08/21/2002 Repair Design
Clerk 01 die
Circul coun
Danny L. Kolhage
Clerk of the Circuit Court
Phone: (305) 292-3550
FAX: (305)295-3663
e-mail: phancock@monroe-clerk.com
Memnrandum
TO: Dent Pierce, Director
Public Works Division
ATTN: Beth Leto, Administrative Assistant
Public Works Division
FROM: Pamela G. Hanc~
Deputy Clerk D
DATE: September 6, 2002
At the August 21, 2002, Board of County Commissioner's meeting the Board granted
approval and authorized execution of a Contract between Monroe County and Kisinger Campo & Associates
Corp. to provide engineering services to repair the bridges on Card Sound Road.
Enclosed is a duplicate original of the above mentioned for your handling. Should you
have any questions please do not hesitate to contact this office.
Cc: County Administrator w/o document
County Attorney
Finance
File./'
REv 2: 8-02-02
CONTRACT FOR
ENGINEERING SERVICES
BETWEEN OWNER AND ENGINEER
This CONTRACT FOR ENGINEERING SERVICES BETWEEN MONROE
COUNTY AND THE ENGINEER (the "Contract") is made and entered into by Monroe
County (the "County") and KISINGER CAMPO & ASSOCIATES CORP., (the "Engineer").
The Engineering services required by this Contract are to be rendered for a project
identified as the Project, described as follows:
CARD SOUND ROAD BRIDGES REPAIR DESIGN
NOW, THEREFORE, in consideration of the mutual promises, covenants and
agreements stated herein, and for other good and valuable consideration, the sufficiency of
which is hereby acknowledged, the County and the Engineer agree:
FORM OF AGREEMENT
ARTICLE I
1.1 REPRESENTATIONS AND WARRANTIES
By executing this Contract, the Engineer makes the following express representations
and warranties to the County:
1.1.1 The Engineer is professionally qualified to act as the Engineer for the Project and is
licensed to practice Engineering by all public entities having jurisdiction over the Engineer
and the Proj ect;
1.1.2 The Engineer shall maintain all necessary licenses, permits or other authorizations
necessary to act as Engineer for the Project until the Engineer's duties hereunder have been
fully satisfied;
1
1.1.3 The Engineer has become familiar with the Project site and the local conditions under
which the Project is to be designed, constructed, and operated;
1.1.4 The Engineer shall prepare all documents required by this Contract including, but not
limited to, all contract plans and specifications, in such a manner that they shall be accurate,
coordinated and adequate for construction and shall be in conformity and comply with all
applicable law, codes and regulations. The Engineer warrants that the documents prepared as
a part of this Contract will be adequate and sufficient to accomplish the purposes of the
Proj ect;
1.1.5 The Engineer assumes full responsibility to the County for the improper acts and
omissions of its consultants or others employed or retained by the Engineer in connection with
the Project;
1.1.6 The Engineer's services shall be performed as expeditiously as is consistent with
professional skill and care and the orderly progress of the Work. The Engineer shall follow in
general the design schedule provided in Exhibit B for the performance of the Engineer's
services which may be adjusted as the Project proceeds if approved by the County, and shall
include allowances for periods of time required for the County's review, and for approval of
submission by authorities having jurisdiction over the Project. Time limits established by this
schedule and approved by the County may not be exceeded by the Engineer except for delay
caused by events not within the control of the Engineer or foreseeable by him, including
extended review time by the County or unreasonable delays by regulatory permitting agencies.
In the event the Engineer does not conform to the schedule, then the Engineer may be
assessed a charge up to one percent (1 %) of the design fee per week until the work product is
produced in an acceptable manner. The penalty shall apply only to the completion of
documents required for bidding, said date being met with the delivery of one final set to the
County. The County is the sole judge on the assessment of the charge.
ARTICLE II
SCOPE OF ENGINEER'S BASIC SERVICES
2.1 DEFINITION
2.1.1 The Engineer's Basic Services consist of those described in Paragraphs 2.2 through
2.4, and any other services identified in this Contract as part of Basic Services, and include
" .
engmeenng servIces.
2.1.2 The Design for Construction shall include, but shall not necessarily be limited to, plans
and specifications which describe all systems, elements, details, components, materials,
equipment, and other information necessary for construction. The Design for Construction
shall be accurate, coordinated and in all respects adequate for construction and shall be in
conformity, and comply, with all applicable law, codes, permits, and regulations. Products,
2
equipment and materials specified for use shall be readily available unless written
authorization to the contrary is given by the County. The Engineer shall be responsible for
designing the Project in accordance with the analyses and recommendations of the
geotechnical information furnished per Article 4.5.
2.2 DESIGN DEVELOPMENT
2.2.1 The Engineer shall review the program and construction budget furnished by the
County to ascertain the requirements of the Project and shall arrive at a mutual understanding
of such requirements with the County.
2.2.2 The Engineer shall review the bridge inspection reports, physically perform a site
review of the bridge, prioritize the bridge deficiencies and make recommendations as to the
necessary repairs. The engineer shall obtain information on the deficiencies from the FDOT
Bridge Inspection Report.
2.2.4 The Engineer shall prepare a Design Development Report for the County's approval.
The Design Development Report shall consist of written documents that establish and
describe the size and character of the proposed Repair Project as to Engineering and structural
systems, materials and such other elements as may be appropriate.
2.3 CONSTRUCTION DOCUMENTS PHASE
2.3.1 Based on the approved Design Development Documents and any further adjustments
authorized by the County in the scope or quality of the Project or in the construction budget,
the Engineer shall prepare, for approval by the County, Construction Documents consisting of
Drawings and Specifications setting forth in detail the requirements for the construction of the
project.
2.3.2 The Engineer shall provide Drawings, applicable and Technical Special Provisions for
the County's review (the Florida Department of Transportation Standard Specifications will
be incorporated by reference).
2.3.3 Upon completion of the Construction Documents Phase, the Engineer shall provide
Construction Documents for the County's approval. The Engineer shall provide the County
up to 30 sets of Construction Documents. The Engineer shall provide an estimate of
anticipated costs in accordance with the construction development phase.
2.3.4 The Engineer shall assist the County in the preparation of the necessary bidding
information for the production of bidding forms, the Conditions of Contracts, and the forms of
Agreements between the County and the Contractors by providing supporting information as
to the projects scope, bid items, and construction duration. The County Engineer shall prepare
all Bidding Forms, Conditions ofthe Contract, and Forms of Agreement.
3
2.3.5 The Engineer's construction documents (plans, specifications, etc.) will conform to all
codes and regulations of the federal government, county, state, municipalities, agencies and
state departments, in effect at the date of this Agreement, and shall be of such completion as
to be acceptable for review and ruling by said agencies when applied for. The Engineer shall
use due care in determining permit requirements and shall meet with regulatory agencies as
necessary to coordinate specific permit requirements. The Engineer shall document all
meetings and conversations with said regulatory agencies. If permits are denied for
incompleteness or for lack of following said codes or regulations, or permit requirements, then
the Engineer will conform the construction documents in such manner to receive permits upon
such plans. Work required by the Engineer to conform with documents to federal, state, city,
county, or agency specifications to allow them to be approved shall be completed at no charge
or cost to the County, unless said requirements are changed during the course ofthe project.
2.3.6 The Engineer shall file (through the County) all documents required for the approval
of governmental authorities having jurisdiction over the project. The Engineer shall file
(through the County) the necessary documents to obtain permits. The County shall be
responsible for the timely submittal of all permit application fees.
2.3.7 At intervals mutually agreeable to the County and Engineer, the Engineer shall provide
drawings and other documents which depict the current status of design for the County's
review and information. The Engineer shall provide an estimate of anticipated cost.
