The URL can be used to link to this page

09/15/2021 Agreement Goa coup}Qc111 ;'oP�°'#7•°gF�,, Kevin Madok, CPA 4��oNRoea Clerk of the Circuit Court&Comptroller—Monroe County, Florida DATE: September 28, 2021 TO: Beth Leto,Airports Business Manager, KWIA Air FROM: Pamela G. Hanc.•, f!). . SUBJECT: September 15th BOCC Meeting Attached is an electronic copy of each of the following items for your handling: J6 Contract to the only bidder DEC Contracting Group, in the amount of $3,814,607.91, for the Key West International Airport Noise Insulation Program Project at Key West by the Sea, Building A, Phase 2.The Federal Aviation Administration (FAA) grant for this project is also on the September 15, 2021 agenda. All project costs to be funded with FAA Grant No. 37-63 (100%). Should you have any questions please feel free to contact me at(305) 292-3550. cc: County Attorney Finance File KEY WEST MARATHON PLANTATION KEY PK/ROTH BUILDING 500 Whitehead Street 3117 Overseas Highway 88820 Overseas Highway 50 High Point Road Key West,Florida 33040 Marathon,Florida 33050 Plantation Key,Florida 33070 Plantation Key,Florida 33070 305-294-4641 305-289-6027 305-852-7145 305-852-7145 CONTRACT Key West International Airport Noise Insulation Program Construction of KWBTS Building A — Phase 2 THIS AGREEMENT made and entered into the15th day of September, 2021, by and between DEC Contracting Group, Inc., (hereinafter referred to as "CONTRACTOR"), and the Monroe County Board of Commissioners, Key West, Florida, (hereinafter referred to as "OWNER"). WITNESSETH: That the CONTRACTOR, for the consideration hereinafter fully set out, hereby agrees with the OWNER as follows: 1. That the CONTRACTOR, shall furnish all the materials, and perform all of the work in the manner and form as provided by the following enumerated documents; Instruction to Bidders, Form of Proposal, General Provisions, Special Provisions, Technical Specifications, Form of Contract, Form of Bond, Drawings and Addenda,which are attached hereto and made a part hereof, as if fully contained herein, for the construction of: Key West International Airport Noise Insulation Proaram Construction of KWBTS Buildina A — Phase 2 Monroe County, Florida 2. That the CONTRACTOR shall commence the work to be performed under this agreement on a date to be specified in a written order of the OWNER and shall fully complete all work hereunder within Two Hundred Fifty-Eight(258)calendar days from the Notice-to-Proceed — Permits pursuant to Special Provision No. 3. 3. The OWNER hereby agrees to pay to the CONTRACTOR for the faithful performance of the agreement, subject to additions and deductions as provided in the specifications or proposal in lawful money of the United States as follows: Approximately Three million eight-hundred fourteen thousand six-hundred seven and 91/100 Dollars ($3,814,607.91) in accordance with lump sum and unit prices set forth in the proposal. 4. On or before the 15th day of each calendar month, the OWNER shall make partial payment to the CONTRACTOR on the basis of a duly certified and approved estimate of work performed during the preceding calendar month by the CONTRACTOR, less ten percent (10%) of the amount of such estimate which is to be retained by the OWNER until all work has been performed strictly in accordance with this agreement. 5. Upon submission by the CONTRACTOR of evidence satisfactory to the OWNER that all payrolls, material bills and other costs incurred by the CONTRACTOR in connection with the construction of the work have been paid in full, final payment on account of this agreement shall be made within twenty (20) days after the completion by the CONTRACTOR of all work covered by this agreement and the acceptance of such work by the OWNER. CONTRACT Page 2 of 11 Key West International Airport Noise Insulation Program Construction of KWBTS Building A — Phase 2 6. It is mutually agreed between the parties hereto that time is of the essence in this contract and in the event the construction of the work is not completed within the time herein specified, it is agreed that from the compensation otherwise to be paid to the CONTRACTOR, the OWNER may retain the amounts described in the Liquidated Damages, Special Provision No. 3, per day for each day thereafter, Sundays and holidays included, that the work remains uncompleted, which sum shall represent the actual damages which the OWNER will have sustained per day by failure of the CONTRACTOR to complete the work within the time stipulated and this sum is not a penalty being the stipulated damages the OWNER will have sustained in the event of such default by the CONTRACTOR. 7. It is further mutually agreed between the parties hereto that if at any time after the execution of this agreement and the surety bond hereto attached for its faithful performance, the OWNER shall deem the surety or sureties upon such bond to be unsatisfactory, or if, for any reason, such bond ceases to be adequate to cover the performance of the work, the CONTRACTOR shall, at its expense within five (5) days after the receipt of notice from the OWNER so to do, furnish an additional bond or bonds in such form and amount and with such surety or sureties as shall be satisfactory to the OWNER. In such event, no further payment to the CONTRACTOR shall be deemed to be due under this agreement until such new or additional security for the faithful performance of the work shall be furnished in manner and form satisfactory to the OWNER. 8. MAINTENANCE OF RECORDS: CONTRACTOR shall maintain all books, records and documents directly pertinent to performance under this Agreement in accordance with generally accepted accounting principles consistently applied. Each party to this Agreement or their authorized representatives shall have reasonable and timely access to such records of each other party to this Agreement for public records purposes during the term of the Agreement and for four years following the termination of this Agreement. If an auditor employed by the OWNER or Clerk determines that monies paid to CONTRACTOR pursuant to this Agreement were spent for purposes not authorized by this Agreement, the CONTRACTOR shall repay the monies together with interest calculated pursuant to Sec. 55,03, Florida Statutes, running from the date the monies were paid to CONTRACTOR. 9. PUBLIC ACCESS: Public Records Compliance. CONTRACTOR must comply with Florida public records laws, including but not limited to Chapter 119, Florida Statutes and Section 24 of article I of the Constitution of Florida. The OWNER and CONTRACTOR shall allow and permit reasonable access to, and inspection of, all documents, records, papers, letters or other "public record" materials in its possession or under its control subject to the provisions of Chapter 119, Florida Statutes, and made or received by the OWNER and CONTRACTOR in conjunction with this contract and related to contract performance. The OWNER shall have the right to unilaterally cancel this contract upon violation of this provision by the CONTRACTOR. Failure of the CONTRACTOR to abide by the terms of this provision shall be deemed a material breach of this contract and the OWNER may CONTRACT Page 3 of 11 Key West International Airport Noise Insulation Program Construction of KWBTS Building A — Phase 2 enforce the terms of this provision in the form of a court proceeding and shall, as a prevailing party, be entitled to reimbursement of all attorney's fees and costs associated with that proceeding. This provision shall survive any termination or expiration of the contract. The CONTRACTOR is encouraged to consult with its advisors about Florida Public Records Law in order to comply with this provision. Pursuant to F.S. 119.0701 and the terms and conditions of this contract, the CONTRACTOR is required to: a) Keep and maintain public records that would be required by the OWNER to perform the service. b) Upon receipt from the OWNER's custodian of records, provide the OWNER with a copy of the requested records or allow the records to be inspected or copied within a reasonable time at a cost that does not exceed the cost provided in this chapter or as otherwise provided by law. c) Ensure that public records that are exempt or confidential and exempt from public records disclosure requirements are not disclosed except as authorized by law for the duration of the contract term and following completion of the contract if the contractor does not transfer the records to the OWNER. d) Upon completion of the contract, transfer, at no cost, to the OWNER all public records in possession of the CONTRACTOR or keep and maintain public records that would be required by the OWNER to perform the service. If the CONTRACTOR transfers all public records to the OWNER upon completion of the contract, the CONTRACTOR shall destroy any duplicate public records that are exempt or confidential and exempt from public records disclosure requirements. If the CONTRACTOR keeps and maintains public records upon completion of the contract, the CONTRACTOR shall meet all applicable requirements for retaining public records. All records stored electronically must be provided to the OWNER, upon request from the OWNER's custodian of records, in a format that is compatible with the information technology systems of the OWNER. e) A request to inspect or copy public records relating to this contract must be made directly to the OWNER, but if the OWNER does not possess the requested records, the OWNER shall immediately notify the CONTRACTOR of the request, and the CONTRACTOR must provide the records to the OWNER or allow the records to be inspected or copied within a reasonable time. f) If the CONTRACTOR does not comply with the OWNER'S request for records, the OWNER shall enforce the public records contract provisions in accordance with the contract, notwithstanding the OWNER'S option and right to unilaterally cancel this contract upon violation of this provision by the CONTRACTOR. A CONTRACTOR who fails to provide the public records to the OWNER or pursuant to a valid public CONTRACT Page 4 of 11 Key West International Airport Noise Insulation Program Construction of KWBTS Building A — Phase 2 records request within a reasonable time may be subject to penalties under Section 119.10, Florida Statutes. Contractor shall not transfer custody, release, alter, destroy or otherwise dispose of any public records unless or otherwise provided in this provision or as otherwise provided by law. IF THE CONTRACTOR HAS QUESTIONS REGARDING THE APPLICATION OF CHAPTER 119, FLORIDA STATUTES, TO THE CONTRACTOR'S DUTY TO PROVIDE PUBLIC RECORDS RELATING TO THIS CONTRACT, CONTACT THE CUSTODIAN OF PUBLIC RECORDS, BRIAN BRADLEY, AT (305) 292-3470, RADLEY- RIAN ONROECOUNTY-FL.GOV, MONROE COUNTY ATTORNEY'S OFFICE, 1111 12th STREET, SUITE 408, KEY WEST, FL 33040. 