HomeMy WebLinkAboutPayment and Performance Bonds TM
Document A312 — 2010
Bond No. 108038712
Performance Bond
CONTRACTOR: SURETY:
(Name, legal status and address) (Name, legal status and principal place
Marino Construction Group, Inc, of business)
7025 Shrimp Rd., Ste. 2E This document has important legal
Key West, FL 33040 Travelers Casualty.and Surety consequences.Consultation wfth
OWNER: Company of America an attorney Is encouraged with
(Name, legal status and address) One tower Square respect to Its completion or
Hartford, CT 06183 modification.
Monroe County Board of County Any singular reference to
Commissioners Contractor,Surety,Owner or
1100 Simonton St., Key West, FL 33040 other party shall be considered
CONSTRUCTION CONTRACT plural where applicable.
AIA Document A312-2010
Date: October 16, 2024 combines two separate bonds,a
Amount:$1,473,006.00 Performance Bond and a
Payment Bond,into one form.
Description: This Is not a single combined
(Name and location) Performance and Payment Bond.
Key West International Airport Noise Insulation Program Construction of Group 1
Monroe County, FL
BOND Doc#2482441 Bk#3302 Pg#1054
Date: October 21, 2024 Recorded 114/2024 9:04 AM Page I of 9
(Not earlier than Construction Conti-act Date)
Filed and Recorded in Official Records of
Amount: $1,473,006.00 MONROE COUNTY KEVIN MADOK,CPA
Modifications to this Bond: ANone 0 See Section 16
CONTRACTOR AS PRINCIPAL SURETY
Company: (Corporate Seal) Company: (Corporate eal)
Marino Cons Travelers Casualty and S r t C mpany of America
Signature: Signature:
Name K IC*tA-0-a. I-AAIC4N 0 Name William L.Parker
and Title: P94LjS I ID fN T and Title: Attorney in Fact Parker
L Res Agent
(Any additional signatures appear on the last page of this Performance Bond.)
(FOR INFORMATION ONLY—Naine,address and telephone)
AGENT or BROKER: OWNER'S REPRESENTATIVE:
(Architect, Engineer or other party.)
Acrisure
9500 S.Dadeland Blvd,Suite 400
Miami,FL 33156
Init. AIA Document A3121m—2010.The American Institute of Architects.
§I The Contractor and Surety,jointly and severally,bind themselves,their heirs,executors,administrators,successors
and assigns to the Owner for the performance of the Construction Contract,which is incorporated herein by reference.
2 If the Contractor performs the Construction Contract,the Surety and the Contractor shall have no obligation under
this Bond,except when applicable to participate in a conference as provided in Section 3.
§3 If there is no Owner Default under the Construction Contract,the Surety's obligation tinder this Bond shall arise
after
J the Owner first provides notice to the Contractor and the Surety that the Owner is considering declaring
a Contractor Default,Such notice shall indicate whether the Owner is requesting a conference among
the Owner,Contractor and Surety to discuss the Contractor's performance.If the Owner does not
request a conference,the Surety may,within five(5)business days after receipt of the owner's notice,
request such a conference.If the Surety timely requests a conference,the Owner shall attend.Unless
the Owner agrees otherwise,any conference requested under this Section 3,1 shall be held within ten
(10)business days of the Surety's receipt of the Owner's notice,If the Owner,the Contractor and the
Surety agree,the Contractor shall be allowed a reasonable time to perform the Construction Contract,
but such an agreement shall not waive the Owner's right,if any,subsequently to declare a Contractor
Default;
.2 the Owner declares a Contractor Default,terminates the Construction Contract and notifies the Surety;
and
3 the Owner has agreed to pay the Balance of the Contract Price in accordance with the terms of the
Construction Contract to the Surety or to a contractor selected to perform the Construction Contract.
§4 Failure on the part of the Owner to comply with the notice requirement in Section 3.1 shall not constitute a failure
to comply with a condition precedent to the Surety's obligations,or release the Surety from its obligations,except to
the extent the Surety demonstrates actual prejudice.