2.3.8 Upon completion of the Construction Documents Phase, the Engineer shall provide
drawings, technical specifications and other documents for the County's approval and
information. The Engineer shall provide an estimate of anticipated construction costs.
2.4 CONSTRUCTION DOCUMENTS PHASE REQUIREMENTS
To satisfactorily perform the Construction Documents phase requirement, the Engineer
must complete the tasks set forth in paragraphs 2.4.1 - 2.4.9.
2.4.1 Plan View - This consists of general plans and overall coordinating plans explaining
repair work, and plan enlargements for important and special areas.
2.4.2 General Elevations
2.4.3 Sections
Overall Sections - Overall bridge longitudinal and transverse "explanation" type.
Detail Sections - Full sections conveying basic configurations and proposed repair
work.
2.4.4 Details - as required. Indicate key conditions.
a. Details to adequately indicate structural system.
b. Details of major unique conditions that impact the proposed repair.
4
2.4.5 Schedules - Prepare an estimate of the Construction Time.
2.4.6 Specifications - For general specifications, FDOT Specifications will be incorporated.
Comprehensive, abbreviated methods, materials and systems descriptions in tune with the
drawings will be developed as necessary with Technical Special Provisions.
2.4.7 Estimate of Construction Cost - Estimate of anticipated cost in accordance with the
Design Development/Construction Documents.
2.4.8 Other Consultants' Design Development Sets- As appropriate to the Project.
2.4.9 Limitations - The above list of drawings represents, in general, the requirements of
the Project.
2.5 CONSTRUCTION PHASE
2.5.1 The Engineer shall review and approve or take other appropriate action upon
Contractor's Shop Drawings submittals for prefabricated elements to be placed permanently
in the structure but only for the limited purpose of checking for conformance with information
given and the design concept expressed in the Contract Documents. The Engineer's action
shall be taken with such reasonable promptness as to cause no delay in the Contractor's Work
or in construction by the County's own forces, while allowing sufficient time in the
Engineer's professional judgment to permit adequate review. In general, said review and
action shall be completed in 10 working days from receipt of a shop drawing submittal,
excluding resubmittals. Review of such submittals is not conducted for the purpose of
determining the accuracy and completeness of other details such as dimensions and quantities
or for substantiating instructions for installation or performance of equipment or systems
designed by the Contractors, all of which remain the responsibility of the Contractors to the
extent required by the Contract Documents. The Engineer's review shall not constitute
approval of safety precautions or, unless otherwise specifically stated by the Engineer, of
construction means, methods, techniques, sequences, or procedures.
2.5.2 The Engineer shall, without additional compensation, promptly correct any errors,
omissions, deficiencies, or conflicts in the work product of the Engineer or its consultants, or
both.
2.5.3 The Engineer must reimburse the County for any added costs paid by the County
during construction that were incurred as the result of any error, omission, deficiency, or
conflict in the work product of the Engineer, its consultants, or both. This added expense is
defined as the difference in cost from that which the County would have paid if the work was
included in the bid, and the actual cost presented by the Contractor. The Engineer shall not be
held responsible for additional deficiencies found due to a delay in the construction of the
project or for those hidden deficiencies that could not reasonably be determined through a
review of the FDOT Bridge Inspection Reports.
5
ARTICLE III
3.1 GENERAL
3.1.1 The services described in this Article III are not included in Basic Services. They shall
be paid for by the County as provided in this agreement as an addition to the compensation
paid for the Basic Services but only if approved by the County before commencement.
3.2 OPTIONAL ADDITIONAL SERVICES
3.2.1 Providing detailed quantity surveys or inventories of material and equipment.
3.2.2 Providing analyses of owning and operating costs.
3.2.3 Providing special inspections, surveys, or environmental studies required for approvals
of governmental authorities or others having jurisdiction over the Project. Providing surveys
and environmental studies for a DEP submerged land easement.
3.2.4 Providing detailed estimates of the construction cost (an item by item enumeration and
analysis of all the costs that go to make up the Engineer's final estimate described in
paragraph 5.1).
3.2.5 Making investigations, inventories of materials or equipment, or valuations and
detailed appraisals of existing facilities.
3.2.6 Providing any other services not otherwise included in this Agreement or not
customarily furnished in accordance with generally accepted Engineering practice.
3.2.7 Preparation of Plans for Navigation aides.
3.2.8 Provide underwater inspection services during design or construction.
3.3 CONTINGENT ADDITIONAL SERVICES
3.3.1 Making revisions in Drawings, Specifications or other documents when such revisions
are:
a. Inconsistent with approvals or instructions previously given by the County,
including revisions made necessary by adjustments in the County's
program or Project budget;
b. Required by the enactment or reVlSlon of codes, laws or regulations
subsequent to the preparation of such documents and not reasonably
anticipated; or
c. Due to changes required as a result of the County's failure to render
decisions in a timely manner.
6
3.3.2 Providing services required because of significant changes in the Project including, but
not limited to, size, quality, complexity, the County's schedule, or the method of bidding or
negotiating and contracting for construction.
3.3.3 Providing consultation concerning replacement of Work damaged by fire or other
cause during construction, and furnishing services required in connection with the
replacement of such Work.
3.3.4 Providing services in connection with public hearings.
3.3.5 Providing expert testimony on the County's behalf to assist with any judicial
proceeding concerning the Project. When requested in writing by the County, the Engineer
shall make available to the County any personnel or consultants employed or retained by the
Engineer for the purpose of reviewing, studying, analyzing or investigating any claims,
contentions, allegations, or legal actions relating to the Project.
ARTICLE IV
COUNTY'S RESPONSIBILITIES
4.1 The County shall provide full information regarding requirements for the Project,
including a program which shall set forth the County's objectives, schedule, constraints and
criteria.
4.2 The County shall establish and update an overall budget for the Project based on
consultation with the Engineer, which shall include the Construction Cost, the County's other
costs and reasonable contingencies related to all ofthese costs.
4.3 The County shall designate the County Engineer to act on the County's behalf with
respects to the Project. The County Engineer shall render decisions in a timely manner
pertaining to documents submitted by the Engineer in order to avoid unreasonable delay in the
orderly and sequential progress of the Engineer's services.
4.4 The County shall furnish surveys describing physical characteristics, legal limitations
and utility locations for the site of the Project, and a written legal description of the site. The
surveys and legal information shall include, as applicable, grades and lines of streets, alleys,
pavements, and adjoining property and structures; adjacent drainage; rights-of-way;
restrictions, easements, encroachments, zoning, deed restrictions, boundaries and contours of
the site; locations, dimensions and necessary data pertaining to existing buildings, other
improvements and trees; and information concerning available utility services and lines, both
public and private, above and below grade, including inverts and depths. All the information
on the survey shall be referenced to a Project benchmark.
7
4.5 The County shall furnish the geotechnical tests when requested by the Engineer. Such
tests may include but are not limited to test borings, test pits, determinations of soil bearing
values, percolation tests, evaluations of hazardous materials, and ground corrosion and
resistivity tests, including necessary operations for anticipating subsoil conditions, with
reports and appropriate professional recommendations.
4.6 The County shall furnish the required information and services and shall render
approvals and decisions as expeditiously as necessary for the orderly progress of the
Engineer's services.
4.7 The County shall furnish the Engineer copies of written communications.
4.8 The County's review of any documents prepared by the Engineer or its consultants
shall be solely for the purpose of determining whether such documents are generally
consistent with the County's Criteria, as, and if, modified. No review of such documents shall
relieve the Engineer of responsibility for the accuracy, adequacy, fitness, suitability or
coordination of its work product.
