Loading...
The URL can be used to link to this page
Your browser does not support the video tag.
05/15/2024 Agreement
GVS COURTq° o: A Kevin Madok, CPA - �o ........ � Clerk of the Circuit Court& Comptroller Monroe County, Florida �z cooN DATE: May 21, 2024 TO: Judith Clarke, PE, Director Engineering/Roads & Bridges ATTN: Debra London, Project Manager FROM: Liz Yongue, Deputy Clerk SUBJECT: May 15, 2024 BOCC Meeting The following items have been executed and added to the record: C2 Contract with Kisinger Campo & Associates, Corp, for Construction Engineering and Inspection Services for the Key Largo III Roadway and Drainage Project in the maximum not to exceed amount of$393,582.87, partially funded by FDOT SCOP Agreement No. G2P46. R2 Contract with HDR Construction Control Corporation for Construction Engineering and Inspection Services (CEI) for the Twin Lakes (Key Largo) Flood Mitigation Project in the maximum not to exceed amount of$1,422,618.68 partially funded by a Florida Keys Aqueduct Authority Interlocal Agreement. Should you have any questions please feel free to contact me at(305) 292-3550. cc: County Attorney Finance File KEY WEST MARATHON PLANTATION KEY 500 Whitehead Street 3117 Overseas Highway 88770 Overseas Highway Key West, Florida 33040 Marathon, Florida 33050 Plantation Key, Florida 33070 AGREEMENT FOR CONSTRUCTION ENGINEERING AND INSPECTION (CEI) SERVICES FOR THE TWIN LAKES SUBDIVISION (KEY LARGO) FLOOD MITIGATION PROJECT This Agreement ("Agreement") made and entered into this 15th day of MaY 2024 by and between Monroe County, a political subdivision of the State of Florida, whose address is 1100 Simonton Street, Key West, Florida, 33040, its successors and assigns, hereinafter referred to as "COUNTY," through the Monroe County Board of County Commissioners ("BOCC"), AND HDR Construction Control Corporation, a corporation of the State of Nebraska, whose Florida headquarters address is 4830 W Kennedy Blvd, Suite 400, Tampa, FL 33609; its successors and assigns, hereinafter referred to as "CONSULTANT", WITNESSETH: WHEREAS, COUNTY desires to employ the professional services of CONSULTANT for Construction Engineering and Inspection (CEI) Services for the Monroe County Twin Lakes Subdivision (Key Largo) Flood Mitigation Project; and WHEREAS, CONSULTANT has agreed to provide professional services which shall include but not be limited to providing construction engineering and inspection (CEI) services for the Monroe County Twin Lakes Subdivision (Key Largo) Flood Mitigation Project, which services shall collectively be referred to as the "Project"; NOW, THEREFORE, in consideration of the mutual promises, covenants and agreements stated herein, and for other good and valuable consideration, the sufficiency of which is hereby acknowledged, COUNTY and CONSULTANT agree as follows: FORM OF AGREEMENT ARTICLE 1 REPRESENTATIONS AND WARRANTIES 1.1 By executing this Agreement, CONSULTANT makes the following express representations and warranties to the COUNTY: 1.1.1 The CONSULTANT shall maintain all necessary licenses, permits or other authorizations necessary to act as CONSULTANT for the Project until the CONSULTANT'S duties hereunder have been fully satisfied; 1.1.2 The CONSULTANT has become familiar with the Project sites and the local conditions under which the Work is to be completed. -1- 1.1.3 The CONSULTANT shall prepare all documentation required by this Agreement in such a manner that they shall be accurate, coordinated and adequate for use in verifying work completed and shall be in conformity and comply with all applicable law, codes and regulations. The CONSULTANT warrants that the documents prepared as a part of this Agreement will be adequate and sufficient to document costs in a manner that is acceptable for reimbursement by government agencies, therefore eliminating any additional cost due to missing or incorrect information; 1.1.4 The CONSULTANT assumes full responsibility to the extent allowed by law with regards to his performance and those directly under his employ. 1.1.5 The CONSULTANT'S services shall be performed as expeditiously as is consistent with professional skill and care and the orderly progress of the Project. In providing all services pursuant to this agreement, the CONSULTANT shall abide by all statutes, ordinances, rules and regulations pertaining to, or regulating the provisions of such services, including those now in effect and hereinafter adopted. Any violation of said statutes, ordinances, rules and regulations shall constitute a material breach of this agreement and shall entitle the Board to terminate this contract immediately upon delivery of written notice of termination to the CONSULTANT. 1.1.6 At all times and for all purposes under this agreement the CONSULTANT is an independent contractor and not an employee of the Board of County Commissioners for Monroe County. No statement contained in this agreement shall be construed so as to find the CONSULTANT or any of his/her employees, contractors, servants, or agents to be employees of the Board of County Commissioners for Monroe County. 1.1.7 The CONSULTANT shall not discriminate against any person on the basis of race, creed, color, national origin, sex, age, or any other characteristic or aspect which is not job related, in its recruiting, hiring, promoting, terminating, or any other area affecting employment under this agreement or with the provision of services or goods under this agreement. 1.1.8 The CONSULTANT shall complete the scope of services no later than 60 days after construction final completion of the Twin Lakes Subdivision (Key Largo) Flood Mitigation Project, estimated at 22 months. ARTICLE II SCOPE OF BASIC SERVICES 2.1 DEFINITION CONSULTANT'S Scope of Basic Services consist of those described in the Agreement Attachment A. 2.2 CORRECTION OF ERRORS, OMISSIONS, DEFICIENCIES The CONSULTANT shall, without additional compensation, promptly correct any errors, omissions, deficiencies, or conflicts in the work product of the CONSULTANT or its subconsultants, or both. -2- 2.3 NOTICE REQUIREMENT All written correspondence to the COUNTY shall be dated and signed by an authorized representative of the CONSULTANT. Any notice required or permitted under this agreement shall be in writing and hand delivered or mailed, postage pre-paid, to the COUNTY by certified mail, return receipt requested, to the following: Ms. Judith Clarke, P.E. Director of Engineering Services Monroe County 1100 Simonton Street, Room 2-216 Key West, Florida 33040 And: Kevin Wilson, P.E. Monroe County Administrator 1100 Simonton Street, Room 2-205 Key West, Florida 33040 For the Consultant: Katie E. Duty, Vice President HDR Construction Control Corporation 4830 W. Kennedy Blvd. #400 Tampa, FL 33609 ARTICLE III ADDITIONAL SERVICES 3.1 Additional services are services not included in the Scope of Basic Services. Should the COUNTY require additional services they shall be paid for by the COUNTY at rates or fees negotiated at the time when services are required, but only if approved by the COUNTY before commencement. 3.2 If Additional Services are required the COUNTY shall issue a letter requesting and describing the requested services to the CONSULTANT. The CONSULTANT shall respond with a fee proposal to perform the requested services. Only after receiving an amendment to the Agreement and a notice to proceed from the COUNTY, shall the CONSULTANT proceed with the Additional Services. ARTICLE IV COUNTY'S RESPONSIBILITIES 4.1 The COUNTY shall provide full information regarding requirements for the Project including physical location of work, county maintained roads, maps. -3- 4.2 The COUNTY shall designate a representative to act on the COUNTY's behalf with respect to the Project. The COUNTY or its representative shall render decisions in a timely manner pertaining to documents submitted by the CONSULTANT in order to avoid unreasonable delay in the orderly and sequential progress of the CONSULTANT'S services. 4.3 Prompt written notice shall be given by the COUNTY and its representative to the CONSULTANT if they become aware of any fault or defect in the Project or non- conformance with the Agreement Documents. Written notice shall be deemed to have been duly served if sent pursuant to paragraph 2.3. 4.4 The COUNTY shall furnish the required information and services and shall render approvals and decisions as expeditiously as necessary for the orderly progress of the CONSULTANT'S services and work of the contractors. 4.5 The COUNTY's review of any documents prepared by the CONSULTANT or its subconsultants shall be solely for the purpose of determining whether such documents are generally consistent with the COUNTY's criteria, as, and if, modified. No review of such documents shall relieve the CONSULTANT of responsibility for the accuracy, adequacy, fitness, suitability or coordination of its work product. 4.6 The COUNTY shall provide copies of necessary documents required to complete the work. 4.7 Any information that may be of assistance to the CONSULTANT that the COUNTY has immediate access to will be provided as requested. ARTICLE V INDEMNIFICATION AND HOLD HARMLESS 5.1 Notwithstanding any minimum insurance requirements prescribed elsewhere in this agreement, the CONSULTANT covenants and agrees that he shall defend, indemnify and hold the COUNTY and the COUNTY's elected and appointed officers and employees, from and against (i) claims, actions or causes of action, (ii) litigation, administrative proceedings, appellate proceedings, or other proceedings relating to any type of injury (including death), loss, damage, fine, penalty or business interruption, and (iii) costs or expenses that may be asserted against, initiated with respect to, or sustained by the County and the COUNTY's elected and appointed officers and employees from liabilities damages, losses and costs, including but not limited to, reasonable attorney's fees, to the extent caused by the negligence, recklessness, or intentional wrongful misconduct of the CONSULTANT and persons employed or utilized by the indemnifying party in the performance of this Agreement. 5.2 In the event the completion of the project (including the work of others) is delayed or suspended as a result of the CONTRACTOR or CONSULTANT failure to purchase or maintain the required insurance, the CONTRACTOR or CONSULTANT shall indemnify the County from any and all increased expenses resulting from such delay. -4- The extent of liability is in no way limited to, reduced, or lessened by the insurance requirements contained elsewhere within this Agreement. In the event any claims are brought, or actions are filed against the County with respect to the indemnity contained herein, the CONSULTANT agrees to defend against any such claims or actions regardless of whether such claims or actions are rightfully or wrongfully brought or filed. The CONSULTANT agrees that the County may select the attorneys to appear and defend such claims or actions on behalf of the County. The CONSULTANT further agrees to pay at the CONSULTANT's expense the attorneys' fees and costs incurred by those attorneys selected by the County to appear and defend such actions or claims on behalf of the County at both the trial and appellate levels. The County at its sole option, shall have the sole authority for the direction of the defense, and shall be the sole judge of the acceptability of any compromise or settlement of any claims or actions against the County. 5.3 Florida Department of Environmental Protection and Florida Division of Emergency Management Indemnification. CONSULTANT covenants and agrees to indemnify, hold harmless and defend Monroe County BOCC, Florida Department of Environmental Protection and Florida Division of Emergency Management its commissioners, officers, employees, agents and servants against all claims of whatever nature arising out of the performance of work under this agreement to the extent allowed and required by law. The CONSULTANT will include the above indemnification in any sub-contracts. 5.4 The extent of liability is in no way limited to, reduced or lessened by the insurance requirements contained elsewhere within the Agreement. 5.5 This indemnification shall survive the expiration or early termination of the Agreement. Nothing contained in this paragraph is intended to nor shall it constitute a waiver of the State of Florida and the Agency's (COUNTY's) sovereign immunity requirement. ARTICLE VI PERSONNEL 6.1 PERSONNEL The CONSULTANT shall assign only qualified personnel (to be approved by the County) to perform any service concerning the project. ARTICLE VII COMPENSATION 7.1 PAYMENT SUM 7.1.1 The COUNTY shall pay the CONSULTANT monthly in current funds for the -5- CONSULTANT'S performance of this Agreement based on Attachment B and herein on the hours substantiated by timehseets with job function tasks defined at specified hourly rates, materials testing at per unit rates, for a not to exceed amount of $1,349,699.02 and project field office for a lump sum amount of$72,919.66 divided into 22 month payments of $3,314.53, for a total contract amount of $1,422,618.68. Final invoice to be submitted within 30 days of expiration of the agreement. HDR Construction Control Corp. Loaded Hourly Rate Total Hours/Qty. Extended Costs CEI Project Manager(Anthony Sabbag, CGC, CCM, MSCM) $ 257.07 1540 $ 395,887.80 CEI Senior Project Engineer(David Romano, PE) $ 245.12 150 $ 36,768.00 CEI Senior Inspector(Sam Rodriguez) $ 106.72 3630 $ 387,393.60 Senior Electrical Engineer(Jose Gonzalez, PE) $ 243.33 260 $ 63,265.80 CEI Contract Support Specialist(Gary Miller) 1 $ 118.13 1 920 $ 108,679.60 CEI Senior Inspector/Pump Station(Dennys Losa) 1 $ 110.93 1 120 $ 13,311.60 Subconsultant/H.Rodriguez Consulting Engineering,Inc. Loaded Hourly Rate, Total Hours/Qty. I Extended Costs CEI Senior Inspector(Hector Aguilar) $ 129.75 1485 $ 192,678.75 Subconsultant/More Compliance Results,Inc. Loaded Hourly Rate Total e CEI Resident Compliance Specialist(Melissa Leyva) I $ 74.67 1961 $ Extended146,427.87 Laboratory Materials Testing- Rate Per J nit Total Hours/Qty. Extended Costs Concrete:ASTM C-39, Compressive Strength Cylinders Each $ 20.00 24 $ 480.00 Asphalt: FM 1,T-166, Bulk Specific Gravity, Per Core Each $ 45.00 $ - Earthwork/Soils: FM 5-515, L.B.R. Each $ 335.00 6 $ 2,010.00 Earthwork/Soils:AASHTO T-99, Standard Proctor Each $ 111.00 12 $ 1,332.00 Earthwork/Soils:AASHTO T-180, Modified Proctor Each $ 115.00 6 $ 690.00 Earthwork/Soils:AASHTO M-145,Soils Classification Each $ 27.00 6 $ 162.00 Earthwork/Soils: FM 1,T-267, Organic Content, Ignition Each $ 40.00 6 $ 240.00 Earthwork/Soils:AASHTO T-88, No Hydrometer Each $ 62.00 6 $ 372.00 Subtotal Testino: $ 5,286.00 FieldProject Office ® Rate Per J nit Total Hours/Qty. Extended Costs Key Largo Field Office(rent,printer/copier, internet,etc.) LS $ 72,919.66 1 $ 72,919.66 for 22 mos. Total Fee Estimate: $ 1,422,618.68 These costs are for laboratory testing of materials only.Al field/jobsite sampling and testing(ie:concrete slump,air,cylinders,density tests,etc.)is included in the loaded hourly rate for CEI Senior Inspector. 7.2 PAYMENTS 7.2.1 For its assumption and performances of the duties, obligations and responsibilities set forth herein, the CONSULTANT shall be paid monthly. Payment will be made pursuant to the Local Government Prompt Payment Act 218.70, Florida Statutes. (A) If the CONSULTANT'S duties, obligations and responsibilities are materially changed by amendment to this Agreement after execution of this Agreement, compensation due to the CONSULTANT shall be equitably adjusted, either upward or downward; (B) As a condition precedent for any payment due under this Agreement, the CONSULTANT shall submit monthly, unless otherwise agreed in writing by the COUNTY, a proper invoice to COUNTY requesting payment for services properly -6- rendered and reimbursable expenses due hereunder. The CONSULTANT'S invoice shall describe with reasonable particularity the service rendered. The CONSULTANT'S invoice shall be accompanied by such documentation or data in support of expenses for which payment is sought at the COUNTY may require. 7.3 REIMBURSABLE EXPENSES 7.3.1 Reimbursable expenses include expenses incurred by the CONSULTANT in the interest of the project: a. Expenses of transportation submitted by CONSULTANT, in writing, and living expenses in connection with travel authorized by the COUNTY, in writing, but only to the extent and in the amounts authorized by Section 112.061, Florida Statutes; Cost of reproducing maps or drawings or other materials used in performing the scope of services; b. Postage and handling of reports; 7.4 BUDGET 7.4.1 The CONSULTANT may not be entitled to receive, and the COUNTY is not obligated to pay, any fees or expenses in excess of the amount budgeted for this contract in each fiscal year (October 1 - September 30) by COUNTY's Board of County Commissioners. The budgeted amount may only be modified by an affirmative act of the COUNTY's Board of County Commissioners. 7.4.2 The COUNTY's performance and obligation to pay under this Agreement is contingent upon an annual appropriation by the Board of County Commissioners and the approval of the Board members at the time of contract initiation and its duration. ARTICLE VIII INSURANCE 8.1 The CONSULTANT shall obtain insurance as specified and maintain the required insurance at all times that this Agreement is in effect. In the event the completion of the project (to include the work of others) is delayed or suspended as a result of the CONSULTANT'S failure to purchase or maintain the required insurance, the CONSULTANT shall indemnify the COUNTY from any and all increased expenses resulting from such delay. 