Loading...
07/17/2024 Agreement GVS COURTq° o: A Kevin Madok, CPA - �o ........ � Clerk of the Circuit Court& Comptroller Monroe County, Florida �z cooN DATE: July 26, 2024 TO: Beth Leto, Airports Business Manager, KWIA FROM: Liz Yongue, Deputy Clerk SUBJECT: July 17, 2024 BOCC Meeting The following item has been executed and added to the record: I6 Contract with Marino Construction Group, Inc. in the amount of$5,102,839.10 (Base Bid and Bid Alternate 1) for the Customs and Border Protection Facility Phase 3 Terminal Annex construction project at the Key West International Airport. The project is funded by FDOT Customs Grant Contract G2A61 ($1,213,029) with equal match from Airport Operating Fund 404; FDOT Buildings & Security Grant Contract GIP33 ($498,940.00) with equal match from Airport Operating Fund 404; PFC Fund 406 ($1,179,951);plus $498,950.10 from Airport Operating Fund 404. Should you have any questions please feel free to contact me at(305) 292-3550. cc: County Attorney Finance File KEY WEST MARATHON PLANTATION KEY 500 Whitehead Street 3117 Overseas Highway 88770 Overseas Highway Key West, Florida 33040 Marathon, Florida 33050 Plantation Key, Florida 33070 CONTRACT Key West International Airport 05/22 Monroe County Customs and Border Protection Facility Phase 3 Bid Documents Project Manual S E C T 1 0 N D CONTRACT Customs and Border Protection Facility Phase 3 Key West International Airport THIS AGREEMENT made and entered into the 17 th day of July by and between Marino Construction Group, Inc. "Contractor", and the Monroe County Board of Commissioners, Key West, Florida, Owner. WITNESSETH: That the Contractor, for the consideration hereinafter fully set out hereby agrees with the Owner as follows: 1 That the Contractor, shall furnish all the materials, and perform all of the work in the manner and form as provided by the following enumerated documents; Instruction to Bidders, Form of Proposal, General Provisions, Special Provisions, Technical Specifications, Form of Contract, Form of Bond, Drawings and Addenda, which are attached hereto and made a part hereof, as if fully contained herein, for the construction of: Customs and Border Protection Facility Phase 3 Key West International Airport Monroe County, Florida 2. That the Contractor shall commence the work to be performed under this agreement on a date to be specified in a written order of the Owner and shall fully complete all work hereunder within four hundred eighty-five (485) calendar days from the Notice-to-Proceed (Construction) as per Special Provision No. 2. 3. The Owner hereby agrees to pay tothe Contractor for the faithful performance of the agreement, subject to additions and deductions as provided in the contract documents the Contract Lump sum of Five Million, one hundred two thousand, eight hundred thirty-nine dollars and ten cents ($6,102,839.10) 4. On or before the 15th day of each calendar month, the Owner shall make partial payment to the Contractor on the basis of a duly certified and approved estimate of work performed during the preceding calendar month by the Contractor. County shall pay in accordance with the Florida Local Government Prompt Payment Act. Each Application for Payment shall be based upon the Schedule of Values for the project, The Schedule of Values shall allocate the entire Contract Sum among the various portions of the Work and be prepared in such form and supported by such data to substantiate its accuracy as the Director of Airports may require. This schedule, unless objected to by the Director of Airports, shall be used as a basis for reviewing CONTRACT 11-2 Key West International Airport 05/22 Monroe County Customs and Border Protection Facility Phase 3 Bid Documents Project Manual the Contractor's Applications for Payment. Applications for Payment shall indicate the percentage of completion of each portion of the Work as of the end of the period covered by the Application for Payment. Subject to the provisions of the Contract Documents, the amount of each progress payment shall be computed as follows: Take that portion of the Contract Sum properly allocable to completed Work as determined by multiplying the percentage completion of each portion of the Work by the share of the total Contract Sum allocated to that portion of the Work, less retainage of ten percent 10%. Payment will be made after delivery and inspection by County and upon submission of invoices with supporting documentation acceptable to the Clerk, on a monthly schedule in arrears. Acceptability to the Clerk is based on generally accepted accounting principles and such laws, rules and regulations as may govern the Clerk's disbursal of funds. 5. Upon submission by the Contractor of evidence satisfactory to the Owner that all payrolls, material bills and other costs incurred by the Contractor in connection with the construction of the work have been paid in full, final payment on account of this agreement shall be made within twenty (20) days after the completion by the Contractor of all work covered by this agreement and the acceptance of such work by the Owner. 6. It is mutually agreed between the parties hereto that time is of the essence in this contract and in the event the construction of the work is not completed within the time herein specified, it is agreed that from the compensation otherwise to be paid to the Contractor, the Owner may retain the amounts described in the Liquidated Damages, Special Provision No. 3, per day for each day thereafter, Sundays and holidays included, that the work remains uncompleted,which sum shall represent the actual damages which the Owner will have sustained per day by failure of the Contractor to complete the work within the time stipulated and this sum is not a penalty being the stipulated damages the Owner will have sustained in the event of such default by the Contractor. 