE
SWORN STATEMENT UNDER ORDINANCE NO.010-1990
MONROE COUNTY, FLORIDA
ETHICS CLAUSE
(Company)
"... warrants that he/it has not employed, retained or otherwise had act on his/its
behalf any former County officer or employee in violation of Section 2 of Ordinance No.
010-1990 or any County officer or employee in violation of Section 3 of Ordinance No.
010-1990. For breach or violation of this provision the County may, in its discretion,
terminate this Agreement without liability and may also, in its d' etion, deduct from the
Agreement or purchase price, or otherwise recover, the 11 amount of any fee,
commission, percentage, gift, or consideration paid to t former County officer or
employee
(Sigdature)
Date -
STATE OR 7,Ut2I no
COUNTY OF: / ' / (jrVQ OF
—
Subscribed and sworn to (or affirmed) before me on c LLD
(date) by Uri /II /H M = -/Q,f�
personally known to me or has produced
as identification. (type of:
A1rNM.11lf�A
MANY PM1e • a* of ftw
' M► �e"� E�1rlt, 21t
coorim" s op tms!
e� 1�M M�oiMI t�ioUryAs�
22
(name of affiant). 9she is
My commission expires: 7/�i-.
DRUG -FREE WORKPLACE FORM
The undersigned vendor In accordance with Florida Statute 287.087 hereby certifies
that:
Im
(Name of Business)
1. Publish a statement notifying employees that the unlawful manufacture, distribution,
dispensing, possession, or use of a controlled substance is prohibited in the workplace
and specifying the actions that will be taken against employees for violations of such
prohibition.
2. Inform employees about the dangers of drug abuse In the workplace, the business's
policy of maintaining a drug -free workplace, any available drug counseling, rehabilitation,
and employee assistance programs, and the penalties that may be imposed upon
employees for drug abuse violations.
3. Give each employee engaged in providing the commodities or contractual services
that are under bid a copy of the statement specified In subsection (1).
4. In the statement specified In subsection (1), notify the employees that, as a condition
of working on the commodities or contractual services that are under bid, the employee
will abide by the terms of the statement and will notify the employer of any conviction of,
or plea of guilty or nolo contendere to, any violation of Chapter 883 (Florida Statutes) or
of any controlled substance law of the United States or any state, for a violation
occurring in the workplace no later than five (5) days after such conviction.
5. Impose a sanction on, or require the satisfactory participation in a drug abuse
assistance or rehabilitation program if such Is available in the employee's community, or
any employee who Is so convicted.
6. Make a good faith effort to continue to maintain a drug -free workplace through
implementation of this section.
As the person authorized to slgn�ife statement; I certify that this firm complies fully with
the above requirements.
Respondent's
23
%'//i/e
NON -COLLUSION AFFIDAVIT
I, 4MIK , A 9 Adi'1N of the city of _ &k 06 c /�Z
according to law on my oath, and under penalty of perjury, depose and say that:
I lam
of the firm of 1_A1J(1Jl206 AWAY A/'lG &&e ��,
the bidder making the Proposal for the project described in the Request for
Qualifications for. � __!r IOA, 2" A44 k - d
and that I executed the said proposal with full authority to do so:
2, the prices in this bid have been arrived at independently without collusion,
consultation, communication or agreement for the purpose of restricting
competition, as to any matter relating to such prices with any other bidder or
with any competitor,
3. unless otherwise required by law, the prices which have been quoted in this
bid have not been knowingly disclosed by the bidder and will not knowingly
be disclosed by the bidder prior to bid opening; directly or indirectly, to any
other bidder or to any competitor, and
4. no attempt has been made or will be made by the bidder to induce any other
person, partnership or corpor tion to submit, or not to submit, a bid for the
purpose of restricting compe " on;
5. the statements contained i this affidavit are true and correct, and made with
full knowledge that M e County relies upon the truth of the statements
contained in this a vit in awarding contracts for said project
2 e JD
of Respondent) (Date)
STATE OF: Elve-I0,4
COUNTY OF: %�t w /_) g
PERSONALLY APPEARED BEFORE ME, the undersigned authority,
�'� who, after first being sworn by mey (name of individual signing) affixed
hi er signature in the space provided above on this ay of C&-
0 - - -17 �
AWALt"
ftbvA"•sorf:t�
• M�t'areNstas�M'wJr1?1,7M9
� Nr no
My Commission Expires:
24
ROUTING Gl� 11 116110
WILLIAM P. BORN ARO-11TECT, P.A. License N,t, AA
`)IS EATON STR.EET_ICEV WEST, FLORIDA 331190
• rr1014E: 3I)s-29n-x3u3 FA\; .lil>-24h-IUJ3
Date: 2/8/10
To: Jerry A. Barnett
Director of Project Management
Monroe County, Florida
Re: Architectural Fee Proposal
Higgs Beach Master Plan
Key West, Florida
Dear Mr. Barnett,
This letter is to propose cost estimates for the work needed to be completed
to create a master plan for the Higgs Beach Site. Work will be in two phases.
Phase one will include the design and drawing of the master plan and all of
the public meetings that are required to obtain input from the public, City of
Key West and the County Commissioners. Phase two, if needed, will include
all of the required work in order to obtain City of Key West Planning Board
and City Commission approvals, including a development agreement.
Phase one work will include obtaining a new survey of the site, creating an
existing site plan with analysis of all existing conditions, including site and
zoning analysis, "existing building condition analysis and existing landscape
and tree analysis. We will. provide proposed site plan design options for
review by all and finalize the options to create a master site plan with cost
estimates for the new work Meetings will include three public meetings in
Key West, one meeting with the Higgs Beach Steering Committee, one
public meeting with the City of Key West Commission, meeting with the
City of Key West planner, two meetings with the Monroe County
Commission and meetings with county staff as required. We will finalize
the whole process in a bound report.
Costs for phase one is as follows:
Master Site Plan
Fee = $45,000.00
Surveyor
Fee= $10,500.00
Phase two work, if needed, will include developing the master site plan to
include all of the required items to go through the Planning Board approval
process of the City of Key West and preparing a development agreement.
Work will include filling out all of the applications and requirements,
developing the site plan, landscape plan, civil drainage plan, lighting plan
and coordination with all agencies. Work will also include designing and
drawing plans and elevations of any building improvements or new
buildings that are desired (includes a total of four buildings maximum).
Meetings will include coordination meetings with the county staff and City
of Key West staff, DRC meeting, Tree Commission meeting, Planning
Board meeting and City Commission meeting.
Costs for phase two is as follows:
Fee= $76,500.00
Any additional work can be completed at a fixed fee (to be determined), or
at our standard hourly rates as listed in the annual contract.
Please call if u have any questions. We are looking forward to working
with you on t)ds project.
P. HORN ARCHITECT, P.A.
WIllism P. Horn,
Principal, LEED AP
OP ID: NI
CERTIFICATE OF LIABILITY INSURANCE FDA 11J15110
THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND dONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS
CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES
BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED
REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER.
IMPORTANT: if the certificate holder Is an ADDITIONAL INSURED, the policy(los) must he endorsed. If SUBROGATION 13 WAIVED, subject to
the terms and conditions of the policy, certain policies may require an endorsement A statement on this certificate does not confer rights to the
certificate holder In lieu of such endorsemenf(s).
PRODUCER 305-294.6677
The Fullers, Inc 305-292.4641
1432 Kennedy Drive
Key West, FL 33040
Norman Fuller
INSURED William P Horn Architect PA INSURERA.First Community Insurance Co. 13990
Bill Horn INSURERS:
915 Eaton St INSURER C
Key West, FL 33040
INSURER D
INSURER E
INS R P
r`nVFRAA01Q r:FRTIFIr AT0 NI IMIRI=R. RPVISIAN NIIMAER-
THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD
INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS
CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS,
EXCLUSIONS AND CONDITIONS OF SUCH POLICIES, LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS.
L7R
TYPE OF INSURANCE
POLICY NUMBER
POLICY
t
LIMITS
A
GENERAL LIABILITY
COMMERCIAL GENERAL LIABILITY
CLAIMS -MADE FIOCCUR
X Business Owners
X
090004962995808
09/21/10
09121M I
EACH OCCURRENCE
tr 1,000,00
ffff-
PREMISES
S 50,00
MED EXP (Any oneperson)
$ 6,00
PERSONAL S ADV INJURY
$
GENERAL AGGREGATE
b 2,000,00
k-GENI. AGGREGATE LIMIT APPLIES PER,
POLICY JFCTPRO- LOG
PRODUCTS - COMP/OP AGO
$
CSL
; 1,000,00
AUTOMOBILE
LIABILnY
ANY AUTO
ALL OVMVED AUTOS
SCHEDULED AUTOS
HIRED AUTOS
NON -OWNED AUT08
COMBINED SINGLE LIMIT
(Ea accident)
;
BODILY INJURY (Per person)
;
BODILY INJURY (Per accident)
i
PROPERTY DAMAGE
(Per accident)
9
;
UMBRELLA LIAR
EXCESS LIAR
OCCUR
CLAIMS -MADE
-
EACH OCCURRENCE
;
AGGREGATE
;
DEDUCTIBLE
RETENTION S
$
fi
WORKERS COMPENSATION
AND EMPLOYERS' LIABILITY
ANY PROPRIETORIPARTNERIEXECUTIVEYtN
OFFICERIMEMBEREXCLUDE]?