8.2 The coverage provided herein shall be provided by an insurer with an A.M. Best rating of VI or better, that is licensed to do business in the State of Florida and that has an agent for service of process within the State of Florida. The coverage shall contain an endorsement providing sixty (60) days notice to the COUNTY prior to any cancellation of said coverage. Said coverage shall be written by an insurer acceptable to the COUNTY and shall be in a form acceptable to the COUNTY. -7- 8.3 CONSULTANT shall obtain and maintain the following policies: A. Workers' Compensation insurance as required by the State of Florida, sufficient to respond to Florida Statute 440. B. Employers Liability Insurance with limits of $500,000 per Accident, $500,000 Disease, policy limits, $500,000 Disease each employee. C. Comprehensive business automobile and vehicle liability insurance covering claims for injuries to members of the public and/or damages to property of others arising from use of motor vehicles, including onsite and offsite operations, and owned, hired or non- owned vehicles, with $200,000 per person, $300,000 per Occurrence, $200,000 Property Damage or $300,000 combined single limit. D. Commercial general liability, including Personal Injury Liability, covering claims for injuries to members of the public or damage to property of others arising out of any covered act or omission of the CONSULTANT or any of its employees, agents or subcontractors or subconsultants, including Premises and/or Operations, Products and Completed Operations, Independent Contractors; Broad Form Property Damage and a Blanket Contractual Liability Endorsement with $300,000 per Person, $500,000 per Ocurrence, $200,000 Property Damage or$500,000 Combined Single Limit. An Occurrence Form policy is preferred. If coverage is changed to or provided on a Claims Made policy, its provisions should include coverage for claims filed on or after the effective date of this contract. In addition, the period for which claims may be reported must extend for a minimum of 48 months following the termination or expiration of this contract. E. Professional Liability insurance of $500,000 per occurrence and $1,000,000 annual aggregate.If coverage is provided on a claims made basis, an extended claims reporting period of four (4) years will be required. Recognizing that the work governed by this contract involves the furnishing of advice or services of a professional nature, the CONSULTANT shall purchase and maintain, throughout the life of the contract, Professional Liability Insurance which will respond to damages resulting from any claim arising out of the performance of professional services or any error or omission of the CONSULTANT arising out of work governed by this contract. F. COUNTY shall be named as an additional insured with respect to CONSULTANT'S liabilities hereunder in insurance coverages identified in Paragraphs C and D. G. CONSULTANT shall require its subconsultants to be adequately insured at least to the limits prescribed above, and to any increased limits of CONSULTANT if so required by COUNTY during the term of this Agreement. COUNTY will not pay for increased limits of insurance for subconsultants. H. CONSULTANT shall provide to the COUNTY certificates of insurance or a copy of all insurance policies including those naming the COUNTY as an additional insured on General and Auto Liability. The COUNTY reserves the right to require a certified copy of such policies upon request. -g- I. If the CONSULTANT participates in a self-insurance fund, a Certificate of Insurance will be required. In addition, the CONSULTANT may be required to submit updated financial statements from the fund upon request from the COUNTY ARTICLE IX MISCELLANEOUS 9.1 SECTION HEADINGS Section headings have been inserted in this Agreement as a matter of convenience of reference only, and it is agreed that such section headings are not a part of this Agreement and will not be used in the interpretation of any provision of this Agreement. 9.2 OWNERSHIP OF THE PROJECT DOCUMENTS The documents prepared by the CONSULTANT for this Project belong to the COUNTY and may be reproduced and copied without acknowledgement or permission of the CONSULTANT. 9.3 SUCCESSORS AND ASSIGNS The CONSULTANT shall not assign or subcontract its obligations under this agreement, except in writing and with the prior written approval of the Board of County Commissioners for Monroe County and the CONSULTANT, which approval shall be subject to such conditions and provisions as the Board may deem necessary. This paragraph shall be incorporated by reference into any assignment or subcontract and any assignee or subcontractor shall comply with all of the provisions of this agreement. Subject to the provisions of the immediately preceding sentence, each party hereto binds itself, its successors, assigns and legal representatives to the other and to the successors, assigns and legal representatives of such other party. 9.4 NO THIRD PARTY BENEFICIARIES Nothing contained herein shall create any relationship, contractual or otherwise, with or any rights in favor of, any third party. 9.5 TERMINATION A. In the event that the CONSULTANT shall be found to be negligent in any aspect of service, the COUNTY shall have the right to terminate this agreement after five days written notification to the CONSULTANT. B. Either of the parties hereto may cancel this Agreement without cause by giving the other party sixty (60) days written notice of its intention to do so. C. Termination for Cause and Remedies: In the event of breach of any contract terms, the COUNTY retains the right to terminate this Agreement. The COUNTY may also -9- terminate this agreement for cause with CONSULTANT should CONSULTANT fail to perform the covenants herein contained at the time and in the manner herein provided. In the event of such termination, prior to termination, the COUNTY shall provide CONSULTANT with seven (5) days' notice and provide the CONSULTANT with an opportunity to cure the breach that has occurred. If the breach is not cured, the Agreement will be terminated for cause. If the COUNTY terminates this agreement with the CONSULTANT, COUNTY shall pay CONSULTANT the sum due the CONSULTANT under this agreement prior to termination, unless the cost of completion to the COUNTY exceeds the funds remaining in the contract; however, the COUNTY reserves the right to assert and seek an offset for damages caused by the breach. The maximum amount due to CONSULTANT shall not in any event exceed the amount set forth in paragraph 7.1 Payment Sum. In addition, the COUNTY reserves all rights available to recoup monies paid under this Agreement, including the right to sue for breach of contract and including the right to pursue a claim for violation of the COUNTY's False Claims Ordinance, located at Section 2-721 et al. of the Monroe County Code. D. Termination for Convenience: The COUNTY may terminate this Agreement for convenience, at any time, upon 60 days' notice to CONSULTANT. If the COUNTY terminates this agreement with the CONSULTANT, COUNTY shall pay CONSULTANT the sum due the CONSULTANT under this agreement prior to termination, unless the cost of completion to the COUNTY exceeds the funds remaining in the contract. The maximum amount due to CONSULTANT shall not exceed the amount set forth in Paragraph 7.1 Payment Sum. E. For Contracts of any amount, if the County determines that the CONSULTANT has submitted a false certification under Section 287.135(5), Florida Statutes or has been placed on the Scrutinized Companies that Boycott Israel List, or is engaged in a boycott of Israel, the County shall have the option of (1) terminating the Agreement after it has given the CONSULTANT written notice and an opportunity to demonstrate the agency's determination of false certification was in error pursuant to Section 287.135(5)(a), Florida Statutes, or (2) maintaining the Agreement if the conditions of Section 287.135(4), Florida Statutes, are met. F. For Contracts of$1,000,000 or more, if the County determines that the CONSULTANT submitted a false certification under Section 287.135(5), Florida Statutes, or if the Contractor/Consultant has been placed on the Scrutinized Companies with Activities in the Sudan List, the Scrutinized Companies with Activities in the Iran Petroleum Energy Sector List, or been engaged in business operations in Cuba or Syria, the County shall have the option of (1) terminating the Agreement after it has given the Contractor/Consultant written notice and an opportunity to demonstrate the agency's determination of false certification was in error pursuant to Section 287.135(5)(a), Florida Statutes, or (2) maintaining the Agreement if the conditions of Section 287.135(4), Florida Statutes, are met. 9.6 CONTRACT DOCUMENTS This contract consists of the Request for Proposals, any addenda, the Form of Agreement (Articles I-IX), the CONSULTANT'S response to the RFQ, the documents referred to in the -10- Form of Agreement as a part of this Agreement, including Attachments A and B, and modifications made after execution by written amendment. In the event of any conflict between any of the Contract documents, the one imposing the greater burden on the CONSULTANT will control. 9.7 PUBLIC ENTITIES CRIMES A person or affiliate who has been placed on the convicted vendor list following a conviction for public entity crime may not submit a bid on contracts to provide any goods or services to a public entity, may not submit a bid on a contract with a public entity for the construction or repair of a public building or public work, may not submit bids on leases of real property to public entity, may not be awarded or perform work as a contractor, supplier, subcontractor, or consultant under a contract with any public entity, and may not transact business with any public entity in excess of the threshold amount provided in Section 287.017 of the Florida Statutes, for CATEGORY TWO for a period of 36 months from the date of being placed on the convicted vendor list. By signing this Agreement, CONSULTANT represents that the execution of this Agreement will not violate the Public Entity Crimes Act (Section 287.133, Florida Statutes). Violation of this section shall result in termination of this Agreement and recovery of all monies paid hereto and may result in debarment from COUNTY's competitive procurement activities. In addition to the foregoing, CONSULTANT further represents that there has been no determination, based on an audit, that it or any subconsultant has committed an act defined by Section 287.133, Florida Statutes, as a "public entity crime" and that it has not been formally charged with committing an act defined as a "public entity crime" regardless of the amount of money involved or whether CONUSULTANT has been placed on the convicted vendor list. CONSULTANT will promptly notify the COUNTY if it or any subcontractor or subconsultant is formally charged with an act defined as a "public entity crime" or has been placed on the convicted vendor list. 9.8 MAINTENANCE OF RECORDS AND RIGHT TO AUDIT CONSULTANT shall maintain all books, records, and documents directly pertinent to performance under this Agreement in accordance with generally accepted accounting principles consistently applied. Records shall be retained for a period of ten (10) years from the termination of this agreement or for a period of five years from submission of the final expenditure report as per 2 C.F.R. §200.333, whichever is greater, exceptions as set forth in 2 C.F.R. 200.334. Each party to this Agreement or its authorized representatives shall have reasonable and timely access to such records of each other party to this Agreement for public records purposes during the term of the Agreement and for four years following the termination of this Agreement. If an auditor employed by the COUNTY or Clerk determines that monies paid to CONSULTANT pursuant to this Agreement were spent for purposes not authorized by this Agreement, or were wrongfully retained by the CONSULTANT, the CONSULTANT shall repay the monies together with interest calculated pursuant to Sec. 55.03, of the Florida Statutes, running from the date the monies were paid by the COUNTY. -ll- Right to Audit Availability of Records. The records of the parties to this Agreement relating to the Project, which shall include but not be limited to accounting records (hard copy, as well as computer readable data if it can be made available; subcontract files (including proposals of successful and unsuccessful bidders, bid recaps, bidding instructions, bidders list, etc); original estimates; estimating work sheets; correspondence; change order files (including documentation covering negotiated settlements); backcharge logs and supporting documentation; general ledger entries detailing cash and trade discounts earned, insurance rebates and dividends; any other supporting evidence deemed necessary by County or the Monroe County Office of the Clerk of Court and Comptroller (hereinafter referred to as "County Clerk") to substantiate charges related to this agreement, and all other agreements, sources of information and matters that may in County's or the County Clerk's reasonable judgment have any bearing on or pertain to any matters, rights, duties or obligations under or covered by any contract document (all foregoing hereinafter referred to as "Records") shall be open to inspection and subject to audit and/or reproduction by County's representative and/or agents or the County Clerk. County or County Clerk may also conduct verifications such as, but not limited to, counting employees at the job site, witnessing the distribution of payroll, verifying payroll computations, overhead computations, observing vendor and supplier payments, miscellaneous allocations, special charges, verifying information and amounts through interviews and written confirmations with employees, Subcontractors, suppliers, and contractors representatives. All records shall be kept for ten (10) years after the termination of this agreement or for a period of five (5) years from the submission of the final expenditure report. The County Clerk possesses the independent authority to conduct an audit of Records, assets, and activities relating to this Project. If any auditor employed by the Monroe County or County Clerk determines that monies paid to CONSULTANT pursuant to this Agreement were spent for purposes not authorized by this Agreement, the CONSULTANT shall repay the monies together with interest calculated pursuant to Section 55.03, F.S., running form the date the monies were paid to CoONSULTANT. The right to audit provisions survives the termination of expiration of this Agreement. 9.9 GOVERNING LAW, VENUE, INTERPRETATION, COSTS, AND FEES This Agreement shall be governed by and construed in accordance with the laws of the State of Florida applicable to contracts made and to be performed entirely in the State. In the event that any cause of action or administrative proceeding is instituted for the enforcement or interpretation of this Agreement, COUNTY and CONSULTANT agree that venue shall lie in the 161h Judicial Circuit, Monroe County, Florida, in the appropriate court or before the appropriate administrative body. This agreement shall not be subject to arbitration. Mediation proceedings initiated and conducted pursuant to this Agreement shall be in accordance with the Florida Rules of Civil Procedure and usual and customary procedures required by the circuit court of Monroe County. 9.10 SEVERABILITY If any term, covenant, condition or provision of this Agreement (or the application thereof to any circumstance or person) shall be declared invalid or unenforceable to any extent by a court of competent jurisdiction, the remaining terms, covenants, conditions and provisions of this Agreement, shall not be affected thereby; and each remaining term, covenant, condition and provision of this Agreement shall be valid and shall be enforceable to the -12- fullest extent permitted by law unless the enforcement of the remaining terms, covenants, conditions and provisions of this Agreement would prevent the accomplishment of the original intent of this Agreement. The COUNTY and CONSULTANT agree to reform the Agreement to replace any stricken provision with a valid provision that comes as close as possible to the intent of the stricken provision. 9.11 ATTORNEYS FEES AND COSTS The COUNTY and CONSULTANT agree that in the event any cause of action or administrative proceeding is initiated or defended by any party relative to the enforcement or interpretation of this Agreement, the prevailing party shall be entitled to reasonable attorney's fees, court costs, investigative, and out-of-pocket expenses, as an award against the non-prevailing party, and shall include attorney's fees, courts costs, investigative, and out-of-pocket expenses in appellate proceedings. 9.12 BINDING EFFECT The terms, covenants, conditions, and provisions of this Agreement shall bind and inure to the benefit of the COUNTY and CONSULTANT and their respective legal representatives, successors, and assigns. 9.13 AUTHORITY Each party represents and warrants to the other that the execution, delivery and performance of this Agreement have been duly authorized by all necessary County and corporate action, as required by law. 9.14 CLAIMS FOR FEDERAL OR STATE AID CONSULTANT and COUNTY agree that each shall be, and is, empowered to apply for, seek, and obtain federal and state funds to further the purpose of this Agreement.Any conditions imposed as a result of funding that effect the Project will be provided to each party. 9.15 ADJUDICATION OF DISPUTES OR DISAGREEMENTS COUNTY and CONSULTANT agree that all disputes and disagreements shall be attempted to be resolved by meet and confer sessions between representatives of each of the parties. If the issue or issues are still not resolved to the satisfaction of the parties, then any party shall have the right to seek such relief or remedy as may be provided by this Agreement or by Florida law. This provision does not negate or waive the provisions of paragraph 9.5 concerning termination or cancellation. 