Payment/Performance Bond THE PROVISIONSA T IONS OF SECTION 255.05STATUTES, INCLUDING
T NOT LIMITED TIC AND TIMELIMITATIONS IN SECTIONS255.05(2)AND 255.05
(10),ARE INCORPORATEDIN THIS BOND BY REFERENCE,
Ana No. 253628M
CT15N Confornaswith The American Institute of Architects AIA Document 312
aymenrgon
CONTRACTOR: SURETY:
agate,le al steams and address) (Naniee legal star and ri total place of birsiraess)
Air Mechanical&Service Corp, Westfield Insurance Company
ox 001 This document s important ie al
2700 Avenue of the Americas,PH:94 E®475-3715 Westfield Center, OH 44251-5001 consequences.Consultation with
Englewood, FL 34224 Mailing Address for Notices an attorney is encouraged with
respect to Its completion or
see above: : 33 -367-0101 modifleatt6n.
y singular referee to
(iVa/ale,legal siana andaddress) contractor,Surety®Owneror
other party shall be Considered
Monroe County Bayard of County Commissioners plural where applicable.
1100 Simonton Street PH : 3 5-294-4641
Key West, FL 33040
CONSTRUCTIONT T
Date. October 1 , 2022
Amount:$423,500.00 Four Hundred Twenty Three Thousand Five Hundred and 0 /1 0 Dollars
ties °pd
(Name and location)
TH Chiller Replacement, Florida Keys Marathon International Airport_ 9400 Overseas Hwv. Marathon FL 33050
Doc#2417644 Bk#3224 Pg#2441
Recorded 5/1212023 8:41 AM gage 1 of 5
BOND
teo February 22, 2023
Filed and Recorded in official Records of
jNot earlier than Construction Contract Date) MONROE COUNTY VIN NiLkDOIC,CPA,
aunt/$423,500.00 Fair Hundred Twenty Three Thousand Five munarea ana-uua7uu uouars
Modifications to thisBond: Nona: R9 See Section 15
CONTRACTOR AS PRINCIPAL SURETY
comp; ® (Corporate Semi) Company: (Corporate Segal)
Air ei" icl&Service Corp. Westfield Insurance Co piny
i 'o l
a ,
Siesta Y Signature:
BlainePs Kevin ojtoi
Name e r s Narno
and Ti e." Vice President and Title: Attorney-in-Fact
and Florida Licensed ei e i Agent
(Any additional signatures appear on the lasipage of this Payment Hand.)
(FOR INFO&VA TICN ONLY rlrrame,address and telephone)
AGENT or BROKER: OWNER'S REPRESENTATIVE:
Nielson,Wojtowicz, Neu &Associates (Architect, ngincer or of erpar )
1000 Central Avenue, Suite 200
5t. Petersburg, FL 33705
50 -955-9597
§1 The Contractor and Surety,jointly and severally,bind themselves,their heirs,executurs,administrators,successors and assigns to the Owner to
pay for labor,materials and equipment furnished for use in the performance of the Construction Contract,which is incorporated herein by reference,
subject to the following terms.
§2 If the Contractor promptly makes payment of all sums due to Claimants,and defends,indemnifies and holds harmless the Owner from claims,
demands,liens or suits by any person or entity seeking payment for labor,materials or equipment furnished for use in the performance of the
Construction Contract,then the Surety and the Contractor shall have no obligation under this Bond.
§3Ifthere is no Owner Default under the Construction Contract,the Surety's obligation to the Owner under this Bond shall arise after the Owner
has promptly notified the Contractor and the Surety(at the address described in Section 13)of claims,demands,liens or suits against the Owner or
the Owner's property by any person or entity seeking payment for labor,materials or equipment furnished for use in the performance of the
Construction Contract and tendered defense of such claims,demands,liens or suits to the Contractor and the Surety.
§4 When the Owner has satisfied the conditions in Section 3,the Surety shall promptly and at the Surety's expense defend,indemnify and hold
harmless the Owner against a duly tendered claim,demand,lien or suit.
§5 The Surety's obligations to a Claimant under this Bond shall arise after the following:
§5.1 Claimants,who do not have a direct contract with the Contractor,
.1 have fumished a written notice ofnon-payment to the Contractor,stating with substantial accuracy the amount claimed and the
name of the party to whom the materials were,or equipment was,furnished or supplied or for whom the labor was done or
performed,within ninety(90)days after having last performed labor or last furnished materials or equipment included in the Claim;
and
.2 have sent a Claim to the Surety(at the address described in Section 13).
