Item B03
BOARD OF COUNTY COMMISSIONERS
AGENDA ITEM SUMMARY
Meeting Date: 07-27-00
Division: Growth Management
Bulk Item:YESl NO
Department:Marine Resources
AGENDA ITEM WORDING: Approval ofthe Contract Agreement between Monroe
County and Blue Water Marine, Inc. Mr the emergency removal of a two story floating
structure located just of the sea wall, houseboat row, Key West.
ITEM: The City of Key West has J'equested funding assistance for the removal of this
structure. The structure was severely damaged during Hurricane Georges and the owners
have abandoned it. The City did not apply for funding assistance for the removal of this
structure due to the owners advising that they intended to repair it. We requested that we
be allowed to utilize existing FEMA funding to remove and FEMA has approved this
request.
PREVIOUS RELEVANT BOCC ACTION: None
STAFF RECOMMENDATION: Approval
TOTAL COST: $23.456.78
BUDGETED: Yp.~
COST TO COUNTY: Staff Time Only
FEMAlBIF
REVENUE PRODUCING: YES NOl AMT. PER MO. YEAR
APPROVED BY:COATTY X OMB/PURCHASING]LRISKMANAGEMENT XW.VC '
DEPARTMENT HEAD APPROVAL:
George
DIVISION DIRECTOR APPROV
Timothy J. Mc
DOCUMENTATION: INCLUDED: X TO FOLLOW: NOT REQUIRED:
DISPOSITION: - AGENDAITEM#~
MONROE COUNTY BOARD OF COUNTY COM:\H,;w.lG:"L(;..J
CONTRACT SUMMARY
Contract #
Contract with: Blue Water Marine. Inc.
Effective Date: / /
---
Expiration Date:_/ _/_
fln~~ing struGtvre off of
Contract Purpose/Description:
Emergency re.oval of a
Houseboat Row. Key We~~
Contract Manager: Kim McGee
(Name)
4511
(Ext.)
~:?'iD~ PTnjP"''''C!
( Department)
for BOCC meeting on 7 .1
27t 00
Agenda Deadline: 7 I 10 I 00
Total Dollar Value of Contract: $
Budgeted? Yes No
Grant: $ FEMA
County Match: $
CONTRACT COSTS
23.456 78 Current Year Portion: $ 23,456.78
Account Codes: 125 - 5250-o4546-5304~0-49GL~S05-530340
Estimated Ongoing Costs: $
(Not included in dollar value above)
ADDITIONAL COSTS
NI A Iyr For:
(eg. maintenance, utilities, janitorial, salaries, etc.)
Comments :
Date In
CONTRACT REVIEW
Changes
Needed
Yes No
D~te Out
Division Director
ftL~1/00
County Att'Jrney
~/flJDO
(gJ&tJ6
-'-/51J tM.
,
R~nagepA\t
O~.IPu~
)
~// ~/S!J)
~.
~
~
TH E CITY OF KEY WEST
P. o. BOX 1409
KEY WEST, FLORIDA 33041-1409
March 30,2000
Kim McGee
Monroe County
Marine Project Coordinator
5100 College Rd.
Public Service Building
Key West, FL 33040
Dear Ms. McGee,
We need your help. We have a large floating structure sunken in the exit channel from
houseboat row along South Roosevelt Blvd.
This floating structure was sunk during hurricane "Georges". The owner of this floating
structure agreed to re-float it and rebuild it. He has since abandoned the structure and we
are unable to locate him.
The house boats can not move off the sea wall and get to Garrison Bight as per our
original agreement with the DEP and DCA until this floating structure is removed from
the channel. The City is not responsible for removing the structure nor do we have the
funds to remove it.
Please help us if you can.
Sincerely,
~
John Jones
Assistant City Manager
Key to the Caribbean - Average yearly temperature 770 F.
V.I ........, .....J..J1 .....".,. ,JU..J ,..., J.JUV
r1l..JI.lL....J I ,-_., I.....'..... "'-
Blue Water Marine, Ine.
dIbIa
TowBOAT/U.S. South Dade
p.o. BOX 901716
Homestead, Florida 33090-1716
Pbone I Fa. (305) 230-0030
QUOTATION
May 18, 2000
TO: Kim McGee
FROM: Blue Water Marine, Inc.
SUBJ: Removal of houseboat
The following quotation is for the removal of (I) one houseboat
specified on 5/18/00 by Marine Projects. located on Houseboat Row, Key
West. This houseboat can be removed and disposed of for the sum of
S23,4S6.78. Blue Water Marine, Inc. understands it is responsible fOT all
disposal costs.
Respectfully Submitte<L
~
/1 l' I
..~lN A-C-/..,
Capt. Todd Seeds
Blue Water Marine, Inc.
ARNOLD'S
AUTO &: MARINE REPAIR, INC.
SS40 3'" AWIllIe. Stock bland
Key West, FL 33040
(305) 296-3832
FAX 292.9882
May II. 2000
KIM McGEE
MARINE PROJECTS COORDINATOR
SIOO COll.E(iI! 'ROAD
KEY WEST. Fl. 33040
DEAlt. MRS. ~,
OUR BID fOR. 11IE REMOVAl.. AND DISPOSAL OP TIlE DERELECT BL AND WHITE TWO-
STORY HOUSEBOAT SUNK AT HOUSEBOAT ROW IS S24~.
SINCERELY,
~W(k~
RICHARD W. ARNOLD
CONTRACT AGREEMENT
AGREEMENT, MADE THIS day of
2000, by and
between, Blue Water Marine, Inc. ("Contractor"), and the BOARD OF
COUNTY COMMISSIONERS OF MONROE COUNTY, FLORIDA, of the County of
Monroe. State of Florida ("Board").