9.16 COOPERATION In the event any administrative or legal proceeding is instituted against either party relating to the formation, execution, performance, or breach of this Agreement, COUNTY and CONSULTANT agree to participate, to the extent required by the other party, in all proceedings, hearings, processes, meetings, and other activities related to the substance of this Agreement or provision of the services under this Agreement. COUNTY and CONSULTANT specifically agree that no party to this Agreement shall be required to enter -13- into any arbitration proceedings related to this Agreement. 9.17 NONDISCRIMINATION The parties agree that there will be no discrimination against any person, and it is expressly understood that upon a determination by a court of competent jurisdiction that discrimination has occurred, this Agreement automatically terminates without any further action on the part of any party, effective the date of the court order. The parties agree to comply with all Federal and Florida statutes, and all local ordinances, as applicable, relating to nondiscrimination. These include but are not limited to: 1) Title VI I of the Civil Rights Act of 1964 (PL 88-352) which prohibits discrimination in employment on the basis of race, color, religion, sex, and national origin; 2) Title IX of the Education Amendment of 1972, as amended (20 USC ss. 1681-1683, and 1685-1686), which prohibits discrimination on the basis of sex; 3) Section 504 of the Rehabilitation Act of 1973, as amended (20 USC s. 794), which prohibits discrimination on the basis of handicaps; 4) The Age Discrimination Act of 1975, as amended (42 USC ss. 6101- 6107) which prohibits discrimination on the basis of age; 5) The Drug Abuse Office and Treatment Act of 1972 (PL 92-255), as amended, relating to nondiscrimination on the basis of drug abuse; 6) The Comprehensive Alcohol Abuse and Alcoholism Prevention, Treatment and Rehabilitation Act of 1970 (PL 91-616), as amended, relating to nondiscrimination on the basis of alcohol abuse or alcoholism; 7) The Public Health Service Act of 1912, ss. 523 and 527 (42 USC ss. 690dd-3 and 290ee-3), as amended, relating to confidentiality of alcohol and drug abuse patient records; 8) Title VIII of the Civil Rights Act of 1968 (42 USC s.3601 et seq.), as amended, relating to nondiscrimination in the sale, rental or financing of housing; 9) The Americans with Disabilities Act of 1990 (42 USC s. 12101 Note), as may be amended from time to time, relating to nondiscrimination on the basis of disability; 10) Monroe County Code, Chapter 14, Article II, which prohibits discrimination on the basis of race, color, sex, religion, disability, national origin, ancestry, sexual orientation, gender identity or expression, familial status or age; 11) Any other nondiscrimination provisions in any Federal or state statutes which may apply to the parties hereto, or the subject matter of, this Agreement. As amended by Executive Orders 11375 and 12086, and the regulations issued pursuant hereto. During the performance of this Agreement, the CONSULTANT, in accordance with Equal Employment Opportunity(30 Fed. Reg. 12319, 12935, 3 C.F.R. Part, 1964-1965 Comp., p. 339), as amended by Executive Order 11375, Amending Executive Order 11246 Relating to Equal Employment Opportunity, and implementing regulations at 41 C.F.R. Part 60 (Office of Federal Contract Compliance Programs, Equal Employment Opportunity, Department of Labor). See 2 C.F.R. Part 200,Appendix II, C, agrees as follows: 1). The CONSULTANT will not discriminate against any employee or applicant for employment because of race, color, religion, sex, sexual orientation, gender identity, or national origin. The CONSULTANT will take affirmative action to ensure that applicants are employed, and that employees are treated during employment, without regard to their race, color, religion, sex, sexual orientation, gender identity, or national origin. Such action shall include, but not be limited to the following: Employment, upgrading, demotion, or transfer, recruitment or recruitment advertising; layoff or termination; rates of pay or other forms of compensation; and selection for training, including apprenticeship. The -14- CONSULTANT agrees to post in conspicuous places, available to employees and applicants for employment, notices to be provided by the contracting officer setting forth the provisions of this nondiscrimination clause. 2).The CONSULTANT will, in all solicitations or advertisements for employees placed by or on behalf of the CONSULTANT, state that all qualified applicants will receive consideration for employment without regard to race, color, religion, sex, sexual orientation, gender identity, or national origin. 3).The CONSULTANT will not discharge or in any other manner discriminate against any employee or applicant for employment because such employee or applicant has inquired about, discussed, or disclosed the compensation of the employee or applicant or another employee or applicant. This provision shall not apply to instances in which an employee who has access to the compensation information of other employees or applicants as a part of such employee's essential job functions discloses the compensation of such other employees or applicants to individuals who do not otherwise have access to such information, unless such disclosure is in response to a formal complaint or charge, in furtherance of an investigation, proceeding, hearing, or action, including an investigation conducted by the employer, or is consistent with the CONSULTANT's legal duty to furnish information. 4).The CONSULTANT will send to each labor union or representative of workers with which it has a collective bargaining agreement or other contract or understanding, a notice to be provided by the agency contracting officer, advising the labor union or workers' representative of the CONSULTANT's commitments under section 202 of Executive Order 11246 of September 24, 1965, and shall post copies of the notice in conspicuous places available to employees and applicants for employment. 5).The CONSULTANT will comply with all provisions of Executive Order 11246 of September 24, 1965, and of the rules, regulations, and relevant orders of the Secretary of Labor. 6).The CONSULTANT will furnish all information and reports required by Executive Order 11246 of September 24, 1965, and by the rules, regulations, and orders of the Secretary of Labor, or pursuant thereto, and will permit access to his books, records, and accounts by the contracting agency and the Secretary of Labor for purposes of investigation to ascertain compliance with such rules, regulations, and orders. 7),In the event of the CONSULTANT's non-compliance with the nondiscrimination clauses of this contract or with any of such rules, regulations, or orders, this contract may be canceled, terminated or suspended in whole or in part and the CONSULTANT may be declared ineligible for further Government contracts in accordance with procedures authorized in Executive Order 11246 of September 24, 1965, and such other sanctions may be imposed and remedies invoked as provided in Executive Order 11246 of September 24, 1965, or by rule, regulation, or order of the Secretary of Labor, or as otherwise provided by law. -15- 8) The CONSULTANT will include the portion of the sentence immediately preceding paragraph (1) and the provisions of paragraphs (1) through (7) in every subcontract or purchase order unless exempted by rules, regulations, or orders of the Secretary of Labor issued pursuant to section 204 of Executive Order 11246 of September 24, 1965, so that such provisions will be binding upon each subcontractor or vendor. The CONSULTANT will take such action with respect to any subcontract or purchase order as the administering agency may direct as a means of enforcing such provisions, including sanctions for non- compliance; provided, however, that in the event a contractor becomes involved in, or is threatened with, litigation with a subcontractor or vendor as a result of such direction by the administering agency, the contractor may request the United States to enter into such litigation to protect the interests of the United States. 9.18 COVENANT OF NO INTEREST CONSULTANT and COUNTY covenant that neither presently has any interest, and shall not acquire any interest, which would conflict in any manner or degree with its performance under this Agreement, and that only interest of each is to perform and receive benefits as recited in this Agreement. 9.19 CODE OF ETHICS COUNTY agrees that officers and employees of the COUNTY recognize and will be required to comply with the standards of conduct for public officers and employees as delineated in Section 112.313, Florida Statutes, regarding, but not limited to, solicitation or acceptance of gifts; doing business with one's agency; unauthorized compensation; misuse of public position, conflicting employment or contractual relationship; and disclosure or use of certain information. 9.20 NO SOLICITATION/PAYMENT The CONSULTANT and COUNTY warrant that, in respect to itself, it has neither employed nor retained any company or person, other than a bona fide employee working solely for it, to solicit or secure this Agreement and that it has not paid or agreed to pay any person, company, corporation, individual, or firm, other than a bona fide employee working solely for it, any fee, commission, percentage, gift, or other consideration contingent upon or resulting from the award or making of this Agreement. For the breach or violation of the provision, the CONSULTANT agrees that the COUNTY shall have the right to terminate this Agreement without liability and, at its discretion, to offset from monies owed, or otherwise recover, the full amount of such fee, commission, percentage, gift, or consideration. 9.21 PUBLIC ACCESS. Public Records Compliance. The CONSULTANT must comply with Florida public records laws, including but not limited to Chapter 119, Florida Statutes and Section 24 of article I of the Constitution of Florida. The County and CONSULTANT shall allow and permit reasonable access to, and inspection of, all documents, records, papers, letters or other "public record" materials in its possession or under its control subject to the provisions of Chapter 119, Florida Statutes, and made or received by the County and CONSULTANT in -16- conjunction with this contract and related to contract performance. The County shall have the right to unilaterally cancel this contract upon violation of this provision by the CONSULTANT. Failure of the CONSULTANT to abide by the terms of this provision shall be deemed a material breach of this contract and the County may enforce the terms of this provision in the form of a court proceeding and shall, as a prevailing party, be entitled to reimbursement of all attorney's fees and costs associated with that proceeding. This provision shall survive any termination or expiration of the contract. The CONSULTANT is encouraged to consult with its advisors about Florida Public Records Law in order to comply with this provision. Pursuant to F.S. 119.0701 and the terms and conditions of this contract, the CONSULTANT is required to: (1) Keep and maintain public records that would be required by the County to perform the service. (2) Upon receipt from the County's custodian of records, provide the County with a copy of the requested records or allow the records to be inspected or copied within a reasonable time at a cost that does not exceed the cost provided in this chapter or as otherwise provided by law. (3) Ensure that public records that are exempt or confidential and exempt from public records disclosure requirements are not disclosed except as authorized by law for the duration of the contract term and following completion of the contract if the CONSULTANT does not transfer the records to the County. (4) Upon completion of the contract, transfer, at no cost, to the County all public records in possession of the CONSULTANT or keep and maintain public records that would be required by the County to perform the service. If the CONSULTANT transfers all public records to the County upon completion of the contract, the CONSULTANT shall destroy any duplicate public records that are exempt or confidential and exempt from public records disclosure requirements. If the CONSULTANT keeps and maintains public records upon completion of the contract, the CONSULTANT shall meet all applicable requirements for retaining public records. All records stored electronically must be provided to the County, upon request from the County's custodian of records, in a format that is compatible with the information technology systems of the County. (5) A request to inspect or copy public records relating to a County contract must be made directly to the County, but if the County does not possess the requested records, the County shall immediately notify the CONSULTANT of the request,and the CONSULTANT must provide the records to the County or allow the records to be inspected or copied within a reasonable time. If the CONSULTANT does not comply with the County's request for records, the County shall enforce the public records contract provisions in accordance with the contract, notwithstanding the County's option and right to unilaterally cancel this contract upon violation of this provision by the CONSULTANT. A CONSULTANT who fails to provide the public records to the County or pursuant to a valid public records request within a reasonable time may be subject to penalties under section119.10, Florida Statutes. The CONSULTANT shall not transfer custody, release, alter, destroy or otherwise dispose of any public records unless or otherwise provided in this provision or as otherwise provided by law. -17- IF THE CONSULTANT HAS QUESTIONS REGARDING THE APPLICATION OF CHAPTER 119, FLORIDA STATUTES, TO THE CONSULTANT'S DUTY TO PROVIDE PUBLIC RECORDS RELATING TO THIS CONTRACT, CONTACT THE CUSTODIAN OF PUBLIC RECORDS, BRIAN BRADLEY AT PHONE# 305-292-3470 BRADLEY-BRIAN(a,MONROECOUNTY-FL.GOV, MONROE COUNTY ATTORNEY'S OFFICE 1111 12TH Street, SUITE 408, KEY WEST, FL 33040. 9.22 NON-WAIVER OF IMMUNITY Notwithstanding the provisions of Sec. 768.28, Florida Statutes, the participation of the CONSULTANT and the COUNTY in this Agreement and the acquisition of any commercial liability insurance coverage, self-insurance coverage, or local government liability insurance pool coverage shall not be deemed a waiver of immunity to the extent of liability coverage, nor shall any contract entered into by the COUNTY be required to contain any provision for waiver. 9.23 PRIVILEGES AND IMMUNITIES All of the privileges and immunities from liability, exemptions from laws, ordinances, and rules and pensions and relief, disability, workers' compensation, and other benefits which apply to the activity of officers, agents, or employees of any public agents or employees of the COUNTY, when performing their respective functions under this Agreement within the territorial limits of the COUNTY shall apply to the same degree and extent to the performance of such functions and duties of such officers, agents, volunteers, or employees outside the territorial limits of the COUNTY. 9.24 LEGAL OBLIGATIONS AND RESPONSIBILITIES Non-Delegation of Constitutional or Statutory Duties. This Agreement is not intended to, nor shall it be construed as, relieving any participating entity from any obligation or responsibility imposed upon the entity by law except to the extent of actual and timely performance thereof by any participating entity, in which case the performance may be offered in satisfaction of the obligation or responsibility. Further, this Agreement is not intended to, nor shall it be construed as, authorizing the delegation of the constitutional or statutory duties of the COUNTY, except to the extent permitted by the Florida constitution, state statute, and case law. 9.25 NON-RELIANCE BY NON-PARTIES No person or entity shall be entitled to rely upon the terms, or any of them, of this Agreement to enforce or attempt to enforce any third-party claim or entitlement to or benefit of any service or program contemplated hereunder, and the CONSULTANT and the COUNTY agree that neither the CONSULTANT nor the COUNTY or any agent, officer, or employee of either shall have the authority to inform, counsel, or otherwise indicate that any particular individual or group of individuals, entity or entities, have entitlements or benefits -18- under this Agreement separate and apart, inferior to, or superior to the community in general or for the purposes contemplated in this Agreement. 9.26 ATTESTATIONS AND TRUTH IN NEGOTIATION CONSULTANT agrees to execute such documents as COUNTY may reasonably require, including a Public Entity Crime Statement, an Ethics Statement, and a Drug-Free Workplace Statement. Signature of this Agreement by CONSULTANT shall act as the execution of a truth in negotiation certificate stating that wage rates and other factual unit costs supporting the compensation pursuant to the Agreement are accurate, complete, and current at the time of contracting. The original contract price and any additions thereto shall be adjusted to exclude any significant sums by which the agency determines the contract price was increased due to inaccurate, incomplete, or concurrent wage rates and other factual unit costs. All such adjustments must be made within one year following the end of the Agreement. 9.27 NO PERSONAL LIABILITY No covenant or agreement contained herein shall be deemed to be a covenant or agreement of any member, officer, agent or employee of Monroe County in his or her individual capacity, and no member, officer, agent or employee of Monroe County shall be liable personally on this Agreement or be subject to any personal liability or accountability by reason of the execution of this Agreement. 