10. HOLD HARMLESS AND INSURANCE: Notwithstanding any minimum insurance requirements prescribed elsewhere in this agreement, CONTRACTOR shall defend, indemnify and hold the OWNER and the OWNER's elected and appointed officers and employees harmless from and against: (i) any claims, actions or causes of action, (ii)any litigation, administrative proceedings, appellate proceedings, or other proceedings relating to any type of injury(including death), loss, damage, fine, penalty or business interruption, and (iii) any costs or expenses (including,without limitation, costs of remediation and costs of additional security measures that the Federal Aviation Administration, the Transportation Security Administration or any other governmental agency requires by reason of, or in connection with a violation of any federal law or regulation, attorneys' fees and costs, court costs, fines and penalties) that may be asserted against, initiated with respect to, or sustained by, any indemnified party by reason of, or in connection with, (A) any activity of CONTRACTOR or any of its employees, agents, contractors or other invitees on the Construction Site during the term of this Agreement, (B) the negligence or willful misconduct of CONTRACTOR or any of its employees, agents, contractors or other invitees, or (C) CONTRACTOR's default in respect of any of the obligations that it undertakes under the terms of this Agreement, except to the extent the claims, actions, causes of action, litigation, proceedings, costs or expenses arise from the intentional or sole negligent acts or omissions of the OWNER or any of its employees, agents, contractors or invitees (other than CONTRACTOR). Insofar as the claims, actions, causes of action, litigation, proceedings, costs or expenses relate to events or circumstances that occur during the term of this Agreement, this section will survive the expiration of the term of this Agreement or any earlier termination of this Agreement. In the event the completion of the project (including the work of others) is delayed or suspended as a result of the CONTRACTOR's failure to purchase or maintain the required insurance, the CONTRACTOR shall indemnify the OWNER from any and all increased expenses resulting from such delay. The first ten ($10.00) of remuneration paid to the CONTRACTOR is for the indemnification provided for above. CONTRACT Page 5 of 11 Key West International Airport Noise Insulation Program Construction of KWBTS Building A — Phase 2 The extent of liability is in no way limited to, reduced, or lessened by the insurance requirements contained elsewhere within this agreement. CERTIFICATES OF INSURANCE. Original Certificates of Insurance shall be provided to the OWNER at the time of execution of this Agreement and certified copies provided if requested. Each policy certificate shall be endorsed with a provision that not less than thirty(30) calendar days'written notice shall be provided to the OWNER before any policy or coverage is canceled or restricted. The underwriter of such insurance shall be qualified to do business in the State of Florida. If requested by the County Administrator, the insurance coverage shall be primary insurance with respect to the OWNER, its officials, employees, agents and volunteers. Failure of CONTRACTOR to comply with the requirements of this section shall be cause for immediate termination of this agreement. 11. NON-WAIVER OF IMMUNITY: Notwithstanding the provisions of Sec. 768.28, Florida Statutes, the participation of OWNER and CONTRACTOR in this Agreement and the acquisition of any commercial liability insurance coverage, self-insurance coverage, or local government liability insurance pool coverage shall not be deemed a waiver of immunity to the extent of liability coverage, nor shall any Agreement entered into by the OWNER be required to contain any provision forwaiver. 12. NO PLEDGE OF CREDIT: CONTRACTOR shall not pledge the OWNER'S credit or make it a guarantor of payment or surety for any contract, debt, obligation,judgment, lien, or any form of indebtedness. CONTRACTOR further warrants and represents that it has no obligation or indebtedness that would impair its ability to fulfill the terms of this contract. 13. NOTICE REQUIREMENT: Any notice required or permitted under this agreement shall be in writing and hand delivered or mailed, postage prepaid, to the other party by certified mail, returned receipt requested, to the following: FOR OWNER: Pedro Mercado Richard Strickland, Director of Airports Assistant County Attorney Key West International Airport 1111 12th Street, Suite 408 3491 S. Roosevelt Blvd. Key West, FL 33040 Key West, Florida 33040 FOR CONTRACTOR: Douglas R. Masch II, President DEC Contracting Group, Inc 1560 Matthew Drive, Suite B Fort Myers, FL 33907 14. GOVERNING LAW, VENUE, AND INTERPRETATION: This Agreement shall be governed by and construed in accordance with the laws of the State of Florida applicable to Agreements made and to be performed entirely in the State. In the event that any cause of action or administrative proceeding is instituted for the enforcement or interpretation of CONTRACT Page 6 of 11 Key West International Airport Noise Insulation Program Construction of KWBTS Building A — Phase 2 this Agreement, the OWNER and CONTRACTOR agree that venue will lie in the appropriate court or before the appropriate administrative body in Monroe County, Florida. 15. MEDIATION: The OWNER and CONTRACTOR agree that, in the event of conflicting interpretations of the terms or a term of this Agreement by or between any of them the issue shall be submitted to mediation prior to the institution of any other administrative or legal proceeding. Mediation proceedings initiated and conducted pursuant to this Agreement shall be in accordance with the Florida Rules of Civil Procedure and usual and customary procedures required by the circuit court of Monroe County. 16. SEVERABILITY: If any term, covenant, condition or provision of this Agreement (or the application thereof to any circumstance or person) shall be declared invalid or unenforceable to any extent by a court of competent jurisdiction, the remaining terms, covenants, conditions and provisions of this Agreement, shall not be affected thereby; and each remaining term, covenant, condition and provision of this Agreement shall be valid and shall be enforceable to the fullest extent permitted by law unless the enforcement of the remaining terms, covenants, conditions and provisions of this Agreement would prevent the accomplishment of the original intent of this Agreement. The OWNER and CONTRACTOR agree to reform the Agreement to replace any stricken provision with a valid provision that comes as close as possible to the intent of the stricken provision. 17. ATTORNEY'S FEES AND COSTS: OWNER and CONTRACTOR agree that in the event any cause of action or administrative proceeding is initiated or defended by any party relative to the enforcement or interpretation of this Agreement, the prevailing party shall be entitled to reasonable attorney's fees and attorney's fees, in appellate proceedings. Each party agrees to pay its own court costs, investigative, and out-of-pocket expenses whether it is the prevailing party or not, through all levels of the court system. 18. ADJUDICATION OF DISPUTES OR DISAGREEMENTS: OWNER and CONTRACTOR agree that all disputes and disagreements shall be attempted to be resolved by meet and confer sessions between representatives of each of OWNER and CONTRACTOR. If no resolution can be agreed upon within 30 days after the first meet and confer session, the issue or issues shall be discussed at a public meeting of the Board of County Commissioners. If the issue or issues are still not resolved to the satisfaction of OWNER and CONTRACTOR, then any party shall have the right to seek such relief or remedy as may be provided by this Agreement or by Florida law. 19. COOPERATION: In the event any administrative or legal proceeding is instituted against either party relating to the formation, execution, performance, or breach of this Agreement, OWNER and CONTRACTOR agree to participate, to the extent required by the other party, in all proceedings, hearings, processes, meetings, and other activities related to the substance of this Agreement or provision of the services under this Agreement. OWNER and CONTRACTOR specifically agree that no party to this Agreement shall be required to enter into any arbitration proceedings related to this Agreement. CONTRACT Page 7 of 11 Key West International Airport Noise Insulation Program Construction of KWBTS Building A — Phase 2 20. BINDING EFFECT: The terms, covenants, conditions, and provisions of this Agreement shall bind and inure to the benefit of OWNER and CONTRACTOR and their respective legal representatives, successors, and assigns. 21. AUTHORITY: Each party represents and warrants to the other that the execution, delivery and performance of this Agreement have been duly authorized by all necessary County and corporate action, as required by law. 22. PRIVILEGES AND IMMUNITIES: All of the privileges and immunities from liability, exemptions from laws, ordinances, and rules and pensions and relief, disability, workers' compensation, and other benefits which apply to the activity of officers, agents, or employees of any public agents or employees of the OWNER, when performing their respective functions under this Agreement within the territorial limits of the OWNER shall apply to the same degree and extent to the performance of such functions and duties of such officers, agents, volunteers, or employees outside the territorial limits of the OWNER. 23. LEGAL OBLIGATIONS AND RESPONSIBILITIES: This Agreement is not intended to, nor shall it be construed as, relieving any participating entity from any obligation or responsibility imposed upon the entity by law except to the extent of actual and timely performance thereof by any participating entity, in which case the performance may be offered in satisfaction of the obligation or responsibility. Further, this Agreement is not intended to, nor shall it be construed as, authorizing the delegation of the constitutional or statutory duties of the OWNER, except to the extent permitted by the Florida constitution, state statute, and case law. 24. NON-RELIANCE BY NON-PARTIES: No person or entity shall be entitled to rely upon the terms, or any of them, of this Agreement to enforce or attempt to enforce any third-party claim or entitlement to or benefit of any service or program contemplated hereunder, and the OWNER and the CONTRACTOR agree that neither the OWNER nor the CONTRACTOR or any agent, officer, or employee of either shall have the authority to inform, counsel, or otherwise indicate that any particular individual or group of individuals, entity or entities, have entitlements or benefits under this Agreement separate and apart, inferior to, or superior to the community in general or for the purposes contemplated in this Agreement. 