The Contractor and the Board, for the consideration named agree as follows:
I. The Contractor shall furnish all the materials and perform all the work as
required by the Specifications for the Emergency removal of a two story houseboat located off of
Cow Key Channel, Houseboat Row. Pictures of this houseboat are attached as Exhibit A.
2. The work to be performed under this contract must be completed by July 31.
2000.
3. The Contractor understands the rules of the Florida Boating Improvement Fund and the
Federal Emergency Management Agency and shall comply with those rules, along with the rules
and procedures instituted by the Board to ensure an orderly progress to the project. Both the intent
and the requirements of the Specifications, attached as Exhibit B, are understood by the
Contractor.
4. The Board shall pay the Contractor $ 23.456.78 for the removal and legal disposal of the
houseboat-Exhibit A. Payment will be upon completion of work by the Contractor and review and
approval by the Marine Projects Coordinator. No Change Orders allowed.
5. The attached Photos attached as Exhibit A, Specifications attached as Exhibit B, and the
Monroe County Insurance Requirements attached as Exhibit C together with this Agreement. form
the Contract. They are fully a part of this Contract as if repeated herein verbatim.
6. The Contractor covenants and agrees to indemnify and hold harmless the Monroe County
Board of County Commissioners from any and all claims for bodily injury (including death),
personal injury and property damage (including property owned by the County) and other losses,
damages, and expenses (including attorney's fees) which arise out of, in connection with. or by
reason of services provided by the Contractor or any of its Subcontractor (s) in any tier, their
employees or agents. The purchase of the insurance required in paragraph 11 does not vitiate this
indemnification provision.
7. The Contractor ag;'ees to supply the County with a set of photographs of each vessel in all
phases of the removal and disposal process. The Contractor will be responsible for the camera,
film, and development costs.
8. The Contractor must inform the County prior to initiation of work.
9. The parties agree that a timely performance of this agreement is essential due to possible
damage to the natural resources, hazards to navigation, or threats to human health and welfare.
Therefore, the parties agree that the Contractor shall be liable to the Board for $100 per day of
liquidated damages for each day after 7-31-00 that the Contractor's obligations under this
agreement remain unperformed. The parties agree that such amount is by the way of
compensatory damages and does not constitute a penalty.
10. Due to the use of heavy equipment ami at times. dangerous work environment, the
Contractor understands and agrees to maintain an alcohol an drug free work environment.
11. The Contractor will be responsible for all necessary insurance coverage as indicated by an
"X" on the attached forms identified as INSCKLST 1-4, as further detailed on forms VLI, WCl,
WClA, GLI, WL L & POLl attached as Exhibit C. All policies must list Monroe County as
additional insured with the exception of the Worker's Compensation policy.
12. The Contractor warrants that it has not employed, retained or otherwise had act on its
behalf any former County officer or employee subject to the prohibition of Section 2 of Ordinance
No. 010-1990 or any County officer or employee in violation of Section 3 of Ordinance No. 020-
1990. For breach or violation of this provision, the owner may, in its discretion, terminate this
2
contract without liability and may also, in its discretion. deduct from the contract or purchase
price, or otherwise recover the full amount of any fee, commission. percentage, gift, or
consideration paid to the former County officer or emplcyee.
13. A person or affiliate who has been placed on the convicted vendor list following a
conviction for public entity crime may not submit a bid on a contract to provide any goods or
services to a public entity, may not submit a bid on a contract with a public entity for the
construction or repair of a public building or public work. may not submit bids on leases of real
property to public entity, may not perform work as a contractor, supplier, subcontractor, or
consultant under a contract with any public entity, and may not transact business with any public
entity in excess of the threshold amount provided in Section 287.017 of the Florida Statutes, for
CATEGORY TWO for a period of 36 months from the date of being placed on the convicted
vendor list.
IN WITNESS WHEREOF each party hereto have executed this Agreement the day and
year first written above.
(SEAL)
Attest: DANNY L. KOLHAGE, CLERK
BOARD OF COUNTY COMMISSIONERS
OF MONROE COUNTY, FLORIDA
By:
Deputy Clerk
By:
Mayor/Chairman
Witness:
Business/~ame: ~ \ ) ..i.... \.1" \,~"J ;2./ \'--'1(-<, vJ..
r~ ! l t / /
By: " , -/ ~~. 11." ! < \, "
Witness:
~
Title: ',' G-., './'
,"J... /
DATE
3
EXHIBIT A
EXHIBIT B
DERELICT VESSEL REMOVAL CONTRACT SPECIFICATIONS
FOR MONROE COUNTY, FLORIDA
1.
INTENT: It is intended that these specifications shall cover all aspects of the work.
The purpose of this section is to provide specific conditions applicable to this
contract where such coverage is not provided in other portions of the documents.
.,
BID FORMAT: A dollar amount per foot must be submitted for the removal of as
many derelict vessels on the primary list for which a Florida Marine Patrol Derelict
Vessel Report is provided and as funding will allow. Any deviation from this
format will result in an unaccented bid. A contract will not be granted on the basis
of combined, related, linked, or discounted bids. Not applicable due to emergency
removal of one or more derelict vessels for less than $25,000 total.
..,
.J.
PLANS: There are no plans for this project, but copies of the Florida Marine
Patrol Derelict Vessel Report with location sketches have been bound into these
documents for the Contractor's use. The Specifications include a section on
instructions to bidders, both general and specific, and a copy of each Derelict
Vessel Report from the Florida Marine Patrol. Only those derelict vessels for
which a report is included and listed on the Bid Response Form are to be bid upon
and subsequently removed.