9.28 E-VERIFY SYSTEM Beginning January 1, 2021, in accordance with F.S. 448.095, the Contractor and any subcontractor shall register with and shall utilize the U.S. Department of Homeland Security's E-Verify system to verify the work authorization status of all new employees hired by the Contractor during the term of the Contract and shall expressly require any subcontractors performing work or providing services pursuant to the Contract to likewise utilize the U.S. Department of Homeland Security's E-Verify system to verify the work authorization status of all new employees hired by the subcontractor during the Contract term. Any subcontractor shall provide an affidavit stating that the subcontractor does not employ, contract with, or subcontract with an unauthorized alien. The Contractor shall comply with and be subject to the provisions of F.S. 448.095. 9.29 INSPECTOR GENERAL The CONSULTANT agrees to comply with s.20.055(5) Florida Statutes, and to incorporate in all subcontracts the obligation to comply with s.20.055(5), Florida Statutes. "(5) It is the duty of every state officer, employee, agency, special district, board, commission, CONSULTANT, CONTRACTOR, and subcontractor to cooperate with the inspector general in any investigation, audit, inspection, review, or hearing pursuant to this section. 9.30 ETHICS CONSULTANT warrants that he/it had not employed, retained or otherwise had act on his/its behalf any former County officer or employee subject to the prohibition of Section 2 of Ordinance No. 010-1990 or any County officer or employee in violation of Section 3 of Ordinance No. 020-1990. For breach or violation of this provision the County may, in its discretion, terminate this contract without liability and may also, in its discretion, deduct -19- from the contract or purchase price, or otherwise recover the full amount of any fee, commission, percentage, gift, or consideration paid to the former County officer or employee. 9.31 OWNERSHIP OF THE PROJECT DOCUMENTS The documents prepared by the CONSULTANT for this Project belong to the County and may not be reproduced and copied without acknowledgement or permission of the COUNTY. 9.32. SUCCESSORS AND ASSIGNS The CONSULTANT shall not assign or subcontract its obligations under this agreement, except in writing and with the prior written approval of the Board of County Commissioners for Monroe County, which approval shall be subject to such conditions and provisions as the Board may deem necessary. This paragraph shall be incorporated by reference into any assignment or subcontract and any assignee or subcontractor shall comply with all of the provisions of this Agreement. Subject to the provisions of the immediately preceding sentence, each party hereto binds itself, its successors, assigns and legal representatives to the other and to the successors, assigns and legal representatives of such other party. 9.33. FEDERAL CONTRACT REQUIREMENTS The CONSULTANT and/or CONTRACTOR and its Subcontractors must follow the provisions, as applicable, as set forth in 2 C.F.R. §200.326 Contract provisions and Appendix II to 2 C.F.R. Part 200, as amended, and is bound by all applicable state and federal laws and regulations. 9.33.1 DAVIS-BACON ACT As amended (40 U.S.C. §§3141-3148). When required by Federal program legislation, which includes emergency Management Preparedness Grant Program, Homeland Security Grant Program, Nonprofit Security Grant Program, Tribal Homeland Security Grant Program, Port Security Grant Program and Transit Security Grant Program, all prime construction contracts in excess of $2,000 awarded by non-Federal entities must comply with the Davis-Bacon Act (40 U.S.C. §§3141-3144, and §§3146-3148) as supplemented by Department of Labor regulations (29 CFR Part 5, "Labor Standards Provisions Applicable to Contracts Covering Federally Financed and Assisted Construction"). In accordance with the statute, CONSULTANTs must be required to pay wages to laborers and mechanics at a rate not less than the prevailing wages specified in a wage determination made by the Secretary of Labor. In addition, CONSULTANTs must be required to pay wages not less than once a week. If applicable, the COUNTY must place a current prevailing wage determination issued by the Department of Labor in each solicitation. The decision to award a contract or subcontract must be conditioned upon the acceptance of the wage determination. The COUNTY must report all suspected or reported violations to the Federal awarding agency. When required by Federal program legislation, which includes emergency Management Preparedness Grant Program, Homeland Security Grant Program, Nonprofit Security Grant Program, Tribal Homeland Security Grant Program, Port Security Grant Program and Transit Security Grant Program (it does not apply to other FEMA grant and cooperative agreement programs, including the Public Assistance Program), the CONSULTANTs , in -20- contracts for construction repair work above $2,000 in situations where the Davis-Bacon applies, must also comply with the Copeland "Anti-Kickback" Act (40 U.S.C. § 3145), as supplemented by Department of Labor regulations (29 CFR Part 3, "CONSULTANTs and SUBCONSULTANTs on Public Building or Public Work Financed in Whole or in Part by Loans or Grants from the United States"). As required by the Act, each CONSULTANT or subrecipient is prohibited from inducing, by any means, any person employed in the construction, completion, or repair of public work, to give up any part of the compensation to which he or she is otherwise entitled. The COUNTY must report all suspected or reported violations to the Federal awarding agency. (1) CONSULTANT. The CONSULTANT shall comply with 18 U.S.C. § 874, 40 U.S.C. § 3145, and the requirements of 29 C.F.R. pt. 3 as may be applicable, which are incorporated by reference into this contract. (2) Subcontracts. The CONSULTANT or SUBCONSULTANT shall insert in any subcontracts the clause above and such other clauses as the FEMA may by appropriate instructions require, and also a clause requiring the SUBCONSULTANT s to include these clauses in any lower tier subcontracts. The prime CONSULTANT shall be responsible for the compliance by any SUBCONSULTANT or lower tier SUBCONSULTANT with all of these contract clauses. Breach. A breach of the contract clauses above may be grounds for termination of the contract, and for debarment as a CONSULTANT and SUBCONSULTANT as provided in 29 C.F.R. § 5.12.Additionally, in accordance with the regulation, each contractor and subcontractor must furnish each week a statement with respect to the wages paid each of its employees engaged in work covered by the Copeland Anti-Kickback Act and the Davis Bacon Act during the preceding weekly payroll period. The report shall be delivered by the contractor or subcontractor, within seven days after the regular payment date of the payroll period, to a representative of a Federal or State agency in charge at the site of the building or work. Additionally, in accordance with the regulation, each contractor and subcontractor must furnish each week a statement with respect to the wages paid each of its employees engaged in work covered by the Copeland Anti-Kickback Act and the Davis Bacon Act during the preceding weekly payroll period. The report shall be delivered by the contractor or subcontractor, within seven days after the regular payment date of the payroll period, to a representative of a Federal or State agency in charge at the site of the building or work. 9.33.2 COPELAND "ANTI-KICKBACK" ACT The CONSULTANT will comply with the Copeland Anti-Kickback Act of 1986, 41 U.S.C. Chapter 87 which outlaws and prescribes penalties for"kickbacks" of wages in federally financed or assisted construction activities. -21- 9.33.3 CONTRACT WORK HOURS AND SAFETY STANDARDS ACT(40 U.S.C. 3701-3708). Where applicable, which includes all FEMA grant and cooperative agreement programs, all contracts awarded by the COUNTY in excess of$100,000 that involve the employment of mechanics or laborers must comply with 40 U.S.C.§§ 3702 and 3704, as supplemented by Department of Labor regulations (29 CFR Part 5). Under 40 U.S.C. §3702 of the Act, each CONSULTANT must compute the wages of every mechanic and laborer on the basis of a standard work week of 40 hours. Work in excess of the standard work week is permissible provided that the worker is compensated at a rate of not less than one and a half times the basic rate of pay for all hours worked in excess of 40 hours in the work week. The requirements of 40 U.S.C. 3704 are applicable to construction work and provide that no laborer or mechanic must be required to work in surroundings or under working conditions which are unsanitary, hazardous or dangerous. These requirements do not apply to the purchases of supplies or materials or articles ordinarily available on the open market, or contracts for transportation or transmission of intelligence. Compliance with the Contract Work Hours and Safety Standards Act. (1) Overtime requirements. No contractor or subcontractor contracting for any part of the contract work which may require or involve the employment of laborers or mechanics shall require or permit any such laborer or mechanic in any workweek in which he or she is employed on such work to work in excess of forty hours in such workweek unless such laborer or mechanic receives compensation at a rate not less than one and one-half times the basic rate of pay for all hours worked in excess of forty hours in such workweek. (2) Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph 29 C.F.R. § 5.5(b)(1) the contractor and any subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph 29 C.F.R. § 5.5 (b)(1), in the sum of $27 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph29 C.F.R. § 5.5 (b)(1). (3) Withholding for unpaid wages and liquidated damages. The Federal agency shall upon its own action or upon written request of an authorized representative of the Department of Labor withhold or cause to be withheld, from any moneys payable on account of work performed by the contractor or subcontractor under any such contract or any other Federal contract with the same prime contractor, or any other federally- assisted contract subject to the Contract Work Hours and Safety Standards Act, which is held by the same prime contractor, such sums as may be determined to be necessary to satisfy any liabilities of such contractor or subcontractor for unpaid wages and liquidated damages as provided in the clause set forth in paragraph29 C.F.R. § 5.5 (b)(2). (4) Subcontracts. The contractor or subcontractor shall insert in any subcontracts the clauses set forth in paragraph 29 C.F.R. § 5.5 (b)(1) through (4) and also a clause requiring the subcontractors to include these clauses in any lower tier subcontracts. The prime contractor shall be responsible for compliance by any subcontractor or lower tier -22- subcontractor with the clauses set forth in paragraphs 29 C.F.R. § 5.5 (1) through (4). (5) Federal Fair Labor Standards Act, 29 U.S.C. Section 201 et seq., requiring that covered employees be paid at least minimum prescribed wage, and also that they be paid one and one-half times their basic wage rates for all hours worked in excess of the prescribed work-week. 9.33.4 RIGHTS TO INVENTIONS Made Under a Contract or Agreement. If the Federal award meets the definition of "funding agreement" under 37 CFR §401.2 (a) and the recipient or subrecipient wishes to enter into a contract with a small business firm or nonprofit organization regarding the substitution of parties, assignment or performance of experimental, developmental, or research work under that "funding agreement," the recipient or subrecipient must comply with the requirements of 37 CFR Part 401, "Rights to Inventions Made by Nonprofit Organizations and Small Business Firms Under Government Grants, Contracts and Cooperative Agreements," and any implementing regulations issued by the awarding agency. 9.33.5 CLEAN AIR ACT (42 U.S.C. 7401-7671q.) AND THE FEDERAL WATER POLLUTION CONTROL ACT Commonly referred to as the Clean Water Act of 1977: (33 U.S.C. 1251-1387), as amended—Contracts and subgrants of amounts in excess of$150,000 must comply with all applicable standards, orders or regulations issued pursuant to the Clean Air Act, as amended (42 U.S.C. 7401-7671 q) and the Federal Water Pollution Control Act as amended (33 U.S.C. 1251-1387). Violations must be reported to the Federal awarding agency/FEMA and the appropriate Regional Office of the Environmental Protection Agency (EPA). The Clean Air Act (42 U.S.C. 7401-7671 q.) and the Federal Water Pollution Control Act (33 U.S.C. 1251-1387), as amended—applies to Contracts and subgrants of amounts in excess of $150,000. The contractor agrees to include these requirements in each subcontract exceeding $150,000 financed in whole or in part with Federal assistance provided by FEMA/Federal agency. The contractor agrees to report each violation to the COUNTY and understands and agrees that the COUNTY will, in turn, report each violation as required to assure notification to FEMA/Federal Agency and the appropriate EPA Regional Office. CONTRACTORS agrees to comply with all applicable standards, orders, or requirements issued under Section 112 and 306 of the Clean Air Act (42 U.S.C. 7401-7671 q; 42 U.S.C. 1857), Section 508 of the Clean Water Act as amended (33 U.S.C. 1251-1387), Executive Order 11738, and the U.S. Environmental Protection Agency Regulations (40 C.F.R., Part 15 and 61) and will report violations to FEMA and the Regional Office of the Environmental Protection Agency (EPA). This clause shall be added to any subcontracts. 9.33.6 DEBARMENT AND SUSPENSION: (EXECUTIVE ORDERS 12549 AND 12689) A contract award under a "covered transaction" (see 2 CFR 180.220) must not be made to parties listed on the government wide exclusions in the System for Award Management (SAM), in accordance with the OMB guidelines at 2 CFR Part 180 that implement Executive Orders 12549 (3 CFR part 1986 Comp., p. 189) and 12689 (3 CFR part 1989 Comp., p. 235), "Debarment and Suspension." And the Department of Homeland Security's -23- regulations at 2 C.F.R. Part 300 (Nonprocurement Debarment and suspension) SAM Exclusions contains the names of parties debarred, suspended, or otherwise excluded by agencies, as well as parties declared ineligible under statutory or regulatory authority other than Executive Order 12549. SAM exclusions can be accessed at vvww.sam. gLy. Contractor is required to verify that none of the contractor's principals (defined at 2 C.F.R. §180.935) or its affiliates (defined at 2 C.F.R. §180.905) are excluded (defined at 2 C.F.R. §180.940) or disqualified (defined at 2 C.F.R. §180.935). the contractor must comply with 2 C.F.R. pt. 180, subpart C and 2 C.F.R. pt. 3000, subpart C, and must include a requirement to comply with these regulations in any lower tier covered transaction it enters into. This certification is a material representation of fact relied upon by the COUNTY and other State and Federal agencies. If it is later determined that the contractor did not comply with 2 C.F.R. pt. 180, subpart C and 2 C.F.R. pt. 3000, subpart C, in addition to remedies available to the COUNTY and other State agencies, the Federal Government may pursue available remedies, including but not limited to suspension and/or debarment. Bidders or Proposers agree to comply with the requirements of 2 C.F.R. pt. 180, subpart C and 2 C.F.R. pt. 3000, subpart C while this offer is valid and throughout the period of any contract that may arise from this offer. The Bidder or Proposer further agrees to include a provision requiring such compliance in its lower tier covered transactions. i. This contract is a covered transaction for purposes of 2 C.F.R.pt. 180 and 2 C.F.R. pt. 3000. As such the contractor is required to verify that none of the contractor, its principals (defined at 2 C.F.R. § 180.995), or its affiliates (defined at 2 C.F.R. § 180.905) are excluded (defined at 2 C.F.R. § 180.940) or disqualified (defined at 2 C.F.R. § 180.935). ii. The contractor must comply with 2 C.F.R. pt. 180, subpart C and 2 C.F.R. pt. 3000, subpart C and must include a requirement to comply with these regulations in any lower tier covered transaction it enters into. iii. This certification is a material representation of fact relied upon by the Division. If it is later determined that the contractor did not comply with 2 C.F.R. pt. 180, subpart C and 2 C.F.R. pt. 3000, subpart C, in addition to remedies available to the Division, the Federal Government may pursue available remedies, including but not limited to suspension and/or debarment. iv. The bidder or proposer agrees to comply with the requirements of 2 C.F.R. pt. 180, subpart C and 2 C.F.R. pt. 3000, subpart C while this offer is valid and throughout the period of any contract that may arise from this offer. The bidder or proposer further agrees to include a provision requiring such compliance in its lower tier covered transactions. 9.33.7 BYRD ANTI-LOBBYING AMENDMENT: (31 U.S.C. 1352) CONTRACTOR and CONSULTANT that apply or bid for an award exceeding $100,000 must file the required certification. Each tier certifies to the tier above that it will not and has not used Federal appropriated funds to pay any person or organization for influencing or attempting to influence an officer or employee of any agency, a member of Congress, officer or employee of Congress, or an employee of a member of Congress in connection with obtaining any Federal contract, grant or any other award covered by 31 U.S.C. 1352. Each tier must also disclose any lobbying with non- Federal funds that takes place in connection with obtaining any Federal -24- award. Such disclosures are forwarded from tier to tier up to the . recipient who in turn will forward the certification(s) to the awarding agency. If award exceeds $100,00, the attached certification must be signed and submitted by the contractor to the COUNTY.) 