7. It is further mutually agreed between the parties hereto that if at any time after the execution of this agreement and the surety bond hereto attached for its faithful performance, the Owner shall deem the surety or sureties upon such bond to be unsatisfactory, or if, for any reason, such bond ceases to be adequate to cover the performance of the work, the Contractor shall, at its expense within five (5) days after the receipt of notice from the Owner so to do, furnish an additional bond or bonds in such form and amount and with such surety or sureties as shall be satisfactory to the Owner. In such event, no further payment to the Contractor shall be deemed to be due under this agreement until such new or additional security for the faithful performance of the work shall be furnished in manner and form satisfactory to the Owner. 8. MAINTENANCE OF RECORDS: Contractor shall maintain all books, records, and documents directly pertinent to performance under this Agreement in accordance with generally accepted accounting principles consistently applied. Records shall be retained for a period of seven years from the termination of this agreement or for a CONTRACT 11-3 Key West International Airport 05/22 Monroe County Customs and Border Protection Facility Phase 3 Bid Documents Project Manual period of three years from the submission of the final expenditure report as per 2 CFR §200.333, whichever is greater. Each party to this Agreement or its authorized representatives shall have reasonable and timely access to such records of each other party to this Agreement for public records purposes during the term of the Agreement and for seven years following the termination of this Agreement. If an auditor employed by the County or Clerk determines that monies paid to Contractor pursuant to this Agreement were spent for purposes not authorized by this Agreement, or were wrongfully retained by the Contractor, the Contractor shall repay the monies together with interest calculated pursuant to Sec. 55.03, of the Florida Statutes, running from the date the monies were paid by the County. 9. PUBLIC ACCESS. Public Records Compliance. Contractor must comply with Florida public records laws, including but not limited to Chapter 119, Florida Statutes and Section 24 of article I of the Constitution of Florida. The County and Contractor shall allow and permit reasonable access to, and inspection of, all documents, records, papers, letters or other "public record" materials in its possession or under its control subject to the provisions of Chapter 119, Florida Statutes, and made or received by the County and Contractor in conjunction with this contract and related to contract performance. The County shall have the right to unilaterally cancel this contract upon violation of this provision by the Contractor. Failure of the Contractor to abide by the terms of this provision shall be deemed a material breach of this contract and the County may enforce the terms of this provision in the form of a court proceeding and shall, as a prevailing party, be entitled to reimbursement of all attorney's fees and costs associated with that proceeding. This provision shall survive any termination or expiration of the contract. The Contractor is encouraged to consult with its advisors about Florida Public Records Law in order to comply with this provision. Pursuant to F.S. 119.0701 and the terms and conditions of this contract, the Contractor is required to: (1) Keep and maintain public records that would be required by the County to perform the service. (2) Upon receipt from the County's custodian of records, provide the County with a copy of the requested records or allow the records to be inspected or copied within a reasonable time at a cost that does not exceed the cost provided in this chapter or as otherwise provided by law. (3) Ensure that public records that are exempt or confidential and exempt from public records disclosure requirements are not disclosed except as authorized by law for the duration of the contract term and following completion of the contract if the contractor does not transfer the records to the County. (4) Upon completion of the contract, transfer, at no cost, to the County all public records in possession of the Contractor or keep and maintain public records that would be required by the County to perform the service. If the Contractor transfers CONTRACT 11-4 Key West International Airport 05/22 Monroe County Customs and Border Protection Facility Phase 3 Bid Documents Project Manual all public records to the County upon completion of the contract, the Contractor shall destroy any duplicate public records that are exempt or confidential and exempt from public records disclosure requirements. If the Contractor keeps and maintains public records upon completion of the contract, the Contractor shall meet all applicable requirements for retaining public records, All records stored electronically must be provided to the County, upon request from the County's custodian of records, in a format that is compatible with the information technology systems of the County. (5) A request to inspect or copy public records relating to a County contract must be made directly to the County, but if the County does not possess the requested records, the County shall immediately notify the Contractor of the request, and the Contractor must provide the records to the County or allow the records to be inspected or copied within a reasonable time. If the Contractor does not comply with the County's request for records, the County shall enforce the public records contract provisions in accordance with the contract, notwithstanding the County's option and right to unilaterally cancel this contract upon violation of this provision by the Contractor. A Contractor who fails to provide the public records to the County or pursuant to a valid public records request within reasonable time may be subject to penalties under Section 119.10, Florida Statutes. Contractor shall not transfer custody, release, alter, destroy or otherwise dispose of any public records unless or otherwise provided in this provision or as otherwise provided by law. IF THE CONTRACTOR HAS QUESTIONS REGARDING THE APPLICATION OF CHAPTER 119, FLORIDA STATUTES, TO THE CONTRACTOR'S DUTY TO PROVIDE PUBLIC RECORDS RELATING TO THIS CONTRACT, CONTACT THE CUSTODIAN OF PUBLIC RECORDS, BRIAN BRADLEY, AT (305) 292-3470, BRADLEY-BR 16Kc4,MON ROECO U NTY-FL.GOV, MONROE COUNTY ATTORNEY'S OFFICE, 1111 12 th STREET, SUITE 408, KEY WEST, FL 33040. 