§5.2 Claimants,who arc employed by or have a direct contract with the Contractor,have sent a Claim to the Surety(at the address described in
Section 13).
§6 If a notice of non-payment required by Section 5.1.1 is given by the Owner to the Contractor,that is sufficient to satisfy a Claimant's obligation
to furnish a written notice of non-payment under Section 5.1.1.
§7 When a Claimant has satisfied the conditions of Sections 5.1 or 5.2,whichever is applicable,the Surety shall promptly and at the Surety's
expense take the following actions:
§7.1 Send an answer to the Claimant,with a copy to the Owner,within sixty(60)days after receipt of the Claim,stating the amounts that are
undisputed and the basis for challenging any amounts that are disputed;and
§7.2 Fay or arrange for payment of any undisputed amounts.
§7.3 The Surety's failure to discharge its obligations under Section 7.1 or Section 7.2 shall not be deemed to constitute a waiver of defenses the
Surety or Contractor may have or acquire as to a Claim,except as to undisputed amounts for which the Surety and Claimant have reached agreement.
If,however,the Surety fails to discharge its obligations under Section 7.1 or Section 7.2,the Surety shall indemnify the Claimant for the reasonable
attorney's fees the Claimant incurs thereafter to recover any sums found to be due and owing to the Claimant.
§8 The Surety's total obligation shall not exceed the amount of this Bond,plus the amount of reasonable attorney's fees provided under Section 7.3.
and the amount of this Bond shall be credited for any payments made in good faith by the Surety.
§9 Amounts owed by the Owner to the Contractor under the Construction Contract shall be used for the performance of the Construction Contract
and to satisfy claims,if any,under any construction performance bond.By the Contractor furnishing and the Owner accepting this Bond,they agree
that all funds earned by the Contractor in the performance of the Construction Contract are dedicated to satisfy obligations of the Contractor and
Surety under this Bond,subject to the Owner's priority to use the funds for the completion of the work.
§10 The Surety shall not be liable to the Owner,Claimants or others for obligations of the Contractor that are unrelated to the Construction Contract.
The Owner shall not be liable for the payment of any costs or expenses of any Claimant under this Bond,and shall have under this Bond no
obligation to make payments to,or give notice on behalf o$Claimants or otherwise have any obligations to Claimants under this Bond.
§11 The Surety hereby waives notice of any change,including changes of time,to the Construction Contract or to related subcontracts,purchase
orders and other obligations.
§12 No suit or action shall be commenced by a Claimant under this Bond other than in a court of coinpetent jurisdiction in the state in which the
project that is the subject of the Construction Contract is located or after the expiration of one year from the date(1)on which the Claimant sent a
Claim to the Surety pursuant to Section 5.1.2 or 5.2,or(2)on which the last labor or service was performed by anyone or the last materials or
equipment were furnished by anyone under the Construction Contract,whichever of(1)or(2)first occurs.If the provisions of this Paragraph arc void
or prohibited by law,the minimum period of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable.
§13 Notice and Claims to the Surety,the Owner or the Contractor shall be mailed or delivered to the address shown on the page on which their
signature appears.Actual receipt ofnotice or Claims,however accomplished,shall he sufficient compliance as of the date received.
§14 When this Bond has been fumishcd to comply with a statutory or other legal requirement in the location where the construction was to be
performed,any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefrom and provisions
conforming to such statutory or other legal requirement shall be deemed incorporated herein.When so furnished,the Intent is that this Bond shall be
construed as a statutory bond and not as a common law bond.
§15 Upon request by any person or entity appearing to be a potential beneficiary of this Bond,the Contractor and Owner shall promptly furnish a
copy ofthis Bond or shall permit a copy to be made.
§16 Definitions
§16.1 Claim.A written statement by the Claimant including at a minimum;
.1 the name of the Claimant;
.2 the name of the person for whom the labor was done,or materials or equipment furnished;
.3 a copy of the agreement or purchase order pursuant'to which labor,materials or equipment was furnished for use in the
performance of the Construction Contract;
.4 a brief description of the labor,materials or equipment furnished;
.6 the date on which the Claimant last performed labor or last furnished materials or equipment for use in the performance of the
Construction Contract;
.6 the total amount earned by the Claimant for labor,materials or equipment famished as of the date of the Claim;
.7 the total amount of previous payments received by the Claimant;and
.8 the total amount due and unpaid to the Claimant for labor,materials or equipment furnished as of the date of the Claim.