9.33.8 COMPLIANCE WITH PROCUREMENT OF RECOVERED MATERIALS As set forth in 2 CFR § 200.323. CONTRACTOR must comply with section 6002 of the Solid Waste Disposal Act, as amendment by the Resource Conservation and Recovery Act and the provisions of the State Energy Conservation Plan adopted pursuant thereto. The requirements of Section 6002 include procuring only items designed in guidelines of the Environmental Protection Agency (EPA at 40 CPR part 247 that contain the highest percentage of recovered materials practicable, consistent with maintaining a satisfactory level of competition, where the purchase price of the item exceeds $10,000 or the value of the quantity acquired during the preceding fiscal year exceeded $10,000; procuring solid waste management services in a manner that maximizes energy and resource recovery; and establishing an affirmative procurement program for procurement of recovered materials identified in the EPA guidelines. In the performance of this contract, the Contractor shall make maximum use of products containing recovered materials that are EPA-designated items unless the product cannot be acquired- 1. Competitively within a timeframe providing for compliance with the contract performance schedule; 2. Meeting contract performance requirements; or 3. At a reasonable price. Information about this requirement, along with the list of EPA-designated items, is available at EPA's Comprehensive Procurement Guidelines web site, hii s://www.e a. ov/smm/corn rehensive- rocuremeni- guideline-cpg-program. The Contractor also agrees to comply with all other applicable requirements of Section 6002 of the Solid Waste Disposal Act. 9.33.9 PROHIBITION ON CERTAIN TELECOMMUNICATIONS AND VIDEO SURVEILLANCE SERVICES or equipment as set forth in 2 CFR §200.216. Recipients and subrecipients and their contractors and subcontractors may not obligate or expend any federal funds to (1) Procure or obtain; (2) Extend or renew a coniraci to procure or obtain; or (3) Enter into a coniraci (or extend or renew a contract) to procure or obtain gqUjEM2Dj, services, or systems that uses covered telecommunications ui merTt or services as a substantial or essential component of any system, or as critical technology as part of any system. As described in Public .Law------11 -232., section 889, covered telecommunications gLqgjpM2nt. is telecommunications ui merTt produced by Huawei Technologies Company or ZTE Corporation (or anyubsidiar}r or affiliate of such entities). (i) For the purpose of public safety, security of government facilities, physical security surveillance of critical infrastructure, and other national security purposes, video surveillance and telecommunications ui me[2j produced by Hytera Communications Corporation, Hangzhou Hikvision Digital Technology Company, or Dahua Technology Company (or any. �tr iL iary or affiliate of such entities). -25- (ii) Telecommunications or video surveillance services provided by such entities or using such ui meet. (iii) Telecommunications or video surveillance g ui meryt or services produced or provided by an entity that the Secretary of Defense, in consultation with the Director of the National Intelligence or the Director of the Federal Bureau of Investigation, reasonably believes to be an entity owned or controlled by, or otherwise connected to, the government of a covered foreign country. 9.33.10 DOMESTIC PREFERENCE FOR PROCUREMENTS AS SET FORTH IN 2 CFR §200.322 The COUNTY and CONTRACTOR should, to the greatest extent practicable, provide a preference for the purchase, acquisition, or use of goods, products, or materials produced in the United States (including but not limited to iron, aluminum, steel, cement, and other manufactured products). These requirements of this section must be included in all subawards including contracts and purchase orders for work or products under federal award. For purposes of this section: (1) "Produced in the United States" means, for iron and steel products, that all manufacturing processes, from the initial melting stage through the application of coatings, occurred in the United States. (2) "Manufactured products" means items and construction materials composed in whole or in part of non-ferrous metals such as aluminum; plastics and polymer-based products such as polyvinyl chloride pipe; aggregates such as concrete; glass, including optical fiber; and lumber. 9.33.11 AMERICANS WITH DISABILITIES ACT OF 1990 (ADA) The CONSULTANT and CONTRACTOR will comply with all the requirements as imposed by the ADA, the regulations of the Federal government issued thereunder,''L and the assurance by the CONSULTANT and CONTRACTOR pursuant thereto. Disadvantaged Business Enterprise (DBE) Policy and Obligation: It is the policy of the COUNTY that DBEs, as defined in 49 C.F.R. Part 26, as amended, shall have the opportunity to participate in the performance of contracts financed in whole or in part with COUNTY funds under this Agreement. The DBE requirements of applicable federal and state laws and regulations apply to this Agreement. The COUNTY and its CONSULTANT and CONTRACTOR agree to ensure that DBE's have the opportunity to participate in the performance of this Agreement. In this regard, all recipients and CONTRACTORs shall take all necessary and reasonable steps in accordance with applicable federal and state laws and regulations to ensure that the DBE's have the opportunity to compete for and perform contracts. The COUNTY and the CONSULTANT and CONTRACTOR and subcontractors shall not discriminate on the basis of race, color, national origin or sex in the award and performance of contracts, entered pursuant to this Agreement. Consultant and subcontractors will comply with the Rehabilitation Act of 1973, Section 504, 29 U.S.C. 794, regarding nondiscrimination; -26- 9.33.12 2 C.F.R. § 200.321 CONTRACTING WITH SMALL AND MINORITY BUSINESSES, WOMEN'S BUSINESS ENTERPRISES, AND LABOR SURPLUS AREA FIRMS a. If the Sub-Recipient, with the funds authorized by this Agreement, seeks to procure goods or services, then, in accordance with 2 C.F.R. §200.321, the Sub-Recipient shall take the following affirmative steps to assure that minority businesses, women's business enterprises, and labor surplus area firms are used whenever possible: i. Placing qualified small and minority businesses and women's business enterprises on solicitation lists; ii. Assuring that small and minority businesses, and women's business enterprises are solicited whenever they are potential sources; iii. Dividing total requirements, when economically feasible, into smaller tasks or quantities to permit maximum participation by small and minority businesses, and women's business enterprises; iv. Establishing delivery schedules, where the requirement permits, which encourage participation by small and minority businesses, and women's business enterprises; v. Using the services and assistance, as appropriate, of such organizations as the Small Business Administration and the Minority Business Development Agency of the Department of Commerce; and vi. Requiring the prime contractor, if subcontracts are to be let, to take the affirmative steps listed in paragraphs i. through v. of this subparagraph. b. The requirement outlined in subparagraph a. above, sometimes referred to as "socioeconomic contracting," does not impose an obligation to set aside either the solicitation or award of a contract to these types of firms. Rather, the requirement only imposes an obligation to carry out and document the six affirmative steps identified above. c. The "socioeconomic contracting" requirement outlines the affirmative steps that the Sub-Recipient must take; the requirements do not preclude the Sub-Recipient from undertaking additional steps to involve small and minority businesses and women's business enterprises. d. The requirement to divide total requirements, when economically feasible, into smaller tasks or quantities to permit maximum participation by small and minority businesses, and women's business enterprises, does not authorize the Sub-Recipient to break a single project down into smaller components in order to circumvent the micro-purchase or small purchase thresholds so as to utilize streamlined acquisition procedures (e.g. "project splitting"). 9.33.13 ENERGY EFFICIENCY CONTRACTOR will comply with the Energy Policy and Conservation Act (P.L. 94- 163; 42 U.S.C. 6201-6422) and with all mandatory standards and policies relating to energy efficiency and the provisions of the state Energy Conservation Plan adopted pursuant thereto. -27- 9.33.14 FLOOD DISASTER PROTECTION ACT OF 1973 Consultant and contractor and subcontractors to comply with the flood insurance purchase and other requirements of the Flood Disaster Protection Act of 1973, as amended, 42 U.S.C. 50, including requirements regarding the purchase of flood insurance in communities where such insurance is available as a condition for the receipt of any Federal financial assistance for construction or acquisition purposes for use in any area having special flood hazards. The phrase "Federal financial assistance" includes any form of loan, grant, guaranty, insurance payment, rebate, subsidy, disaster assistance loan or grant, or any other form of direct or indirect Federal assistance; For sites located within Special Flood Hazard Areas (SFHA), the Sub-recipient must include a FEMA Model Acknowledgement of Conditions of Mitigation of Property in a Special Flood Hazard Area with FEMA Grant Funds executed by the title holder with the closeout request verifying thatcertain SFHA requirements were satisfied on each of the properties. The Model Acknowledgement can be found at www.fema. ov/ overnmenta/ rangy/sfha condifions.shtm Consultant and contractor and subcontractors will require every building or facility (other than a privately owned residential structure) designed, constructed, or altered with funds provided under this Agreement to comply with the "Uniform Federal Accessibility Standards," (AS) which is Appendix A to 41 C.F.R. Section 101- 19.6 for general type buildings and Appendix A to 24 C.F.R., Part 40 for residential structures.The Sub-recipient will be responsible for conducting inspections to ensure compliance with these specifications by the contractor; 9.33.15 UNIFORM FEDERAL ACCESSIBILITY STANDARDS CONSULTANT and CONTRACTOR will require every building or facility (other than a privately owned residential structure) designed, constructed, or altered with funds provided under this Agreement to comply with the "Uniform Federal Accessibility Standards," (AS) which is Appendix A to 41 C.F.R. Section 101-19.6 for general type buildings and Appendix A to 24 C.F.R., Part 40 for residential structures. The Sub- recipient will be responsible for conducting inspections to ensure compliance with these specifications by the contractor. 9.33.16 NATIONAL HISTORIC PRESERVATION ACT OF 1966 CONSULTANT and CONTRACTOR will assist the awarding agency in assuring compliance with the Preservation of Archeological and Historical Preservation Act of 1966, 16 U.S.C. 54 U.S.C. 3125. CONSULTANT and CONTRACTOR will comply with Section 106 of the National Historic Preservation Act of 1966 (54 U.S.C.), Executive Order 11593, 36 C.F.R., Part 800, and the Preservation of Archaeological and Historical Data Act of 1966 (54 U.S.C. 3125) by: (1) Consulting with the State Historic Preservation Office to identify properties listed in or eligible for inclusion in the National Register of Historic Places that are subject to adverse effects (see 36 C.F.R., Section 800.8) by the proposed activity; and -28- (2) Complying with all requirements established by the State to avoid or mitigate adverse effects upon such properties. (3) Abiding by the terms and conditions of the "Programmatic Agreement Among the Federal Emergency Management Agency, the Florida State Historic Preservation Office, the Florida Division of Emergency Management and the Advisory Council on Historic Preservation, (PA)" which addresses roles and responsibilities of Federal and State entities in implementing Section 106 of the National Historic Preservation Act (NHPA), 54 U.S.C., and implementing regulations in 36 C.F.R., Part 800. (4) When any of the Sub-recipient's projects funded under this Agreement may affect a historic property, as defined in 36 C.F.R., Part 800.16 (1)(1), the Federal Emergency Management Agency (FEMA) may require the Sub-recipient to review the eligible scope of work in consultation with the State Historic Preservation Office (SHPO) and suggest methods of repair or construction that will conform with the recommended approaches set out in the Secretary of Interior's Standards for Rehabilitation and Guidelines for Rehabilitating Historic Buildings 1992 (Standards), the Secretary of the Interior's Guidelines for Archeological Documentation (Guidelines) (48 Federal Register 44734-37), or any other applicable Secretary of Interior standards. If FEMA determines that the eligible scope of work will not conform with the Standards, the Sub-recipient agrees to participate in consultations to develop, and after execution by all parties, to abide by, a written agreement that establishes mitigation and recondition measures, including but not limited to, impacts to archeological sites, and the salvage, storage, and reuse of any significant architectural features that may otherwise be demolished. (5) The Sub-recipient agrees to notify FEMA and the Division if any project funded under this Agreement will involve ground disturbing activities, including, but not limited to: subsurface disturbance; removal of trees; excavation of footings and foundations, and installation of utilities (such as water, sewer, storm drains, electrical, gas, leach lines and septic tanks) except where these activities are restricted solely to areas previously disturbed by the installation, replacement or maintenance of such utilities. FEMA will request the SHPO's opinion on the potential that archeological properties may be present and be affected by such activities. The SHPO will advise the Sub- recipient on any feasible steps to be accomplished to avoid any National Register eligible archaeological property or will make recommendations for the development of a treatment plan for the recovery or archaeological data from the property. If the Sub- recipient is unable to avoid the archeological property, develop, in consultation with SHPO, a treatment plan consistent with the Guidelines and take into account the Advisory Council on Historic Preservation (Council) publication "Treatment of Archeological Properties". The Sub-recipient shall forward information regarding the treatment plan to FEMA, the SHPO and the Council for review. If the SHPO and the Council do not object within fifteen (15) calendar days of receipt of the treatment plan, FEMA may direct the Sub-recipient to implement the treatment plan. If either the Council or the SHPO object, Sub-recipient shall not proceed with the project until the objection is resolved. (6) The Sub-recipient shall notify the Division and FEMA as soon as practicable: (a) of any changes in the approved scope of work for a National Register eligible or listed property; (b) of all changes to a project that may result in a supplemental DSR or modify a LPDM project for a National Register eligible or listed property; (c) if it appears that a project funded under this Agreement will affect a previously unidentified property that may be eligible for inclusion in the National Register or -29- affect a known historic property in an unanticipated manner. The Sub-recipient acknowledges that FEMA may require the Subrecipient to stop construction in the vicinity of the discovery of a previously unidentified property that may eligible for inclusion in the National Register or upon learning that construction may affect a known historic property in an unanticipated manner. The Subrecipient further acknowledges that FEMA may require the Sub-recipient to take all reasonable measures to avoid or minimize harm to such property until FEMA concludes consultation with the SHPO. The Sub-recipient also acknowledges that FEMA will require, and the Sub-recipient shall comply with, modifications to the project scope of work necessary to implement recommendations to address the project and the property. (7) The Sub-recipient acknowledges that, unless FEMA specifically stipulates otherwise, it shall not receive funding for projects when, with intent to avoid the requirements of the PA or the NHPA, the Sub-recipient intentionally and significantly adversely affects a historic property, or having the legal power to prevent it, allowed such significant adverse effect to occur. 9.33.17 ENDANGERED SPECIES ACT OF 1973, 16 U.S.C. 1531-1544 CONSULTANT and CONTRACTOR will comply with the endangered Species Act of 1973, 16 U.S.C. 1531-1544. 9.33.18 STATEMENT OF NO CONFLICT Neither the COUNTY nor any of its CONSULTANTS, CONTRACTORS or their subcontractors shall enter into any contract, subcontract or arrangement in connection with the Project or any property included or planned to be included in the Project in which any member, officer or employee of the COUNTY or the locality during tenure or for 2 years thereafter has any interest, direct or indirect. If any such present or former member, officer or employee involuntarily acquires or had acquired prior to the beginning of tenure any such interest, and if such interest is immediately disclosed to the COUNTY, the COUNTY, with prior approval of the Department, may waive the prohibition contained in this paragraph provided that any such present member, officer or employee shall not participate in any action by the COUNTY or the locality relating to such contract, subcontract or arrangement. The COUNTY shall insert in all contracts entered into in connection with the Project or any property included or planned to be included in any Project, and shall require its CONSULTANTS and CONTRACTORS to insert in each of their subcontracts, the following provision: "No member, officer or employee of the COUNTY or of the locality during his tenure or for 2 years thereafter shall have any interest, direct or indirect, in this contract or the proceeds thereof." The provisions of this paragraph shall not be applicable to any agreement between the COUNTY and its fiscal depositories or to any agreement for utility services the rates for which are fixed or controlled by a governmental agency. 