Item B13BOARD OF COUNTY COMMISSIONERS
AGENDA ITEM SUMMARY
Meeting Date: 08-17-00 Division: Growth Management
Bulk Item: YES X NO Department: Marine Resources
AGENDA ITEM WORDING: Approval of the Resolution and the Contract Agreement
between Monroe County and Blue Water Marine, Inc. for the emergency removal of
DV3A3163, located off of Duck Key, Monroe County.
ITEM: The Florida Marine Patrol has requested immediate removal of this vessel due
to it posing a serious threat to navigation. Two proposals received, A.S.A.P., Inc.-
$56,300.00, and Blue Water Marine, Inc.-$12,987.50.
PREVIOUS RELEVANT BOCC ACTION: None
STAFF RECOMMENDATION: Approval
TOTAL COST: $12,987.50 BUDGETED: Yes
COST TO COUNTY: Staff Time Only BIF
REVENUE PRODUCING: YES NO X AMT. PER MO. YEAR
APPROVED BY:COATTY X OMB/PURC X RISKMANAGEMENT XO1 -
n A .A
DEPARTMENT HEAD APPROVAL:
DIVISION DIRECTOR APPROVAL:
Timothy J. D
DOCUMENTATION: INCLUDED: X TO FO
DISPOSITION:
, Marine Resources
, Growth Management
JW:_ NOT REQUIRED:
AGENDA ITEM #AI-7�NJ3
MONROE COUNTY BOARD OF COUNTY COMMISSIONERS
CONTRACT SUMMARY
Contract //
Contract with: Blue Water Marine, Inc. Effective Date:_/_/_
Expiration Date:—/—/_
Contract Purpose/Description: Emergency removal of DV3A3163
Contract Manager: Rim McGee
(Name)
for BOCC meeting on 8 ./ 17 / 00
4511 Marine Proiects
(Ext.) (Department)
Agenda Deadline: 7 / 31 / 00 crt
CONTRACT COSTS
Total Dollar Value of Contract: $ 12.987.50 Current Year Portion: $ 12,987.50
Budgeted? Yes No Account Codes: NEW - - - -
Grant: $ 12,987.50 (BIF) /LS - -5-3634(Q -
County Match: $ N/A _ _ _
ADDITIONAL COSTS
Estimated Ongoing Costs: $ /yr For:
(Not included in dollar value above) (eg. maintenance, utilities, janitorial, salaries, etc.)
Division Director
ROVsknag�me�nt
Pirsehang
County Attorney
Comments :
CONTRACT REVIEW
Char
Date In Nee(
Yes
—7/jL/cr) ( )
OMB Form Revised 8/30/95 MCP #2
Date Out
2-i - �_ 0 f_1
Growth Management Division
RESOLUTION NO. 2000
RESOLUTION OF THE BOARD OF COUNTY COMMISSIONERS OF MONROE
COUNTY, FLORIDA, AUTHORIZING AN ALLOCATION FROM THE BOATING
IMPROVEMENT FUND FOR THE EMERGENCY REMOVAL OF DV3A3163
LOCATED OFF OF DUCK KEY, MONROE COUNTY.
BE IT RESOLVED, by the Board of County Commissioners of Monroe County,
Florida, as follows:
1. That said Board has been notified of the availability of funds from the Monroe
County Boating Improvement Fund for the Emergency removal of DV03A3163
located off of Duck Key, Monroe County.
2. That the Growth Management Division, Marine Resources -Marine Projects
Section acting for Monroe County has determined the eligibility of this project
for the use of Boating Improvement Funds in the amount of $12,987.50.
3. That said Board hereby directs the implementation of this project by the Marine
Projects Coordinator.
PASSED AND ADOPTED by the Board of County Commissioners of Monroe
County, Florida, at a regular meeting of said Board held on day of
A.D., 2000.
(Seal)
Attest:
MAYOR Shirley Freeman
COMMISSIONER Wilhelmina Harvey
COMMISSIONER George Neugent
COMMISSIONER Nora Williams
COMMISSIONER Mary Kay Reich
Clerk
BOARD OF COUNTY COMMISSIONERS
OF MONROE COUNTY, FLORIDA
BY:
MAYOR/ COMMISSIONERS
A PRO ALSUFT O FORM
B
ROB T ,
DATE
Florida Fish and Wildlife Conservation Commission
James L. "J » Adams, Jr. Barbara C. $crab Quinton L. Hedppah' DDS
J:��r.
David K. Meehan Jobe K. Mae
St. Petsrsburt Sarasota
ALLAN L. EGBERT, Phm., Eseeativa Diraeor
V=OR L WMIJIM, ydeam X=cutift DhVetor
July 13, 2000
Mrs. Kim McGee
Monroe County Derelict Vessel Removal Program
Stock island, FL 33040
Dear Mrs. McGee:
Tony Moss
Miami
H.A. "Hertq" Huffman 'mamas E. Kibler
P. Robarts, DC Jobe D. Rood
Ptoneela JadnonvIlle
DIVISION OF LAW ENFOACEMM
COLONEL ROERRT L. EDWARDB, Director
L. COLONEL RANDY 80PKIM, AssiN= Director
as South Maiam &red
Tan base. FL 3MW1W
www.cat&d.=/twe
(MA8it-251
On October 30'a, 1999 a House on a barge owned by Mr. Robert E. Reckwerdt of Key West, FL sank near Channel
Key Pass off of Long Key, FL. All attempts to have Mr. Reckwerdt remove his barge with auached house have failed.
This barge constitutes a severe navigation and we request emergency removal of said barge. On the 2r of March a
40h commercial fishing vessel struck the barge an house causing an estimated S600 damage to the fishing vessel. Your
help in this Inatter would be greatly appreciated.
Sincerely yours,
Lieutenant Robert G. Cu
Via Major M. 3. Long
FWC / Bureau of Marine Enforcement
District Three A
2796 Overseas Highway Suite 100
Marathon, Florida 33050
A.SJLP INC.
MARDIE CONTRACKPRS
P.O. BOX 904
TAVSRNIM FL. 33WM
715-Z000
Mi0■l+00 commy 1VMsrim Projeew
AdadoA Kimm
Job~ D► 3A-3103
PAMU"d and Di powi- S66,.300.00
AS". MC
rises"
Blue Water Marine, Inc.
d/b/a
TowBOAT/U.S. South bade
PO BOX 901716
Homestead, Florida 33090-1716
Phone / Fax (305) 230-0030
QUOTATION
July 17, 2000
TO: Kim McGee
FROM: Blue Water Marine, Inc.
SUBJ: Removal of DV-3163
The following quotation is for the removal of DV-3163, a 30' steel
and wood houseboat located 2 nines North of duck Key by Channel Key
Pars. DV-3163 can be removed and disposed of for tho mum of $12,987.50.
