Item B23
BOARD OF COUNTY COMMISSIONERS
AGENDA ITEM SUMMARY
Meeting Date: 04-20-00
Division: Growth Management
Bulk Item:YES X NO
Department:Marine Resources
AGENDA ITEM WORDING: Approval of the Amendment to the Agreement between
Monroe County and Arnold's Towing for the removal of derelict vessels Zone I-lower
Keys.
ITEM: The original Contract Agreement states in section 4 that three partial payments
will be allowed during the Contract period. Contractor is in the process of submitting
his third billing and there are two months remaining under the Contract. This
Amendment will allow us to fully utilize the funding.
PREVIOUS RELEV ANT BOCC ACTION: Approval to call for bids approved 2-11-
98, Contract with Key West Towing Approved 6-10-98, Cancellation of Contract with
Key West Towing approved 7-22-98, Contract with Arnold's Towing approved 7-22-
99.
ST AFF RECOMMENDATION: Approval
BUDGETED:
TOTAL COST: $ 50,000
COST TO COUNTY: Staff Time Only
BIF
REVENUE PRODUCING: YES
NO X AMT. PERMO.
YEAR
DIVISION DIRECTOR APPROVAL:
Timothy J. McG
APPROVED BY:COATTY X OMB/PURCH
DEPARTMENT HEAD APPROVAL:
Geor
DOCUMENTATION: INCLUDED: X TO FOLLO: NOT REQUIRED:
DISPOSITION: - AGEN~A ITEM #~
MOJ'j'ROE COUl\TY BOARD OF COUNTY COMl\fISSIONERS
CONTRACT SUMMARY
Contract #
Contract wiLl].: Arnold's Towing Effective Date: _/ _/ _
Expiration Date: / /
Contract Purpose/Description: _ Ammendment to the Agreement for a time extlmsiOii:'"-
Contract Manager: Kim McGee
(Name)
4511
(Ext. )
Marine Proiects
(Department)
for BOCC meeting on 4.1 20
00
Agenda Deadline: 4 I 3 /00 (GM)
CONTRACT COSTS
Total Dollar Value of Contract: $ 50.000 Current Year Portion: $ 50,000
Budgeted? Yes_No . Account Codes: 157_ 62550 530 340
Grant: $ 50,000 BIF
County Match: $
ADDmONAL COSTS
Estimated Ongoing Costs: $ N/A Iyr For:
(Not included in dollar value above) (eg. maintenance. utilities, janitorial, salaries, etc.)
Reviewer
Date Out
Date In
Division Director ij~/~ ( )
~:!t ':LI 1~.J .fJJ2 ( )
. .B. g )
County Attorney
L/~J~
~I .&/ 00
.f)? led
AMENDMENT T 0 AGREEMENT
THIS AMENDMENT TO THE AGREEMENT is made and entered into this
day of 2000, between the County of Monroe, hereafter
County, and Arnold's Towing, hereafter Contractor, in order to amend the agreement
between the parties dated July 22, 1999, a copy of which is attached to this
amendment.
The County and Arnold's Towing, amend section 4 of the July 22, 1999
agreement as follows:
4. The Board shall pay the Contractor $42.00 per linear foot for the removal
and legal disposal of Florida Marine Patrol marked derelict vessels. Payment
will be upon completion of work by the Contractor and and review an approval
by the Marine Projects Coordinator. Five partial payments will be allowed
during the Contract period.
.
IN WITNESS WHEREOF, the parties have here on to set their hands and seal,
the day and year first written above.
BOARD OF COUNTY COMMISSIONERS
OF MONROE COUNTY, FLORIDA
By:
Mayor / Chairman
(Seal)
Attest: Danny L. Kolhage
Arnold's Towing
By:
;j /1
\l{lc-c-.;J ~.'-: v~R
By:
Title: tJW<<EI(
(Seal)
Attest:
By:
CONTRACT AGREEMENT
AGREEMENT, MADE THIS ~day of -S\l.\y 1999, by and
between, Arnold's Towing ("Contractor"), and the BOARD OF
COUNTY COMMISSIONERS OF MONROE COUNTY, FLORIDA, of the County of
Monroe, State of Florida ("Board").
The Contractor and the Board, for the consideration named agree as follows:
1. The Contractor shall furnish all the materials and perform all the work as
required by the Specifications for the removal of Derelict Vessels located in the
nearshore waters of the lower Keys.
2. The work to be performed under this contract shall commence immediately from
the date the Liaison provides the Notice to Proceed and shall be completed by
June 30, 2000.
3. The Contractor understands the rules of the Florida Department of
Environmental Protection and shall comply with those rules, along with the rules and
procedures instituted by the Board to ensure an orderly progress to the project. Both
the intent and the requirements of the specifications, attached as Exhibit A, are
understood by the Contractor.
4. The Board shall pay the Contractor $42.00 per linear foot for the removal and
legal disposal of Florida Marine Patrol marked derelict vessels. Payments will be
upon completion of work by the Contractor and review and approval by the Marine
Projects Coordinator. Three partial payments will be allowed during the Contract
period.
1
5. The attached Specifications, and Monroe County Insurance Requirements
together with this Agreement, form the Contract. They are fully a part of this Contract
as if repeated herein verbatim.
6. The Contractor covenants and agrees to indemnify and hold harmless the
Monroe County Board of County Commissioners from any and all claims for bodily
injury (including death), personal injury and property damage (including property
owned by the County) and other losses, damages, and expenses (including attorney's
fees) which arise out of, in connection with, or by reason of services provided by the
Contractor or any of its Subcontractor (s) in any tier, their employees or agents. The
purchase of the insurance required in paragraph 11 does not vitiate this indemnification
provision.