4.9 The County shall furnish structural, chemical, air and water pollution tests, tests for
hazardous materials, and other laboratory and environmental tests, inspections and reports
required by law or the Contract Documents.
4.10 The services, information, surveys and reports required by Paragraphs 4.5 through 4.8
shall be furnished at the County's expense, and the Engineer shall be entitled to rely upon the
accuracy and completeness thereof.
4.11 The County Engineer shall obtain bids or negotiated proposals and prepare contracts
for construction.
4.12 The County Engineer shall issue bidding documents to bidders, conduct pre-bid
conferences with prospective bidders, respond to questions from bidders, issue addenda,
review contractor material submittals, perform construction inspection tasks, and perform
construction administration duties.
ARTICLE V
CONSTRUCTION COST
5.1 Contemporaneously with the submission of the Design, the Engineer shall submit to
the County in writing its final estimate of the contractor's anticipated bid price for
constructing the Project. Once submitted, the final anticipated price estimate shall be adjusted
by the Engineer to reflect any increase or decrease in anticipated price resulting from a change
in Design.
8
5.2 The Construction Cost shall be the total estimated bid cost to the County of all
elements of the Project designed or specified by the Engineer.
5.3 The Construction Cost shall include the cost at current market rates of labor and
materials furnished by the County and equipment designed, specified, selected or specially
provided for by the Engineer, plus a reasonable allowance for the Contractor's overhead and
profit.
5.4 Construction cost does not include the compensation of the Engineer and the
Engineer's consultants, the costs ofland, rights-of-way, financing or other costs which are the
responsibility of the County.
5.5 The Engineer agrees that, should the bid for construction of the project exceed its
estimate by ten percent (10%) or more, it will redesign, redraw or rebid, at no additional cost
or expense to the Owner, until the bids are within the stated limits.
ARTICLE VI
6.1 INDEMNITY
6.1.1 The Indemnity requirements are detailed in the attached Exhibit A.
ARTICLE VII
7.1 PERSONNEL
7.1.1 The Engineer shall assign only qualified personnel to perform any service concerning
the Project. At the time of execution of this Contract, the parties anticipate that the following
named individuals will perform those functions as indicated:
Name
Function
Paul Folev
David Thompson
Douf!las Stoker
Jack Havnes
Craif! Toth
Luis Buitraf!o
Oualitv Control Enf!ineer
Pro;ect Manaf!er and Chief Enf!ineer
Structures Department Manaf!er
Senior Structures Enf!ineer
Structures Enf!ineer
Structures Enf!ineer
So long as the individuals named above remain actively employed or retained by the Engineer,
they shall perform the functions indicated next to their names.
9
ARTICLE VIII
8.1 PAYMENTS
8.1.1 For its assumption and performance of the duties, obligations and responsibilities set
forth herein, the Engineer shall be paid monthly, not to exceed the percentages shown in
Paragraph 8. 1. LA.
(A) The Engineer shall be paid for those services required by this Contract and for
estimated expenses the lump sum amount of $207.487.00 , as detailed in Exhibit B,
attached hereto;
1.
2.
3.
Design Development Phase:
Construction Documents Phase:
Construction Phase
26 percent
68 percent
6 percent
(B) For the performance of the optional additional services and contingent
additional services described in Article ill of this contract, provided same are first
authorized in writing by the County, the Engineer shall be paid hourly at the following
rates:
Ouality Control Engineer
Proi ect Manager
Senior Engineer
EngineerIDesigner
Technician
$166.90
$115.60
$108.80
$88.64
$68.80
(C) If the Engineer's duties, obligations and responsibilities are materially changed
through no fault of the Engineer after execution of this Contract, compensation due to
the Engineer shall be equitably adjusted, either upward or downward;
(D) As a condition precedent for any payment due under this Contract, the
Engineer shall submit monthly, unless otherwise agreed in writing by the County, an
invoice to the County requesting payment for services properly rendered. The
Engineer's invoice shall describe with reasonable particularity the service rendered.
The Engineer's invoice shall be accompanied by such documentation or data in
support of additional approved expenses for which payment is sought as the County
may require under Section 8.2.
Momoe County's performance and obligation to pay under this contract is contingent upon an
annual appropriation by the BOCC. Therefore, it is agreed that the Engineer will not be
obligated to perform services or incur costs which would result in the exceeding of the
County's approved appropriations.
10
8.2 REIMBURSABLE EXPENSES
8.2.1 Reimbursable expenses include additional expenses incurred by the Engineer in the
interest of the Project and at the request of the County Engineer which are associated with
optional and contingent services as described in Section ill:
a. Expense of transportation and living expenses in connection with out-of-county
travel authorized by the County, but only to the extent and in the amounts
authorized by Section 112.061, Florida Statutes;
b. Fees paid for securing approval of authorities having jurisdiction over the Project;
c. Reproductions (beyond 30 sets of Bid Documents);
d. Postage and handling of Drawings and Specifications;
e. Renderings and Models requested by the County.
f. Expense of additional insurance coverage or limits, including professional liability
insurance requested by the County in excess of $1 ,000,000.
The Engineer shall be reimbursed for the above expenses based on the actual expense incurred
with no additional markup. Said amount shall be in addition to the amount listed 8.1.1 (A).
ARTICLE IX
9.1 APPLICABLE LAW
9.1.1 This Contract is governed by the laws of the State of Florida. Venue for any litigation
arising under this Contract must be in Monroe County, Florida.
ARTICLE X
10.1 AUTHORITYSHIP OF THE PRELIMINARY DESIGN AND THE DESIGN
FOR CONSTRUCTION
10.1.1 The Drawings, Specifications and other documents prepared by the Engineer for this
Project are instruments of the Engineer's service for use solely with respect to this Project,
and the Engineer shall be deemed the author of these documents and shall retain all common
law, statutory and other reserved rights, including the copyright. The County shall be
permitted to retain copies, including reproducible copies of the Engineer's Drawings,
Specifications and other documents for information and reference in connection with the
County's use and occupancy of the Project. The Engineer's Drawings, Specifications or other
documents shall not be used by the County or others on other projects, for additions to this
Project or for completion of this Project by others, unless the Engineer is adjudged to be in
default under this Agreement, except by agreement in writing and with appropriate
compensation to the Engineer.
10.1.2 Submission or distribution of documents to meet official regulatory requirements or
for similar purposes in connection with the Project is not to be construed as publication in
derogation of the Engineer's reserved rights.
11
ARTICLE XI
11.1 SUCCESSORS AND ASSIGNS
11.1.1 The Engineer shall not assign its rights hereunder, excepting its right to payment, nor
shall it delegate any of its duties hereunder without the written consent ofthe County. Subject
to the provisions of the immediately preceding sentence, each party hereto binds itself, its
successors, assigns and legal representatives to the other and to the successors, assigns and
legal representatives of such other party.
ARTICLE XII
12.1 NO THIRD PARTY BENEFICIARIES
12.1.1 Nothing contained herein shall create any relationship, contractual or otherwise, with
or any rights in favor of, any third party.
ARTICLE XIII
13.1 INSURANCE
13.1.1 The Engineer shall obtain insurance as specified in the attached Exhibit A and
maintain the required insurance at all times this Contract is in effect. Errors and Omissions
Insurance shall also be maintained for a period of two years after final completion of the
project.
13.1.2 The coverage provided herein shall contain an endorsement providing sixty (60) days
notice to the County prior to any cancellation of said coverage. Said coverage shall be written
by an insurer acceptable to the County and shall be in a form acceptable to the County.
ARTICLE XIV
TERMINATION
14.1 Either party hereto may terminate this Contract upon giving seven (7) days' written
notice to the other in the event that such other party substantially fails to perform its material
obligations set forth herein.