25. NO PERSONAL LIABILITY: No covenant or agreement contained herein shall be deemed to be a covenant or agreement of any member, officer, agent or employee of Monroe County in his or her individual capacity, and no member, officer, agent or employee of Monroe County shall be liable personally on this Agreement or be subject to any personal liability or accountability by reason of the execution of this Agreement. 26. EXECUTION IN COUNTERPARTS: This Agreement may be executed in any number of counterparts, each of which shall be regarded as an original, all of which taken together shall constitute one and the same instrument and OWNER and CONTRACTOR hereto may execute this Agreement by signing any such counterpart. CONTRACT Page 8 of 11 Key West International Airport Noise Insulation Program Construction of KWBTS Building A — Phase 2 27. NON-DISCRIMINATION: CONTRACTOR agrees that there will be no discrimination against any person, and it is expressly understood that upon a determination by a court of competent jurisdiction that discrimination has occurred, this Agreement automatically terminates without any further action on the part of any party, effective the date of the court order. CONTRACTOR agrees to comply with all Federal and Florida statutes, and all local ordinances, as applicable, relating to nondiscrimination. These include but are not limited to: a) Title VII of the Civil Rights Act of 1964 (PL 88-352) which prohibit discrimination in employment on the basis of race, color, religion, sex. and national origin. b) Title IX of the Education Amendment of 1972, as amended (20 USC §§ 1681- 1683, and 1685-1686), which prohibits discrimination on the basis of sex. c) Section 504 of the Rehabilitation Act of 1973, as amended (20 USC § 794), which prohibits discrimination on the basis of handicaps. d) The Age Discrimination Act of 1975, as amended (42 USC §§ 6101-6107) which prohibits discrimination on the basis of age e) The Drug Abuse Office and Treatment Act of 1972 (PL 92-255), as amended, relating to nondiscrimination on the basis of drug abuse. f) The Comprehensive Alcohol Abuse and Alcoholism Prevention, Treatment and Rehabilitation Act of 1970 (PL 91-616), as amended, relating to nondiscrimination on the basis of alcohol abuse or alcoholism. g) The Public Health Service Act of 1912, §§ 523 and 527 (42 USC §§ 690dd-3 and 290ee- 3), as amended, relating to confidentiality of alcohol and drug abuse patient records. h) Title VIII of the Civil Rights Act of 1968 (42 USC § et seq.), as amended, relating to nondiscrimination in the sale, rental or financing of housing. i) The Americans with Disabilities Act of 1990 (42 USC § 1201), as amended from time to time, relating to nondiscrimination in employment on the basis of disability. j) Monroe County Code Chapter 14, Article II, which prohibits discrimination on the basis of race, color, sex, religion, national origin, ancestry, sexual orientation, gender identity or expression, familial status or age; and k) Any other nondiscrimination provisions in any federal or state statutes which may apply to the parties to, or the subject matter of, this Agreement. 28. COVENANT OF NO INTEREST: County and Contractor covenant that neither presently has any interest, and shall not acquire any interest, which would conflict in any manner or degree with its performance under this Agreement, and that the only interest of each is to perform and receive benefits as recited in this Agreement. CONTRACT Page 9 of 11 Key West International Airport Noise Insulation Program Construction of KWBTS Building A — Phase 2 29. CODE OF ETHICS: County agrees that officers and employees of the County recognize and will be required to comply with the standards of conduct for public officers and employees as delineated in Section 112.313, Florida Statutes, regarding, but not limited to, solicitation or acceptance of gifts; doing business with one's agency; unauthorized compensation; misuse of public position, conflicting employment or contractual relationship; and disclosure or use of certain information. 30. ETHICS CLAUSE: Contractor warrants that he/it had not employed, retained or otherwise had act on his/its behalf any former County officer or employee subject to the prohibition of Section 2 of Ordinance No. 010-1990 or any County officer or employee in violation of Section 3 of Ordinance No. 020-1990. For breach or violation of this provision the County may, in its discretion, terminate this contract without liability and may also, in its discretion, deduct from the contract or purchase price, or otherwise recover the full amount of any fee, commission, percentage, gift, or consideration paid to the former County officer or employee. 31. ATTESTATIONS: Contractor agrees to execute such documents as the County may reasonably require, to include a Public Entity Crime Statement, an Ethics Statement, and a Drug-Free Workplace Statement. 32. MUTUAL REVIEW: This agreement has been carefully reviewed by CONTRACTOR and the COUNTY; therefore, this agreement is not to be construed against either party on the basis of authorship. CONTRACT Page 10 of 11 Key West International Airport Noise Insulation Program Construction of KWBTS Building A— Phase 2 IN WITNESS, WHEREOF the parties hereto have executed this agreement on the day and date first above written in two(2)counterparts, each of which shall, without proof or accounting for the other counterpoit, be deerned all Original contract. JJj4ri "7 t (CO T ACT R) (OWNER) By: Domilas R. Masch Coldiron Title: President DEC Ccintractina Group, Inc, Title: mayor, Monroe County Board of County Commissioners - ATTEST.: Kevin IVIadok, CPA. Monroe County Clerk g--10 .40504""vt-*'"11-/ ,NnoE COU ATTORNEY As Deputy'Clerk x07 FORM RED 0,1; L.• ASSIST— -• NTY ATTORNEY. Dale 8/27/21 STATE OF FLORIDA COUNTY OF.LEE I, the undersigned authority, a Notary Public, in.and for said County and State, hereby certify that Douglas R..Masch II whose name as President of DEC Contracting Gram Inc. (who is authorized by the corporation to execute this contract),signed the foregoing instrument and who is known to Me, acknowledged before me on this day that being informed of the contents of the within instrument, he, in his capacity as such, executed the same voluntarily on the date the same bears date. Given under my hand and seal this 20day of August, 2021. — P 1 -73 1 7r, -77 .7) Notary lic Signature ,§01.1:0", REGINA L.DUNN • .e• CommIsslon#HH 010506 * Z,L1.1. * ' • U3, Expires Atigu0 29,2024 tonds4ihruDditelliotary6ervicss CONTRACT Page 11 of 11 Key West International Airport Noise Insulation Program Construction of KWBTS Building A — Phase 2 ATTACHMENTS 1. Acknowledgement of Change Orders 2. Insurance Agents Statement 3. Certificate of Insurance 4. Performance Bond will be provided prior to County execution 5. Payment Bond will be provided prior to County execution 6. Corporate Acknowledgement 7. Surety Acknowledgement will be provided prior to County execution 8. Power of Attorney will be provided prior to County execution S TO: Monroe County Board of Commissioners Key West, Florida REF: Key West International Airport Noise Insulation Program Construction of KWBTS Building A— Phase 2 Ladies and Gentlemen: In order to avoid the necessity of extensive amendments to the referred contract, the undersigned acknowledges hereby that the following conditions are those for which change orders are allowed under the Bid Law: 1. Unusual and difficult circumstances which arose during the course of the execution of the contract which could not have been reasonably foreseen. 2. Where competitive bidding for the new work for new money will work to the serious detriment of the awarding authority, 3. Emergencies arising during the course of the work. 4. Changes or alterations provided for in the original bid and originals contract. Contractor: DEC Contracting Group, Inc. By: Douglas R. Masch 11, President Date: &r- z Key West International Airport Noise Insulation Program Construction of KWBTS Building A y-Phase IN5jjRANCE Ag NT' „"SAT MENT I have reviewed the insurance requirements with the bidder named below. The following deductibles apply to the corresponding policy: POLICY TYPE; POLICY NUMBER DEDUCTIBLES: General Liability PKG 167517 9 $1,000 Worker's Compensation UCV0167992_0 none Vehicle Liability B1 P0157N none Builder's Fisk To be provided by Janua 21 2022 Asbestos Abatement Liability Provided by Asbestos Abatement Subcontractor—See Attached Liability Policies are: X Occurrence ElClaims Made r �f Five County Insurance Agency, Inc. .. Insurance Agency Signature BIDDE ° STATEMENT I understand the insurance that will be mandatory if awarded the Contract and will comply in full with all the requirements. Bidder: Signature: 4 DEC Contracting Group, Inc. " � �e_ Douglaa. IUlasch II, President CORPORATE ACKNOWLEDGMENT STATE OF FLORIDA COUNTY OF LEE On this this 15th day of September, 2021. Before me personally came Douglas R. Masch 11 to me known, who being by me duly sworn, did depose and say he is the President of DEC Contracting Group, Inc. the corporation described in and which executed the above instrument; that he knows the seal of said corporation', that the seal affixed to said instrument is such corporate seal; that it was so affixed by the Board of Directors of said corporation and that he signed his name thereto by like order. Ile Notary Ajblic Signature 4�,Y.!�fe,6 REGINALDUNN COMMISSIon N HH 030505 A'10* Exp Ires August 29,2024 41`L-'0, poridA Ihm Rudget Nowry seryko Key West International Airport Noise Insulation Program Construction of KWBTS Building A Phase 2 SECTION E DRUG FREE WORKPLACE FORM The undersigned Contractor, in accordance with Florida Statute 287,087, hereby certifies that.-, DEC Contracting Group, Inc. (Name of Business) 9 . Publish a statement notifying employees that the unlawful manufacture, distribution, dispensing, possession or use of a controlled substance is prohibited in the workplace and specifying the actions that will be taken against employees for violations of such prohibition. 