7. The Contractor agrees to supply the County with a set of photographs of each
vessel in all phases of the removal and disposal process. The Contractor will be
responsible for the camera, film, and development costs.
8. The Contractor must inform the County and the Florida Marine Patrol prior to
initiation of work.
9. The parties agree that a timely performance of this agreement is essential due to
possible damage to the natural resources, hazards to navigation, or threats to human
health and welfare. Therefore, the parties agree that the Contractor shall be liable to
the Board for $100 per day of liquidated damages for each day after June 30, 2000
that the Contractor's obligations under this agreement remain unperformed. The
parties agree that such amount is by the way of compensatory damages and does not
constitute a penalty.
2
10. Due to the use of heavy equipment and, at times, dangerous work environment,
the Contractor understands and agrees to maintain an alcohol an drug free work
environment.
11. The Contractor will be responsible for all necessary insurance coverage as
indicated by an "X" on the attached forms identified as INSCKLST 1-4, as further
detailed on forms VL1, WC1, WCJA, GL1, WL1, & POLl attached as Exhibit B. All
policies must list Monroe County as additional insured with the exception of the
Worker's Compensation policy.
12. A person or affiliate who has been placed on the convicted vendor list
following a conviction for public entity crime may not submit a bid on a contract to
provide any goods or services to a public entity, may not submit a bid on a contract
with a public entity for the construction or repair of a public building or public work,
may not submit bids on leases of real property to public entity, may not be awarded or
perform work as a contractor, supplier, subcontractor, or consultant under a contract
with any public entity, and may not transact business with any public entity in excess of
the threshold amount provided in Section 287.017, for CATEGORY TWO ($10,000)
for a period of 36 months from the date of being placed on the convicted vendor list.
13. The Contractor warrants that it has not employed, retained or otherwise had
act on its behalf any former County officer or employee subject to the prohibition of
Section 2 of Ordinance No. 010-1990 or any County officer or employee in violation of
Section 3 of Ordinance No. 020-1990. For breach or violation of this provision, the
owner may, in its discretion, terminate this contract without liability and may also, in
its discretion, deduct from the contract or purchase price, or otherwise recover the full
3
amount of any fee, commission, percentage, gift, or consideration paid to the former
County officer or employee.
14. The Board may terminate this agreement with or without cause at anytime
upon giving the contractor a minimum of ten days in writing. The Contractor, upon
receipt of the notice, shall immediately cease work. The Board shall pay the contractor
the percentage of the contract sum which is proportional to the amount of work
performed by the Contractor in a manner satisfactory to the Board up to the date the
Contractor received the Notice of Termination.
IN WITNESS WHEREOF the parties hereto have executed this Agreement to day
- '.,.....
, ~ ~:~tfi.~~t written above.
-".,.,
'. . '.~'" '. ,'"'.
. -' '!"-t, , '"
. (SEA~)"':
Attest: . DANNy L KOLHAGE, CLERK
r.1~~
~ DePuty Clerk
Witness: ~ ~~
Witness:ln...... ~.. - t.:'f-.r.~: ~ ~
BOARD OF COUNTY COMMISSIONERS
\ ~i~~~~E ,c~~::-\{:o~~. ,
Mayor/Chairman
BUS:7l~~
By: ~
Title: ~AfIt.M-
4
EXHIBIT A
DERELICT VESSEL REMOVAL CONTRACT SPECIFICATIONS'
FOR MONROE COUNTY, FLORIDA
1 . INTENT: It is intended that these specifications shall cover all aspects of the work.
The purpose of this section is to provide specific conditions applicable to this
contract where such coverage is not provided in other portions of the documents.
2, BID FORMAT: A dollar amount per foot must be submitted for the removal of as
many derelict vessels on the primary list for which a Florida Marine Patrol Derelict
Vessel Report is provided and as funding will allow. Any deviation from this
format will result in an unaccented bid. A contract will not be granted on the basis
of combined, related, linked, or discounted bids. Not applicable due to emergency
removal of one or more derelict vessels for less than $25,000 total.
3. PLANS: There are no plans for this project, but copies of the Florida Marine
Patrol Derelict Vessel Report with location sketches have been bound into these
documents for the Contractor's use. The Specifications include a section on
instructions to bidders, both general and specific, and a copy of each Derelict
Vessel Report from the Florida Marine Patrol. Only those derelict vessels for
which a report is included and listed on the Bid Response Form are to be bid upon
and subsequently removed.
The County reserves the right to remove any or all vessels from this contract at any
time prior to actual removal from the water and disposal by the Contractor.
The County has a limited amount of money to effect the removal of these derelict
vessels. We have established priorities based on public safety, navigational hazard,
and environmental considerations. Ifbids exceed the County's resources for
removal based on these considerations, we shall limit vessel removal based on the
considerations and cost effectiveness.
4. VESSEL IDENTIFICATION AND LOCATION: Each ofthe vessels have been
given a derelict vessel identification number, which is shown with the location in
the Florida Marine Patrol Derelict Vessel Report, included herewith.
Each bidder is respon"sible for his own identification of each derelict vessel as to
location, description and condition. If a derelict vessel cannot be (l) located, (2)
removed, (3) verified and (4) disposed of, as specified in these procedures, then no
payment will be made forthcoming to the Contractor for that vessel. Those four
conditions mllst he met on each derelict vessel along with compliance of all laws
for payment to he made.
, ._,
r-
It is understood that the Contractor has, by personal examination and inquiry, if
necessary, satisfied himself as to local conditions of each derelict vessel and as to
the meaning, requirements and reservations of the specifications; for after contract
letting, no deviation will be allowed. In case errors are discovered, they are
to be reported by the Contractor to the County. The county assumes no
responsibility should there be any discrepancies in what is stated in these
documents and what the bidder evaluates.
