08/16/2006 Contract
DANNY L. KOLHAGE
CLERK OF THE CIRCUIT COURT
DATE:
August 22, 2006
TO:
Bevette Moore
Airport Business Administrator
Pamela G. Hanc&
Deputy Clerk
FROM:
At the August 16, 2006, Board of County Commissioner's meeting the Board granted
approval and authorized execution of the following:
) Construction Contract between Monroe County and Koch Corporation for the Noise
Insulation Program, Phase 5 Construction, for the Key West International Airport. Enclosed is a
duplicate original for your handling.
Professional/Service Order NO.5 between Monroe County and THC, Inc. for the Noise
Insulation Program, Phase 5 Construction Services, for the Key West International Airport.
Enclosed is a copy for your handling.
Purchase/Service Order No. 05/06-35 between Monroe County and URS, for Noise
Coordinator Services for the Key West International Airport. Enclosed is a copy for your
handling.
Purchase/Service Order No. 05/06-37 between Monroe County and URS, for DBE
Implementation Services for the Key West International Airport and the Marathon Airport.
Enclosed is a copy for your handling.
Should you have any questions please do not hesitate to contact this office.
cc: County Attorney
Finance
File
Key West International Airport ~ Monroe County -Noise Insulation Program
CONSTRUCTION CONTRACT
THIS AGREEMENT effective 16th day of August ,20~, between the MONROE
COUNTY, a munic~pal core.oration org~nized and existing under the laws of the State of Florida (hereinafter referred to as the
"Sponsor") and Koch Corporat, on ,(hereinafter referred to as rhe
"Contractor").
WITNESSETH
WHEREAS, the Sponsor is the sponsor of the Key West International Airport Noise Insulation Program (hereinafter referred to as
the "NIP"); and
WHEREAS, rhe Sponsor has elected to implement rhe fifth phase of the NIP (hereinafter referred to as "Phase 5"); and
WHEREAS, the Phase 5 NIP is managed by the consultant team consisting of the prime manager, architect, acoustician and
construction manager (hereinafter referred to as the Program Manager"); and
WHEREAS, the Contractor shall perform all necessary work and labor in the Phase 5 NIP (hereinafter referred to as the "Work");
and
WHEREAS, the Work shall be performed in accordance with the approved Phase 5 NIP Construction Drawings dated April 17,
2006 (herinafter referred to as the "Drawings" and the approved Phase 5 NIP Construction Specifications dated April ]7,2006
(hereinafter referred to as the "Specifications"); and
WHEREAS, the Work shall be completed in accordance with the Phase 5 NIP Construction Schedule (hereinafter referred to as the
"Schedule"), consisting of the sub-construction construction schedules (1-6) and total construction period schedule; and
NOW, THEREFORE, in consideration of the terms, covenants and conditions set forth herein, and other good and valuable
consideration, the receipt and sufficiency of which are hereby acknowledged, the Sponsor and the Contractor hereby agree as
follows;
That the Contractor in consideration of the payment of the Contract price thereof amounting to Two Million Seven Hundred
Eiahteen Three Hundred Ninetv Four Dollars ($2.718.394.00). shall perform all work set forth in the Drawings and
Specifications, and agrees to furnish all materials (except as specified to be furnished by the NIP), together with all necessary to
furnish all necessary equipment, tools, labor, and other means of construction and do and perform all necessary work and lahor for
the full completion of the Work under Contract No. , the Work to be performed in accordance with approved
Drawings and Specifications and for the price and compensation set forth above and as specified in the Bid Form of the Contractor
which is hereto attached and hereby made a part of this agreement. The Work will be performed in accordance with Schedule.
Work and payments will be pursuant to and in accordance with Drawings and Specifications, therein set forth and addenda thereto,
all being incorporated by reference and being a part of this agreement.
The Contractor agrees to utilize the following Disadvantaged Business Enterprises:
Ken/1ar General Contracting
CONSTRUCTION CONTRACT/BONDS
00500 - 1
Contractor agrees that the Work shall be done and performed in a good and workmanlike manner, that all materials and labor shall
be in strict conformity in every respect with the Drawings and Specifications for the improvement and shall be subject to
inspection and approval of the Sponsor through its duly authorized Program Manager and, in case any material or labor supplied
shall be rejected by the Sponsor as defective or unusable, such rejected material shall be removed and replaced with approved
material, and the rejected work shall be corrected to the satisfaction and approval of the Sponsor through its authorized Program
Manager, at no additional cost or expense to the Sponsor.