The County reserves the right to remove any or all vessels from this contract at any
time prior to actual removal from the water and disposal by the Contractor.
The County has a limited amount of money to effect the removal of these derelict
vessels. We have established priorities based on public safety, navigational hazard.
and environmental considerations. If bids exceed the County's resources for
removal based on these considerations, we shall limit vessel removal based on the
considerations and cost effectiveness.
4. VESSEL IDENTIFICATION AND LOCATION: Each of the vessels have been
given a derelict vessel identification number, which is shown with the location in
the Florida Marine Patrol Derelict Vessel Report, included herewith.
Each bidder is responsible for his own identification of each derelict vessel as to
location, description and condition. If a derelict vessel cannot be (I) located. (2)
removed, (3) verified and (4) disposed of, as specified in these procedures, then no
payment will be made forthcoming to the Contractor for that vessel. Those four
conditions must be met on each derelict vessel along with compliance of all laws
for payment to be made.
It is understood that the Contractor has, by personal examination and inquiry, if
necessary, satisfied himself as to local conditions of each derelict vessel and as to
the meaning, requirements and reservations of the specifications; for after contract
letting, no deviation will be allowed. In case errors are discovered, they are
to be reported by the Contractor to the County. The county assumes no
responsibility should there be any discrepancies in what is stated in these
documents and what the bidder evaluates.
The Contractor should take special ca1'e to remove only those derelict vessel's on
his Contract and for which he possesses a Florida Marine Patrol Derelict Vessel
Report. Other derelict vessels in the area but not under Contract, cannot be
molested.
It may be possible to replace a derelict vessel of like kind, for the same or less
money, when mutual agreement can be reached by the Fl?rida Department of
Environmental Protection, Monroe County Administrator of the Derelict Vessel
Program, and the Contractor. This will be applicable when a contracted derelict
vessel cannot be located. No derelict vessel may be replaced and removed without
the tri-party consent noted in this paragraph. A contractor may suggest a possible
replacement vessel but he may not remove it without the appropriate consent above.
5. SCOPE OF WORK: The Contractor shall be responsible for providing all permits,
supervision, labor, equipment, tools, fees and taxes required to complete this
project to the satisfaction of the County.
The Contractor's procedure and methods of removal may be of his own selection
provided they secure results which satisfy the requirements of the Specifications
and any necessary environmental permits.
Any vessel which is removed and disposed of shall be removed from its present site
in such a manner as to do the least possible damage to the natural environment.
All debris from the vessel shall be removed and the site left in a reasonably clean
condition. No oil or fuel shall be permitted to be dumped or spilled into or unto the
water or land. All pollutants shall be removed from the derelict vessel prior to
removal from the water.
The Contractor shall be responsible for making any and all arrangement for access
to the vessel to be removed. If private property has to be traversed, then written
permission of the owner is necessary. In removing a derelict vessel that may lie on
or near grass or sponge flats extreme caution must be used to do the least possible
damage.
2
Prior to delivery of derelict vessels to the disposal site. the Contractor must remo've
all oil. gas and engines. He must dispose of them in any legal manner. Pure used
oil will be taken by Monroe County for disposal. Mixture of oil. gas. seawater or
any combination of the three must be transported from the County by an approved
hazardous waste handler. The names of handlers will be supplied by the Monroe
County Solid Waste Department. Metal becomes the property of me Contractor.
6. MATERIALS AND WORKMANSHIP: The Contractot shall provide the
necessary materials and equipment to safely complete the job. The Contractor
agrees that all work shall be performed by competent employees who are
experienced and qualified to do the work specified, and that all work will be
performed in accordance with the best commercial practices. A list of equipment
to be used and a description of the removal and transporting procedures to be
followed must be provided to the County at the pre-work conference described
below.
Precaution shall be exercised at all times for the protection of persons and property,
The safety provisions of the Occupational Safety and Health Act of 1970 (Public
Law 91-596) and other applicable laws, including building and construction codes
shall be observed. Machinery, equipment and other hazards shall be guarded in
accordance with safety provisions of the "Manual of Accident Prevention in
Construction", published by the Associated General Contractors of America, to the
extent that such provisions are not in contradiction of appJicable law.
If any property is destroyed by any cause or means whatsoever. the Contractor shall
repair and replace or not receive payment for the unaccomplished work. The
Contractor shall maintain suitable and sufficient guards and barriers, and at night,
suitable and sufficient light or other appropriate security or protection for the
prevention of accidents.
Use of explosives is prohibited in carrying out the project.
7. ASSIGNMENT OF CONTRACT AND SUBCONTRACTS: It is expressly
understood that the Contractor is in all respects an independent Contractor for this
work, not withstanding under certain conditions he is bound to follow the
directions of the County, and is in no respect an agent, servant, or employee of the
County. Neither the Contract, nor any part thereof, nor any Moines due or to
become due thereunder, may be assigned by the Contractgr without the prior
written approval of the County.
3
The Contractor is fully responsible to the County for the acts and omissions of his
subcontractors and of persons either directly or indirectly employed by said
subcontractor. as he is for the acts and omissions of persons directly employed by
him. Nothing contained in the relation between any subcontractors shall abide by
the terms, conditions, and requirements of this Contract. It is the responsibility of
the Contractor to pay all debt obligations incurred with subcontractors in an
expedient manner.