12
ARTICLE XV
ENTIRE AGREEMENT
15.1 This Contract constitutes of the form of agreement (Articles I-XV), the exhibits (A and B)
that are attached and made a part of the Contract, and the documents referred to in the form of
agreement as a part of this Contract. In the event any conflict between any of those Contract
docwnents, the one imposing the greater burden on the Engineer will control.
c-.----.-_~_ IN" ~SS ~RE<?F, each party has cause~_ A~ment to be executed by its
l8~~~nzed representative this 2.'Af; day of ~ ,2002.
!~4;'-~~~(~NY L. KOLHAGE, Clerk
. "'1 ,'01\'{S~) ~
r ',I" '~.;"~". \'\~~~ ~>> ,Clerk
.., ...J!!1.~
"")'{/ Deputy Clerk
. . .-~.:.~::::.-:-""
IATES CORP.
By:
(SEAL)
Attest:
, Clerk
BOARD OF CO~." MMISSlONERS
OF MONROE CO'\tIfFLORlDA
/. i
By' j '.
. \'
By:
Title:
Date: ~rmt( z.o.:l 2-
(::)
0:::
o
C)
Ld
e::
G~
o
l..l-
o
W
---1
l..l-
--
-
w <C
(-:,1 ...J
< LA...
-;: .....: ,.:
:3'-'1-
c.? "-r
:..::~=:;
.(.;'0
_J .'-'
::n
o
c....
\..0
I
0..
LLJ
v'J
(".....,2
c:J
c.: :~
('-..j
,_.
>- ---; uJ
:~u~
<:( :~
Cl 0
13
EXHIBIT A
INSURANCE
1996 Edition
ENGINEERS ERRORS AND OMISSIONS
LIABILITY
INSURANCE REQUIREMENTS
FOR
CONTRACT
BETWEEN
MONROE COUNTY, FLORIDA
AND
KISINGER CAMPO & ASSOCIATES CORP
Recognizing that the work governed by this contract involves the furnishing of engineering
services, the Contractor shall purchase and maintain, throughout the life of the contract,
Engineers Errors and Omissions Liability Insurance which will respond to damages resulting
from any claim arising out of the performance of professional services or any error or omission
of the Contractor arising out of work governed by this contract. This insurance shall be
maintained in force for a period of two years after the date of Substantial Completion of the
Proj ect.
The minimum limits of liability shall be:
$250,000 per Claim/$500,000 Aggregate
EO!
Administration Instruction
#4709.3
1996 Edition
INSURANCE REQUIREMENTS
FOR
CONTRACT
BETWEEN
MONROE COUNTY, FLORIDA
AND
KISINGER CAMPO & ASSOCIATES CORP
Prior to the commencement of work governed by this contract, the Contractor shall obtain
General Liability Insurance. Coverage shall be maintained throughout the life of the contract and
include, as a minimum:
. Premises Operations
. Products and Completed Operations
. Blanket Contractual Liability
. Personal Injury Liability
. Expanded Definition of Property Damage
The minimum limits acceptable shall be:
$500,000 Combined Single Limit (CSL)
If split limits are provided, the minimum limits acceptable shall be:
$250,000 per Person
$500,000 per Occurrence
$ 50,000 Property Damage
An Occurrence Form policy is preferred. If coverage is provided on a Claims Made policy, its
provisions should include coverage for claims filed on or after the effective date of this contract.
In addition, the period for which claims may be reported should extend for a minimum of twelve
(12) months following the acceptance of work by the County.
The Monroe County Board of County Commissioners shall be named as Additional Insured on
all policies issued to satisfy the above requirements.
GL2
Administration Instruction
#4709.3
1996 Edition
VEHICLE LIABILITY
INSURANCE REQUIREMENTS
FOR
CONTRACT
BETWEEN
MONROE COUNTY, FLORIDA
AND
KISINGER CAMPO & ASSOCIATES CORP
Recognizing that the work governed by this contract requires the use of vehicles, the Contractor,
prior to the commencement of work, shall obtain Vehicle Liability Insurance. Coverage shall be
maintained throughout the life of the contract and include, as a minimum, liability coverage for:
. Owned, Non-Owned, and Hired Vehicles
The minimum limits acceptable shall be:
$100,000 Combined Single Limit (CSL)
If split limits are provided, the minimum limits acceptable shall be:
$ 50,000 per Person
$100,000 per Occurrence
$ 25,000 Property Damage
The Monroe County Board of County Commissioners shall be named as Additional Insured on
all policies issued to satisfy the above requirements.
VLl
Administration Instruction
#4709.3
1996 Edition
WORKERS' COMPENSATION
INSURANCE REQUIREMENTS
FOR
CONTRACT
BETWEEN
MONROE COUNTY, FLORIDA
AND
KISINGER CAMPO & ASSOCIATES CORP
Prior to the commencement of work governed by this contract, the Contractor shall obtain
Workers' Compensation Insurance with limits sufficient to respond to Florida Statute 440.
In addition, the Contractor shall obtain Employers' Liability Insurance with limits of not less
than:
$100,000 Bodily Injury by Accident
$500,000 Bodily Injury by Disease, policy limits
$100,000 Bodily Injury by Disease, each employee
Coverage shall be maintained throughout the entire term of the contract.
Coverage shall be provided by a company or companies authorized to transact business in the
state of Florida.
lfthe Contractor has been approved by the Florida's Department of Labor, as an authorized self-
insurer, the County shall recognize and honor the Contractor's status. The Contractor may be
required to submit a Letter of Authorization issued by the Department of Labor and a Certificate
of Insurance, providing details on the Contractor's Excess Insurance Program.
If the Contractor participates in a self-insurance fund, a Certificate of Insurance will be required.
In addition, the Contractor may be required to submit updated financial statements from the fund
upon request from the County.
WCl
Administration Instruction
#4709.3
1996 Edition
Indemnification and Hold Harmless
for
Construction Contractors and Subcontractors
The Contractor covenants and agrees to indemnify and hold harmless Monroe County Board of
County Commissioners from any and all claims for bodily injury (including death), personal
injury, and property damage (including property owned by Monroe County) and any other losses,
damages, and expenses (including attorney's fees) which arise out of, in connection with, or by
reason of services provided by the Contractor or any of its Subcontractor(s) in any tier,
occasioned by the negligence, errors, or other wrongful act or omission of the Contractor or its
Subcontractor(s) in any tier, their employees, or agents.
In the event the completion ofthe project (to include the work of others) is delayed or suspended
as a result of the Contractor's failure to purchase or maintain the required insurance, the
Contractor shall indemnify the County from any and all increased expenses resulting from such
delay.
The first ten dollars ($10.00) of remuneration paid to the Contractor is for the indemnification
provided for above.
The extent of liability is in no way limited to, reduced, or lessened by the insurance requirements
contained elsewhere within this agreement.
ccs
Administration Instruction
#4709.3
EXHIBIT B
SCHEDULE & FEE DETAILS
Design Schedule
Inspection and Preliminary Report
8 weeks
County Review
2 weeks
Preliminary Design Plans
14 weeks
County Review
2 weeks
Final Design Plans
16 weeks
County Review
2 weeks
Final Revisions to Plans
4 weeks
Total Design Time
48 weeks
Post Design Services, including development of specifications, assistance with bid
documents, review of shop drawings, and final inspection, will extend beyond the design
period depending on the County's schedule of construction.