9.33.19 ENVIRONMENTAL POLICY ACT OF 1969 CONSULTANT and CONTRACTOR will comply with: environmental standards which may be prescribed pursuant to the National Environmental Policy Act of 1969, 42 -30- U.S.C. 4321-4347; environmental standards which may be prescribed pursuant to the Safe Drinking Water Act of 1974, 42 U.S.C. 300f-300j-27, regarding the protection of underground water sources; Executive Orders: EO 11514 (NEPA); EO 11738 (violating facilities); EO 11988 (Floodplain Management); EO 11990 (Wetlands); and EO 12898 (Environmental Justice); Coastal Barrier Resources Act of 1977, 16 U.S.C. 3501-3510; will assure project consistency with the approved State program developed under the Coastal Zone Management Act of 1972, 16 U.S.C. 1451-14674; and comply with the Fish and Wildlife Coordination Act of 1958, 16 U.S.C. 661-668. (Wild and Scenic Rivers Act of 1968, 16 U.S.C. 1271-1287, related to protecting components or potential components of the national wild and scenic rivers system not applicable). 9.33.20 UNIFORM RELOCATION ASSISTANCE AND PROPERTY ACQUISITION POLICIES ACT OF 1970 CONSULTANT and subcontractors will comply with the requirements of Titles II and III of the Uniform Relocation Assistance and Property Acquisition Policies Act of 1970, 42 U.S.C. 4621-4638, which provide for fair and equitable treatment of persons displaced or whose property is acquired as a result of Federal or Federally assisted programs; 9.33.21 ACCESS TO RECORDS CONSULTANT and CONTRACTOR and their successors, transferees, assignees, and subcontractors acknowledge and agree to comply with applicable provisions governing the Department of Homeland Security (DHS) and the Federal Emergency Management Agency's (FEMA) access to records, accounts, documents, information, facilities, and staff. Contractors/Consultants must 1. cooperate with any compliance review or complaint investigation conducted by DHS 2. Give DHS access to and the right to examine and copy records, accounts, and other documents and sources of information related to the grant and permit access to facilities, personnel, and other individuals and information as may be necessary, as required by DHS regulations and other applicable laws or program guidance. 3. Submit timely, complete, and accurate reports to the appropriate DHS officials and maintain appropriate backup documentation to support the reports. 9.33.22 DHS SEAL, LOGO AND FLAGS CONSULTANT and Contractor shall not use the Department of Homeland Security seal(s), logos, crests, or reproduction of flags or likeness of DHS agency officials without specific FEMA pre-approval. The Contractor shall include this provision in any subcontracts. 9.33.23 CHANGES TO CONTRACT CONSULTANT and Contractor understands and agrees that any cost resulting from a change or modification, change order, or constructive change of the agreement must be within the scope of any Federal grant or cooperative agreement that may fund this Project and be reasonable for the completion of the Project. Any contract changes or modification, change order or constructive change must be approved in writing by both the COUNTY and Contractor. -31- 9.33.24 COMPLIANCE WITH FEDERAL LAW, REGULATIONS, AND EXECUTIVE ORDERS. This is an acknowledgement that FEMA financial assistance may be used to fund all or a portion of the contract. The contractor will comply will all applicable Federal Law, regulations, executive orders, FEMA policies, procedures, and directives. 9.33.25 NO OBLIGATION BY FEDERAL GOVERNMENT The Federal Government is not a party to this contract and is not subject to any obligations or liabilities to the COUNTY/non-Federal entity, contractor, or any other party pertaining to any matter resulting from the contract. 9.33.26 PROGRAM FRAUD AND FALSE OR FRAUDULENT STATEMENTS OR RELATED ACTS If applicable, the contractor acknowledges that 31 U.S.C. Chap. 38 (Administrative Remedies for False Claims and Statements) applies to the contractor's actions pertaining to this contract. 9.33.27 GRANT AGREEMENT(S) The CONSULTANT and CONTRACTOR are bound by the terms and conditions of the Federally Funded Subaward and Grant Agreement between COUNTY and the Florida Division of Emergency Management (Division) and the Standard Grant Agreement between the COUNTY and the Florida Department of Environmental Projection (FDEP). 9.33.28 CONSULTANT TO COMPLY WITH C.F.R. 200.318-327 &APPENDIX II o (2 C.F.R. 200.318 History of Procurement records, rationale for method of selection of contract type, selection or rejection & basis for contract price, maintain oversight of contractors; 200.318(b) include in quarterly report) o Contractor and subcontractors are bound by the terms of this Agreement. o Contractor and subcontractors must comply with 200.319- Full and open competition- Sealed bids in accordance with 2 C.F.R. 200.320(d) and 287.057(1)(a o Contractor and subcontractors maynot give brand name or geographic preference (unless approved by FDEM/FDEP) o Contractor and subcontractor must provide written statement to Division on whether Contractor is minority business enterprise as defined in Sec. 288.703, F.S. and execute Minority Business Form attached herein. o Contractor and subcontractor must comply with 200.321 Affirmative Steps. -32- 9.33.29 ADDITONAL STATUTES AND REGULATIONS The Consultant/subconsultant assures that it will comply with the following statutes and regulations to the extent applicable: (1) 53 Federal Register 8034 (2) Federal Acquisition Regulations 31.2 (3) Section 1352, Title 31, US Code (4) Chapter 473, Florida Statutes (5) Chapter 215, Florida Statutes (6) Section 768.28, Florida Statutes (7) Chapter 119, Florida Statutes 39 (8) Section 216.181(6), Florida Statutes (9) Cash Management Improvement Act of 1990 (10) American with Disabilities Act (11) Section 112.061, Florida Statutes (12) Immigration and Nationality Act (13) Section 286.011, Florida Statutes (14) 2 C.F.R. Part 200— Uniform Administrative Requirements, Cost Principles, and Audit Requirements for Federal Awards (15) Uniform Relocation Assistance and Real Property Acquisitions Act of 1970 (16) Title I of the Omnibus Crime Control and Safe Streets Act of 1968 (17) Juvenile Justice and Delinquency Prevention Act, or the Victims of Crime Act (18) Omnibus Crime Control and Safe Streets Act of 1968, as amended (19) Victims of Crime Act (as appropriate) (20) Section 504 of the Rehabilitation Act of 1973, as amended (21) Subtitle A, Title II of the Americans with Disabilities Act (ADA) (1990) (22) Department of Justice regulations on disability discrimination, 28 C.F.R., Part 35 and Part 39 (23) 42 U.S.C. 5154a (Remainder of page blank) -33- EXECUTION This Agreement may be executed electronically and shall be regarded as an original and shall constitute one and the same instrument of this Agreement. IN WITNESS WHEREOF, each party has caused this Agreement to be executed by its duly authorized representative on the day and year first above written: ly`lr,�' rSEA -i ,Llrc; BOARD OF COUNTY COMMISSIONERS l:'''' 'r�-Attest KEVI '` M AD.OK Clerk OF MONROE COUNTY FLORIDA L. `,, ;I -.ti f t y1 i-`:1,,, r it-' �r ".-1,,,,',<';.... : -__,,,' ,,,--'d,„,'. A .,, ArP1. $ F B:y:w.:il-.::"''''''' ajkli) (A(YVY Or By: As Deputy Clerk Mayor/Chairman Date: 5 1 SI 2 0'-4 MONROE COUNTY ATTORNEY 71i PPR V.�DASTOEO t: CHRISTINE LIMBERT-BARROWS ASSISTANT COUNTY ATTORNEY DATE'..-_-5/.-8.2 (Seal) HDR Construction Control Corporation Attest: ...�. .,.5..�0 j.5 ro:.CN nmr�smq, #2/%54 --Thi4c---- �'-'EPaua/�.rvap I.I OCO�OOOI87aDU9lB7VOUB r10, Anthony A Sabbag_.R„,m:`ei I'm:n bs:,ro-rda BY: Anthony a b ag By:Katie E Duty Associate Vice. President Vice President Title: Title; END OF AGREEMENT ' ;;(yy('' - _34_ CERTIFICATE The undersigned hereby certifies that she is the Assistant Secretary of HDR Construction Control Corporation, a Nebraska corporation (the "Corporation"), and that, as such, has custody of the minute books of the Corporation, and that, by Consent and Agreement of the Board of Directors, the following resolution was unanimously adopted: 1. "RESOLVED, that effective immediately, and until termination of said individual from the Corporation, or until recision by the Corporation's Board of Directors, whichever occurs first, the following individuals are hereby granted the nondelegable authority to execute or approve on behalf of the Corporation, contracts, amendments or change orders for engineering services and architectural services incidental to engineering services to be rendered by the Corporation, . . ., or releases of claim or lien in connection with such services, such contracts, amendments, change orders or releases so executed or approved shall be binding upon the Corporation: Jennifer E. Hunt—Senior Vice President. . . L. Kevin Mosteller—Senior Vice President . . . Katie E. Duty—Vice President. . . Marc Silva—Vice President . . . James R.Vansteenburg—Associate Vice President.. ." 2. "RESOLVED, that the following are elected officers of the Corporation until their successors are elected and qualified: . . .Jennifer E. Hunt—Senior Vice President. . . Harold E. Lewis,Jr.—Senior Vice President. . . L. Kevin Mosteller—Senior Vice President. . . . . . Katie E. Duty—Vice President. . . . . . Marc Silva—Vice President . . . . . .Anthony A.Sabbag—Associate Vice President . . . . . .James R.Vansteenburg—Associate Vice President. . . . . Elizabeth C. Buell—Assistant Secretary. . . . . . Laurie S.Vik—Assistant Secretary. . ." The undersigned further certifies that the foregoing resolution has been spread in full upon the minute books of the Corporation and is in full force and effect. DATED August 19, 2022. � Olt ,, ( RDRAT ,,Aell ). �w '�� "� �°`� �� Eliza th C. Bu" ': el rAssistant Secretary STATE OFNEBRASKA COUNTY OF DOUGLAS On this 19th day of August, 2022, before me personally appeared Elizabeth C. Buell, known to me to be the person who executed the within instrument as Assistant Secretary of and on behalf of the corporation therein named and acknowledged to me that the corporation executed it. l (NOTARY SEAL) 4i arie lek, Notary Public HtW CAM CvM*WM �2 ATTACHMENT A SCOPE OF SERVICES SCOPE OF WORK 1.0 The Consultant shall provide Construction Engineering and Inspection (CEI) Services for the Twin Lakes Flood Mitigation Project. The Scope of Work consists of reconstruction and elevation of roads in the Twin Lakes Subdivision of Key Largo, construction of a stormwater management system consisting of a collection system, treatment unit, pump station with controls and a force main and injection well for disposal. Roadway work includes reconstruction, establishing crowns, asphalt paving, re-grading roadway shoulders, harmonization to adjacent private property, pavement markings and signage. The work includes replacement of water utility infrastructure on behalf of the Florida Keys Aqueduct Authority (FKAA scope) and coordination with Florida Keys Electric Cooperative (FKEC pass thru scope) for electrical infrastructure to the pump station. 2.0 The CEI will ensure that the roadway and drainage work conform with Florida Department of Transportation (FDOT) standards and will facilitate communications between all parties (FKAA, FKEC, Key Largo Wastewater Treatment District (KLWTD) ensuring responses and resolutions are provided in a timely manner. The Consultant shall exercise their independent professional judgment in performing their obligations and responsibilities under this Contract. Pursuant to Section 4.1.4 of the FDOT's Construction Project Administration Manual (CPAM), the authority of the Consultant's lead person, such as the Senior Project Engineer, and the Consultant's Project Administrator shall be identical to the Department's Resident Engineer and Project Administrator respectively and shall be interpreted as such. Services provided by the Consultant shall comply with FDOT manuals, procedures, and memorandums in effect as of the date of execution of the Task Order unless otherwise directed in writing by the County. On a single Construction Contract, it is a conflict of interest for a professional firm to receive compensation from both the County and the Contractor either directly or indirectly. 2.0 LENGTH OF SERVICE: The length of contract shall be from award of construction contract through grants closeout. The County shall have the option to extend the Agreement. The Consultant Senior Project Engineer will track the execution of the Construction Contracts such that the Consultant is given timely authorization to begin work. While no personnel shall be assigned until written notification by the County has been issued, the Consultant shall be ready to assign personnel within two weeks of notification. For the duration of the project, the Consultant shall coordinate closely with the County and Contractor to minimize rescheduling of Consultant activities due to construction delays or changes in scheduling of Contractor activities. For estimating purposes, the Consultant will be allowed an accumulation of thirty working days to perform preliminary administrative services prior to the issuance of the Contractor's notice to proceed and thirty calendar days to demobilize after final acceptance of the Construction Contract. 3.0 DEFINITIONS: A. Resident Engineer: The Engineer assigned to a particular Project or area to administer Construction Contracts for the County. B. Construction Project Manager: The County employee assigned to manage the Construction Engineering and Inspection Contract and represent the County during the performance of the services covered under this Agreement. C. Engineer of Record: The Engineer noted on the Construction plans as the responsible person for the design and preparation of the plans. D. Consultant: The Consulting firm under contract to the County for administration of Construction Engineering and Inspection services. E. Agreement: The Professional Services Agreement between the County and the Consultant setting forth the obligations of the parties thereto, including but not limited to the performance of the work, furnishing of services, and the basis of payment. F. Consultant Senior Project Engineer: The Engineer assigned by the Consultant to be in charge of providing Construction Contract administration for one or more Construction Projects. This person may supervise other Consultant employees and act as the lead Engineer for the Consultant. G. Consultant Project Administrator: The employee assigned by the Consultant to be in charge of providing Construction Contract administration services one or more Construction Projects. H. Contractor: The individual, firm, or company contracting with the County for performance of work or furnishing of materials. I. Construction Contract: The written agreement between the County and the Contractor setting forth the obligations of the parties thereto, including but not limited to the performance of the work, furnishing of labor and materials, and the basis of payment. J. CPAM: Florida Department of Transportation, Construction Project Administration manual; latest. K. Department: Florida Department of Transportation L. F.D.O.T.: Florida Department of Transportation. M. County: Monroe County Board of County Commissioners. 4.0 REQUIREMENTS: 4.1 General: It shall be the responsibility of the Consultant to administer, monitor, and inspect the Construction Contract such that the project is constructed in reasonable conformity with the plans, specifications, and special provisions for the Construction Contract. The Consultant shall observe the Contractor's work to determine the progress and quality of work, identify discrepancies, report significant discrepancies to the County, and direct the Contractor to correct such observed discrepancies. The Consultant is hereby designated by the County to negotiate Supplemental Agreements. However, the Consultant must seek input from the Construction Project Manager. The Consultant shall prepare the Supplemental Agreement as a recommendation to the County, which the County may accept, modify or reject upon review. The Consultant shall consult with the Construction Project Manager, as it deems necessary and shall direct all issues, which exceed its delegated authority to the Construction Project Manager for County action or direction. The Consultant shall advise the Construction Project Manager of any significant omissions, substitutions, defects, and deficiencies noted in the work of the Contractor and the corrective action that has been directed to be performed by the Contractor. Work provided by the Consultant shall not relieve the Contractor of responsibility for the satisfactory performance of the Construction Contract. 4.2 Survey Control: The Consultant shall check or establish the survey control baseline(s) along with sufficient baseline control points and bench marks at appropriate intervals along the project in order to: (1) make and record such measurements as are necessary to calculate and document quantities for pay items; (2) make and record pre- construction and final cross section surveys of the project site in those areas where earthwork (i.e., embankment, excavation, subsoil excavation, etc.) is part of the construction project; and (3) perform incidental engineering surveys. The Senior Project Engineer will establish the specific survey requirements for each project prior to construction. Any questions or requests for "Waiver of Survey" should be directed to the Senior Project Engineer. 