10. HOLD HARMLESS AND INSURANCE: The successful Respondent shall defend, indemnify and hold the County and the County's elected and appointed officers and employees harmless from and against (i) any claims, actions or causes of action, (i i) any litigation, administrative proceedings, appellate proceedings, or other proceedings relating to any type of injury (including death), loss, damage, fine, penalty or business interruption, and (iii) any costs or expenses (including, without limitation, costs of remediation and costs of additional security measures that the Federal Aviation Administration, the Transportation Security Administration or any other governmental agency requires by reason of , or in connection with a violation of any federal law or regulation, attorneys' fees and costs, court costs, fines and penalties) that may be asserted against, initiated with respect to, or sustained by, any indemnified party by reason of, or in connection with, (A) any activity of Respondent or any of its CONTRACT Key West International Airport 05/22 Monroe County Customs and Border Protection Facility Phase 3 Bid Documents Project Manual employees, agents, contractors or other invitees during the term of the Agreement, (B) the negligence or recklessness, intentional wrongful misconduct, errors or omissions, or other wrongful act or omission of Respondent or any of its employees, agents, sub-contractors or other invitees, or (C) Respondent's default in respect of any of the obligations that it undertakes under the terms the Agreement, except to the extent the claims, actions, causes of action, litigation, proceedings, costs or expenses arise from the intentional or sole negligent acts or omissions of the County or any of its employees, agents, contractors or invitees (other than Respondent). The monetary limitation of liability under this contract shall be equal to the dollar value of the contract and not less than $1 million per occurrence pursuant to Section 725.06, Florida Statutes. Insofar as the claims, actions, causes of action, litigation, proceedings, costs or expenses relate to events or circumstances that occur during the term of the Agreement, this provision will survive the expiration of the term of the Agreement or any earlier termination of the Agreement. In the event the completion of the project (including the work of others) is delayed or suspended as a result of the Contractor's failure to purchase or maintain the required insurance, the Contractor shall indemnify the County from any and all increased expenses resulting from such delay. The extent of liability is in no way limited to, reduced, or lessened by the insurance requirements contained elsewhere within this agreement. CERTIFICATES OF INSURANCE. Original Certificates of Insurance shall be provided to the COUNTY at the time of execution of this Agreement and certified copies provided if requested. Each policy certificate shall be endorsed with a provision that not less than thirty (30) calendar days' written notice shall be provided to the COUNTY before any policy or coverage is canceled or restricted.The underwriter of such insurance shall be qualified to do business in the State of Florida. If requested by the County Administrator, the insurance coverage shall be primary insurance with respect to the COUNTY, its officials, employees, agents and volunteers. Failure of CONTRACTOR to comply with the requirements of this section shall be cause for immediate termination of this agreement. 11. NON-WAIVER OF IMMUNITY: Notwithstanding the provisions of Sec. 768.28, Florida Statutes, the participation of COUNTY and CONTRACTOR in this Agreement and the acquisition of any commercial liability insurance coverage, self- insurance coverage, or local government liability insurance pool coverage shall not be deemed a waiver of immunity to the extent of liability coverage, nor shall any Agreement entered into by the COUNTY be required to contain any provision for waiver. 12. NO PLEDGE OF CREDIT: CONTRACTOR shall not pledge the COUNTY'S credit or make it a guarantor of payment or surety for any contract, debt, CONTRACT 11-6 Key West International Airport 05/22 Monroe County Customs and Border Protection Facility Phase 3 Bid Documents Project Manual obligation, judgment, lien, or any form of indebtedness. CONTRACTOR further warrants and represents that it has no obligation or indebtedness that would impair its ability to fulfill the terms of this contract. 13. NOTICE REQUIREMENT,: Any notice required or permitted under this agreement shall be in writing and hand delivered or mailed, postage prepaid, to the other party by certified mail, returned receipt requested, to the following: FOR COUNTY: Richard Strickland AND Monroe County Attorneys Office Exec, Director of Airports 1111 12 1h St., Suite 408 3491 S. Roosevelt Blvd. Key West, Florida. 