IMaodatoryInNH)
Nyes, describe under
DESCRIPTION OF OPERATIONS belog
NIA
WC STATrORYLIMU- OTH
E.L. EACH ACCIDENT
;
E.L•DISEASE - EA EMPLOYE
;
E.LDISEASE- POLICY LIMIT
S
PROPERTY
DESCRIPTION OF OPERATIONS I LOCATIONS I VEHICLES (Attach ACORD 101, AddWonal Remade Schadula, If mom space Is required)
Certificate holder Is an additional insured.
MONRCON
SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE
Monroe County Board of County THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN
tY ty ACCORDANCE WITH THE POLICY PROVISIONS.
Commissioners
1100 Simonton Street Rm 268 AUTHORIZED REPRESENT
Key West, FL 33040 Norman Fuller
®1988 2 CORD CORPORATION. All rights reserved.
ACORD 25 (2009109) The ACORD name and logo are registered mark of • CORD
OP ID: NI
CERTIFICATE OF LIABILITY INSURANCE[7,Effl(MMIDDNM)
5l10
THIS CgRTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND dONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS
CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES
BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURERS), AUTHORIZED
REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER.
IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the pollcy(tea) must be endorsed. If SUBROGATION IS WAIVED, subject to
the terms and conditions of the policy, certain policies may require an endorsement A statement on this Certificate does not confer rights to the
certificate holder In lieu of such endorsementfs).
PRODUCER
The Fullers, Inc
1432 Kennedy Drive
Key West, FL 33040
Norman Fuller
INSURED William Hom
151 Key Haven Rd.
Key West, FL 33040
305-294-6677
305.292-4841
I.nVFRar;FLC r`GRTIAIf`ATC All IiU492C117. RGIIIRInl11 All UUFIFR-
THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD
INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS
CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS,
EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS.
ILTR NSR
TYPE OF INSURANCE
ADDt
SURF
POLICY NUMBER
POLICY
MMIDD
LIMITS
GENERAL LIABILITY
EACH OCCURRENCE
$
PREMISES ■ occurrence)$
4 COMMERCIAL GENERAL LIABILITY
CLAIMS -MADE OCCUR
IVIED EXP (Any ons paaon)
S
PERSONAL 3ADVINJURY
s
GENERAL AGGREGATE
B
�GEN`L AGGREGATE LIMIT APPLIES PER;
PRODUCTS - COMPIOP AGG
s
s
POLICY PRO• LOC
AUTOMOBILE LIABIUTY
A ANYAUTO
X
D2168346-7
05/29/10
05129/11
COMBINED SINGLE LIMB
s 1,000,00
Baaccident)ODILY (Few person)
s
ALL OWNED AUTOS
X SCHEDULEDAUT09
X HIREDAUTOS
BODILY INJURY (Per eccidwfl)
s
PROPERTYDAMAGE
(Foracadod)
S
s
X NON -OWNED AUTOS
s
UMBRELLA LIAR
OCCUR
I
EACH OCCURRENCE
HCLAIM'
AGGREGATE:
s
EXCESS LIAB
'.MADE
1
DEDUCTIBLE
$
RETENTION
WORKERS COMPENSATION
WC STATfS OTH-
AND EMPLOYERS' LIABILITY
ANY PROPRIETORIPARTNEWEXECUTNEY/N
OFFICER/MEEMBEREXCLUDED?
(Mandatory In MIN)
NIA
E.LEACH ACCIOENT
S
EL DISEASE -Flu EMPLOYE
s
E.L. DISEASE -POLICY LIMIT I
s
if yyess, describe under
D£SCRIP ON OF OPERATIONS below
DESCRIPTION OF OPEERATION9 / LOCATIONS I VEHICLES (Attach ACORD 101, Additional Remarks Schedule, If mars $pact is requind)
2007 Chevrolet Tahoe C1501GNFC13027R293917. Certificate holder is an
additional insured.
MONRCON
SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE
Monroe County board of County THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN
tY ty ACCORDANCE WITH THE POLICY PROVISIONS.
Commissioners
1100 Simonton Street Rm 268 AUTHOR¢EO REPRESENTA
Key West, FL 33040 Norman Fuller
7
0 1988-2A ORD CORPORATION. All rights reserved.
ACORD 25 (2009/09) The ACORD name and logo are registered marks Of A ORD
= 4COR u, CERT I L it
PRODUCER
iSU Suncoast Insurance Assoc
P.O. Sox 22668
Tampa, FL 33622 2663
813 289-5200
INSURED
William P. Horn, Architect, P.A.
915 Eaton Street
Key West, FL 33040
E OF LIABILITY INSf "__?J,_ J'CE 0812 2010 "�'
THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION
ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE
HOLDER. THIS CERTIFICATE DOES NOT AMEND, EXTEND OR
ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW.
INSURERS AFFORDING COVERAGE NAIC#
INSURER A: Beazley Insurance Company, Inc. 37540
INSURER B:
INSURER C:
I I INSURER E. I I
nMM0Ar_ee
THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING
ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR
MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECTTO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH
POLICIES. AGGREGATE LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS.
LTR
S
TYPEOFINSURANCE
POLICY NUMBER
POLICY EFFECTIVE
D
POLICY EXPIRATION
UMITS
GENERAL LIABILITY
EACH OCCURRENCE
$ _
PDAMAGETO RENTED
$
COMMERCIAL GENERAL LIABILITY
CLAIMS MADE71 OCCUR
MED EXP (Any one person)
$
PERSONAL a ADV INJURY
$
GENERALAGGREGATE
$
GEML AGGREGATE LIMITAPPLIES PER:
PRODUCTS -COMPIOP AGG
$
POLICY �Ec Loc
AUTOMOBILE LIABILITY
ANYAUTO
COMBINED SINGLE LIMIT
(Eaascident)
$
BODILY INJURY
(Per person)
$
ALL OWNED AUTOS
SCHEDULEDAUTOS
S eracci accident)
(Per acc6dent)
$
AU
HIREOWNED
MOM -OWNED AUTOS
PROPERTY DAMAGE
(Per eccidenq
$
...
GARAGE
LIABILITY
AUTO ONLY: FAACCIDENT
$
O-mFRmA, EAACC
$
ANY AUTO
$
AUTO ONLY'. AGG
EXCESS/UMBRELLA LIABILITY
EACH OCCURRENCE
$
AGGREGATE
$
OCCUR F_1CLAIMSMADE
-
$
DEDUCTIBLE
$
RETENTION $
WORKERS COMPENSATION AND
we sraTu oTH-
E.L. EACH ACCIDENT
$
EMPLOYERS' LIABILITY
ANY PROPRIETORIPARTNERIEXECUTIVE
E.L. DISEASE -EA EMPLOYEE
$
OFFICERfMEMBE rXCLUDED?
Ifyes, describe under
SPECIAL PROVISIONSB ek w
E.L. DISEASE -POLICY LIMIT
$
A
OTHE"R Professional
V15V8D100301
08120/10
08/20/11
$1,000,000 per claim
Liability
$1,000,000 anni aggr.
DESCRIPTION OF OPERATIONS / LOCATIONS 1 VEHICLES I EXCLUSIONS ADDED BY ENDORSEMENT I SPECIAL PROVISIONS
Professional Liability is claims made and reported.
Project: Conch Key, Big Pine & North Key Largo Fire Stations
Annual Contract for Architectural Services
i,crtlln■.A+Ienul ucls I+AI1A1c1.1.HIIVN IV ua a RA nv:Ira u.c„a
SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION
Monroe County ➢ATE THEREOF, THE ISSUING INSURER WILL ENDEAVOR TO MAIL 10 DAYS WRITTEN
Board of County Commissioners NOTICE TO THE CERTfFICATE HOLDER NAMED TO THE LEFT, BUT FAILURE TO DO SO SHALL
Attn: Risk Management 1100 IMPOSE NO OBLIGATION OR LIABILITY OF ANY KIND UPON THE INSURER, ITS AGENTS OR
Simonton REPRESENTATIVES.
Key West, F! 33040 A TATIVE
—9.:I , Rese —at- A<2—
ACORD 25 (2001108)1 of 2 #S266185/M266181 KEB 0 AGURU GURrUtwl IVN -JUDO
OP ID: N
ACC:)RRD' J
I,,,,�.TIFICATE OF LIABILITY INSURANCE
DATE P AWOM'YYY)
01/31/11
THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS
CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES
BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER($), AUTHORIZED
REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER
IMPORTANT: If the cerfficate holder Is an ADDITIONAL INSURED, the policy(les) must be endorsed. If SUBROGATION IS WAIVED, subject to
the tarns and conditions of the policy, certain policies may require an endorsement A statement on this Certificate does not confer rights to the
certiflcate holder In lieu of such endorsem s .
PRODUCER 305-294-W77
The Fullers, Inc 305-2924641
1432 Kennedy Drive
Key West, FL 33040
Norman Fuller
PND"E EM:FAAx No
E-MAIL
PRODUCER }iORNW-1
I S AF COVERAGE
NM F
INSURED William P Horn Architect PA
Bill Horn
915 Eaton St
Key West, FL 33040
INSURERA: Florida Retall Federation
INSURERS:
0URERC:
RMRERD:
INSURER E :
WSURER F
r4nVFRA1-'9fit f_FRTIeICATF NI 11MIAPR! REVISION NUMBER -
THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD
INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS
CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS,
EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS.