§16.2 Claimant.An individual or entity having a direct contract with the Contractor or with a subcontractor of the Contractor to furnish labor,
materials or equipment for use in the performance of the Construction Contract.The term Claimant also includes any Individual or entity that has
rightfully asserted a claim under an applicable mechanic's lien or similar statute against the real property upon which the Project is located.The intent
of this Bond shall be to include without limitation In the terms`labor,materials or equipment"that part of water,gas,power,light,heat,oil,gasoline,
telephone service or rental equipment used in the Construction Contract,architectural and engineering services required for performance of the work
of the Contractor and the Contractor's subcontmetors,and all other items for which a mechanic's lien may be asserted in tho jurisdiction where the
labor,materials or equipment were furnished.
§16.3 Construction Contract.The agreement between the Omer and Contractor identified on the cover page,including all Contract Documents
and all changes made to the agreement and the Contract Documents.
§16.4 Owner Default.Failure of the Owner,which has not been remedied or waived,to pay the Contractor as required under the Construction
Contract or to perform and complete or comply with the other materiat terms of the Construction Contract.
§16.5 Contract Documents.All the documents that comprise the agreement between the Owner and Contractor.
§17 If this Bond is issued for an agreement between a Contractor and subcontractor,the term Contractor in this Bond shall be deemed to be
Subcontractor and the term Owner shall be deemed to be Contractor.
§18 Modifications to this bond are as follows:
THE PROVISIONS AND LIMITATIONS OF SECTION 255.05 FLORIDA STATUTES,INCLUDING BUT NOT LIMITED TO THE
NOTICE AND TIME LIMITATIONS IN SECTIONS 255.05(2),255.05(8)AND 255.05(10),ARE INCORPORATED IN THIS BOND
BY REFERENCE.
(Space is pYhvlded below for additional signatures of added parties,other than those appearing on the cover page.)
CONTRACTOR AS PRINCIPAL SURETY
Company: (Cotporale Seal) Company,. (Corporate Seal)
„ „
m_.
Signature: �' �' „� Signature: N/A
Name and Title: Name and Title:
Address Address
m General POWER NO. 0994782 00
Power Westfield Insurance Co.
of Attorney Westfield National Insurance Co.
CERTIFIED COPY Ohio Farmers Insurance Co.
Westfield Center, Ohio
Know All Men by These Presents, That WESTFIELD INSURANCE COMPANY, WESTFIELD NATIONAL INSURANCE COMPANY and OHIO
FARMERS INSURANCE COMPANY, corporations, hereinafter referred to individually as a "Company" and collectively as "Companies," duly
organized and existing under the laws of the State of Ohio, and having its principal office in Westfield Center, Medina County, Ohio, do by these
presents make,constitute and appoint
KEVIN WOJTOWICZ,JENNIFER STEPHENS,JOHN R. NEU,JOINTLY OR SEVERALLY
of ST PETERSBURG and State of FL its true and lawful Attorney(s)-in-Fact,with full power and authority hereby conferred in its name,
place and stead, to execute, acknowledge and deliver any and all bonds, recognizances, undertakings, or other instruments or contracts of
suretyship- - - - - - - - -- - - - - - - - - - - - - - - - - - - - - - - -- - - - - - - - - - - - - - - - - - - - - - -- - -
LIMITATION: THIS POWER OF ATTORNEY CANNOT BE USED TO EXECUTE NOTE GUARANTEE, MORTGAGE DEFICIENCY, MORTGAGE
U9TRA1 TEE,OR BANK DEPOSITORY BONDS.
and to bind any of the Companies thereby as fully and to the same extent as if such bonds were signed by the President,sealed with the corporate
seal of the applicable Company and duly attested by its Secretary, hereby ratifying and confirming all that the said Attorney(s)-in-Fact may do in
the premises, Said appointment is made under and by authority of the following resolution adopted by the Board of Directors of each of the
WESTFIELD INSURANCE COMPANY,WESTFIELD NATIONAL INSURANCE COMPANY and OHIO FARMERS INSURANCE COMPANY:
"Be It Resolved,that the President,any Senior Executive,any Secretary or any Fidelity& Surety Operations Executive or other Executive shall
be and is hereby vested with full power and authority to appoint any one or more suitable persons as Attorney(s)-in-Fact to represent and act for
and on behalf of the Company subject to the following provisions:
The Attorney-in-Fact. may be given full power and authority for and in the name of and on behalf of the Company,to execute,acknowledge and
deliver, any and all bonds, recogmzances, contracts, agreements of indemnity and other conditional or obligatory undertakings and any and all
notices and documents canceling or terminating the Company's liability thereunder, and any such instruments so executed by any such
Attorney-in-Fact shall be as binding upon the Company as if signed by the President and sealed and attested by the Corporate Secretary."
