Loading...
Performance/Payment Bond Doc#2430551 Bk#3240 Pg#2422 Recorded 813112023 2:02 PM Page I of 4 Bond No.2346020 Executed in 5 Counterparts Filed and Recorded in Official Records of Performance Bond MONROE COUNTY KEVIN MI ADOK,CPA CONTRACTOR: SURETY: (1Tarne,legal status and address) (1\Tame,legal stalus and principal place of Gu_riness) Aqua Waste Repairs,Inc. Swiss Re Corporate Solutions America Insurance Corporation 3575 Sneed Road Ft.Pierce,FL 34945 772-461-6228 1200 Main Street,Suite 800 OWNER: Kansas City,MO 64105-2478 816-235-3700 (Name,legal status and addmss) This document has important Board of County Commissioners of Monroe County,Florida legal consequences.Consultation 1100 Simonton Street The Gato Building,Room 2-205 with an attorney is encouraged Key West,FL 33040, 305-453-8787 with respect to its completion or modification. CONSTRUCTION CONTRACT Any singular reference to Date: July 19,2023 Contractor,Surety,Owner or other party shall be considered Amount: $299,000.00 plural where applicable. This document combines two Description: Gravity Flow Injection Well Water Quality Improvement Project, separate bonds,a Performance (Tame and location)Canal#58 Key largo,Monroe County,FL Bond and a Payment Bond,into one form.This is not a single combined Performance and BOND Payment Bond. Date: August 25,2023 (1\Tot earlier than Construction Contract Date) Amount: $299,000.00 Modifications to this Bond: None X;See Section 16 CONTRACTOR AS PRINCIPAL SURETY Company: (Corponae Seal) Company: (Corporate Seal) Aqua Waste Repairs,Inc. Swiss Re Corporate Solutions America Insurance Corporation r Signature: �� /c Z'` _�ti Signature: Name Name Lisa A.Roseland and.Title: and Title: Attorney-in-Fact&Florida Licensed Resident Agent (Ark,additional signatures appear on the last page of this Performance Bond) (FOR I_N,TFOXAL-47701\ 0A'LA—Natne,addrrss and telephone) AGENT or BROKER: OWNER'S REPRESENTATIVE: Florida Surety Bonds,Inc. (Arrhitea,Engineerorotherpaq.) WSP Environment&Infrastructure Solutions,Inc. 620 N.Wymore Rd. Suite 200 16250 NW 59th Ave.,Suite 206 Maitland,FL 32751 Miami Lakes FL 33014 407-786-7770 314-920-8359 By arrangement with the American Institute of Architects, the National Association of Surety Bond Producers 1 (NASBP) (www.nasbp.org) makes this form document available to its members, affiliates, and associates in Microsoft Word format for use in the regular course of surety business.NASBP vouches that the original text of this document conforms exactly to the text in AIA Document A312-2010,Performance Bond and Payment Bond.Subsequent modifications may be made to the original text of this document by users,so careful review of its wording and consultation with an attorney are encouraged before its completion,execution or acceptance. §1 The Contractor and Surety,jointly and severally,bind themselves,their heirs,executors,administrators,successors and assigns to the Owner for the performance of the Construction Contract,which is incorporated herein by reference. S 2 If the Contractor performs the Construction Contract,the Surety and the Contractor shall have no obligation under this Bond,except when applicable to participate in a conference as provided in Section 3. §3 If there is no Owner Defaultt under the Construction Contract,the Surety's obligation under this Bond shall arise after .1 the Owner first provides notice to the Contractor and the Surety that the Owner is considering declaring a Contractor Default.Such notice shall indicate whether the Owner is requesting a conference among the Owner,Contractor and Surety to discuss the Contractor's performance.If the Owner does not request a conference,the Surety may,within five(5)business days after receipt of the Owner's notice, request such a conference.If the Surety timely requests a conference,the Owner shall attend.Unless the Owner agrees otherwise,any conference requested under this Section 3.1 shall be held within ten(10) business days of the Surety's receipt of the Owner's notice.If the Owner,the Contractor and the Surety agree,the Contractor shall be allowed a reasonable time to perform the Construction Contract,but such an agreement shall not waive the Owner's right,if any,subsequently to declare a Contractor Default; .2 the Owner declares a Contractor Default,teminates the Construction Contract and notifies the Surety; and .3 the Owner has agreed to pay the Balance of the Contract Price in accordance with the terms of the Construction Contract to the Surety or to a contractor selected to perform the Construction Contract. 