INSR
IYKOF INSURANCE
SUM
POLICY NUMBER
Po T EFF
POLICY ExP
LIMITS
C4XERAL LIABILITY
COMMERCIAL GENERAL LIABILITY
CLARA94AADE OCCUR
EACH OCCURRENCE
S
PRomES Es oa worzo
S
MED EXP (Any one arson)
$
PERSONAL BADVINJURY
i
GENERAL AGGREGATE
3
GENII L AGGREGATE LIMIT APPLIES PER.
-1 7POLICY PRO LOC
PRODUCTS-COMPIOP AGG
5
$
AUTOMOBILE
LIABILITY
ANYAUTO
ALL OWNED AUTOS
HIR ED UTOS TOS
HIRED AUTOS
NON-OWNEDAUTOS
��
COMBINED SINGLE LIMIT
(Ea mctdent)
$
BODILY INJURY(Per penon)
$
BODILY INJURY (Per aaddwd)
S
Peracdd YDAMAGE
(Paracade�)
$
$
UMBRELLALIAS
EXCESS LIAR
OCCUR
r
1i `
EACHOCCURRENCE
S
HCLAIMS-ME
AGGREGATE
$
DEDUCTIBLE
S
s
A
WORKERS COMPENSA• ION
ANDEMPLOYERS'UABMM
ANY PROPMETORIPARTNERIEXECUITIVE YIN Q
OFF(CERAU MBER EXCLUDED?
(AfymesWOCKYIMNH)
DESGIRaIPT10N0P 0 TIONSb.I.
N A A
520-40146
01101111
01/01112
WC SLATU- X OTH-
E.L EACH ACCIDENT
S 1,000+DO
E.LDISEASE -EAEMPLOYE
S 11000,00
EL DISEASE -POLICY LIMIT
$ 1DOIit,OS
DESCRIPTION OF OPERATKM J LOCATIONS I VEHICLES (Attach ACORD IC1, AddOond Ra orks Soheda ei Hmero *&" is mquir )
Monroe County SOCC
Risk Management
1100 Simonton St.
Key West, FL 33040
ACORD 26 (2009100)
SHQULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE
THE EXP§tATION DAV THEREOF, NOTICE VALL BE DELIVERED IN
ACCORDANCE WITH TkO POLICYPROYISIONS.
AUTHORM REPM
Norman Fuller
a
The ACORD name and logo are registered I
CORPORATION. All rights reserved.
EXHIBIT A
Hourly Rates
Monree C,:un1y
i Y ?!j ZtiO'ry^
WILLIAM A HORN ARCHITECT, PAECE1vED er:
-ManCertsEi'fQ'AA 000304o
915 EATON STREET, KEY WEST, FLORIDA 33040
Date: 11/20/09
To: Jerry Barnett
Facilities DOY916pment Coordinator
Monroe County
Re: Hourly Rstes
Annual Contract
Dear Mr. Barnett,
Our standard hourly rates are as follows:
Principal Architect
$195.00/hr
Architect
$130.00/hr
Intern Architect
$100.00/hr
Dptwn
$85.00/hr
Structural Engineer
$150 00/hr
MI' Engineer
$125.00/hr
Principe! Civil Engineer $150.00/hr
Senior Civil Engineer
$120 00/hr
Civil Engineer
$10.0.00/hr
Planner
$150.00/hr
PHONE:303-296-8302 FAX:303-296-1033
Please call if you have any questions. We are looking forward to working
with you. ,
Sincerely
P. HORN A.RCHiTECT, F.A.
William P. Horn,
Principal
CONTRACT FOR
PROFESSIONAL SERVICES
BETWEEN OWNER AND ARCHITECT/ENGINEER
THIS CONTRACT FOR PROFESSIONAL SERVICES BETWEEN OWNER AND
ARCHITECT/ENGINEER (the "Contract" or "Agreement") is made and entered into by
Monroe County ("Owner" or "County"), a political subdivision of the State of Florida,
whose address is 1100 Simonton Street, Key West, Florida 33040, its successors and
assigns through the Monroe County Board Of County Commissioners (`BOCC"), and
William P. Horn. Architect, P.A. , the ( "Architect'D., whose address is 915 Eaton St,
Key West, FL 33040, its successors and assigns.
This contract shall be effective on the date of execution by the last party signatory to the
contract.
This contract is issued as a continuing contract pursuant to Florida Statute 287.055(2) (g).
The professional services required by this Contract are to be rendered for projects in
which the estimated construction costs of each individual project under the contract does
not exceed Two Million Dollars ($2,000,000.00), or for study activity if the fee for
professional services for each individual study under the contract does not exceed Two
Hundred Thousand Dollars ($200,000.00).
The parties shall enter into a separate contract for each project awarded to the Architect
by the Owner. The specific services to be performed under these separate contracts will
be determined by the Owner and agreed to by the Architect. Each separate contract will
contain specific scope of work, time schedule, charges and payment conditions, and
additional terms and conditions applicable to that specific contract. Architect will be
chosen pursuant to Owner policy and work will be distributed among all contractors who
have signed a continuing contract.
The professional services required by this contract will be for services in the form of a
continuing contract, commencing on the effective date of this contract and ending four
years thereafter, with options for Owner to renew on an annual basis for two additional
years.
The terms and conditions of this Contract shall apply to any separate contract, unless
expressly modified in the provisions of the separate contract. Where the terms of this
Contract differ from the terms of the separate contract, the terms of the separate contract
shall take precedence. The separate contract will contain its specific scope of work and it
is anticipated by this Contract that the scope of work in the separate contract will be in
addition to the scope of work outlined in this Contract
NOW, THEREFORE, in consideration of the mutual promises, covenants and
agreements stated herein, and for other good and valuable consideration, the sufficiency
of which hereby acknowledged, the Owner and the Architect agree:
FORM OF AGREEMENT
ARTICLE 1
1.1 REPRESENTATIONS AND WARRANTIES
By executing this Contract, Architect makes the following express representations and
warranties to the Owner:
1.1.1 The Architect is a professional qualified to act as the Architect for the Project and
is licensed to practice Architecture/Engineering by all public entities having jurisdiction
over the Architect/Engineer and the Project;
1.1.2 The Architect shall maintain all necessary licenses, permits or other
authorizations necessary to act as Architect for the Project until the Architect's duties
hereunder have been fully satisfied;
1.1.3 The Architect shall become familiar with the individual Project site and the local
conditions under which the Project is to be designed, constructed, and operated prior to
entering a separate contract for any specific Project.
1.1.4 The Architect shall prepare all documents required by this Contract including, but
not limited to, all contract plans and specifications, in such a manner that they shall be in
conformity and comply with all applicable law, codes and regulations. The Architect
warrants that the documents prepared as a part of this Contract will be adequate and
sufficient to accomplish the purposes of the Project, therefore, eliminating any additional
construction cost due to missing or incorrect design elements in the contract documents;
1.1.5 The Architect assumes full responsibility to the extent allowed by law with
regards to his performance and those directly under his employ as Architect of Record.
1.1.6 The Architect's services shall be performed as expeditiously as is consistent with
professional skill and care and the orderly progress of the Work. The Architect shall
submit, for the Owner's and Monroe County Project Management Department's
information, a schedule for the performance of the Architect's services which may be
adjusted as the Project proceeds if approved by the Owner, and shall include allowances
for periods of time required for the Owner's and Monroe County Project Management
Department's review, and for approval of submission by authorities having jurisdiction
over the Project. Time limits established by this schedule and approved by the Owner
may not be exceeded by the Architect except for delay caused by events not within the
control of the Architect or foreseeable by him.
1.1.7 In providing all services pursuant to this agreement, the Architect shall abide by
all statutes, ordinances, rules and regulations pertaining to, or regulating such services,
including those now in effect and hereinafter adopted. Any violation of said statutes,
ordinances, rules and regulations shall constitute a material breach of this agreement and
2
shall entitle the COUNTY to terminate this agreement immediately upon delivery of
written notice of termination to the Architect.
ARTICLE II
SCOPE OF ARCHITECTIENGINEER'S BASIC SERVICE
2.1 DEFINITION
2.1.1 Architect's Basic Services consist of those described in Paragraphs 2.2 through
2.8, and other services identified as part of Basic Services, and include normal, civil,
structural, mechanical, and electrical engineering services.
2.1.2 The Design for Construction shall include, but shall not necessarily be limited to,
plans and specifications which describe all systems, elements, details, components,
materials, equipment, and other information necessary for construction. The Design for
Construction shall be accurate, coordinated and in all respects adequate for construction
and shall be in conformity, and comply, with all applicable law, codes, permits, and
regulations. Products, equipment and materials specified for use shall be readily
available unless written authorization to the contrary is given by the Owner. The
Architect shall be responsible for designing the Project in accordance with the analyses
and recommendations of the geotechnical information furnished by the Owner.
2.1.3 These services shall include, but not be limited to: Preparation and completion of
the design program for space requirements and relationships, schematic design, design
development, preparation of contract documents for bids, preparation and advertisement
for Request for Bids, tabulation and review of bids, recommendation of contract awards,
cost estimating during design and document preparation, administration of contract
documents, consultation and on -site inspections during construction, review and
recommend. approval of contractor invoices, preparation and submittal of permit
applications, zoning applications, public presentations and presentations to the County
Commission. Architect shall arrange his schedule in order to be available to perform the
listed services for one or for several projects if requested by COUNTY and with the
understanding that for any individual project the construction costs will not exceed the
limits under F.S. 287.055 (2)(g).