The Contractor should take special care to remove only those derelict vessel's on
his Contract and for which he possesses a Florida Marine Patrol Derelict Vessel
Report. Other derelict vessels in the area but not under Contract, cannot be
molested.
It may be possible to replace a derelict vessel of like kind, for the same or less
money, when mutual agreement can be reached by the Florida Department of
Environmental Protection, Monroe County Administrator of the Derelict Vessel
Program, and the Contractor. This will be applicable when a contracted derelict
vessel cannot be located. No derelict vessel may be replaced and removed without
the tri-party consent noted in this paragraph. A contractor may suggest a possible
replacement vessel but he may not remove it without the appropriate consent above.
5. SCOPE OF WORK: The Contractor shall be responsible for providing all permits,
supervision, labor, equipment, tools, fees and taxes required to complete this
project to the satisfaction of the County.
The Contractor's procedure and methods of removal may. be of his own selection
provided they secure results which satisfy the requirements of the Specifications
and any necessary environmental permits.
Any vessel which is removed and disposed of shall be removed from its present site
in such a manner as to do the least possible damage to the natural environment.
All debris from the vessel shall be removed and the site left in a reasonably clean
condition. No oil or fuel shall be permitted to be dumped or spilled into or unto the
water or land. All pollutants shall be removed from the derelict vessel prior to
removal from the water.
The Contractor shall be responsible for making any and all arrangement for access
to the vessel to be removed. If private property has to be traversed. then written
permission of the owner is necessary. In removing a derelict vessel that may lie 011
or near grass or sponge flats extreme caution must be used to do the least possihle
damage.
l _ - ...
r
,
Prior to delivery of derelict vessels to the disposal site, the Contractor must remove
all oil, gas and engines. He must dispose of them in any legal manner. Pure used
oil will be taken by Monroe County for disposal. Mixture of oil, gas, seawater or
any combination of the three must be transported from the County by an approved
hazardous waste handler. The names of handlers will be supplied by the Monroe
County Solid Waste Department. Metal becomes the property of the Contractor.
6. MA TERIALS AND WORKMANSHIP: The Contractor shall provide the
necessary materials and equipment to safely complete the job. The Contractor
agrees that all work shall be performed by competent employees who are
experienced and qualified to do the work specified, and that all work will be
performed in accordance with the best commercial practices. A list of equipment
to be used and a description of the removal and transporting procedures to be
followed must be provided to the County at the pre-work conference described
below.
Precaution shall be exercised at all times for the protection of persons and property.
The safety provisions of the Occupational Safety and Health Act of 1970 (Public
Law 91-596) and other applicable laws, including building and construction codes
shall be observed. Machinery, equipment and other hazards shall be guarded in
accordance with safety provisions of the "Manual of Accident Prevention in
Construction", published by the Associated General Contractors of America, to the
extent that such provisions are not in contradiction of applicable law.
If any property is destroyed by any cause or means whatsoever, the Contractor shall
repair and replace or not receive payment for the unaccomplished work. The
Contractor shall maintain suitable and sufficient guards and barriers, and at night,
suitable and sufficient light or other appropriate security or protection for the
prevention of accidents.
Use of explosives is prohibited in carrying out the project.
7. ASSIGNMENT OF CONTRACT AND SUBCONTRACTS: It is expressly
understood that the Contractor is in all respects an indepepdent Contractor for this
work, not withstanding under certain conditions he is bound to follow the
directions of the County, and is in no respect an agent, servant, or employee of the
County, Neither the Contract, nor any part thercof, nor any Moines due or to
becomc duc thereunder, may be assigned by the Contractor without the prior
written approval of the County.
1--- ,
r -
3
The Contractor is fully responsible to the County for the acts and omissions of his
subcontractors and of persons either directly or indirectly employed by said
subcontractor, as he is for the acts and omissions of perso,ns directly employe'd by
him. Nothing contained in the relation between any subcontractors shall abide by
the terms, conditions, and requirements of this Contract. It is the responsibility of
the Contractor to pay all debt obligations incurred with subcontractors in an
expedient manner.
8. LEGAL RESTRICTIONS, PERMITS AND TRAFFIC PROVISIONS: The
Contractor shall comply with all applicable local, State and Federal requirements
pertaining to the terms of this Contract. The Contractor will be responsible for
obtaining, at his own expense, any licenses or permits that may be required and
should inquire about permit requirements with the appropriate agencies. The
Contractor shall comply with all the requirements of the Federal Pollution Control
Act.
The Contractor shall conduct his operations so that he shall not close any
thoroughfare nor interfere in any way with traffic on high, ways, or on water,
without the written consent of the proper authorities. Work shall be done at any
time that shall not interrupt or disturb members of the public.
Utilization of off-loading sites located on private property (water to land for
transport to the landfill or other disposal site by vehicle) must have written
approval of the land owner.
The Florida Marine Patrol should be contacted to initiate eviction proceedings for
contracted derelict vessels which are inhabited at the time of removal and when
another vessel is too close to the contracted derelict vessel to allow safe operations.
Direct confrontations with other boaters should be avoided and the Florida Marine
Patrol should be contacted immediately if such confrontations results from removal
of any contracted derelict vessels.
9. INSURANCE: The Contractor must obtain insurance required by the County and
submit proof of same to the County prior to acceptance of bid and contract approval
by Board of County Commissioners but no later than five working days after notice
of low bidder. All insurance shall be maintained until work has been completed
and accepted by the County.