Contractor further agrees that he will commence the Work hereunder upon receipt of the executed copy thereof and will complete
the Work to the satisfaction and approval of the Program Manager within the time limits specified in Time of Completion
and Schedule sections in the Specifications.
It is further agreed that any delay caused by the elements and other causes over which Contractor has no control or by strikes or
other combined action of workers employed in the construction or in the transportation of materials, in no part caused or resulting
from default or collusion on the part of the Contractor, shall be excused and the time for completion extended to the extent that
Program Manager may find and determine such condition to have delayed completion within the time limit through no
fault of the Contractor, but the judgment of Program Manager in respect thereto shall be final and conclusive upon the
parties. Contractor agrees that neither it nor its Subcontractors shall have any claim for damages against the Sponsor
or its agents arising from delays in the Work. Contractor understands that its sole remedy for a delay is an extension of time.
The Sponsor and the Contractor agree that the damages which would be incurred by the Sponsor in the event of delay of the
Project would be substantial but are not capable of being precisely calculated as of the execution of this Contract. The Sponsor
and the Contractor therefore agree based upon their professional knowledge and experience with projects of this type and their best
estimates of the damage associated with delay of the Project that the Contractor (and his surety) shall be liable for and shall forfeit
One Thousand Dollars ($1,000.00) from the Contract Sum for each calendar day (Sundays and Holidays included) after the final
Completion Date that any part of the Work upon any property remains incomplete, herein stipulated as fixed, agreed, as liquidated
damages, and not as a penalty.
It is further understood and agreed that no claim for extra Work done or materials furnished by the Contractor will be allowed
except as provided by the Drawings and Specifications, nor shall the Contractor do any work or furnish any materials not covered
by the Drawings and Specifications and by this Contract unless such work is first ordered in writing as provided in the Drawings
and Specifications. Any extra work done or materials furnished by the Contractor without written order first being gi ven therefore
as in the Drawings and Specifications provided shall be at Contractor's risk, cost and expense, and Contractor agrees in such event
that he will make no claim for compensation for such extra work or materials.
It is further agreed that in no event shall the contracting officers of the Sponsor be personally liable or responsible in any manner
to the Contractor, Subcontractors, suppliers, laborers or to other person or persons whomsoever for claim, demand, damages,
actions, or causes of action or character arising out of or by reason of the execution of this agreement or the performance and
completion of the Work and improvement provided herein.
Contractor certifies to being not disqualified or debarred from entering into or receiving a Florida Department of Transportation
contract, or a municipal State-aid or County State-aid Contract administered by the Department of Transportation as agent of a
municipality or county pursuant to Florida Statutes. Further, Contractor agrees not to utilize either directly or indirectly any
contractor, corporation, partnership, or business however organized, which is disqualified or debarred from entering into or
receiving contract as stated above. This restriction applies regardless of whether the disqualified or disbarred party acts in the
capacity of a Contractor, a Subcontractor, or as an equipment or material supplier.
It is further agreed that the Contractor will abide by the provisions of Title VI of the Civil Rights Act of 1964 and Federal
Regulations of the Department of Transportation, set forth in Section 00210 of the Specifications, will afford opportunity for
Disadvantaged Business Enterprise as set forth in Section 00210 of the Specifications, will comply with restrictions on Federal
Public Works Projects as set forth in Section 00210 of the Specifications, will comply with the General Civil Rights Provisions as
set forth in Section 00210 of the Specifications, and will comply with Buy American Steel and Manufactured Products for
Construction requirements as set forth in Section 00210 of the Specifications.
CONSTRUCTION CONTRACT/BONDS
00500 - 2
MONROE COUNTY NOISE INSULATION PROGRAM
By
MAf'R CI1AI(L-c-> ~So~oJ
STATE OF FLORIDA )
) SS
MONROE COUNTY )
This instrument was acknowledged before me on
day of
, as the authorized representative of Monroe County NIP.
(Notarial Seal)
Notary Public Signature
--
0d~ ( CONT
By
Title C. Steph n Koch, Pres i dent
Contractor
Individual & Co-Partnership Acknowledgment
STATE OF FLORIDA )
) SS
MONROE COUNTY )
This instrument was acknowledged before me on
day of
,20
by
Notary Public Signature
::t .....