2e Inform Such employees about the dangers of drug abuse in the workplace, the business policy of maintaining a drug-free workplace, any available drug counseling, rehabilitation and employee assistance programs and the penalties that may be imposed upon employees for drug abuse violations. 3. 0-ive each ernployee engaged in providing the commodities or contractual services that are under bid a copy of the statement specified in Sub-section(1). 4. In the statement specified in Sub-Section (1), notify the employees that as a condition of working on the commodities or contractual services that are under bid, the employee will abide by the terms of the statement and will notify the employer of any conviction of or plea of guilty or nolo contend re to any violation of Chapter 893 (Florida Statutes) or of any controlled substance law of the United States or any state for a violation occurring In the workplace no later than five(5)days after such conviction. 5. Impose a sanction on or require the satisfactory participation in a drug abuse assistance or rehabilitation program if Such is available in the employee's community or any employee who is so convicted. 6. Make a good faith effort to continue to maintain a drug-free workplace through implementation of this section. As a person authorized to sign the statement, I certify that this firm complies fully with the above requirements. (Signature) Vice President (Title) 4-29-2021 (Date) BID DOCUMENTS 1-20 Key West International Airport Noise Insulation Program Construction of KWBTS Building A— Phase 2 SECTION K PUBLIC ENTITY CRIME STATEMENT "A person or affillate who has been placed on the convicted vendor list following a conviction for public entity crime may not submit a bid on a contract to provide any goods or services to a public entity, may not submit a bid on a contract with a public entity for the construction or repair of a public building or public work, may not submit bids on leases of real property to public entity, may not be awarded or perform work as a CONTRACTOR,supplier,subcontractor,or CONTRACTOR under a contract with any public entity, and may not transact business with any public entity in excess of the threshold amount provided in Section 287.017, for CATEGORY TWO for a period of 36 months from the date of being placed on the convicted vendor list." DEC Contracting Group, Inc./Erika Bodenstein I have read the above and state that neither___ —_ (Respondent's name) nor any Affiliate has been placed on the convicted vendor list within the last 36 months. (Signature ,a �d Vice President (Title) 4/2912021 (Date) STATE OF: Florida COUNTY OF: Lee Subscribed and sworn to(or affirmed) before me, by means of physical presence or 0 online notarization, on q. 2�.&Z L_(date)by A (name of affiant). He/She is personally known to me or has produced (type of identification) as identification. "—"IrMOTARY PUBLIC My Commission Expires: 4,0-1 e? 0111GIA1 I MAIIII 11 2. 14X Notary Mile-State o!F[DrIda Commission N GG 202730 ray Comm.Expires Apr 2,1021 BID DOCUMENTS 1-,39 Key West International Airport Noise Insulation Program Construction of KWBTS Building A- Phase 2 SECTION L SWORN STATEMENT UNDER ORDINANCE NO. 10-1990 MONROE COUNTY FLORIDA ETHICS CLAUSE DEC Contracting Group, Inc. Erika Bodenstein warrants that he/she/it has not employed, retained or otherwise had act on his/her/its behalf any former County officer or employee in violation of Section 2 of Ordinance No. 10-1990 or any County officer oremployee in violation of Section 3 of Ordinance No. 10-1990. For breach or violation of this provision the County may,in its discretion,terminate this Contract without liability and may also, In Its d1scretion, deduct from the Contract or purchase price or otherwise recover the full amount of any fee, commission, percentage, gift or consideration paid to the former County officer or employee. �( igna tire) Vice President (Title) 4/2912021 (Date) STATE OF: Florida COUNTY OF: Lee Subscribed and sworn to (or affirmed) before me, by means of physical presence or 0 online notarization, on a •Z 6,F- A ,PzJ 64( (date) by (name of affiant). He/She is personally known to me or lies produced (type of identification) as identification. OTARY PMILIC My Commission E 01GLAS R kka"F' N V PumIC• 5 D D OUGLAS R MASC H 11 R�X&i) Naiary Pumic-stake of rivida Com misslon N GG 2017 3 0 my Comm,Exftes Apr C G 20 C.P�r. .2022 1,Ap,2,2022 MY=C BID DOCUMENTS 1-40 Key West International Airport Noise Insulation Program Construction of KWBTS Building A—Phase 2 SECTION P NON-COLLUSION AFFIDAVIT 1, Erika Bodenstein (name) according to law on my oath, and under penalty of perjury,depose and say that. 1) 1 am Vice President ........................ (title) of the firm of DEC Contracting Group, Inc. (company name) the Bidder makingbid—Proposai for the project described in the Notice for Calling for bids for K r West International Al tart- DiesInsulation PEggrarn Construction of KWBTS Building A,—•Phl§_q_2 and that I executed the said proposal with full authority to do so: 2) The prices in this bid have been arrived at independently without collusion, consultation, communication or agreement for the purpose of restricting competition, as to any matter relating to such prices with any other bidder or with any coma titer; 3) Unless otherwise required by law, the prices which have been quoted in this bid have not been knowingly disclosed by the Bidder and will not knowingly be disclosed by the Bidder prior to bid opening, directly or indirectly,to any other bidder or to any competitor; and 4) No attempt has been made or will be made by the Bidder to induce any other person, partnership or corporation to submit, or not to submit, a bid for the purpose of restricting competition; 5) The statements contained In this affidavit are true and correct, and made with full knowledge that Monroe County relies upon the truth of the statements contained in this affidavit in awarding contracts for said project. Vice President (Title) 4/29/2021 (Date) BID DOCUMENTS 1-49 Key West International Airport Noise Insulation Program Construction of KWBTS Building A—Phase 2 SECTION R VENDOR CERTIFICATION REGARDING SCRUTINIZED COMPANIES LISTS Project Description(s): DEC Contracting Group,inc. Respondent Vendor Name: DEC Contracting Group, Inc. Vendor FEIN: 46-4934701 Vendor's Authorized Representative Name and Title: Erika Bodenstein Address: 1560 Matthew Drive Suite B City:.Fort Myers State: Florida Zip: 33907 ..............- - Phone Number: 239-332-4322 Email Address: cabot@deccontracting.com Section 287.135, Florida Statutes prohibits a company from bidding on, submitting a proposal for, or entering into or renewing a contract for goods or services of any amount if, at the time of contracting or renewal, the company is on the Scrutinized Companies that Boycott Israel List, created pursuant to Section 215.4725, Florida Statutes, or is engaged in a Boycott of Israel. Section 287.135, Florida Statutes, also prohibits a company from bidding on, submitting a proposal for, or entering into or renewing a contract for goods or services of$1,000,000 or more, that are on either the Scrutinized Companies with Activities in Sudan List or the Scrutinized Companies with Activities in the Iran Petroleum Energy Sector Lists which were created pursuant to s. 215.473, Florida Statutes, or is engaged in business operations in Cuba or Syria. As the person authorized to sign on behalf of Respondent, I hereby certify that the company identified above in the Section entitled"Respondent Vendor Name"is not listed on the Scrutinized Companies that Boycott Israel List or engaged in a boycott of Israel and for Projects of$1,000,000 or more is not listed on either the Scrutinized Companies with Activities in Sudan List, the Scrutinized Companies with Activities in the Iran Petroleum Energy Sector List, or engaged in business operations in Cuba or Syria. I understand that pursuant to Section 287.135, Florida Statutes, the submission of a false certification may subject company to civil penalties, attorney's fees, and/or costs. I further understand that any contract with the County may be terminated, at the option of the County, if the company is found to have submitted a false certification or has been placed on the Scrutinized Companies that Boycott Israel List or engaged in a boycott of Israel or placed on the Scrutinized Companies with Activities in Sudan List or the Scrutinized Companies with Activities in the Iran Petroleum Energy Sector List or been engaged in business operations in Cuba or Syria. BID DOCUMENTS 1-52 Key West International Airport Noise Insulation Program Construction of I S Building A- Phase 2 Certified By: who is authorized to sign d b the ve rT,ed company. Authorized Signatu —-------------------- Print Name: Erika Badenstein Title: Vice President Note: The List are available at the following Department of Management Services Site: AU2-L/w_w_wqm q a m yflo rid sL sink erkliqn stat qMjgg q§ qp _.q./ qLp�g ct sus d discrionjIinks vendor lists BID DOCUMENTS 1-53 w,twAIA Document A312'm - 2010 Performance Bond Bond No.015214869 CONTRACTOR: SURETY: (Name, legal status and address) (Name, legal status and principal place DEC Contracting Group,Inc. of business) ADDITIONS AND DELETIONS: The author of this document has 1560 Matthew Drive,Suite B The Ohio Casualty Insurance Company Fort Meyers,FL 33907 1200 MacArthur Boulevard,3rd Floor added information needed for its Mahwah,NJ 07430 completion.The author may also have revised the text of the original OWNER:(Name, legal status and address) AIA standard form.An Additions and Monroe County Board of Commissioners Deletions Report that notes added 1100 Simonton Street information as well as revisions to the Key West,FL 33040 standard form text is available from the author and should be reviewed.A CONSTRUCTION CONTRACT vertical line in the left margin of this Date: September 15,2021 document indicates where the author Amount:$3,814,607.91 Three Million Eight Hundred Fourteen Thousand Six Hundred Seven has added necessary information Description: and 91/100 Dollars and where the author has added to or (Name and location) deleted from the original AIA text IKey West International Airport Noise Insulation Program Construction of KWBTS Building A Phase II This document has Important legal consequences.Consultation with an BOND attorney Is encouraged with respect Date: September 15,2021 to Its completion or modification. (Not earlier than Construction Contract Date) Any singular reference to Contractor, Surety,Owner or other party shall be 3,814,607.91 Three Million Eight Hundred Fourteen Thousand Six Hundred Seven considered lural where a licable- �r�n Ilars p pp Amount:$ and 9 Modifications to this Bond: XJ None See Section 16 CONTRACTOR AS PRINCIPAL SURETY Company: (Corporate Seal) Company: (Corporate Seal) DEC ContraWGroc The Ohio Casualty Insurance mpany $ignaturv,, Signature:Name,-anti% LAr Name and Sandra A.Pace' `itle: t Title: Attorney-in-Fact ,fAt y edditional signatttres appear on the last page of this Performance Bond.) (FOR INFORMATIONONLY- Name,address and telephone) AGENT or BROKER: OWNER'S REPRESENTATIVE: (Architect,Engineer or other party:) True&Associates 325 North Avenue East Westfield,NJ 07090 B.