Blue Water Marine, Inc. understands it is responsible for all disposal costs.
Respectfully Submitted,
Capt. Todd Seeds
Blue Water Marine, Inc.
CONTRACT AGREEMENT
AGREEMENT, MADE THIS day of 2000, by and
between, Blue Water Marine, Inc. ("Contractor"), and the BOARD OF
COUNTY COMMISSIONERS OF MONROE COUNTY, FLORIDA, of the County of
Monroe, State of Florida ("Board").
The Contractor and the Board, for the consideration named agree as follows:
1. The Contractor shall furnish all the materials and perform all the work as
required by the Specifications for the emergency removal of DV3A3163 for
which a Florida Marine Patrol Derelict Vessel Report is attached as Exhibit A.
2. The work to be performed under this contract must be completed by August 31,
3. The Contractor understands the rules of the Florida Department of Environmental
Protection Boating Improvement Fund and shall comply with those rules, along with the rules
and procedures instituted by the Board to ensure an orderly progress to the project. Both the
intent and the requirements of the Specifications, attached as Exhibit B, are understood by the
Contractor.
4. The Board shall pay the Contractor $ 12,987.50 for the removal and legal disposal of
DV3A3163. Payment will be upon completion of work by the Contractor and review and
approval by the Marine Projects Coordinator. No Change Orders allowed.
5. The attached Derelict Vessel Reports, Specifications, and the Monroe County Insurance
Requirements together with this Agreement, form the Contract. They are fully a part of this
Contract as if repeated herein verbatim.
6. The Contractor covenants and agrees to indemnify and hold harmless the Monroe
County Board of County Commissioners from any and all claims for bodily injury (including
1
other losses, damages, and expenses (including attorney's fees) which arise out of, in
connection with, or by reason of services provided by the Contractor or any of its
Subcontractor (s) in any tier, their employees or agents. The purchase of the insurance
required in paragraph 11 does not vitiate this indemnification provision.
7. The Contractor agrees to supply the County with a set of photographs of each vessel in
all phases of the removal and disposal process. The Contractor will be responsible for the
camera, film, and development costs.
8. The Contractor must inform the County and the Florida Marine Patrol prior to initiation
of work.
9. The parties agree that a timely performance of this agreement is essential due to possible
damage to the natural resources, hazards to navigation, or threats to human health and welfare.
Therefore, the parties agree that the Contractor shall be liable to the Board for $100 per day of
liquidated damages for each day after 8-31-00 that the Contractor's obligations under this
agreement remain unperformed. The parties agree that such amount is by the way of
compensatory damages and does not constitute a penalty.
10. Due to the use of heavy equipment and, at times, dangerous work environment, the
Contractor understands and agrees to maintain an alcohol an drug free work environment.
11. The Contractor will be responsible for all necessary insurance coverage as indicated by
an "X" on the attached forms identified as INSCKLST 1-4, as further detailed on forms VL1,
WC1, WCJA, GL1, WL1, & POL1 attached as Exhibit C. All policies must list Monroe
County as additional insured with the exception of the Worker's Compensation policy.
12. The Contractor warrants that it has not employed, retained or otherwise had act on its
behalf any former County officer or employee subject to the prohibition of Section 2 of
Ordinance No. 010-1990 or any County officer or employee in violation of Section 3 of
Ordinance No. 020-1990. For breach or violation of this provision, the owner may, in its
2
discretion, terminate this contract without liability and may also, in its discretion, deduct from
the contract or purchase price, or otherwise recover the full amount of any fee, commission,
percentage, gift, or consideration paid to the former County officer or employee.
13. A person or affiliate who has been placed on the convicted vendor list following a
conviction for public entity crime may not submit a bid on a contract to provide any goods or
services to a public entity, may not submit a bid on a contract with a public entity for the
construction or repair of a public building or public work, may not submit bids on leases of real
property to public entity, may not perform work as a contractor, supplier, subcontractor, or
consultant under a contract with any public entity, and may not transact business with any
public entity in excess of the threshold amount provided in Section 287.017 of the Florida
Statutes, for CATEGORY TWO for a period of 36 months from the date of being placed on the
convicted vendor list.
IN WITNESS WHEREOF each party hereto have executed this Agreement the day and
year first written above.
(SEAL)
Attest: DANNY L. KOLHAGE, CLERK
0
Deputy Clerk
Witness:
Witness:
APPROVED A5 TO FC);rn
AN l SUFFIC y, r
i
B
ROBERT N. Wp
DATE T , _
BOARD OF COUNTY COMMISSIONERS
OF MONROE COUNTY, FLORIDA
By: '
Mayor/Chairman
Busines ame: V 14
By:
Title:!1����
3
KAHIBIl A w, A c.
DERELICT VESSEL 3A-
IIlgCIDENT NO.00-3A- t 3(b
1. REG/DOC#:- ✓F LENGTH: -�Q FT. J✓�A- TYPE: r [
HULL MATERIAL: WOOD F/G METAL(sPrc;n&Ll' RUBBER OTHER (sPEclry)
COLOR: -. MOTOR ATTACHED: YES NO_XTYPE H.I.N.:
NAME ON VESSEL: wove OTHER IDENTIFIERS; 'f ALIEN:
2. VESSEL
CITY/STATE/ZIP:
3. PHYSICAL LOCATION OF DV: ,h - Oe4!
LATITUDE/LONGTTUDE (DEGREES, MINUTES, SECO S) /V. :2 y
4. CONDITION: WRECKED JUNKED DISMANTLED ABANDONED_ AGROUND h
BROKEN UP BURNED CAPSIZED LISTING SCUTTLED
5. SUBMERGED: 1-5- % DEPTH;-Z&_FT. ANCHORED DOCKED AFLOAT ADRIFT
IN WETLANDS TIED TO OBJECT(sPECnrn MARKED WITH BUOY
WASHED ASHORE BELOW M.H.W.L. ABOVE M.H.W.L. OTI-fER
6. CAUSE: UNK_ NATURAL DISASTER_ OTHER (EXPLAIN) $'unk A'
7. PROPERTY OWNER: STATE SUBMERGED LANDS FEDERAL PROPERTY A OTHER (sPl:cn-,Y)
OWNER/ADDRESS g4&4-P aj_j..,.r,,,,j /,%,j -- .-�-_ / All _. _ 0
& THREAT TO NAVIGATION: YES •, NO UNK HOW Pp r- G f r
9. DANGER TO ENVIRONMENT. YES NO UNK HOW a0— S
10. TOWED WITHOUT REPAIR: YES_ NO UNI _ OTHER
11. RECOMMENDED DISPOSITION: LEAVE AS IS TAKE TO LANDFILL RECYCLE METAL
HAVE THE OWNER/CUSTODIAN REMOVE IT TURN OVER TO ANOTHER AGENCY
MARINE HABITAT/ARTIFICIAL REEF OTHER < 4c r r
12. NARRATIVE / DILIGENT SEARI H: (71L Auk
- LA tyt4 tdlll aft [ GrG)e S'CI� .n /�.n /A, .2�,.--AG /�
13. REPORTING AGENCY: F.W.C.C--4 U.S.C.G._ N.P.S._ U.S.F.W.S. US-B.P._ S.O._ OTHER
14. DV #PAINTED ON VESSEL: NOTICE DECAL PLACED ON DV: 4 DV PHOTOS INCLUDED: k
Officer(3) Reporting8� (P� .0 print) sZ Dmte & ^'%00
Rodawod By.
