Loading...
Item B04 BOARD OF COUNTY COMMISSIONERS AGENDA ITEM SUMMARY .\1eeting Date: 07 -?,7 -00 Division: Gro\V1h ManalZemem Bulk Item:YESl :.JO Department:Marine Resources AGENDA ITEM WORDING: Approval of the Contract Agreement between Monroe County and Blue Water Marine. Inc. for the removal ofDV3A2470. ITEM: This vessel is a two-story 60' wooden hull and is in unrepairable condition. People that do not own it having been living aboard in unsafe conditions. The vessel could pose danger to surrounding homeowners if the area was hit by a major storm. It needs to be removed as soon as possible. Two quotes for removal received. A.S.A.P.. Inc.-$Sl.SOO.OO and Blue Water Marine, Inc.-$lS,749.98. PREVIOUS RELEVANT BOCC ACTION: Grant Agreement with FWCC approved 4- 20-00. STAFF RECO~1MENDA nON: Approval TOTAL COST: $15,749.98 BUDGETED: COST TO COUNTY: Staff Time Only 100% Grant Funding REVENUE PRODUCING: YES NOl AMT. PER MO. YEAR .-\PPROVED BY:COATTY X OMB/PLRCHASING'~S TMA'\iAGE.\lEl\T X Lv, Ie ' DIVISION DIRECTOR APPROVAL: Timothy 1. McGarry-Divisio DEPARTMENT HEAD APPROVAL: George DOCUMENTATION: INCLUDED:~ TO FOLLOW:_ NOT REQUI~~lll' DISPOSITION: :\GENDAITEM#~ MONROE COUNTY BOARD OF COUNTY COi\tl\'I~ . ~~"S CONTRACT SUMMARY Contract # ~, Contract with: Blue Water Marine, Inc. Effective Date: 1 --- Expiration Date: _I_I _ Contract Purpose/Description: Removal of DV3A2470 -S"~I Contract Manager: Kim McGee (Name) 4511 (Ext.) Marine Projects ( Department) for BOCC meeting on 07./ 27 / 00 Agenda Deadline: 07 / 10 / 00 Total Dollar Value of Contract: $ Budgeted? Yes_No Grant: $ 15.749.98 County Match: $ NI A CONTRACT COSTS 15.749.98 Current Year Portion: $ 15.749.98 Account Codes:~- 62512 - 53049(} GB0012 5JOJ40 Estimated Ongoing Costs: $ (Not included in dollar value above) ADDITIONAL COSTS NI A /yr For: (eg. maintenance, utilities, janitorial. salaries, etc.) County Attorney CONTRACT REVIEW Changes Date In Needed Yes No ~/20/~ (.if (~ Date Out Division Director R~'S anagernent ~ . ,) ~ ,. - t.1\)u o .M.B./Purc~~g J ~/ J.:b..1..Q.9 ( r ...::-1 ~/~ ~/1J 1M ( ""'''<I'''''CI'''( &~~. y.O. ~,. , ~..<(.,. ~ \. " VJ." 3\Vv / '---- IJ Iv \ ~ Blue Water Marine, Ine. d/b/a TowBOATIU.S. South Dade PO BOX 901716 Homestead, Florida 33090-1716 Phone I Fax (305) 230-0030 QUOTATION May 5,2000 TO: Kim McGee FROM: Blue Water Marine, Inc. SUBJ: Removal ofDV-2470 The following quotation is for the removal ofDV -2470, a 60' wooden vessel located in Little Basin near Cockerham Dock. DV-2470 can be removed and disposed of for the sum of $15,749.98. Blue Water Marine, Inc. understands it is responsible for all disposal costs. Respectfully Submitted, ;L Ifl f I I fA-)JV~U Capt. Todd Seeds Blue Water Marine, Inc. a5/::/2000 B7:14 305-85:-';;30'3 LISA FRINS r-~ UJ./UJ. A.S.A.P., INC. P.O. Box 804 Tavernier, FL 33070 (305}85Z..4554 MARINE CONTRAcrORS May 22, 2000 Monroe County Marine Services Attn.: Kim McGee VIA FACSIMILE. 295-4317 RE: DV-3A~2470; 60' 3 Story Vessel in Little Basin J51amora~ FL Please accept OUT proposed removal and disposal price of$5 1,500. PartiaJ payment oftbiny percent (30%) dunng the course of the work will be expected. If you have any questions, please call. SinceIely, ASAP., me. MARINE COmRAcrORS CONTRACT AGREEMENT AGREEMENT. \1ADE THIS day of 2000. bv and between. Blue Water Marine. Inc. ('"Contractor"), and the BOARD OF COUNTY COMMISSIONERS OF MONROE COUNTY. FLORIDA. of the County of Monroe. State of Florida ("Board"). The Contractor and the Board. for the consideration named agree as follows: 1. The Contractor shall furnish all the materials and perform all the \vork as required by the Specifications for the emergency removal of DV3A24 70 for which a Florida \-1arine Patrol Derelict Vessel Report is attached as Exhibit A. ") The work to be performed under this contract must be completed by August 3 I. 2000. 3. The Contractor understands the rules of the Florida Fish and Wildlife Conservation Commisssion and shall comply with those rules, along with the rules and procedures instituted by the Board to ensure an orderly progress to the project. Both the intent and the requirements of the Specifications, attached as Exhibit B. are understood by the Contractor. -+. The Board shall pay the Contractor :5 15.7"+9.98 tor the remO\.al and legal disposal of DV3A2470. Payment will be upon completion of work by the Contractor and review and approval by the Marine Projects Coordinator. 5. The attached Derelict Vessel Reports, Specifications, and the Monroe County Insurance Requirements together with this Agreement, form the Contract. They are fully a part of this C an tract as if repeated herein verbatim. 6. The Contractor covenants and agrees to indemnify and hold harmless the Monroe County Board of County Commissioners from any and all claims for bodily injury (including death). personal injury and property damage (including property owned by the County) and other losses. damages. and expenses (including attorney's fees) which arise out ot: in connection with. or by reason of services provided by the Contractor or any of its Subcontractor (s) in any tier, their employees or agents. The purchase of the insurance required in paragraph 11 does not vitiate this indemnification provision. 7. The Contractor agrees to supply the County with a set of photographs of each vessel in all phases of the removal and disposal process. The Contractor will be responsible for the camera. film, and development costs. 8. The Contractor must inform the County and the Florida Marine Patrol prior to initiation of \vork. 9. The parties agree that a timely performance of this agreement is essential due to possible damage to the natural resources, hazards to navigation, or threats to human health and welfare. Therefore, the parties agree that the Contractor shall be liable to the Board for $100 per day of liquidated damages for each day after 8-31-00 that the Contractor's obligations under this agreement remain unperformed. The parties agree that such amount is by the way of compensatory damages and does not constitute a penalty. 