~ :l>
::o.,.,:z:
or-z
"'::x;-<
n- r-
on-
e-A
:;=?J c)
-; n~::=
::< :~b
"T1 -
r- C>
:l> r'1
(Notarial Seal)
Contractor
Corporate Acknowledgment
KENTUCKY
STATEOFJ(D(OJIJUOOt - )
) ss
~1IOJ1; COUNTY )
JEffERSON
This instrument was acknowledged before me on 28th day of
C. Stephen Koch
,2006
(Notarial Seal)
CONSTRUCTION CONTRACT/BONDS
~
=
l!ji!
-
c::
G")
N
N
-0
:%
.."
,-
m
:=l
-"
-:::>
;'0
;:;)
T"'1
C"')
o
::::J
Cl
-
..
~
, by
00500 - 3
M<<Hlroe CoI.Mty Npisc Insulation Pro,gram (NIP)
PAYMENT AND PERFORMANCE BOND
Part A: Payment Bond
IUlD R). 3481632
KNOW ALL BY THESF.; PRESENTS, that we, KOCH <X1U'ORATIaI
.'Principal, who,e addres, is 1131 LOGAN S'IREET, LOOISVILLE, KY 40204
GREAT AMElUCAN INSURANCE
Contractor,
, and Surety
l'YWD:a.NV
. whose add"". is o;An _T.lIm' !'l'I'RRR'I'. C'TII1l"'TlIWll.TT. 011 45202
duly aUlhorittd and licensed ro do busine" in the State of Florida, as Surety. hereinafter called Surety. 81e held and firmly bound
unto the MONROE COUNT\' NOISE INSUlATION PROGltA~, as obli~naft.er called ~.or the use and
benefit of claimants .. hereinafter provided in ti,e .mount of ~lMf ~.. r the
pa)''t'M:nt whili:reof Principal and Surety bind tbemflfl:lve~, thei t, ~ BMtlINtI~~ ll, Qssigns, jointly and
severally, fi1'1nly by these present<. WHEREAS. J'rincip.1 ha, written agreement dated . 2()_, entered
10to:a contract with Owner for NIP CONTRACf A.lP ~~ in accordance with drawing... af1d specifications prepared
bylfor MONROE COUNTY NIP which contract i. b mad. party of hereof and IS rcq\J1red by Section 255.05, Flond.
Statutes. The said written aweemenl, drawing.', 'Jl<'Ciflcations and amendments afe hereinafter referred to as tbe Contract.
NOW THEREFORI'.. THE CONDITION OF THIS OBLIGATION, as required by Section 255.05, Florida Statutes, is such
lMt, if the Principal shall faithfllll\l perfOrm the ,aid contract and pay every person entitled thereto for all the claims for labor
pcrfonned am materiab fl1r"iiJ~ed under tbe Contr.act. to be used or eonsumed ill mak1ng the public improvement:'li or performin.t
the public work.. provided in lbe Contract, then thi. obligation shan be null and void; otherwise js shall remain in full force and
effect subject. however, to the following condition,: 1) No ....ignment, modification or change ofthe Contract, or change in the
work covered thereby, or any extension of time for the completion oftbe Contract shall release the sureties on the bond. 2.) Not
later than one yeal' after the completion of the work under the Contract~ any party in interest may maintain an action in hiill own
name against the Principal and lhe Surety upon thi. bond for the recovery of any damaJlCS he may have sustained by reason of the
failure of lhe Principallo comply with the Contract or with tbe Contract between the Principal and his subcontracrors. If the
amount ~alized on this bond i. insufficient to satisfy all claim, of the p.rtie, in full. it ,haU be distributed among the partie, pro
rata.
Signed and sealed this
28th day of
June
, 20 06
IN THE PRESENCE OF:
KOCH
aI
tit; l&~
L. G ~ y.tne.
1 sa '. '.1reen
By;
(Seal)
c.