LnV oo6mme. sig.u.
( k cRlL-ft- *340
FWCC 20-045A (1/00) V.1_
Reviewer's sign
,Zr- Al,
Date Report I OBIS Number
complded 467. *O
Page 1 of 3
Original
supplement
LwCIDENT REPORT NARRATIVE CONTINUATION
ZONE:
DERELICT VESSEL
AVO 3,4- 3/0
�- •o co f- 3/9 -13 60
• offi— (pint) om=.s s4pud m; Dsto
Rcvkw By: Revicwds Sigustum Data
FWCC 20-045A (9/99) VL Page 2 of 3 41P,
0
O Q O�9 8 8
C=� � S
v Sq. g
8
C
S2. 8
6
S
7 7
7 7 7
9
8
rky 9 8 S 8
9
�10 9 to ` 1 1^�
10 ��11 9 9
O
9 CO S
9 CO A 8 C�4R
9 8 fie!
9 i0 /see 1104
10
S 10 ? a
10
1 H 8
9
'p 9•
rky 8 9 rky 10
10 10 9
i 9 7 '�I G 4s 16ft "9'• 9
9 5 1 9 9 ei
9 Co �aNr 1�'\
8 7 f G 8 7 4e 8
8 8
7 Grs 8
0{ s �4
9 e Gr
8 rky 5 7 1 �0
9 8 1 7
5 6
8 5 7= 4 8 % Piles e 6 4 1
O
4 � I
6 5 1 t 1 8 7 rky i° 4
PA ! 5 4 6 8 7 SOPole
s 7
1 � r PA � 7 7 °
I �"OR Ij(E�L am 41 � f 5 9 4 7 8
vfnrcc jrr i--� 1 5 5
rr ' " / Poles
ne� 3 0 8 ° °o�ie-s-7-- 8 ? ° 4 6 7 \
Ci n 1 6� 3 17 7 �-
��
LJUUK K
4 Q - IF:Y �►
2 v nil 3 7 S 5
3 two note
PWR CAB �0 4 4
12 10 6 2 5 8 5
4 / 8 7
13 12 10 •i•�;
r R 4 '.: 7 9
11
S Fl 43 3M +2+ 6 rky
Priv 11 11 10 14
v, 12 ° 11
7 rky 7
8 7
7 7
7
7 6 5
7 5
Grs /
8 7 7 4 6l
a / 7 A'4"
8
G 43 16ft 4M •5• 9 8
9
10 9
T 10
Ip
10
10 10
� 11
10
IC
8
10 10
Gr
10
9 hrd hrd S
8
9 Ppe 7 8
Kt,v Banks7P: 9
7 6 O 9 ri, ° \\v 8 Pipe
7 I `•• e
r'ekers°O
'
Q PilF+i 1 9 Q 11
4
8 5
OL Conch l�r•v o I
L'Vti 0 4. 0 14 7
°
1
C�5 3 g 5 5
6 9 13 9
7 4
7
CO 1 12
j Progs y 8
7 8 10
rky 5 8
10 10
10 8 10 IS
EXHIBIT B
DERELICT VESSEL REMOVAL CONTRACT SPECIFICATIONS
FOR MONROE COUNTY, FLORIDA
INTENT: It is intended that these specifications shall cover all aspects of the work.
The purpose of this section is to provide specific conditions applicable to this
contract where such coverage is not provided in other portions of the documents.
BID FORMAT: A dollar amount per foot must be submitted for the removal of as
many derelict vessels on the primary list for which a Florida Marine Patrol Derelict
Vessel Report is provided and as funding will allow. Any deviation from this
format will result in an unaccented bid. A contract will not be granted on the basis
of combined, related, linked, or discounted bids. Not applicable due to emergency
removal of one or more derelict vessels for less than $25,000 total.
PLANS: There are no plans for this project, but copies of the Florida Marine
Patrol Derelict Vessel Report with location sketches have been bound into these
documents for the Contractor's use. The Specifications include a section on
instructions to bidders, both general and specific, and a copy of each Derelict
Vessel Report from the Florida Marine Patrol. Only those derelict vessels for
which a report is included and listed on the Bid Response Form are to be bid upon
and subsequently removed.
The County reserves the right to remove any or all vessels from this contract at any
time prior to actual removal from the water and disposal by the Contractor.
The County has a limited amount of money to effect the femoval of these derelict
vessels. We have established priorities based on public safety, navigational hazard,
and environmental considerations. If bids exceed the County's resources for
removal based on these considerations, we shall limit vessel removal based on the
considerations and cost effectiveness.
4. VESSEL IDENTIFICATION AND LOCATION: Each of the vessels have been
given a derelict vessel identification number, which is shown with the location in
the Florida Marine Patrol Derelict Vessel Report, included herewith.
Each bidder is responsible for his own identification of each derelict vessel as to
location, description and condition. If a derelict vessel cannot be (1) located, (2)
removed, (3) verified and (4) disposed of, as specified in these procedures, then no
payment will be made forthcoming to the Contractor for that vessel. Those four
conditions must be met on each derelict vessel along with compliance of all laws
for payment to be made. -
It is understood that the Contractor has, by personal examination and inquiry, if
necessary, satisfied himself as to local conditions of each derelict vessel and as to
the meaning, requirements and reservations of the specifications; for after contract
letting, no deviation will be allowed. In case errors are discovered, they are
to be reported by the Contractor to the County. The county assumes no
responsibility should there be any discrepancies in what is stated in these
documents and what the bidder evaluates.
The Contractor should take special care to remove only those derelict vessel's on
his Contract and for which he possesses a Florida Marine Patrol Derelict Vessel
Report. Other derelict vessels in the area but not under Contract, cannot be
molested.
It may be possible to replace a derelict vessel of like kind, for the same or less
money, when mutual agreement can be reached by the Florida Department of
Environmental Protection, Monroe County Administrator of the Derelict Vessel
Program, and the Contractor. This will be applicable when a contracted derelict
vessel cannot be located. No derelict vessel may be replaced and removed without
the tri-party consent noted in this paragraph. A contractor may suggest a possible
replacement vessel but he may not remove it without the appropriate consent above.