(908)232-0760 Doc#2339802 B1c#3125 Pg#2410 Recorded 9 16/2021 12:43 PM Page 1 of 12 Filed and Recorded in Official Records of MONROE COUNTY KEVI N MADOK,CPA Init. AIA Document A312 —2010 Performance Bond.The American Institute of Architects.All rights reserved. ,NIN This AAA'"'Document ds protected by 4f.5 Copyrbitil Low and international Treatdss Unauthorized reirmducflon or distribuf&an of this AW` Document,or any portion of it,may resu@t in 7 severe civii and crtnonal penarfles.and witl be prosecuted to the maximum extent psosihbW under the taw This document was produced by AIA software at / 15:25:48 on 01/10/2013 under Order No.8871475021,_1 which expires on 12/27/2013,and is not for resale. User Notes: (1382705251) § 1 The Contractor and Surety,jointly and severally,bind themselves,their heirs,executors,administrators, successors and assigns to the Owner for the performance of the Construction Contract,which is incorporated herein by reference. § 2 If the Contractor performs the Construction Contract,the Surety and the Contractor shall have no obligation under this Bond,except when applicable to participate in a conference as provided in Section 3. § 3 If there is no Owner Default under the Construction Contract,the Surety's obligation under this Bond shall arise after .1 the Owner first provides notice to the Contractor and the Surety that the Owner is considering declaring a Contractor Default.Such notice shall indicate whether the Owner is requesting a conference among the Owner,Contractor and Surety to discuss the Contractor's performance.If the Owner does not request a conference,the Surety may,within five(5)business days after receipt of the Owner's notice, request such a conference. If the Surety timely requests a conference,the Owner shall attend.Unless the Owner agrees otherwise,any conference requested under this Section 3.1 shall be held within ten (10)business days of the Surety's receipt of the Owner's notice. If the Owner,the Contractor and the Surety agree,the Contractor shall be allowed a reasonable time to perform the Construction Contract, but such an agreement shall not waive the Owner's right,if any,subsequently to declare a Contractor Default; .2 the Owner declares a Contractor Default,terminates the Construction Contract and notifies the Surety; and .3 the Owner has agreed to pay the Balance of the Contract Price in accordance with the terms of the Construction Contract to the Surety or to a contractor selected to perform the Construction Contract. § 4 Failure on the part of the Owner to comply with the notice requirement in Section 3.1 shall not constitute a failure to comply with a condition precedent to the Surety's obligations,or release the Surety from its obligations,except to the extent the Surety demonstrates actual prejudice. § 5 When the Owner has satisfied the conditions of Section 3,the Surety shall promptly and at the Surety's expense take one of the following actions: § 5.1 Arrange for the Contractor,with the consent of the Owner,to perform and complete the Construction Contract; § 5.2 Undertake to perform and complete the Construction Contract itself,through its agents or independent contractors; § 5.3 Obtain bids or negotiated proposals from qualified contractors acceptable to the Owner for a contract for performance and completion of the Construction Contract,arrange for a contract to be prepared for execution by the Owner and a contractor selected with the Owner's concurrence,to be secured with performance and payment bonds executed by a qualified surety equivalent to the bonds issued on the Construction Contract,and pay to the Owner the amount of damages as described in Section 7 in excess of the Balance of the Contract Price incurred by the Owner as a result of the Contractor Default;or § 5.4 Waive its right to perform and complete,arrange for completion,or obtain a new contractor and with reasonable promptness under the circumstances: .1 After investigation,determine the amount for which it may be liable to the Owner and,as soon as practicable after the amount is determined,make payment to the Owner;or .2 Deny liability in whole or in part and notify the Owner,citing the reasons for denial. § 6 If the Surety does not proceed as provided in Section 5 with reasonable promptness,the Surety shall be deemed to be in default on this Bond seven days after receipt of an additional written notice from the Owner to the Surety demanding that the Surety perform its obligations under this Bond,and the Owner shall be entitled to enforce any remedy available to the Owner.If the Surety proceeds as provided in Section 5.4,and the Owner refuses the payment or the Surety has denied liability,in whole or in part,without further notice the Owner shall be entitled to enforce any remedy available to the Owner. Intt AIA Document A312 ®2010 Performance Bond.The American Institute of Architects.All rights reserved.ti A ial :ThIs AIAa''Document W per laded by t 5 Capyrtpht Law and Miern&UanW Tre aVes Unauthodzed$reproducHon or distribiutlon of this AlA`,' Document ant or any portion of it,oral rs;sull.in 2 savant clvH and crirMnai pena itie s and w'si8 be prosecuted to the maximum extent possible a ndm the law This document was produced byAIA software at f 15:25:48 on 01110/2013 urxrer Order No.6871475021_,1 which expires on 12/27/2013,and Is not for resale. User Notes: (1382705251) § 7 If the Surety elects to act under Section 5.1,5.2 or 5.3,then the responsibilities of the Surety to the Owner shall not be greater than those of the Contractor under the Construction Contract,and the responsibilities of the Owner to the Surety shall not be greater than those of the Owner under the Construction Contract.Subject to the commitment by the Owner to pay the Balance of the Contract Price,the Surety is obligated,without duplication,for .1 the responsibilities of the Contractor for correction of defective work and completion of the Construction Contract; .2 additional legal,design professional and delay costs resulting from the Contractor's Default,and resulting from the actions or failure to act of the Surety under Section 5;and .3 liquidated damages,or if no liquidated damages are specified in the Construction Contract,actual damages caused by delayed performance or non-performance of the Contractor. § 8 If the Surety elects to act under Section 5.1,5.3 or 5.4,the Surety's liability is limited to the amount of this Bond. § 9 The Surety shall not be liable to the Owner or others for obligations of the Contractor that are unrelated to the Construction Contract,and the Balance of the Contract Price shall not be reduced or set off on account of any such unrelated obligations.No right of action shall accrue on this Bond to any person or entity other than the Owner or its heirs,executors,administrators,successors and assigns. § 10 The Surety hereby waives notice of any change,including changes of time,to the Construction Contract or to related subcontracts,purchase orders and other obligations. § 11 Any proceeding,legal or equitable,under this Bond may be instituted in any court of competent jurisdiction in the location in which the work or part of the work is located and shall be instituted within two years after a declaration of Contractor Default or within two years after the Contractor ceased working or within two years after the Surety refuses or fails to perform its obligations under this Bond,whichever occurs first. If the provisions of this Paragraph are void or prohibited by law,the minimum period of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable. § 12 Notice to the Surety,the Owner or the Contractor shall be mailed or delivered to the address shown on the page on which their signature appears. § 13 When this Bond has been furnished to comply with a statutory or other legal requirement in the location where the construction was to be performed,any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefrom and provisions conforming to such statutory or other legal requirement shall be deemed incorporated herein.When so furnished,the intent is that this Bond shall be construed as a statutory bond and not as a common law bond. § 14 Definitions § 14.1 Balance of the Contract Price.The total amount payable by the Owner to the Contractor under the Construction Contract after all proper adjustments have been made,including allowance to the Contractor of any amounts received or to be received by the Owner in settlement of insurance or other claims for damages to which the Contractor is entitled,reduced by all valid and proper payments made to or on behalf of the Contractor under the Construction Contract. § 14.2 Construction Contract The agreement between the Owner and Contractor identified on the cover page, including all Contract Documents and changes made to the agreement and the Contract Documents. § 14.3 Contractor Default.Failure of the Contractor,which has not been remedied or waived,to perform or otherwise to comply with a material term of the Construction Contract. § 14.4 Owner Default.Failure of the Owner,which has not been remedied or waived,to pay the Contractor as required under the Construction Contract or to perform and complete or comply with the other material terns of the Construction Contract. § 14.5 Contract Documents.All the documents that comprise the agreement between the Owner and Contractor. AIA Document A312t"—2010 Performance Bond.The American Institute of Architects.All rights reserved.WARNING:This AIAs Document is protected by Init. U fa Copytight Law and internatt oast Treaties Unauthorized regaod€astIon or distribution of this M0 Document,or any porllon of it,may result In 3 severe civil and cdminal penaai es,and MH be prosecuted to the nax'nrurn extent posMble under the laws This document was produced by AIA software at f 15:26:48 on 01/10/2013 under Order No.6871475021_1 which expires on 12/27/2013,and is not for resale User Notes: (1382705251) § 15 If this Bond is issued for an agreement between a Contractor and subcontractor,the tern Contractor in this