"Be it Further Resolved, that the signature of any such designated person and the seal of the Company heretofore or hereafter affixed to any
power of attorney or any certificate relating thereto by facsimile,and any power of attorney or certificate bearing facsimile signatures or facsimile
seal shall be valid and binding upon the Company with respect to any bond or undertaking to which it is attached." (Each adopted at a meeting
held on February 8,2000).
In Witness Whereof, WESTFIELD INSURANCE COMPANY, WESTFIELD NATIONAL INSURANCE COMPANY and OHIO FARMERS INSURANCE
COMPANY have caused these presents to be signed by their National Surety Leader and Senior Executive and their corporate seals to be hereto
affixed this 02nd day of JANUARY A.D., 2020 .
wnnrMu,4 NNu,. UrB,p,
Corporate ,.•`' ONA ^ •w WESTFIELD INSURANCE COMPANY
Seals �aSlln.ttf pS�,... .�lys'.,, rJ' N
Or•' • 4,N �•<' •.G a �"';�'' WESTFIELD NATIONAL INSURANCE COMPANY
Affixed �+ ••':�►= c Or' '• A': ? :ce�'�''' OHIO FARMERS INSURANCE COMPANY
= SEAL % 'LL: SEAL :m
�F _
••'•.......r'r y4 i
State of Ohio By;
County of Medina ss.: Gary W. tumper, Nations Surety Leader and
Senior Executive
On this 02nd day of JANUARY A.D., 2020 , before me personally came Gary W. Stumper to me known, who, being by me duly sworn,
did depose and say, that he resides in Hartford, CT;that he is National Surety Leader and Senior Executive of WESTFIELD INSURANCE
COMPANY,WESTFIELD NATIONAL INSURANCE COMPANY and OHIO FARMERS INSURANCE COMPANY, the companies described in and which
executed the above instrument;that he knows the seals of said Companies;that the seals affixed to said instrument are such corporate seals;that
they were so affixed by order of the Boards of Directors of said Companies;and that he signed his name thereto by like order.
Notarial M w.n ,,
INA
Seal 11
Affixed
State of Ohio David David A. Kotnik, Attorney at Law, Notary Public
County of Medina ss.: My Commission Does Not Expire(Sec. 147.03 Ohio Revised Code)
ON,�
I, Frank A. Carrino, Secretary of WESTFIELD INSURANCE COMPANY,WESTFIELD NATIONAL INSURANCE COMPANY and OHIO FARMERS
INSURANCE COMPANY, do hereby certify that the above and foregoing is a true and correct copy of a Power of Attorney, executed by said
Companies,which is still in full force and effect; and furthermore,the resolutions of the Boards of Directors, set out in the Power of Attorney are
�rtn �,ess
inu II orce an'effect.
ereof, I hav hereunto set my hand and affixed the seals of said Companies at Westfield Center, Ohio, thi „ day of
t
.,.•- ••.tip ••G., ar �['.
e, r
►- S % :�' SEAL F�:W;
, `" .' '` o: 'ter Secretary
84
''••.� ;* •.. .. • - Frank A. Carrino, Secretary
• a�� a
BPOAC2 (combined) (06-02)
Doc#2417643 Bk#3224 Pa#2437
Recorded 5l12i2023 9:41 AM Page 1 of 4
Filed and Recorded in Official Records of
Bond No. 253628M MONROE COUNTY KEVIN MADOK,CPA
...... . ......
Document A312 TM 2010
Conforms with The American institute of Architects AIA Document 312
PUBLIC CONSTRUCTION
Performance Bond
CONTRACTOR: SURETY:
(Nate,legal stadrs and address) (Name,legal status and princ4ml place of business)
Air Mechanical&Service Corp. Westfield Insurance Company
P.O. Box 5001 This document has Important legal
2700 Avenue of the Americas,PH:941-475-3715 Westfield Center, OH 44251-5001 consequences.Consultation with
Englewood, FL 34224 Mailing Address for Notices an attorney is encouraged with
respect to Its completion or
see above: PH: 330-887-0101 modification.