5. SCOPE OF WORK: The Contractor shall be responsible for providing all permits,
supervision, labor, equipment, tools, fees and taxes required to complete this
project to the satisfaction of the County.
The Contractor's procedure and methods of removal may be of his own selection
provided they secure results which satisfy the requirements of the Specifications
and any necessary environmental permits.
Any vessel which is removed and disposed of shall be removed from its present site
in such a manner as to do the least possible damage to the natural environment.
All debris from the vessel shall be removed and the site left in a reasonably clean
condition. No oil or fuel shall be permitted to be dumped or spilled into or unto the
water or land. All pollutants shall be removed from the derelict vessel prior to
removal from the water.
The Contractor shall be responsible for making any and all arrangement for access
to the vessel to be removed. If private property has to be traversed, then written
permission of the owner is necessary. In removing a derelict vessel that may lie on
or near grass or sponge flats extreme caution must be used to do the least possible
damage.
2
Prior to delivery of derelict vessels to the disposal site, the Contractor must remove
all oil, gas and engines. He must dispose of them in any legal manner. Pure used
oil will be taken by Monroe County for disposal. Mixture of oil, gas, seawater or
any combination of the three must be transported from the County by an approved
hazardous waste handler. The names of handlers will be supplied by the Monroe
County Solid Waste Department. Metal becomes the property of the Contractor.
6. MATERIALS AND WORKMANSHIP: The Contractor shall provide the
necessary materials and equipment to safely complete the job. The Contractor
agrees that all work shall be performed by competent employees who are
experienced and qualified to do the work specified, and that all work will be
performed in accordance with the best commercial practices. A list of equipment
to be used and a description of the removal and transporting procedures to be
followed must be provided to the County at the pre -work conference described
below.
Precaution shall be exercised at all times for the protection of persons and property.
The safety provisions of the Occupational Safety and Health Act of 1970 (Public
Law 91-596) and other applicable laws, including building and construction codes
shall be observed. Machinery, equipment and other hazards shall be guarded in
accordance with safety provisions of the "Manual of Accident Prevention in
Construction", published by the Associated General Contractors of America, to the
extent that such provisions are not in contradiction of applicable law.
If any property is destroyed by any cause or means whatsoever, the Contractor shall
repair and replace or not receive payment for the unaccomplished work. The
Contractor shall maintain suitable and sufficient guards and barriers, and at night,
suitable and sufficient light or other appropriate security or protection for the
prevention of accidents.
Use of explosives is prohibited in carrying out the project
7. ASSIGNMENT OF CONTRACT AND SUBCONTRACTS: It is expressly
understood that the Contractor is in all respects an independent Contractor for this
work, not withstanding under certain conditions he is bound to follow the
directions of the County, and is in no respect an agent, servant, or employee of the
County. Neither the Contract, nor any part thereof, nor any Moines due or to
become due thereunder, may be assigned by the Contractor without the prior
written approval of the County.
The Contractor is fully responsible to the County for the acts and omissions of his
subcontractors and of persons either directly or indirectly employed by said
subcontractor, as he is for the acts and omissions of persons directly employed by
him. Nothing contained in the relation between any subcontractors shall abide by
the terms, conditions, and requirements of this Contract. It is the responsibility of
the Contractor to pay all debt obligations incurred with subcontractors in an
expedient manner.
8. LEGAL RESTRICTIONS, PERMITS AND TRAFFIC PROVISIONS: The
Contractor shall comply with all applicable local, State and Federal requirements
pertaining to the terms of this Contract. The Contractor will be responsible for
obtaining, at his own expense, any licenses or permits that may be required and
should inquire about permit requirements with the appropriate agencies. The
Contractor shall comply with all the requirements of the Federal Pollution Control
Act.
The Contractor shall conduct his operations so that he shall not close any
thoroughfare nor interfere in any way with traffic on highways, or on water,
without the written consent of the proper authorities. Work shall be done at any
time that shall not interrupt or disturb members of the public.
Utilization of off-loading sites located on private property (water to land for
transport to the landfill or other disposal site by vehicle) must have written
approval of the land owner.
The Florida Marine Patrol should be contacted to initiate eviction proceedings for
contracted derelict vessels which are inhabited at the time of removal and when
another vessel is too close to the contracted derelict vessel to allow safe operations.
Direct confrontations with other boaters should be avoided and the Florida Marine
Patrol should be contacted immediately if such confrontations results from removal
of any contracted derelict vessels.
9. INSURANCE: The Contractor must obtain insurance required by the County and
submit proof of same to the County prior to acceptance of bid and contract approval
by Board of County Commissioners but no later than five working days after notice
of low bidder. All insurance shall be maintained until work has been completed
and accepted by the County.
The Contractor shall furnish the following certificates of insurance for review by
the County's Risk Management Division:
Certificate (s) of Insurance which clearly indicates that he has obtained the
insurance coverage required in paragraphs a,b,c and d below.
4
The Contractor hereby certifies that no modification or change in insurance shall be
made without (10) days written advance notice to MONROE County, c/o the
Director of the Risk Management Division.
a. Worker's Compensation Insurance per Fl. Statutes
b. Federal Jones Act Coverage
C. General Liability Insurance on a comprehensive basis, in an amount not less than
$300,00.00 per occurrence for Bodily Injury and Property Damage combined, to
include contractual liability.
C. Pollution Liability Insurance in the Amount of $500,000.
d. Water Craft Liability Insurance in the Amount of $500,000.
e. Automobile liability insurance covering all owned, non -owned and hired vehicles
used in connection with the work, in an amount not less than
$100,000 per occurrence for Bodily Injury and Property and Damaged combined.
All insurance policies required above shall be issued by companies authorized to do
business under the laws of the state of Florida. The MONROE County Board
of County Commissioners must be listed as "Additional Insured" on all policies,
except for the Worker's Compensation policy.
10. COMMENCEMENT, DELAYS AND COMPLETION OF WORK: After
receiving Board of County Commission approval of the Contract, and after
reconciliation of any details or conditions which may directly or indirectly interfere
or conflict with work of the Contract, the County will issue a "Notice to Proceed"
officially authorizing the Contractor to commence. The Contractor shall
commence work within one week from the date on the "Notice to Proceed" letter.
If the Contractor should be delayed in the progress of the work included in the
Contract by enforceable causes beyond his control, the time for the completion of
the work may be extended upon agreement of the County representative. Requests
for an extension of time must be submitted in writing to the County representative.
Extensions of time cannot legally be approved unless the written request is
submitted in the time to permit it to be acted upon before"the Contract expiration
date. To allow sufficient time for the administrative procedures required to obtain
action by the County Commission, a request for time extension must be received by
the County representative at least sixty (60) calendar days prior to the Contract
expiration date.
Provided further that the Contractor shall within ten (10) days from the beginning
of such delay notify the County, in writing, of the causes of the delay. The County
representative will ascertain the facts and the extent of the delay and notify the
Contractor within a reasonable time of her decision in the matter.