2.2 SCHEMATIC DESIGN PHASE
2.2.1 The Architect shall review the County's program, schedule and construction
budget furnished by the Owner to ascertain the requirements of the Project and shall
arrive at a mutual understanding of such requirements with the Owner.
2.2.2 The Architect shall review with the Owner and Monroe County Project
Management Department's proposed site use and improvements, required permits,
zoning, selection of materials, building systems and equipment; and method of Project
delivery.
2.2.3 The Architect shall review with the Owner and Monroe County Project
Management Department's alternative approaches to design and construction of the
Project.
2.2.4 Based on the mutually agreed -upon program, schedule and construction budget
requirements, the Architect shall prepare, for approval by the Owner, Schematic Design
Documents consisting of drawings and other documents illustrating the scale and
relationship of Project components.
2.2.5 Upon completion of the Schematic Design Phase, the Architect shall provide
drawings, outline specifications, estimate of anticipated cost in accordance with the
schematic designs, and other documents for the Owner's approval and the Monroe
County Project Management Department's information.
2.2.6 The Schematic Design must be approved in writing, by the Owner prior to
Architect continuing to the Design Development Phase.
2.3 DESIGN DEVELOPMENT/DOCUMENT PHASE
2.3.1 Upon completion of the Design Development Phase, the Architect shall provide
drawings, outline specifications and other documents for the Owner's approval and the
Monroe County Project Management Department's information. The Architect shall
provide an estimate of anticipated costs in accordance with the design development
phase.
2.3.2 The Design Development Documents must be approved in writing, by the Owner
prior to Architect continuing to the Construction Documents Phase.
2.4 CONSTRUCTION DOCUMENTS PHASE
2.4.1 The Architect shall provide Drawings and Specifications for the Owner's and the
Monroe County Project Management Department's review.
2A.2 The Architect shall assist the Owner and Monroe County Project Management
Department in the preparation of the necessary bidding information, bidding forms, the
Conditions of Contracts, and the forms of Agreement between the Owner and the
Contractors.
2.4.3 The Architect's construction documents (plans, specifications, etc.) will conform
to all written codes and regulations of the federal government, county, state,
municipalities, agencies and state departments, in effect at the date of this Agreement,
and shall be of such completion as to receive all permits when applied for. If permits are
4
denied, then the Architect will conform the construction documents in such manner to
receive permits upon such plans. Work required from the Architect to conform the
documents to federal, state, city, county, or agency specifications and permit
requirements to allow them to be approved shall be completed at no charge or cost to the
Owner.
2.5 BIDDING OR NEGOTIATION PRASE
2.5.1 The Architect, following the Owner's approval of the Construction Documents
and the Architect's latest estimate of Construction Cost, shall assist the Monroe County
Project Management Department in obtaining bids or negotiated proposals and assist in
preparing contracts for construction.
2.5.2 The Architect shall assist the Monroe County Project Management Department in
issuing bidding documents to bidders and conducting pre -bid conferences with
prospective bidders. The Architect, with the assistance of the Monroe County Project
Management Department, shall respond to questions from bidders, and shall issue
addenda.
2.6 CONSTRUCTION PRASE - ADMINISTRATION OF THE
CONSTRUCTION CONTRACT
2.6.1. The Architect's responsibility to provide Basic Services for the Construction
Phase under this Agreement commences with the award of the Contract for construction
and terminates with the issuance to the Owner of the final Project Certificate for Payment
including the submission of all project close-out documents by the Architect and
Contractor. The Architect will administer the Owner's contract as provided for in that
document. The Architect'agrees to perform a project check prior to the end of the
warranty period as a part of the contract. The check shall not exceed one working day
unless additional time is approved by the Owner.
2.6.2 The Architect shall at all times have access to the Work whenever it is in
preparation or progress.
2.6.3 The Architect shall, as contemplated herein and in the Construction Contract, but
not otherwise, act on behalf, and be the agent, of the Owner throughout construction of
the Project. Instructions, directions, and other appropriate communications from the
Owner to the Contractor shall be given to the Contractor by the Architect or Monroe
County Project Management Department.
2.6.4 The Architect shall have authority, after notification to the Monroe County
Project Management Department to reject Work, which does not conform to the Contract
Documents.
2.6.5 The Architect shall review and sign or take other appropriate action on Change
Orders and Construction Change Directives prepared by the Monroe County Project
Management Department for the Owner's approval and execution in accordance with the
Contract Documents.
2.6.6 The Architect shall promptly provide appropriate interpretations as necessary for
the proper execution of the work as long as there is no change in Contract price.
2.6.7 The Architect shall require inspection or re -inspection and testing or retesting of
the work, to include architectural/engineering, structural, mechanical and electrical
engineering portions of the work, in accordance with the provisions of the Construction
Contract whenever appropriate.
2.6.8 The Architect, assisted by the Monroe County Project Management Department,
shall conduct inspections to determine the dates of Substantial Completion and the date
of Final Completion.
2.6.9 The Architect shall interpret and decide matters concerning performance of the
Contractor under the requirements of the Contract Documents upon written request.
2.6.10 Interpretations and decisions of the Architects shall be consistent with the intent
of and reasonably inferable from the Contract Documents and shall be in writing or in the
form of drawings and submitted on proper Construction Change Directives.
2.6.11 The Architect shall render written decisions within a reasonable time on all
claims, disputes or other matters in question between Owner and Contractors relating to
the execution or progress of the Work as provided in the Contract Documents.
2.6.12 Duties, responsibilities and limitations of authority of the Architect shall not be
restricted, modified or extended without written agreement of the Owner and Architect.
2.6.13 The Architect shall be a representative of and shall advise and consult with the
Owner (1) during construction until final payment to the Contractor is due and (2) as a
Basic Service at the Owner's direction from time to time during the correction period
described in the Contract for Construction.
2.6.14 The Architect shall transmit to the Owner all manuals, operating instructions, as -
built plans, warranties, guarantees and other documents and things required by the
Construction Contract and submitted by the Contractor.
2.6.15 The Architect shall not have control over or charge of and shall not be responsible
for construction means, methods, techniques, sequences or procedures, or for safety
precautions and programs in connection with the Work, since these are solely the
Contractor's responsibility under the Contract for Construction. The Architect shall not
be responsible for the Contractor's schedules or failure to carry out the work in
accordance with the contract documents. The Architect shall not have control over or
charge of acts or omissions of the Contractor, Subcontractors, or their agents or
employees, or of any other persons performing portions of the work.
2.6.16 The Architect shall make available to the Owner any personnel or consultants
employed or retained by the Architect for the purpose of reviewing, studying, analyzing
or investigating any claims, contentions, allegations, or legal actions relating to, or arising
out of, the design or construction of the project.
2.6.17 The Architect shall review any as -built drawings fumished by the Contractor and
shall certify to the Owner that same are adequate and complete.
2.6.18 The Architect shall, without additional compensation, promptly correct any errors,
omissions, deficiencies, or conflicts in the work product of the Architect or its
consultants, or both.
2.6,19 The Architect must reimburse the Owner for any added costs paid by the Owner
during construction that were incurred as the result of any omission, deficiency, or
conflict in the work product of the Architect, its consultants, or both. This added expense
is defined as the difference in cost from that which the Owner would have paid if the
work was included in the bid, and the actual cost presented by the Contractor.
ARTICLE III
ADDITIONAL SERVICES
3.1 GENERAL
3.1.1 The services described in this Article III are not included in Basic Services. They
shall be paid for by the Owner as provided in this agreement as an addition to the
compensation paid for the Basic Services but only if approved by the Owner before
commencement, and as follows:
A. Providing services of Architect for other than the previously listed consulting
scope of Project provided as a part of Basic Services.
B. Providing any other services not otherwise included in this Agreement or not
customarily furnished in accordance with generally accepted consulting
practice.
C. Providing representation before public bodies in connection with the Project,
upon approval by the Owner.
3.2 If Additional Services are required, such as those listed above, the Owner
shall issue a letter requesting and describing the requested services to the Architect. The
Architect shall respond with fee proposal to perform the requested services. Only after
receiving an amendment to the Agreement and a notice to proceed from the Owner
proceed with the Additional Services.
7
ARTICLE IV
OWNER'S RESPONSIBILITIES
4.1 The Owner shall designate Monroe County Project Management Department to
act on the Owner's behalf with respects to the Project. The Owner or Monroe County
Project Management Department shall render decisions in a timely manner pertaining to
documents submitted by the Architect in order to avoid unreasonable delay in the orderly
and sequential progress of the Architect's services. However, the parties acknowledge
that due to Monroe County Policy, Ordinances or State or Federal Statute there may be
times when a decision must be made by the BOCC, in which case any delay shall not be
attributed to Monroe County or its representative.
4.2 Prompt written notice shall be given by the Owner and Monroe County Project
Management Department to the Architect if they become aware of any fault or defect in
the Project or non-conformance with the Contract Documents.
4.3 The Owner shall furnish the required information and services and shall render
approvals and decisions as expeditiously as necessary for the orderly progress of the
Architect's services and work of the contractors.
4.4 The Owner's review of any documents prepared by the Architect or its consultants
shall be solely for the purpose of determining whether such documents are generally
consistent with the Owner's criteria, as and if, modified. No review of such documents
shall relieve the Architect of responsibility for the accuracy, adequacy, fitness, suitability
or coordination of its work product.