4 Failure on the part of the Owner to comply with the notice requirement in Section 3.1 shall not constitute a failure to comply with a condition precedent to the Surety's obligations,or release the Surety from its obligations,except to the extent the Surety demonstrates actual prejudice. 5 When the Owner has satisfied the conditions of Section 3,the Surety shall promptly and at the Surety's expense take one of the following actions: §5.1 Arrange for the Contractor,with the consent of the Owner,to perform and complete the Construction Contract; §5.2 Undertake to perform and complete the Construction Contract itself,through its agents or independent contractors; §5.3 Obtain bids or negotiated proposals from qualified contractors acceptable to the Owner for a contract for performance and completion of the Construction Contract,arrange for a contract to be prepared for execution by the Owner and a contractor selected with the Owner's concurrence,to be secured with performance and payment bonds executed by a qualified surety equivalent to the bonds issued on the Construction Contract,and pay to the Owner the amount of damages as described in Section 7 in excess of the Balance of the Contract Price incurred by the Owner as a result of the Contractor Default;or §5.4 Waive its right to perform and complete,arrange for completion,or obtain a new contractor and with reasonable promptness under the circumstances: .1 After investigation,determine the amount for which it may be liable to the Owner and,as soon as practicable after the amount is determined,make payment to the Owner;or .2 Deny liability in whole or in part and notify the Owner,citing the reasons for denial. 6 If the Surety does not proceed as provided in Section 5 with reasonable promptness,the Surety shall be deemed to be in default on this Bond seven days after receipt of an additional written notice from the Owner to the Surety demanding that the Surety perform its obligations under this Bond,and the Owner shall be entitled to enforce any remedy available to the Owner.If the Surety proceeds as provided in Section 5.4,and the Owner refuses the payment or the Surety has denied liability,in whole or in part,without further notice the Owner shall be entitled to enforce any remedy available to the Owner_ By arrangement with the American Institute of Architects, the National Association of Surety Bond Producers 2 (NASBP) (www.na bp.org) makes this font document available to its members, affiliates, and associates in Microsoft Word format for use in the regular course of surety business.NASBP vouches that the original text of this document conforms exactly to the text in AIA Document A312-2010, Performance Bond and Payment Bond. Subsequent modifications may be made to the original text of this document by users,so careful review of its wording and consultation with an attorney are encouraged before its completion,execution or acceptance. 7 If the Surety,elects to act under Section 5.1,5.2 or 5.3,then the responsibilities of the Surety to the Owner shall not be greater than those of the Contractor under the Construction Contract,and the responsibilities of the Owner to the Surety shall not be greater than those of the Owner under the Construction Contract.Subject to the cominitment by the Owner to pay the Balance of the Contract Price,the Surety is obligated,without duplication,for .1 the responsibilities of the Contractor for correction of defective work and completion of the Construction Contract, .2 additional legal,design professional and delay costs resulting from the Contractor's Default,and resulting from the actions or failure to act of the Surety under Section 5;and .3 liquidated damages,or if no liquidated damages are specified in the Construction Contract,actual damages caused by delayed perfoli-nance or non-performance of the Contractor. 8 If the Surety elects to act under Section 5.1,5.3 or 5.4,the Surety's liability is limited to the amount of this Bond. 9 The Surety shall not be liable to the Owner or others for obligations of the Contractor that are unrelated to the Construction Contract,and the Balance of the Contract Price shall not be reduced or set off on account of any such unrelated obligations.No right of action shall accrue on this Bond to any person or entity other than the Owner or its heirs,executors,administrators,successors and assigns. §10 The Surety hereby waives notice of any change,including changes of time,to the Construction Contract or to related subcontracts,purchase orders and other obligations. §11 Any proceeding,legal or equitable,under this Bond