President
GREAT AMIlRICAN INSURANCE <nn'ANY
Name of Surety
5J~"~.~
DIANE L. PHELPS Witne,
(Seal)
CONSTRUCTION CONTRACT/BONDS
005()()-4
Monroe Count)' NoiRe fnSl,1lation Program (NIP)
PAYMENT AND PERFORMANCE BOND
Part B: Performanee Bond
IUID liD. 3481632
KNOW ALL BY TRESE PRESENTS. tllat we,
KOCH ~
Contractor,
as Principal. who.e address ia 1131 r.tY:l\N ~RR'I'. r.lI1TlWTr.r.R,]{V dll?nll , and Surety
GREAT AMERICAN INSlJRANCE
CXMPANY .who...ddr...i. 'iRn WAr.1\lf1'l' ~RR'I'r t"'~'PT OR 45202
duly authorized and licensed to do bu,ine.", in the ,state of Florida. as Surety, hereinafter called Surel)l. are h.ld and firmly bound
unto MONROE COUNTY NOISE INSULA nON PROGRAM (NIP), a. ob ligee, hereinafter called owner, for the u.e and
benefit of claimantlil alii hereinafter provided in the <lmount of iDI) MILI.J[B' ~ IIRIRl KI(.HI~ ........,r the
payment whereof Principal and Surety bind them[';el ve.o;;. their heirs, executors, administrators, !llUccessors and asmgns, jOi11tly and
severally, firmly by tn..se presents. WHEREAS. ~en agrecm.m dated ,20_. emered
into a contract with Owner for NIP CONTRACf. , in ac<ordance with drawings and 'pecifications prepared
by/for MONROE COUNTY NIP which contract is y renee made party of n....of and is required hY Section 255.05, Florida
Statutes. The Mid written agreement, drawings. sp,,.ifieation, and amendment, are hereinall:errcfared to a, the Contract.
NOW THEREFORE, THE CONOITlON OF THIS OBLIGATION, if 'he Principal shall faithfully complete the Contrac,(s)
according to its terms and shall save the Monroe County NIP bannle.. .from all cost and cltaIg.. that m.y accroe on accoun' of the
doing of the Work specified a.nd shall pay all CO"" of enforcement of tile term. of 'he bond, if action is broogh' thereon, including
reasonable attorney's fee", C()tIIU and disbursc.mcnt~:l in any case in which such action ilS ~uccessfulJy maintained. or succes..tt.fully
appealed. and shall comply with the laws of the .tate appertaining to such Contraet(.), then d,is obligation ,h.1I be void but
otherwise it mall remain in full force and effect pu,,"u.nt to Florida StlllUtes.
Signed and ,ealed this 28th
day of
June
.20 06
IN THR PRESENCE OF,
KOCH
m
Name of Principal (Contolctor)
"; I
~.~.>
Lis ,Green wil11e..
,1
(S.al)
c.
President
GREAT AMERICAN INSURAliICE <XE>ANY
cSJ~~
DIANE L. PHELPS Witn..,., .
~{}.:i;i;.1i-~
(Seal)
CONSTRUCTION CONTRACTIBONDS
00500 - 5
GREAT AMERICAN INSURANCE COMPANY@
Administrative Office: 580 WALNUT STREET . CINCINNATI, OHIO 45202 . 513-369-5000 . FAX 513-723-2740
The numher of persons authorized hy
this power of attorney is not more than
Eight
No.O 18129
POWER OF ATTORNEY
KNOW ALL MEN BY THESE PRESENTS: That the GREAT AMERICAN INSURANCE COMPANY. a corporation organized and existing
under and by virtue of the laws of the State of Ohio. does hereby nominate. constitute and appoint the person or persons named below its true and lawful atlorncy-
in-facl. for it and in its name. place and stead to execute in behalf of the said Company. as surety. any and all honds. undertakings and contracts of suretyship. or
other written obligations in the nature thereof: provided thai the liability of the said Company on any such bond. undertaking or contract of suretyship executed
under this authority shall not exceed the limit stated below.
Steven M. Garrett
Name
Deborah A. Yates
Jeffrey A.Brown
Diane L. Phelps
Address
all of
Louisville, Kentucky
Limit of Power
all
Unlimited
William A. Kantlehner, III
Thomas J. Mitchell
Roger A. Neal Linda Kapfhammer
This Power of AUorney revokes all previous powers issued in behalf of the attorney(sl-in-fact named above.