Bond shall be deemed to be Subcontractor and the term Owner shall be deemed to be Contractor. § 16 Modifications to this bond are as follows: None (Space is provided below for additional signatures of added parries,other than those appearing on the cover page.) CONTRACTOR AS PRINCIPAL SURETY Company: (Corporate Seal) Company: (Corporate Seal) Signature: N/A ...... Signature: N/A Name and Title: Name and Title: Address: Address: AIA Document A312"—2010 Performance Bond.The American Institute of Architects.All rights reserved. d, ;i ,This AIA'"`Document is protected by Init. U 5 Copyright Law and International Treaters Unauthorized rsprodaarrtiort or distditut"stare of this AiAa Docunntra or any portion of it,may retmPt in 4 severe,OvH and criminal penallies and will be prosecuted try the maximum sates:possiWe under the lair This document was produced by AIA software at / 15 26:48 on 0111012013 under Order No.6871475021_1 which expires on 12127/2013,and is not for resale. User Notes: (1382705251) Document A312"a — 2010 Payment Bond Bond No.015214869 CONTRACTOR: SURETY: (Name, legal status and address) (Name,legal status and principal place f business) DEC Contracting Group,Inc. o ADDITIONS AND DELETIONS: 1560 Matthew Drive,Suite B The Ohio Casualty Insurance Company The author of this document has Fort Meyers,FL 33907 1200 MacArthur Boulevard,3rd Floor added information needed for its Mahwah,NJ 07430 completion.The author may also OWNER: have revised the text of the original (Name,legal status and address) AIA standard form.An Additions and Monroe County Board of Commissioners Deletions Reporf that notes added 1100 Simonton Street information as well as revisions to the Key West,FL 33040 standard form text Is available from the author and should be reviewed.A CONSTRUCTION CONTRACT vertical line in the left margin of this Date:September 15,2021 document Indicates where the author Amount:$3,814,607.91 Three Million Eight Hundred Fourteen Thousand Six Hundred Seven has added necessary information Description: and 91/100 Dollars and where the author has added to or (Name and location) deleted from the original AIA text. Key West International Airport Noise Insulation Program Construction of KWBTS This document has Important legal Building A Phase II consequences.Consultation with an BOND attorney is encouraged with respect Date:September 15,2021 to its completion or modification. (Not earlier than Construction Contract Date) Any singular reference to Contractor, 3,814,607.91 Three Million Eight Hundred Fourteen Thousand Six Hundred Seven Surety,Owner or other party shag be Amount:$ a 9-1/1--00-� Dollars considered plural where applicable. Modifications to this Bond: LJ Note See Section 18 CONTRACTOR AS PRINCIPAL SURETY Company: (Corporate Seal) Company: (Corporate Seal) DEC Contrac Gr p Inca The Ohio Casualty Insurance Company Signature. Signature: Name andr Name and Sandra A.Pace Title: r Title: Attorney-in-Fact (Any ditiatal signatures appear on the last page of this Payment Bond.) (FOR INFORMATION ONL Y--Name,address and telephone) AGENT or BROKER: OWNER'S REPRESENTATIVE: (Architect, Engineer or other party) True&Associates 325 North Avenue East Westfield,NJ 07090 B.(908)232-0760 AIA Document A312m®2010 Payment Bond.The American Institute of Architects.All rights reserved.WARNMG:Thls AfA` Nooument is protected by Ink. US,Copyright Law and Intemotionsl TrcetWs Unauthorizod reproducUon or dlstdbartion of Me A10 Document-or any portion of It,may result in severe ciAl and crimmW Penalties,and will be prosecuted to the maxdrnum extent poeMble-under the new.This document was produced by AIA software at / 11:43:03 on 10/09/2012 under Order No.5820952305_1 which expires on 0411 3/2 01 3.and is not for resale. User Notes: (1718888249) § I The Contractor and Surety,jointly and severally,bind themselves,their heirs,executors,administrators, successors and assigns to the Owner to pay for labor,materials and equipment furnished for use in the performance of the Construction Contract,which is incorporated herein by reference,subject to the following terns. § 2 If the Contractor promptly makes payment of all sums due to Claimants,and defends,indemnifies and holds harmless the Owner from claims,demands,liens or suits by any person or entity seeking payment for labor,materials or equipment furnished for use in the performance of the Construction Contract,then the Surety and the Contractor shall have no obligation under this Bond. § 3 If there is no Owner Default under the Construction Contract,the Surety's obligation to the Owner under this Bond shall arise after the Owner has promptly notified the Contractor and the Surety(at the address described in Section 13)of claims,demands,liens or suits against the Owner or the Owner's property by any person or entity seeking payment for labor,materials or equipment famished for use in the performance of the Construction Contract and tendered defense of such claims,demands,liens or suits to the Contractor and the Surety. § 4 When the Owner has satisfied the conditions in Section 3,the Surety shall promptly and at the Surety's expense defend,indemnify and hold harmless the Owner against a duly tendered claim,demand,lien or suit. § 5 The Surety's obligations to a Claimant under this Bond shall arise after the following: § 5.1 Claimants,who do not have a direct contract with the Contractor, .1 have furnished a written notice of non-payment to the Contractor,stating with substantial accuracy the amount claimed and the name of the party to whom the materials were,or equipment was,furnished or supplied or for whom the labor was done or performed,within ninety(90)days after having last performed labor or last furnished materials or equipment included in the Claim;and .2 have sent a Claim to the Surety(at the address described in Section 13). § 5.2 Claimants,who are employed by or have a direct contract with the Contractor,have sent a Claim to the Surety(at the address described in Section 13). § 6 If a notice of non-payment required by Section 5.1.1 is given by the Owner to the Contractor,that is sufficient to satisfy a Claimant's obligation to furnish a written notice of non-payment under Section 5.1.1. § 7 When a Claimant has satisfied the conditions of Sections 5.1 or 5.2,whichever is applicable,the Surety shall promptly and at the Surety's expense take the following actions: § 7.1 Send an answer to the Claimant,with a copy to the Owner,within sixty(60)days after receipt of the Claim, stating the amounts that are undisputed and the basis for challenging any amounts that are disputed;and § 7.2 Pay or arrange for payment of any undisputed amounts. § 7.3 The Surety's failure to discharge its obligations under Section 7.1 or Section 7.2 shall not be deemed to constitute a waiver of defenses the Surety or Contractor may have or acquire as to a Claim,except as to undisputed amounts for which the Surety and Claimant have reached agreement,If,however,the Surety fails to discharge its obligations under Section 7.1 or Section 7.2,the Surety shall indemnify the Claimant for the reasonable attorney's fees the Claimant incurs thereafter to recover any sums found to be due and owing to the Claimant. § 8 The Surety's total obligation shall not exceed the amount of this Bond,plus the amount of reasonable attorney's fees provided under Section 7.3,and the amount of this Bond shall be credited for any payments made in good faith by the Surety. § 9 Amounts owed by the Owner to the Contractor undo the Construction Contract shall be used for the performance of the Construction Contract and to satisfy claims,if any,under any construction performance bond.By the Contractor furnishing and the Owner accepting this Bond,they agree that all funds earned by the Contractor in the performance of the Construction Contract are dedicated to satisfy obligations of the Contractor and Surety under this Bond,subject to the Owner's priority to use the funds for the completion of the work. Inft. AIA Document A312"'-2010 Payment Bond.The American Institute of Architects.All rights reserved. ARNIN G This�9 s' ocu mrant is p tecM b US Copywight Law and International Treaties Unauthorixed reproduction or distribuVon of this MAs Document,or:turfy portion of it,may reran in 2 severe 60 and,.irlar inm pensftie3s,and will be prosecuted to the.9rsas6murn extent pnssibW vender the law This document was produced by AIA software at 11:43:03 on 10/09/2012 under Order No.5820952305_1 which e:Vlres on 04/13/2013,and is not for resale. User Notes: (1718896249) § 10 The Surety shall not be liable to the Owner,Claimants or others for obligations of the Contractor that are unrelated to the Construction Contract.The Owner shall not be liable for the payment of any costs or expenses of any Claimant under this Bond,and shall have under this Bond no obligation to make payments to,or give notice on behalf of,Claimants or otherwise have any obligations to Claimants under this Bond. § 11 The Surety hereby waives notice of any change,including changes of time,to the Construction Contract or to related subcontracts,purchase orders and other obligations. § 12 No suit or action shall be commenced by a Claimant under this Bond other than in a court of competent jurisdiction in the state in which the project that is the subject of the Construction Contract is located or after the expiration of one year from the date(1)on which the Claimant sent a Claim to the Surety pursuant to Section 5.1.2 or 5.2,or(2)on which the last labor or service was performed by anyone or the last materials or equipment were famished by anyone under the Construction Contract,whichever of(1)or(2)first occurs.If the provisions of this Paragraph are void or prohibited by law,the minimum period of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable. § 13 Notice and Claims to the Surety,the Owner or the Contractor shall be mailed or delivered to the address shown on the page on which their signature appears.Actual receipt of notice or Claims,however accomplished,shall be sufficient compliance as of the date received. § 14 When this Bond has been furnished to comply with a statutory or other legal requirement in the location where the construction was to be performed,any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefrom and provisions conforming to such statutory or other legal requirement shall be deemed incorporated herein.When so furnished,the intent is that this Bond shall be construed as a statutory bond and not as a common law bond. § 15 Upon request by any person or entity appearing to be a potential beneficiary of this Bond,the Contractor and Owner shall promptly