may be instituted in any court of competent jurisdiction in the location in which the work or part of the work is located and shall be instituted within two years after a declaration of Contractor Default or within two years after the Contractor ceased working or within two years after the Surety refuses or fails to perform its obligations under this Bond,whichever occurs first.If the provisions of this Paragraph are void or prohibited by law,the rriinimum period of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable. §12 Notice to the Surety,the Owner or the Contractor shall be mailed or delivered to the address shown on the page on which their signature appears. §13 When this Bond has been furnished to comply with a statutory or other legal requirement in the location where the construction was to be performed,any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefrorn and provisions conforming to such statutory or other legal requirement shall be deemed incorporated herein.When so furnished,the intent is that this Bond shall be construed as a statutory bond and not as a cornmon law bond. 14 Definitions 14.1 Balance of the Contract Price.The total amount payable by the Owner to the Contractor under the Construction Contract after all proper adjustments have been made,including allowance to the Contractor of any amounts received or to be received by the Owner in settlement of insurance or other claims for damages to which the Contractor is entitled,reduced by all valid and proper payments made to or on behalf of the Contractor under the Construction Contract. §14.2 Construction Contract.The agreement between the Owner and Contractor identified on the cover page, including all Contract Documents and changes made to the agreement and the Contract Documents. S 14.3 Contractor Default.Failure of the Contractor,which has not been remedied or waived,to perform or otherwise to comply with a material term of the Construction Contract. §14.4 Owner Default,Failure of the Owner,which has not been remedied or waived,to pay the Contractor as required under the Construction Contract or to perform and complete or comply with the other material terms of the Construction Contract. §14.5 Contract Documents.AD the documents that comprise the agreement between the Owner and Contractor. §15 If this Bond is issued for an agreement between a Conti-actor and subcontractor,the term Contractor u-i this Bond shall be deemed to be Subcontractor and the term Owner shall be deemed to be Contractor. By arrangement with the American Institute of Architects, the National Association of Surety Bond Producers (NASBP) (www.nasb.o ) makes this form document available to its members, affiliates, and associates in Microsoft Word format for use in the regular course of surety business.NASBP vouches that the original text of this document conforms exactly to the text in AIA Document A312-2010,Performance Bond and Payment Bond.Subsequent modifications may be made to the original text of this document by users,so careful review of its wording and consultation with an attorney are encouraged before its completion,execution or acceptance. 16 Modifications to this bond are as follows: THIS BOND IS GIVEN TO COMPLY WITH SECTION 255.05 OR SECTION 713.23 FLORIDA STATUTES,AND ANY ACTION INSTITUTED BY A CLAIMANT UNDER THIS BOND FOR PAYMENT MUST BE IN ACCORDANCE WITH THE NOTICE AND TIME LIMITATION PROVISIONS IN SECTION 255.05(2)OR SECTION 713.23 FLORIDA STATUTES. (Space i t psnvided Ge%w far adclitional siprtalm-ex o f added parties,other than those cpeaiing on the cover page.) CONTRACTOR AS PRINCIPAL SURETY CompanNI: (CospowleSeal) Company- (Cospowle.Seal) Signature: Signature: Name and Title: Name and Title: .Address: address: By arrangement with the American Institute of Architects, the National Association of Surety Bond Producers 4 (NASBP) (www.nasbp.org) makes this form document available to its members, affiliates, and associates in Microsoft Word format for use in the regular course of surety business.NASBP vouches that the original text of this document conforms exactly to the text in AIA Document A312-2010, Performance Bond and Payment Bond. Subsequent modifications may be made to the original text of this document by users,so careful review of its wording and consultation with an attorney are encouraged before its completion,execution or acceptance. Bond No. 2346020 Executed in 5 Counterparts Payment Bond CONTRACTOR: SURETY: (Name,legal stairs and addnus) (Name,legal statzas and p in(ipal place of business) Aqua Waste Repairs,Inc. Swiss Re Corporate