IN WITNESS WHEREOF the GREAT AMERICAN INSURANCE COMPANY has caused these presents to be signed and attested by its appropriate
off1cers and its corporate seal hereunto affixed this 26th day of May . 2005
Attest GREAT AMERICAN INSURANCE COMPANY
STATE OF OHIO. COUNTY OF HAMILTON _ ss: DAVID C. KITCHIN (513-412-4602)
On this 26th day of May,2005 . before me personally appeared DAVID C. KITCHIN, to me known. being
duly sworn. deposes and says that he resides in Cincinnati. Ohio. that he is the Divisional Senior Vice President of the Bond Division of Greal American
Insurance Company. the Company described in and which executed the above instrument: that he knows the seal of the said Company: that the seal affixed to
the said instrument is such corporate seal: that it was so affixed by authority of his office under the By-Laws of said Company, and that he signed his name
therelo hy like authority.
This Power of Attorney is granted by authority of the following resolutions adopted by the Board of Directors of Great American Insurance Company
by unanimous written consent dated March I, 1993.
RESOLVED: Tha[ [he Divi.'i'io1} Presidenr, the set'eraf Dil'isiofl Vict' Presidenrs and Assistanr Vice Presidenrs, or tlll\' olle o{them, be and herel))' is
authori::ed, from time {O lime, to appoint one or more Attorneys-in-Fact to execute on beha(f (~f the Company, (/.1' surety. any a~ld all iHmds, ufldenakings ;lI1d
col1fracls (!lsllretyship, or other written obligations in the nature therel?f: /() prescribe their respectil'e duties and the respectil'e limits of rheir authority; and to
rel'oke {lny such apl'oillfment at any time.
RESOLVED FURTHER: Ihat the Company seal and rhe signature (l any of the afore.wid (~f{icers and any SecreTarv or Assistant Secretary (If the
Company may be affixed by Iac.l"imife to any power (l (/ftorney or certificate (l eirher given for the execl/fion of any bond. undertaking, contract or surety.I'hip.
or mher written obligation ill the nature {here(~f, such signa/lire {lnd seal when so used being hereby adopted by the Company (IS the original signature o{such
officer and the original seal of the Company, to be I'tdid and binding upon rhe Company with the s(/me fOIT'f;' and e.ffeet as though manllallv {lffixed.
CERTIFICATION
I. RONALD C. HAYES, Assistant Secretary of Great American Insurance Company. do hereby certify that (he foregoing Power of Attorney and the
Resolutions of the Hoard ()f Directors of March I. 1993 have not been revoked and are now in full force and effect.
Signed and sealed this
day of
S1029U (4-04)
ACORD CERTIFICATE OF LIABILITY INSURANCE I DATE
,. 06/20/2006
PRODUCER Garrett-Stotz Company THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION
ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE
6011 Brownsboro Park Blvd HOLDER. THIS CERTIFICATE DOES NOT AMEND, EXTEND OR
Suite B ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW.
Louisville KY 40207-1292 INSURERS AFFORDING COVERAGE
INSURED Koch Corporation INSURER A: Amerisure COffinanies
P. O. Box 4398 INSURER B: Amerisure Comnanies
Louisville KY 40204 INSURER c: Great American Insurance Comnanies
INSURER 0:
I INSURER E:
COVERAGES
THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING
ANY REQUIREMENT. TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR
MAY PERTAIN. THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS. EXCLUSIONS AND CONDITIONS OF SUCH
POLICIES. AGGREGATE LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS.
INSR TYPE OF INSURANCE POLICY NUMBER POLICY EFFECTIVE POLICY EXPIRAllON LIMITS
A ~NERAL UABIUTY CPP 1322729 12/31/2005 12/31/2006 EACH OCCURRENCE . 1,000,000
X COMMERCIAl GENERAL LIABILITY FIRE DAMAGE (An" onefirel . 100,000
I CLAIMS MADE [K] OCCUR MED EXP 14...., one narsonl . 5,000
- PERSONAL & ADV INJURY . 1,000,000
- GENERAL AGGREGATE . 2,000,000
~'L AGG:iY1E LIMIT APflS PER: PRODUCTS-COM~OPAGG . 2,000,000
POLICY X PRO- Loe
B .MITOMOBlLE LIABILITY CA 1322730 12/31/2005 12/3 1/2006 COMBINED SINGLE LIMIT 1.000,000
(Ea accident) .
- ANY AUTO
.x ALL OWNED AUTOS BODilY INJURY
4 (Per person) .
SCHEDULED AUTOS
X HIRED AUTOS
X BODilY INJURY .