4.3 On-site Inspection: The Consultant shall monitor the Contractor's on-site construction activities and inspect materials entering into the work in accordance with the plans, specifications, and special provisions for the Construction Contract to determine that the projects are constructed in reasonable conformity with such documents. The County will monitor all off-site activities and fabrication. The Consultant shall keep detailed accurate records of the Contractor's daily operations and of significant events that affect the work. Consultant shall be responsible for monitoring and inspection of Contractor's Work Zone traffic control plan and review of modifications to the Work Zone Traffic Control Plan, including alternate Work Zone Traffic Control Plan, in accordance with F.D.O.T. procedures. Consultant employees performing such services shall be qualified in accordance with F.D.O.T. department procedure. 4.4 Engineering Services: The Consultant shall coordinate the Construction Contract administration activities of all parties other than the Contractor involved in completing the construction project. Notwithstanding the above, the Consultant is not liable to the County for failure of such parties to follow written direction issued by the Consultant. Services include maintaining the required level of surveillance of Contractor activities, interpreting plans, specifications, and special provisions for the Construction Contract, maintaining complete, accurate records of all activities and events relating to the project, and properly documenting all significant project changes. The Consultant shall perform the following services: (1) Schedule and attend, within ten days after the Notice to Proceed, a pre- construction conference for the project. The Consultant shall provide appropriate staff to attend and participate in the pre-construction meeting. (2) The Consultant shall record a complete and concise record of the proceedings of the pre-construction meeting and distribute copies of this summary to the participants and other interested parties within seven days. (3) Analyze the Contractor's schedule(s) (i.e. baseline(s), revised baseline(s), updates, as-built, etc.) for compliance with the contract documents. Elements including, but not limited to, completeness, logic, durations, activity, flow, milestone dates, concurrency, resource allotment, and delays will be reviewed. Verify the schedule conforms with the construction phasing and MOT sequences, including all contract modifications. Provide a written review of the schedule identifying significant omissions, improbable or unreasonable activity durations, errors in logic, and any other concerns as detailed in CPAM. (4) Verify that the Contractor is conducting inspections, preparing reports and monitoring all storm water pollution prevention measures associated with the project. (5) Analyze problems that arise on a project and proposals submitted by the Contractor, endeavor to resolve such issues, and process the necessary paperwork. (6) Produce reports, verify quantity calculations, field measure for payment purposes as needed to prevent delays in Contractor operations and ensure prompt processing of such information in order for the County to make timely payment to the Contractor. (7) Provide Public Information services as required to manage inquiries from the public, public officials, and the news media. Prepare newsletters for distribution to adjacent property owners. The County Construction Project Manager shall approve all notices, brochures, responses to news media, etc., prior to release. (8) Prepare and submit to the Construction Project Manager monthly, a Construction Status Reporting System (CSRS) report. (9) Schedule and conduct a meeting with the County Engineering Office at least 45 calendar days prior to project final acceptance. The purpose of this meeting is to discuss the required documentation, including as-builts, necessary to close out the permit(s). (10) Video tape the pre-construction conditions throughout the project limits. Provide a digital photo log or video of project activities, with heavy emphasis on potential claim items/issues and on areas of real/potential public controversy. (11) The Consultant shall have a digital camera for photographic documentation of noteworthy incidents or events to cover the following areas: (a). Pre-construction photographs (b). Normal and exceptional progress of work (c). Critical path activities (d). Accidents showing damage (e). Unsafe working conditions (f). Unusual construction techniques (g). Damaged equipment or materials (h). Any activity, which may result in claims These photographs will be filed and maintained on the Consultant's computer. Copies of photographs will be electronically transferred to the County at an interval determined by the Senior Project Engineer and the Construction Project Manager. The taking of the photographs shall begin the day prior to the start of construction and continue regularly throughout this project. Photographs shall be taken the days of Conditional, Partial and/or Final Acceptance. (12) Monitor each Contractor and Subcontractor's compliance with specifications and special provisions of the Construction Contract. (13) Provide a Resident Compliance Specialist for surveillance of the Contractor's compliance with Construction Contract and Florida Division of Emergency Management and Florida Department of Environmental Protection requirements. The Resident Compliance Specialist is responsible for reviewing, monitoring, evaluating and acting upon documentation required for Construction Contract compliance, and maintaining the appropriate files thereof. Typical areas of compliance responsibility include EEO Affirmative Actions for the prime contractor and subcontractor, DBE Affirmative Action, Contractor Formal On the Job Training, Payroll, and Subcontracts. The Resident Compliance Specialist must keep all related documents and correspondence accurate and up to date; attend all compliance reviews and furnish the complete project files for review. (14) Public meetings: As needed, prepare and make presentation before the subdivision homeowners, Board of County Commissioners and/or county staff, FDEP or FDEM personnel in connection with the project covered by this Agreement. 5.0 ITEMS TO BE FURNISHED BY THE COUNTY TO CONSULTANT: A. The County, on as needed basis, will furnish the following Construction Contract documents for this project. These documents may be provided in either paper or electronic format. 1 Construction Documents (drawings, specifications) 2 Special Provisions 3 Copy of the executed Construction Contract. 6.0 ITEMS FURNISHED BY THE CONSULTANT: 6.1 County Documents: All applicable documents referenced herein shall be a condition of this Agreement. 6.2 Vehicles: Vehicles will be equipped with appropriate safety equipment and must be able to effectively carry out requirements of this Agreement. Vehicles shall have the name and phone number of the consulting firm visibly displayed on both sides of the vehicle. 6.3 Field Equipment: The Consultant shall supply survey, inspection and testing equipment, essential in order to carry out the work under this Agreement. Such equipment includes those non-consumable and non-expendable items, which are normally needed for a CEI project and are essential in order to carry out the work under this Agreement. Hard hats shall have the name of the consulting firm visibly displayed. Equipment described herein and expendable materials under this Agreement will remain the property of the Consultant and shall be removed at completion of the work. The Consultant's handling of nuclear density gauges shall be in compliance with their license. The Consultant shall retain responsibility for risk of loss or damage to said equipment during performance of this Agreement. Field office equipment shall be maintained and in operational condition at all times. 6.4 Licensing for Equipment Operations: The Consultant will be responsible for obtaining proper licenses for equipment and personnel operating equipment when licenses are required. The Consultant shall make the license and supporting documents available to the County, for verification, upon request. Radioactive Materials License for use of Surface Moisture Density Gauges shall be obtained through the State of Florida Department of Health. 7.0 LIAISON: The Consultant shall keep the Construction Project Manager informed of all significant activities, decisions, correspondence, reports, and other communications related to its responsibilities under this Agreement, and seek input from the Construction Project Manager in order for the Construction Project Manager to oversee the Consultant's performance. Agreement administrative duties relating to Invoice Approval Requests, Personnel Approval Requests, User ID Requests, Time Extension Requests, and Amendment and Supplemental Amendment Requests shall be reviewed and approved by the Construction Project Manager. 8.0 PERSONNEL: 8.1 General Requirements: The Consultant shall staff the project with the qualified personnel necessary to efficiently and effectively carry out its responsibilities under this Agreement. Not all positions listed below may be required; however, personnel performing a specific task must have the qualifications required for the task. Unless otherwise agreed by the County, the County will not compensate straight overtime or premium overtime for the positions of Senior Project Engineer, Project Administrator, Contract Support Specialist, and Associate Contract Support Specialist. 8.2 Personnel Qualifications: The Consultant shall utilize only competent personnel, qualified by experience, and education. The Consultant shall submit in writing to the Construction Project Manager the names of personnel proposed for assignment to the project, including a detailed resume for each containing at a minimum salary, education, and experience. The Consultant Action Request form for personnel approval shall be submitted to the Construction Project Manager at least two weeks prior to the date an individual is to report to work. Personnel identified in the Consultant technical proposal are to be assigned as proposed and are committed to performing services under this Agreement. Personnel changes will require written approval from County. Previously approved staff, whose performance is unsatisfactory, shall be replaced by the Consultant within one week of County notification. Before the project begins, all project staff shall have a working knowledge of the current CPAM and must possess all the necessary qualifications/certifications for obtaining the duties of the position they hold. Cross training of the Consultant's project staff is highly recommended to ensure a knowledgeable and versatile project inspection team but shall not be at any additional cost to the County and should occur as workload permits. Visit the training page on the State Construction Office website for training dates. Minimum qualifications for the Consultant personnel are set forth as follows. Exceptions to these minimum qualifications will be considered on an individual basis. The County Engineer or designee will have the final approval authority. CEI SENIOR PROJECT ENGINEER -A Civil Engineer degree and be registered in the State of Florida as a Professional Engineer (or if registered in another state, the ability to obtain registration in the State of Florida within six months) and six years of engineering experience (two years of which are in major road and bridge construction), or for non-degreed personnel the aforementioned registration and ten years of engineering experience (two years of which are in major road or bridge construction). Qualifications include the ability to communicate effectively in English (verbally and in writing); direct highly complex and specialized construction engineering administration and inspection program; plans and organizes the work of subordinate and staff members; develops and/or reviews policies, methods, practices, and procedures; and reviews programs for conformance with County standards. Also must have the following: Qualification: FDOT Advanced MOT Certifications: None A Master's Degree in Engineering may be substituted for one (1) year engineering experience. CEI PROJECT ADMINISTRATOR -A Civil Engineering degree plus two (2) years of engineering experience in construction of major road or bridge structures, or eight (8) years of responsible and related engineering experience, two (2) years of which involved construction of major road and bridge structures. Receives general instructions regarding assignments and is expected to exercise initiative and independent judgment in the solution of work problems. Directs and assigns specific tasks to inspectors and assists in all phases of the construction project. Will be responsible for the progress and final estimates throughout the construction project duration. Must have the following: Qualifications: FDOT Intermediate MOT Pass the CTQP examination covering the training video "Grouting of Bridge Post-tensioning Tendons" (If applicable) CTQP Final Estimates Level II Certifications: None Other: Attend CTQP Quality Control Manager Course and pass the examination. A Master's Degree in Engineering may be substituted for one (1) year of engineering experience CEI CONTRACT SUPPORT SPECIALIST - A Civil Engineering Degree or High School diploma or equivalent and four years of road & bridge construction engineering inspection (CEI) experience having performed/assisted in project related duties (i.e., progress and final estimates, EEO compliance, processing Construction Contract changes, etc.) or a Civil Engineering degree. Should exercise independent judgment in planning work details and making technical decisions related to the office aspects of the project. Should be familiar with the County's Procedures covering the project related duties as stated above and be proficient in the computer programs necessary to perform these duties. Shall become trained in CTQP Final Estimates Level II course and maintain a current qualification. CEI SENIOR INSPECTOR/ CEI SENIOR ENGINEER INTERN — High school graduate or equivalent plus four years of experience in construction inspection, two years of which shall have been in bridge and/or roadway construction inspection. Must have the following: Qualifications: CTQP Concrete Field Inspector Level I(If applicable) CTQP Concrete Transportation Construction Inspector (CTCI) Level II (If applicable) CTQP Asphalt Roadway Level I (If applicable) CTQP Asphalt Roadway Level II (If applicable) CTQP Earthwork Construction Inspection Level I CTQP Earthwork Construction Inspection Level II CTQP Pile Driving Inspection (If applicable) CTQP Drilled Shaft Inspection (If applicable) CTQP Grouting Technician Level I (If applicable) CTQP Post-Tensioning Technician Level I (If applicable) FDOT Intermediate MOT CTQP Final Estimates Level I Certifications: Nuclear Radiation Safety Or a Civil Engineering degree and one year of road & bridge CEI experience with the ability to earn additional required qualifications within one year. (Note: Senior Engineer Intern classification requires one year experience as an Engineer Intern.) Responsible for performing highly complex technical assignments in field surveying and construction layout, making, and checking engineering computations, inspecting construction work, and conducting field tests and is responsible for coordinating and managing the lower level inspectors. Work is performed under the general supervision of the Project Administrator. 8.3 Staffing: Once authorized, the Consultant shall establish and maintain an appropriate staff through the duration of construction and completion of the final estimate. Responsible personnel, thoroughly familiar with all aspects of construction and final measurements of the various pay items, shall be available to resolve disputed final pay quantities until the appropriate Construction Contract has been paid off. Construction engineering and inspection forces will be required of the Consultant at all times while the Contractor is working. If Contractor operations are substantially reduced or suspended, the Consultant will reduce its staff appropriately. In the event that the suspension of Contractor operations requires the removal of Consultant forces from the project, the Consultant will be allowed ten (10) days maximum to demobilize, relocate, or terminate such forces. 9.0 QUALITY ASSURANCE (QA) PROGRAM: 9.1 Quality Reviews: The Consultant shall conduct semi-annual reviews to make certain his own organization is in compliance with the requirements cited in the Scope of Services. Quality Reviews shall be conducted to evaluate the adequacy of materials, processes, documentation, procedures, training, guidance, and staffing included in the execution of this Agreement. Quality Reviews shall also be developed and performed to achieve compliance with specific QA provisions contained in this Agreement. The semi-annual reviews shall be submitted to the Construction Project Manager in written form no later than one month after the review. On short duration CCEI projects (nine months or less), the CCEI shall perform an initial QA review within the first two months of the start of construction. 