8. LEGAL RESTRICTIONS, PERMITS AND TRAFFIC PROVISIONS: The
Ccmtractor shall comply with all applicable local, State and Federal requirements
p~rtaining to the terms of this Contract. The Contractor will be responsible for
obtaining, at his own expense, any licenses or permits that may be required and
should inquire about permit requirements with the appropriate agencies. The
Contractor shall comply with all the requirements of the Federal Pollution Control
Act.
The Contractor shall conduct his operations so that he shall not close any
thoroughfare nor interfere in any way with traffic on highways, or on water,
without the written consent of the proper authorities. Work shall be done at any
time that shall not interrupt or disturb members of the public.
Utilization of off-loading sites located on private property (water to land for
transport to the landfill or other disposal site by vehicle) must have written
approval of the land owner.
The Florida Marine Patrol should be contacted to initiate eviction proceedings for
contracted derelict vessels which are inhabited at the time of removal and when
another vessel is too close to the contracted derelict vessel to allow safe operations.
Direct confrontations with other boaters should be avoided and the Florida Marine
Patrol should be contacted immediately if such confrontations results from removal
of any contracted derelict vessels.
9. INSURANCE: The Contractor must obtain insurance required by the County and
submit proof of same to the County prior to acceptance of bid and contract approval
by Board of County Commissioners but no later than five working days after notice
of low bidder. All insurance shall be maintained until work has been completed
and accepted by the County.
The Contractor shall furnish the following certificates of insurance for review by
the County's Risk Management Division:
Certificate (s) of Insurance which clearly indicates that he has obtained the
insurance coverage required in paragraphs a,b,c and d below.
4
The Contractor herebv certifies that no modification or change in insurance shall be
. ~
made without (0) days written advance notice to MONROE County, c/o the
Director of the Risk Management Division.
<1. Worker's Compensation Insurance per Fl. Statutes
b. Federal Jones Act Coverage
c. General Liability Insurance OJI a comprehensive basis, in an amount not less than
5300,00.00 per occurrence 1'01' Bodily Injury and Property Damage combined, to
include contractual liability.
c. Pollution Liability Insurance in the Amount of $500,000.
d. Water Craft Liability Insurance in the Amount of $500,OGO.
e. Automobile liability insurance covering all owned, non-owned and hired vehicles
used in connection with the work, in an amount not less than
$100,000 per occurrence for Bodily Injury and Property and Damaged combined.
All insurance policies required above shall be issued by companies authorized to do
business under the laws of the state of Florida. The MONROE County Board
of County Commissioners must be listed as "Additional Insured" on all policies,
except for the Worker's Compensation policy.
10. COMMENCEMENT, DELAYS AND COMPLETION OF WORK: After
receiving Board of County Commission approval of the Contract, and after
reconciliation of any details or conditions which may directly or indirectly interfere
or conflict with work of the Contract, the County will issue a "Notice to Proceed"
officially authorizing the Contractor to commence. The Gontractor shall
commence work within one week from the date on the "Notice to Proceed" letter.
If the Contractor should be delayed in the progress of the work included in the
Contract by enforceable causes beyond his control, the time for the completion of
the work may be extended upon agreement of the County representative. Requests
for an extension of time must be submitted in writing to the County representative.
Extensions of time cannot legally be approved unless the written request is
submitted in the time to permit it to be acted upon before the Contract expiration
date. To allow sufficient time for the administrative procedures required to obtain
action by the County Commission, a request for time extension must be received by
the County representative at least sixty (60) calendar days prior to the Contract
expiration date.
5
Provided further that the Contractor shall within ten (10) days from the beginning
of such delay notify the County, in writing, of the causes of the delay. The County
representative will ascertain the facts and the extent of the delay and notify the
Contractor within a reasonable time of her decision in the matter.
If the Contractor fails to complete the work within the time limit. and if the County
should nevertheless permit the Contractor to continue and complete the same
without official extension of time in writing, such permission shall not modify nor
waive any liability of the Contractor for damages arriving non.-completion of work
within the time limit, but such liabilities shall be subject 1;0 :ontinuation in full
force against the contractor.
11. CHANGES AND INSPECTION: The vessels herein considered are to be removed
for the County by the Contractor in accordance with the specifications. The County
may give instructions or directions to supplement the specifications. These shall be
binding upon the Contractor and upon all his subcontractors, employees and agents
of every kind.
All work and every process and operation shall be subject to inspection at all
times. and the County and their representatives shall have free access to all aspects
of the work. The Contractor shall remove and make good, as may be directed.
without charge, any defective work. Oversight or error of judgment of
inspections, or previous acceptance, shall not relieve the Contractor from the
obligation to make good any defect whenever discovered.
~
The right is reserved to change the Specifications consistent with regard to the
general intention of the contract for any part of the work or materials, either before
or after work has begun. Notice of such changes shall be given in writing to the
Contractor: such changes are not to be grounds for any claim by the Contractor for
damages, nor for the forfeiture of the Contract. It is possible that a Derelict Vessel
could disappear between the time of inspection by the contractor and the actual
effort to remove it. No payment will be forthcoming in event that this occurs.
Except when otherwise specified, the expense of all tests requested by the County
will be borne by the County.
12. AUDIT RIGHTS: As a provision of the grant from the State of Florida to the
County, and if so requested by the State, the successful bidder agrees to provide
access to all records and allow the audit of any books, documents and papers
related to this project for a period of up to one year and during and after termination
of the contract. .
13. CONTRACT A WARD: The County reserves the right to evaluate the submitted
bids and award a contract to the bidder submitting the lowest per foot bid for the
derelict vessels listed in the bid package as one project and for which a
6
Florida Marine Patrol Derelict Vessel Report is included. One bid will be accepted
and a Contract issued for the total removal of all listed derelict vessels as one
project, up to the limit of available funds.