ARTICLE V
CONSTRUCTION COST
5.1 The Construction Cost, if applicable, shall be defined in a contract for the specific
Project.
ARTICLE VI
INDEMNIFICATION AND HOLD HARMLESS
6.1 The Architect covenants and agrees to indemnify and hold harmless
Owner/Monroe County and Monroe County Board of County Commissioners from any
and all claims for bodily injury, including death, personal injury, and property damage,
including property owned by Monroe County, and any other losses, damages, and
expenses, including attorney's fees, court costs and expenses, which arise out of, in
connection with, or by reason of services provided by the Architect or its
Subcontractor(s), occasioned by the negligence, errors, or other wrongful act or omission
of the Architect, their employees, or agents.
6.2 The first ten dollars ($10.00) of remuneration paid to the Architect is for the
indemnification provided for above. Should any claims be asserted against the County by
virtue of any deficiency or ambiguity in the plans and specifications provided by the
Architect, the Architect agrees and warrants that he shall hold the County harmless and
shall indemnify him from all losses occurring thereby and shall further defend any claim
or action on the County's behalf.
6.3 In the event the completion of the project (to include the work of others) is delayed
or suspended as a result of the Architect's failure to purchase or maintain the required
insurance, the Architect shall indemnify County from any and all increased expenses
resulting from such delays. Should any claims be asserted against County by virtue of
any deficiencies or ambiguity in the plans and specifications provide by the Architect the
Architect agrees and warrants that Architect hold the County harmless and shall
indemnify it from all losses occurring thereby and shall further defend any claims or
action on the County's behalf.
6A The extent of liability is in no way limited to, reduced or lessened by the insurance
requirements contained elsewhere within the Agreement.
6.5 This indemnification shall survive the expiration or early termination of the
Agreement.
ARTICLE VII
7.1 PERSONNEL
The Architect shall assign only qualified personnel to perform any service concerning the
project.
ARTICLE VIII
8.1 PAYMENT
Terms of payment will be governed by state guidelines and/or hourly rates to be approved
by the County. Hourly rates are provided in Exhibit A and are subject to annual
affirmation. Details of payment will be set out in the specific separate contract.
8.2 REIMBURSABLE EXPENSES
Shall be negotiated and agreed to prior to award of the separate contract, but only to the
extent and the amounts authorized by Section 112.061, Florida Statutes; however prior to
incurring any expense written approval for any reimbursable expense must be obtained
from the County.
8.3 BUDGET
8.3.1 The Architect may not be entitled to receive, and the County is not obligated to
pay, any fees or expenses in excess of the amount budgeted for this Agreement in each
fiscal year (October 1- September 30) by County's Board of County Commissioners. The
budgeted amount may only be modified by an affirmative act of the County's Board of
County Commissioners.
9
8.3.2 AVAILABILITY OF FUNDS. if funding cannot be obtained or cannot be
continued at a level sufficient to allow for continued reimbursement of expenditures for
services specified in this Contract or in the separate contracts for individual projects, the
agreement may be terminated immediately at the option of the County by written notice
of termination delivered to the Architect. The County shall not be obligated to pay for
any services provided by the Architect after the Architect has received written notice of
termination, unless otherwise required by law.
8.3.3 The County does not guarantee Architect any specific amount of work or
contracts under this agreement. The parties shall enter into a separate contract for each
project awarded to the Architect by the County. The specific services to be performed
under these separate contracts will be determined by the County and agreed to by the
Architect. Each separate contract will contain specific scope of work, time schedule,
charges and payment conditions, and additional terms and conditions applicable to that
specific contract. Architect will be chosen pursuant to County policy and work will be
distributed among all contractors who have signed a continuing contract.
8.3.4 Monroe County's performance and obligation to pay under this contract is
contingent upon an annual appropriation by the Board of County Commissioners and the
approval of the Board members at the time of contract initiation and its duration.
ARTICLE IX
9.1 APPLICABLE LAW
This contract is governed by and construed in accordance with the laws of the State of
Florida applicable to contracts made and performed entirely in the State. Venue for any
mediation, dispute conferences or litigation arising under this contract must be in Monroe
County, Florida. The Parties waive their rights to a trial by jury.
ARTICLE X
10.1 OWNERSHIP OF THE PRELIMINARY DESIGN AND THE DESIGN
FOR CONSTRUCTION
10.1 The Drawings, Specifications and other documents prepared by the Architect for
this project are instruments of the Architect's service for use solely with respect to this
project, and the Architect shall be deemed the author of these documents and shall retain
all common law, statutory and other reserved rights, including reproducible copies, of the
Architect's Drawings, Specifications and other documents shall not be used by the Owner
or others on other projects except by agreement in writing and with appropriate
compensation to the Architect.
10.1.2 Submission or distribution of documents to meet official regulatory requirements
or for similar purposes in connection with the project is not to be construed as publication
in derogation of the Architect's reserved rights.
10
s
10.1.3 The As -Built drawings and specifications may be furnished by the Architect to the
Owner in electronic format in addition to the original As -Built documents.
10.1.4 The Owner may utilize the construction documents, As -Built documents, etc. as
required for reference on any necessary future work on the site, and for constructing,
using and maintaining the Project.
ARTICLE XI
11.1 SUCCESSORS AND ASSIGNS
The Architect shall not assign its right hereunder, excepting its right to payment, nor shall
it delegate any of its duties hereunder without the written consent of the Owner. The
Owner and Architect, respectively, bind themselves, their partners, successors, assigns
and legal representatives to the other party to this Agreement and to the partners,
successors, assigns and legal representatives of such other party with respect to all
covenants of this Agreement.
ARTICLE XII
NO THIRD PARTY BENEFICIARIES
AND INDEPENDENT CONTRACTOR RELATIONSHIP
12.1 NO THIRD PARTY BENEFICIARIES
Nothing contained herein shall create any relationship, contractual or otherwise, between
the parties which creates or gives rise to any rights in favor of, any third party.
12.2 INDEPENDENT CONTRACTOR RELATIONSHIP
The Architect is and shall be an independent contractor in the performance of all work,
services, and activities under this Agreement and is not an employee, agent or servant of
the County. The Architect shall exercise control over the means and manner in which it
and its employees perform the work and in all respects the Architect's relationship and
the relationship of its employees to the County shall be that of an independent contractor
and not as employees or agents of the County. The Architect does not have the power or
authority to bind the County in any promise, agreement or representation other than such
power and authority that is specifically provided for in this Agreement.
ARTICLE XIII
13.1 INSURANCE
13.1.1 The Architect shall obtain insurance as specified and maintain the required
insurance at all times that this Agreement is in effect. Professional Liability Insurance
shall also be maintained as specified. In the event the completion of the project (to
include the work of others) is delayed or suspended as a result of the Architect's failure to
11
purchase or maintain the required insurance, the Architect shall indemnify the County
from any and all increased expenses resulting from such delay.
13.1.2 The coverage provided herein shall be provided by an insurer with an A.M. Best
Rating of VI or better, that is licensed to do business in the State of Florida and that has
an agent for service of process within the State of Florida. The insurance certificate shall
contain an endorsement providing thirty (30) days notice to the County prior to any
cancellation of said coverage. Said coverage shall be written by an insurer acceptable to
the County and shall be in a form acceptable to the County.
13.1.3 Architect shall obtain and maintain the following policies:
A. Workers' Compensation insurance as required by the State of Florida.
B. Employers Liability Insurance with limits of $100,000 per Accident, $500,000
Disease, policy limits, $100,000 Disease each employee.
C. Comprehensive business automobile and vehicle liability insurance covering
claims for injuries to members of the public and/or damages to property of
others arising from use of motor vehicles, including onsite and offsite
operations, and owned, hired or non -owned vehicles, with One Hundred
Thousand Dollars ($100,000.00) combined single limit and One Hundred
Thousand Dollars ($100,000.00) annual aggregate.
D. Commercial general liability covering claims for injuries to members of the
public or damage to property of others arising out of any covered act or
omission of the Architect or any of its employees, agents or subcontractors or
subconsultants, including Premises and/or Operations, Independent
Contractors; Broad Form Property Damage and a Contractual Liability
Endorsement with Five Hundred Thousand Dollars ($500,000.00) per
occurrence and annual aggregate.
E. Professional liability insurance of Five Hundred Thousand Dollars
($500,000.00) per claim and One Million Dollars ($1,000,000.00) annual
aggregate. If the policy is a "claims made" policy, Architect shall maintain
coverage or purchase a "tail" to cover claims made after completion of the
project to cover the statutory time limits in Chapter 95 of the Florida Statutes.
F. County shall be named as an additional insured with respect to Architect's
liabilities hereunder in insurance coverage identified in Paragraphs C and D.
G. Architect shall require its subconsultants to be adequately insured at least to
the limits prescribed above, and to any increased limits of Architect if so
required by County during the tern of this Agreement. County will not pay
for increased limits of insurance for subconsultants.
12
H. Architect shall provide to the County certificates of insurance or a copy of all
insurance policies including those naming the County as an additional insured
by including any subsection thereunder. The County reserves the right to
require a certified copy of such policies upon request.
ARTICLE XIV
TERMINATION
14.1 Either party hereto may terminate this contract prior to expiration upon giving
seven (7) days written notice to the other in the event that such other party negligently or
for any reason substantially fails to perform its material obligations set forth herein. No
termination expenses shall be paid by the Owner after the date of notice of termination.