§5 When the Owner has satisfied the conditions of Section 3,the Surety shall promptly and at the Surety's expense
take one of the following actions-
§5.1 Arrange for the Contractor,with the consent of the Owner,to perform and complete the Construction Contract;
§5.2 Undertake to perform and complete the Construction Contract itself,through its agents or independent
contractors;
§5,3 Obtain bids or negotiated proposals from qualified contractors acceptable to the Owner for a contract for
performance and completion of the Construction Contract,arrange for a contract to be prepared for execution by the
Owner and a contractor selected with the Owner's concurrence,to be secured with performance and payment bonds
executed by a qualified surety equivalent to the bonds issued on the Construction Contract,and pay to the Owner the
amount of damages as described in Section 7 in excess of the Balance of the Contract Price incurred by the Owner as
a result of the Contractor Default;or .
§5.4 Waive its right to perform and complete,arrange for completion,or obtain a new contractor and with reasonable
promptness under the circumstances:
.1 After investigation,determine the amount for which it may be liable to the Owner and,as soon as
practicable after the amount is deterinined,make payment to the Owner;or
2 Deny liability in whole or in part and notify the Owner,citing the reasons for denial,
§6 If the Surety does not proceed as provided in Section 5 with reasonable promptness,the Surety shall be deemed to
be in default on this Bond seven days after receipt of an additional written notice from the Owner to the Surety
demanding that the Surety perform its obligations under this Bond,and the Owner shall be entitled to enforce any
remedy available to the Owner.If the Surety proceeds as provided in Section 5.4,and the Owner refuses the payment
or the Surety has denied liability,in whole or in part,without further notice the Owner shall be entitled to enforce any
remedy available to the Owner,
Init. AIA Document A3121m—2010,The American Institute of Architects.
2
§7 If the Surety elects to act under Section 5.1,5.2 or 5.3,then the responsibilities of the Surety to the Owner shall not
be greater than those of the Contractor under the Construction Contract,and the responsibilities of the Owner to the
Surety shall not be greater than those of the Owner under the Construction Contract.Subject to the commitment by the
Owner to pay the Balance of the Contract Price,the Surety is obligated,without duplication,for
.1 the responsibilities of the Contractor for correction of defective work and completion of the
Construction Contract;
.2 additional legal,design professional and delay costs resulting from the Contractor's Default,and
resulting from the actions or failure to act of the Surety under Section 5;and
.3 liquidated damages,or if no liquidated damages are specified in the Construction Contract,actual
damages caused by delayed performance or non-performance of the Contractor.
§8 If the Surety elects to act under Section 5.1,5.3 or 5.4,the Surety's liability is limited to the amount of this Bond.
§9The Surety shall not be liable to the Owner or others for obligations of the Contractor that are unrelated to the
Construction Contract,and the Balance of the Contract Price shall not be reduced or set off on account of any such
unrelated obligations.No right of action shall accrue on this Bond to any person or entity other than the Owner or its
heirs,executors,administrators,successors and assigns.
§10 The Surety hereby waives notice of any change,including changes of time,to the Construction Contract or to
related subcontracts,purchase orders and other obligations.
§11 Any proceeding,legal or equitable,under this Bond may be instituted in any court of competent jurisdiction in
the location in which the work or part of the work is located and shall be instituted within two years after a declaration
of Contractor Default or within two years after the Contractor ceased working or within two years after the Surety
refuses or fails to perform its obligations under this Bond,whichever occurs first.If the provisions of this Paragraph
are void or prohibited by law,the inininium period of limitation available to sureties as a defense in the jurisdiction of
the suit shall be applicable.
§12 Notice to the Surety,the Owner or the Contractor shall be mailed or delivered to the address shown on the page
on which their signature appears.
§13 When this Bond has been furnished to comply with a statutory or other legal requirement in the location where
the construction was to be performed,any provision in this Bond conflicting with said statutory or legal requirement
shall be deemed deleted berefrom and provisions conforming to such statutory or other legal requirement shall be
deemed incorporated herein.When so fumishcd,the intent is that this Bond shall be construed as a statutory bond and
not as a common law bond.
§14 Definitions
§14.1 Balance of the Contract Price.The total amount payable by the Owner to the Contractor under the Construction
Contract after all proper adjustments have been made,including allowance to the Contractor of any amounts received
or to be received by the Owner in settlement of insurance or other claims for damages to which the Contractor is
entitled,reduced by all valid and proper payments made to or on behalf of the Contractor under the Construction
Contract.
§14.2 Construction Contract.The agreement between the Owner and Contractor identified on the cover page,
including all Contract Documents and changes made to the agreement and the Contract Documents,
§14.3 Contractor Default.Failure of the Contractor,which has not been remedied or waived,to perform or otherwise to
comply with a material term of the Construction Contract.