10. Due to the use of heavy equipment and, at times. dangerous work environment, the Contractor understands and agrees to maintain an alcohol an drug free work environment. 11. The Contractor will be responsible for all necessary insurance coverage as indicated by an "X" on the attached forms identified as fNSCKLST 1-4. as further detailed on forms VL I. WC 1. WCJA. GL 1. WL I. & POL 1 attached as Exhibit C. A.II policies must list Monroe County as additional insured with the exception of the Worker's Compensation policy. ,., -- 12. The Contractor warrants that it has not employed. retained or otherwise had act on its behalf any former County officer or employee subject to the prohibition of Section 2 of Ordinance \io. 0 I 0-1990 or any County officer or employee in violation of Section 3 of Ordinance No. 020- 1990. For breach or violation of this provision, the owner may, in its discretion, terminate this contract without liability and may also, in its discretion, deduct from the contract or purchase price. or otherwise recover the full amount of any fee. commission, percentage. gift. or consideration paid to the former County officer or employee. 13. A person or affiliate who has been placed on the convicted vendor list following a conviction for public entity crime may not submit a bid on a contract to provide any goods or services to a public entity, may not submit a bid on a contract with a public entity for the construction or repair of a public building or public work. may not submit bids on leases of real property to public entity. may not perform work as a contractor. supplier. subcontractor, or consultant under a contract with any public entity, and may not transact business with any public entity in excess of the threshold amount provided in Section 287.017 of the Florida Statutes, for CATEGORY TWO for a period of 36 months from the date of being placed on the convicted vendor list. IN WITNESS WHEREOF each party hereto have executed this Agreement the day and year tirst written above. (SEAL) Attest: DANNY L. KOLHAGE, CLERK BOARD OF COUNTY COMMISSIONERS OF MONROE COUNTY, FLORIDA By: Deputy Clerk By: Mayor/Chairman Witness://S'. 7/~ ~ ~ ~Je'& Witne : . _,/~I// _~/~ '" :- . "::! ~/ .WJ Busmess Name: ~?>/#r ///f"A:/I"'C By: d'g, ~' &. ,,- /r; Title: // // / 3 to INC!DE~T REPORT NARRATIVE CONTINUATION l-~ I I 1. 3. PHYSICAL LOCATION OF DV: L\-M'"~ Bb.$\....J - \'-k2.. c.oc..lo:::'.oE""-\~~M COc.1L. LATITUDE/LONGITUDE (DEGREES, MINUTES, SECONDS] 2~ L)..c;.:Sf(2f/J f0.,jrE7'z-v/ 4. CONDITION: WRECKED-L- JUNKED~ DISMANTLED ---X ABANDONED_ AGROUND BURNED CAPSIZED BROKEN UP 5. SUBMERGED 20% % DEPTH 3' FT. ANCHORED ADRIFT ON SHORE_IN WETLANDS_ TIED TO OBJECT_ OTHER ;.. 2. 6. I 7. 8. 9. 10. " EXHIBIT A ZONE I DERELICT VESSEL # 3A- "2..47 D INCIDENT # "''"1 REG # ~ lENGTH~FT. MAKE: Unknown MODEL HULL MATERIAL: WOODL F/G_ METAL-",- OTHER (SPECIFY) MOTOR YES_ NO-.! TYPE OTHER IDENTIFIERS -"I. A - 15::&-S" COLOR GraY/Whit. VESSEL OWNER: ADDRESS: Unknown D.O.B. / I COUNTY PROPERTY OWNER: State of Florida STATE lAND_ PERMIT FOR ABANDONMENT: YES_ NO~ ISSUED BY ABANDONMENT REASON - Unknown NAVIGATION THREATENED? YES~ NO_ HOW Unlighted may ~et bit at ni2:ht. ENVIRONMENT ENDANGERED? YES X NO_ HOW Resting on bottom. !. - 11. TOWED WITHOUT REPAIR? YES NO X UNK OTHER 12. RECOMMENDED DISPOSITION: LANDFILL X ARTIFICIAL REEF MARINE HABITAT_ RECYCLE METAL OTHER 13. NARRATIVE I DILIGENT SEARCH (EXPLAIN! Vessel in very 'Door condition_ 'MtPTP ar~ / ;:::,1 ,;1f" numerous' holes in tbe bottom p]anldnf~_ ApPP="T'" t-n b~ !'l~lIr1c- ;n . tJ' /I/~ ,1,1 r A 5 a'Dproximatelv 18" of mud. It also appTP="T~ ~n h:n.... pfitQP18 I '1 J ~ ( 1. . . ! '. ~ - (,,, ',;' l.Vl.n~ on it. It 1S unsaf~ and ne~ds t'o hp TPmnv..r1 ;......ediat81~,.. ul.- , uj'l J /.,0//; 'v1C"C No on~ visibl~ at rim,. o~ rppnrf" No v;~;blQ identifier". - r-. . /' ~( Ie; I:- ::: I.:)/'~i ~ (I ~.'rl( ,1'7 "t/I Y,~' , '.. .' I /"'7~--:;-----11 Ii . --r hf- 1 ?f r ~!.-E ,v;).f(- 7/ {" 'I 14. PAINTED DVII ON VESSEL? N DATE I I 4 PHOTOS OF DV INCLUDED? Yes Offlcer(sl Reporting (please prlntJ Deputy John W.. McGee-MCSO #7878 Reviewed [Jy' V. L- ..LT. }I -21 - 7' I CI Lalloll NUIIII )1'1 , , hrr- '0 0"1 r;i\\r1111t11rJlC -. ___ __'_~_'_'_,___.~_*_ 1_~ NUll1lJcr MrcsLcd OUl S Numbcr Ollglllal <;UPlllc!l1cnl P,l<jC. r()T~ \NClQENT Rk:t-'UK l 'I-T.: r" M. K K J-\ I I \II C '- V I'" , il 'HJ i-"I. I I U I '& - . - --- ------- ~~_i'lL ; T' DERELICT VESSEL 4 3A- 2- '-! ~7 c' i :z: ~ \ Offlcerlsl Renn. f I.',:~!.;,PI(,. ;]',(' 111 IIlI) ~.fr? oh/ ~ 4'd ~ F - /Ylr ~Q pt' '\ltf'VJf 'f 1 I ~,' ()(f::"fj' ,'nl']'I~' '_'. If 1~1 ~"-v -0~(AJ,:0 '(C':~CL[ 9-2. , , .Ill! I i',rr' ?O Oftr,r, ml']f, , .:::':"1] tJ' ,~. \ en "-) "':J \ '> , \ 'J' " " ~ 'J> ".) ""'" 'J> ." 'll "-.l \ \ / / u' --/, , ~r 0' i' 'U = '::l. I -.! :;1 A j~ <"; ------ ',-: )1 01 I l~ ~"" 'T' i' (1 lJ "I \) " ,J ~I '\ (0) 0 ~J 'I) ___~:~__- _ _ ~--- \0 :; GJ ." - " '" " (1) !;'\ t. :!! c. .... / ) -,j GJ ~ (;-'1/ A. '''1 '" I' -. ~ -':<' ~~: . A",' s:~ :t :: ~ I_r, ( ", r 0., \ , , - 0-\ .. \ " o if] '.. ~"", ~ ::r' '-"\ \." l>> ~..... <>.~ \ :J ,"" . 'CJ ....... " ~ ~ - .... .~^l ( .,,' n~ ~, ~ ~. --1~ '" ~ .,. '" . \ .. 'Jl r. '" )1 ,/ / ... :.. :T> ! V'/ N ~)~ / "'W N / ~" T' ('0 '!l' .... .... --. "' W (./ ~ :: 2J . ~ ~ 9 ;: . ;.., <1t 2 ,0. ____ .t' .,..., V" 0. "Oota. lJ '-. ..--- ~ '~'" oo~!'\~ n ,./' :, i t..: ~.t'i 0 " , '. t" G't,'" ',I'" , ;? '" ; 'J' I ',) "'d " -., , (;:-) "' '1' I [; I; ,- 1 I ,\,' I i I I" I ..I I ' J$ . ,,) '~_j'~l 11'" , I :G) " \ ( "~~ JilU:i ~ -~ ~~jt-rrl " '" ~~ %:~1"~ < 'I "". '" ... "I::'" "-.,~(]l.,.,II" ~'"'" C)" lOI v,'" i '\." --. , " ~ (L') .f?,> ~ ;~ , co v In ~ ~ J 0- 3 .", ,> EXHIBIT B DERELICT VESSEL RE~10VAL CONTRACT SPECIFIC.-\. TIONS FOR \IONROE COUNTY. FLORIDA I~TE~T: It is intended that these specifications shall cover all aspects of the \vork. The purpose of this section is to provide specific conditions applicable to this contract where such coverage is not provided in other portions of the documents. BID FOR.v1A T .