Solutions America Insurance Corporation 3575 Sneed Road 1200 Main Street,Suite 800 Ft.Pierce,FL 34945 772-461-6228 Kansas City,MO 64105-2478 816-235-3700 OWNER: (Narne,legal stratus and adds-ess) 17h is document has important Board of County Commissioners of Monroe County,Florida legal consequences.Consultation with an attorney is encouraged 1100 Simonton Street The Gato Building,Room 2-205 with respect to its completion or Key West,FL 33040, 305-435-8787 modification. Any singular reference to CONSTRUCTION CONTRACT Contractor,Surety,Owner or Date: July 19,2023 other Pam shall be considered plural where applicable. Amount: $299,000.00 This document combines two separate bonds,a Performance Description: Bond and a Payment Bond,into (!game and location)Gravity Flow Injection Well Water Quality Improvement Project, one form.This is not a single Canal#58 Key largo,Monroe County,FL g combined Performance and BOND Pavment Bond. Date: August 25,2023 (Not earlier thrnr Consimetion Contract Date) Amount: $299,000.00 i\lodifications to this Bond: None X See Section 18 CONTRACTOR AS PRINCIPAL SURETY Company: (Corporate Seal) Company: (Corporate Seal) Aqua Waste Repairs,Inc. Swiss Re Corporate Solutions America Insurance Corpuratio?r. Signature: a Signature: t Name Name Lisa A.Roseland and Title: and'title: Attorney-in-Fact&Florida Licensed Resident Agent (AiDl additional signatures appear on the last pi e oJ'this Pad nrent Bond) (l70K 1AT-OK1IM 1701V ONL)'—Name,address and telephone) AGENT or BROKER: OWNER'S REPRESENTATIVE: (Arzhitecz`,Engineer or otberpq:) Florida Surety Bonds,Inc. WSP Environment&Infrastructure Solutions,Inc. 620 N.Wymore Rd. Suite 200 16250 NW 59th Ave.,Suite 206 Maitland,FL 32751 Miami Lakes FL 33014 407-786-7770 314-920-8359 By arrangement with the American Institute of Architects,the National Association of Surety Bond Producers 5 (NASBP) (xvww.nasbp.org) makes this form document available to its members, affiliates, and associates in Microsoft Word format for use in the regular course of surety business.NASBP vouches that the original text of this document conforms exactly to the text in AIA Document A312-2010,Performance Bond and Payment Bond. Subsequent modifications may be made to the original text of this document by users,so careful review of its wording and consultation with an attomey are encouraged before its completion,execution or acceptance. 1 The Contractor and Surety,jointly and severally,bind themselves,their heirs,executors,administrators, successors and assigns to the Owner to pay for labor,materials and equipment furnished for use in the performance of the Construction Contract,which is incorporated herein by reference,subject to the following terms. §2 If the Contractor promptly makes payment of all sums due to Claimants,and defends,indemnifies and holds harmless the Owner from claims,demands,liens or suits by any person or entity seeking payment for labor,materials or equipment furnished for use in the performance of the Construction Contract,then the Surety and the Contractor shall have no obligation under this Bond. §3 If there is no Owner Default under the Construction Contract,the Surety's obligation to the Owner under this Bond shall arise after the Owner has promptly notified the Contractor and the Surety(at the address described in Section 13)of claims,demands,liens or suits against the Owner or the Owner's property by any person or entity seeking payment for labor,materials or equipment furnished for use in the performance of the Construction Contract and tendered defense of such claims,demands,liens or suits to the Contractor and the Suret,. §4 When the Owner has satisfied the conditions in Section 3,the Surety shall promptly and at the Surety's expense defend,indemnify and hold harmless the Owner against a duly tendered claim,demand,lien or suit. 5 The Surety's obligations to a Claimant under this Bond shall arise after the following: 5.1 Claimants,who do not have a direct contract with the Contractor, .1 have furnished a written notice of non-payment to the Contractor,stating with substantial accuracy the amount claimed and the name of the party to whom the materials were,or equipment was, furnished or supplied or for whom the labor was done or performed,within ninety-(90)days after having last performed labor or last furnished materials or equipment included in the Clain;and .2 have sent a Claim to the Surety(at the address described in Section 13). 5.2 Claimants,who are employed by or have a direct contract with the Contractor,have sent a Claim to the Surety (at the address described in Section 13). S 6 If a notice of non-payment required by Section 5. 