9.2 QA Plan: Within thirty (30) days after receiving award of an Agreement, the Consultant shall furnish a QA Plan to the Construction Project Manager. The QA Plan shall detail the procedures, evaluation criteria, and instructions of the Consultant's organization to assure conformance with the Agreement. Unless specifically waived, no payment shall be made until the County approves the Consultant QA Plan. Significant changes to the work requirements may require the Consultant to revise the QA Plan. It shall be the responsibility of the Consultant to keep the plan current with the work requirements. The Plan shall include, but not be limited to, the following areas: A. Organization: A description is required of the Consultant QA Organization and its functional relationship to the part of the organization performing the work under the Agreement. The authority, responsibilities and autonomy of the QA organization shall be detailed as well as the names and qualifications of personnel in the quality control organization. B. Quality Reviews: The Consultant QA shall detail the methods used to monitor and achieve organization compliance with Agreement requirements for services and products. C. Quality Records: The Consultant will outline the types of records, which will be generated and maintained during the execution of his QA program. D. Control of Sub-consultants and Vendors: The Consultant will detail the methods used to control sub-consultants and vendor quality. E. Quality Assurance Certification: An officer of the Consultant firm shall certify that the inspection and documentation was done in accordance with project specifications, plans, standard indexes, and County procedures. 9.3 Quality Records: The Consultant shall maintain adequate records of the quality assurance actions performed by his organization (including subcontractors and vendors) in providing services and products under this Agreement. All records shall indicate the nature and number of observations made, the number and type of deficiencies found, and the corrective actions taken. These records shall be available to the County, upon request, during the Agreement term. All records shall be kept at the primary job site and shall be subject to audit review. 10.0 CERTIFICATION OF FINAL ESTIMATES: 10.1 Final Estimate and As-Built Plans Submittal: Prepare documentation and records in compliance with the Agreement, Consultant's approved QC Plan and the County's Procedures. Submit the Final Estimate(s) and three sets of final as built plans documenting Contractor's work (one record set with two copies) as follows: (a) Within thirty (30) calendar days of final acceptance; or (b) Where all items of work are complete and conditional/partial acceptance is utilized (Lighting, Plant establishment, etc.) for a period exceeding thirty (30) calendar days, the final estimate(s)will be due on the thirtieth (30th) day after conditional/partial acceptance. A memorandum with documentation will be transmitted to the Director of Engineering Services at final acceptance detailing any necessary revisions to the pay items covered under the conditional/partial acceptance. The Consultant shall be responsible for making any revisions to the Certified Final Estimate. 10.2 Certification: Consultant personnel preparing the Certified Final Estimate Package shall be CTQP Final Estimates Level II qualified. Duly authorized representative of the Consultant firm will provide a notarized certification on a form pursuant to Department procedures. 11.0 SUBCONSULTANT SERVICES: Upon written approval by the Construction Project Manager and the County, and prior to performance of work, the Consultant may subcontract for engineering surveys, materials testing, or specialized professional services. 12.0 OTHER SERVICES: Upon written authorization by the Director of Engineering Services or designee, the Consultant will perform additional services in connection with the project not otherwise identified in this Agreement. The following items are not included as part of this Agreement, but may be required by the County to supplement the Consultant services under this Agreement. A. Assist in preparing for arbitration hearings or litigation that occurs during the Agreement time in connection with the construction project covered by this Agreement. B. Provide qualified engineering witnesses and exhibits for any litigation or hearings in connection with the Agreement. C. Provide on- and off-site inspection services in addition to those provided for in this Agreement. 13.0 POST CONSTRUCTION CLAIMS REVIEW: In the event the Contractor submits a claim for additional compensation and/or time after the Consultant has completed this Agreement, the Consultant shall, at the written request from the County, analyze the claim, engage in negotiations leading to settlement of the claim, and prepare and process the required documentation to close out the claim. Compensation for such services will be negotiated and effected through a Supplement to this Agreement. 14.0 CONTRADICTIONS: In the event of a contradiction between the provisions of this Scope of Services and the Consultant's proposal as made a part of their Agreement, the provisions of the Scope of Services shall apply. 15.0 THIRD PARTY BENEFICIARY: It is specifically agreed between the parties executing this Agreement that it is not intended by any of the provisions of any part of the Agreement to create in the public or any member thereof, a third party beneficiary hereunder, or to authorize anyone not a party to this Agreement to maintain a claim, cause of action, lien or any other damages or any relief of any kind pursuant to the terms or provisions of this Agreement. 16.0 COUNTY AUTHORITY: The County shall be the final authority in considering contract modification of the Contractor for time, money or any other consideration except matters agreed to by the Contractor through contract changes negotiated by the Consultant, as authorized in Section 9.1 herein. ATTACHMENT B FEE PROPOSAL HDR Construction Control Corp. Fee Estimate Date: 5/7/2024(revised) Project: CEI for Twin Lakes Flood Mitigation Project(Monroe County) Duration: 670 cal.days construction,22 mos. (est. 8/1/2024 through 6/1/2026) CEI Services,24 mos. (est. 7/1/2024 through 7/1/2026) HDR Construction Control Corp. Loaded Hourly Rate Total Hours/Qty. Extended Costs CEI Project Manager(Anthony Sabbag,CGC,CCM, MSCM) $ 257.07 1540 $ 395,887.80 CEI Senior Project Engineer(David Romano, PE) $ 245.12 150 $ 36,768.00 CEI Senior Inspector(Sam Rodriguez) $ 106.72 3630 $ 387,393.60 Senior Electrical Engineer(Jose Gonzalez, PE) $ 243.33 260 $ 63,265.80 CEI Contract Support Specialist(Gary Miller) $ 118.13 920 $ 108,679.60 CEI Senior Inspector/Pump Station(Dennys Losa) 1 $ 110.93 1 120 $ 13,311.60 Subconsultant/H.Rodriguez Consulting Engineering,Inc. Loaded Hourly Rate Total Hours/Qty. Extended Costs CEI Senior Inspector(Hector Aguilar) $ 129.75 1485 $ 192,678.75 Subconsultant/More Compliance Results,Inc. Loaded Hourly Rate Total Hours/Qty. Extended Costs CEI Resident Compliance Specialist(Melissa Leyva) $ 74.67 1961 $ 146,427.87 Laboratory Materials Testing ® Unit • Concrete:ASTM C-39,Compressive Strength Cylinders Each $ 20.00 24 $ 480.00 Asphalt: FM 1,T-166, Bulk Specific Gravity, Per Core Each $ 45.00 $ - Earthwork/Soils: FM 5-515, L.B.R. Each $ 335.00 6 $ 2,010.00 Earthwork/Soils:AASHTO T-99,Standard Proctor Each $ 111.00 12 $ 1,332.00 Earthwork/Soils:AASHTO T-180, Modified Proctor Each $ 115.00 6 $ 690.00 Earthwork/Soils:AASHTO M-145,Soils Classification Each $ 27.00 6 $ 162.00 Earthwork/Soils: FM 1,T-267,Organic Content, Ignition Each $ 40.00 6 $ 240.00 Earthwork/Soils:AASHTO T-88, No Hydrometer Each $ 62.00 6 $ 372.00 1 Subtotal Testing: $ 5,286.00 Lodging(if applicable) ® Unit • N/A $ - Project Field Office ® Unit • Key Largo Field Office(rent,printer/copier,internet,etc.) ILS 1 $ 72,919.66 1 $ 72,919.66 for 22 mos. Total Fee Estimate: $ 1,422,618.68 "These costs are for laboratory testing of materials only.All field/jobsite sampling and testing(ie:concrete slump,air,cylinders,density tests,etc.)is included in the loaded hourly rate for CEI Senior Inspector. Construction Cost: $21,734,258.71 CEI Percent of Construction: 7 DATE(MMIDDIYYYY) ACOR" CERTIFICATE OF LIABILITY INSURANCE 6/1/2024 4/26/2024 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER,AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). CONTACT PRODUCER LOckton Companies NAME: 444 W 47th Street,Suite 900 PHOfAIC,NE FAx Kansas City MO 641 1 2-1 906 E-MAIL Ext: A/C No (816)960-9000 ADDRESS: 1CCasuG1Ockton.com INSURER(S)AFFORDING COVERAGE NAIC# INSURER A:Lloyds Of London INSURED HDR CONSTRUCTION CONTROL CORPORATION INSURER B: 1429583 1917 SOUTH 67TH STREET INSURER C: OMAHA,NE 68106 INSURER D: INSURER E: INSURER F: COVERAGES CERTIFICATE NUMBER: 20530353 REVISION NUMBER: XXXXXXX THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES.LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR TYPE OF INSURANCE ADDL SUBR POLICY EFF POLICY EXP LIMITS LTR INSD WVD POLICY NUMBER MM/DDIYYW W MMIDD/ YY COMMERCIAL GENERAL LIABILITY NOT APPLICABLE EACH OCCURRENCE $ XXXXXXX OCCUR DAMAGE TO RENTED CLAIMS-MADE PREMISES Ea occurrence) ccurrence $ XXXXXXX MED EXP(Any one person) $ XXXXXXX PERSONAL&ADV INJURY $ XXXXXXX GEN'L AGGREGATE LIMIT APPLIES PER: GENERAL AGGREGATE $ XXXXXXX POLICY❑ PRO ❑ LOC PRODUCTS-COMP/OP AGG $ XXXXXXX JECT OTHER: $ AUTOMOBILE LIABILITY NOT APPLICABLE EOa aBINEDccdentSINGLE LIMIT $ XXXXXXX ANY AUTO BODILY INJURY(Per person) $ XXXXXXX OWNED SCHEDULED BODILY INJURY(Per accident) $ AUTOS ONLY AUTOS XXXXXXX HIRED NON-OWNED PROPERTY DAMAGE $ XrXrXrXrXrXrXr AUTOS ONLY AUTOS ONLY Per accident $ XXXXXXX UMBRELLA LIAB OCCUR NOT APPLICABLE EACH OCCURRENCE $ XXXXXXX EXCESS LIAB CLAIMS-MADE AGGREGATE $ XXXXXXX DED RETENTION$ $ XXXXXXX WORKERS COMPENSATION NOT APPLICABLE PER OTH- AND EMPLOYERS'LIABILITY STATUTE ER YIN ANY PROPRIETOR/PARTNER/EXECUTIVE ❑ E.L.EACH ACCIDENT $ XXXXXXX OFFICER/MEMBER EXCLUDED? N I A (Mandatory in NH) E.L.DISEASE-EA EMPLOYEE $ XXXXXXX If yes,describe under DESCRIPTION OF OPERATIONS below E.L.DISEASE-POLICY LIMIT $ XXXXXXX A ARCH&ENG N N P001412300 6/1/2023 6/1/2024 PER CLAIM:$1,000,000 PROFESSIONAL AGGREGATE:$1,000,000 LIABILITY DESCRIPTION OF OPERATIONS/LOCATIONS I VEHICLES (ACORD 101,Additional Remarks Schedule,may be attached if more space is required) RE:MONROE CO.TWIN LAKES(KEY LARGO)FLOOD MITIGATION 9.14 T ,, -- WAS CERTIFICATE HOLDER CANCELLATION SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE 20530353 THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN MONROE COUNTY BOCC ACCORDANCE WITH THE POLICY PROVISIONS. ATTENTION: DEBRA LONDON AUTHORIZED REPRIESENTATIV j 1100 SIMONTON ST. KEY WEST FL 33040 ©19884015 ACORD CORPORATION. All rights reserved. ACORD 25(2016/03) The ACORD name and logo are registered marks of ACORD Page 1 of 2 ' CERTIFICATE OF LIABILITY INSURANCE DATE(MM/ 05/09/2024Y) 2024 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER,AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies)must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER CONTACT WTW Certificate Center NAME: Willis Towers Watson Midwest, Inc. c/o 26 Century Blvd PHONE 1-877-945-7378 FAX 1-888-467-2378 AIC No Ext: AIC,No): E-MAIL certificates@wtwco.corn P.O. Box 305191 ADDRESS: Nashville, TN 372305191 USA INSURER(S)AFFORDING COVERAGE NAIC# INSURERA: Liberty Mutual Fire Insurance Company 23035 INSURED INSURER B: Ohio Casualty Insurance Company 24074 HDR Construction Control Corporation 1917 South 67th Street INSURERC: Liberty Insurance Corporation 42404 Omaha, NE 68106 INSURER D INSURER E INSURER F: COVERAGES CERTIFICATE NUMBER:W33522844 REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES.LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR ADDLSUBRTYPE OF INSURANCE INSD WVD POLICY NUMBER POLICY EFF POLICY EXP LTR MM/DDIYYYYJ fMM1DDIYYYYJ LIMITS X COMMERCIAL GENERAL LIABILITY EACH OCCURRENCE $ 2,000,000 CLAIMS-MADE �X OCCUR DAMAGE TO RENTED 1,000,000 PREMISES Ea occurrence $ A X Contractual Liability MED EXP(Any one person) $ 10,000 Y Y TB2-641-444950-033 06/01/2023 06/01/2024 PERSONAL&ADV INJURY $ 2,000,000 GEN'L AGGREGATE LIMIT APPLIES PER: GENERAL AGGREGATE $ 4,000,000 POLICY� JECT PRO � LOC PRODUCTS-COMP/OP AGG $ 4,000,000 OTHER: $ AUTOMOBILE LIABILITY COMBINEDSINGLELIMIT $ 2,000,000 Ea accident X ANY AUTO BODILY INJURY(Per person) $ A OWNED SCHEDULED Y Y AS2-641-444950-043 06/01/2023 06/01/2024 BODILY INJURY(Per accident) $ AUTOS ONLY AUTOS HIRED NON-OWNED PROPERTY DAMAGE $ AUTOS ONLY AUTOS ONLY Per accident B UMBRELLALIAB X OCCUR EACH OCCURRENCE $ 51000,000 X EXCESS LIAB CLAIMS-MADE Y Y EUO(24)57919363 06/01/2023 06/01/2024 AGGREGATE $ 5,000,000 DED X RETENTION$ 0 $ WORKERS COMPENSATION X PER OTH- AND EMPLOYERS'LIABILITY YIN STATUTE ER C ANYPROPRIETOR/PARTNER/EXECUTIVE E.L.EACH ACCIDENT $ 1,000,000 OFFICER/MEMBER EXCLUDED? No NIA Y WA7-64D-444950-013 06/01/2023 06/01/2024 1,000,000 (Mandatory in NH) E.L.DISEASE-EA EMPLOYEE $ If yes,describe under 1,000,000 DESCRIPTION OF OPERATIONS below E.L.DISEASE-POLICY LIMIT $ DESCRIPTION OF OPERATIONS I LOCATIONS/VEHICLES (ACORD 101,Additional Remarks Schedule,may be attached if more space is required) Certificate Holder is named as Additional Insured on General Liability, Automobile Liability and Umbrella/Excess Liability on a Primary, Non-contributory basis where required by written contract. Waiver of Subrogation applies on General Liability, Automobile Liability, Umbrella/Excess Liability and Workers Compensation where required by written contract and as permitted by law. Umbrella/Excess policy is follow form over General Liability, Auto Liability and Employers Liability. Irk CERTIFICATE HOLDER ay "I ANCELLATION DAT SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. Monroe County BOCC AUTHORIZED REPRESENTATIVE Attention: Debra London 1100 Simonton St. /fry Key West, FL 33040 ©1988-2016 ACORD CORPORATION. All rights reserved. ACORD 25(2016/03) The ACORD name and logo are registered marks of ACORD SR ID: 25848116 BATCH: 3454274 AGENCY CUSTOMER ID: LOC#: ACCOR 0 ADDITIONAL REMARKS SCHEDULE Page 2 of 2 AGENCY NAMED INSURED Willis Towers Watson Midwest, Inc. HDR Construction Control Corporation 1917 South 67th Street POLICY NUMBER Omaha, NE 68106 See Page 1 CARRIER NAIC CODE See Page 1 See Page 1 EFFECTIVE DATE: See Page 1 ADDITIONAL REMARKS THIS ADDITIONAL REMARKS FORM IS A SCHEDULE TO ACORD FORM, FORM NUMBER: 25 FORM TITLE: Certificate of Liability Insurance Re: Monroe Co. Twin Lakes (Key Largo) Flood Mitigation Additional Insured: Monroe County BOCC. ACORD 101 (2008/01) ©2008 ACORD CORPORATION. All rights reserved. The ACORD name and logo are registered marks of ACORD SR ID: 25848116 BATCH: 3454274 CERT: W33522844 Page 1 of 2 ' CERTIFICATE OF LIABILITY INSURANCE DATE(MM/ 05/09/2024Y) 2024 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER,AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies)must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER CONTACT WTW Certificate Center NAME: Willis Towers Watson Midwest, Inc. c/o 26 Century Blvd PHONE 1-877-945-7378 FAX 1-888-467-2378 AIC No Ext: AIC,No): E-MAIL certificates@wtwco.corn P.O. Box 305191 ADDRESS: Nashville, TN 372305191 USA INSURER(S)AFFORDING COVERAGE NAIC# INSURERA: Liberty Mutual Fire Insurance Company 23035 INSURED INSURER B: Ohio Casualty Insurance Company 24074 HDR Engineering, Inc. 1917 South 67th Street INSURERC: Liberty Insurance Corporation 42404 Omaha, NE 68106 INSURER D INSURER E INSURER F: COVERAGES CERTIFICATE NUMBER:W33529663 REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES.LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR ADDLSUBRTYPE OF INSURANCE INSD WVD POLICY NUMBER POLICY EFF POLICY EXP LTR MM/DDIYYYYJ fMM1DDIYYYYJ LIMITS X COMMERCIAL GENERAL LIABILITY EACH OCCURRENCE $ 2,000,000 CLAIMS-MADE �X OCCUR DAMAGE TO RENTED 1,000,000 PREMISES Ea occurrence $ A X Contractual Liability MED EXP(Any one person) $ 10,000 Y Y TB2-641-444950-034 06/01/2024 06/01/2025 PERSONAL&ADV INJURY $ 2,000,000 GEN'L AGGREGATE LIMIT APPLIES PER: GENERAL AGGREGATE $ 4,000,000 POLICY� JECT PRO � LOC PRODUCTS-COMP/OP AGG $ 4,000,000 OTHER: $ AUTOMOBILE LIABILITY COMBINEDSINGLELIMIT $ 2,000,000 Ea accident X ANY AUTO BODILY INJURY(Per person) $ A OWNED SCHEDULED Y Y AS2-641-444950-044 06/01/2024 06/01/2025 BODILY INJURY(Per accident) $ AUTOS ONLY AUTOS HIRED NON-OWNED PROPERTY DAMAGE $ AUTOS ONLY AUTOS ONLY Per accident B UMBRELLALIAB X OCCUR EACH OCCURRENCE $ 51000,000 X EXCESS LIAB CLAIMS-MADE Y Y EUO(25)57919363 06/01/2024 06/01/2025 AGGREGATE $ 5,000,000 DED X RETENTION$ 0 $ WORKERS COMPENSATION X PER OTH- AND EMPLOYERS'LIABILITY YIN STATUTE ER C ANYPROPRIETOR/PARTNER/EXECUTIVE E.L.EACH ACCIDENT $ 1,000,000 OFFICER/MEMBER EXCLUDED? No NIA Y WA7-64D-444950-014 06/01/2024 06/01/2025 1,000,000 (Mandatory in NH) E.L.DISEASE-EA EMPLOYEE $ If yes,describe under 1,000,000 DESCRIPTION OF OPERATIONS below E.L.DISEASE-POLICY LIMIT $ DESCRIPTION OF OPERATIONS I LOCATIONS/VEHICLES (ACORD 101,Additional Remarks Schedule,may be attached if more space is required) Certificate Holder is named as Additional Insured on General Liability, Automobile Liability and Umbrella/Excess Liability on a Primary, Non-contributory basis where required by written contract. Waiver of Subrogation applies on General Liability, Automobile Liability, Umbrella/Excess Liability and Workers Compensation where required by written contract and as permitted by law. Umbrella/Excess policy is follow form over General Liability, Auto Liability and Employers Liability. CERTIFICATE HOLDER NCELLATION "� 5.9.24 HOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE HE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN CCORDANCE WITH THE POLICY PROVISIONS. Monroe County BOCC AUTHORIZED REPRESENTATIVE 1100 Simonton Street /fry Key West, FL 33040 ©1988-2016 ACORD CORPORATION. All rights reserved. ACORD 25(2016/03) The ACORD name and logo are registered marks of ACORD SR ID: 25830812 BATCH: 3454790 AGENCY CUSTOMER ID: LOC#: ACCOR 0 ADDITIONAL REMARKS SCHEDULE Page 2 of 2 AGENCY NAMED INSURED Willis Towers Watson Midwest, Inc. HDR Engineering, Inc. 1917 South 67th Street POLICY NUMBER Omaha, NE 68106 See Page 1 CARRIER NAIC CODE See Page 1 See Page 1 EFFECTIVE DATE: See Page 1 ADDITIONAL REMARKS THIS ADDITIONAL REMARKS FORM IS A SCHEDULE TO ACORD FORM, FORM NUMBER: 25 FORM TITLE: Certificate of Liability Insurance Project: On Call Professaional Engineering Services Agreement. Additional Insured: FDOT and Monroe County Board of County Commissioners (MCBOCC) . ACORD 101 (2008/01) ©2008 ACORD CORPORATION. All rights reserved. The ACORD name and logo are registered marks of ACORD SR ID: 25830812 BATCH: 3454790 CERT: W33529663