§14.4 Owner Default,Failure of the Owner,which has not been remedied or waived,to pay the Contractor as required
under the Construction Contract or to perform and complete or comply with the other material terms of the
Construction Contract.
14.5 Contract Documents.All the documents that comprise the agreement between the Owner and Contractor.
15 If this Bond is issued for an agreement between a Contractor and subcontractor,the term Contractor in this Bond
shall be deemed to be Subcontractor and the term Owner shall be deemed to be Contractor.
[nit. AIA Document A312m—2010.The American Institute of Architects. 3
§16 Modifications to this bond are as follows:
(Space is provided below for additional signatures of addedparties, other than those appearing on the cover page)
CONTRACTOR AS PRINCIPAL SURETY
Company: (Corporate Seal) Company: (Corpor ate Seal)
Signature: Signature:
Name and Title: M00 940, POZSIII NName and Title:
Address. t 0\) -q Address
® fL :3 0
[nit. AIA Document A312TM—2010.The American Institute of Architects.
4
/
A �� � �& ^�� w��� u�d�� x�
U������������N ����N � ^�' "� ��R �� �� ������Vnu�mw= ° °� � = �� � �
Bond No. 1U8O38712
Payment B=~"=
CONTRACTOR: SURETY:
(Nzme legal status and address) (Name, legal status ondpm>mipa/place
Marino Construction Group, Inc. of business)
7025Shrimp Rd., Stu. 2E This document has important legal
Key West, FL 33040 Travelers Casualty and Surety consequences.Consultation with
on�mmoyive000u�Qed w\�
OWNER: ComPenyofAmericm �opm��(mcomp|edonor
One Tower
(Nzn� k�o/x�/m'un�oo6�ou� m .|�maKon
' Hartford, CT uo .
Monroe County Board of County Any singular reference W
Commissioners Contractor,Surety,Owner vr
1100Simonton SL, Key West, FL 33040 other party shall beounoidenad
p|um|whamapplicable.
CONSTRUCTION CONTRACT
Date: AiA Document xu1o_oV10
October 2O24' combines two separate bonds,a
Performance Bond and a
Amount: $1.473.006.00 Payment Bond,Into one form.
ThIs}u not a single combined
Description: Performance and Payment Bond,
(7onooxd location)
Key West International Airport Noise Insulation Program Construction of Group 1
Monroe County, FL
BQNE)
Date: October 21. 2O24
(Aro,earlier than Construction Contract Date)
Amount:$1.473.006.00
Modifications tn this Bond: ONnon Xsoe section l8
CONTRACTOR A8PRINCIPAL SURETY
Company: (Corporate Seal) Company: ([ogno/a/eJerV
MarinoConstruc on Group, Inc. Travelers Casualty and ompany of America
Signature:
and Title: and Title:
Attorney^'' ~~^�' ^'`~^~v~^^
(Any additional signatures appear onthe lost page of this}qymextDond/
(FOR/N9LB8d.4 77O8y0JVL Y--Name, address and
AGENTurBR0KER; OWNER'S REPRESENTATIVE:
(Architect, F»gineerorooherpo,�.)
Acrisuna
S5UOO.made|anu Blvd,Suite 4UU
Miami,FL33150
|n|t. A—'Document A-- --The—American Institute
of Architects. 0611io 5
§I The Contractor and Surety,jointly and severally,bind themselves,their heirs,executors,administrators,successors
and assigns to the Owner to pay for labor,materials and equipment furnished for use in the performance of the
Construction Contract,which is incorporated herein by reference,subject to the following terms,
§2 If the Contractor promptly makes payment of all sums due to Claimants,and defends,indemnifies and holds
harmless the Owner from claims,demands,liens or suits by any person or entity seeking payment for labor,materials
or equipment furnished for use in the performance of the Construction Contract,then the Surety and the Contractor
shall have no obligation under this Bond..
§3 If there is no Owner Default under the Construction Contract,the Surety's obligation to the Owner under this Bond
shall arise after the Owner has promptly notified the Contractor and the Surety(at the address described in Section 13)
of claims,demands,liens or suits against the Owner or the Owner's property by any person or entity seeking payment
for labor,materials or equipment fumished for use in the performance of the Construction Contract and tendered
defense of such claims,demands,liens or suits to the Contractor and the Surety.