1.1 is given by the Owner to the Contractor,that is sufficient to satisfy a Claimant's obligation to furnish a written notice of non-payment under Section 5.1.1. 7 When a Claimant has satisfied the conditions of Sections 5.1 or 5.2,whichever is applicable,the Surety shall promptly and at the Surety's expense take the following actions: §7.1 Send an answer to the Claimant,with a copy to the Owner,within sixty(60)days after receipt of the Claim, stating the amounts that are undisputed and the basis for challenging any amounts that are disputed;and 7.2 Pay or arrange for payment of any undisputed amounts. 7.3'The Surety's failure to discharge its obligations under Section 7.1 or Section 7.2 shall not be deemed to constitute a waiver of defenses the Surety or Contractor may have or acquire as to a Claim,except as to undisputed amounts for which the Surety and Claimant have reached agreement.If,however,the Surety fails to discharge its obligations under Section 7.1 or Section 7.2,the Surety shall indemnify the Claimant for the reasonable attorney's fees the Claimant incurs thereafter to recover any sums found to be due and owing to the Claimant. 8 The Surety's total obligation shall not exceed the amount of this Bond,plus the amount of reasonable attorney's fees provided under Section 7.3,and the amount of this Bond shall be credited for any payments made in good faith by the Surety. §9,-Amounts owed by the Owner to the Contractor under the Construction Contract shall be used for the performance of the Construction Contract and to satisfy claims,if any,under any construction performance bond.By the Contractor furnishing and the Owner accepting this Bond,they agree that all funds earned by the Contractor in the performance of the Construction Contract are dedicated to satisfy obligations of the Contractor and Surety under this Bond,subject to the Owner's priority to use the funds for the completion of the work. By arrangement with the American Institute of Architects, the National Association of Surety Bond Producers (NASBP) (www.nasbp.org) makes this form document available to its members, affiliates, and associates in Microsoft Word format for use in the regular course of surety business.NASBP vouches that the original text of this document conforms exactly to the text in AIA Document A312-2010,Performance Bond and Payment Bond.Subsequent modifications may be made to the original text of this document by users,so careful review of its wording and consultation with an attorney are encouraged before its completion,execution or acceptance. 10 The Surety shall not be liable to the Owner,Claimants or others for obligations of the Contractor that are unrelated to the Construction Contract.The Owner shall not be liable for the payment of any costs or expenses of any Claimant under this Bond,and shall have under this Bond no obligation to make payments to,or give notice on behalf of,Claimants or otherwise have any obligations to Claimants under this Bond. 11 The Surety hereby waives notice of any change,including changes of time,to the Construction Contract or to related subcontracts,purchase orders and other obligations. §12 No suit or action shall be commenced by a Claimant under this Bond other than in a court of competent jurisdiction in the state in which the project that is the subject of the Construction Contract is located or after the expiration of one year from the date(1)on which the Claimant sent a Claim to the Surety pursuant to Section 5.1 2 or 5.2,or(2)on which the last labor or service was performed by anyone or the last materials or equipment were furnished by anyone under the Construction Contract,whichever of(1)or(2)first occurs.If the provisions of this Paragraph are void or prohibited by law,the minimum period of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable. §13 Notice and Claims to the Surety,the Owner or the Contractor shall be mailed or delivered to the address shown on the page on which their signature appears.actual receipt of notice or Claims,however accomplished,shall be sufficient compliance as of the date received. §14\N,'hen this Bond has been furnished to comply with a statutory-or other legal requirement in the location where the construction was to be performed,any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefrom and provisions conforming to such statutory or other legal requirement shall be deemed incorporated herein.Wlien so furnished,the intent is that this Bond shall be construed as a