33040 Key West, Florida 33040 FOR CONTRACTOR: Jennifer Socha Director of Operations Marino Construction Group, Inc. P.O. Box 1706 Key West, Florida 33041 14. GOVERNING LAW, VENUE, AND INTERPRETATION: This Agreement shall be governed by and construed in accordance with the laws of the State of Florida applicable to Agreements made and to be performed entirely in the State. In the event that any cause of action or administrative proceeding is instituted for the enforcement or interpretation of this Agreement, the COUNTY and CONTRACTOR agree that venue will lie in the appropriate court or before the appropriate administrative body in Monroe COUNTY, Florida. 15. MEDIATION: The COUNTY and CONTRACTOR agree that, in the event of conflicting interpretations of the terms or a term of this Agreement by or between any of them the issue shall be submitted to mediation prior to the institution of any other administrative or legal proceeding. Mediation proceedings initiated and conducted pursuant to this Agreement shall be in accordance with the Florida Rules of Civil Procedure and usual and customary procedures required by the circuit court of Monroe County. 16. SEVERABILITY: If any term, covenant, condition or provision of this Agreement (or the application thereof to any circumstance or person) shall be declared invalid or unenforceable to any extent by a court of competent jurisdiction, the remaining terms, covenants, conditions and provisions of this Agreement, shall not be affected thereby; and each remaining term, covenant, condition and provision of this Agreement shall be valid and shall be enforceable to the fullest CONTRACT 11-7 Key West International Airport 05/22 Monroe County Customs and Border Protection Facility Phase 3 Bid Documents Project Manual extent permitted by law unless the enforcement of the remaining terms, covenants, conditions and provisions of this Agreement would prevent the accomplishment of the original intent of this Agreement. The COUNTY and CONTRACTOR agree to reform the Agreement to replace any stricken provision with a valid provision that comes as close as possible to the intent of the stricken provision, 17. ATTORNEY'S FEES AND COSTS: COUNTY and CONTRACTOR agree that in the event any cause of action or administrative proceeding is initiated or defended by any party relative to the enforcement or interpretation of this Agreement, the prevailing party shall be entitled to reasonable attorney's fees and attorney's fees, in appellate proceedings. Each party agrees to pay its own court costs, investigative, and out-of-pocket expenses whether it is the prevailing party or not, through all levels of the court system. 18. ADJUDICATION OF DISPUTES OR DISAGREEMENTS: COUNTY and CONTRACTOR agree that all disputes and disagreements shall be attempted to be resolved by meet and confer sessions between representatives of each of COUNTY and CONTRACTOR. If no resolution can be agreed upon within 30 days after the first meet and confer session, the issue or issues shall be discussed at a public meeting of the Board of County Commissioners. If the issue or issues are still not resolved to the satisfaction of COUNTY and CONTRACTOR, then any party shall have the right to seek such relief or remedy as may be provided by this Agreement or by Florida law. 19. COOPERATION: In the event any administrative or legal proceeding is instituted against either party relating to the formation, execution, performance, or breach of this Agreement, COUNTY and CONTRACTOR agree to participate, to the extent required by the other party, in all proceedings, hearings, processes, meetings, and other activities related to the substance of this Agreement or provision of the services under this Agreement. COUNTY and CONTRACTOR specifically agree that no party to this Agreement shall be required to enter into any arbitration proceedings related to this Agreement. 20. BINDING EFFECT: The terms, covenants, conditions, and provisions of this Agreement shall bind and inure to the benefit of COUNTY and CONTRACTOR and their respective legal representatives, successors, and assigns. 21. AUTHORITY: Each party represents and warrants to the other that the execution, delivery and performance of this Agreement have been duly authorized by all necessary County and corporate action, as required by law. 22. PRIVILEGES AND IMMUNITIES: All of the privileges and immunities from liability, exemptions from laws, ordinances, and rules and pensions and relief, disability, workers' compensation, and other benefits which apply to the activity of officers, agents, or employees of any public agents or employees of the COUNTY, when performing their respective functions under this Agreement within the territorial limits of the COUNTY shall apply to the same degree and CONTRACT 11-8 Key West International Airport 05/22 Monroe County Customs and Border Protection Facility Phase 3 Bid Documents Project Manual extent to the performance of such functions and duties of such officers, agents, volunteers, or employees outside the territorial limits of the COUNTY. 23. LEGAL OBLIGATIONS AND RESPONSIBILITIES: This Agreement is not intended to, nor shall it be construed as, relieving any participating entity from any obligation or responsibility imposed upon the entity by law except to the extent of actual and timely performance thereof by any participating entity, in which case the performance may be offered in satisfaction of the obligation or responsibility. Further, this Agreement is not intended to, nor shall it be construed as, authorizing the delegation of the constitutional or statutory duties of the COUNTY, except to the extent permitted by the Florida constitution, state statute, and case law. 24. NON-RELIANCE BY NON-PARTIES: No person or entity shall be entitled to rely upon the terms, or any of them, of this Agreement to enforce or attempt to enforce any third-party claim or entitlement to or benefit of any service or program contemplated hereunder, and the COUNTY and the CONTRACTOR agree that neither the COUNTY nor the CONTRACTOR or any agent, officer, or employee of either shall have the authority to inform, counsel, or otherwise indicate that any particular individual or group of individuals, entity or entities, have entitlements or benefits under this Agreement separate and apart, inferior to, or superior to the community in general or for the purposes contemplated in this Agreement. 