OWNER: Any singular reference to
(Moshe,Legal aottes and address) Contractor,Surety,Owner or
other party shall be considered
Monroe County Board of County Commissioners plural where applicable.
1100 Simonton Street PH : 305-294-4641
Key West, FL 33040
CONSTRUCTION CONTRACT
Date: October 19, 2022
Amount:S 423,500.00 Four Hundred Twenty Three Thousand Five Hundred and 00/100 Dollars
Description:
(Nate and location)
MTH Chiller Replacement, Florida Keys Marathon International Airport, 9400 Overseas Hwy, Marathon FL 33050
BOND
Date: February 22, 2023
(Not earlier than Constniction Contract Date)
Amount.S423,500.00 Four Hundred Twenty Three Thousand Five Hundred and 00/100 Dollars
Modification to this Bond: None ❑ Sce Section 16
CONTRACTOR AS PRINCIPAL SURETY
Company: t, `.� (Corporate Seal) Company: (Corporate Seal)
Air h. ecHani6af'.&Service Corp. Westfield In range CoMany
000
M 'rviq, iwMa•.
W �I
u
Suture: ' mwr 4e' "" *" Signature:
Name Blaine B y i r s Name Kevin Wojtowicz
andTide: Vice President and Title: Attorney-in-Fact
and Florida Licensed Resident Agent
(4ny additional signatutres appear on the last page of this Perfor►uance Bond,)
(FOR INF0RkM770N0NLY—Name,address and telephone)
AGENT or BROKER: OWNER'S REPRESENTATIVE:
Nielson, Wojtowicz, Neu &Associates (Arcdleci,Engineer orotherpar&.)
1000 Central Avenue, Suite 200
St. Petersburg, FL 33705
800-965-9597
§1 The Contractor and Surety,jointly and severally,bind themselves,their heirs,executors,administrators,successors and.assigns to the Owner for
the performance of the Construction Contract,which is incorporated herein by reference.
§2 If the Contractor performs the Construction Contract,the Surety and the Contractor shall have no obligation under this Bond,except when
applicable to participate in a conference as provided in Section 3.
§3 if there is no Owner Default under the Construction Contract,the Surety's obligation under this Bond shall arise after
.1 the Owner first provides notice to the Contractor and the Surey that.the Owner is considering declaring a Contractor Default.Such
notice shall indicate whether the Owner is requesting a conference among the Owner,Contractor and Surety to discuss the
Contractor's performance.If the Owner does not request a conference,the Surety may,within five(5)business days after receipt of
the Ownees notice,request such a conference.If the Surety timely requests a conference,the Owner shall attend.Unless the Owner
agrees otherwise,any conference requested under this Section 3.1 shall be held within ten(I0)business days of the Surety's receipt
of the Owner's notice.If the Owner,the Contractor and the Surety agree,the Contractor shall be allowed a reasonable time to
perform the Construction Contract,but such an agreement shall not waive the Owner's right,if any,subsequently to declare a
Contractor Default;
.2 the Owner declares a Contractor Default,terminates the Construction Contract and notifies the Surety,and
.3 the Owvner has agreed to pay the Valance of the Contract Price in accordance with the terms of the Construction Contract to the
Surety or to a contractor selected to perform the Construction Contract.
§4 Failure on the part of the Owner to comply with the notice requirement in Section 3.1 shall not constitute a failure to comply with a condition
precedent to the Surety's obligations,or release the Surety from its obligations,except to the extent the Surety demonstrates actual prejudice.
§5 When the Owner has satisfied the conditions of Section 3,the Surety shall promptly and at the Surety's expense take one of the following actions:
§6.1 Arrange for the Contractor,with the consent of the Owner,to perform and complete the Construction Contract,
§6.2 Undertake to perform and complete the Construction Contract itself;through its agents or independent contractors;
§6.3 Obtain bids or negotiated proposals from qualified contractors acceptable to the Owner for a contract for performance and completion of the
Construction Contract,arrange for a contract to be prepared for execution by the Owner and a contractor selected with the Owner's concurrence,to be
secured with performance and payment bonds executed by a qualified surety equivalent to the bonds issued on the Construction Contract,and pay to
the Owner the amount of damages as described in Section 7 in excess of the Balance of the Contract Price incurred by the Owner as a result of the
Contractor Default;or
§6.4 Waive its right to perform and complete,arrange for completion,or obtain a new contractor and with reasonable promptness under the
circumstances:
.1 After investigation,determine the amount for which it may be liable to the Owner and,as soon as practicable after the amount is
determined,wake payment to the Owner;or
.2 Deny liability in whole or in part and notify the Owner,citing the reasons for denial.