PROJECT DESCRIPTION:
CARD SOUND BRIDGES REPAIR
FOR: MONROE COUNTY
ESTIMATE BY : DBT 7-30-02
MANHOUR BY TASK AND ASSOCIATED FEES
BASIS OF NO. OF
ITEM ESTI- UNITS
MATE TOTAL
DESIGN DEVELOPMENT
SITE REVIEW
REVIEW INSPECTION REPORTS (10) LS 1 26
VERIFICATION INSPECTION OF BRIDGES LS 1 48
MANHOUR SUBTOTAL 74
ASSOCIATED FEE SUBTOTAL $8,385.00
DESIGN DEVELOPMENT REPORT
GATHER DATA LS 1 8
DEVELOP ALTERNATIVE REPAIRS LS 1
REINFORCED CONCRETE LS 1 6
PILES LS 1 6
STEEL PILE TIPS LS 1 6
STRUCTURAL STEEL REPAIRS LS 1 12
PRESTRESSED BEAM REPAIRS LS 1 12
PAINTING LS 1 2
CATHODIC PROTECTION LS 1 12
MISC LS 1 8
DEVELOP COSTS FOR ALTERNATES LS 1 20
DEVELOP REPORT LS 1 42
PRELIMINARY PERMIT PRODUCTION LS 1 36
UTILITY LOCATION LS 1 8
QC REPORT LS 1 12
REPRODUCE REPORT LS 1 6
REPORT FINALIZATION LS 1 32
SELECT ALTERNATIVES WITH COUNTY ENGINEER LS 1 12
SUBTOTAL - REPORT PREPARATION 248
ASSOCIATED FEE SUBTOTAL $26,919.00
TOTAL - DESIGN DEVELOPMENT PHASE 322
ASSOCIATED FEE $35,304.00
DEVELOP PLANS
KEY SHEET PER SHEET 1 20
GENERAL NOTES PER SHEET 2 48
GENERAL PLAN AND ELEVATION (5) PER SHEET 5 130
TYPICAL SECTIONS PER SHEET 5 140
STRUCTURAL STEEL REPAIR PER SHEET 2 84
PRESTRESSED BEAM REPAIRS PER SHEET 2 84
PILE TIP REPAIR PER SHEET 1 36
PILE JACKET INSTALLATION PER SHEET 4 144
SPALL AND CRACK REPAIR - TYP DETAILS PER SHEET 2 56
PAINTING PER SHEET 2 64
DEFICIENCY TABLE PER SHEET 8 160
MISCELLANEOUS REPAIRS PER SHEET 2 84
ESTIMATE QUANTITIES AND PREPARE SHEETS PER SHEET 1 44
MANHOUR SUBTOTAL 37 1094
ASSOCIATED FEE SUBTOTAL $98,927.00
PREPARE PERMITS
PERMIT DOCUMENTATION LS 1 20
PERMIT APPLICATIONS (USCG, ACOE, SFWMD & DEP) EACH 2 72
MANHOUR SUBTOTAL 92
ASSOCIATED FEE SUBTOTAL $9,385.00
SPECXFXCATXONS AND COST ESTXMATES
PREPARE TECHNICAL SPECIFICATIONS LS 1 60
ASSIST COUNTY WITH BOILER PLATE LS 1 26
COST ESTIMATES LS 1 30
MANHOUR SUBTOTAL 116
ASSOCIATED FEE SUBTOTAL $13,008.00
SUPERVJ:SJ:ON 5% 1 85
ASSOCIATED FEE SUBTOTAL $10,647.00
TOTAL -CONSTRUCTION DOCUMENTATION PHASE 1387
ASSOCIATED FEE $131,967.00
CONSTRUCTION PHASE
SHOP DRAWING (PREFAB ELEMENTS) EA 4 40
FINAL INSPECTION LS 1 50
TOTAL - CONSTRUCTION PHASE 90
ASSOCIATED FEE $10,126.00
GRAND TOTAL 1799
ASSOCIATED FEE TOTAL $177,397.00
N
o
~
o
..,
~
....
o
0 0 0 0
0 0 0 0
H 0 0 0 0
<( '" 00 ... "'.0 .... .... '" '" ....
E-< N ... .... oo~ 00 '" .... 00 '" 0 0 0 N '" '"
0 0 00 ... .., '" ... '" '" ... .... ..,
E-< ';~ 0 '" ... - ... .:
00 - .; ... 0
.., .., ....
'" ... ... ... ... ...
... ... ... ... ...
~ H :i! , 0
... 0
CO E'i HO ~b 00 00
... Uoo 0
Q E-< ~.,; 0 0 0 '" ... 0 '" 0
H 0 0 '" 0 0 ... 00
p: ~ 0 '" 0 0 '" ..,
... U'" ... 0 0 -
.c fiI ... ... ...; ... N
110 '" E-< ... ...
tl ,,; ... ...
fiI
CO '" ,,;
... t1)_~..., ... 00 N
8 0 N ": ...
!3ci~~ 0 0 0
... ~~i~ 0 00 0 N '" 0 ~ 00 ...
p: 0 ... .., .., '" ...
III ... ... 0 00 0 ...
...; ... - ... .n
~ N
... ... ...
fiI
:>
~ H 0 0 0 0
E-<,,; 0 0 0 00 N
<o~oo co 00
~i~~ '" ... 0 N 0 '" ... ... '" N ... '"
co ... N ... '" .0 N 0 '" 00 00 00 ..,
.., " '" .., 0 N '" '" '" '"
a '" ... 0 0 0 -
U .; ,; '" ...; ,; ..,
... ... ... '"
... '" '"
,,;
fiI
~ 0 0 0 0
";0 ~ 0 00 ~
~~ '" ... ~
co ... N '" M '" ... N '" .... '"
N M '" .0 ... '" '" 0 N N '" 00
... '" ., '" '" .... M 0 N M '" ... '"
t:>... ... '" '" -
~ ...; .; .... .n - M
... M M '"
'" ... ... '" ...
,,;
fiI 0 0
~o 0 0 ... 0 0 '"
Z H'" 00 N
00 0
0 ~ . N N '" '" 0 0 ... ...
H ~~ M Xl ... N N '"
E-< M .., ... .... '" 0 M .... M
'" ... M M '" M -
... N .; M N
H U ...; ...
,,; 0 ... ...
U ... '" ...
'"
fiI
Q
E-< r>.",
U OE-<
fiI .H ... ... ......
t:> ~~ ...
~
'"
r>.
0 'fi1
",HE-< '" '"
ti:1i;::i H H .. r:l '"
<(fi1 '" H
o:l
3: r-
J ZW W ~
W t oU) U) 0
:; -< < m
W ) 1-:1: :I:
a: 00. a. <
W Q ::::lz Z do
l- ) a:o 0 ..J
Ui ') tii= ti <
I-
0 z< 0
..J O!z ::::l I-
< a:
I- 9w I- 0
0 ..J:!: U) z
I- <::::l Z <
'" m 1-0 0 a:
fiI ::::l 00 0 ~
8 U) 1-0 0
t5 - H ..J
0 .. Ui
E-< I- ... o:l <
H - ~ I-
Z r>.
'" 0 0
W E-< t5 I-
:E .. z
0 0 H
D. '" H fiI
fiI E-<
0 ,,; U ~
-I fiI
Z '"
W 0 '" l:!
> H Z Z
.. E-< H '" 0
w 3: U - H
fiI Z E-<
~ C w '" 0 I!l U
:; '" H 15 fiI
E-< Z Z E-< i '"
W H <( H '"
U " a: U '" Z
fiI en fli H H H
t:> W r>. ~
~ H H H
W I- ~ ~ fiI '" ~
'" c Ui '" 0
p :.: H
'" '" r>.