The actual !lumber of vessels to be removed will depend on the accepted per foot
bid price and the available funds.
14. PREWORK CONFERENCE: A meeting will be necessary involving a
representative of the County, the Contractor and other parties with direct
involvement prior to the signing of the Contract. The time and place of this
conference will be set by the County representative. At this time the Contractor
shall provide the County with a schedule as to the order in which he proposes to
remove the vessels awarded to him.
15. CONTRACT SECURITY: The Contractor is expected to act and deliver in good
faith all work, at the agreed price. in the allowed time. Failure to do so. could
jeopardize the contractor's reputation with the County and potentially influence any
future contracts with MONROE County.
16. EXECUTION OF CONTRACT DOCUMENT: Due to the time frame involved
with this project. the Contractor upon notification that he is to be awarded the
contract documents for execution, shall return said documents properly executed
along with insurance within TEN WORKING DAYS. This will assist in
acceleration of execution of the contract documents.
The Contractor, by virtue of signing the Contract, acknowledges that he and all his
subcontractors have satisfied themselves as to the nature and location of the work,
the general and local conditions. including, but not restricted to, those bearing upon
transportation. handling, access to the pick-up and disposal sites; and the character
of equipment and facilities needed to perform the work. Failure on the part of the
Contractor to completely or properly evaluate any factors of his costs prior to
bidding shall not form a basis for additional compensation if he is awarded the
Contract.
If for any reasons, not acceptable to the County, the Contractor does not perform.
the County shall have the right to levy liquidated damages against the Contractor.
Liquidated damages in the amount of $1 00 per day shall be assessed against the
Contractor for any bid item awarded to him which is not completed and accepted
by the County within the number of calendar days specified in the Contract.
Liquidated damages are accumulative.
17. NOTICE TO PROCEED: The Contractor shall commence work upon this project
within one week of the date of the Notice to Proceed letter and perform in a
continuous manner until completion and acceptance by the County. For Contracts
7
wherein a specified number of days for completion is stated in the Contract. the
etfective date of the "'Notice to Proceed with Contract Work" will establish the
"beginning date" of the project.
18. TERMINATION OF CONTRACT: This Contract may be terminated by the
County, giving up to ten (10) days written notice to the Contractor; said notice
shall be sufficient if delivered to the party personally or mailed by certified mail to
his mailing address as specified on the accepted bid.
19. FINAL CLEAN-UP: l'pon completion of the work specified herein and before
acceptance and final payment shall be made, the Contractor shall remove from the
sites all machinery, equipment, surplus and discarded materials and temporary
structures. The disposal of materials, rubbish and debris shall be made at a legal
disposal site.
20. DISPOSAL SITES AND FEES: The Contractor is responsible for disposal of all
derelict vessels included in this contract and must make arrangements for legal
disposal. It is the responsibility of the Contractor to pay all disposal fees
incurred, and such removal related costs should be considered when bidding on this
contract.
The Contractor will deliver the derelict vessels to a Florida Department of
Environmental Protection permitted disposal site that has current occupational tax
licenses. It is the intent of this contract to remove derelict vessels from their
present site and legally dispose of them. Upon receipt of vessels at the landfill,
they must be disposed of immediately.
There are several Monroe County disposal sites, Cudjoe Landfill, MM 21.5
(vessels must be 26' and under to be delivered in tact. over 26' they must be
broken up), Long Key Landfill MM 68, and Card Sound Road AKA SR905 other
landfills in neighboring countries or any other location for disposal as long as the
site is a legal licensed disposal site. Prior to transportation of vessels out of
County the County representative must approve. Vessels being disposed of at
County Landfill sites must be free of pollutants and engines.
21. PROOF OF PROPER DISPOSAL AND NOTIFICATION TO MARINE
PATROL: Contractor must submit prior to receiving any payment: A receipt for
each vessel including the date of disposal, the Florida Marine Patrol Derelict Vessel
Number, disposal site location, and the telephone number. Recipient of debris
should provide detailed receipt showing type and description of debris received.
In addition to the above information, Contractor must submit three pictures of
each vessel removed. The first photograph must be of the vessel at the current
location prior to removal, the second photograph must be of the vessel after
removal but in the same general area preferably while in tow, and the third
8
photograph must be of the vessel at the disposal site with sufficient background to
depict disposal (i.e.. building or sign identifying disposal site). The derelict
vessel number. when possible, must appear in all photographs.
The Contractor will be responsible for the camera, film. and development costs.
The photographs should be taken with a Polaroid camera that provides instant
photos since this minimizes loss of documentation due to camera malfunction or
loss overboard. This photos must be submitted on a vessel by to document the
removal and disposal of the contracted vessels final pa:'11lent can not be assured.
The Contractor must notify the Florida Marine Patrol and the County
Representative in writing as to the work schedule 01 removal. This ~hould be done
after the pre-work conference with the County representative. Notification is to be
made before doing any work on each vessel. This multiparty communication for
each Derelict Vessel is a requirement of the contract.
II
PAYMENT: All payments for the removal and disposal of each vessel'. shall be
for the performance of the work as stipulated in these specifications and associated
contractual documents. The unit rate of bid shall be totally inclusive for all phases
of the operation. The Contractor may request two partial payments by submitting
an invoice for the number of vessels removed up to the date of the invoice.
providing the Contract agreement does not explicitly prohibit partial payments.