If the Contractor fails to complete the work within the time limit, and if the County
should nevertheless permit the Contractor to continue and complete the same
without official extension of time in writing, such permission shall not modify nor
waive any liability of the Contractor for damages arriving non -completion of work
within the time limit, but such liabilities shall be subject to continuation in full
force against the contractor.
11. CHANGES AND INSPECTION: The vessels herein considered are to be removed
for the County by the Contractor in accordance with the specifications. The County
may give instructions or directions to supplement the specifications. These shall be
binding upon the Contractor and upon all his subcontractors, employees and agents
of every kind.
All work and every process and operation shall be subject to inspection at all
times, and the County and their representatives shall have free access to all aspects
of the work. The Contractor shall remove and make good, as may be directed,
without charge, any defective work. Oversight or error of judgment of
inspections, or previous acceptance, shall not relieve the Contractor from the
obligation to make good any defect whenever discovered.
The right is reserved to change the Specifications consistent with regard to the
general intention of the contract for any part of the work or materials, either before
or after work has begun. Notice of such changes shall be given in writing to the
Contractor; such changes are not to be grounds for any claim by the Contractor for
damages, nor for the forfeiture of the Contract. It is possible that a Derelict Vessel
could disappear between the time of inspection by the contractor and the actual
effort to remove it. No payment will be forthcoming in event that this occurs.
Except when otherwise specified, the expense of all tests requested by the County
will be borne by the County.
12. AUDIT RIGHTS: As a provision of the grant from the State of Florida to the
County, and if so requested by the State, the successful bidder agrees to provide
access to all records and allow the audit of any books, documents and papers
related to this project for a period of up to one year and during and after termination
of the contract.
13. CONTRACT AWARD: The County reserves the right to evaluate the submitted
bids and award a contract to the bidder submitting the lowest per foot bid for the
derelict vessels listed in the bid package as one project and for which a
6
Florida Marine Patrol Derelict Vessel Report is included. One bid will be accepted
and a Contract issued for the total removal of all listed derelict vessels as one
project, up to the limit of available funds.
The actual number of vessels to be removed will depend on the accepted per foot
bid price and the available funds.
14. PREWORK CONFERENCE: A meeting will be necessary involving a
representative of the County, the Contractor and other parties with direct
involvement prior to the signing of the Contract. The time and place of this
conference will be set by the County representative. At this time the Contractor
shall provide the County with a schedule as to the order in which he proposes to
remove the vessels awarded to him.
15. CONTRACT SECURITY: The Contractor is expected to act and deliver in good
faith all work, at the agreed price, in the allowed time. Failure to do so, could
jeopardize the contractor's reputation with the County and potentially influence any
future contracts with MONROE County.
16. EXECUTION OF CONTRACT DOCUMENT: Due to the time frame involved
with this project, the Contractor upon notification that he is to be awarded the
contract documents for execution, shall return said documents properly executed
along with insurance within TEN WORKING DAYS. This will assist in
acceleration of execution of the contract documents.
The Contractor, by virtue of signing the Contract, acknowledges that he and all his
subcontractors have satisfied themselves as to the nature and location of the work,
the general and local conditions, including, but not restricted to, those bearing upon
transportation, handling, access to the pick-up and disposal sites; and the character of equipment and facilities needed to perform the work. Failure on the part of the
Contractor to completely or properly evaluate any factors of his costs prior to
bidding shall not form a basis for additional compensation if he is awarded the
Contract.
If for any reasons, not acceptable to the County, the Contractor does not perform,
the County shall have the right to levy liquidated damages against the Contractor.
Liquidated damages in the amount of $100 per day shall be assessed against the
Contractor for any bid item awarded to him which is not completed and accepted
by the County within the number of calendar days specified in the Contract.
Liquidated damages are accumulative.
17. NOTICE TO PROCEED: The Contractor shall commence work upon this project
within one week of the date of the Notice to Proceed lettdr and perform in a
continuous manner until completion and acceptance by the County. For Contracts
wherein a specified number of days for completion is stated in the Contract, the
effective date of the "Notice to Proceed with Contract Work" will establish the
"beginning date" of the project.
18• TERMINATION OF CONTRACT: This Contract may be terminated by the
County, giving up to ten (10) days written notice to the Contractor; said notice
shall be sufficient if delivered to the party personally or mailed by certified mail to
his mailing address as specified on the accepted bid.
19. FINAL CLEAN-UP: Upon completion of the work specified herein and before
acceptance and final payment shall be made, the Contractor shall remove from the
sites all machinery, equipment, surplus and discarded materials and temporary
structures. The disposal of materials, rubbish and debris shall be made at a legal
disposal site.
20. DISPOSAL SITES AND FEES: The Contractor is responsible for disposal of all
derelict vessels included in this contract and must make arrangements for legal
disposal. It is the responsibility of the Contractor to pay all disposal fees
incurred, and such removal related costs should be considered when bidding on this
contract.
The Contractor will deliver the derelict vessels to a Florida Department of
Environmental Protection permitted disposal site that has current occupational tax
licenses. It is the intent of this contract to remove derelict vessels from their
present site and legally dispose of them. Upon receipt of vessels at the landfill,
they must be disposed of immediately.
There are several Monroe County disposal sites, Cudjoe Landfill, MM 21.5
(vessels must be 26' and under to be delivered in tact, over 26' they must be
broken up), Long Key Landfill MM 68, and Card Sound Road AKA SR905 other
landfills in neighboring countries or any other location for disposal as long as the
site is a legal licensed disposal site. Prior to transportation of vessels out of
County the County representative must approve. Vessels being disposed of at
County Landfill sites must be free of pollutants and engines.
21. PROOF OF PROPER DISPOSAL AND NOTIFICATION TO MARINE
PATROL: Contractor must submit prior to receiving any payment: A receipt for
each vessel including the date of disposal, the Florida Marine Patrol Derelict Vessel
Number, disposal site location, and the telephone number. Recipient of debris
should provide detailed receipt showing type and description of debris received.
In addition to the above information, Contractor must submit three pictures of
each vessel removed. The first photograph must be of the vessel at the current
location prior to removal, the second photograph must be of the vessel after
removal but in the same general area preferably while in tow, and the third
8
photograph must be of the vessel at the disposal site with sufficient background to
depict disposal (i.e., building or sign identifying disposal site). The derelict
vessel number, when possible, must appear in all photographs.
The Contractor will be responsible for the camera, film, and development costs.
The photographs should be taken with a Polaroid camera that provides instant
photos since this minimizes loss of documentation due to camera malfunction or
loss overboard. This photos must be submitted on a vessel by to document the
removal and disposal of the contracted vessels final payment can not be assured.