-\ doilar :.lmount per foot must be submitted for the removal of as many derelict vessels on the primary list for \vhich a Florida :vlarine Patrol Derelict Vessel Report is provided and as funding will allow. Any deviation from this format will result in an unaccented bid. A contract will not be granted on the basis of combined. related. linked. or discounted bids. Not applicable due to emergency removal of one or more derelict \'essels for less than $25.000 total. , PLANS: There are no plans for this project, but copies of the Florida :v1arine Patrol Derelict Vessel Report with location sketches have been bound into these documents for the Contractor's use. The Specifications include a section on instructions to bidders. both general :.lnd specifIc. and a copy of each Derelict Vessel Report from the Florida Marine Patrol. Only those derelict vessels for which a report is included and listed on the Bid Response Form are to be bid upon and subsequently removed. The County reserves the right to remove any or all vessels from this contract at any time prior to actual removal from the water and disposal by the Contractor. The County has a limited amount of money to effect the removal of these derelict \essels. \Ve have established pnorities based on public safety. navigational hazard. ,md environmental considerations. If bids exceed the County' s resources for removal based on these considerations. we shall limit vessel removal based on the considerations and cost etIectiveness. .f. VESSEL IDENTIFICATION AND LOCATION: Each of the vessels have been given a derelict vessel identification number. which is shown with the location in the Florida Marine Patrol Derelict Vessel Report. included herewith. Each bidder is responsible for his own identification of each derelict vessel as to location. description and condition. If a derelict vessel cannot be (1) located. (2) removed. (3) verified and (4) disposed ot: as specified in these procedures. then no payment \vill be made fonhcoming to the Contractor for that vessel. Those four conditions must be met on each derelict vessel along with compliance of all laws for payment to be made. It is understood that the Contractor has. by personal examination and inquiry. if necessary. satistied himself as to local conditions of each derelict \"essel and as to :he meaning, requirements and reservations of the specitlcarions: for after contract letting. no deviation will be allowed. In case errors are discovered. they are to be reported by the Contractor to the County. The county assumes no responsibility should there be any discrepancies in \vhat is stated in these documents and what the bidder evaluates. The Contractor should take special care to remove only those derelict \"essel" s on his Contract and for which he possesses a Florida ~lanne Patrol Derelict Vessel Report. Other derelict vessels in the area but not under Contract. cannot be molested. It may be possible to replace a derelict vessel of like kind. for the same or less money. when mutual agreement can be reached by the FI?rida Department of Environmental Protection. Monroe County Administrator of the Derelict Vessel Program. and the Contractor. This will be applicable when a contracted derelict \"essel cannot be located. No derelict vessel may be replaced and removed without the tri-pany consent noted in this paragraph. .-\ contractor may suggest a possible replacement vessel but he may not remove it without the appropriate consent above. 5. SCOPE OF WORK: The Contractor shall be responsible for providing all permits. supervision. labor, equipment, tools, fees and taxes required to complete this project to the satisfaction of the County. The Contractor"s procedure and methods of removal may be of his own selection :cro\"ided they "ecure results '.\hich satist\ the reauirements nf :he ::::recifications :md any necessary environmental permits. Any vessel which is removed and disposed of shall be removed from its present site in such a manner as to do the least possible damage to the natural environment. All debris from the vessel shall be removed and the site left in a reasonably clean condition. No oil or fuel shall be permitted to be dumped or spilled into or unto the \vater or land. All pollutants shall be removed from the derelict vessel prior to removal from the water. The Contractor shall be responsible for making any and all arrangement for access to the vessel to be removed. If private propeny has to be traversed. then written permission of the owner is necessary. In removing a derelict vessel that may lie on or near grass or sponge Hats extreme caution must be used to do the least possible damage. Prior to delivery of derelict vessels to the disposal site. the Contractor must remove all oil. gas and engines. He must dispose of them in any legal manner. Pure used oil will be taken by \lonroe County for disposal. ~lixture of oil. gas. seawater or any combination of the three must be transported from the County by an approved hazardous waste handler. The names of handlers will be supplied by the Monroe County Solid Waste Department. \tletal becomes the property of the Contractor. o. \lA TERIALS AND WORK.."\lANSHIP: The ContractoI:. shall provide the necessary materials and equipment to safely complete the job. The Contractor agrees that all work shall be performed by competent employees who are experienced and qualified to do the work specified. and that all work will be performed in accordance with the best commercial practices. .