14.2 The Owner may terminate this Contract without cause by giving the other party
sixty (60) days written notice of its intention to do so. Termination expenses shall include
expenses available under the contract through the date on the notice of termination and
shall not include any additional services required in order to stop performance of
services, unless agreed to in writing by the County and subject to audit for the purpose of
verification.
ARTICLE XV
ENTIRE AGREEMENT
15.1 This contract constitutes of the form of agreement, the exhibits that are attached
and made a part of the contract, and the documents referred to in the form of agreement
as a part of this contract. In the event any conflict between any of those contract
documents, the one imposing the greater burden on the Architect will control.
15.2 A person or affiliate who has been place on the convicted vendor list following a
conviction for public entity crime may not submit a bid on contract to provide any goods
or services to a public entity, may not submit a bid on a contract with a public entity for
the property to public entity, may not be awarded or perform work as a
contractor, supplier, subcontractor, or consultant under a contract with any public entity,
and may not transact business with any public entity in excess of the threshold amount
provided in Section 287.017 of the Florida Statutes, for CATEGORY TWO for a period
of 36 months from the date of being placed on the convicted vendor list.
ARTICLE XVI
DISPUTE RESOLUTION
16.1 County and Architect agree that all disputes and disagreements shall first be
attempted to be resolved by meet and confer sessions between representatives of each of
the parties. If no resolution can be agreed upon within 30 days after the first meet and
confer session, the issue or issues shall be submitted to mediation before a mediator
13
mutually agreed to by the parties. The cost of mediation shall be shared equally. The
parties agree that mediation is a condition precedent to the institution of legal or equitable
proceedings by either party. Request for mediation shall be in writing and sent to the
other party. The parties shall agree on a mediator to hear the dispute.
16.2 Mediation shall be held in Monroe County Florida in a location in Key West; the
location may be moved only by mutual agreement of the parties.
16.3 Agreements reached in mediation shall be reduced to writing and signed by the
representative of each party; however agreements must be approved by the Board of
County Commissioners to be enforceable. Agreements reached in mediation shall be
enforceable as settlement agreements in any court having jurisdiction in Monroe County.
16.4 Nothing in this Agreement shall be construed to interfere with a subsequent order
from any court of competent jurisdiction ordering the parties to enter into mediation after
institution of legal or equitable proceedings.
16.5 Arbitration is specifically rejected by the parties as a method of settling disputes
which arise under this agreement; neither of the parties shall be compelled by the other to
arbitrate a dispute which may arise under this Agreement.
ARTICLE XVII
Additional Requirements
17.1 The following items are part of this contract:
a) Architect shall maintain all books, records, and documents directly pertinent to
performance under this Agreement in accordance with generally accepted accounting
principles consistently applied. Each party to this Agreement or their authorized
representatives shall have reasonable and timely access to such records of each other
party to this Agreement for public records purposes during the term of the Agreement and
for four years following the termination of this Agreement. If an auditor employed by the
County or Clerk determines that monies paid to Architect pursuant to this Agreement
were spent for purposes not authorized by this Agreement, the Architect shall repay the
monies together with interest calculated pursuant to F.S. Sec. 55.03, running from the
date the monies were paid to County.
b) Governing Law, Venue, Interpretation, Costs, and Fees: This Agreement
shall be governed by and construed in accordance with the laws of the State of Florida
applicable to contracts made and to be performed entirely in the State. In the event that
any cause of action or administrative proceeding is instituted for the enforcement or
interpretation of this Agreement, the County and Architect agree that venue will lie in the
appropriate court or before the appropriate administrative body in Monroe County,
Florida. The Parties waive their rights to a trial by jury. The County and Architect agree
that, in the event of conflicting interpretations of the terms or a term of this Agreement by
or between any of them the issue shall be submitted to mediation prior to the institution
14
of any other administrative or legal proceeding, pursuant to Section XVi of this
agreement.
c) Severability. If any term, covenant, condition or provision of this
Agreement (or the application thereof to any circumstance or person) shall be declared
invalid or unenforceable to any extent by a court of competent jurisdiction, the remaining
terms, covenants, conditions and provisions of this Agreement, shall not be affected
thereby; and each remaining term, covenant, condition and provision of this Agreement
shall be valid and shall be enforceable to the fullest extent permitted by law unless the
enforcement of the remaining terms, covenants, conditions and provisions of this
Agreement would prevent the accomplishment of the original intent of this Agreement.
The County and Architect agree to reform the Agreement to replace any stricken
provision with a valid provision that comes as close as possible to the intent of the
stricken provision.
d) Attorney's Fees and Costs. The County and Architect agree that in the
event any cause of action or administrative proceeding is initiated or defended by any
party relative to the enforcement or interpretation of this Agreement, the prevailing party
shall be entitled to reasonable attorney's fees and court costs expenses, as an award
against the non -prevailing party, and shall include attorney's fees and courts costs
expenses in appellate proceedings.
e) Binding Effect. The terms, covenants, conditions, and provisions of this
Agreement shall bind and inure to the benefit of the County and Architect and their
respective legal representatives, successors, and assigns.
f) Authority. Each party represents and warrants to the other that the
execution, delivery and performance of this Agreement have been duly authorized by all
necessary County and corporate action, as required by law. Each party agrees that it has
had ample opportunity to submit this Contract to legal counsel of its choice and enters
into this agreement freely, voluntarily and with advise of counsel.
g) Claims for Federal or State Aid. Architect and County agree that each
shall be, and is, empowered to apply for, seek, and obtain federal and state funds to
further the purpose of this Agreement; provided that all applications, requests, grant
proposals, and funding solicitations shall be approved by each party prior to submission.
h) Adjudication of Disputes or Disagreements. County and Architect agree
that all disputes and disagreements shall be attempted to be resolved under Section XVI
of this agreement. If no resolution can be agreed upon within 30 days after mediation,
then any party shall have the right to seek such relief or remedy as may be provided by
this Agreement or by Florida law.
i) Cooperation. In the event any administrative or legal proceeding is
instituted against either party relating to the formation, execution, performance, or breach
of this Agreement, County and Architect agree to participate, to the extent required by the
15
other party, in all proceedings, hearings, processes, meetings, and other activities related
to the substance of this Agreement or provision of the services under this Agreement.
County and Architect specifically agree that no party to this Agreement shall be required
to enter into any arbitration proceedings related to this Agreement.
j) Nondiscrimination. Architect and County agree that there will be no
discrimination against any person, and it is expressly understood that upon a
determination by a court of competent jurisdiction that discrimination has occurred, this
Agreement automatically terminates without any further action on the part of any party,
effective the date of the court order. Architect or County agree to comply with all
Federal and Florida statutes, and all local ordinances, as applicable, relating to
nondiscrimination. These include but are not limited to: 1) Title VI of the Civil Rights
Act of 1964 (PL 88-352) which prohibits discrimination on the basis of race, color or
national origin; 2) Title IX of the Education Amendment of 1972, as amended (20 USC
ss. 1681-1683, and 1685-1686), which prohibits discrimination on the basis of sex; 3)
Section 504 of the Rehabilitation Act of 1973, as amended (20 USC s. 794), which
prohibits discrimination on the basis of handicaps; 4) The Age Discrimination Act of
1975, as amended (42 USC ss. 6101-6107) which prohibits discrimination on the basis of
age; 5) The Drug Abuse Office and Treatment Act of 1972 (PL 92-255), as amended,
relating to nondiscrimination on the basis of drug abuse; 6) The Comprehensive Alcohol
Abuse and Alcoholism Prevention, Treatment and Rehabilitation Act of 1970 (PL 91-
616), as amended, relating to nondiscrimination on the basis of alcohol abuse or
alcoholism; 7) The Public Health Service Act of 1912, ss. 523 and 527 (42 USC ss.
690dd-3 and 290ee-3), as amended, relating to confidentiality of alcohol and drug abuse
patent records; 8) Title VIII of the Civil Rights Act of 1968 (42 USC s. et seq.), as
amended, relating to nondiscrimination in the sale, rental or financing of housing; 9) The
Americans with Disabilities Act of 1990 (42 USC s. 1201 Note), as maybe amended from
time to time, relating to nondiscrimination on the basis of disability; 10) Any other
nondiscrimination provisions in any Federal or state statutes which may apply to the
parties to, or the subject matter of, this Agreement.
k) Covenant of No Interest. Architect and County covenant that neither
presently has any interest, and shall not acquire any interest, which would conflict in any
manner or degree with its performance under this Agreement, and that only interest of
each is to perform and receive benefits as recited in this Agreement.