§4 When the Owner has satisfied the conditions it)Section 3,the Surety shall promptly and at the Surety's expense
defend,indemnify and hold harmless the Owner against a duly tendered claim,demand,lien or suit,
§5 The Surety's obligations to a Claimant tinder this Bond shall arise after the following:
§5.1 Claimants,who do not have a direct contract with the Contractor,
.1 have furnished a written notice of non-payment to the Contractor,stating with substantial accuracy the
amount claimed and the name of the party to whom the materials were,or equipment was,furnished or
supplied or for whom the labor was done or performed,within ninety(90)days after having last
performed labor or last furnished materials or equipment included in the Claim;and
,2 have sent a Claim to the Surety(at the address described in Section 13).
§5.2 Claimants,who are employed by or have a direct contract with the Contractor,have sent a Claim to the Surety(at
the address described in Section 13).
§6 If a notice of non-payment required by Section 5.1.1 is given by the Owner to the Contractor,that is sufficient to
satisfy a Claimant's obligation to furnish a written notice of non-payment under Section 5.1.1.
§7 When a Claimant has satisfied the conditions of Sections 5.1 or 5.2,whichever is applicable,the Surety shall
promptly and at the Surety's expense take the following actions:
§7.1 Send an answer to the Claimant,with a copy to the Owner,within sixty(60)days after receipt of the Claim,
stating the amounts that are undisputed and the basis for challenging any amounts that are disputed;and
§7.2 Pay or arrange for payment of any undisputed amounts.
§7.3 The Surety's failure to discharge its obligations under Section 7.1 or Section 7.2 shall not be deemed to
constitute a waiver of defenses the Surety or Contractor may have or acquire as to a Claim,except as to undisputed
amounts for which the Surety and Claimant have reached agreement.If,however,the Surety fails to discharge its
obligations under Section 7.1 or Section 7.2,the Surety shall indemnify the Claimant for the reasonable attorney's
fees the Claimant incurs thereafter to recover any sums found to be due and owing to the Claimant.
§8 The Surety's total obligation shall not exceed the amount of this Bond,plus the amount of reasonable attorney's
fees provided under Section 7.3,and the amount of this Bond shall be credited for any payments made in good faith
by the Surety.
9 Amounts owed by the Owner to the Contractor under the Construction Contract shall be used for the performance
of the Construction Contract and to satisfy claims,if any,under any construction performance bond.By the
Contractor furnishing and the Owner accepting this Bond,they agree that all funds earned by the Contractor in the
performance of the Construction Contract are dedicated to satisfy obligations of the Contractor and Surety under this
Bond,subject to the Owner's priority to use the funds for the completion of the work.
Init, AIA Document MUM—2010.The Amedcan Institute of Architects,
§10 The Surety shall not be liable to the Owner,Claimants or others for obligations of the Contractor that are
unrelated to the Construction Contract.The Owner shall not be liable for the payment of any costs or expenses of any
Claimant under this Bond,and shall have under this Bond no obligation to malce payments to,or give notice on behalf
of,Claimants or otherwise have any obligations to Claimants under this Bond,
§11 The Surety hereby waives notice of any change,including changes of time,to the Construction Contract or to
related subcontracts,purchase orders and other obligations.
§12 No suit or action shall be commenced by a Claimant under this Bond other than in a court of competent
jurisdiction in the state in which the project that is the subject of the Construction Contract is located or after the
expiration of one year from the date(1)on which the Claimant sent a Claim to the Surety pursuant to
Section 5.1.2 or 5.2,or(2)on which the last labor or service was performed by anyone or the last materials Or
equipment were famished by anyone under the Construction Contract,whichever of(1)or(2)first occurs.If the
provisions of this Paragraph are void or prohibited by law,the minimum period of limitation available to sureties as a
defense in the jurisdiction of the suit shall be applicable.
§13 Notice and Claims to the Surety,the Owner or the Contractor shall be mailed or delivered to the address shown
on the page on which their signature appears.Actual receipt of notice or Claims,however accomplished,shall be
sufficient compliance as of the date received.
§14 When this Bond has been furnished to comply with a statutory or other legal requirement in the location where
the construction was to be performed,any provision in this Bond conflicting with said statutory or legal requirement
shall be deemed deleted herefrom and provisions conforming to such statutory or other legal requirement shall be
deemed incorporated herein.When so furnished,the intent is that this Bond shall be construed as a statutory bond and
not as a common law bond.