NQN.QWNEO AUTOS (Per accident)
-
- PROPERTY DAMAGE .
(Per accident)
~RAGE LIABIUTY AUTO ONLY - fA ACCIDENT .
ANY AUTO OTHER THAN EA ACe .
AUTO ONLY: AGG .
B EXCESS lIABILITY CU 1322731 12/31/2005 12/31/2006 EACH OCCURRENCE . 5,000,000
~. OCCUR D CLAIMS MADE AGGREGATE . 5,000,000
.
=1 DEDUCTIBLE .
RETENTION . .
B WORKERS COMPENSATION AND WC 132177002 12/31/2005 12/31/2006 X 1.'X<;<~m~~ I IDJ~'
EMPLOYERS' L1AB1L1TY 100,000
E.L. EACH ACCIDENT .
E.L. DISEASE - EA EMPLOYEE $ 100,000
E.l. DISEASE - POLICY LIMIT . 500 000
OTHER
B EQUlP.FLOATER CPP 1322729 12/31/2005 12/31/2006 $80,000 PER ITEM & AGGREGATE
C BUILDERS RISK BINDER 07/01/2006 05/01/2007 LIMIT: $2,718,394.00
DESCRIPTION OF OPERATIONSlLOCATlONSNEHICLESJEXCLUSIONS ADDED BY ENDORSEMENT/SPECIAL PROVISIONS
ALL WORK INCLUDING MONROE COUNTY NOISE INSULATION PROGRAM (NIP), PROJECT NO.
AIP-3-12-0037-029-2006
CERTIFICATE HOLDER I X I ADDITIONAL INSURED- INSURER LETTER: A CANCELLATION
SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION
MONROE COUNTY BOARD OF COMMISSIONERS DATE THEREOF, THE ISSUING INSURER wtLL ENDEAVOR TO MAlL ~ DAYS WRITTEN
1100 SIMONTON ST.. RM 2-213 NOTICE TO THE CERTIFICATE HOLDER NAMED TO THE LEFT, BUT FAILURE TO 00 SO SHALL
KEY WEST FL 33040 IMPOSE NO OBLIGATION OR LIABILITY OF ANY KIND UPON THE INSURER, ITS AGENTS OR
REPRESENTATIVES.
AUTHORIZED REPRESENTATIVE ~Sl.n"#.A all
I
ACORD 25-S (7/97) (.At; ACORD CORPORATION 1988
IMPORTANT
If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must be endorsed. A statement
on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s).
If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may
require an endorsement. A statement on this certificate does not confer rights to the certificate
holder in lieu of such endorsement(s).
DISCLAIMER
The Certificate of Insurance on the reverse side of this form does not constitute a contract between
the issuing insurer(s), authorized representative or producer, and the certificate holder, nor does it
affirmatively or negatively amend, extend or alter the coverage afforded by the policies listed thereon.
ACORD 25-5 (7/97)
FROM :MUA FAX NO. :3052930678
• Jul. 11 2005 02:42PM P1
KEY WEST CONSTRUCTION SCHEDULE -PHASE 5
imams
Name ADDRESS Start finish
1 Smith 11b1 Seidenberg Kve 1122120a/ zi21 601
2 G`ritfvt 1909 Seidenberg Ave 1/22/2007 222007
3.Helzrnann r 1911 SeidenbertAve Unit A 1/292007 2/9/2007
4 HNEm•nn 1911 SeldenberkAve nit 8 1/29/2007 2/ W2007
%Pereira 1917 Seidenberg Ave 215/2007 2/16/2007
8 Simonlnl&Walsh 1924 Seidenberg Ave 2/5/2007 2/1612A07
7 Simonini 3 Walsh —'r 1925 Seldertierq Ave 2/1220071 2723/2007
8 Bradford 1922 SeldenberQAve 4 2/12/2007 2/23/2007 9 Bradford 1923 SerdenberVive 2/19/2007 3/2/2007
10 Men _ 106 Abtidenberp,ve 2/16/2t5tl7"'• 3/212007
11 Hansen 1907 Seldenbe�Ave /2007 11 3116/A7 '
12 Cahill 8 Reichert -1 1902 Seidenberg Ave 3/5/2007 ~ 3/16/2007