1) Code of Ethics. County agrees that officers and employees of the County
recognize and will be required to comply with the standards of conduct for public officers
and employees as delineated in Section 112.313, Florida Statutes, regarding, but not
limited to, solicitation or acceptance of gifts; doing business with one's agency;
unauthorized compensation; misuse of public position, conflicting employment or
contractual relationship; and disclosure or use of certain information.
m) No Solicitation/Payment. The Architect and County warrant that, in
respect to itself, it has neither employed nor retained any company or person, other than a
bona fide employee working solely for it, to solicit or secure this Agreement and that it
16
E
has not paid or agreed to pay any person, company, corporation, individual, or firm, other
than a bona fide employee working solely for it, any fee, commission, percentage, gift, or
other consideration contingent upon or resulting from the award or making of this
Agreement. For the breach or violation of the provision, the Architect agrees that the
County shall have the right to terminate this Agreement without liability and, at its
discretion, to offset from monies owed, or otherwise recover, the full amount of such fee,
commission, percentage, gift, or consideration.
n) Public Access. The Architect and County shall allow and permit
reasonable access to, and inspection of, all documents, papers, letters or other materials in
its possession or under its control subject to the provisions of Chapter 119, Florida
Statutes, and made or received by the Architect and County in conjunction with this
Agreement; and the Architect shall have the right to unilaterally cancel this Agreement
upon violation of this provision by County.
o) Non -Waiver of Immunity. Notwithstanding he provisions of Sec. 286.28,
Florida Statutes, the participation of the Architect and the County in this Agreement and
the acquisition of any commercial liability insurance coverage, self-insurance coverage,
or local government liability insurance pool coverage shall not be deemed a waiver of
immunity to the extent of liability coverage, nor shall any contract entered into by the
County be required to contain any provision for waiver.
p) Privileges and Immunities. All of the privileges and immunities from
liability, exemptions from laws, ordinances, and rules and pensions and relief, disability,
workers' compensation, and other benefits which apply to the activity of officers, agents,
or employees of any public agents or employees of the County, when performing their
respective functions under this Agreement within the territorial limits of the County shall
apply to the same degree and extent to the performance of such functions and duties of
such officers, agents, volunteers, or employees outside the territorial limits of the County.
q) Legal Obligations and Responsibilities: Non -Delegation of Constitutional
or Statutory Duties. This Agreement is not intended to, nor shall it be construed as,
relieving any participating entity from any obligation or responsibility imposed upon the
entity by law except to the extent of actual and timely performance thereof by any
participating entity, in which case the performance may be offered in satisfaction of the
obligation or responsibility. Further, this Agreement is not intended to, nor shall it be
construed as, authorizing the delegation of the constitutional or statutory duties of the
County, except to the extent permitted by the Florida constitution, state statute, and case
law.
r) Non -Reliance by Non -Parties. No person or entity shall be entitled to rely
upon the terms, or any of them, of this Agreement to enforce or attempt to enforce any
third -party claim or entitlement to or benefit of any service or program contemplated
hereunder, and the Architect and the County agree that neither the Architect nor the
County or any agent, officer, or employee of either shall have the authority to inform,
counsel, or otherwise indicate that any particular individual or group of individuals, entity
17
or entities, have entitlements or benefits under this Agreement separate and apart, inferior
to, or superior to the community in general or for the purposes contemplated in this
Agreement.
s) Attestations. Architect agrees to execute such documents as the County
may reasonably require including a Public Entity Crime Statement, an Ethics Statement,
and a Drug -Free Workplace Statement.
t) No Personal Liability. No covenant or agreement contained herein shall
be deemed to be a covenant or agreement of any member, officer, agent or employee of
Monroe County in his or her individual capacity, and no member, officer, agent or
employee of Monroe County shall be liable personally on this Agreement or be subject to
any personal liability or accountability by reason of the execution of this Agreement.
u) Americans with Disabilities Act of 1990 (ADA). The Architect will
comply with all the requirements as imposed by the ADA, the regulations of the Federal
government issued thereunder, and the assurance by the Architect pursuant thereto.
v) Disadvantaged Business Enterprise (DBE) Policy And Obligation. It is the
policy of the County that DBE's, as defined in C.F.R. Part 26, as amended, shall have the
opportunity to participate in the performance of contracts financed in whole or in part
with County funds under this Agreement. The DBE requirements of applicable federal
and state laws and regulations apply to this Agreement. The County and its Architect
agree to ensure that DBE's have the opportunity to participate in the performance of the
Agreement. In this regard, all recipients and contractors shall take all necessary and
reasonable steps in accordance with applicable federal and state laws and regulations to
ensure that DBE's have the opportunity to compete and perform contracts. The County
and the Architect and subcontractors shall not discriminate on the basis of race, color,
national origin or sex in the award and performance of contracts, entered pursuant to this
Agreement.
w) Execution in Counterparts. This Agreement may be executed in any
number of counterparts, each of which shall be regarded as an original, all of which taken
together shall constitute one and the same instrument and any of the parties hereto may
execute this Agreement by singing any such counterpart.
18
I Section Headings. Section headings have been inserted in this Agreement
er of convenience of reference only, and it is agreed that such section headings
are not a part of this Agreement and will not be used in the interpretation of any provision
of this Agreement.
IN WITNESS WHEREOF, each party caused this Agreement to be executed by its duly
authorized representative on the day and year first above written.
(SEAL) BOARD OF COUNTY COMMISSIONERS
Attest: DANNY L. KOLHAGE, Clerk OF MONROE COUNTY, FLORIDA
B
By:
Deputy Clerk Mayor/airman
i s it_t nir VJ. _%H a ".FL
ASGASTP.NT All CY41
WITNESS TO Architect's
By: C21L.�— 0/
WITNESS Si ature
'� U i • (� Q. lti
Print Witness Name
Date:&Oui9.zG��
Date: DEC 1 6 2009
1AJA41AM VAAN h6h N,l1f)Pfi .
(INSERT NAA of Architect)
Lo
of Corporate Agent
1bblAm P, AVAP
Print Na7;71;7o
of
rate Agent
Date:
�cti001
C S�A�G��32g3
0
0,BptiOik
END OF AGREEMENT
19
—3.
C-)
c^ =
O
.
O
rr rn
p
SECTION FIVE
INSURANCE REQUIREMENTS AND INDEMNIFICATION STATEMENT
Insurance Requirement
Worker's Compensation
Employer's Liability
General Liability
Vehicle Liability
Architects Errors and Omissions Liability
Required Limits
Statutory Limits
$100,0001$500,0001$100,000
$100,000 Combined Single Limit
$100,000 Combined Single Limit per
Occurrence/$1,000,000 Aggregate
$500,000 per occurrence/ $1,000,000
Aggregate
IDEMNIFICATION AND HOLD HARMLESS FOR CONSULTANTS AND
SUBCONSULTANTS
The Architect/Consultant covenants and agrees to indemnify, hold harmless and defend
Monroe County, its commissioners, officers, employees, agents and servants from any
and all claims for bodily injury, including death, personal injury, and property damage,
including property owned by Monroe County, and any other losses, damages, and
expenses of any kind, including attorney's fees, court costs and expenses, which arise out
of, in connection with, or by reason of services provided by the Architect or Consultant
or any of its Subcontractor(s) in any tier, occasioned by the negligence, errors, or other
wrongful act or omission of the Architect/Consultant, including its Subcontractor(s) in
any tier, their officers, employees, servants or agents.
In the event that the completion of the project (to include the work of others) is delayed
or suspended as a result of the Architect/Consultant's failure to purchase or maintain the
required insurance, the Architect/Consultant shall indemnify the County from any and all
increased expenses resulting from such delay. Should any claims be asserted against the
COUNTY by virtue of any deficiency or ambiguity in the plans and specifications
provided by the Architect/Consultant, the Architect/Consultant agrees and warrants that
Architect/Consultant shall hold the County harmless and shall indemnify it from all
losses occurring thereby and shall further defend any claim or action on the County's
behalf.
The first ten dollars ($10.00) of remuneration paid to the Architect/Consultant is
consideration for the indemnification provided for above.
20
The extent of liability is in no way limited to, reduced, or lessened by the insurance
requirements contained elsewhere within this agreement.
This indemnification shall survive the expiration or earlier termination of the Agreement.
RESPONDENT'S STATEMENT
I understand the insurance that will be mandatory if awarded t contract and will comply
in fall with all the requirements. ,J
w144o1Am A ,Po4N
Respondent
21
INSURANCE AGENT'S STATEMENT
I have reviewed the above requirements with the Architect named below. The following
deductibles apply to the corresponding policy.
POLICY
r
'✓2 (� � c lc �r'G � �
Liability policies are
Insurance Agency
The Fullers Ins.
1432 Kennedy Dr.
Key West, FL 33040
✓ Occurrence
22
DEDUCTIBLES
c�
D
Claims Made
Signatu
Print N
' ji onroe Cn!n4y
-rb i ,
WE—
WILLIAM P. HORN ARCHITECT, P.AECENED BY: AA 0003040
915 EATON STREET, KEY WEST, FLORIDA 33040 PHONE: 305-296-8302 FAX: 305-296-1033
Date:11/20/09
To: Jerry Barnett
Facilities Deyelopment Coordinator
Monroe County
Re: Hourly Rates
Annual Contract
Dear Mr. Barnett,
Our standard hourly rates are as follows:
Principal Architect $195.00/hr
Architect
$130.00/hr
Intern Architect
$100.00/br
Draftsperson
$85.00/hr
Structural Engineer
$150.00/hr
MEP Engineer
$125.00/hr
Principal Civil Engineer $150.00/hr
Senior Civil Engineer
$120.00/hr
Civil Engineer
$.100.00/hr
Please call if you have any questions. We are looking forward to working
with you. ,
Sincerely
P. HORN ARCHITECT, P.A.
William P. Horn,
Principal
SECTION SIX
COUNTY RESPONSE FORMS
RESPOND TO: MONROE COUNTY BOARD OF COUNTY COMMISSIONERS
c/o PURCHASING DEPARTMENT
GATO BUILDING, ROOM 1-213
1100 SIMONTON STREET
KEY WEST, FLORIDA 33040
I acknowledge receipt of Addenda No.(s) ON% 4 71W a
I have included:
o The Response Form 6
o Lobbying and Conflict of Int7est Clause (.
o Non -Collusion Affidavit d
o Drug Free Workplace Formy
o Respondent's Insurance and Inder�r reification Statement IJ
a Insurance Agent's Statement
o Professional and Occupational Licenses L/
I have included a current copy of the following professional and occupational licenses:
(Check mark items above, /as a reminder that they are included.)