The Contractor must notify the Florida Marine Patrol and the County
Representative in writing as to the work schedule of removal. This should be done
after the pre -work conference with the County representative. Notification is to be
made before doing any work on each vessel. This multiparty communication for
each Derelict Vessel is a requirement of the contract.
22- PAT: All payments for the removal and disposal of each vessel, shall be
for the performance of the work as stipulated in these specifications and associated
contractual documents. The unit rate of bid shall be totally inclusive for all phases
of the operation. The Contractor may request two partial payments by submitting
an invoice for the number of vessels removed up to the date of the invoice,
Providing the Contract agreement does not explicitly prohibit partial payments.
Photographs, disposal receipts, and signed FDEP Disposition Certification form for
the vessels for which payment is being requested.
The Contractor understands and agrees that no payment will be forthcoming for the
removal and disposal of any derelict vessel (1) not listed on this contract nor (2) for
any derelict vessel on this contract for which a written certification verifying the
removal of the subject vessel has not been obtained from the Florida Marine Patrol
and a Representative of the disposal site at the time of delivery.
In addition, property, public or private, if damaged during the work or removed for
the convenience of the work, shall be replaced at the expense of the Contractor in a
manner acceptable to the County and the Owner, prior torthe final payment for
contracted work.
23. NON -COLLISION AFFIDAVIT: Upon entering into the contract, the Contractor
agrees to sign and endorse the Non -Collusion Affidavit form.
24. ETHICS CLAUSE: Upon entering into the contract, the Contractor agrees to sin n
and endorse the Ethics Clause form. g
25. DRUG FREE WORK PLACE FORM: Upon entering the contract, Contractor
agrees to sign and endorse the Drug Free Work Place form.
9
E%HIBIT C
1996 Edition
MONROE COUNTY, FLORIDA
INSURANCE CHECKLIST
FOR
VENDORS SUBA1I1P ING PROPOSALS
FOR WORK
To assist in the development of your proposal, the insurance coverages marked with an 'X',
be required in the event an award is made to your firm. Please review this form with yowill
ur
insurance agent and have him/her sign it in the place provided. It is also required sign the form and submit it with each proposal. that the bidder
WC1
WC2
WC3
WCUSLH
WCJA
WORKERS' COMPENSATION
ANTD
EMPLOYERS' .IABI 1TY
_..X_Workers' Compensation
x.__ Employers Liability
Employers Liability
Employers Liability
US Longshoremen &
Harbor Workers Act
g Federal Jones Act
Administration Instruction
N4709.2
Statutory Limits
$ 100,000/$500,000/$100,000
$S00,000/$500,000/$500,000
$1,000,000/$1,000,000/$1,000,000
Same as Employers'
Liability
Same as Employers'
Liability
INSCKLST 1
1996 Edition
GENERAL t.tAarr ts-v
As a minimum, the required general liability coverages will include:
• Premises Operations Products and Completed Operations
• Blanket Contractual Personal Injury
• Expanded Definition
of Property Damage
Required Limits:
GL1 g
$100,000 per Person; $300,000 per Occurrence
$50,000 Property Damage
or
$300,000 Combined Single Limit
GL2
$250,000 per Person; $500,000 per Occurrence
$50,000 Property Damage
or
$500,000 Combined Single Limit
GL3
$500,000 per Person; $1,000,OQO per Occurrence
$100,000 Property Damage
or
$1,000,000 Combined Single Limit
GL4
$5,000,000 Combined Single Limit
Required Endorsement:
GLXCU
Underground, Explosion and Collapse (XCU)
GLLIQ
Liquor Liability
GLS
Security Services
All endorsements are required to have the same limits as the basic policy.
INSCKLST 2
Administration Instruction
M4709 2
1"6 Edition
As a minimum, coverage should extend to liability for:
• Owned; Non -owned; and Hired Vehjrles
Required Limits:
VL1 X
$50,000 per Person: $100,000 per Occurrence
$25,000 Property Damage
or
$100,000 Combined Single Limit
VL2
$100,000 per Person; $300,000 per Occurrence
$50,000 Property Damage
or
$300,000 Combined Single Limit
VL3
$500,000 per Person; $1,000,000 per Occurrence
$100,000 Property Damage
or
$1,000,000 Combined Single Limit
VL4
$5,000,000 Combined Single Limit
MIS AN OUS COVpgAGpq
BRl
Builders'
Limits equal to the
Fisk
completed project.
MVC
Motor Truck
Limits equal to the maximum
Cargo
value of any one shipment.
PRO 1
Professional
$ 250,000 per Occurrence/$ 500,000 Agg.
PR03
Liability
$ 500,000 per Occurrence/$1,000,000
Agg.
$1,000,000 per Occurrence/$2,000,000 Agg.
POLI
POL2
X Pollution
$ 500,000 per Occurrence/$1,000,000 Agg.
POL3
Liability
$1,000,000 per Occurrence/S2,000,000 Agg.
$5,000,000 per Occurrence/$10,000,000 Agg.
ED 1
ED2
Employee
000
Disonsty
$100,000
GKI
Garage
Keepers
$ 300,000 ($ 25,000 per Veh)
$
GK3
500,000 ($100,000 per Veh)
Will
$1,000,000 ($250,000 per Veh)
X Watercraft
Liability $500,000
INSCKLST 3
Administration Instruction
#4709 2
1996 Edition
INSURA. - ES S12.TIF-M ENT
I have reviewed the above requirements with the bidder named belw. The following deductibles
apply to the corresponding policy. o
POLICY
U
Liability policies are _ Occurrence _ Claims Made
DEDUCTIBLES
Insurance Agency Signature
Q0 u
I understand the insurance that will be mandatory if awarded the contract and will comply in full
with all the requirements. p y
Bidder
INSCKLST 4
Administration Instruction
#4 709.2
Signature
1996 Edition
NVORKERS' COMPENO-ATION
INSURANCE REQUIREMENTS
FOR
CONTRACT
BETiiVEEN
MONROE COUNTY, FLORIDA
AND
Prior to the commencement of work governed by this contract, the Contractor shall obtain
Workers' Compensation Insurance with limits sufficient to respond to Florida Statute 440.
In addition, the Contractor shall obtain Employers' Liability Insurance it limits of not less
than:
$100,000 Bodily Injury by Accident
$500,000 Bodily Injury by Disease, policy limits
$100,000 Bodily Injury by Disease, each employee
Coverage shall be maintained throughout the entire term of the contract.
Coverage shall be provided by a company or companies
state of Florida. authorized to transact business in the
If the Contractor has been approved by the Florida's Department of Labor, as an authorized self -
insurer, the County shall recognize and honor the Contractor's status. The Contractor may be
required to submit a Letter of Authorization issued by the Department of Labor and a Certificate
of Insurance, providing details on the Contractor's Excess Insurance Program.