E-<
o:l
Q
~
~
o
Pi
o
~
Pi
I
ESTIMATED EXPENSES FOR:
DESIGN DEVELOPMENT
FIELD REVIEW
BASED ON 1 DAY WITH INSPECTOR 50 AND 2 DAYS WITH BOAT
BOAT 2 DAY 1 $250.00 PER DAY
CAR RENTAL 1 CAR 3 DAYS $60.00 PER DAY
AIR FARE 2 PEOPLE 1 TRIPS $400.00 PER TRIP
MEALS 2 PEOPLE 3 DAYS $21.00 PER DAY
HOTEL 2 PEOPLE 3 DAYS $80.00 PER DAY
PHOTOS/VIDEO
$500.00
$180.00
$800.00
$126.00
$480.00
$100.00
I SUBTOTAL FOR INSPECTION
$2,186.00
REPORT PRODUCTION COST
EXISTING PLANS 100 SHEETS
XEROX 8 1/2" X 1 100 PAGES
XEROX 11 II X 17" 40 PAGES
MISC POSTAGE, PHONE, ETC
1
15
15
$4.00
$0.055
$0.15
PER SHEET
PER PAGE
PER PAGE
REDUCT
COPIES
COPIES
$400.00
$82.50
$90.00
$400.00
ISUBTOTAL FOR REPORT
$972.50
I TOTAL THIS SHEET
$3,158.50 I
ESTIMATED EXPENSES FOR:
CONSTRUCTION DOCUMENTATION PHASE
CADD DESIGN TIME =
PLANS PRODUCTION
PRELIMINARY SUBMITTAL
PLANS AND CALCULATIONS
PLOTTING 50
XEROX 8 1/2" X 1 100
XEROX 11" X 17" 100
CADD TIME 109
INTERMEDIATE SUBMITTAL
485
PAGES
PAGES
PAGES
HOURS
PLANS AND CALCULATIONS
PLOTTING 50 PAGES
XEROX 8 1/2" X 1 100 PAGES
XEROX 11" X 17" 100 PAGES
CADD TIME 109 HOURS
SPECIFICATIONS
XEROX 8 1/2" X 1 200
FINAL SUBMITTAL
PLANS AND CALCULATIONS
PLOTTING 50
XEROX 8 1/2" X 1 100
XEROX 11" X 17" 1 0 0
CADD TIME 146
SPECIFICATIONS
XEROX 8 1/2" X 1 200
MISC POSTAGE, PHONE, ETC
HRS
1
1
15
1
$6.00
COPIES $0.055
COPIES $0.15
$20.00
1
1
15
1
$6.00
COPIES $0.055
COPIES $0.15
$20.00
PAGES 15 COPIES $0.055
PAGES
PAGES
PAGES
HOURS
1 $6.00
1 COPIES $0.055
35 COPIES $0.15
1 $20.00
PAGES 35 COPIES $0.055
ISUBTOTAL FOR DESIGN
PER PAGE
PER PAGE
PER PAGE
PER HOUR
PER PAGE
PER PAGE
PER PAGE
PER HOUR
PER PAGE
PER PAGE
PER PAGE
PER PAGE
PER HOUR
PER PAGE
$300.00
$5.50
$225.00
$2,180.00
$300.00
$5.50
$225.00
$2,180.00
$165.00
$300.00
$5.50
$525.00
$2,920.00
$385.00
$600.00
$10,321. 50
ITOTAL THIS SHEET
$10,321. 50
ESTIMATED EXPENSES FOR:
SHOP DRAWING REVIEW SERVICES
SHOP DRAWING REVIEW
XEROX 8 1/2" X 1 40 PAGES 5 COPIES $0.055
XEROX 11" X 17" 20 PAGES 15 COPIES $0.15
MISC POSTAGE, PHONE, ETC
PER PAGE
PER PAGE
$11.00
$45.00
$200.00
I SUBTOTAL FOR SHOP DRAWINGS
$256.00
FINAL INSPECTION
ABOVE WATER
CAR RENTAL
AIR FARE
BOAT
MEALS
HOTEL
1
2
1
2
2
CAR 2 DAYS $60.00 PER DAY $120.00
PEOPLE 1 TRIPS $400.00 PER TRIP $800.00
DAYS 1 $250.00 PER DAY $250.00
PEOPLE 2 DAYS $21. 00 PER DAY $84.00
PEOPLE 2 DAYS $80.00 PER DAY $320.00
ISUBTOTAL FOR FINAL INSPECTION $1,574.00
ITOTAL THIS SHEET
$1,830.00
IGRANDTOTAL-EXPENSES
$15,310.00
0j/~~/~~02 15:09
I::ll~':l/l.:l/bb
~~H~VA ~~ULU~l~AL A~
t-'A~~ 11:,a I1b
ScHEDA
ECOLOGICAL
ASSOCIATES
'NCOf:lPORATED
May 7, 2002
David Thompson, P.E.
Kisinger Campo & Associates
2203 North Lois Avenue
Suite 1200
Tampa, Florida 33607
RE: SCOPE OF SERVICES AND ASSOCIATED FEE ESTIMATE
Card Sound Road Bridge Repair Design
Environmental Support Services
Monroe County, Rorida
SEA Proposal No. 1137.02
Dear Mr. Thompson:
In accordance with your recent request, I have developed a scope of servioes and
associated fee estimate for the project referenced above. Scheda Eoological Associates,
Inc. (SEA) will provide environmental permitting support for the project, which involves
preparation of plans and specifications for rehabilitation of five bridges on Card Sound
Road in Monroe County.
SEA scientists will research available data and conduct field investigations to characterize
the on-site natural communities and the potential for occurrence of Threatened or
Endangered species. SEA will provide a written report documenting the data oollection
effort and findings, including an evaluation of the permits required and/or regulatory
constraints on the proposed projects. SEA will assist KCA in preparing any necessary
permit applications and attend up to four meetings with the County, project team, and/or
agency representatives to discuss environmental aspects of the project.
SCOPE OF SERVICES
Task Descriotion"
1.0 COLLECTION OF EXISTING DATA
Prior to any field efforts, all readify available, existing data related to Federal
and State proteoted species will be collected and reviewed. This data will
~IZOO2\I 1117\Cl2OS07lener 00rIncl."'Pd
4013 t!:AST P"OWl.EI't AVENUE. TAMPA. FLcRIOA 3.1517
TEL.'81~..71.37!S!S. F'AX '.13..7"0'70
07/30/2002 15:09
8139713755
~GH~UA ~LULU~~LAL A~
rHl",;;IL... U...J' u.....
David Thompson, P.E.
May 7. 2002
Page 2 of 3
include site-specific information obtained from local authorities as necessary.
A list of protected animal and plant species \Nhich may potentially occur on the
site will be developed for use in conducting the field surveys.
2.0 FIELD DATA COLLECTION
Following the collection and analysis of available data, SEA scientists will
conduct a single field data collection effort to characterize the various natural
habitats located at the bridge locations. All habitats will be classified in
accordance with the Florida Land Use Cover, Forms and Classification System
(FLUCCS). In addition, wetlands will be classified in accordance with the U.S.
Fish and Wildlife Service's classification system.
During field data collection efforts, all observations indicating that protected
species are present in habitats within and immediately adjacent to the site will
be recorded. Observations may include both direct sightings and indirect
evidence (e.g., calls, scat, dens, tracks, burrows, nests, or other evidence).
Any observations of protected species will be recorded in a field data book,
and the approximate location will be depicted on an aerial photograph.
3.0 REPORT PREPARATION
SEA will provide a written report describing the data collection and findings.
Natural habitats and land use will be characterized, and mapped on an aerial
base. The location of any protected species or sIgns of their presence will be
approximated and depicted on an aerial photograph or site plan. In addition; ,
the report will provide a discussion of the permits required, or basis for
exemption from permitting and environm~ntal constraints.