-\ list of equipment to be used and a description of the removal and transponing procedures to be followed must be provided to the County at the pre-work conference described below. Precaution shall be exercised at all times for the protection of persons and property" The safety provisions of the Occupational Safety and Health Act of 1970 (Public Law 91-596) and other applicable laws. including building and construction codes shall be observed. Machinery, equipment and other hazards shall be guarded in accordance with safety provisions of the "Manual of Accident Prevention in Construction", published by the Associated General Contractors of America, to the extent that such provisions are not in contradiction of appJicable law. 1f'ln\" nrorerT'l.';' ,~-~C'trO'l:".::Joa' :.....,'l. '~." ......,,11,..2l. -r -'-''''::''lr'l(;: ...;...,'1't>::'""'\:"J.'1.....::l.t'" ~~"'..:l /-. .,t'tr"c'or .'n"l") ..... '-'" . ,t-4 .. .1..._.:.') ul;,;..J...;1: .. _~.....; '....<,A.............\".. "_1 ....................J .\1.'-..........\..);;;.. '\.... ...1... ,-,--' l 1.4.. ,')......... repair and replace or not receive payment for the unaccomplished work. The Contractor shall maintain suitable and sufficient guards and barriers. and at night. suitable and sufficient light or other appropriate security or protection for the prevention of accidents. Use of explosives is prohibited in carrying out the project. 7. ASSIGNMENT OF CONTRACT AND SUBCONTRACTS: It is expressly understood that the Contractor is in all respects an independent Contractor for this work. not withstanding under certain conditions he is bound to follow the directions of the County. and is in no respect an agent. servant. or employee of the County. Neither the Contract. nor any part thereof. nor :my \loines due or to become due thereunder. may be assigned by the Contract9r without the prior written approval of the County. The Contractor is fully responsible to the County for the acts and omissions of his subcontractors and of persons either directly or indirectly employed by said subcontractor. as he is for the acts and omissions of persons directly employed by him. :Nothing contained in the relation benveen any subcontractors shall abide by the terms. conditions. and requirements of this Contract. It is the responsibility of the Contractor to pay all debt obligations incurred with subcontractors in an expedient manner. S. LEGAL RESTRICTIONS. PERMITS AND TRAFFIC PROVISIONS: The Contractor shall comply \vith all applicable local. State and Federal requirements penaining to the terms of this Contract. The Contractor will be responsible for obtaining, at his own expense. any licenses or permits that may be required and should inquire about permit requirements with the appropriate agencies. The Contractor shall comply \vith all the requirements of the Federal Pollution Control .-\ct. The Contractor shall conduct his operations so that he shall not close :my thoroughfare nor interfere in any way with traffic on highways. or on water. without the \vTitten consent of the proper authorities. Work shall be done at any :ime that shall not interrupt or disturb members of the public. Utilization of off-loading sites located on private property (water to land for transpon to the landtill or other disposal site by vehicle) must have \VTitten approval of the land owner. The Florida Marine Patrol should be contacted to initiate eviction proceedings for contracted derelict vessels which are inhabited at the time of removal and when another vessel is too close to the contracted derelict vessel to allow safe operations. ,)irect confront~tlOns \\ith (,ther oo:ners should be J\oided Jnd 'he F"\'rida \brine Patrol should be contacted immediately if such confrontations results from removal of any contracted derelict vessels. 9. INSURANCE: The Contractor must obtain insurance required by the County and submit proof of same to the County prior to acceptance of bid and contract approval by Board of County Commissioners but no later than five working days after notice of low bidder. .-\ll insurance shall be maintained until work has been completed and accepted by the County. The Contractor shall furnish the following certificates of insurance for review by the County"s Risk Management Division: Certiticate (s) ofInsurance which clearly indicates that he has obtained the insurance coverage required in paragraphs a.b.c and d below. 4 The Contractor hereby certities that no modification or change in insurance shall be made \vithout (I 0) days \\Titten advance notice to :.-100IROE County. c,o the Director of the Risk \lanagemem Di\"ision. a. Worker's Compensation Insurance per Fl. Statutes b. Federal Jones Act Coverage 12. General Liability Insurance on a comprehensi\"e basis, in an amount not less than S300.00.00 per occurrence for Bodily Injury and Property Damage combined. to include contractual liabilitv. c. Pollution Liability Insurance in the Amount of S500.000. d. Water Craft Liability Insurance in the Amount of S500.000. "' '-. Automobile liability insurance covering all owned. non-owned and hired vehicles used in connection with the work. in an amount not less than S 1 00.000 per occurrence for Bodily Injury and Property and Damaged combined. All insurance policies required above shall be issued by companies authorized to do business under the laws of the state of Florida. The MONROE County Board of County Commissioners must be listed as "Additional Insured" on all policies, except for the Worker's Compensation policy. 1 O. COMMENCEMENT. DELAYS AND COMPLETION OF WORK: After receiving Board of County Commission approval of the Contract. and after ~econcili::ltton \ if any details or 12onditions \\hi12h may jirectly (~r indirectly interfer;: or cont1ict with work of the Contract. the County will issue a 000Iotice to Proceed" officially authorizing the Contractor to commence. The Gontractor shall commence work within one week from the date on the "Notice to Proceed" letter. If the Contractor should be delayed in the progress of the work included in the Contract by enforceable causes beyond his control. the time for the completion of the work may be extended upon agreement of the County representative. Requests for an extension of time must be submitted in writing to the County representative. Extensions of time cannot legally be approved unless the \Hitten request is submitted in the time to permit it to be acted upon before the Contract expiration date. To