The Contractor shall furnish the following certificates of insurance for review bv
the County's Risk Management Division:
Certificate (s) of Insurance which clearly indicates that he has ohtained the
insurance cover:Jgc required in paragraphs a.b.c and d below.
t
.1
The Contractor hereby certifies that no modification or change in insurance shall be
made without (10) days written advance notice to MONROE County, c/o th~
Director of the Risk Management Division.
a. Worker's Compensation Insurance per Fl. Statutes
b, Federal Jones Act Coverage
c. General Liability Insurance on a comprehensive basis, in an amount not less than
$500,00.00 per occurrence for Bodily Injury and Property Damage combined, to
include contractual liability,
c. Pollution Liability Insurance in the Amount of $500,000.
d. Water Craft Liability Insurance in the Amount of$500,000.
e. Automobile liability insurance covering all owned, non-owned and hired vehicles
used in connection with the work, in an amount not less than
$300,000 per occurrence for Bodily Injury and Property and Damaged combined.
All insurance policies required above shall be issued by companies authorized to do
business under the laws of the state of Florida. The MONROE County Board
of County Commissioners must be listed as "Additional Insured" on all policies,
except for the Worker's Compensation policy.
10. COMMENCEMENT, DELAYS AND COMPLETION OF WORK: After
receiving Board of County Commission approval of the Gontract, and after
reconciliation of any details or conditions which may directly or indirectly interfere
or conflict with work of the Contract, the County will issue a "Notice to Proceed"
officially authorizing the Contractor to commence. The Contractor shall
commence work within one week from the date on the "Notice to Proceed" letter.
If the Contractor should be delayed in the progress of the work included in the
Contract by enforceable causes beyond his control, the time for the completion of
the work may be extended upon agreement of the County representative. Requests
for an extension of time must be submitted in writing to the County representative.
Extensions of time c~nnot legally be approved unless the written request is
submitted in the time to pennit it to be acted upon before the Contract expiration
date. To allow sufficient time for the administrative procedures required to obtain
action by the County Commission, a request for time extension must be received by
the County representative at least sixty (60) calendar days prior to the Contract
expiration date,
t---
5
Provided further that the Contractor shall within ten (10) days from the beginning
of such delay notify the County, in writing, of the causes of the delay. The <;:ounty
representative will ascertain the facts and the extent of the delay and notify the
Contractor within a reasonable time of her decision in the matter.
If the Contractor fails to complete the work within the time limit, and if the County
should nevertheless permit the Contractor to continue and complete the same
without official extension of time in writing, such permission shall not modify nor
waive any liability of the Contractor for damages arriving non-completion of work
within the time limit, but such liabilities shall be subject to continuation in full
force against the contractor.
11, CHANGES AND INSPECTION: The vessels herein considered are to be removed
for the County by the Contractor in accordance with the specifications. The County
may give instructions or directions to supplement the specifications. These shall be
binding upon the Contractor and upon all his subcontractors, employees and agents
of every kind.
All work and every process and operation shall be subject to inspection at all
times, and the County and their representatives shall have free access to all aspects
of the work. The Contractor shall remove and make good, as may be directed,
without charge, any defective work. Oversight or error of judgment of
inspections. or previous acceptance, shall not relieve the Contractor from the
obligation to make good any defect whenever discovered.
The right is reserved to change the Specifications consistent with regard to the
general intention of the contract for any part of the work or materials, either before
or after work has begun. Notice of such changes shall be given in writing to the
Contractor; such changes are not to be grounds for any claim by the Contractor for
damages, nor for the forfeiture of the Contract. It is possible that a Derelict Vessel
could disappear between the time of inspection by the contractor and the actual
effort to remove it. No payment will be forthcoming in event that this occurs.
Except when otherwise specified, the expense of all tests requested by the County
will be borne by the County.
12. AUDIT RIGHTS: As a provision of the grant from the State of Florida to the
County. and if so requested by the State, the successful bidder agrees to provide
access to all records and allow the audit of any books, documents and papers
related to this project for a period of up to one year and during and after termination
of the contract.
13, CO!\!TRACT;\ \V ARD: The County reserves the right to evaluate the suhmitted
bids and award a contract to the bidder submitting the lowest per foot bid for the
dcrdi<1 'c,",,1s listed in thc bid package as one project and for which 1-~ ~
6
Florida Marine Patrol Derelict Vessel Report is included. One bid will be accepted
and a Contract issued for the total removal of all listed derelict vessels as one
project, up to the limit of available funds. .
The actual number of vessels to be removed will depend on the accepted per foot
bid price and the available funds.
14. PREWORK CONFERENCE: A meeting will be necessary involving a
representative of the County, the Contractor and other parties with direct
involvement prior to the signing of the Contract. The time and place of this
conference will be set by the County representative. At this time the Contractor
shall provide the County with a schedule as to the order in which he proposes to
remove the vessels awarded to him.
IS. CONTRACT SECURITY: The Contractor is expected to act and deliver in good
faith all work, at the agreed price, in the allowed time. Failure to do so, could
jeopardize the contractor's reputation with the County and potentially influence any
future contracts with MONROE County.
16. EXECUTION OF CONTRACT DOCUMENT: Due to the time frame involved
with this project, the Contractor upon notification that he is to be awarded the
contract documents for execution, shall return said documents properly executed
along with insurance within TEN WORKING DAYS. This will assist in
acceleration of execution of the contract documents.
The Contractor, by virtue of signing the Contract, acknowledges that he and all his
subcontractors have satisfied themselves as to the nature and location of the work,
the general and local conditions, including, but not restricted to, those bearing upon
transportation, handling, access to the pick-up and disposal sites; and the character
of equipment and facilities needed to perform the work. Failure on the part of the
Contractor to completely or properly evaluate any factors of his costs prior to
bidding shall not form a basis for additional compensation if he is awarded the
Contract.