statutory bond and not as a common law bond. 15 Upon request by any person or entity appearing to be a potential beneficiary of this Bond,the Contractor and Owner shall promptly furnish a copy of this Bond or shall permit a copy to be made. 16 Definitions 16.1 Claim.A written statement by the Claimant including at a minimum: .1 the name of the Claimant; .2 the name of the person for whom the labor was done,or materials or equipment furnished; .3 a copy of the agreement or purchase order pursuant to which labor,materials or equipment was furnished for use in the performance of the Construction Contract; .4 a brief description of the labor,materials or equipment furnished; .5 the date on which the Claimant last performed labor or last furnished materials or equipment for use in the performance of the Construction Contract; .6 the total amount earned by the Claimant for labor,materials or equipment furnished as of the date of the Claim; .7 the total amount of previous payments received by the Claimant;and .8 the total amount due and unpaid to the Claimant for labor,materials or equipment furnished as of the date of the Claim. 16.2 Claimant.An individual or entity having a direct contract with the Contractor or with a subcontractor of the Contractor to furnish labor,materials or equipment for use in the performance of the Construction Contract.The term Claimant also includes any individual or entity that has rightfully-asserted a claim under an applicable mechanic's lien or similar statute against the real property upon which the Project is located.The intent of this Bond shall be to include without lirnitation in the terms"labor,materials or equipment"that part of water,gas,power,light,heat,oil, gasoline,telephone service or rental equipment used in the Construction Contract,architectural and engineering services required for performance of the work of the Contractor and the Contractor's subcontractors,and all other items for which a mechanic's lien may be asserted in the jurisdiction where the labor,materials or equipment were furnished. §16.3 Construction Contract.The agreement between the Owner and Contractor identified on the cover page, including all Contract Documents and all changes made to the agreement and the Contract Documents. By an-angement with the American Institute of Architects, the National Association of Surety Bond Producers (NASBP) (www.nasbp.or ) makes this form document available to its members, affiliates, and associates in t Microsoft Word format for use in the regular course of surety business.NASBP vouches that the original text of this document conforms exactly to the text in AIA Document A312-2010, Performance Bond and Payment Bond. Subsequent modifications may be made to the original text of this document by users,so careful review of its wording and consultation with an attorney are encouraged before its completion,execution or acceptance. 16.4 Owner Default.Failure of the Owner,which has not been remedied or waived,to pay the Contractor as required under the Construction Contract or to perform and complete or comply with the other material terms of the Construction Contract. §16.5 Contract Documents.All the documents that comprise the agreement between the Owner and Contractor. §17 If this Bond is issued for an agreement between a Contractor and subcontractor,the term Contractor in this Bond shall be deemed to be Subcontractor and the term Owner shall be deemed to be Contractor. 18 Modifications to this bond are as follows: THIS BOND IS GIVEN TO COMPLY WITH SECTION 255.05 OR SECTION 713.23 FLORIDA STATUTES,AND ANY ACTION INSTITUTED BY A CLAIMANT UNDER THIS BOND FOR PAYMENT MUST BE IN ACCORDANCE WITH THE NOTICE AND TIME LIMITATION PROVISIONS IN SECTION 255.05(2)OR SECTION 713.23 FLORIDA STATUTES. (Space zs pibvider!belont for aciclitional rignalun,s of adder!paitzes,other than those appeafzng on the cover page.) CONTRACTOR AS PRINCIPAL SURETY Company: (Coipiowle Seal) Company: (Corporate Seal) Signature: Signature: Name and Title: Name and Title: Address: address: By arrangement with the American Institute of Architects, the National Association of Surety Bond Producers 8 (NASBP) (www.nasbp.ort, makes this form document available to its members, affiliates, and associates in Microsoft Word format for use in the regular course of surety business.NASBP vouches that the original text of this document conforms exactly to the text in AIA Document A312-2010,Performance Bond and Payment Bond. Subsequent modifications may be made to the original text of this document by users,so careful review of its