§6 If the Surety does not proceed as provided in Section 5 with reasonable promptness,the Surety shall be deemed to be in default on this Bond
seven days after receipt of an additional written notice from the Owner to the Surety domarmding that the Surety perform its obligations under this
Bond,and the Owner shall be entitled to enforce any remedy available to the Owner.If the Surety proceeds as provided in Section 5A,and the
Owner refute the payment or the Surety has denied liability,in whole or in part,without further notice the Owner shall be entitled to enforce any
remedy available to the Owner.
§7 If the Surety elects to not under Section 5.1,5.2 or 5.3,then the responsibilities of the Surety to the Owner shall not be greater than those of the
Contractor under the Construction Contract,and the responsibilities of the Owner to the Surety shall not be greater than those of the Owner under the
Construction Contract.Subject to the commitment by the Owner to pay the Balance of the Contract Price,the Surety is obligated,without
duplication,for
.1 the responsibilities of the Contractor for correction of defective work and completion of the.Construction Contract;
.2 additional legal,design professional and delay costs resulting from the Contractor's Default,and resulting from the actions or
failure to act of die Surety under Section 5;and
.3 -liquidated damages,or If no liquidated damages are specified in the Construction Contract,actual damages caused by delayed.
performance or non-performance of the Contractor.
§8If the Surety elects to act under Section 5.1,5.3 or 5.4,the Surety's liability is limited to the amount of this Bond.
§9 The Surety shall not be liable to the Owner or others for obligations of the Contractor that arc unrelated to the Construction Contract,and the
Balance of the Contract Price shall not be reduced or set off on account of any such unrelated obligations.No right of action shall accrue on this
Bond to any person or entity other than the Owner or its heirs,executors,administrators,successors and assigns.
§10 The Surety hereby waives notice of any change,including changes of time,to the Construction Contract or to related subcontracts,purchase
orders and other obligations.
§11 Any proceeding,legal or equitable,under this Bond may be instituted in any court of competent jurisdiction in the location in which the work or
part of the work is located and shall be instituted within two years after a declaration of Contractor Default or within two years after the Contractor
ceased working or within two years after the Surety refuses or fails to perform its obligations under this Bond,whichever occurs first.Tf the
provisions of this Paragraph are void or prohibited by law,the minimum period of limitation available to sureties as a defense in the jurisdiction of
the suit shall be applicable.
§12 Notice to the Surety,the Owner or the Contractor shall be mailed or dclivcred to the address shown on the page on which their signature
appears.
§13 When this Bond has been fitmished to comply with a statutory or other legal requirement in the location where the construction was to be
performed,any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefrom and provisions
conforming to such statutory or other legal requirement shall be deemed incorporated herein.When so furnished,the intent is that this Bond shall be
construed as a statutory bond and not as a common law'bond.
§14 Definitions
§14.1 Balance of the Contract Price.The total amount payable by the Owner to the Contractor under the Construction Contract after all proper
adjustments have been made,including allowance to the Contractor of any amounts received or to be received by the Owner in settlement of
insurance or other claims for damages to which the Contractor is entitled,reduced by all valid and proper payments made to or on behalf of the
Contractor under the Construction Contract.
§14.2 Construction Contract.The agreement between the Owner and Contractor identified on the cover page,including all Contract Documents
and changes made to the agreement and the Contract Documents.
§14.3 Contractor Default.Failure of the Contractor,which has not been remedied or waived,to perform or otherwise to comply with a material
term of the Construction Contract.
§14.4 Owner Default.Failure of the Owner,which has not been remedied or waived,to pay the Contractor as required under the Construction
Contract or to perform and complete or comply with the other material terms of the Construction Contract.
§14.6 Contract Documents.All the documents that comprise the agreement between the Owner and Contractor.
§15 if this Bond is issued for an agreement between a Contractor and subcontractor,the term Contractor in this Bond shall be deemed to be
Subcontractor and the term Owner shall be deemed to be Contractor.
§16 Modifications to this bond are as follows:
(Space is ptovfded belmv for additional signatures of added parties,other than those appearing on the cover page.)
CONTRACTOR AS PRINCIPAL. SURETY
company: (Corporate Seal) Company: (Corporate Seal)
Signature: � ,.�...._ Signature: N/A
Name and Title: Name and Title:
Address Address