25. NO PERSONAL LIABILITY: No covenant or agreement contained herein shall be deemed to be a covenant or agreement of any member, officer, agent or employee of Monroe County in his or her individual capacity, and no member, officer, agent or employee of Monroe County shall be liable personally on this Agreement or be subject to any personal liability or accountability by reason of the execution of this Agreement. 26. EXECUTION IN COUNTERPARTS: This Agreement may be executed in any number of counterparts, each of which shall be regarded as an original, all of which taken together shall constitute one and the same instrument and COUNTY and CONTRACTOR hereto may execute this Agreement by signing any such counterpart. 27. NON-DISCRIMINATION: Contractor agrees that there will be no discrimination against any person, and it is expressly understood that upon a determination by a court of competent jurisdiction that discrimination has occurred, this Agreement automatically terminates without any further action on the part of any party, effective the date of the court order. Contractor agrees to comply with all Federal and Florida statutes, and all local ordinances, as applicable, relating to nondiscrimination. These include but are not limited to: 1) Title Vil of the Civil Rights Act of 1964 (PL 88-352) which prohibits discrimination on the basis of race, color or national origin; 2) Title IX of the Education Amendment of 1972, as amended (20 USC ss. 1681-1683, and 1685-1686), which prohibits discrimination on the basis of sex; 3) Section 504 of the Rehabilitation Act of 1973, as amended (20 USC s. 794), which prohibits CONTRACT 11-9 Key West International Airport 05/22 Monroe County Customs and Border Protection Facility Phase 3 Bid Documents Project Manual discrimination on the basis of handicaps; 4) The Age Discrimination Act of 1975, as amended (42 USC ss. 6101-6107)which prohibits discrimination on the basis of age; 5) The Drug Abuse Office and Treatment Act of 1972 (PL 92-255), as amended, relating to nondiscrimination on the basis of drug abuse; 6) The Comprehensive Alcohol Abuse and Alcoholism Prevention, Treatment and Rehabilitation Act of 1970 (PL 91-616), as amended, relating to nondiscrimination on the basis of alcohol abuse or alcoholism; 7) The Public Health Service Act of 1912, ss. 523 and 527 (42 USC ss. 690dd-3 and 290ee-3), as amended, relating to confidentiality of alcohol and drug abuse patient records; 8)Title Vill of the Civil Rights Act of 1968(42 USC s. et seq.), as amended, relating to nondiscrimination in the sale, rental or financing of housing; 9) The Americans with Disabilities Act of 1990 (42 USC s. 1201 Note), as maybe amended from time to time, relating to nondiscrimination on the basis of disability; 10) Monroe County Code Chapter 14, Article 11, which prohibits discrimination on the basis of race, color, sex, religion, national origin, ancestry, sexual orientation, gender identity or expression, familial status or age; and 11) Any other nondiscrimination provisions in any Federal or state statutes which may apply to the parties to, or the subject matter of, this Agreement. CONTRACT 11-10 ' I. t' lAi Key West: nterna iona rport 05/22 Monroe Count t ti :Facility ili . Customs and Border Pro ec. onF aci.ity P hale 3 Bid D Project Man ual o c• uments� ro�ec IN WITNESS WHEREOF:the'parties hereto have executed thisagreement:on the day:and:date : :first:above written in:two (2) counterparts, each of which shall:, without proof or accounting for the : : y other counterpart, be deemed an original contract: • . " • ' • 1 J ,,1;: it G (SEAI4\ BOARD OF•COUNTY COMMISSIONERS p✓ 1 J : ,',':1 4:--,:A.' 6 A.';::',4: .i A KEVIN MADOK, CLERK OF MONROE COUNTY, FLORIDA • ,A�' 4\:' r1.Y.:. � ki.A,,::`K.:';',14.1„.•,q ,c7 ',,,,'•,',:4):`-':.':',:, i ,l !6' P�: _ : - ,:;,?:;.:: ,` ` :t B`V• :; 4' ....1 f '���`` : • ;*,:: I.'�;;i�, "__VV„ Bye • -:�-� '�n;,-�:,::�P�or�:�'' .�y As eputy Clerk. ' � . ' . �� : =: . 1,,:f,-',.:;• ' • : Mayor/Chairman 1 aoE COUNTY AuonNEY AovE• Foy 4,7jL CONTRACT ••. :.. ASSI we UNTY.ATTORNEY ". - flats •. • 7/1 � �: �• • . Title.'� ..CEO:. ' .. . • • : . NOTARIAL JURAT:1 : ••. •STATE OF:: Orl rid et. COUNTY OF: : : f?1ofl(Oe ubscribed and sworn to (or:affirmed) before:me, by means of physical presence or D.online : • notarization, on: Tvly j .. . • Oa. . (date) by t • K' .(name of affiant). He/She is personally:known to me or has produced : ' ' • (type of ids .ntifi V 1 n) s identification.. 1. r • • • , fF P � No a"ry Public.State o� .{orid • • �igiii �� r°... ,:. 0 Hubert N Reuter - ! • " My Commission - 'f—'•A: 9 HH'15.9708 " NOTA�RY . ' 4. EX 8/2/2025 '�, *Who is authorized by the corporation to:execute this contract. : . . • . • . : : - : : : • : : .: : • : : : . : : ' : 2 • ., . Z :H:71 . xi :: : N- . C CONTRACT II-11 Key West International Airport O5/22 Monroe County Customs and Border Protection Facility Phase 3 Bid Documents Project Manual INTENTIONALLY LEFT BLANK. CONTRACT 11-12 Key West International Airport 03/24 Monroe County Customs and Border Protection Facility phase 3 Bid Docurnents ProJect Manual SECTION E DRUG FREE WORKPLACE FORM The undersigned Contractor, in accordance with Florida Statute 287.087, hereby certifies that: MAKINIO lQ'ou'p (Name of Business) 1 Publish a statement notifying employees that the unlawful manufacture, distribution, dispensing, possession or use of a controlled substance is prohibited in the workplace and specifying the actions that will be taken against employees for violations of such prohibition, 2. Inform such employees about the dangers of drug abuse in the, workplace, the business' pollicy of maintaining a drug-free workplace, any available drug counseling, rehabilitation and employee assistance programs and the penalties that may be imposed upon employees for drug abuse violations. 