§IS Upon request by any person or entity appearing to be a potential beneficiary of this Bond,the Contractor and
Owner shalt promptly furnish a copy of this Bond or shall permit a copy to be made.
§16 Definitions
16.1 Claim.A written statement by the Claimant including at a minimum:
.1 the name of the Claimant;
.2 the name of the person for whom the labor was done,or materials or equipment famished;
.3 a copy of the agreement or purchase order pursuant to which labor,materials or equipment was
famished for use in the performance of the Construction Contract;
.4 a brief description of the labor,materials or equipment furnished;
.5 the date on which the Claimant last performed labor or last furnished materials or equipment for use in
the performance of the Construction Contract;
.6 the total amount earned by the Claimant for labor,materials or equipment furnished as of the date of
the Claim,
.7 the total amount of previous payments received by the Claimant;and
.8 the total amount due and unpaid to the Claimant for labor,materials or equipment famished as of the
date of the Claim.
§16.2 Claimant.An individual or entity having a direct contract with the Contractor or with a subcontractor of the
Contractor to furnish labor,materials or equipment for use in the performance of the Construction Contract.The term
Claimant also includes any individual or entity that has rightfully asserted a claim under an applicable mechanic's lien
or similar statute against the real property upon which the Project is located.The intent of this Bond shall be to
include without limitation in the terms"labor,materials or equipment"that part of water,gas,power,light,heat,oil,
gasoline,telephone service or rental equipment used in the Construction Contract,architectural and engineering
services required for performance of the work of the Contractor and the Contractor's subcontractors,and all other
items for which a mechanic's lien may be asserted in the jurisdiction where the labor,materials or equipment were
famished.
§16.3 Construction Contract.The agreement between the Owner and Contractor identified on the cover page,
including all Contract Documents and all changes made to the agreement and the Contract Documents.
AIA DoeumentkiV-—MO.Th.American VMAIA.of Architects.
§16.4 Owner Default.Failure of the Owner,which has not been remedied or waived,to pay the Contractor as required
under the Construction Contract or to perform and complete or comply with the other material terms of the
Construction Contract.
§16.5 Contract Documents,All the documents that comprise the agreement between the Owner and Contractor.
§17 If this Bond is issued for an agreement between a Contractor and subcontractor,the term Contractor in this Bond
shall be deemed to be Subcontractor and the term Owner shall be deemed to be Contractor.
§18 Modifications to this bond are as follows:
bond is ,riven
, ' to comply with Section 255()5
F1orida8ntt,,i and any action instituted by'�l
"'airitunt Under this bond tbl'Payine,"t must be it,
fteordance willi the ll()tico�
e and time Ihnitation
in Section 255.05(2).Florida Statutes
(Space is provided below for additional signatures ofaddedparties, other than those appearing on the coverpoge)
CONTRACTOR AS PRINCIPAL SURETY
Company: (Corporate Seal) Company: (Corporate Seal)
Marino Construction Gro , Inc. Travelers Casualty and Surety y of America
Signature: Signature: -------- AW
Name and Title: "I CA*tL t4fm4 WO, IV Name and Title:William L. Park 11,Attorney in Fact& FL Res Agent
Address 7025 Shrimp Rd., Ste. 2E Address One Tower Square 7
Key West, FL 33040 Hartford, CT 06183
Init. AIA Document A312111-2010.The American Institute of Architects.
8
Travelers Casualty and Surety Company of kni—ericW
Aftk Travelers Casualty and Surety Company
TRAVELERS,J St. Paul Fire and Marine Insurance Company
POWER OF ArrOnweY
KNOW ALL MEN ev THESE PRESENTS: That Travelers Casualty and Surety Company o America, Travelers Casualty and Surety Company, and St.
po"| Fire and Marine Insurance Company are corporations uv|y organized under the laws of the State of Connecticut (herein 0000miwa|y called the
"Companiea^).and that the Companies uo hereby make,constitute and appoint William L.Parker nxM|xM| .
Florida ' m*|r true and lawful Attumoy-in-Fact to mgo, exeovte, ooa| and acknowledge any and all bunu*, reoognizanm,s,
conditional undertakings and other writings obligatory in the nature thereof on behalf of the Companies in their business of guaranteeing the
fidelity o, pomuno, yvammecmg the performance of contracts and executing or guaranteeing bonds and undertakings required or permitted in any
actions o,proceedings allowed uylaw.