Photographs, disposal receipts, and signed FDEP Disposition Certification form for
the vessels for which payment is being requested.
The Contractor understands and agrees that no payment will be forthcoming for the
removal and disposal of any derelict vessel (1) not listed on this contract nor (2) for
any derelict vessel on this contract for which a written certification verifying the
removal of the subject vessel has not been obtained from the Florida Marine Patrol
and a Representative of the disposal site at the time of delivery.
In addition, property, public or private, if damaged during the work or removed for
the convenience of the work, shall be replaced at the expense of the Contractor in a
manner acceptable to the County and the Owner, prior to the final payment for
contracted work.
23. NON-COLLISION AFFIDAVIT: Upon entering into the contract, the Contractor
agrees to sign and endorse the Non-Collusion Affidavit form (attached).
24. ETHICS CLAUSE: Upon entering into the contract, the Contractor agrees to sign
and endorse the Ethics Clause form (attached).
25. DRUG FREE WORK PLACE FORM: Upon entering the contract, Contractor
agrees to sign and endorse the Drug Free Work Place form (attached).
9
C.G< l~ .. '';' 'J
1996 Edilion
MONROE COUNTY, FLORIDA
INSURANCE CHECKLIST
FOR
VENDORS SUBMItTING PROPOSALS
FOR \VORl(
To assist in the development of your proposal, the insurance coverages marked with an ..X.......,ill
be r~quired in the event an award is made to your firm. Please review this fonn 'with your
insurance agent and have hirnlher sign it in the place provided. It is also required that the bidder
sign the fonn and submit it with each proposal.
WORKERS' COMPENSA nON
AND
EMPLOYERS' LIABILITY
WCI
WC2
WC3
WCUSLH
X \V orkers' Compensation
x Employers Liability
Employers Liability
Employers Liability
US Longshoremen &
Harbor Workers Act
X Federal Jones Act
Statutory Limits
$l 00,000/$500,000/$1 00,000
$:5 00,000/$ 500,000/$ 500,000
$1,000,000/$1,000,000/$1,000,000
Same as Employers'
Liability
Same as Employers'
Liability
WCJA
INSCKLST 1
<\dl11ll1lSlrallOn InslrUCllon
~ 4709 2
I Q96 Edlllon
As a minimum, the required general liability coverages will include:
GENERAL LIABIU=iY
· Premises Operations
· Blanket Contractual
· Expanded Definition
of Property Damage
Required Limits:
GLl
x
GL2
GL3
GL4
Required Endorsement:
GLXCU
GLLIQ
GLS
PrQducts and Completed Operations
Personal Injury
.
.
$ I 00,000 per Person; $300,000 per Occurrence
$50,000 Property Danlage
or
$300,000 Combined Sinl!le Limit
. -
$250,000 per Person; $500,000 per Occurrence
$50,000 Property Damage
or
$500,000 Combined Single Limit
$500,000 per Person; $1 ,ooo,oqo per Occurrence
$100,000 Property Damage
or .
$1,000,000 Combined Single Limit
$5,000,000 Combined Single Limit
Underground, Explosion and Collapse (XCU)
Liquor Liability
Security Services
All endorsements are required to have the same limits as the basic policy.
Administration InslruCllon
114709 2
[l'\SCKLST 2
1996 Edition
As a minimum, coverage should extend to liability for:
VEHICLE LIABIL;,:,}Y
· Owned; Non-owned; and Hired Vehjcles
Required Limits:
VLI
VL2
VL3
VL4
BRl
MVC
PROl
PR02
PR03
POLl
POL2
POL3
EDl
ED2
GKl
GK2
GK3
WI.l
x
x
x
AdnllnlSlrallon InstruCllon
/lOO'j 2
S50,000 per Person: $100,000 p~r Occurrence
$25,000 Property Damage
or
$100,000 Combined Single Limit
$ I 00,000 per Person; $3GO,000 per Occurrence
$50,000 Property Damage
or
$300,000 Combined Single Limit
$500,000 per Person; $1,000,000 per Occurrence
$100,000 Property Damage
or
$1,000,000 Combined Single L.imit
$5,000,000 Combined Single Li~it
MISCELLANEOUS COVERAGES
Builders'
Risk
Limits equal to the
completed project.
Motor Truck
Cargo
Limits equal to the maximum
value of anyone shipment.
Professional
Liability
$ 250,000 per Occurrencel$ 500,000 Agg.
$ 500,000 per Occurrence/$l ,000,000 Agg.
$1,000,000 per Occurrence/$2,000,000 Agg,
$ 500,000 per Occurrencel$l ,000,000 Agg.
$1,000,000 per Occurrence/$2,000,000 Agg.
$5,000,000 per Occurrence/$10,000,000 Agg.
$ 10,000
$100,000
Pollution
Liability
Employee
Dishonesty
Garage
Keepers
$ 300,000 ($ 25,000 per Veh)
$ 500,000 ($100,000 per Veh)
$1,000,000 ($250,000 per Veh)
Watercraft Liability $500,000
INSCKLST 3
1996 Edlllon
INSl lRANCE AGENTS ST j, T2!vfENT
I have reviewed the above requirements with the bidder named below. The following deductibles
apply to the corresponding policy.
POLlCY DEDUCTIBLES
Liability policies are Occurrence _ Claims Made
Insurance Agency
Signature
BIDDERS STATEMENT
I understand the insurance that will be mandatory if awarded the contract and will comply in full
with all the requirements.