I f for any reasons, not acceptable to the County, the Contractor does not perform,
the County shall have the right to levy liquidated damages against the Contractor.
Liquidated damages in the amount of $100 per day shall be assessed against the
Contractor for any bid item awarded to him which is not completed and accepted
by the County within the number of calendar days specified in the Contract.
l.iquidated damages are accumulative.
17. NOTICE: TO PROCEED: The Contractor shall commence work upon this project
within one \\leek of the date of the Notice to Proceed letter and perform in a
continuous manner until completion and acceptance by the County, For Contracts
7
wherein a specified number of days for completion is stated in the Contract, the
effective date of the "Notice to Proceed with Contract Work" will establish the
"beginning date" of the project.
18. TERM IN A TION OF CONTRACT: This Contract may be terminated by the
County, giving up to ten (10) days written notice to the Contractor; said notice
shall be sufficient if delivered to the party personally or mailed by certified mail to
his mailing address as specified on the accepted bid.
19. FINAL CLEAN-UP: Upon completion of the work specified herein and before
acceptance and final payment shall be made, the Contractor shall remove from the
sites all machinery, equipment, surplus and discarded materials and temporary
structures. The disposal of materials, rubbish and debris shall be made at a legal
disposal site.
20. DISPOSAL SITES AND FEES: The Contractor is responsible for disposal of all
derelict vessels included in this contract and must make arrangements for legal
disposal. It is the responsibility of the Contractor to pay all disposal fees
incurred, and such removal related costs should be considered when bidding on this
contract.
The Contractor will deliver the derelict vessels to a Florida Department of
Environmental Protection permitted disposal site that has current occupational tax
licenses. It is the intent of this contract to remove derelict vessels from their
present site and legally dispose of them. Upon receipt of vessels at the landfill,
they must be disposed of immediately_
There are several Monroe County disposal sites, Cudjoe Landfill, MM 21.5
(vessels must be 26' and under to be delivered in tact, over 26' they must be
broken up), Long Key Landfill MM 68, and Card Sound Road AKA SR905 other
landfills in neighboring countries or any other location for disposal as long as the
site is a legal licensed disposal site. Prior to transportation of vessels out of
County the County representative must approve. Vessels being disposed of at
County Landfill sites must be free of pollutants and engines.
21. PROOF OF PROPER DISPOSAL AND NOTIFICATION TO MARINE
PATROL: Contractor must submit prior to receiving any payment: A receipt for
each vessel including the date of disposal, the Florida Marine Patrol Derelict Vessel
Number. disposal site location. and the telephone number. Recipient of debris
should provide detailed receipt showing type and description of debris received.
In addition to the above information. Contractor must submit three pictures of
each vessel removed. The lirst photograph must be of the vessel at the current
location prior to removal. the second photograph must be of the vessel after
removal but in the same general area preferably while in tow, and the third
l_- "
r.. -
8
photograph must be of the vessel at the disposal site with sufficient background to
depict disposal (i.e., building or sign identifying disposal site). The derelict
vessel number, when possible, must appear in all photographs.
The Contractor will be responsible for the camera, film, and development costs.
The photographs should be taken with a Polaroid camera that provides instant
photos since this minimizes loss of documentation due to camera malfunction or
loss overboard. This photos must be submitted on a vessel by to document the
removal and disposal of the contracted vessels final payment can not be assured.
The Contractor must notify the Florida Marine Patrol and the County
Representative in writing as to the work schedule of removal. This should be done
after the pre-work conference with the County representative. Notification is to be
made before doing any work on each vessel. This multiparty communication for
each Derelict Vessel is a requirement of the contract.
22. PAYMENT: All payments for the removal and disposal of each vessel, shall be
for the performance of the work as stipulated in these specifications and associated
contractual documents. The unit rate of bid shall be totally inclusive for all phases
of the operation. The Contractor may request two partial payments by submitting
an invoice for the number of vessels removed up to the date of the invoice,
providing the Contract agreement does not explicitly pronibit partial payments.
Photographs, disposal receipts, and signed FDEP Disposition Certification form for
the vessels for which payment is being requested.
The Contractor understands and agrees that no payment will be forthcoming for the
removal and disposal of any derelict vessel (1) not listed on this contract nor (2) for
any derelict vessel on this contract for which a written certification verifying the
removal of the subject vessel has not been obtained from the Florida Marine Patrol
and a Representative of the disposal site at the time of delivery.
In addition, property, public or private, if damaged during the work or removed for
the convenience of the work, shall be replaced at the expense of the Contractor in a -
manner acceptable to the County and the Owner, prior to the final payment for
contracted work.
1-'
-j.
NON-COLLISION AFFIDAVIT: Upon entering into the contract, the Contractor
agrees to sign and en,dorse the Non-Collusion Affidavit form (attached).
24.
ETHICS CLAUSE: Upon entering into the contract. the Contractor agrees to sign
and endorse the Ethics Clause form (attached).
25.
DRUG FREE WORK PLACE FORM: Upon entering the contract. Contractor
agrees to sign and endorse the Drug Free Work Place form (attached),
q
26. DERELICT VESSELS AT ISSUE: The derelict vessels listed on the Derelict
Vessel Working Bid List shall be removed and disposed of by the Contractor
in accordance with the provisions of these Specifications. .
10
EXur.lln,$
1996 Edilion
MONROE COUNTY, FLORIDA
INSURANCE CHECKLIST
FOR
VENDORS sunJ\lItTING PROPOSALS
FOR'VORK
To assist in tl~e development of your proposal, the insurance coverages marked with an "X" will
be required in the event an award is made to your firm. Please review this fonn 'with your
insurance agent and have himlher sign it in the place provided. It is also required that the bidder
sign the foml and submit it ",,rith each proposal.