If the Contractor participates in a self-insurance fund, a Certificate of Insurance will be required.
In addition, the Contractor may be required to submit updated financial statements from the fund
upon request from the County.
NN'C 1
Administration Instruction
a4709 2
1996 Edition
%'WORKERS' COMr NSATION
INSURANCE REQUIREMENTS
FOR
CONTRACT
BETWEEN
MONROE COUNTY, FLORIDA
AND
Workers' Compensation Insurance Policy shall include coverage
Recognizing that the work governed by this contract involvesMaritime
forlclaims subject to the FedeContractor's
Act (46 U.S.C.A. subsection 688) with limits not less than those specified for Employer's Li bilil Jones
The Contractor shall be permitted to provide Jones Act Coverage through a separate Protection and
Indemnity Policy, in so far as the coverage provided is no less restrictive than would have been rovided
by a Workers' Compensation policy. P
NN'CJA
Adininistraiion Instruction
#4709 2
1996 Edition
GENERAL LIABIL TY
INSURANCE REQUIREMENTS
FOR
CONTRACT
BETWEEN
MONROE COUNTY, FLORIDA
AND
Prior to the commencement of work governed by this contract, the Contractor shall obtain
General Liability Insurance. Coverage shall be maintained throughout the life of the contract and
include, as a minimum:
• Premises Operations
• Products and Completed Operations
• Blanket Contractual Liability
• Personal Injury Liability
• Expanded Definition of Property Damage
The minimum limits acceptable shall be:
$300,000 Combined Single Limit (CSL)
If split limits are provided, the minimum limits acceptable shall be:
$100,000 per Person
$300,000 per Occurrence
$ 50,000 Property Damage
An Occurrence Form policy is preferred. If coverage is provided on a Claims Made policy, its
provisions should include coverage for claims filed on or after the effective date of this contract.
In addition, the period for which claims may be reported should extend for a minimum of twelve
(12) months following the acceptance of work by the County.
The Monroe County Board of County Commissioners shall be named as Additional Insured on
all policies issued to satisfy the above requirements.
GL1
Administration Instruction
N4 709.2
1996 Edition
VEHICLE LIABILIV '
INSURANCE REQUIREMENTS
FOR
CONTRACT
BETWEEN
MONROE COUNTY, FLORIDA
AND
Recognizing that the work governed by this contract requires the use of vehicles, the Contractor,
prior to the commencement of work, shall obtain Vehicle Liability Insurance. Coverage shall be
maintained throughout the life of the contract and include, as a minimum. liability coverage for:
• Owned, Non-O,"med, and Hired Vehicles
The minimum limits acceptable shall be:
$100,000 Combined Single Limit (CSL) •
If split limits are provided, the minimum limits acceptable shall be:
$ 50,000 per Person
$ l 00,000 per Occurrence
$ 25,000 Property Damage
The Monroe County Board of County Commissioners shall be named as Additional Insured on
all policies issued to satisfy the above requirements.
VL1
Administration Instruction
$14 709 2
xo
1996 Edition
POLLUTION LIABILITY
INSURANCE REQUIREMENTS
FOR
CONTRACT
BETWEEN
MONROE COUNTY, FLORIDA
AND
Recognizing that the work governed by this contract involves the storage, treatment, processing,
or transporting of hazardous materials (as defined by the Federal Environmental Protection
Agency), the Contractor shall purchase and maintain, throughout the life of the contract,
Pollution Liability Insurance which will respond to bodily injury, property damage, and
environmental damage caused by a pollution incident.
The minimum limits of liability shall be:
$500,000 per Occurrence/$1,000,000 Aggregate
If coverage is provided on a claims made basis, an extended claims reporting period of four (4)
years will be required.
POL1
Administration Instruction
#4709.2
71
1996 [di(ion
WATER CRAFT LIABii,�,:}},,'
INSURANCE REQUIRE11c1�T'(�
CONTRACT FOR
BETNN'EEN
MONROE COUNTY, FLORIDA
AND
Prior to the commencement of %vork governed by this contract; the Contractor shall obtain
Water Craft Liability Insurance with terns no less restrictive than those found in the
standard "American Institute Hull Clauses" (June 2, 1977 edition). maintained throughout the life of the contract and include, as a minimum: shall be
• Injury (including death) to any Person
• Damage to Fixed or Movable Objects
• Costs Associated with the Removal of Wrecked Vessels
• Contractual Liability mrith Respect to this Contract
If the policy obtained states that coverage applies for the "Acts,or Omissions of a Vessel"
it shall be endorsed to provide coverage for the legal liability of the shipowner.
The minimum limits acceptable shall be:
$500,000 Combined Single Limit (CSL)
Coverage provided by a Protection and Indemnity Club (P&I) shall
approval oval of the County. be subject to the
The Monroe County Board of County Commissioners shall be named as Additional
Insured on all policies issued to satisfy the above requirements.
NVL1
Adminis(ra(ion Instruction
#4709 2
TM CERTIFICATE OF LIABILITY INSURANCE
03 / 17 / 00
Starkwenther & Shepley, Inc. � AM CO NO RI� � TU �, �oT�N
P.O. Box 549 BOLDER. T= CERIMCATE DOES NOT ,M, EMND OF
Providence, RI 02901 'V'T COVERAGE AFFORD® BY THE POLICns BELOW.
INK)RERS AFFORDING COVERAGE
Blue Water Marine Services aaiuRERA. NEW HAMPSHIRE INSURANCE
Capt . Cole Murray B:
16015 S.W. 298 Terrace 0KIRERQ
Homestead, FL 33033 OMMERO:
rnWen ..... INSURER E.
THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITKSTANDLN(
ANY REQUIREMENT. TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUIUM WITH RESPECT TO
MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIIY is SUBIECT WHICH THIS CERTIFICATE MAY BE ISSUED 01
POLICIES. AGGREGATE LD,IITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAM0. To ALL THE 77'JtM.4. EXCLUSIONS AND CONDITIONS OF SUCH Halt
TYR OF INSI-RAMC= POLICY NUMBER �lOIdCY� POLICY fIRATION:
A _covvKRAL LIABILITY I GL 6 0 8 2 2 6 7 U MI1'f
12/20/99 :12/20/00 : EACH OCCURRENCE f 1 000 00
COMMBRCW,GfiNERALL1ABaI1Y '
CLAIMS MADE OCCUR PBiB DAMAGfi (As, eee Axel : f S O O O O
MED EXP (Ayr am Wm) I f 5 0 0 0
t—=
PERSONAL A ADV INJURY ' f S 1.000. 0 Q
GENLAGGREGrATEL RAPPLMSPER:' I ��LAGGREGATE IS$2 000. OO
�I POLICY LOC PRODUCrs-COMP/OP AGG ' f $1, 0 0 0 , O 0
I
rAUTOMOBIIR LIABILITY
ANY AUTO •.� r : r Q A'. COMBINED SINGLE LIMIT
ALL OWNED AUTOS eeadesl IS
V I _
SCHEDULED AUTOS LYIURY j
"
HIRED AUTOS �
... l.iv f
t.F
NON-GWNED AUTOS =t1� URY !S
jPROPERTY DAMAGE f
,GARAGE LIABILTTY
ANY AUTO i AUTO ONLY - EA ACCIDENT f
OTHER THAN EA ACC , S
AUTO ONLY: AGO , f
tECL4E1.lABIW7'Y_
OCCUR
CLAIMS MADE EACH OCCURRENCE I f
i AGGREGATE I f
DEDUCTIBLE S
RETENTION S f
WORKERS COMMEATION AND f
ZMFWYRW LIABILITY WC STA
L tuTT
U- OH-
i !'tffYy ne
I LL EACH ACCIDENT I f
iE.LDISEASE-FAEMPLOYEE: 3
E L DOEASfi - POLICY LIMIT'S
A GTHRR P & ICV3030352-13721 112/20/99 12/20/00 $500, 000
maurnON OF 0rz"- IONL1.00Aa
2ERTIFICATE HOLDER LISTED BELOW IS NAMED AS
INSUREDS MARINE RELATED PROJECTS ADDITIONAL INSURED AS RESPECTS
& I includes Jones Act, Collision, Tower's and Salvor'a Liability
7essels: 1992 25, Orange, 1994 26' Silvership, 1978 26' Dusky, 20, Shamrock,
1998 2519" Madison, 1998 24' Silvership & 26' Baycat
CERTIFICATE AOLDER iADDIIpVAI NSURID:NSUR1XL "1TI : CANCELLATION
Monroe County Board of comm. $BMW„PVC, , M� „=C==MX`a�,Ia
B`"s°BTHZZ'Q"A=N
DATZERaR �.LENDRAVcW TowAIL1o.�DAWWNU EN Xttn: No. Kim McGee
3100 College Road sYOUR
:Key West, FL 33040 fifraRNooBucAl>oNOR ug�IlsAGalrnsOR
�RE�If1'ATIYfa.
AIRSORMW 2,,,, .AT.
,wxU z3-5 (7Mn 1 of 2
#S10316/M10314
0 AGOAD CORPORATION IM
MPORTANT
N the certificate holder is an ADDITIONAL INSURED, the policAies) must be endorsed. A statement
on this certificate does not confer rights to the certificate holder in lieu of such endorsemeags).
If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may
require an endorsement.A statement on this catificate does not confer rightsto the certificate
holder in lien of such endorsement(s).
DISCLAIMER
The Certificate of Insurance on the reverse side of this form does not constitute a contract between
the issuing iaiurer{s). authorized representative or producer, and the certificate bolder. nor does it
affirmatively or negatively amend. extend or alter the coverage afforded by the policies listed thereon.
CORD zs-S (7/" 2 Of 2 #S10316/M10314
CERTIFICATE OF INSURANCE
CLSTATE INSURANCE COMPANY ❑ ALLSTATE INDEMNITY COMPANY ❑ ALLSTATE TEXAS LLOYD'S
THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFI-
ft& . . n ne sm TCO TYc t'rWFaer,P AFFORDED BY THE POLICIES BELOW
CERTIFICATE HOLDER
NAMED INSURED
Name and Address of Party to Whom this Certificate is Issued
Name and Address of Insured
14MM MHU B3W CF MM.9MM
SIE WPM NiliM SEW=. IW-
3�T 296 '
LQ9U5 ZEEM
� ED.
RMIk 3
�D. Flii 330Lii0
3ES
MG IV FM4 410
This is to certify that policies of Insurance listed below have been issued to the insured named above subject to the expiration date inalcateo Deiow,
notwithstanding any requirement, term or condition of any contract or other document with respect to which this certificate may be issued or may
3artain. The insurance afforded by the policies described herein is subject to all the terms, exclusions, and conditions of such policies.
TYPE OF INSURANCE AND LIMITS
COMMERCIAL GENERAL LIABILITY NCiicy Effective Expiration I
Number Date Date
Limit
Amount
GENERAL AGGREGATE OMIT Other than Products — Completed Operations)
S
PRODUCTS — COMPLETED OPERATIONS AGGREGATE UMIT
S
PERSONAL AND ADVERTISING INJURY OMIT
=
EACH OCCURRENCE LIMIT
S
PHYSICAL DAMAGE LIMIT
S
ANY ONE LOSS
MEDICAL EXPENSE LIMIT
S
ANY ONE PERSON
WORKERS' COMPENSATION 3 Policy Effective
EMPLOYERS' LIABILITY Number Date
Expiration
Date
coverage
Limits
WORKERS' COMPENSATION
STATUTORY — applies only in the following states:
EMPLOYERS'
LIABILITY
BODILY INJURY BY ACCIDENT
=
EACH ACCIDENT
BODILY INJURY BY DISEASE
=
EACH EMPLOYEE
BODILY INJURY BY DISEASE
_
POLICY LIMIT
AUTOMOBILE LIABILITY Policy Effective
Numbe2ffr.10899033M Date
Expiration
Date
Coverage Basis
OANY AUTO 99 OWNED AUTOS QtHIRED AUTOS
Combined Single Limit of Liability
BODILY INJURY b PROPERTY DAMAGE S EACH ACCIDENT
Saw
MhUmLimits
QSPECIFIED AUTOS 50 NON -OWNED AUTOS
In
Dsaa s
6h
S
= -^ '-
PERSON
DOWNED PRIVATE PASSENGER AUTOS
CIOWNED AUTOS OTHER THAN PRIVATE PASSENGER
S
$
ACCIDENT
UMBRELLA LIABILITY Policy DaEffective
Number
eration
Expiration
EACH OCCURRENCE GENERAL AGGREGATE PRODUCTS — COMPLETED OPERATIONS AGGREGATE
$ = s
OTHER (Show Policy Effective
"of Policy) Number Date
Expiration
Date
DESCRIPTION OF OPERATIONSfLOCATIONSNEN16a IRESTRICTIONSISPECWL ITEMS
-- ,,
�- ; rr •c- RY ' '_ :
(WAH MM
8COTT GORHAM, INSURANCE AGENT
125 NE Bth STREET. #7
HOMESTEAD, FL 33030
u Y It
BUS: PM 245.8488 • FAX: (305) 245-SGW
CANCELLATION ...-, _
, 0Cr1.>•�0
Number of days notice _—VCs _ DO,
Should any of the above described policies be cancelled before the expiration date, the issuing company will endeavor to mail within the number of
days entered above, written notice to the certificate holder named above. But failure to mail such notice shall impose no obligation or liability of any
W-A ...,nn thw rmmnAnv it* snants or representatives.
U10523.2