3. Give each employee engaged in providing the commodities or contractual services that are under bid a copy of the statement specified in Sub-section (1). 4. In the statement specified in Sub-Section (1)1, notify the employees that as a condition of working on the commodities or contractual services that are under bid, the employee will abide by the terms, of the statement and will notify the employer of any conviction of or plea of guilty or nolo contenders to any violation of Chapter 893 (Florida Statutes) or of any, controlled substance law of the United States or any state for a violation occurring in the workplace no later than five (5) days after such conviction. 5. Impose a sanction on or require the satisfactory participation in a drug abuse assistance or rehabilitation program if such is available in the employee's community or any employee who is so convicted!. 6. Make a good;: faith effort to continue to maintain a drug-free workplace through implementation of this section. As a person authorized to sign the statement, I certify that this firm complies fully with the above requirements, .......... Bidder's Signature Date: BIDDING REQUIREMENTS AND CONTRACT FORMS 1-27 Key West International Airport 03/24 Monroe County Customs and Border Protection Facility Phase 3 Bid Documents Project Manual SECTION L SWORN STATEMENT PURSUANT TO SECTION 287.133(3)(a), FLORIDA STATUTES, ON PUBLIC ENTITY CRIMES This form must be signed and sworn to in the presence of a Notary Public or other official authorized to administer oaths. 1. This sworn statement is submitted with Bid, Proposal or Contract No. for KW l A O,Id_rau MS Fft i L.I ?4 4A 2. This sworn statement is submitted by RAIZ IND t0IQ ST -U7ar Warn ofentity submitting sworn statement} whose business address is 177042 ' ej- EL- and (if applicable) its Federal Employer Identification Number(FEIN) is:65'D 9 Z 3 27 J (If the entity has no FEIN, include the Social Security Number of the individual signing this sworn statement: ) 3. My name is MprT tf S�4LL\� and (please print name of individual signing) my relationship to the entity named above is �.�C) 4. 1 understand that a "public entity crime", as defined in Paragraph 287.133(1)(g), Florida Statutes. means a violation of any state or federal law by a person with respect to and directly related to the transaction of business with any public entity or with an agency or political subdivision of any other state or of the United States, including, but not limited to, any bid or contract for goods or services to be provided to any public entity or an agency or political subdivision of any other state or of the United States and involving anti-trust, fraud, theft, bribery, collusion, racketeering, conspiracy or material misrepresentation. 5. 1 understand that "convicted" or "conviction", as defined in Paragraph 287.133(1)(6), Florida Statutes, means a finding of guilt or a conviction of a public entity crime with or without an adjudication of guilt in any federal or state trial court of record relating to charges brought by indictment or information after July 1, 1989, as a BIDDING REQUIREMENTS AND CONTRACT FORMS I-39 Key West International Airport 03/24 Monroe County Customs and Border Protection Facility Phase 3 Bid Documents Project Manual result of a jury verdict, non-jury trial or entry of a plea of guilty or polo contendere. 6. 1 understand that an "affiliate", as defined in Paragraph 287.133(1)(a), Florida Statutes. means: a. A predecessor or successor of a person convicted of a public entity crime; or b. An entity under the control of any natural person who is active in the management of the entity and who has been convicted of a public entity crime. The term "affiliate" includes those officers, directors, executives, partners, shareholders, employees, members and agents who are active in the management of an affiliate. The ownership by one person of shares constituting a controlling interest in another person or a pooling of equipment or income among persons when not for fair market value under an arm's length agreement, shall be a prima facie case that one person controls another person. A person who knowingly enters into a joint venture with a person who has been convicted of a public entity crime in Florida during the preceding 36 months shall be considered an affiliate. 7. 1 understand that a "person", as defined in Paragraph 287.133(1)(e), Florida Statutes, means any natural person or entity organized under the laws of any state or of the United States with the legal power to enter into a binding contract and which bids or applies to bid on contracts for the provision of goods or services let by a public entity or which otherwise transacts or applies to transact business with a public entity. The term "person" includes those officers, directors, executives, partners, shareholders, employees, members and agents who are active in management of an entity. 