WORKERS' COMPENSATION
AND
EMPLOYERS'LIABILITY
WC1
\VC2
\VC3
\VCUSLH
X Workers' Compensation
X Employers Liability
Employers Liability
Employers Liability
US Longshoremen' &
Harbor \Vorkers Ac~
X Federal Jones Act
Statutory Limits
$100,000/$500,000/$100,000
$500,000/$500,000/$ 500, 000
$1,000,000/$1,000,000/$1,000,000
Same as Employers'
'Liability
Same as Employers'
, Liability
\VCJ.A
IJ'\'S<I( LS"'
Adlllllll',II.111IIII 11l'.ll\1Cll<111
/,4 7\1'1 :'
1996 [dilion
GENERAL LIABILITY
As a minimum, the required general liability coverages will include:
· Premises Operations
· Blanket Cpntractual
· Expanded Definition
of Property Damage
Required Limits:
GLI
x
GL2
GL3
GL4
Required Endorsement:
GLXCU
GLLIQ
GLS
PrqQucts and Completed Operations
Personal Injury
.
.
S 1 00,000 per Person; S300,000 per Occurrence
S50,000 Property Dan1age
or
S300,000 Combined Single Limit
$250,000 per Person; S500,000 per Occurrence
S50,000 Property Damage
or
S500,000 Combined Single Limit
S500,000 per Person; $1,000,000 per Occurrence
SIOO,OOO Property Damage
or ,
$1,000,000 CombIned Single Limit
...
$5,000,000 Combined Single Limit
Underground, Explosion and Collapse (XCU)
Liquor Liability
Security Services
All endorsements are required 10 have the same limits as the basic policy.
/\,11111111"\1.1111111 11l\(ructl<Hl
1:.1 )11'1.'
I ~SCI{ LST 7
1996 Edition
VEHICLE LIABILITY
As a minimum, coverage should extend to liability for:
· Owned; Non-owncd; and Hircd VehjGles
Required Limits:
VLl
x
Vl2
Vl3
Vl4
BR]
MVC
PROl
PR02
PR03
POll
POl2
POl3
ED]
ED2
x
(;}( ]
(i J< 2
Gf<3
\..' l. J
x
- ------
Adlllllll"II,Itlnn In-,true11011
/, ,1 "Iii') )
$50,000 pcr Person: $100,000 per Occurrence
$25,000 Property Damage
or
$100,000 Combincd Single limit
$100,000 per Person; $300,000 per Occurrence
$50,000 Property Damage
or
$300,000 Combined Single Limit
$500,000 per Person; $1,000,000 per Occurrence
$100,000 Property Damage
or
$1,000,000 Combined Single Limit
$5,000,000 Combiped Single Limit
MISCELLANEOUS COVERAGES
Builders'
Risk
limits equal to the
completed project.
limits equal to the maximum
value of anyone shipment.
Motor Truck
Cargo
Professional
Liability
$ 250,000 per Occurrence/$ 500,000 Agg.
$ 500,000 per Occurrence/$l ,000,000 Agg.
$1,000,000 per Occurrence/$2,000,000 Agg.
$ 500,000 per Occurrence/$l ,000,000 Agg.
$1,000,000 per Occurrcnce/$2,000,000 Agg.
$5,000,000 per Occurrcncc/$1 0,000,000 Agg.
5; 10,000
$100,000
Pollution
Liability
Employce
Dishonesty
Garage
Keepers
s; 300,000 ($ 25,000 per Veh)
5; 500,000 ($100,000 per Veh)
$1,000,000 ($250,000 per Veil)
\.l.-.tC'rcrafl Li:lbilily $500,000
J l':SCJ( LST 3
1996 Edilion
INSURANCE AGENTS ST A TEMEN.I
I have reviewed the above requirements with the bidder named below. The following deductibles
apply to the corresponding policy.
POLICY
DEDUCTIBLES
Liability policies are
Occurrence
Claims Made
Insurance Agency
Signature
BIDDERS STA TEMENT
I understand the insurance that will be mandatory if awarded the contract and will comply in full
with all the requirements.
Bidder
Signature
I"\SCld .,\T II
^dlnllll"II~JlIlIII 1Il',t't1(-tIO'1
114 7()') :'
1996 rdi(;on
\VORKERS' C01\1PENSA TION
INSURANCE REQUlRE1\'lENTS
FOR
CONTRACT
I
n ET\VEEN
MONROE COUNTY, FLORIDA
AND
Prior to the commencement of work governed by this contract, the Contractor shall obtain
Workers' Compensation Insurance with limits sufficicnt to respond to Florida Statutc 440.
In addition, thc Contractor shall obtain Employers' Liability Insurance v.ith limits of not less
than:
$100,000 Bodily Injury by Accident
$500,000 Bodily Injury by Disease, policy limits
$100,000 Bodily Injury by Disease, each employee
Coverage shall be maintained throughout the entire term of the contract.
Coverage shall be provided by a company or companies authorized to transact business in the
state of Florida.
I f the Contractor has been approved by the Florida's Deparyment of Labor, as an authorized self-
insurer, the County shall recognize and honor the Contractor's status. The Contractor may be
required to submit a Lener of Authorization issued by the Department of Labor and a Certificate
of Insurance, providing details on the Contractor's Excess Insurance Program.
I f the Contractor participates in a self-insurance fund, a Certificate ofInsurance will be required.
In addition, the Contractor may be required to submit updated financial statements from the fund
upon request from the County.