furnish a copy of this Bond or shall permit a copy to be made. § 16 Definitions § 16.1 Claim.A written statement by the Claimant including at a minimum: .1 the name of the Claimant; .2 the name of the person for whom the labor was done,or materials or equipment furnished; .3 a copy of the agreement or purchase order pursuant to which labor,materials or equipment was furnished for use in the performance of the Construction Contract; .4 a brief description of the labor,materials or equipment furnished; .5 the date on which the Claimant last performed labor or last furnished materials or equipment for use in the performance of the Construction Contract; .6 the total amount earned by the Claimant for labor,materials or equipment famished as of the date of the Claim; .7 the total amount of previous payments received by the Claimant;and .8 the total amount due and unpaid to the Claimant for labor,materials or equipment furnished as of the date of the Claim. § 16.2 Claimant An individual or entity having a direct contract with the Contractor or with a subcontractor of the Contractor to furnish labor,materials or equipment for use in the performance of the Construction Contract.The term Claimant also includes any individual or entity that has rightfully asserted a claim under an applicable mechanic's lien or similar statute against the real property upon which the Project is located.The intent of this Bond shall be to include without limitation in the terms"labor,materials or equipment"that part of water,gas,power,light,heat,oil,gasoline, telephone service or rental equipment used in the Construction Contract,architectural and engineering services required for performance of the work of the Contractor and the Contractor's subcontractors,and all other items for which a mechanic's lien may be asserted in the jurisdiction where the labor,materials or equipment were furnished. § 16.3 Construction Contract The agreement between the Owner and Contractor identified on the cover page, including all Contract Documents and all changes made to the agreement and the Contract Documents. AIA 0*cument A312""—2010 Payment Bond.The American Institute of Architects.AD rights reserved.b Ait RM This M. Document is ti oter:ted by Ink. U.9,Copyright Law and international Treaties,Unauuthodiz d reproduction w.dNtdbrutlon of this A 0 Docaument,or any porMan of Gt,may nes u t do sevoro c1vH and crier 4tol penalties and will be prosecuted to the maximum extent possiRde tinder Who Mw This document was produced by AIA software at 11:43:03 on 10/09/2012 under Order No.5820952305 1 which expires on 04/13/2013,and is not for resale. User Notes: (1718898249) § 16.4 Owner Default Failure of the Owner,which has not been remedied or waived,to pay the Contractor as required under the Construction Contract or to perform and complete or comply with the other material terms of the Construction Contract. § 16.5 Contract Documents.All the documents that comprise the agreement between the Owner and Contractor. § 17 If this Bond is issued for an agreement between a Contractor and subcontractor,the term Contractor in this Bond shall be deemed to be Subcontractor and the term Owner shall be deemed to be Contractor. § 16 Modifications to this bond are as follows: None (Space is provided below for additional signatures of added parries, other than those appeming on the cover page.) CONTRACTOR AS PRINCIPAL SURETY Company: (Corporate Seal) Company: (Corporate Seal) Signature: ---N/A Signature: N/A Name and Title: Name and Title: Address: Address: AIA Document A312* —2010 Payment Bond.The American Institute of Architects.AU rights reserved.WARNMG This AIA`>lust urnent Is protected by Ink. US CopyrIght Low and lnternatssnxd TovrsUes Unauthorized reproduction raa distribu lcn of thft A10 Document,or any portion of u,may result in 4 severe c 19 a nd aarl;rtmM penauft§ss.and will be prosecuted to-he easz�Mmurn extent possible under Haas law.This document was produced by AIA software at / 11:43:03 on 10/09/2012 under Order No.5820952305_l which stores on 04/13/2013,and Is not for resale. User Notes: (1718898249) CORPORATE ACKNOWLEDGMENT STATE OF FLORIDA COUNTY OF LEE On this this 15th day of September, 2021. Before me personally came Douglas R. Masch II to me known, who being by me duly sworn, did depose and say he is the President of DEC Contracting Group, Inc. the corporation described in and which executed the above instrument; that he knows the seal of said corporation; that the seal affixed to said instrument is such corporate seal; that it was so affixed by the Board of Directors of said corporation and that he signed his name thereto by like order. Notary lAublic Signature p��Y�Ueli REGINA L.DUNN Commission#HH 030505 a ce Expires August 29,2024 Bondad Thm Buds*Notary Sa vim Key West International Airport Noise Insulation Program Construction of KWBTS Building A— Phase 2 UR ACKIW W� 16 DENT STATE OF New Jersey COUNTY OF Union On this this 151h day of September, 2021. Before me personally came Sandra A. Pace to me known, who being by me duly sworn, did depose and say he/she is the Attorney-in-Fact of The Ohio Casualty Insurance Company described in and which executed the within instrument; that he/she knows the corporate seal of said corporation; that the seal affixed to the within instrument is such corporate seal; that he/she signed the said instrument and affixed the said seal as Attorney-in- Fact by authority of the Board of Directors of said corporation and by authority of this office under the Standing Resolutions hereof.. Notaryu lic Signature LISA BRIEL Commission#50119811 Notary Public, State of New Jersey My Commission Expires commission 10,2025 This Power of Attorney limits the acts of those named herein,and they have no authority to bind the Company except in the manner and to the extent herein stated. Liberty Liberty Mutual Insurance Company The Ohio Casualty Insurance Company Certificate No: 8203825-969516 ®SURETYWest American Insurance Company POWER OF ATTORNEY KNOWN ALL PERSONS BY THESE PRESENTS:That The Ohio Casualty Insurance Company is a corporation duly organized under the laws of the State of New Hampshire,that Liberty Mutual Insurance Company is a corporation duly organized under the laws of the State of Massachusetts,and West American Insurance Company is a corporation duly organized under the laws of the State of Indiana(herein collectively called the"Companies"),pursuant to and by authority herein set forth,does hereby name,constitute and appoint, Marc J. Michalewsk ;Sandra A.Pace;Ch 1 R.Coleman;M22 J.D'Amato;_Rachael Hurle_;Thomas M.True all of the city of Westfield state of NJ each individually if there be more than one named,its true and lawful attomey-in-fact to make, execute,seal,acknowledge and deliver,for and on its behalf as surety and as its act and deed,any and all undertakings,bonds,recognizances and other surety obligations,in pursuance of these presents and shall be as binding upon the Companies as if they have been duly signed by the president and attested by the secretary of the Companies in their own proper persons. IN WITNESS WHEREOF,this Power of Attorney has been subscribed by an authorized officer or official of the Companies and the corporate seals of the Companies have been affixed thereto this 2nd day of June 2020 . Liberty Mutual Insurance Company Py\Nsu tY INBV %"So The Ohio Casualty Insurance Company �P O'it.-�� West American Insurance Company vi V, 1912�+ c 8 1919 1991 c /� d Yd��+,cNueb' L yo `h,tab� leca aDIANr a� , 5 c J'9n * * �Ml * �� M ,► * By: m David M.Carey,Assistant Secretary t`o State of PENNSYLVANIA ss c County of MONTGOMERY to c o (D On this 2nd day of June 2020 before me personally appeared David M.Carey,who acknowledged himself to be the Assistant Secretary of Liberty Mutual Insurance_0 ` cc Company,The Ohio Casualty Company,and West American Insurance Company,and that he,as such,being authorized so to do,execute the foregoing instrument for the purposes—N therein contained by signing on behalf of the corporations by himself as a duly authorized officer. E — o IN WITNESS WHEREOF,I have hereunto subscribed my name and affixed my notarial seal at King of Prussia,Pennsylvania,on the day and year first above written. ECL tp N " 0�? O COMMONWEALTH OF PENNSYLVANIA Q 60 Notarial Seal O C 0 N OF �`' Teresa Pastella,Notary Public0 t0 Cupper MarionTwp.,Montgomery County By: N La E My Commisalon E*res March 28,2021 3 y w m erase Pastella,Notary Public C cc �rn r t Member,Penrnywante Association of Notaries d O lt1 N o a3 This Power of Attorney is made and executed pursuant to and by authority of the following By-laws and Authorizations of The Ohio Casualty Insurance Company, Liberty Mutual o c Insurance Company,and West American Insurance Company which resolutions are now in full force and effect reading as follows: o t L-46 ARTICLE IV—OFFICERS:Section 12.Power of Attorney. -erj 4 Any officer or other official of the Corporation authorized for that purpose in writing by the Chairman or the President,and subject to such limitation as the Chairman or the'a a President may prescribe,shall appoint such attomeys-in-fact,as may be necessary to act in behalf of the Corporation to make,execute,seal,acknowledge and deliver as surety 5 c j C any and all undertakings,bonds,recognizances and other surety obligations.Such attomeys-in-fact,subject to the limitations set forth in their respective powers of attorney,shall o I= have full power to bind the Corporation by their signature and execution of any such instruments and to attach thereto the seal of the Corporation. When so executed,such €N Z v instruments shall be as binding as if signed by the President and attested to by the Secretary.Any power or authority granted to any representative or attomey-in-fact under the,c provisions of this article may be revoked at any time by the Board,the Chairman,the President or by the officer or officers granting such power or authority. ARTICLE XIII—Execution of Contracts:Section 5.Surety Bonds and Undertakings. Any officer of the Company authorized for that purpose in writing by the chairman or the president,and subject to such limitations as the chairman or the president may prescribe, shall appoint such attomeys-in-fact,as may be necessary to act in behalf of the Company to make,execute,seal,acknowledge and deliver as surety any and all undertakings, bonds,recognizances and other surety obligations.Such attomeys-in-fact subject to the limitations set forth in their respective powers of attorney,shall have full power to bind the Company by their signature and execution of any such instruments and to attach thereto the seal of