8. Based on information and belief, the statement which I have marked below is true in relation to the entity submitting this sworn statement. (Indicate which statement applies.) , V/Neither the entity submitting this sworn statement nor any of its officers, directors, executives, partners, shareholders, employees, members or agents who are active in the management of the entity, nor any affiliate of the entity has been charged with and convicted of a public entity crime subsequent to July 1, 1989. The entity submitting this sworn statement or one or more of its officers, directors, executives, partners, shareholders, employees, members or agents who are active in the management of the entity or an affiliate of the entity has been charged with and convicted of a public entity crime subsequent to July 1, 1989, AND (please indicate which additional statement applies) There has been a proceeding concerning the conviction before a Hearing Officer of the State of Florida, Division of Administrative Hearings. The BIDDING REQUIREMENTS AND CONTRACT FORMS I-40 Key West International Airport 03/214 Monroe County Custorns and Border Protection Facility Phase 3 Bid Documents Protect Manual Final Order entered by the Hearing Officer did not place the person or affiliate on the convicted vendor list, (Please attach a copy of the Final Order.) The person or affiliate was placed on the convicted vendor list. There has been a subsequient proceeding before a hearing officer of the State of Florida, Division of Administrative Hearings. The Final Order entered by the hearing officer determined that it was in the public interest to remove the person or affiliate from the convicted vendor list. (Please attach a copy of the Final Order.) The person or affiliate has not been placed on the convicted vendor list, (Please describe any action taken by or pending with the Department of General Services.) Signature of Authorized Representative: to s 0 AIM+ ?�,M-AtLr) Title Date NOT'ARIAL.JURAT STATE OF: EI-0 ki,D A COUNTY OF: b 1�h bi—ll Subscribed and sworn to (or affirmed) before me, by means of physical Bence or 0 online notarization, on O'S"1 0 9 (date) by 'e- AWA (name of affiant). He/She is personally known to me or has prodTc—ed ............... ............... (type of identification) as identification. qgnuao NOTAR'f PUBLIC Notary Public State of Florida Re0bmeca Malorano f,if fury C mission HH445929 Expires 9120/2027 BIDDING REQUIREMF1s1'1-S AND CONTRACT FORMS 1-41 Key West International Airport 03/24 Monroe County Custorns and Border Protection Facility Phase 3 Bid Documents Project Manual SECTION M SWORN STATEMENT UNDER ORDINANCE NO. 10-1990 MONROE COUNTY, FLORIDA ETHICS CLAUSE MkRIND I Al L .- warrants that he/it has not employed, retained or otherwise had act on his/its behalf any former County officer or employee in violation of Section 2 of Ordinance No. 10-1990 or any County officer or employee in violation of Section 3 of Ordinance No. 10-1990. For breach or violation of this provision the County may, in its discretion, terminate this Contract without liability and may also, in its discretion, deduct from the Contract or purchase price or otherwise recover the full amount of any fee, commission, percentage, gift or consideration paid to the former County officer or employee. (Signature) Date: NOTARIAL JURAT STATIC OF. L---�bbA- COUNTY OF: Subscribed and sworn to (or affirmed) before me, by means ofK" hysical p7ence or 0 online notarization, on 051 oLi 1 0 (date) by �fm, (name of affiant). He/She is personally known to me or has produl ced ..................................................................................................................................................................................................................................................................... (type of identification) as identification, P (ya�ecal/ NOT RY PUBLIC L Notary puMle State of Florid* Robeca Matiorano M Vk om lilt My 4 ISSIOM HH 445929 midsl' My C Expires 912012027 BIDDING REIQUIREMENTS AND CONTRAcT FORMS 1-42 Key West International Airport 03/24 Monroe County Customs and Border Protection Facility Phase 3 Bid Documents Project Manual SECTION Q NON-COLLUSION!: AFFIDAVIT 1, hA A Mft a , of the city of k q�j according to law on my, oath, and under penalty of perjury, depose ands say that: I am 01qD of the,firm of ME5V` 76I d INC, the bidde making tl bid proposal for the project d cribed in the Notice for Calling for Kids for: HASE andl that I executed the said proposal with full aAithority to do so: 2) The prices in this, bid have been arrived at independently without collusion, consultation, communication or agreement for the purpose of restricfing competition, as to any matter relating to such prices with any other bidder or with any competitor: 3) Unless otherwise required by law, the prices which have been quoted in this bid have not been I knowingly disclosed by the bidder and' will not knowingly be disclosed by the, bidder prior to bid opening, directly or indirectly, to any other bidder or to any competitor; and 4) No attempt has been made or will be made by the bliddler to induce any other person, partnership or corporation to submit, or not to submit, a bid for the purpose of restricting competition; 5) The statements contained in this affidavit, are true and correct, and made with full knowledge that Monroe County relies upon the truth of the statements contained in this, affidavit in awarding c9ntractsJor-saW.project. ry (Signature of the Bidder) (Date) NOTARIAL JURAT STATE OF: t7�tlktbA COUNTY OF: r�LL Subscribed and sworn to (or affirmed) before me, by means of 2�physical esence or El online notarization, on 05,10 01 12 LA (date) by_ 1ArjAak (name of affiant). dHe/�SAe i erso�� k�n:own to me or has prodUcied (type of i0etifification) as identification, NOTARY PUBLIC N'olary Public State of FIori4a 'I BIDDING REQUIREMENTS AND CONTRACT FORMS Aebeccd Niniarano'] 1-501 wary MY COMMISSWO HH 444M�2I9 [M� EXP4e$ W20�LW2:7 Key West International Airport O3/24 Monroe County Customs and Border Protection Facility Phase 3 Bid Documents Project Manual SECTION T VENIDOR CERTIFICATION REGARDING SCRUTINIZED COMPANIES LISTS Project Description(s). kw i A �sl-ft"s FAc i ti Tv , ?