wording and consultation with an attorney are encouraged before its completion,execution or acceptance. SWISS RE CORPORATE SOLUTIONS SWISS RE CORPORATE SOLUTIONS AMERICA INSURANCE CORPORATION("SRCSAIC") SWISS RE CORPORATE SOLUTIONS PREMIER INSURANCE CORPORATION("SRCSPIC") WESTPORT INSURANCE CORPORATION("WIC") GENERAL POWER OF ATTORNEY KNOW ALL MEN BY THESE PRESENTS,THAT SRCSAIC,a corporation duly organized and existing under laws of the State of Missouri,and having its principal office in the City of Kansas City,Missouri,and SRCSPIC,a corporation organized and existing under the laws of the State of Missouri and having its principal office in the City of Kansas City,Missouri,and WIC,organized under the laws of the State of Missouri,and having its principal office in the City of Kansas City,Missouri,each does hereby make,constitute and appoint: JEFFREY W.REICH,SUSAN L.REICH,KIM E.NIV,TERESA L.DURHAM,GLORIA A.RICHARDS,CHERYL A.FOLEY, LISA A.ROSELAND,EMILY J.GOLECKI,SONJA AMANDA FLOREE HARRIS,ROBERT P.O-LINN,NATHAN K.REICH,and SARAH OTINN JOINTLY OR SEVERALLY Its true and lawful Attoniey(s)-in-Pact,to make,execute,seal and deliver,for and on its behalf and as its act and deed,bonds or other writings obligatory in the nature of a bond on behalf ofeach of said Companies,as surety,on contracts of suretyship as are or may be required or permitted by law,regulation,contract or otherwise,provided that no bond or undertaking or contract or suretyship executed tinder this authority shall exceed the amount of: TWO HUNDRED MILLION(S200,000,000.00)DOLLARS This Power ofAttomey is granted and is signed by facsimile under and by the authority of the following Resolutions adopted by the Boards of Directors of both SRCSAIC and SRCSPIC at meetings duly called and held on the 18th of November 2021 and WIC by written consent of its Executive Committee dated July 18,2011. "RESOLVED,that any two of the President.any Managing Director,any Senior Vice President,any Vice President,the Secretary or any Assistant Secretary be,and each or any of them hereby is,authorized to execute a Power of Attorney qualifying the attorney named in the given Power of Attorney to execute on behalf oflie Corporation bonds,undertakings and all contracts of surety,and that each or any of them hereby is authorized to attest to the execution of why such Power of Attorney and to attach therein the seal of the Corporation, and itis FURTHER RESOLVED,that the Signature of such officers and the seal of the Corporation may be affixed to any such Power of Attorney or to any certificate relating thereto by facsimile,and any such Power orAttorney or certificate bearing such facsimile signatures or facsimile seal shall be bindine.unon the Corporation when so affixed and in the future with repard to anv bond,undertaking or contract of surety to which it is attached." ............... P 0;? P o R 4". By Erik Janssens,Senior Vice President orSRCSAIC&Senior Vice President nrSRCSPIC&StuiorVirc P"Adcut.fIVIC S E A L so,., M S 1973 a 0 Soo... 4, '-./Ssokj Bits y Ge"dJagr-wski.N',-P,esid.tt*fSRCSAIC&Vi,ePr.ide.t.fSRCSPIC &Vice President.fIVIC IN WITNESS WHEREOF,SRCSAIC,SRCSPIC,and WIC have caused their official seals to be hereunto affixed,and these presents to be signed by their authorized officers this 10 day of NOVEMBER 20 22 Swiss Re Corporate Solutions America Insurance Corporation State of Illinois Swiss Re Corporate Solutions Premier Insurance Corporation County of Cook E S-1 j Westport Insurance Corporation On this 10 day of NOVEMBER 20 22 before me,a Notary Public personally appeared Erik Janssens,Senior Vice President of SRCSAIC and Senior VicePrcsidcnt of SRCSPIC and Senior Vice President of WIC and GeraldJagrowski,Vice President of SRCSAIC and Vice President of SPCSPIC and Vice President of WIC,personally known to me,who being by me duly sworn,acknowledged that they signed the above Power of Attorney as officers of and acknowledged said instrument to be the voluntary act and deed of their respective companies. - - OFFICIAL SEA.A-L C14RIS11NA i. NOTARY MOW WYE OF 2faF -� - - - %k&&a-Pq--;1" 1.Jeffrey Goldberg.the duly elected Senior Vice President and Assistant Secretary of SRCSAIC and SRCSPIC and WIC,do hereby certify that the above and foregoing is a true and correct copy or a Power ofAttorney given by said SRCSAIC and SRCSPIC and WIC,which is still in full force and effect. IN WITNESS WHEREOF,I have set my hand and affixed the seals of die Companies this 25th day of August 120 23. Jeffrey Goldberg,Senior Vice President& Assistant Secretary of SRCSAIC and SRCSPIC and WIC