13 CaCaa iri8,Reichert ', 1955- Seidenberg Ave 311222007 3/21/27
14 Zerga _ 1401 lat St. _ 3/1 7 3/23/2007
15\7_srpa 1403 1st Si. 3/192007 3/30/2007
16rders 1416 131 S1. , 5119/2007 3/30/2007
17 e, alez 1419 let St. UrtitA 3/26/2007 4/6/2007
18 Gonzalez 1419 1st St. Unit C - 3/26/2007 - 4/AJ2007
19 Gorrsaiez 1900 1st St. 4/2/2007 4/132007
20'NWen 8 Spenbng 112V2 Staples-rve. 4J2?700T- 4/15/2007
21 Varela r le 1904 Stap Ave. + 4/1t32007 4/27/2 -
B�e+9141 1907 ^ Stapes Ave. _ 4/16/2007 4/272007
23 ke 1908 Staples Ave. 4/23/2007 5/412007_1
24 Gonzalez 1909 Stales Ave. — 4/2372007 5/4/2007
25 Maquiers 4- 1910 Staples Ave. Unit A 4/30/2007 5/11/2007
236 mere 1910 Staples Ave. Unit 6I. 4/302007 5/11/2007 +
ua ,
27 1.tsquiera ~ 1912 Staples Ave. Unit A 5/7/2007 5/18/2007
28 Magtiliera 1912 Staples.Ave. Un—it 8 6/7/2007 - 5/18/2007
29 Mendoze 1914 Stapes Ave. 5/14/2007 6/2b/2007
30 Ogoar j 1916 Aapl.e Ave. 5/14200r 5/25/,t6 ~
31 Lawrence 1918 Staples Ave. Unit A 5/Z8/Z007 6/gl0657
32 Lawrence 1918 Staples Ave Unit B 628/2007 6/872007
53 Lawrrtnce 1918 Staple►Ave. Unit C 8/4/2007 8/15/2007
34 Cordelle 1923 Staptet Ave. 6/4/2007 8/16/2007
35 BredfOrd 1408 2nd St. 0/112007 8/22/2007
36 Rondueles 1421 2r+d St l 6111/200? 5/222007
37 Rendu•les 1425 2rd St. 6118/2007 8/29/20011
38 Menge 2607 81vie6 Ave 6/18/2007 • 6/292007
39 JenicIns 2011 S Ave. 8/2512007 7/8/2007
401=to k 201r Staples Ave. &25 7" ' 7/6/2007 j
41 Cross 2019 SIq 4Ave. 7/9/2007 ` 7202007
42:Rojas 2022 Stapes Ave. Unit A/9 7/9/2007 720/2007
43 Rojes 2022 Stapes Ave. Unit C 7/15/2007 7272007
44 hi 2023 sea. • Ave. 7/18/2007 _ 727/2007
4 Lavin/Church 2027 Sta Ave. Unit A 7/23/1007 8/3/2007
46 LevinsChurth 2027 Ste•!es Ave. Una 8 7/23/7007 _ 8132007 ,
47 Collin 1921 FL.•ler Ave 7/30/2007 8/102007
48 Pine 200? Fl ler Ave Unit A 7 ► OM8/10/1007
4.9 Pine I 2007 ti jlorAve Unit8 8/6200 .7 7/2007
50 Pine 2007 l-iagler Ave 87312.07 . 7/2007
51 Galiano 2111 Fle9ler Ave 8/20 2007 Et/31007
52 oung 2203 Fla.ler Ave Unit A 8/202007 8/3112007
53 You 9 2208 Ft et Ave Unit B /27/2007 9/7/2007
54 Knowtes 2205 Fla ler Ave 8/27/2007 9/7 40'07
55 Koehn 1638 4tfi St. 9/322007 9/14/2007
58 Genova 1539 4th St. 8�32007 9114/2007
57 Busehe 1807 Venetian Cr. '� 3f1Qrr07 • 9721/2007
58 Hernandez 2807 Venn Dr. 9/10/2007 921/2067
59 i•tam!ltnn 2810 Venetian Jr Unit A, 0/17/2007 62612007
60 Harmon 2819 Venetian Dr. —nit B D/17/2001 ' 9/2812007
61 oWanasvick f704 danarnA Or. --.4, 97242007 1015/2007
ACORD CERTIFICATE OF LIABILITY INSURANCE I DATE
'" 06/20/2006
PRODUCER Garrett-Stotz Compatty THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION
ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE
60 II Brownsboro Park Blvd HOLDER. THIS CERTIFICATE DOES NOT AMEND, EXTEND OR
SuiteB ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW.