�fhst -m! Respondent Vendor Name: MOA-1 Vendor FEIN: Vendor's Authorized Representative Name and Title: Address: q M) City: I W';�GT Staie Zip: Phone Number: 7005 - 3 !a) - Email Address: �rlD M , OUW) Section 287,135, Florida Statutes prohibits a company from bidding on, submitting a proposal for, or entering into or renewing a contract for goods or services of any amount if, at the time of contracting or renewal, the company is oil the Scrutinized Companies that Boycott Israel List,created pursuant to Section 215.4725, Florida Statutes, or is engaged in a Boycott of`Israel. Section 287.135, Florida Statutes, also prohibits a company from bidding on, submitting a proposal for, or entering into or renewing a contract for goods or services of$1,000,000 or more, that are on either the Scrutinized Companies with Activities in Sudan List or the Scrutinized Companies with Activities in the Iran Petroleum Energy Sector Lists which were created pursuant to s. 215.473, Florida Statutes,or is engaged in business operations in Cuba or Syria. As the person authorized to sign on behalf of Respondent. I hereby certify that the company identified above in the Section entitled "Respondent Vendor Narne" is not listed on the Scrutinized Companies that Boycott, Israel List or engaged in a boycott of1srael and for Projects of S1,00f 0,000 or more is not listed on either the Scrutinized Companies with Activities in Sudan List. the Scrutinized Companies with Activities in the Iran Petroleum Energy Sector List, or engaged in business operations in Cuba or Syria. I understand that pursuant to Section 287.135, Florida Statutes,the submission of a false certification niay subject company to civil penalties, attorney's fees, and/or costs, I further understand that any contract with tile County may be tenninated, at the option of the County, if the company is found to have submitted a false certification or has been placed on the Scrutinized Companies that Boycott Israel List or engaged in a boycott of"Israel or placed on the Scrutinized Companies with Activities in Sudan List or the Scrutinized Companies with Activities in tile Iran Petroleum Energy Sector List or been engaged in business operations in Cuba or Syria. Certified By:.ffi�!i� F�K- who is authorized to sign on, behalf of the a 3: bove reft0 Author-ized signature: Print Name: -,Title Note: Tile List are available at the following Department of Management Set-vices Site: op! J_Oscrmumatory ('! 'i dahvs vendor hsts H.........._-1-1-1--. � ­111..........._" BIDDING REQUIREMENTS AND CONTRACT FORMS 1-53 Client#: 1930344 MARINCON4 DATE(MM/DD/YYYY) ACORDTM CERTIFICATE OF LIABILITY INSURANCE 1 7/11/2024 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER.THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND,EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW.THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S),AUTHORIZED REPRESENTATIVE OR PRODUCER,AND THE CERTIFICATE HOLDER. IMPORTANT:If the certificate holder is an ADDITIONAL INSURED,the policy(ies)must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED,subject to the terms and conditions of the policy,certain policies may require an endorsement.A statement on this certificate does not confer any rights to the certificate holder in lieu of such endorsement(s). PRODUCER CONTACT Amanda Schneider NAME: USI Insurance Svcs LLC, CL PHONE 352-390-2768 FAX 352-732-0132 A/C,No,Ext: (A/C,No): 4600 Touchton Rd E-MAIL ADDRESS: Amanda.Schneider@usi.com Building 100, Suite 275 INSURER(S)AFFORDING COVERAGE NAIC# Jacksonville, FL 32246 INSURER A:Security National Insurance Company 19879 INSURED INSURER B:Insurance Company of the West 27847 Marino Construction Group, Inc. Upland Specialty Insurance Company 16988 INSURER C: p P Y P y P.O. Box 1706 Starstone Specialty Ins.Co. 44776 INSURER D: p Y Key West, FL 33041 Ironshore Specialty Insurance Co 25445 INSURER E: p Y INSURER F: Progressive American Insurance Company 24252 COVERAGES CERTIFICATE NUMBER: REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACTOR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR TYPE OF INSURANCE ADDLSUBR POLICY EFF POLICY EXP LIMITS LTR INSR WVD POLICY NUMBER MM/DD/YYYY MM/DD/YYYY A X COMMERCIAL GENERAL LIABILITY SES1814945 07/12/2024 07/12/2025 EACH OCCURRENCE $1,000,000 CLAIMS-MADE [X OCCUR PREMISESOEa occur°nce $100,000 X PD Ded:5,000 MED EXP(Any one person) $10,000 PERSONAL&ADV INJURY $1,000,000 GEN'L AGGREGATE LIMIT APPLIES PER: GENERAL AGGREGATE $2,000,000 PRO- POLICY JECT LOC PRODUCTS-COMP/OPAGG $2,000,000 OTHER: $ MBINED F AUTOMOBILE LIABILITY 983714925 07/12/2024 07/12/202 (CEO, identS INGLE LIMIT 1r 000r 000 acc X ANY AUTO BODILY INJURY(Per person) $ OWNED SCHEDULED AUTOS ONLY AUTOS BODILY INJURY(Per accident) $ HIRED NON-OWNED PROPERTY DAMAGE X AUTOS ONLY X AUTOS ONLY Per accident $ A X UMBRELLA LAB X OCCUR EXS1809701 07/12/2024 07/12/2025 EACH OCCURRENCE $5 OOO 000 EXCESS LAB CLAIMS-MADE AGGREGATE s5,000,000 DED RETENTION$ $ B WORKERS COMPENSATION WFL507889700 07/12/2024 07/12/202 X PER OTH- AND EMPLOYERS'LIABILITY STATUTE ER Y/N ANY PROPRIETOR/PARTNER/EXECUTIVE E.L.EACH ACCIDENT $1,000,000 OFFICER/MEMBER EXCLUDED? N] N/A (Mandatory in NH) E.L.DISEASE-EA EMPLOYEE $1,000,000 If yes,describe under DESCRIPTION OF OPERATIONS below E.L.DISEASE-POLICY LIMIT $1,000,000 DESCRIPTION OF OPERATIONS/LOCATIONS/VEHICLES(ACORD 101,Additional Remarks Schedule,may be attached if more space is required) RE: EYW CBP Phase 3 Project Monroe County BOCC is additional insured under the terms and conditions of the General Liability policy and Auto Liability policy when required by written contract.The Umbrella policy follows form of the underlying General Liability and Auto Liability coverage. AP! 16 T 8Y. _. 0AT"�»., 7.17.24 CERTIFICATE HOLDER CANCELLATION WAM _ — Monroe Count BOCC SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE y THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN 1100 Simonton St. ACCORDANCE WITH THE POLICY PROVISIONS. Key West, FL 33040 AUTHORIZED REPRESENTATIVE ©1988-2015 ACORD CORPORATION.All rights reserved. ACORD 25(2016/03) 1 of 1 The ACORD name and logo are registered marks of ACORD #S45522056/M45521373 RAKZR