Bidder
Signature
INSCKLST 4
AdmlnlSlr.lllon InslruC!lon
114709 2
1996 Edition
WORKERS' COMPE~c;ATION
INSURANCE REQUIREMENTS
FOR
CONTRACT
,
BET\VEEN
MONROE COUNTY, FLORIDA
AND
Prior to the commencement of work governed by this contract the Contractor shall obtain
Workers' Compensaticn Insurance v..ith limits sufficient to respond to Florida Statute 440.
In addition, the Contractor shall obtain Employers' Liability Insurance v..ith limits of not less
than:
$100,000 Bodily Injury by Accident
$500,000 Bodily Injury by Disease, policy limits
$100,000 Bodily Injury by Disease, each employee
.
Coverage shall be maintained throughout the entire term of thoe contract
Coverage shall be provided by a company or companies authori"zed to transact business in the
state of Florida.
If the Contractor has been approved by the Florida's Department of Labor, as an authorized self-
insurer, the County shall recognize and honor the Contractor's status. The Contractor may be
required to submit a Letter of Authorization issued by the Department of Labor and a Certificate
of Insurance, providing details on the Contractor's Excess Insurance Program.
If the Contractor panicipates in a self-insurance fund, a Certificate ofInsurance will be required.
In addition, the Contractor may be required to submit updated financial statements from the fund
upon request from the COUnty.
weI
AdminlStrallon Instruction
# 4709 2
1996 EditIon
\\'ORKERS' CO~1rEN3A TION
INSURANCE REQUIREMENTS
FOR
CONTRACT
I I
BET\VEEN
MONROE COUNTY, FLORIDA
AND
Recognizing that the work governed by this contract involves Maritime Operations, the Contractor's
Workers' Compensation Insurance Policy shall include coverage for claims subject to the Federal Jones
Act (46 U.S.C.A. subsection 688) with limits not less than those specified for Employer's Liability.
The Contractor shall be permitted to provide Jones Act Coverage through a separate Protection and
Indemnity Policy, in so far as the coverage provided is no less restrictive than would have been provided
by a Workers' Compensation policy. .'
\\' CJ A
Ad/mnlstratlon Instruction
1/4709 2
1996 Edition
GENERAL LIAIHL~TY
INSURANCE REQUIREMENTS
FOR
CONTRACT
I
IJ ET\VEEN
MONROE COUNTY, FLORIDA
AND
Prior to the conunencement of work governed by this contract, the Contractnr shall obtain
General Liability Insurance. Coverage shall be maintained throughout the life of the contract and
include, as a minimum:
· Premises Operations
· Products and Completed Operations
· Blanket Contractual Liability
· Personal Injury Liability
· Expanded Definition of Property Damage
The minimum limits acceptable shall be:
.>
$300,000 Combined Single Limit (CSL)
If split limits are provided, the minimum limits acceptable shall be:
$100,000 per Person
$300,000 per Occurrence
$ 50,000 Property Damage
An Occurrence Form policy is preferred. If coverage is provided on a Claims Made policy, its
provisions should include coverage for claims filed on or after the effective date of this contract.
In addition, the period for which claims may be reported should extend for a minimum of twelve
(12) months follov.ring the acceptance of work by the County.
The Monroe County Board of County Commissioners shall be named as Additional Insured on
all policies issued to satisfy the above requirements.
GLl
AdmrnlSlrallon InSlrUCllon
114709 2
. 'Nfl Edlt,on
VEHICLE LIABILll;Y'
I:"SURA:"CE REQUIREMENTS
FOR
CONTRACT
BET\VEEN
\10NROE COUNTY, FLORIDA
AND
Recognizing that the work governed by this contract requires the use of vehicles, the Contractor,
prior to the comrnencement of \l,'ork, shall obtain Vehicle Liability Insurance. Coverage shall be
maintained throughout the life of the contract and include, as a minimum. liability coverage for:
· Ovmed, Non-O\l.'T1ed. and Hired Vehicles
The minimum limits acceptable shall be:
$100,000 Combined Single Limit (CSL)
.'
If split limits are provided, the minimum limits acceptable shall be:
$ 50,000 per Person
$100,000 per Occurrence
$ 25,000 Property Damage
The Monroe Countv Board of Count" Commissioners shall be named as Additional Insured on
all policies issued to satisfy the above requirements.
VLI
-\dnllnl'lrallllll Instruction
11470't 2
xo
1996 Edition
POLLUTION LIABILITY
INSURANCE REQUIREMENTS
FOR
CONTRACT
BET'VEEN
MONROE COUNTY, FLORIDA
AND
Recognizing that the work governed by this contract involves the storage, treatment, processing,
or transporting of hazardous materials (as defined by the Federal Environmental Protection
Agency), the Contractor shall purchase and maintain, throughout the life of the contract,
Pollution Liability Insurance which will respond to bodily injury, property damage, and
environmental damage caused by a pollution incident.
The minimum limits of liability shall be:
$500.000 per Occurrence/$I,OOO,OOO Aggregate
If coverage is provided on a claims made basis, an extended claims reporting period of four (4)
years will be required.
POLl
.\dmlnlstrallon Instruction
114709 2
71
1'1'16 Edition
\V A TER CRAFT LIAIHL.!J.Y
INSURANCE REQUIRE1\7f;N1-S
FOR
CONTRACT
, I
BET\\'EEN
MONROE COUNTY, FLORIDA
AND
Prior to the commencement of \J,.'ork governed by this contract, the Contractor shall obtain
Water Craft Liability Insurance with terms no less restrictive than those found in the
standard "American Institute Hull Clauses" (June 2, 1977 edition). Coverage shall be
maintained throughout the life of the contract and include, as a minimum:
· Injury (including death) to any Person
· Damage to Fixed or Movable Objects
· Costs Associated with the Removal of \Vrecked Vessels
· Contractual Liability with Respect to this Contract
If the policy obtained states that coverage applies for the "Acts.,or Omissions ofa Vessel",
it shall be endorsed to provide coverage for the legal liability of the Shipo~l1er.