/w WITNESS WHEREOF,the Companies have caused this instrument to be signed,and their corporate seals to be hereto affixed,this 3rd day of February,
2017.
HA r
State of Connecticut
By:
City m Hartford ao. Robert L. wuney.aemu,Vice President
On this the am day of February, 2017 before me personally appeared Robert L. Raney, who ammo=|ougeu himself to be the Senior Vice pmomont of
Travelers Casualty and Surety Company ry America,Travelers Casualty and Surety Company, and so, Paul Fire and Marine Insurance Company, and that
he, as such, being authorized so to do, executed the foregoing instrument for the purposes therein oomomeu by signing on behalf nfthe oo,pomunno by
himself aaa duly authorized officer.
m Witness Whereof,|hereunto set myhand and official seal,
My Commission expires the xmx day o,June, eoc10
manec.Tetrexuu. Notary Public
This puwo, of Attorney in granted under and by the authority of the following resolutions adopted by the Boards of Directors of Travelers Casualty
Surety Company of America,Travelers Casualty and Surety Company, and St. Paul Fire and Marine Insurance Company,which resolutions are now in full
force and effect,muuinn as follows:
nEaocveo that the Chairman, the President, any Vice Chairman, any Executive Vice President, any Senior Vice President, any v|oe President, any
Second Vice President, the Treasurer, any Assistant Treasurer, the Corporate Secretary or any Assistant Secretary may appoint Attorneys-in-Fact and
Agents to act for and on behalf of the Company and may give such appointee such authority as his or her certificate of authority may prescribe to sign with
the Company's name and seal with the Company's seal bonds, recognizances,contracts of indemnity, and other writings obligatory in the nature of a bond,
recognizance, or conditional undertaking, and any of said officers or the Board of Directors at any time may remove any such appointee and revoke the
power given him or her;and it is
punrnER RsooLvso. that the o»oinnan, the pream*nt, any woo Chainnan, any Executive mov President, any Senior v|oo President o, any Vice
President may delegate all u,any part o,the foregoing authority m one o,more officers v,employees m this Company, provided that each such delegation
ism writing and a copy thereof io filed in the office of the Secretary;and nio
puRrxsn Rsaocvso, that any »^nu, mooVn|zence, contract of indernnity, or writing obligatory in the nature of umnu, reongnizenoo, or conditional
undertaking nxao be valid and binding upon the Company when(o)signed uythe pmuiuem.any Vice Cxoinnon, any Executive Vice pmoiuont, any Senior
Vice Pnamuont o, any vioo preaiuem, any Second woa President, the Treasurer, any Assistant Treaoumr. the Corporate Secretary or any Assistant
Secretary and duly attested and sealed with the Company's seal by a Secretary or Assistant Secretary;or(b) duly executed(under seal, if required) by one
or more Amumeyw'in'pact and Agents pursuant to the power pmnn,ioou in his o, her certificate o, their certificates of authority or by one or more
Company officers pursuant ma written delegation nf authority;and nis
FURTHER RESOLVED, that the signature of each nrthe following officers: President, any Executive Vice President, any Senior Vice President, any Vice
President, any Assistant Vice President, any Secretary, Assistant Secretary,and the seal w the Company may be affixed by facsimile to any Power of
Attorney or to any certificate relating thereto appointing Resident Vice Presidents, Resident Assistant Secretaries or Attorneys-in-Factmrpumnoosvnlyof
executing and attesting bonds and undertakings and other writings obligatoryin the t thereof, andany such Power of Attorney or certificate bearing
such facsimile signature or facsimile aae| uxon be valid and binding upon the Company and any such power enexecuted and certified by such facsimile
signature and facsimile seal shall be valid and binding on the Company in the future with respect to any bond or understanding to which it is attached.
|. Kevin E. nuoxee, the undersigned, Assistant aeuoxory of Tm,*|em 000uauv and Surety Company of America, Travelers Casualty and Surety
Company, and St. Paul Fire and Marine Insurance uompany, do hereby certify that the above and foregoing is a true and correct copy of the Power of
Attorney executed uv said Companies,which remains in full force and effect.
Dated this 21 day of omvum, zoo* Hughes,Assiltant Secretary
mverify the aiithenticity of this Power o Attorney,please call usat 1-800-421-3880.
Please refer to the above~amedAttomey-in-Factmd the details of the bond to which the power is attached