Louisville KY 40207-1292 INSURERS AFFORDING COVERAGE
INSURED Koch Corporation INSURER A: Arnerisure COffinanies
P. O. Box 4398 INSURER B: Amerisure Comnanies
Louisville KY 40204 INSURER c: Great American Insurance Comnanies
INSURER 0:
I INSURER E:
COVERAGES
THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING
ANY REQUIREMENT. TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR
MAY PERTAIN. THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH
POLICIES. AGGREGATE LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS.
INSR TYPE OF INSURANCE POLICY NUMBER POLICY EFFECnvE POLICY EXPIRAnDN LIMITS
A ~NERAL UABILlTY CPP 1322729 12/31/2005 1213112006 EACH OCCURRENCE $ 1,000,000
X COMMERCIAL GENERAL LIABILITY . FIRE DAMAGE IAnvonefire\ $ 100,000
I CLAIMS MADE [R] OCCUR MED EXP 16."" one ""'rsonl $ 5,000
- PERSONAL & ADV INJURY . 1,000,000
- GENERAL AGGREGATE . 2,000,000
~'L AGG~EOOE LIMIT APFt PER: PROOUCTS-COM~OPAGG . 2,000,000
POLICY X ~f.k'.; LOC
B -A!,lTOMOBlLE LIABILITY CA 1322730 12/31/2005 12/31/2006 COMBINED SINGLE LIMIT
(Eaaccident) . 1.000,000
X ANY AUTO
ALL OWNED AUTOS /1 .
= "'\M',~~ tA( j,~DIL Y INJURY $
~ SCHEDULED AUTOS ']V erperson)
~ HIRED AUTOS &~3D ~Qh BODILY INJURY
X (Per accident) .
NON-QWNED AUTOS .' v/
- PROPERTY DAMAGE $
,,, (Per aCCident)
~RAGE LIABILITY AUTO ONLY - EA ACCIDENT .
ANY AUTO OTHER THAN EAACC .
AUTO ONL V: AGG .
B ~ESS LIABILITY CU 1322731 12/31/2005 12/31/2006 EACH OCCURRENCE $ 5,000,000
X OCCUR D CLAIMS MADE AGGREGATE $ 5,000,000
$
==1 ~EDUCTIBLE $
RETENTION . .
B WORKERS COMPENSATION AND WC 132177002 12/31/2005 12/31/2006 X I T"X9.:!T~I.~~ I IOJ~-
EMPLOYERS' LIABILITY 100,000
EL EACH ACCIDENT .
E.L DISEASE - EA EMPLOYEE $ 100,000
E,L. DISEASE. POLICY LIMIT . 500,000
OTHER
B EQUIP.FLOATER CPP 1322729 12/31/2005 12/31/2006 $80,000 PER ITEM & AGGREGATE
C BUILDERS RISK BINDER 07/01/2006 05/01/2007 LIMIT: $2,718,394.00
DESCRIPTION OF OPERATIONSlLOCATlONSNEHICLES/EXCLUSIONS ADDED BY ENDORSEMENT/SPECIAL PROVISIONS
ALL WORK INCLUDING MONROE COUNTY NOISE INSULATION PROGRAM (NIP), PROJECT NO.
AIP-3-12-0037-029-2006
CERTIFICATE HOLDER I X I ADDITIONAL INSURED- INSURER LETTER: A CANCELLATION
SHOULD ANY OF THE ABOVE DESCRIBED PQUCIES BE CANCELLED BEFORE THE EXPIRATION
MONROE COUNTY BOARD OF COMMISSIONERS DATE THEREOF, THE ISSUING INSURER WILL ENDEAVOR TO MAil ~ CAYS WRnTEN
1100 SIMONTON ST.. RM 2-213 NOTICE TO THE CERTlACATE HOLDER NAMED TO THE lEFT, BUT FAILURE TO 00 SO SHALL
KEY WEST FL 33040 IMPOSE NO OBLIGATION OR L1AB1l1TY OF ANY KIND UPON THE INSURER, ITS AGENTS OR
REPRESENTATIVES.
AUTHORIZED REPRESENTATIVE ,,//jI \\ ,n/4J2,oO
I
ACORD 25-5 (7/97) C.@ACORD CORPORATION 1988