The minimum limits acceptable shall be:
$500,000 Combined Single Limit (CSL)
Coverage provided by a Protection and Indemnity Club (P&I) shall be subject to the
approval of the County.
The Monroe County Board of County Commissioners shall be named as Additional
Insured on all policies issued to satisfy the above requirements.
WLl
AdmlnlSlrlli<:ln Il1\1rucllon
1/47092
C.L.LenC4+; ~od"':
OLUr:;WAl
PRODUCER
Starkweather & Shepley,
P.o. Box 549
Providence, RI 02901
Inc.
DATE (MMffiDIYY)
03/17/00
TIllS CERTIFICATE IS ISSUED AS A MATI'ER OF INFORMATION
ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE
HOLDER. TIllS CERTIFICATE DOES NOT AMEND, EXTEND OR
ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW.
I
ACDRD".
CERTIFICATE OF LIABILITY INSURANCE
INSURERS AFFORDING COVERAGE
INSURED
Blue Water
Capt. Cole
16015 S.W.
Homestead,
COVERAGES
NEW HAMPSHIRE INSURANCE
Marine Services
Murray
298 Terrace
FL 33033
INSURER A:
INSURER B:
INSURER C:
I INSURER D:
INSURER E:
THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDIN
ANY REQUIREMENT. TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED 0
MAY PERTAIN. THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS. EXCLUSIONS AND CONDITIONS OF SUC!
POLICIES. AGGREGATE LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS.
ilNSR ' I POLICY EFFECTIVE IPOLICY EXPIRATION I
LTR TYPE OF INSU1VINCE POLICY NUMBER I DATE lMMffiDJYY) I DATE lMMffiDJYY) , LIMITS
A GENERAL LIABILITY IGL6082267 12/20/99 '12/20/00 ,EACHOCCURRENCE $$1, ,)00,001
_ _S:,~MERCIALGENERALLIABn..m' ! ~E DA~AG~_(AnJ.... fi~J.!.S.5 O~<L-_
_, ___ CLAIMS MADE OCCUR : MED EXP (Anyone po=) $ $ 5 , 0 0 0
PERSONAL &t ADV INJURY : $ $1, 000 , 00'
GENERAL AGGREGATE $$2,000,001
PRODU<:!!~_MP/OP AGO ! $ $1, 000 , 00 I
GEN'LAGGREGATE LIMIT APPLIES PER: I
- POLICY 0 r~~ - LOC
AUTOMOBILE LIABILITY
HIRED AUTOS
'~"I ~ Ql'\;~"~"
uY ..~~. ')1, wlW~: ~~
. DAiE _3.L~J (X.\
1','!,:VtR:i'>!.;~ . L YES
COMBINED SINGLE LIMIT
(Ea ac<.deno
ANY AUTO
ALL OWNED AUTOS
BODILY INJURY
(Per po=.
SCHEDULED AUTOS
NON-OWNED AUTOS
BODILY INJURY
(Per ac<.dent)
PROPERTY DAMAGE
(Per ac<.dent)
,-GARAGE LIABILITY
: AUTO ONLY , EA ACCIDENT ,$
ANY AUTO
OTHER THAN
AUTO ONLY:
EA ACC $
AGO $
EXCESS LIABILITY
-- ------,
_ OCCUR .~ CLAIMS MADE I
EACH OCCURRENCE
AGGREGATE
,$
:$
,$
$
--------~--
DEDUCTIBLE
RETENTION $
WORKERS COMPENSATION AND
EMPLOYERS' LIABILITY
!
:T'6i~ L'I~\!rs I
: E.L. EACH ACCIDENT
$
OJ~-I
is
AIOTHERP&I
lCV3030352-13721
I
E.L. DISEASE ' EA EMPLOYEE I $
I E.L. DISEASE . POLICY LIMIT I S
112/20/99 112/20/00 i $500,000
,
DESCRIPTION OF OPERATlONSILOCATIONSIYEHICLES/EXCLUSIONS ADDED BY ENDORSEMENT/SPECIAL PROVISIONS
CERTIFICATE HOLDER LISTED BELOW IS NAMED AS ADDITIONAL INSURED AS RESPECTS
CERTIFICATE HOLDER
ACORD 25-8 (7/97) 1 0 f 2
#S10316/MI0314
CANCELLATION
SHOUIJ) ANYOF'DIE ABOVE DESCRmED POLJ:IES BE CANCEUED BEFORE 'DIE EXPItA11DN
DATE THEREOF, THE ISSUING INSURER WILL ENDEAVOR TOMAIL1Q_ DAW WJUrn:N
Nan::ETO'DIE CER11Fa:An: HOU>ERNAMED TOmE LEFT, BUTFA&AJRE TODOSOSHALL
IMPOS E NO OB LlGA~iEtV.or ANv\<alln lI~c)~JD:'1lJRER.rrs AGENTS OR
REPRESENTATIVES.TNSU .f: U'C:;;T"~'.~E .,
AlfI'HORIZED REPRESENT I\UMn'"
f'
........
SLN /" .1CORD CORPORATION 19
I ADDIIDNALfIlSURED'fIlSlJRERLETmR:
Monroe County Board of Comm.
Attn; Ms. Kim McGee
5100 College Road
Key West, FL 33040