. .
4.0 AGENCY COORDINATION
SEA scientists will conduct informal coordination with regulatory agencies to
obtain concurrence with the environmental assessment and facilitate permitting
of the project.
5.0 MEETINGS
SEA repres~ntatives will attend up to four meetings with the County, project
team, and/or regulatory agency representatives to discuss the environmental
aspects of the project.
PRoPcsAL\2IXI2I',37\Ol!Q507.........~.wpcI
~Jlj~/~~~~ Ib:~~
l:ll.:i':!(l..:l(t!t!
~~HcUA ~~U~U~~~H~ H~
rHU~ tJ""t/tJ;.J
David Thompson, P.E.
May 7, 2002
Page 3 of 3
FEE ESTIMATE
The fee estimate for the tasks listed above is detailed In Attachment A. This will be
considered a lump-sum fee estimate, which will not be exceeded without prior written
authorization from the client. This project will be billed monthly, in accordance with the
percent complete of each task. Please note that the following assumptions were used for
devel'opment of the fee estimate:
1. Field delineation of wetland boundaries or aquatic habitats will not be required.
2. The scope of the repair work will be such that the projects will be exempt from
permitting, or will qualify for a Noticed General Environmental Resource Permit from
South Florida Water Management District and a Nationwide Permit from the U.S.
Army Corps of Engineers.
3. A Coast Guatd permit will not be required.
4. Species-specific wildlife surveys will not be required.
SEA staff biologists can begin the data collection immediately upon acceptance of this
proposal. If these terms and conditions are satisfactory, please authorize the work by
signing below and returning one copy to our office within 30 days of the date first written
above. Upon receipt of such signature, this document shall constitute a binding
Agreement. I look forward to working with you on this project.
Sincerely,
Scheda Ecological Associates, Inc.
~ {J-rL-r&-~
Sandra Scheda Klaus, M.S.
President
The above terms are accepted as stated on this _ day of
,2002.
Title
Witness
1'ROPC8AL\2OJ2\11~ -*8Ct."Pd
~llj~/~~~~ Ib:~~
~~
:;;0
ill ~
<<i .J:J
o '0
l!?
!
l!?
Q.
z
lu C!)
uJ c;;
:c w
CQ Cl
:2: c::
o :a:
S ~
:;) UJ
a) C!)
~ 0
.-- cz:-
W 0 a:
wll,.l%I
LL. C
<(
o
a:
o
z
~
o
en
o
a:
~
<(
~
w
::i
:r
~
~
III
~
IS !!S
~ ~ ~ 2
I j~ ~
~~~~~
J~~j!
1::I1j':l Il.:l 188
~ a: 2: a ~18. ~ a
~ ~ >.~ i i i i la
f?~a,)iti~~aa
~~ .~
:::l;!:-.OteNUl....C\leN
~_~~cn..,~....
-I~Cl)
~~~
a:
w
-I
O:ii~
:!!!~
~~
::JiU
O:r::~a::
~~
ct?
~6
:I:
~
~
w
<
<3
o
~
-I
;j
a
9
8
w
~
w
:t:
~
cr:tii'.!!!
Q~f!
ffi~
CQ~ ~
r:: ~
~o
z
4i!1-~S!
0...~5a1
o~:r:a::
~UJ
0:0 III
0...(1)5;;
~:E
~
~
8
Iri
~
eN
8
~
U)
Pl~~~
:5
8
...
...
~
e
.S!
~ a a
'6Ti.&'j
~~e>8
_ ol!"" -
III u g
i t U,~
j ~16 ~ i
. e'e !Ii! m
Jii.i:l<~
q,~ ~ C! C!
... I IN ~ .,. II)
~~H~VA ~VULU~LVAL A~
t"'A\:lt:. ~::J/~::J
I
I~~
~~
"
i~
II~
~ij
...
~lD
j~
jo
o
. ~ C!
Ij 0
ClIUl
CQI~
~
i;
o
Iji
CCl
...
ii
o
j~
CQ "
14
i~
~
o
....
cr:
~
:5
8
~
~
i!;
~""""
CCl
(g
.....
8.8.8
~~~
N... .
.... ..
...
14M-
~ =
o !
~ !
5 ~
0... ~
:E ~
8 ..:.
w 0
If! !;
-J'l!IO~
<0-<
S~!6
F-CQt;)1-
=
~
IJ
(I)
'l5
!.
~
s
..
s
CD
cr:
;,;
e
j
Q.
E
i
~
j
!
i
I
I
OPTIONAL SERVICE RATE SUMMARY
SERVICES TO BE PROVIDED BY BOLT UNDERWATER SERVICES, INC. IF REQUIRED
UNDERWATER INSPECTION
EACH TRIP WITH 8 HOUR DAY
EACH ADDITIONAL OVERNIGHT STAY
$2,400.00 PER DAY (INCL.
ROUND TRIP TRAVEL)
$1,300.00 PER DAY
UNDERWATER INSPECTION EQUIPMENT
UNDERWATER VIDIO
35 MM CAMERA
ULTRASONIC TESTING
DIVE BOAT
JET PUMP OR AIR LIFT
$200.00 PER DAY
$60.00 PER DAY
$300.00 PER DAY
$200.00 PER DAY
$200.00 PER DAY
ATTACHED REQUIRED DOCUMENTS:
1) Public Entity Crime Statement,
2) Non-collusion Affidavit,
3) Sworn Statement under Ordinance No. 10-1990, Monroe County,
4) Drug-free Workplace Form
PUBLIC ENTITY CRIME STATEMENT
"A person or affiliate who has been placed on the convicted vendor list
following a conviction for public entity crime may not submit a bid on a
contract to provide any goods or services to a public entity, may not submit
a bid on a contract with a public entity for the construction or repair of a
public building or public work, may not submit bids on leases of real
property to public entity, may not be awarded or perform work as a
contractor, supplier, subcontractor, or consultant under a contract with any
public entity, and may not transact business with any public entity in excess
of the threshold amount provided in Section 287.017, for CATEGORY
TWO for a period of36 months from the date of being placed on the
convicted vendor list."
NON-COLLUSION AFFIDAVIT
I,
Joaauin M. Camoo. P.E.
of the city of
Tamoa. Florida
according to law on my oath, and under penalty of perjury, deposes and says that;
1) I am Chairman of the Board of Kisinaer Camoo & Associates Coro. . the bidder
making the Proposal for the project described as follows:
Card Sound Road Bridaes ReDair Desian
2) The prices in this bid have been arrived at independently without collusion,
consultation, communication or agreement for the purpose of restricting competition, as to any
matter relating to such prices with any other bidder or with any competitor;
3) Unless otherwise required by law, the prices which have been quoted in this bid have
not been knowingly disclosed by the bidder and will not knowingly be disclosed by the bidder
prior to bid opening, directly or indirectly, to any other bidder or to any competitor; and
4) No attempt has been made or will be made by the bidder to induce any other person,
partnership or corporation to submit, or not to submit, a bid for the purpose of restricting
competition;
5) The statements contained in this affidavit are true and correct, and made with full
knowledge that Monroe County relies upon the truth of the statements contained in this affidavit
in awarding contracts for said project.
COUNlY OF HILLSBOROUGH
STATE OF FLORIDA
PERSONALLY APPEARED BEFORE ME, the undersigned authority, Joaauin M. Camoo. P.E.
who, after first being sworn by me, Madae L. Miller , affixed his/heF signature in the space
/J Ie&... day of
provided above on this 'tv Auaust . 20~.