allow sufficient time for the administrative procedures required to obtain action by the County Commission. a request for time extension must be received by the County representative at least sixty (60) calendar days prior to the Contract expiration date. .;; Provided further that the Contractor shall within ten ( 10) days from the beginning of such delay notify the County, in writing, of the causes o!the delay. The County representative will ascenain the facts and the extent of the delay and notify the Contractor within a reasonable time of her decistOn in the matter. If the Contractor fails to complete the work \vithin the time limit. and if the County should nevertheless permit the Contractor to continue and complete the same without official extension of time in 'vvriting, such permission shall not modify nor waive any liability of the Contractor for damages arriving non-completion of work within the time limit. but such liabilities shall be subject to continuation in full force against the contractor. 11. CHANGES AND INSPECTION: The vessels herein considered are to be removed for the County by the Contractor in accordance with the specifications. The County may give instructions or directions to supplement the specitlcations. These shall be binding upon the Contractor and upon all his subcontractors. employees and agents of every kind. All work and every process and operation shall be subject to inspection at all times. and the County and their representatives shall have free access to all aspects o I' the work. The Contractor shall remove and make good. as may be directed. without charge. any defective work. Oversight or error of judgment of inspections. or previous acceptance. shall not relieve the Contractor from the obligation to make good any defect whenever discovered. The right is reserved to change the Specifications consistent with regard to the general intention of the contract for any part of the work or materials, either before or after work has begun. Notice of such changes shall be given in writing to the '~clntr::lctor::uch ch:ll1~es ,::':' :1Cit [,I be grounds :'l'r ::n~ c!Jim by ,1,e C'ntrJctor t(,r damages. nor for the forieiture of the Contract. It is possible that a Derelict Vessel could disappear between the time of inspection by the contractor and the actual effort to remove it. :-.Jo payment will be forthcoming in event that this occurs. Except when otherwise specified. the expense of all tests requested by the County will be borne by the County. 12. AUDIT RIGHTS: As a provision of the grant from the State of Florida to the County, and if so requested by the State. the successful bidder agrees to provide access to all records and allow the audit of any books. documents and papers related to this project for a period of up to one year and dl}ring and after termination of the contract. 13. CONTRACT A WARD: The County reserves the right to evaluate the submitted bids and award a contract to the bidder submitting the lowest per foot bid for the derelict vessels listed in the bid package as one project and for \vhich a 6 Florida \-larine Patrol Derelict Vessel Report is included. One bid \vill be accepted and a Contract issued for the total removal of all listed derelict vessels as one project. up to the limit of available funds. The actual number of vessels to be removed \vill depend on the accepted per foot bid price and the available funds. 1-1-, PREWORK CONFERENCE: .-\ meeting will be necessary involving a representative of the County, the Contractor and other parties with direct involvement prior to the signing of the Contract. The time and place of this conference will be set by the County representative. .-\t this time the Contractor shall provide the County with a schedule as to the order in \vhich he proposes to remove the vessels awarded to him. 15, CONTRACT SECURITY: The Contractor is expected to act and deliver in good faith all work. at the agreed price. in the allowed time. Failure to do so, could jeopardize the contractor's reputation \vith the County and potentially int1uence any future contracts with MONROE County. 16. EXECUTION OF CONTRACT DOCe~lENT: Due to tne time frame involved \vith this project. the Contractor upon notitlcation that he is to be awarded the contract documents for execution. shall return said documents properly executed along \vith insurance \vithin TEN \VORKING DAYS. This \vill assist in acceleration of execution of the contract documents. The Contractor, by virtue of signing the Contract, acknowledges that he and all his subcontractors have satisfied themselves as to the nature and location of the work. the general and local conditions. including, but not restricted to. those bearing upon ~ransponJtion. handling, .1CCCSS '\) ,he :--ic k -'-1 I' .lnd d i srosal ~ i teS: ,::J the character \)f equipment and facilities needed to perform the work. Failure on the pan of the Contractor to completely or properly evaluate any factors of his costs prior to bidding shall not form a basis for additional compensation if he is awarded the Contract. If for any reasons, not acceptable to the County, the Contractor does not perform. the County shall have the right to levy liquidated damages against the Contractor. Liquidated damages in the amount of $100 per day shall be assessed against the Contractor for any bid item awarded to him \vhich is not completed and accepted by the County within the number of calendar days specified in the Contract. Liquidated damages are accumulative. 17, ~OTICE TO PROCEED: The Contractor shall commence work upon this project within one week of the date of the Notice to Proceed letter and perform in a continuous manner until completion and acceptance by the County, For Contracts wherein a specitied number of days for completion is stated in the Contract. the etfective date at the "~otice to Proceed with Contract Work" \vill establish the "beginning date"" ()fthe project. 