the Company.When so executed such instruments shall be as binding as if signed by the president and attested by the secretary. Certificate of Designation—The President of the Company,acting pursuant to the Bylaws of the Company,authorizes David M.Carey,Assistant Secretary to appoint such attomeys-in- fact as may be necessary to act on behalf of the Company to make,execute,seal,acknowledge and deliver as surety any and all undertakings,bonds,recognizances and other surety obligations. Authorization—By unanimous consent of the Company's Board of Directors,the Company consents that facsimile or mechanically reproduced signature of any assistant secretary of the Company,wherever appearing upon a certified copy of any power of attorney issued by the Company in connection with surety bonds,shall be valid and binding upon the Company with the same force and effect as though manually affixed. I,Renee C.Llewellyn,the undersigned,Assistant Secretary,The Ohio Casualty Insurance Company,Liberty Mutual Insurance Company,and West American Insurance Company do hereby certify that the original power of attorney of which the foregoing is a full,true and correct copy of the Power of Attorney executed by said Companies,is in full force and effect and has not been revoked. IN TESTIMONY WHEREOF,I have hereunto set my hand and affixed the seals of said Companies this 15th day of September , 2021 PV INBU �SY INgv �iiifllso Olt P�"� a'rso°ta $ 1912 c181 c a 1991 ,e 01A. se By Renee C.Llewellyn,Assistant Secretary LMS-12873 LMIC OCIC WAIL Multi Co 12/19 ® THE OHIO CASUALTY INSURANCE COMPANY SURETY FINANCIAL STATEMENT—DECEMBER 31,2020 Assets Liabilities Cash and Bank Deposits......................................... $1,50,376,256 Unearned Premiums................................................$1,351,793,120 *Bonds—U.S Government..................................... 637,339,036 Reserve for Claims and Claims Expense................. 3,820,674,665 *Other Bonds............................................................ 4,501,743,412 Funds Held Under Reinsurance Treaties................. 0 Reserve for Dividends to Policyholders.................. 190,835 *Stocks..................................................................... 231,503,116 Additional Statutory Reserve.................................. 0 Real Estate.............................................................. 0 Reserve for Commissions,Taxes and Agents'Balances or Uncollected Premiums........... 774,786,642 Other Liabilities................................................ 407,364,363 Accrued Interest and Rents..................................... 33,410,287 Total.................................................................$5,580,022,983 Other Admitted Assets............................................ 1,390,387,941 Special Surplus Funds................. $ 28,504,816 Capital Stock............................... 4,500,000 Paid in Surplus............................ 738,183,897 Unassigned Surplus..................... 1,368,334,994 Total Admitted Assets..................................... S7.719.546.690 Surplus to Policyholders................................ 2,139,523,707 Total Liabilities and Surplus................................S7.719.546.690 �11 INS�� * Bonds are stated at amortized or investment value;Stocks at Association Market Values. c1919 The foregoing financial infonnation is taken from The Ohio Casualty Insurance Company's financial statement filed with the state of Ohio Department of Insurance. t I,TIM MIKOLAJEWSKI,Assistant Secretary of The Ohio Casualty Insurance Company,do hereby certify that the foregoing is a true,and correct statement of the Assets and Liabilities of said Corporation,as of December 31,2020,to the best of my knowledge and belief. IN WITNESS WHEREOF, I have hereunto set my hand and affixed the seal of said Corporation at Seattle, Washington,this 25°i day of March,2021. Assistant Secretary S-12620cIGa 3121 0 DATE(MM/DD/YYYY) A - CERTIFICATE OF LIABILITY INSURANCE 8i27i2021 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER,AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED,the policy(ies)must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER CONTACT NAME: Certificate Department Five County Insurance Agency Inc PHONE FAX 14120 Metropolis Ave A/C No Ext: 239 939-1400 A/c No:239 939 3813 Fort Myers FL 33912 ADODRESS: certs@fivecountyinsurance.com INSURER(S)AFFORDING COVERAGE NAIC# INSURERA:American Builders Insurance 11240 INSURED DECCO-1 INSURER B: National Builders Insurance 16632 DEC Contracting Group Inc 1560 Matthew Dr Unit B INsuRERc: Old Dominion Insurance 40231 Fort Myers FL 33907 INSURERD: INSURER E: INSURER F: COVERAGES CERTIFICATE NUMBER:1323161879 REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES.LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR TYPE OF INSURANCE ADDL SUBR POLICY EFF POLICY EXP LIMITS LTR INSD WVD POLICY NUMBER MM/DD/YYYY MM/DD/YYYY B X COMMERCIAL GENERAL LIABILITY Y PKGO16751709 3/6/2021 3/6/2022 EACH OCCURRENCE $1,000,000 DAMAGE TO RENTED CLAIMS-MADE X OCCUR PREMISES Ea occurrence $300,000 Approved RISC Management MED EXP(Any one person) $10,000 t � PERSONAL&ADV INJURY $1,000,000 GEN'L AGGREGATE LIMIT APPLIES PER: GENERAL AGGREGATE $2,000,000 PRO- X POLICY JJ ECT 1:1LOC @0@01 PRODUCTS-COMP/OP AGG $2,000,000 OTHER: $ C AUTOMOBILE LIABILITY Y BlPO157N 5/8/2021 5/8/2022 COMBINED SINGLE LIMIT $1,000,000 Ea accident X ANY AUTO BODILY INJURY(Per person) $ OWNED SCHEDULED BODILY INJURY(Per accident) $ AUTOS ONLY AUTOS X HIRED X NON-OWNED PROPERTY DAMAGE $ AUTOS ONLY AUTOS ONLY Per accident A X UMBRELLA LIAB X OCCUR UMB018902306 3/6/2021 3/6/2022 EACH OCCURRENCE $2,000,000 EXCESS LIAB CLAIMS-MADE AGGREGATE $ DED RETENTION$ $ A WORKERS COMPENSATION WCV016799207 3/6/2021 3/6/2022 X PER OTH- AND EMPLOYERS'LIABILITY Y/N STATUTE ER ANYPROPRIETOR/PARTNER/EXECUTIVE NIA E.L.EACH ACCIDENT $1,000,000 OFFICER/MEMBER EXCLUDED? (Mandatory in NH) E.L.DISEASE-EA EMPLOYEE $1,000,000 If yes,describe under DESCRIPTION OF OPERATIONS below E.L.DISEASE-POLICY LIMIT $1,000,000 DESCRIPTION OF OPERATIONS I LOCATIONS I VEHICLES (ACORD 101,Additional Remarks Schedule,maybe attached if more space is required) PROJECT: KWBTS BLDG A Monroe County Board of County Commissioners and Key West By the Sea Association Inc are included as additional insureds with respects to General Liability and Auto Liability(as provided by the carrier'enhancement endorsements).Thirty(3)days Notice of Cancellation applies;Ten(10)days for non-payment of premium per Florida Statute. CERTIFICATE HOLDER CANCELLATION SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN MONROE COUNTY BOARD OF COUNTY ACCORDANCE WITH THE POLICY PROVISIONS. COMMISSIONERS 1100 SIMONTON ST AUTHORIZED REPRESENTATIVE KEY WEST FL 33040 ©1988-2015 ACORD CORPORATION. All rights reserved. ACORD 25(2016/03) The ACORD name and logo are registered marks of ACORD y y CROSSENV1 f l i R[J LATE(MMIDD1YY'YY) CERTIFICATE OF LIABILITY INSURANCE 3/8/2021 THIS CERTIFICATE IS ISSUED AS A (NATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW, THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING IN,SURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER,AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies)must have ADDITIONAL INSURED provisions or be endorsed,. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER CO s CT Certificate Department Commercial Lines-(813)321-7500 PHONE FAx (Arc,Na,Ext}. (813)639 3000 USI Insurance Services LLC E-MAIL clw.certre uest usi.com A€DRESS: q @ 2502 N Rocky Point Dr ......._ ........INSURER s1 AFFORDING COVERAGE ....... ......... ......._ ..... NAIC# .. Tampa, FL 33607 114SURERA. Steadfast Insurance Company 26387 INSURED INSURERS: Zurich American Insurance Co 16535 Cross Environmental Services, Inc. INSURERC: P.O. Box 1299 INSURER o INSURER E: Crystal Springs, FL 33524 INSURERF: COVERAGES CERTIFICATE NUMBER: 15312681 REVISION NUMBER: See below THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED- NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES,LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAIL?CLAIMS, INSR 'Abb sUBR... I ...POLICY EFF POLICY EXP r...... LTR. TYPE OF INSURANCES .INSLt wVD POLICY NUMBER I JM.fy1DD1YYYY) MM/DDIYYYY LINTS.. X COMMERCIAL GENERAL LIABILITY ,.,.EACH OCCURRENCE S 2,000,000 A X G P L090854302 1 03/01/2021 03/01/2022 9 DAMAGE TO RE NT'E D CLAIMS-MADE X OCCUR r PREMISES(Ea czcz,utrenn,e) 1 5 100 000 X Max Agg Per Policy$10 000 000 MED FXP(Any orse pomon) 5 10 000 BI/PD Combined l X Contractual Llab $5,000 Ded. Per Claim PERSONAL&r",D'��3NJURY S 2,000,000 GEN`L.A sGRFGNI-F I M II F AP PLIES PER ' -GENERAL AGGREGAI E $ .... 6,000,000 PRO ,approved Risk Mana enilent ( POLICY X JLCT -LOC PRODUCTSCOMP:OP AGG 5. 4,000,000 @30-20 1 01HER. I CO B AUTOMOBILE LIABILITY X BAP055127702 103/01/2021 03/01/2022 A'§SINEEI SINGLE LF IIT s 1,000,000 jEa aa.ra�fetrrll x ;ANY AUTO includes MCS 90 BODILY INJURY wnr nerson, S OWNED SCHEDULED.' i BODILY INJURY Prr ae Illpl Yl S AUTOS ONLY AUTOS X NIREs"`) X NON Oti+VNECI PROPERTY DAMAGE 5. ......... AUTOS ONLY AUTOS ONLY i r al-o le"t" s UMBRELLA LIAR X OCCUR X SXS090854202 03/01/2021 03/01/2022 EACH OCCURRENCE S s 000,000 A _, _..._.. _...._ _._._._._ _._._._ X EXCESS LIAS CLAIMS-MADE AGGRFGATF 5,000,000 DED X RETENTION.$ None. p �..-. ..... .... vc, WORKERS COMPENSATICIN--- __ 9 E'ER OTI-t B WC090854102 , 03/01/2021 03/01/2022 X s rarTE [ _'_ER ___ AND EMPLOYERS'LIABILITY YIN ' '-- ----- ----- ANYPROPR ETORIPARTNERiE.XECllTIVE E L F„CH ACCIDI-N1" $. 1,000,000 OFFICERILIEI sfg€REXCLUDED'} N N r A (Mandatory 1n NH) `—'' E I DISEASE-EA EMPLOYEE S 1,000,000 If yns,t owj be under i 1,000,000 DI SCRIPT C'N OF OPERATIONS below I �E L DISEASE-POUCY LIMIT 5 A Contractors Pollution Liab X GPL090854302 1 0310112021 03/01/2022 Occurrence Limit-$2,000000 Each Occurrence $5,000 Ded. Each Claim I DESCRIPTION OF OPERATIONS,`LOCATIONS 1 VEHICLES (ACORD 101,Additional Remarks Schedule,may be attaclied of more space is required) Certificate holder&those required by written contract are named as additional insured as it relates to general liability per form STF-ESP-1 01-F CW(04/13) when required by written contract and in accordance with the terms and conditions of the policy. CERTIFICATE HOLDER CANCELLATION Monroe County BOCC SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN 1100 Simonton St. ACCORDANCE WITH THE POLICY"PROVISIONS. Key West, FL 33040 AUTHORIZED REPRESENTATIVE The ACORD name and logo are registered marks of ACORD O 19 8-2015 ACORD CORPORATION. All rights reserved, ACORD 25(2016103) (This certificate replaces certificate#15294977 issued on 2262021)