My commission expires:
~~
OMB - MCP FORM #1
SWORN STATEMENT UNDER ORDINANCE NO. 10-1990
MONROE COUNTY, FLORIDA
ETHICS CLAUSE
KISINGER CAMPO & ASSOCIATES, CORP. warrants that he/it has not employed,
retained or otherwise had act on Ris/its behalf any former County officer or employee in
violation of Section 2 of Ordinance No. 10-1990 or any County officer or employee in
violation of Section 3 of Ordinance No. 10-1990. For breach or violation of this provision
the County may, in its discretion, terminate this contract without liability and may also,
in its discretion, deduct from the contract or purchase price, or otherwise recover, the
full amount of any fee, commission, percentage, gift, or consideration paid to the former
County officer or employee.
Date: (1Al ~~2. ~1-.
STATE OF FLORIDA
COUNTY OF HILLSBOROUGH
PERSONALLY APPEARED BEFORE ME, the undersigned authority, Joaauin M. Camoo. P.E.
who, after first being sworn by me, Madae L. Miller , affixed his/flet: signature in the space
provided above on this ~L day of Auaust . 20~.
~oIS}y~
NARY PUBLIC
My commission expires:
OMB - MCP FORM #4
DRUG-FREE WORKPLACE FORM
The undersigned vendor in accordance with Florida Statute 287.087 hereby certifies that:
KISINGER CAMPO &. ASSOCIATES CORP.
(Name of Business)
1. Publish a statement notifying employees that the unlawful manufacture, distribution,
dispensing, possession, or use of a controlled substance is prohibited in the workplace and
specifying the actions that will be taken against employees for violations of such prohibition.
2. Inform employees about the dangers of drug abuse in the workplace, the business's policy of
maintaining a drug-free workplace, any available drug counseling, rehabilitation, and employee
assistance programs, and the penalties that may be imposed upon employees for drug abuse
violations.
3. Give each employee engaged in providing the commodities or contractual services that are
under bid a copy of the statement specified in subsection (1).
4. In the statement specified in subsection (1), notify the employees that, as a condition of
working on the commodities or contractual services that are under bid, the employee will abide
by the terms of the statement and will notify the employer of any conviction of, or plea of guilty
or nolo contendere to, any violation of Chapter 893 (Florida Statutes) or of any controlled
substance law of the United States or any state, for a violation occurring in the workplace no later
than five (5) days after such conviction.
5. Impose a sanction on, or require the satisfactory participation in a drug abuse assistance or
rehabilitation program if such is available in the employee's community, or any employee who is
so convicted.
6. Make a good faith effort to continue to maintain a drug-free workplace through
implementation of this section.
As the person authorized to sign the statement, I certify that this firm complies fully with the
above requirements.
, P.E., Chairman of the Board)
Date
OMB - MCP#5
CSR SB DATE (MM/DD/YY)
ACORA CERTIFICATE OF LIABILITY INSURANCE eTTFROFINFORMATON 02
TMIJ GtKIIriVN1
I PRODUCER
WALL & SHONTER INS INC ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE
PRODUCER
800 4 9TH ST NORTH HOLDER. THIS CERTIFICATE DOES NOT AMEND, EXTEND OR
ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW.
P.O. BOX 14448
ST. PETERSBURG FL 33733 INSURERS AFFORDING COVERAGE
Phon@:727-327-7070 Fax:727-328-2502
INSURER A: Travelers Insurance Companies
INSURED
Kisinger Campo & Associates INSURERB: Continental Casualty CO an
COrrppOration; INSURER C:
KCCB, Inc. and KCIS, Inc. INSURERD:
P.O. Box 25261
Tampa, FL 33622-5261 INSURERE:
COVERAGES
POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED
ABOVE FOR THE POLICY
TO WHICH
PERIOD INDICATED.
THIS CERTIFICATE MAY
NOTWITHSTANDING
BE ISSUED OR
THE
ANY
REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH
BY THE POLICIES DESCRIBED HEREIN IS SUBJECT
RESPECT
TO ALL THE TERMS,
EXCLUSIONS AND CONDITIONS
OF SUCH
MAY
PERTAIN, THE INSURANCE AFFORDED
AGGREGATE LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS.
POLICIES.
ILTR
TYPE OF INSURANCE POLICY NUMBER
DATE MM/DD/YY
09/O1/02
DATE MM/DD/YY
09/O1/03 ]FIRE
LIMITS
CE
7DAMA7GE(Any one fire)
$ 1, O O O, O O O
$ 3 0 0 , 0 0 0
GENERAL LIABILITY
P630198X4694TIA02
A
X COMMERCIAL GENERAL LIABILITY
MEDEnP(Any one person)
a 5, 000
CLAIMS MADE y. i OCCUR
PERSONAL & ADV INJURY
$ 1, 0 0 0 , 0 0 0
GENERAL AGGREGATE
$ 2, 0 0 0, 0 0 0
PRODUCTS - COMP/OP AGG
$ 2, 0 0 0, 0 0 0
GEN'L AGGREGATE LIMIT APPLIES PER:
PRO- LOC
POLICY JECT
COMBINED SINGLE LIMIT
$ 1, O O O , O O O
AUTOMOBILE LIABILITY
P810863K592ATIL02
09/01/02
09/01/03
(Ea accident)
A
X ANY AUTO
BODILY INJURY
$
ALL OWNED AUTOS
(Per person)
SCHEDULED AUTOS
K MA EM
T
BODILY INJURY
$
X HIREDAUTOS AP D
(Per accident)
PROPERTY DAMAGE
$
X NON -OWNED AUTOS BY
(Per accident)
GARAGE LIABILITY
WAIVER A
YES
AUTO ONLY - EA ACCIDENT
$
EA ACC
OTHER THAN
$
$
ANY AUTO
AUTO ONLY: AGG
09/Ol/02
09/O1/03
EACH OCCURRENCE
$ 2, 000,000
EXCESS LIABILITY
CLAIMS MADE PSMCUP863K5967TIL02
AGGREGATE
$ 2, 0 0 0, 0 0 0
A
X OCCUR
$
$
$
DEDUCTIBLE
RETENTION $
1U/03/U2
10/03/03
X TORY LIMITS ER
WORKERS COMPENSATION AND
F.MPL.OYERS' LIABILITY PACRUB863K43')A02
E.L. EACH ACCIDENT
$SU0,(JU(�
E.L. DISEASE - EA EMPLOYEE
$ 5 0 0, 0 0 0
A
I
I
E.L. DISEASE - POLICY LIMIT
1 $ 5 0 0, 0 0 0
I
I I
OTHER
B Professional Liab. AEA008231128 10/24/01 10/24/02 per Claim $2,000,000
Aggregate $5,000,000
Ins. ID #20443 $150,000 DED. PSR CLAIX OVISIONS
DESCRIPTION OF OPERATIONS/LOCATIONS/VEHICLES/EXCLUSIONS ADDED BY ENDORSEMENT/SPECIAL PR
Project: Card Sound Road Bridges Repair Design
Certificate Holder is Additional Insured with Respects to General Liability,
Automobile Liability and Excess Liability.
CERTIFICATE HOLDER I N I ADDITIONAL INSURED; INSURER LETTER: _
MONRC-2
Monroe County, Florida
Board of County Commissioners
Attn: Jo Walters, Eng. Dept.
1100 Simon Street, Room 216
Key West FL 33040
CANCELLATION
SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATIO
DATE THEREOF, THE ISSUING INSURER WILL ENDEAVOR TO MAIL _I_Q— DAYS WRITTEN
NOTICE TO THE CERTIFICATE HOLDER NAMED TO THE LEFT, BUT FAILURE TO DO SO SHALL
IMPOSE NO OBLIGATION OR LIABILITY OF ANY KIND UPON THE INSURER, ITS AGENTS OR
REPRESENTATIVES. _