1 S. TE~ylI0JA TIO~ OF CO~TRACT: This Contract may be terminated by the County. giving up to ten ( 10) days \\'Titten notice to the Contractor: said notice shall be sufficient if delivered to the party personally or mailed by certified mail to his mailing address as specitied on the accepted bid. 19. H~AL CLEAN-UP: Cpon completion of the \vork specified herein and before acceptance and tinal payment shall be made. the Contractor shall remove from the sites all machinery. equipment. surplus and discarded materials and temporary structures. The disposal of materials. rubbish and debris shall be made at a legal disposal site. 20. DISPOSAL SITES AND FEES: The Contractor is responsible for disposal of all derelict \'essels included in this contract and must make arrangements for legal disposal. It is the responsibility of the Contractor to pay all disposal fees incurred. and such removal related costs should be considered when bidding on this contract. The Contractor will deliver the derelict vessels to a Florida Department of Environmental Protection permitted disposal site that has current occupational tax licenses. It is the intent of this contract to remove derelict vessels from their present site and legally dispose of them. Upon receipt of vessels at the landfill, they must be disposed of immediately. There are several Monroe County disposal sites. Cudjoe Landfill. MM 21.5 I wssels :nust n.: 2fi'md under to be delivered;:1 t::let.vcr 25' 'hey must be broken UP). Long Key Landtill MM 68. and Card Sound Road AKA. SR905 other landtills in neighboring countries or any other location for disposal as long as the site is a legal licensed disposal site. Prior to transportation of vessels out of County the County representative must approve. Vessels being disposed of at County Landfill sites must be free of pollutants and engines. 21, PROOF OF PROPER DISPOSAL AND :--JOTIFIC-\ TION TO MARINE PATROL: Contractor must submit prior to receiving any payment: A receipt for each vessel including the date of disposal. the Florida Marine Patrol Derelict Vessel Number. disposal site location. and the telephone number. Recipient of debris should provide detailed receipt showing type and description of debris received. In addition to the above information, Contractor must submit three pictures of each vessel removed. The tIrst photograph must be of the vessel at the current location prior to removal. the second photograph must be of the vessel after removal but in the same general area preferably while in tow. and the third s photograph must be of the vessel at the disposal site with sufficient background to depict disposal (i.e.. building or sign identifying disposal site). The derelict \essel number. when possible. must appear in all photographs. The Contractor will be responsible for the camera. rilm. and development costs. The photographs should be taken with a Polaroid camera that provides instant photos since this minimizes loss of documentation due to camera malfunction or loss overboard. This photos must be submitted on a vessel by to document the removal and disposal of the contracted vessels final paYIIlent can not be assured. The Contractor must notit~' the Florida Marine Patrol and the County Representative in writing as to the work schedule of removal. This should be done after the pre-work conference with the County representative. :.rotification is to be made before doing any work on each vessel. This multiparty communication for each Derelict Vessel is a requirement of the contract. ""l'") PA Y\-lENT: All payments for the removal and disposal of each vesseL shall be for the performance of the work as stipulated in these specifications and associated contractual documents. The unit rate of bid shall be totally inclusive for all phases of the operation. The Contractor may request two panial payments by submitting an invoice for the number of \'essels removed up to the date of the invoice. providing the Contract agreement does not explicitly prohibit partial payments. Photographs. disposal receipts. and signed FDEP Disposition Cenification form for the vessels for which payment is being requested. The Contractor understands and agrees that no payment will be forthcoming for the removal and disposal of any derelict vessel (1) not listed on this contract nor (2) for any derelict vessel on this contract for which a written certification verifying the -~mo\':J.l of the subiect '.essel ;;JS not been \IbtJined from the Fl,'ri(iJ \brine PJtfol Jnd a Representative of the disposal site at the time of delivery. In addition. property. public or private. if damaged during the work or removed for the convenience of the work. shall be replaced at the expense of the Contractor in a manner acceptable to the County and the Owner. prior to the final payment for contracted work. 23. NON-COLLISION AFFIDAVIT: Upon entering into the contract, the Contractor agrees to sign and endorse the Non-Collusion Affidavit form (attached). 24, ETHICS CLAUSE: Upon entering into the contract. the Contractor agrees to sign and endorse the Ethics Clause form (attached). 25. DRUG FREE WORK PLACE FORM: Upon entering the contract. Contractor agrees to sign and endorse the Drug Free Work Place form (attached). q :=-...;m.u:. .:. :- _ .'G6 Edition :\10;\'ROE COU~TY, FLORIDA INSl;RANCE CHECKLIST FOR \T;\'DORS SUBMITTING PROPOSALS FOR \VORK To assist in the development of your proposal, the insurance coverages marked with an "X" will be required iri the event an award is made to your firm. Please review this form \vith your insurance agent and have him/her sign it in the place provided. It is also required L~at the bidder sign the form and submit it with each proposal. WORKERS' COMPENSA nON AND EMPLOYERS'LIABILITY WC1 WC2 WC3 WCUSLH x x Workers' Compensation Employers Liability Employers Liability Employers Liability US Longshoremen & Harbor Workers Act Federal Jones Act Statutory Limits $100,000/$500,000/$100,000 $500,000/$500,000/$500,000 S 1 ,000,000/$1 ,000,000/$ 1 ,000,000 Same as Employers' Liability Same as Employers' Liability WClA x INSCKLST 1 ".lIl1l(lI'.!rallOn InstruCllon :: ~ ~n(1 ~ :J'.;A r:C:ltIOn \s a minimum. the required general liability coverages \vill include: \.:E~<E~,-\L ~:;\8IL~~~1' Premises Operations · Blanket Contractual · Expanded Definition of Property Damage Required Limits: GL1 x GL2 GL3 GL4 Required Endorsement: GLXCU GLLIQ _.L....... PrOQucts and Comoleted Operations Personal InJury' . S 1 00.000 per Person: S300,000 per Occ'J...