\\'(1
A<1l1lll1l\lrJI'OIl)I\\\,lI, I'""
Ij'UO'} ]
1996 Edition
\\'ORKERS' COMPENSATION
INSURANCE REQUlREl\IENTS
FOR
CONTRACT
, ,
llET\VEEN
l\10NROE COUNTY, FLORIDA
AND
Recognizing that the '''.'ork governed by this contract involves Maritime Operations, the Contractor's
Workers' Compensation Insurance Policy shall include coverage for claims subject to the Federal Jone~
Act (46 U.S.C.A. subsection 688) with limits not less than those specified for Employer's Liability.
The Contractor shall be permitted to provide Jones Act Coverage through a separate Protection and
Indenutity Policy, in so far as the coverage provided is no less restrictive than would have been provide
by a Workers' Compensation policy.
\\( .lA
:\dlllllllSlratHlll 111\1111.11'"'
11470'} I
/996 Edition
GENERAL LIAOILITY
INSURANCE REQUIREMENTS
FOR
CONTRACT
,
n ET\'vEEN
MONROE COUNTY, FLORIDA
AND
Prior to the commencement of work governed by this contract, the Contractor shall obtain
General Liability Insurance. Coverage shall be maintained throughout the life of the contract and
include, as a minimum:
· Premises Operations
· Products and Completed Operations
· Blanket Contractual Liability
· Personal Injury Liability
· Expanded Definition of Property Damage
The minimum limits acceptable shall be:
$300,000 Combined Single Limit (CSL)
If split limits are provided, the minimum limits aq~eptable shall be:
$100,000 per Person
$300,000 per Occurrence
$ 50,000 Propeny Damage
An Occurrence Form policy is preferred. If coverage is provided on a Claims Made policy, its
provisions should include coverage for claims filed on or after the effective date of this contract.
In addition, the period for which claims may be reponed should extend for a minimum of twelve
(12) months fOllowing the acceptance of work by the County.
The Monroe County Board of County Commissioners shall be named as Additional Insured on
all policies issued to satisfy the above requirements.
GLl
Ad'I1'lll\ll,tlltlll IfI,.tru( 11011
1I.17()') 7
1'19(, Fdllln"
VEHICLE LIABILITV
INSURANCE REQUIREMENTS
FOR
CONTRACT
BET'VEEN
MONROE COUNTY, FLORIDA
AND
Recognizing that the work governed by this contract requires the use of vehicles, the Contractor
prior to the commencement of \vork, shall obtain Vehicle Liability Insurance. Coverage shall b~
maintained throughout the life of the contract and include, as a minimum, liability coverage for:
· Owned, Non-Owned, and Hired Vehicles
The minimum limits acceptable shall be:
$100,000 Combined Single Limit (CSL)
If split limits are provided, the minimum limits acceptable shall be:
$ 50,000 per Person
$100,000 per Occurrence
$ 25,000 Property Damage
The Monroe Countv Board of County Commissioners shall be named as Additional Insured on
all policies issued to satisfy the above requirements.
VLl
AdmilllqraliOn ImlrUCII(1I1
# 4709 2
1\()
1996 Edition
POLLUTION LIABILITY
INSURANCE REQUIREMENTS
FOR
CONTRACT
BET'VEEN
MONROE COUNTY, FLORIDA
AND
Recognizing that the work governed by this contract involves the storage, treatment, processing,
or transporting of hazardous materials (as defined by the Federal Environmental Protection
Agency), the Contractor shall purchase and maintain, throughout the life of the contract,
Pollution Liability Insurance which will respond to bodily injury, property damage, and
environmental damage caused by a pollution incident.
The minimum limits of liability shall be:
$500,000 per Occurrence/$l ,000,000 Aggregate
If coverage is provided on a claims made basis, an extended claims reporting period of four (4)
years ,,,,,ill be required.
POLl
AdministratIOn Instruction
# 4 709 2
-; I
1996 Edition
\V A TER CRAFT LIAIlILITY
INSURANCE REQUIREMENTS
FOR
CONTRACT
, ,
n ET\VEEN
~10NROE COUNTY, FLORIDA
AND
Prior to the commencement of v..'ork governed by this contract, the Contractor shall obtain
\Vater Craft Liability Insurance with terms no less restrictive than those found in the
standard "American Institute Hull Clauses" (June 2, 1977 edition). Coverage shall be
maintained throughout the life of the contract and include, as a minimum:
· Injury (including death) to any Person
· Damage to Fixed or Movable Objects
· Costs Associated with the Removal of \Vrecked Vessels
· Contractual Liability with Respect to this Contract
If the policy obtained states that coverage applies for the "Acts or Omissions ofa Vessel"
it shall be endorsed to provide coverage for the lc.galliability of the shipowner. '
The minimum limits acceptable shall be:
$500,000 Combined Single Limit (CSL)
Coverage provided by a Protection and Indemnity Club (P&I) shall be subject to the
approval of the County.
The Monroe County Board of County Commissioners shall be named as Additional
Insured on all policies issued to satisfy the above requirements.
WLI
A,lnllnl\tl;&II<H\ 11I\IIU<"I1<11I
11470'17
1996 Edition
\V A TER CRAFT LIAIlILITY
INSURANCE REQUIREMENTS
FOR
CONTRACT
, ,
n ET\VEEN
~10NROE COUNTY, FLORIDA
AND
Prior to the commencement of v..'ork governed by this contract, the Contractor shall obtain
Water Craft Liability Insurance with terms no less restrictive than those found in the
standard "American Institute Hull Clauses" (June 2, 1977 edition). Coverage shall be
maintained throughout the life of the contract and include, as a minimum:
· Injury (including death) to any Person
· Damage to Fixed or Movable Objects
· Costs Associated with the Removal of \Vrecked Vessels
· Contractual Liability with Respect to this Contract
If the policy obtained states that coverage applies for the "Acts or Omissions of a Vessel"
it shall be endorsed to provide coverage for the legal liability of the shipov.mer. '
The minimum limits acceptable shall be:
$500,000 Combined Single Limit (CSL)
Coverage provided by a Protection and Indemnity Club (P&I) shall be subject to the
approval of the County.