Mailing Address: 9 / 6 Ayw .6r.
Telep
Date:
Signet
1/j/1& AM e• CYtN
(Name)
(Title)
Z 6-10 33
itness- 9
(Seal)
ljOTMy PUBLIC -STATE OF FLO I h
,•• •.,David W.GangWi
- Commission # DD603253
Expire$: OCT. 08, 2010
BONAED'IiiRU A77ANFl
�ao.•' C BONDING CO., INC.
23
LOBBYING AND CONFLICT OF INTEREST CLAUSE
SWORN STATEMENT UNDER ORDINANCE NO.010-1990
MONROE COUNTY, FLORIDA
ETHICS CLAUSE
(Company)
"... warrants that he/it has not employed, retained or otherwise had act on his/its
behalf any former County officer or employee in violation of Section 2 of Ordinance No.
010-1990 or any County officer or employee in violation of Section 3 of Ordinance No.
010-1990. For breach or violation of this provision the County ay, in its discretion,
terminate this Agreement without liability and may also, in its d' cretion, deduct from the
Agreement or purchase price, or otherwise recover, the 1I amount of any fee,
commission, percentage, gift, or consideration paid to tl} former County officer or
employee".
(Signa
Date:
STATE. OF: 1�
COUNTY OF:
Subscribed and sworn to (or affirmed) before me on�
(date) by C.t>i//.ay P �d;-,x (name of affiant).
personally known to me or has produced —
as identification. (type of identificatinn)
He/She is
My commission Soh
�4 aw �o� 3
,,,,.,, , ,paw on #UA 2p1�
s+,' 1 per.
F,xpi��� caorD�N
24
DRUG -FREE WORKPLACE FORM
The undersigned vendor in accordance with Florida Statute 287.087 hereby certifies
that:
AN14/0m
(Name of Business)
1. Publish a statement notifying employees that the unlawful manufacture, distribution,
dispensing, possession, or use of a controlled substance is prohibited in the workplace
and specifying the actions that will be taken against employees for violations of such
prohibition.
2. Inform employees about the dangers of drug abuse in the workplace, the business's
policy of maintaining a drug -free workplace, any available drug counseling, rehabilitation,
and employee assistance programs, and the penalties that may be imposed upon
employees for drug abuse violations.
3. Give each employee engaged in providing the commodities or contractual services
that are under bid a copy of the statement specified in subsection (1).
4. In the statement specified in subsection (1), notify the employees that, as a condition
of working on the commodities or contractual services that are under bid, the employee
will abide by the terms of the statement and will notify the employer of any conviction of,
or plea of guilty or nolo contendere to, any violation of Chapter 893 (Florida Statutes) or
of any controlled substance law of the United States or any state, for a violation
occurring in the workplace no later than five (5) days after such conviction.
5. Impose a sanction on, or require the satisfactory participation in a drug abuse
assistance or rehabilitation program if such is available in the employee's community, or
any employee who is so convicted.
6. Make a good faith effort to continue to maintain a drug -free workplace through
implementation of this section.
As the person authorized to sign a statement, I certify that this firm complies fully with
the above requirements.
Respondent's Signature
111171099
25
NON -COLLUSION AFFIDAVIT
I, &i Il i h rA of the city of
according to law on my oath, and under penalty of perjury, depose and say that:
1. I am G✓1a'1Arh P. do n N
of the firm of ZA11 L" M j?,; d/l� ,A&4# 404 , A .
the bidder making the Proposal for the project described in the Request for
Qualifications for:
and that I executed the said proposal with full authority to do so:
2. the prices in this bid have been arrived at independently without collusion,
consultation, communication or agreement for the purpose of restricting
competition, as to any matter relating to such prices with any other bidder or
with any competitor;
3. unless otherwise required by law, the prices which have been quoted in this
bid have not been knowingly disclosed by the bidder and will not knowingly
be disclosed by the bidder prior to bid opening, directly or indirectly, to any
other bidder or to _any competitor; and
4. no attempt has been made or will be made by the bidder to induce any other
person, partnership or corpor tion to submit, or not to submit, a bid for the
purpose of restricting comp tion;
5. the statements contained i this affidavit are true and correct, and made with
full knowledge that Mop%oe County relies upon the truth of the statements
contained in this affidavit in awarding contracts for said project.
,s f D
(Signature of Respondent) (bate)
STATE OF:r'/��
COUNTY OF:��
PERSONALLY APPEARED BEFORE ME, the undersigned authority, Ga%an,14 ►-17
who, after first being sworn by me, (name of individual signing) affixed
his/her signature in the space provided above on this /1day of jklo
202?f -- /I ---,N /
NOTARY PU LI y p C-STAI1;
My Commission re i.. Ad W.GanSwlSch
Commission # Ap603253
,01
OS, 2010
DING Co.,
Expires: ACT INC.
Eoy
BONDED T!'IA
26
IDEMNIFICATION AND HOLD HARMLESS FOR CONSULTANTS AND
SUBCONSULTANTS
The Architect/Consultant covenants and agrees to indemnify, hold harmless and defend
Monroe County, its commissioners, officers, employees, agents and servants from any
and all claims for bodily injury, including death, personal injury, and property damage,
including property owned by Monroe County, and any other losses, damages, and
expenses of any kind, including attorney's fees, court costs and expenses, which arise out
of, in connection with, or by reason of services provided by the Architect or Consultant
or any of its Subcontractor(s) in any tier, occasioned by the negligence, errors, or other
wrongful act or omission of the Architect/Consultant, including its Subcontractor(s) in
any tier, their officers, employees, servants or agents.
In the event that the completion of the project (to include the work of others) is delayed
or suspended as a result of the Architect/Consultant's failure to purchase or maintain the
required insurance, the Architect/Consultant shall indemnify the County from any and all
increased expenses resulting from such delay. Should any claims be asserted against the
COUNTY by virtue of any deficiency or ambiguity in the plans and specifications
provided by the Architect/Consultant, the Architect/Consultant agrees and warrants that
Architect/Consultant shall hold the County harmless and shall indemnify it from all
losses occurring thereby and shall further defend any claim or action on the County's
behalf.
The first ten dollars ($10.00) of remuneration paid to the Architect/Consultant is
consideration for the indemnification provided for above.
The extent of liability is in no way limited to, reduced, or lessened by the insurance
requirements contained elsewhere within this agreement.
This indemnification shall survive the expiration or earlier termination of the Agreement.
RESPONDENT'S STATEMENT
I understand the insurance that will be mandatory if awarded the'contract and will comply
in full with all the requirements.
Respondent Sign 'a etur
27
ST-ATE-,,'p TLORIDA...
X0
3,2 3 37.'
CITY OF KEY WEST. FLORIDA
Business Tax Receipt
This Document is a business tax receipt
Holder must meet all City zoning and use provisions.
P.O. Box 1409, Key West, Florida 33040 (305) 809-3955
Business Name HORN, WILLIAM Ct1Nbr:0003377
Location Addr 915 EATON ST
Lic NBR/Class 11-00006982 SERVICE - PROFESSIONAL
Issue Date: September 24, 2010 Expiration Date:September 30, 2011
License Fee $309.75
Add. Charges $0.00
Penalty $0.00
Total $309.75 -
Comments: ARCHITECT doer , '-l?'i�+ �1 �e=E=�`. 157t
Dek E
s document must
HORN, WILLIAM
915 EATON ST
KEY WEST FL 33040
OR LIti
>minently`r;di' p�la
�.;.g
HORN, WI?�MPW;R:
'10 1 L-309.75
. 11
?rar,: sate: 3/27/ :'0+
rt 1. 1.
�.itU�
.�_ .15 7J
28H: i2.34: A
2010 2011
MONROE COUNTY BUSINESS TAX RECEIPT
EXPIRES SEPTEMBER 30, 2011
Business Name: WILLIAM P HORN ARCHITECT
Owner Name: WILLIAM P HORN
Mailing Address: 915 EATON ST
KEY WEST, FL 33040
Rooms Seats
Number of Machines:
RECEIPT# 46110-61429
Business Location: 915 EATON ST
KEY WEST, FL 33040
Business Phone: 305-296-8302
Business Type: PROFESSIONALS (PROFESSIONAL ARCHITEC
Employees Machines Stalls
9
Vending TYoe:
unt
Transfer Fee
Sub-t to _..
Penalty
Prior Years
Collection Cost
Total Pai
�30.00
0.00
30.00
0.00 1
0.00 1
0.00
30.00
Paid 123-09-0000898-7 09/17/2010 30.00
THIS RECEIPT MUST BE POSTED CONSPICUOUSLY IN YOUR PLACE OF BUSINESS
THIS BECOMES A TAX RECEIPT Danise D. Henriquez, CFC, Tax Collector THIS IS ONLY A TAX.
WHEN VALIDATED PO Box 1129, Key West, FL 33041 YOU MUST MEET ALL
COUNTY AND/OR
MUNICIPALITY PLANNING
AND ZONING REQUIREMENTS.