-rc:--.cc S50,000 Property Dan1age or S300,000 Combined Single Limit S250.000 per Person; $500,000 per Occurrence S50,000 Property Damage or 5500,000 Combined Single Limit $500,000 per Person; $1 ,ooo,oqo per Occurrence $100.000 Property Damage or S 1 ,000,000 Combined Single Limit $5,000,000 Combined Single Limit Underground, Explosion and Collapse (XCU) Liquor Liability SecurItv Services All endorsements are required to have the same limits as the basic policy. .\llrn"\I'lr~ll()n InSlructton "~cn'l , lNSCKLST 2 ;G~ [~'ltOn :\5 a minImum, coverage should extend to liability for: ':E;-{ICI-~ I I..~BIL~-~.'~. ()wned: Non-o\\'Tlec: ::L'lO Hired \'ehicles ReqUtred Limits: VLl x ':L:. VL3 VL4 BR1 MVC PROl PR02 PR03 POLl POL2 POL3 ED1 ED2 x GKl (Jr~ GK2 WLl x \dnlil1l<,lrallon InstructIOn ~ ~ -; {\'J ~ S50.000 per Person: $100,000 per Occurrence $25,000 Property Damage or S 100.000 Combined Single Limit S 1 00.000 per Person; $300,000 per OccuITence 550,000 Property Damage or $300.000 Combined Single Limit $500.000 per Person; $1,000,000 per Occurrence S I 00.000 Property Damage or $1,000,000 Combined Single L.imit S5,000,000 Combined Single LiI!).it \1TSCELLANEOUS COVERAGES Builders' Risk Limits equal to the completed project. Motor Truck Limits equal to the maximum , 'alu" 0'- ..,-.. .'-" .-'- :_~"'_. \ ........ ........... 4.' - ~."- ..... ~ ;--.............ll..a CafC0 Professional Liability $ 250,000 per Occurrence/$ 500,000 Agg. $ 500,000 per Occurrence/$l ,000,000 Agg. $1,000,000 per Occurrence/$2,000,000 Agg. $ 500,000 per Occurrence/$ I ,000,000 Agg. $1,000,000 per Occurrence/$2,000,000 Agg. $5,000,000 per Occurrence/$l 0,000,000 Agg. $ 10,000 $ I 00,000 Pollution Liability Employee Dishonesty Garagc Kecpcrs $ 300,000 ($ 25.000 per Veh) $ 500,000 ($100.000 pcr Veh) $1,000,000 ($250,000 pcr Vch) Watercraft Liability $500,000 rNSCKLST 3 ')Q6 Ec,~lon .:< ~: . ?~.\>~. (~= .\G E~<T5 ~ 7 ~J..~=~' fE~<T I have reviewed the Jbove requirements with the bidder named below, The following deductibles Jppiy to the corresponding policy. roue;' DEDliCTIBLES Liability policies are Occurrence Claims Made Insurance Agency Signature BIDDERS STA TEMENT I understand the insurance that will be mandatory if awarded the contract and will comply in full with all the requirements. Bidder Signature INSCKLST 4 .\dmlnl'>1ratlon Instruction "4709 ~ QQ6 EdlllOn WORKERS' C01\1rE~':'AfIO.'\C I:\1SURANCE REQUlRE!\lE.'\CTS FOR CONTRACT IJET\VEEN \10NROE COUNTY, FLORIDA AND Prior to the commencement of work covemed bv this contract. the Contractor shall obtain \Vorkers' Compensation Insurance \l.lth limits sufficient to respond to Florida Statute 440. In addition, the Contractor shall obtain Employers' Liability Insurance \l.ith limits of not less than: S 1 00,000 Bodily Injury by Accident S500,000 Bodily Injury by Disease, policy limits $100,000 Bodily Injury by Disease, each employee . Coveral2e shall be maintained throUl!hout the entire term of th"e contract. ~ ~ Coverage shall be provided by a company or companies authorized to transact business in the state of Florida. If the Contractor has been approved by the Florida's Department of Labor, as an authorized self- insurer, the County shall recognize and honor the Contractor's status. The Contractor may be required to submit a Letter of Authorization issued by the Department of Labor and a Certificate of Insurance, providing details on the Contractor's Excess Insurance Program. If the Contractor participates in a self-insurance fund. a Certificate ofInsurance will be required. In addition. L~e COr1t:-3c:or m3V be rec:ui:-eci to sUDmll u:JCiJ.teci financial statements from the fund upon request from the County'-' . wel \JrnlnlSlrallon InSlrUC\l<H1 ~~:n(): )Qf, EClllOn ",\ ORKERS' CO~lrL~:;A TIO:~ I~SURANCE REQUIREMENTS FOR CONTRA.CT BET\VEEN \10NROE COUNTY, FLORIDA AND Recognizing that the work governed by this contract involves Maritime Operations, the Contractor's Workers' Compensation Insurance Policy shall include coverage for claims subject to the Federal Jones .-\ct (46 U .S.C.A. subsection 688) with limits not less than those specified for Employer's Liability. The Contractor shall be permitted to provide Jones Act Coverage through a separate Protection and Indemnity Policy, in so far as the coverage provided is no less restrictive than would have been provided by a Workers' Compensation policy. .' \VeJA \drnlf1I',:rJI"m Instruction c ~ ;(!() ~ ,Q6 [=:110n GC\ER,A,L LrAI3lJ~-T''' L\'SURANCE REQUIRL\lE~TS FOR CONTRACT I3ET\VEEN \10NROE COUNTY, FLORIDA AND Prior to the commencement of work Qo\'emed bv this contract. the Contractor shall obtain (reneral Liability Insurance. Coverage shall be T"TIaintained throughout the life of the contract and Inciude, as a minimum: · Premises Operations · Products and Completed Operations · Blanket Contractual Liability · Personal Injury Liability · Expanded Definition of Property Damage The minimum limits acceptable shall be: -' $300,000 Combined Single Limit (CSL) If split limits are provided, the minimum limits acceptable shall be: $100,000 per Person $300,000 per Occurrence $ 50,000 Property Damage An Occurrence Form policy is preferred. If coverage is provided on a Claims Made policy, its provisions should include coverage for claims filed on or after the effective date of this contract. In addition, the period for which claims may be reported s~o:.::-::: extend for a minimum of nveive ' : 2) months follO\.ving the acceptance of work by the County. The Monroe County Board of County Commissioners shall be named as Additional Insured on all policies issued to satisfy the above requirements. GLI \dmlnlstrallon Instrucllon "~"()<J 2 J', : .