The Monroe County Board of County Commissioners shall be named as Additional
Insured on all policies issued to satisfy the above requirements.
WLI
Adlllllll~tratinn 111\IIU"11<11l
11470') 2
A C' ODD .., ~1.clt3:l'Nmc::r~c;l%l:<<:CJlt.~~h
. ~ 1\1 ~~ ............: ~ .113Je1~~I~W~~:.F\R~!SI...~
10108198
THIS CERTlF1CATE IS ISSUED AS A MATTER OF INfORMATION
ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE
HOLDER. THIS CERT1FICATE DOES NOT AMEND., EXTEND OR
COMPANIES AFFORDING COVERAGE
:OtVJCER
ONDUNINTERNATIONALGROUP
500 KOGER BLVD., SUITE #225
T. PETERSBURG, FLORIDA 33702
r:t::MPNlY
A
UNITED CAPITOL INSURANCE CO.
ARNOLD'S TOWING SERVICE
5540 3RD AVENUE
KEY WEST, FLORIDA 33040
y'
r:t::MPNlY
B
SURED
COMPANY
C
COMPNlY
D
"':~~~~~~1~~~~i~;;~~~':':':;~~~'~'i':""~~';':~':~~';"'~':':~~':'i'fG'~"'i.;::.::t'i~'~i':~'i~~~~~~;'~;~~::::'~O:::'~';':':~'i':':':w,~,,~~>"':~'~"~"'~"'I't""~':"""'::'''':''''::::::::;'i~'I'i~'~:~',':':':':';':':':'~~~':':~~~':~~::::f$~~t~~~~~$'~~ ..:,.... ..
THIS IS TO CERTlFY THAT THE POlICIES OF INSURANCE USTEO BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POUCY PERIOD
INDICATED. NOlWlTHSTANOING IWY REQUIREMENT, TCRM OR CONOIT1ON OF IWY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH nus
CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED B Y THE PQUCJES DESCRIBED HEREIN IS SUBJECT TO AU. THE TERMS,
EXClUSIONS AND CONomoNS OF SUCH POUCJES. LMTS SHOWN MAY HAVE BEEN REDUCED BY PAID ClAIMS.
)
R
TYPE OF INSURANCE
GENERAL UABIUTY
COMMERCIAL GENERAL. UASlUTY
CLAIMS MACE 0 OCCUR
OINNER"S & CONTRACTOR'S PROf
POUCY NUMBER
POLICY EFFECTIVE POUCY EXPIRATION
DATE (MMIDDIYYl DATE (MMIDD/YY)
UMITS
GENERAL AGGREGATE S
PROOUCTS . COMPIOP AGG S
S
S
S
S
PERSONAL & AOV INJURY
EAQol OCCURRENCE
ARE DAMAGE (Anyone m.l
MEO EXP (Anyone__1
AUTOMOBILE LlABIUTY
IWYAUTO
AU. OWNED AUTOS
SCHEDULED AUTOS
HIRED AUTOS
NON-OWNED AUTOS
11 n\C(
(
COMBINED SINGLE UMIT S
BOOlLY INJURY S
(Per __I
IlOOILY INJURY S
(Per KlCldenI)
PROPERlY DAMAGE S
AUTO ONLY - EA ACODENT S
OTHER THAN AUTO ONLY:
EACH ACCIDENT S
AGGREGATE S
EACH OCCURRENCE S
AGGREGATE S
S
0'1)00
at
S
So DISEASE . POUCY UMIT S
So DISEASE . EA EMPLOYEE S
08119/99 HULL $5.000
P&I $500,000 CSL
uY
I\:-"'wOVED SY-RlSK ~NAGEM: -r
~ \ \ \
I \ "
EXCESS UABIUTY
UMBREllA FORM
OTHER ~ UMBREllA FORM
c"t..
(/
'.
QATE
W41VER:
~.;
GARAGE UABIUTY
IWY AUTO
0\(;\: ffi
1 r_
I 1
WORKER'S COMPENSAnOH AND
EMPLOYERS UABIUTY
". PROPltIETOlll INCL.
~
0l'l'lCEIUI AIlE: EXCl
OTHER
A HULL & P&I
WOM1258296
08119/98
DESCRIPTION OF OPERATlONSlLOCATIONSlVEHICLESlSPEClAL ITEMS
COVERAGE: HULL & PROTECTION & INDEMNITY
CERTIFICATE HOLDER ALSO AN ADDITIONAL INSURED AS RESPECTS TO DEREUCT VESSEL REMOVAL CONTRACT.
SHOULD ANY OF THE AIJQYE DESCRIBED POUCIES BE CANCELLED BEJ'ORE THE
MONROE COUNTY BOARD OF COUNTY COMM. EXPIRAnOH DATE THEREOF. THE ISSUING COMPANY WILL ENDeAVOR TO_MAIL
MONROE COUNTY RISK MANAGEMENT . 30 DAYS WRITTEN NoncETO THECERnFICATE HOLDER NAMED TO THE LEFT.
5100 COLLEGE ROAD BUT FAlLURETOMAlLSUCH NoncE SHALL IMPOSE NOOBUOATION ORUABlLITY
KEY WEST, FLORIDA 33040 . F ANY KIND UPON THE COMPANY TS G .
~~,,,.~;~~~~