-.:; ~ I, ,n "' EIIICLE Ll:\BILl~-1 I~SLRA..\CE REQl;IRE\lE~TS FOR CO:\TTR-\CT BET\VEEN \10~'iROE COUNTY, FLORlDA AND Recognizing that the \\"ork governed by this contract requires the use or \"erucles. the Contractor. prior to the commencement of work. shail obtain Vehicle Liabiiity Insurance. Covera2:e shall be maintained throughout the life of the contract and include, as a minimum. liability coverage for: · Ov.l1ed, N on-O\\l1ed. and Hired Vehicles The minimum limits acceptable shall be: S 1 00,000 Combined Single Limit (CSL) .' If split limits are provided. the minimum limits acceptable shall be: S 50,000 per Person S 1 00,000 per Occurrence S 25,000 Propeny Damage The Monroe Countv Board of Count\' Commissioners shall be named as Additional Insured on all policies issued to satisfy the above requirements. \'U \dn)lfll~lr;lll(lfl lllstructlofl "~~(I'i = ") ~Q~ Edition POLLUTION LIABILITY INSURANCE REQUIRE~IE~TS FOR CO;\TTR.\CT BET\VEEN \10~ROE COUNTY, FLORIDA Al'ID Recognizing that the v..'ork governed by this contract involves the storage, treatment. processing, Clr transponing of hazardous materials (as detIned by the Federal Environmental Protection :\gency), the Contractor shall purchase and maintain, throughout the life of the contract. Pollution Liability Insurance which v,'ill respond to bodily injury. property damage, and environmental damage caused by a pollution incident. The minimum limits or liability shall be: S500.000 per Occurrence/$l.OOO,OOO Aggregate If co\'erage is provided on a claims made basis. a11 exterlded claims reponing period or four (4) years will be required. rOll ~T, T~:~-."-:l:] :-'L :~...;~rUCll()r. ::~ ~(iq =- -I . ~. i .,; ,qln \". .'\ T ERe R..,\. fT L 1.-\ 13 r LlJ.\ I:\"SCRAI\CE REQUIRE~('f::'n:) fOR CONTRACT I3ET\VEEN MONROE COUNTY, fLORIDA AND ?nor to the commencement of work governed by this contract, the Contractor shall obtain Water Craft Liability Insurance with terms no less restrictive than those found in the standard "American Institute Hull Clauses" (June 2, 1977 edition). Coverage shall be maintained throughout the life of the contract and include, as a minimum: · Injury (including death) to any Person Damage to Fixed or Movable Objects · Costs Associated with the Removal of \Vrecked Vessels · Contractual Liability with Respect to this Contract I[the policy obtained states that coverage applies for the "Acts..or Omissions of a Vessel", it shall be endorsed to provide coverage for the legal liability of the shipov,ner. The minimum limits acceptable shall be: $500,000 Combined Single Limit (CSL) Coverage provided by a Protection and Indemnity Club (P&I) shall be subject to the approval of the County. The Monroe County Board of County Commissioners shall be named as Additional Insured on all polides issued to satisfy the above requirements. \\ILl ^,drnlnl~lrallo)ll l,l',If\Jctlon ~ 4 709 ~ I..-...L...I...cllL-T+: _'Od~ wl..JUCV';.M.~ ACORD". CERTIFICA. TE OF LIABILITY INSURANCE f'ROOlCER .=t::;.rkweather J? .:::;. Box 549 Providence, 5c Shepley, DATE ,\I\\;OO/YY) 03/17/00 TIllS CERTIFICATE IS ISSUED -\.S ..\. "IATTER OF 1"'FOR1\tATIO~ ONL Y \.!'iD CONFERS "0 RIGHTS l1'ON TIlE CERTIFICA TE HOLDER. TIllS CERTIFICATE DOES :\"OT A."'-tEND. EXTE:-.n ()I. ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. RI 02901 INSURERS AFFORDING COVERAGE I...SlREO Blue Water Cape. Cole 16015 S.W. Homestead, COVERAGES Marine Services Murray 298 Terrace FL 33033 f,"SURER A: NEW HAMPSHIRE INSURANCE I,"SURER B: !,"SURER C: INSURER D: INSURER E: THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWlTHSTANDl~ ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED ( ~ Y PERT AlN. THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS. EXCLUSIONS AND CONDITIONS OF sue POLICIES. AGGREGATE LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. :1~fRR TYPE OF I...SVRA'iCE POLICy...l\IBER POLICY EFFECTIVE POLICY EXPIRATlO...... . . OATE <MMIDOIYY) OATE (\IMIDOIYY) r A ';E...ERALLlABILITY GL6082267 12/20/99 12/20/00 LI\IlTS CLAIMS MADE OCCUR i:.\CH occ'R.~~c~_____~$.l, LO_O_O J. 0 C F..IRE[)."~",G~ .!AnY~~.'ire.I_ ..~ 5 Q.LQ9 0 \lED E2'P_(Any o.""yerso~_~5 LQ QO. PERSONAL & ADV INJURY $ ~Q.Q Q. LOC 9E'ERAL AGG_R~~~_. ~$_~ 009 J _QC PROlJ.UC~. CO_MP/OP AGG ~.l _OQ9 ,-0_ 0 COM MERClALGE!\ERALLIAB ILITY GE...1. AGGREGATE LIMIT APPLIES PER: PRO. JECT ?OLlCY LOC Al TO\IOBILE LIABILITY .ANY AUTO ALL OWNED AUTOS 'rIlEDU.ED A\.'TOS :nRED .\C TOS 5~S Q(J{Jf;~ y uy'~~.~":'. . '. .....'l;r ~_." J \ ~.'~ .~~ ()( ~~iH!t.._ ~ CO~BI"ED SINGLE LIMIT \ Ea accident) BODILY I"JURY {Per personl "ODIL Y I:\Jl RY ,Per accl~nt) W!,,'VfR: c~.' ..L vr<; PROPERTY DAMAGE Per acc:ueno ~ON.OW"ED AL:TOS GARAGE LIABILITY ANY AUTO AUTO ONLY. EA ACCIDENT S -- -~~----------- OTHER THAN Al TO ONLY: EA ACC S ~--------- AGG S EXCESS LIABILITY EACH OCCURRENCE OCCUR CLAIMS MADE AGGREGATE S ._---~--~----_._-- " ETESTION A OTHUp & I i CV3 030352 -13 721 WC STATU- OTH. .I.QRYJ..LMlIS.. _.-J;JL _ _. __. . E.L. EACH ACCIDENT $ E.L. DISEASE . EA EMPLOYEE! S : E.L. DISEASE . POLICY LIMIT' S !12/20/99i12/20/00 $500,000 I WORKERS COMPENSATION AND EMPLOYERS' LIABILITY DESCRIPTIO:'o. OF OPERA nONS/LOCATIONSIYEHICLES/EXCLUSIOI'S ADDED 8Y ENDORSEMENT/SPECIAL PROVISIO:'o.S CERTIFICATE HOLDER LISTED BELOW IS NAMED AS ADDITIONAL INSURED AS RESPECTS CERTIFlCA TE HOLDER ADDmoNALr<SLRED'INSLRER LEITER: CANCELLATION Monroe County Board of Comm. Attn: Ms. Kim McGee 5100 College Road Key West, FL 33040 SHOUlD ANYOF11iEABOVE DESCRDlEO POIXIES BECANCEULD BEFORE 11iEEXPlRAllClI' OATE THEREOF, THE ISSUING INSURER WILL ENDEAVOR TOMAIL10 IlAYS WRIITI:" \CORD 25-S (7197) 1 0 f 2 #S10316/M10314 NOTICETOllIE CERT!i'ICAn: HOUlERNAMF.1l TOnIE LEFT. 8UTFAIU;RE m 1l0S0SIIALL \TA!'VY' ,. ,.. 1M POS E "008 LIG An6~ \jIH.."IA1J ILl!"\' OF AN Y KJNptjpO:Q""11fElJNS CRER.ITS AG E....r'i OR . rNSUiUh!-' , . .' '-' '. . REPRESENTATIVES. ,,'r:'''''.', ,::,,;,,;'r: [;',~( I ALTIIORIZED REPRESE!';T,\ vt , -" /-' I /J~~...:- "-J SLN /(1A.CORDCORPORATIO:>lI'